HomeMy WebLinkAboutT&M Electric Inc dba Perry Electric; 2016-03-29; PWM16-80TRAN\Q__;
RECORDED REQUESTED BY
CITY OF CARLSBAD
AND WHEN RECORDED PLEASE
MAIL TO:
City Clerk
City of Carlsbad
1200 Carlsbad Village Drive
Carlsbad, California 92008
DOC# 2016-0452120
I IIIII I IIIII IIIII 111111111111111 IIIII 11111111111111111111 IIIII 11111111
Aug 30, 2016 04:59 PM
OFFICIAL RECORDS
Ernest J. Dronenburg Jr
SAN DIEGO COUNTY RECORDER
FEES $0.00
PAGES 1
Space above this line for Recorder's use.
PARCEL NO: n/a -------------------
NOTICE OF COMPLETION
Notice is hereby given that:
1. The undersigned is owner of the interest or estate stated below in the property hereinafter described.
2. The full name of the undersigned is City of Carlsbad, a municipal corporation.
3. The full address of the undersigned is 1200 Carlsbad Village Drive, Carlsbad, California 92008.
4. The nature of the title of the undersigned is: In fee.
5. A work or improvement on the property hereinafter described was completed on July 29, 2016.
6. The name of the contractor for such work or improvement is T&M Electric, dba Perry Electric.
7. The property on which said work or improvement was completed is in the City of Carlsbad, County of
San Diego, State of California, and is described as follows: Project No. 6320 (PWM16-80TRAN),
Faraday Fiber Conduit Installation.
8. The street address of said property is on Faraday Avenue in the City of Carlsbad.
VERIFICATION OF CITY CLERK
I, the undersigned, say:
I am the City Clerk of the City of Carlsbad, 200 Carlsbad Village Drive, Carlsbad, California,
92008; the City Manager of said City on ~ , 20...l..le_, accepted the above
described work as completed and ordered that a Notice of Completion be filed.
I declare under penalty of perjury that the foregoing is true and correct.
Executed one\~ c2q , 20liL., at Carlsbad, California.
CITY OF CARLSBAD
,lll~J o Jla Q1s.~~ t:P~ BARBARA ENGLSO
City Clerk
Word\Masters\Forms\Notice of Completion (City) 3/9/98
CITY OF CARLSBAD
ACCEPTANCE OF PUBLIC IMPROVEMENTS
COMPLETION OF PUBLIC IMPROVEMENTS
The contractor has constructed the improvements required for Project No. 6320 (PWM 16-
80TRAN), Faraday Fiber Conduit Installation and has requested that the City of Carlsbad
accept the public improvements. City forces have inspected the public improvements and found
them to be satisfactory. The public improvements consist of:
IMPROVEMENTS VALUE
Fiber optic conduit $27,100
PUBLIC WORKS DIRECTOR CERTIFICATION OF COMPLETION OF IMPROVEMENTS
~ ~~ ~ ej;Jd&,-~,
¥Public ~t<)f~ ~atet
CITY MANAGER'S ACCEPTANCE OF PUBLIC IMPROVEMENTS
The construction of the above described public improvements is deemed complete and hereby
accepted. The City Clerk is hereby authorized to record the Notice of Completion and release
the bonds in accordance with State Law and City Ordinances.
is hereby directed to commence maintaining the above described
Date
APPROVED AS TO FORM:
CELIA BREWER, City Attorney
By:~
Deputy City Attorney
Word\Masters\Forms\Acceptance of Public Improvements (City) 3/9/98
PWM16-80TRAN
CITY OF CARLSBAD
MINOR PUBLIC WORKS CONTRACT
FARADAY FIBER CONDUIT INSTALLATION; CONT. NO. 6320
This agreement is made on the ~q~ day of \\c..~ , 2016, by the City
of Carlsbad, California, a municipal corporation, (hereinafter called "City"), and T&M Electric, Inc. dba Perry
Electric, a California corporation, whose principal place of business is 10765 Woodside Avenue, Suite B,
Santee, CA 92071 (hereinafter called "Contractor").
City and Contractor agree as follows:
DESCRIPTION OF WORK. Contractor shall perform all work specified in the Contract documents for the
project described by these Contract Documents (hereinafter called "Project").
PROVISIONS OF LABOR AND MATERIALS. Contractor shall provide all labor, materials, tools,
equipment, and personnel to perform the work specified by the Contract Documents unless excepted
elsewhere in this Contract.
CONTRACT DOCUMENTS. The Contract Documents consist of this Contract, exhibits to this Contract,
Contractor's Proposal, the Plans and Specifications, the General Provisions, addendum(s) to said Plans
and Specifications, and all proper amendments and changes made thereto in accordance with this Contract
or the Plans and Specifications, all of which are incorporated herein by this reference. When in conflict,
this Contract will supersede terms and conditions in the Contractor's proposal.
LABOR. Contractor will employ only skilled workers and abide by all State laws and City of Carlsbad
Ordinances governing labor.
GUARANTEE. Contractor guarantees all labor and materials furnished and agrees to complete the Project
in accordance with directions and subject to inspection approval and acceptance by:
Tam Tran. Traffic Systems Specialist
(City Project Manager)
WAGE RATES. The general prevailing rate of wages for each craft or type of worker needed to execute
the Contract shall be those as determined by the Director of Industrial Relations pursuant to Sections 1770,
1773 and 1773.1 of the Labor Code. Pursuant to Section 1773.2 of the Labor Code, a current copy of the
applicable wage rates is on file in the Office of the City Engineer. Contractor shall not pay less than the said
specified prevailing rates of wages to all workers employed by him or her in execution of the Contract.
Contractor shall be responsible for insuring compliance with provisions of section 1777.5 of the Labor Code
and section 4100 et seq. of the Public Contracts Code, "Subletting and Subcontracting Fair Practices Act."
The City Engineer is the City's "duly authorized officer'' for the purposes of section 4107 and 4107.5.
The provisions of Part 7, Chapter 1, of the Labor Code commencing with section 1720 shall apply to the
Contract for work.
A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the
requirements of Section 41 04 of the Public Contract Code, or engage in the performance of any contract
for public work, unless currently registered and qualified to perform public work pursuant to Section 1725.5.
This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations.
Contractor and any subcontractors shall comply with Section 1776 of the California Labor Code, which
generally requires keeping accurate payroll records, verifying and certifying payroll records, and making
them available for inspection. Contractor shall require any subcontractors to comply with Section 1776.
FARADAY FIBER CONDUIT
INSTALLATION; CONT. N0.6320 Page 1 of 7 City Attorney Approved 2/29/2016
PWM 16-SOTRAN
FALSE CLAIMS. Contractor hereby agrees that any contract claim submitted to the City must be asserted
as part of the contract process as set forth in this agreement and not in anticipation of litigation or in
conjunction with litigation.
Contractor acknowledges that California Government Code sections 12650 et seq., the False Claims Act,
provides for civil penalties where a person knowingly submits a false claim to a public entity. These
provisions include false claims made with deliberate ignorance of the false information or in reckless
disregard of the truth or falsity of the information.
The provisions of Carlsbad Municipal Code sections 3.32.025, 3.32.026, 3.32.027 and 3.32.028 pertaining
to false claims are incorporated herein by reference.
Contractor hereby acknowledges that the filing of a false claim may subject the Contractor to an
administrative debarment proceeding wherein the contractor may be prevented from further bidding on
public contracts for a period of up to five years and that debarment by another jurisdiction is grounds for
the City of Carlsbad to disqualify the Contractor or s ~tor from participating in contract bidding.
Signature: ·
,;
Print Name:
REQUIRED INSURANCE. The successful contractor shall provide to the City of Carlsbad, a Certification
of Commercial General Liability and Property Damage Insurance and a Certificate of Workers'
Compensation Insurance indicating coverage in a form approved by the California Insurance Commission.
The certificates shall indicate coverage during the period of the contract and must be furnished to the City
prior to the start of work. The minimum limits of liability insurance are to be placed with California admitted
insurers that have a current Best's Key Rating of not less than "A-:VII"; OR with a surplus line insurer on
the State of California's List of Approved Surplus Line Insurers (LASLI) with a rating in the latest Best's Key
Rating Guide of at least "A:X"; OR an alien non-admitted insurer listed by the National Association of
Insurance Commissioners (NAIC) latest quarterly listings report.
Commercial General Liability Insurance of Injuries including accidental death, to any one person in an
amount not less than ........ $1 ,000,000
Subject to the same limit for each person on account of one accident in an amount not less than
....... $1 ,000,000
Property damage insurance in an amount of not less than ........ $1 ,000,000
Automobile Liability Insurance in the amount of $1 ,000,000 combined single limit per accident for bodily
injury and property damage. In addition, the auto policy must cover any vehicle used in the performance of
the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-
scheduled. The automobile insurance certificate must state the coverage is for "any auto" and cannot be
limited in any manner.
The above policies shall have non-cancellation clauses providing that thirty (30) days written notice shall
be given to the City prior to such cancellation.
The policies shall name the City of Carlsbad as an additional insured. The full limits available to the named
insured shall also be available and applicable to the City as an additional insured.
WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY. Workers' Compensation limits as
required by the California Labor Code. Workers' Compensation will not be required if Contractor has no
employees and provides, to City's satisfaction, a declaration stating this.
INDEMNITY. The Contractor shall assume the defense of, pay all expenses of defense, and indemnify and
hold harmless the City, and its officers and employees, from all claims, loss, damage, injury and liability of
every kind, nature and description, directly or indirectly arising from or in connection with the performance
FARADAY FIBER CONDUIT
INSTALLATION; CONT. N0.6320 Page 2 of 7 City Attorney Approved 2/29/2016
PWM 16-SOTRAN
of the Contract or work; or from any failure or alleged failure of Contractor to comply with any applicable
law, rules or regulations including those related to safety and health; and from any and all claims, loss,
damages, injury and liability, howsoever the same may be caused, resulting directly or indirectly from the
nature of the work covered by the Contract, except for loss or damage caused by the sole or active
negligence or willful misconduct of the City. The expenses of defense include all costs and expenses
including attorneys' fees for litigation, arbitration, or other dispute resolution method.
JURISDICTION. The Contractor agrees and hereby stipulates that the proper venue and jurisdiction for
resolution of any disputes between the parties arising out of this agreement is San Diego County,
California.
Start Work: Contractor agrees to start within thirty (30) calendar days after receipt of Notice to Proceed.
Completion: Contractor agrees to complete work within fourteen (14) calendar days after receipt of
Notice to Proceed.
CONTRACTOR'S INFORMATION.
T&M Electric, Inc, dba Perry Electric
(name of Contractor)
747931
(Contractor's license number)
C1 0-Eiectrical I Exp. 4/30/2016
(license class. and exp. date)
'100000'12332
(DIR registration number)
06/30/2016
(DIR registration exp. date)
/II
/II
/II
/II
/II
/II
/II
/II
FARADAY FIBER CONDUIT
INSTALLATION; CONT. N0.6320
10765 Woodside Av, Ste 8
(street address)
Santee, CA 92071
(city/state/zip)
619-449-0045
(telephone no.)
619-449-0511
(fax no.)
arivera@perryelectricsd.com
(e-mail address)
Page 3 of7 City Attorney Approved 2/29/2016
PWM 16-SOTRAN
EXHIBIT A
LISTING OF SUBCONTRACTORS BY GENERAL CONTRACTOR
Set forth below is the full name and location of the place of business of each sub-contractor whom the
Contractor proposes to subcontract portions of the Project in excess of one-half of one percent of the total
bid, and the portion of the Project which will be done by each sub-contractor for each subcontract.
NOTE: The Contractor understands that if it fails to specify a sub-contractor for any portion of the Project
to be performed under the contract in excess of one-half of one percent of the bid, the contractor
shall be deemed to have agreed to perform such portion, and that the Contractor shall not be
permitted to sublet or subcontract that portion of the work, except in cases of public emergency or
necessity, and then only after a finding, reduced in writing as a public record of the Awarding
Authority, setting forth the facts constituting the emergency or necessity in accordance with the
provisions of the Subletting and Subcontracting Fair Practices Act (Section 4100 et seq. of the
California Public Contract Code).
If no subcontractors are to be employed on the project, enter the word "NONE."
SUBCONTRACTORS
Portion of Project to Business Name and Address DIR Registration
be Subcontracted
~ Total% Subcontracted: ___ '±_......_ __ _
FARADAY FIBER CONDUIT
INSTALLATION; CONT. N0.6320
No.
Page 5 of7
License No., %of
Classification & Total
Expiration Date Contract
City Attorney Approved 2/29/2016
EXHIBIT B
EXECUTED IN TRIPLICATE
BOND NO. 2202068
PREMIUM: $281.00 PWM16 SOTRAN
PREMIUM IS FOR CONTRACT TERM -
AND IS SUBJECT TO ADJUSTMENT
BASED ON FINAL CONTRACT PRICE
LABOR AND MATERIALS BOND
WHEREAS, the City Council of the City of Carlsbad, State of California, has awarded to T&M Electric, Inc.
dba Perry Electric (hereinafter designated as the "Principal"), a Contract for:
FARADAY FIBER CONDUIT INSTALLATION
CONTRACT NO. 6320
in the City of Carlsbad, in strict conformity with the drawings and specifications, and other Contract
Documents now on file in the Office of the City Clerk of the City of Carlsbad and all of which are incorporated
herein by this reference.
WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the
furnishing of a bond, providing that if Principal or any of its subcontractors shall fail to pay for any materials,
provisions, provender or other supplies or teams used in, upon or about the performance of the work agreed
to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same to
the extent hereinafter set forth.
NOW, THEREFORE, WE, T&M Electric, Inc. dba Perry Electric, as Principal, (hereinafter designated as
the "Contractor"), and NORTH AMERICAN SPECIALTY INSURANCE COMPANY as
Surety, are held firmly bound unto the City of Carlsbad in the sum of twenty eight thousand eight hundred
fifty six dollars and twenty five cents ($28,856.25), said sum being an amount equal to: One hundred percent
(1 00%) of the total amount payable under the terms of the Contract by the City of Carlsbad, and for which
payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors,
or assigns, jointly and severally, firmly by these presents.
THE CONDITION OF THIS OBLIGATION IS SUCH that if the Contractor or his/her subcontractors fail to
pay for any materials, provisions, provender, supplies, or teams used in, upon, for, or about the performance
of the work contracted to be done, or for any other work or labor thereon of any kind, consistent with
California Civil Code section 9100, or for amounts due under the Unemployment Insurance Code with
respect to the work or labor performed under this Contract, or for any amounts required to be deducted,
withheld, and paid over to the Employment Development Department from the wages of employees of the
contractor and subcontractors pursuant to section 13020 of the Unemployment Insurance Code with
respect to the work and labor, that the Surety will pay for the same, and, also, in case suit is brought upon
the bond, reasonable attorney's fees, to be fixed by the court consistent with California Civil Code section
9554.
This bond shall inure to the benefit of any of the persons named in California Civil Code section 9100, so
as to give a right of action to those persons or their assigns in any suit brought upon the bond.
Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the
Contract, or to the work to be performed hereunder or the specifications accompanying the same shall
affect its obligations on this bond, and it does hereby waive notice of any change, extension of time,
alterations or addition to the terms of the contract or to the work or to the specifications.
FARADAY FIBER CONDUIT
INSTALLATION; CONT. N0.6320 Page 6 of 7 City Attorney Approved 2/29/2016