Loading...
HomeMy WebLinkAboutCollier Construction; 2018-03-30; PWS18-121TRANRECORDED REQUESTED BY CITY OF CARLSBAD DOC# 2018-0299270 111111111111 lllll 111111111111111111111111111111 IIIII IIIII IIIII IIII IIII Jul 23, 2018 03:14 PM OFFICIAL RECORDS Ernest J. Dronen burg, Jr, AND WHEN RECORDED PLEASE MAIL TO: SAN DIEGO COUNTY RECORDER FEES $0.00 (SB2 Atkins $0.00) City Clerk City of Carlsbad 1200 Carlsbad Village Drive Carlsbad, California 92008 PAGES 1 Space above this line for Recorder's use. PARCEL NO: n/a ~~-------- NOTICE OF COMPLETION Notice is hereby given that: 1. The undersigned is owner of the interest or estate stated below in the property hereinafter described. 2. The full names of the undersigned are City of Carlsbad, a municipal corporation. 3. The full address of the undersigned is 1200 Carlsbad Village Drive, Carlsbad, California 92008. 4. The nature of the title of the undersigned is: In fee. 5. A work or improvement on the property hereinafter described was completed on June 14, 2018. 6. The name of the contractor for such work or improvement is Collier Construction. 7. The property on which said work or improvement was completed is in the City of Carlsbad, County of San Diego, State of California, and is described as follows: Project No. 3896, Beach Access Stairway Repair at Sycamore Ave. 8. The street address of said property is at Sycamore Ave., in the City of Carlsbad. VERIFICATION OF CITY CLERK I, the undersigned, say: I am the City Clerk of the City of Carlsbad, 1200 Carlsbad Village Drive, Carlsbad, California, 92008; the City Manager of said City on ~ Q~S , 20 /'8, accepted the above described work as completed and ordered that a Notice of mpletion be filed. I declare under penalty of perjury that the foregoing is true and correct. Executed onJtJ(S 9 , 20/8, at Carlsbad, California. C~Y OF CARLSBAD ~~ ~BARBARA ENGLESON [;r City Clerk Q \Public Works\PW Common\CAPITAL-ACTIVE\3896 Beach Access Stairway Repair at Sycamore Avenue\NOC (Public and Private) -revised 2018-02-27.doc CITY OF CARLSBAD ACCEPTANCE OF PUBLIC IMPROVEMENTS COMPLETION OF PUBLIC IMPROVEMENTS Collier Construction has completed the contract work required for Project No. 3896, Beach Access Stairway Repair at Sycamore Ave. City forces have inspected the work and found it to be satisfactory. The work consisted of: Stairway repair IMPROVEMENTS (Specify if City or CMWD) VALUE $114,757 CERTIFICATION OF COMPLETION OF IMPROVEMENTS Date 7 CITY MANAGER'S ACCEPTANCE OF PUBLIC IMPROVEMENTS The construction of the above described contract is deemed complete and hereby accepted. The City Clerk is hereby authorized to record the Notice of Completion and release the bonds in accordance with State Law and City Ordinances. directed to commence maintaining the above described Kevi ~f APPROVED AS TO FORM: CELIA BREWER, City Attorney By:~~---- Deputy City Attorney Date Q \Pubhc Works\PW Common\CAPITAL-ACTIVE\3896 Beach Access Sta11way Repair at Sycamore Avenue\API (Public Works) -revised 2018-02-15.doc CITY OF CARLSBAD San Diego County California CONTRACT DOCUMENTS, GENERAL PROVISIONS, SUPPLEMENT AL PROVISIONS, AND TECHNICAL SPECIFICATIONS FOR BEACH ACCESS STAIRWAY REP AIR AT SYCAMORE A VE CONTRACT NO. 3896 BID NO. PWS18-121TRAN l' • ., Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 1 of 101 Pages March 14, 2018 ADDENDUM NO. 2 ( City of Carlsbad RE: BEACH ACCESS STAIRWAY REPAIRS ATSYCAMORE AVE BID NO.PWS18-121TRAN Please include the attached addendum in the Notice to Bidder/Request for Bids you have for the above project. This addendum--receipt acknow\edged--must be included to your bid when your bid is submitted. ;;) ' . ;f""'"'77 -/ // i~f:> /Luk. l/<~c/t,,.._x: ___ , · ida Felix Yackel // Senior Contract Administrator I ACKNOWLEDGE RECEIPT OF ADDENDUM NO. 2 Public Works Contract Administration 1635 Faraday Avenue DCarlsbad, CA 92008 D760-602-4677 t From: No. of Pages: Date: Bid Opening Date: NOTICE CITY OF CARLSBAD BEACH ACCESS STAIRWAY REPAIRS AT SYCAMORE A VE BID NO. PWS18-121TRAN Addendum No. 2 Eleida Felix Yackel, Senior Contract Administrator Phone: 760-602-2767 1635 Faraday Ave Carlsbad, CA 92008 4 (including thispage) March 14, 2018 Remains the same -March 20, 2018 -11 a.m. The following changes to the Contract Documents are hereby made effective as though originally issued with the bid package. Bidders are reminded that all previous requirements to this solicitation remain in full force and effect. Contractor must acknowledge receipt of this Addendum on the Bid Form. Failure to do so may subject bidder to disqualification. 1. To ADDENDUM NO.1, DELETE sheet 77(A), 77(8) AND 78, DELETE in their entirety and SUBSTITUTE with sheet 77(A), 77(8) and 78 of this Addendum No. 2. For clarity where applicable, ADDITIONS, if any, have been Underljned and DELETIONS, if any, have been Strisken out. Addendum No.2-PWS18-121TRAN-ContractNo. 3896 6-7 TIME OF COMPLETION. 6-7.1 General. The Contractor shall complete the Work within the time set forth in the Contract. The Contractor shall complete each portion of the Work within such time as set forth in the Contract for such portion. The time of completion of the Contract shall be expressed in working days. The Contractor shall diligently prosecute the work to completion within thjrtv-fjye {35) working days after the starting date specified in the Notice to Proceed. 6-7.2 Working Day. A working day is any day within the period between the start of the Contract time as defined in Section 6-1 and the date provided for completion, or upon field aeeeptanee by the Engineer for all work provided for in the Contrast, whiehever oeeurs first, other than: 1. Saturday 2. Sunday 3. any day designated as a holiday by the Agency, 4. any other day designated as a holiday in a Master Labor Agreement entered into by the Contractor or on behalf of the Contractor as an eligible member of a contractor association, 5. any day the Contractor is prevented from working at the beginning of the workday for cause as defined in Section 6-6.1, 6. any day the Contractor is prevented from working during the first 5 hours with at least 60 percent of the normal work force for cause as defined in Section 6-6.1. Unless superseded by the above paragraphs or the approved Traffic Control Plan, the hours of work shall be between the hours of 7:00 a.m. and 4:00 p.m. The Contractor shall obtain the written approval of the Engineer if the Contractor desires to work outside said hours, days, and/or holidays. This written permission must be obtained at least 48 hours prior to such work The Engineer may approve work outside the hours and/or days stated herein when, in his/her sole opinion, such work conducted by the Contractor is beneficial to the best interests of the Agency. The Contractor shall pay the inspection costs of such work. The Contractor shall incorporate the dates, areas and types of work prohibited in this section in the Construction Schedule required by Section 6.1. No additional payment, adjustment of bid prices or adjustment of contract time of completion will be allowed as a consequence of the prohibition of work being performed within the dates, areas and/or types of work prohibited in this section. 6-7.3 Contract Time Accounting. The Engineer will make a daily determination of each working day to be charged against the Contract time. These determinations will be discussed and the Contractor will be furnished a periodic statement showing allowable number of working days of Contract time, as adjusted, at the beginning of the reporting period. The statement will also indicate the number of working days charged during the reporting period and the number of working days of Contract time remaining. If the Contractor does not agree with the statement, it shall file a written protest within 15 days after receipt, setting forth the facts of the protest. Otherwise, the statement will be deemed to have been accepted. 6-8 COMPLETION, ACCEPTANCE, AND WARRANTY. The Work will be inspeeted by the Engineer for aooeptanoe upon reoeipt of the Contraotor's wri"en assertion that the 'l\lorl< has been ooR'lpleteel. The Engineer will not aooept the 'l'lorl< or any portion of the 'l'lork before all of the Work is oompleted and all outstanding defieieneies that may m<ist are eorreeted by the Contraotor and the Engineer is satisfied that all the materials and workR'lanship, and all other features of the 1/IJork, R'leet the requirements of all of the speeifieations for the Work. Use, temporary, interim or permanent, of all, or portions of, the \11.'ork does not eonstitute aeeeptanee of the Work. If, in the Engineer's judgment, the 'Nork has been eompleted and is ready for aeeeptanee the Engineer will so eertify to the Board. Upon sueh eertifieation by the Engineer the Board may aeeept the eompleted Work. Upon the Board's aeeeptanee of the 'Nork the Engineer will eause a "Notiee of Completion" to be filed in the offiee of the San Diego County Reeorder. The date of reeordation shall be the date of eompletion of the Work. l'\ •,; Revised 2/27 /18 Addendum No. 2-PWS 18-12 HRAN-Contract No. 3896 Page 77(A) of 101 Pages All work shall be warranted for one (1) year after reoordation of the "Notice of Completion" and any fa1:Jlty work or materials discovered dl:lring the ·,varranty period shall be repaired or replaced by the Contraster, at its mEpense. Twenty five percent of the faithful performance bond shall be retained as a vtarranty bond for the one year warranty period. The Contraster shall replace or repair any Sl:lGh defective work in a manner satisfactory to the Engineer, after notice to do so from the Engineer, and within the time specified in the notioe. lfthe Contraotorfails to make Sl:lGh replacement or repairs within the time specified in the notice, the Agonoy may perform this work and the Contractor's Sl:lreties shall be liable for the oostthereof. 6-8.1 Request for Final Walk-Through. With Inspector's approval. the Contractor may submit written assertion in the form of a Request for Final Walk-Through Letter that the Work is substantially complete and that the Work is ready for inspection. 6-8.2 Final Walk-Through. Upon receipt of the Request for Final Walk-Through Letter, the Inspector will then schedule the Final Walk-Through to occur within the next five working days. Prior to the Final Walk-Through, the Inspector will meet individually with each private property owner and will compile any deficiencies noted by the property owners. The Contractor, Agency, Engineer, Inspector, and Construction Manager shall be present at the Final Walk- Through and all outstanding deficiencies shall be included in a List of Deficiencies. A review of the red-line record drawings shall also be completed at this time and all deficiencies will also be included in the List of Deficiencies. 6-8.3 List of Deficiencies. Following the Final Walk-Through, the Inspector will generate the List of Deficiencies {also known as the punch list) within three working days. The Contractor shall then address the List of Deficiencies and shall provide a written response to each punch list item. 6-8.4 Request for Final Inspection. Once the punch list is completed and with the Inspector's approval. the Contractor may submit written assertion in the form of a Request for Final Inspection, certifying that all listed deficiencies have been addressed and request a Final Inspection to demonstrate project completion to the Agency. The Contractor shall provide an attachment to the Request for Final Inspection with the Contractor's written response to each deficiency. The Request for Final Inspection shall not be considered complete without the Contractor's written response to each deficiency. 6-8.5 Final Inspection. Upon receipt of the Request for Final Inspection, the Inspector shall schedule the Final Inspection within three business days. The Inspector and Contractor shall be present at the final inspection. The Agency, Engineer, and Construction Manager reserve the right to be present at the Final Inspection. The red-line record drawings shall also be inspected to verify all deficiencies were addressed. If any deficiencies are not satisfactorily addressed, the process shall be repeated, starting with Section 6-8.3. 6-8.6 Request for Completion. The Engineer will not accept the Work or any portion of the Work before all of the Work is completed and all outstanding deficiencies that may exist are corrected by the Contractor and the Engineer is satisfied that all the materials and workmanship, and all other features of the Work, meet the requirements of all of the specifications for the Work. Once the Final Inspection has been completed and all outstanding deficiencies satisfactorily completed to Agency's approval, the Contractor shall submit a written assertion in the form of Request for Completion letter, certifying that the Work has been completed. 6-8. 7 Completion. Upon receipt of the Request for Completion letter, the Agency shall review the written assertion within 2 business days. If, in the Engineer's judgment, the Work has been completed in accordance with the Contract Documents, the Engineer will issue a Completion Letter. The date of completion shall be the date that the Completion Letter is issued by the Agency, conditional upon the Contractor demobilizing and ceasing all on-site labor within two business days. l' •ff Revised 2/27/18 Addendum No.2-PWS18-121TRAN-Contract No. 3896 Page 77(8) of 101 Pages If the Contractor does not fully demobilizes and cease on-site labor accordingly, the Agency may revise the date of Completion to be the date which the Contractor has fully demobilized and has ceased all on-site labor. The completion date will be the date to which incentive and liquidated damages will be computed. Use, temporary, interim or permanent, of all, or portions of. the Work does not constitute completion or acceptance of the Work. 6-8.8 Acceptance. Acceptance will occur after all of the requirements contained in the Contract Documents have been fulfilled. If, in the Engineer's judgment, the Contractor has fully performed the Contract, the Engineer will so certify to the Board. Upon such certification by the Engineer the Board may accept the Work. Upon the Board's acceptance of the Work the Agency will cause a "Notice of Completion" to be filed in the office of the San Diego County Recorder. The date of recordation shall be the date of acceptance of the Work. 6-8.9 Warranty. All work shall be warranted for one (1) year after acceptance of the Work and any faulty work or materials discovered during the warranty period shall be repaired or replaced by the Contractor, at its expense. Twenty-five percent of the faithful performance bond shall be retained as a warranty bond for the one year warranty period. The Contractor shall replace or repair any such defective work in a manner satisfactory to the Engineer. after notice to do so from the Engineer, and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice. the Agency may perform this work and the Contractor's sureties shall be liable for the cost thereof. 6-9 LIQUIDATED DAMAGES. Failure of the Contractor to complete the Work within the time allowed will result in damages being sustained by the Agency. For each consecutive calendar day in excess of the time specified for completion of Work, as adjusted in accordance with Section 6-6, the Contractor shall pay the Agency, or have withheld monies due it, the sum of five hundred dollars ($500) Such sum is liquidated damages and shall not be construed as a penalty. and may be deducted from payments due the Contractor if such delay occurs. Execution of the Contract shall constitute agreement by the Agency and Contractor that five hundred dollars ($500) per day is the minimum value of costs and actual damages caused by the Contractor to complete the Work within the allotted time. Any progress payments made after the specified completion date shall not constitute a waiver of this paragraph or of any damages. 6-10 USE OF IMPROVEMENT DURING CONSTRUCTION. The Agency reserves the right to take over and utilize all or part of any completed facility or appurtenance. The Contractor will be notified in writing in advance of such action. Such action by the Agency will relieve the Contractor of responsibility for injury or damage to said completed portions of the improvement resulting from use by public traffic or from the action of the elements or from any other cause. except Contractor operations or negligence. The Contractor will not be required to reclean such portions of the improvement before field acceptance. except for cleanup made necessary by its operations. Nothing in this section shall be construed as relieving the Contractor from full responsibility for correcting defective work ormaterials. In the event the Agency exercises its right to place into service and utilize all or part of any completed facility or appurtenance. the Agency will assume the responsibility and liability for injury to persons or property resulting from the utilization of the facility or appurtenance so placed into service, except for any such injury to persons or property caused by any willful or negligent act or omission by the Contractor, Subcontractor, their officers, employees, or agents. 6-11 INCENTIVE. For each and every working day that the work is completed prior to May 26, 2018, the Contractor will receive an incentive payment totaling one thousand ($1,000) per working day. The total incentive payment will not exceed $10,000. Completion of the Work shall be subject to Section 6-8. SECTION 7-RESPONSIBILITIES OF THE CONTRACTOR 7-1 CONTRACTOR'S EQUIPMENT AND FACILITIES. The Contractor shall furnish and maintain in good condition all equipment and facilities as required for the proper execution and inspection of the Work. Such equipment and facilities shall meet all requirements of applicable ordinances and laws. t., •'I Revised 2/27/18 Addendum No.2-PWS18-121TRAN-Contract No. 3896 Page 78 of 101 Pages March 13, 2018 ADDENDUM NO. 1 RE: BEACH ACCESS STAIRWAY REPAIRS AT SYCAMORE AVE BID NO. PWS18-121TRAN (city of Carlsbad Please include the attached addendum in the Notice to Bidder/Request for Bids you have for the above project. This addendum--receipt acknowledged--must be included to your bid when your bid is submitted. -;~~/ ff..uk. l;/;'.£-fu_-<.__ ... · ~ -' //JI/ / /".< ·· leida Felix Yackel j Senior Contract Administrator I ACKNOWLEDGE RECEIPT OF ADDENDUM NO. 1 Bidder's Signature Public Works Contract Administration 1635 Faraday Avenue I Carlsbad, CA 92008 I 760-602-4677 t From: No. of Pages: Date: Bid Opening Date: NOJICE CITY OF CARLSBAD BEACH ACCESS STAIRWAY REPAIRS AT SYCAMORE A VE BID NO. PWS18-121TRAN Addendum No. 1 Eleida Felix Yackel, Senior Contract Administrator Phone: 760-602-2767 1635 Faraday Ave Carlsbad, CA 92008 4 (including this page) March 13, 2018 Remains the same -March 20, 2018 -11 a.m. The following changes to the Contract Documents are hereby made effective as though originally issued with the bid package. Bidders are reminded that all previous requirements to this solicitation remain in full force and effect. Contractor must acknowledge receipt of this Addendum on the Bid Form. Failure to do so may subject bidder to disqualification. 1. To the GENERAL PROVISIONS, DELETE sheet 77 and 78 of 101, DELETE in their entirety and SUBSTITUTE with sheet 77(A), 77(8) and 78 of this Addendum. For clarity where applicable, ADDITIONS, if any, have been Underlined and DELETIONS, if any, have been Strisken out. 2. BIDDER's QUESTIONS Q1. Will the engineer or PM clearly mark which treads are being replaced and which ones are re-used to avoid confusion?They are all so corroded, it is difficult to tell one from another in the field. A 1. The concrete treads to be re-used or replaced are clearly identified on the plans. Q2. After the metal plate is installed, the treads will have to be 1/5" narrower. A2. Contractor must field measure each tread prior to ordering or fabricating any material. Tread lengths must be approved by the Engineer prior to fabrication. Q3. Does the city want the angles replaced for the treads being "cleaned"? A3. Yes. All the treads (new and re-used) will require new angles. This is shown on the plans, and accounted for in the bid items. Q4. When the city says "clean treads" do they mean clean metal angles? A4. No. The term "treads" refers to the concrete steps, not the metal angles that connect the concrete steps to the steel stringer. The metal angles are corroded, therefore they will all be replaced. QS. From the prints, it looks like the entire stair way steel structure where the metal angles are needs to be cleaned. Is this the case? A5. Contractor's attention is directed to Section 9-4 (Bid Item No. 5, Clean and Paint Structural Steel) and Section 310. Q6. Does the city want a gate for the fence for access? Doe the fence need to be surface mounted or sand bags. A6. The fencing is to secure and contain the project site. The project site is to be accessible to the city's inspector at all times. Addendum No.1-PWS18-121TRAN-Contract No. 3896 6-7 TIME OF COMPLETION. 6-7 .1 General. The Contractor shall complete the Work within the time set forth in the Contract. The Contractor shall complete each portion of the Work within such time as set forth in the Contract for such portion. The time of completion of the Contract shall be expressed in working days. The Contractor shall diligently prosecute the work to completion within thirty-five (35) working days after the starting date specified in the Notice to Proceed. 6-7.2 Working Day. A working day is any day within the period between the start of the Contract time as defined in Section 6-1 and the date provided for completion, or upon fielEI aooeptanoe by the Engineer for all work pro¥iEleEI for in the Contrast, 1Nhiohever ooours first, other than: 1. Saturday 2. Sunday 3. any day designated as a holiday by the Agency, 4. any other day designated as a holiday in a Master Labor Agreement entered into by the Contractor or on behalf of the Contractor as an eligible member of a contractor association, 5. any day the Contractor is prevented from working at the beginning of the workday for cause as defined in Section 6-6.1, 6. any day the Contractor is prevented from working during the first 5 hours with at least 60 percent of the normal work force for cause as defined in Section 6-6.1. Unless superseded by the above paragraphs or the approved Traffic Control Plan, the hours of work shall be between the hours of 7:00 a.m. and 4:00 p.m. The Contractor shall obtain the written approval of the Engineer if the Contractor desires to work outside said hours, days, and/or holidays. This written permission must be obtained at least 48 hours prior to such work The Engineer may approve work outside the hours and/or days stated herein when, in his/her sole opinion, such work conducted by the Contractor is beneficial to the best interests of the Agency. The Contractor shall pay the inspection costs of such work. The Contractor shall incorporate the dates, areas and types of work prohibited in this section in the Construction Schedule required by Section 6.1. No additional payment, adjustment of bid prices or adjustment of contract time of completion will be allowed as a consequence of the prohibition ofwork being performed within the dates, areas and/or types of work prohibited in this section. 6-7.3 Contract Time Accounting. The Engineer will make a daily determination of each working day to be charged against the Contract time. These determinations will be discussed and the Contractor will be furnished a periodic statement showing allowable number of working days of Contract time, as adjusted, at the beginning of the reporting period. The statement will also indicate the number of working days charged during the reporting period and the number of working days of Contract time remaining. If the Contractor does not agree with the statement, it shall file a written protest within 15 days after receipt, setting forth the facts of the protest. Otherwise, the statementwill be deemed to have been accepted. 6-8 COMPLETION, ACCEPTANCE, AND WARRANTY. The Work will be inspeoteEI by the Engineer for aoooptanoo upon receipt of the Contractor's written assertion that tho \'\fork has boon oomplotoEI. The Engineer will not aooept tho 1Nork or any portion of the \11lork before all of the 1Nork is oompleteEI anEI all outstanEling Elefioienoies that may mEist are oorreoteEI by the Contractor anEI the Engineer is satisfies that all the materials and workmanship, anEI all other features of tho Work, moot tho requirements of all of tho spooifioations for the Work. Use, temporary, interim or permanent, of all, or portions of, the 1Nork does not constitute aoooptanoo of tho 1Nork. If, in tho Engineer's juElgmont, tho \'\fork has boon oomplotoEI anEI is roaay for aoooptanoo tho Engineer will so certify to the Boan;!. Upon such oertifioation by tho Engineer the BoarEI may aooopt tho completed Work. Upon tho BoarEl's aooeptanoo of tho 1Nork tho Engineer will cause a "Notice of Completion" to be filed in tho office of tho San Diogo County RooorElor. Tho date of rooordation shall be tho date of completion of the Work. ('\ -~ Revised 2/27/18 Addendum No.1-PWS18-121TRAN-Contract No. 3896 Page 77(A) of 101 Pages All work shall be warranted for one (1) year after reeordation of the "Notiee of Completion" and any fa1:1lty work or materials diseo•,ered during the warranty period shall be repaired or replaeed by the Contraetor, at its mEpense. T>.venty fi11e pereent of the faithf1:1I performanee bond shall be retained as a warranty bond for the one year warranty period. The Contraetor shall replaee or repair any sueh defeetive work in a manner satisfaetory to the Engineer, after notiee to do so from the Engineer, and within the time speeified in the notiee. If the Contraetorfails to make s1:1eh replaeement or repairs within the time speeified in the notiee, the Agonoy may perform this work and the Contraetor's s1:1reties shall be liable for the eost thereof. 6-8.1 Request for Final Walk-Through. With Inspector's approval, the Contractor may submit written assertion in the form of a Request for Final Walk-Through Letter that the Work is substantially complete and that the Work is ready for inspection. 6-8.2 Final Walk-Through. Upon receipt of the Request for Final Walk-Through Letter, the Inspector will then schedule the Final Walk-Through to occur within the next five working days. Prior to the Final Walk-Through, the Inspector will meet individually with each private property owner and will compile any deficiencies noted by the property owners. The Contractor. Agency, Engineer. Inspector, and Construction Manager shall be present at the Final Walk- Through and all outstanding deficiencies shall be included in a List of Deficiencies. A review of the red-line record drawings shall also be completed at this time and all deficiencies will also be included in the List of Deficiencies. 6-8.3 List of Deficiencies. Following the Final Walk-Through, the Inspector will generate the List of Deficiencies (also known as the punchlist) within three working days. The Contractor shall then address the List of Deficiencies and shall provide a written response to each punchlist item. 6-8.4 Request for Final Inspection. Once the punchlist is completed and with the Inspector's approval, the Contractor may submit written assertion in the form of a Request for Final Inspection, certifying that all listed deficiencies have been addressed and request a Final Inspection to demonstrate project completion to the Agency. The Contractor shall provide an attachment to the Request for Final Inspection with the Contractor's written response to each deficiency. The Request for Final Inspection shall not be considered complete without the Contractor's written response to each deficiency. 6-8.5 Final Inspection. Upon receipt of the Request for Final Inspection, the Inspector shall schedule the Final Inspection within three business days. The Inspector and Contractor shall be present at the final inspection. The Agency. Engineer. and Construction Manager reserve the right to be present at the Final Inspection. The red-line record drawings shall also be inspected to verify all deficiencies were addressed. If any deficiencies are not satisfactorily addressed. the process shall be repeated. starting with Section 6-8.3. 6-8.6 Request for Completion. The Engineer will not accept the Work or any portion of the Work before all of the Work is completed and all outstanding deficiencies that may exist are corrected by the Contractor and the Engineer is satisfied that all the materials and workmanship. and all other features of the Work. meet the requirements of all of the specifications for the Work. Once the Final Inspection has been completed and all outstanding deficiencies satisfactorily completed to Agency's approval. the Contractor shall submit a written assertion in the form of Request for Completion letter. certifying that the Work has been completed. 6-8. 7 Completion. Upon receipt of the Request for Completion letter. the Agency shall review the written assertion within 2 business days. If. in the Engineer's judgment. the Work has been completed in accordance with the Contract Documents. the Engineer will issue a Completion Letter. The date of completion shall be the date that the Completion Letter is issued by the Agency, conditional upon the Contractor demobilizing and ceasing all on-site labor within two business days. {'\ •,r Revised 2/27/18 Addendum No.1-PWS18-121TRAN-Contract No. 3896 Page 77(8) of 101 Pages If the Contractor does not fully demobilizes and cease on-site labor accordingly, the Agency may revise the date of Completion to be the date which the Contractor has fully demobilized and has ceased all on-site labor. The completion date will be the date to which incentive and liquidated damages will be computed. Use, temporary, interim or permanent, of all, or portions of, the Work does not constitute completion or acceptance of the Work. 6-8.8 Acceptance. Acceptance will occur after all of the requirements contained in the Contract Documents have been fulfilled. If, in the Engineer's judgment, the Contractor has fully performed the Contract, the Engineer will so certify to the Board. Upon such certification by the Engineer the Board may accept the Work. Upon the Board's acceptance of the Work the Agency will cause a "Notice of Completion" to be filed in the office of the San Diego County Recorder. The date of recordation shall be the date of acceptance of the Work. 6-8.9 Warranty. All work shall be warranted for one (1) year after acceptance of the Work and any faulty work or materials discovered during the warranty period shall be repaired or replaced by the Contractor, at its expense. Twenty-five percent of the faithful performance bond shall be retained as a warranty bond for the one year warranty period. The Contractor shall replace or repair any such defective work in a manner satisfactory to the Engineer, after notice to do so from the Engineer, and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the Agency may perform this work and the Contractor's sureties shall be liable for the cost thereof. 6-9 LIQUIDATED DAMAGES. i;:ailure of the Contractor to complete the 'Nork within the time allowed will result in damages being sustained by the Agency. i;:or each consecuti•,•e calendar day in e*cess of the time specified for completion of 'Nork, as adjusted in accordance with Section 6 6, the Contractor shall pay the Agency, or ha¥e withheld monies due it, the sum of fi·,e hundred dollars ($500) Such sum is liquidated damages and shall not be construed as a penalty, and may be deducted from payments due the Contractor if such delay OCCllrS. E*ecution of the Contract shall constitute agreement by the Agency and Contractor that fi¥e hundred dollars ($500) per day is the minimum ¥alue of costs and actual damages caused by the Contractor to complete the Work within the allotted time. Any progress payments made after the specified completion date shall not constitute a wai¥er of this paragraph or of any damages. 6-10 USE OF IMPROVEMENT DURING CONSTRUCTION. The Agency reseF\•es the right to take o¥er and utilize all or part of any completed facility or appurtenance. The Contractor will be notified in writing in ad¥ance of such action. Such action by the Agency will relie¥e the Contractor of responsibility for injury or damage to said completed portions of the impro¥ement resulting from use by public traffic or from the action of the elements or from any other cause, e*cept Contractor operations or negligence. The Contractor 'Nill not be required to reclean such portions of the impro¥ement before field acceptance, e*cept for cleanup made necessary by its operations. Nothing in this section shall be constrned as relieving the Contractor from full responsibility for correcting defecti'.'e work or materials. In the e¥ent the Agency e*ercises its right to place into service and utilize all or part of any completed facility or appurtenance, the Agency will assume the responsibility and liability for injury to persons or property resulting from the utilization of the facility or appurtenance so placed into service, e*cept for any such injury to persons or property caused by any willful or negligent act or omission by the Contractor, Subcontractor, their officers, employees, or agents. 6-11 INCENTIVE. For each and every working day that the work is completed prior to May 26, 2018, the Contractor will receive an incentive payment totaling one thousand ($1,000) per working day. The total incentive payment will not exceed $10,000. Completion of the Work shall be subject to Section 6-8. SECTION 7 -RESPONSIBILITIES OF THE CONTRACTOR 7-1 CONTRACTOR'S EQUIPMENT AND FACILITIES. The Contractor shall furnish and maintain in good condition all equipment and facilities as required for the proper execution and inspection of the Work. Such equipment and facilities shall meet all requirements of applicable ordinances and laws. ~, Twt; Revised 2/27/18 Addendum No.1-PWS18-121TRAN-Contract No. 3896 Page 78 of 101 Pages TABLE OF CONTENTS Item Page NOTICE INVITING BIDS ................................................................................................................... 4 CONTRACTOR'S PROPOSAL ......................................................................................................... 9 BID SECURITY FORM ................................................................................................................... 14 BIDDER'S BOND TO ACCOMPANY PROPOSAL .......................................................................... 15 GUIDE FOR COMPLETING THE "DESIGNATION OF SUBCONTRACTORS" FORM ................... 16 DESIGNATION OF SUBCONTRACTOR AND AMOUNT OF SUBCONTRACTOR'S BID ITEMS ... 18 BIDDER'S STATEMENT OF TECHNICAL ABILITY AND EXPERIENCE ........................................ 19 BIDDER'S CERTIFICATE OF INSURANCE FOR GENERAL LIABILITY, EMPLOYERS' LIABILITY, AUTOMOTIVE LIABILITY AND WORKERS' COMPENSATION ................................... 20 BIDDER'S STATEMENT RE DEBARMENT .................................................................................... 21 BIDDER'S DISCLOSURE OF DISCIPLINE RECORD .................................................................... 22 NONCOLLUSION DECLARATION TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID ........................................................................................................................................ 24 CONTRACT PUBLIC WORKS ........................................................................................................ 25 LABOR AND MATERIALS BOND ................................................................................................... 31 FAITHFUL PERFORMANCE/WARRANTY BOND .......................................................................... 33 OPTIONAL ESCROW AGREEMENT FOR SECURITY DEPOSITS IN LIEU OF RETENTION ....... 35 GENERAL PROVISIONS SECTION 1 -TERMS, DEFINITIONS, ABBREVIATIONS, AND SYMBOLS 1-1 TERMS .......................................................................................................................... 38 1-3 ABBREVIATIONS .......................................................................................................... 42 1-4 UNITS OF MEASURE ................................................................................................... 45 1-5 SYMBOLS ..................................................................................................................... 47 SECTION 2 -SCOPE AND CONTROL OF WORK 2-1 AWARD AND EXECUTION OF CONTRACT ................................................................. 47 2-2 ASSIGNMENT ............................................................................................................... 47 2-3 SUBCONTRACTS ......................................................................................................... 47 2-4 CONTRACT BONDS ..................................................................................................... 48 2-5 PLANS AND SPECIFICATIONS .................................................................................... 49 2-6 WORK TO BE DONE .................................................................................................... 53 2-7 SUBSURFACE DATA .................................................................................................... 53 2-8 RIGHT-OF-WAY ............................................................................................................ 53 2-9 SURVEYING ................................................................................................................. 53 2-10 AUTHORITY OF BOARD AND ENGINEER. .................................................................. 54 2-11 INSPECTION ................................................................................................................. 55 l' •+' Revised 7/19/17 PWS 18-121 TRAN-Contract No. 3896 Page 2 of 101 Pages SECTION 3 -CHANGES IN WORK 3-1 CHANGES REQUESTED BY THE CONTRACTOR. ..................................................... 55 3-2 CHANGES INITIATED BY THE AGENCY ..................................................................... 55 3-3 EXTRA WORK .............................................................................................................. 57 3-4 CHANGED CONDITIONS ............................................................................................. 59 SECTION 4 -CONTROL OF MATERIALS 4-1 MATERIALS AND WORKMANSHIP .............................................................................. 63 4-2 MATERIALS TRANSPORTATION, HANDLING AND STORAGE .................................. 67 SECTION 5-UTILITIES 5-1 LOCATION .................................................................................................................... 68 5-2 PROTECTION ............................................................................................................... 68 5-3 REMOVAL ..................................................................................................................... 69 5-4 RELOCATION ............................................................................................................... 69 5-5 DELAYS ........................................................................................................................ 70 5-6 COOPERATION ............................................................................................................ 70 SECTION 6-PROSECUTION, PROGRESS, AND ACCEPTANCE OF THE WORK 6-1 CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK ........................... 70 6-2 PROSECUTION OF WORK. ......................................................................................... 74 6-3 SUSPENSION OF WORK ............................................................................................. 74 6-4 DEFAULT BY CONTRACTOR. ...................................................................................... 75 6-5 TERMINATION OF CONTRACT ................................................................................... 75 6-6 DELAYS AND EXTENSIONS OF TIME. ........................................................................ 76 6-7 TIME OF COMPLETION ................................................................................................ 77 6-8 COMPLETION, ACCEPTANCE, AND WARRANTY ...................................................... 77 6-9 LIQUIDATED DAMAGES .............................................................................................. 78 6-10 USE OF IMPROVEMENT DURING CONSTRUCTION .................................................. 78 SECTION 7-RESPONSIBILITIES OF THE CONTRACTOR 7-1 CONTRACTOR'S EQUIPMENT AND FACILITIES ........................................................ 78 7-2 LABOR .......................................................................................................................... 79 7-3 LIABILITY INSURANCE ................................................................................................ 79 7-4 WORKERS' COMPENSATION INSURANCE ................................................................ 79 7-5 PERMITS ...................................................................................................................... 79 7-6 THE CONTRACTOR'S REPRESENTATIVE ................................................................. 80 7-7 COOPERATION AND COLLATERAL WORK ................................................................ 80 7-8 PROJECT SITE MAINTENANCE .................................................................................. 80 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS ....................... 82 7-10 PUBLIC CONVENIENCE AND SAFETY ....................................................................... 82 7-11 PATENT FEES OR ROYALTIES ................................................................................... 88 7-12 ADVERTISING .............................................................................................................. 89 7-13 LAWS TO BE OBSERVED ............................................................................................ 89 7-14 ANTITRUST CLAIMS .................................................................................................... 89 SECTION 9 -MEASUREMENT AND PAYMENT 9-1 MEASUREMENT OF QUANTITIES FOR UNIT PRICE WORK ..................................... 89 9-2 LUMP SUM WORK ........................................................................................................ 90 9-3 PAYMENT ..................................................................................................................... 90 9-4 BID ITEMS ..................................................................................................................... 93 l' •+' Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 2 of 101 Pages SECTION 201 -CONCRETE, MORTAR, AND RELATED MATERIALS 201-1 PORTLAND CEMENT CONCRETE .............................................................................. 96 201-2 REINFORCEMENT FOR CONCRETE .......................................................................... 96 201-3 EXPANSION JOINT FILLER AND JOINT SEALANTS .................................................. 96 SECTION 206-MISCELLANEOUS METAL ITEMS 206-1 STRUCTURAL STEEL, RIVETS, BOLTS, PINS, AND ANCHOR BOLTS ...................... 96 SECTION 210-PAINT AND PROTECTIVE COATINGS 210-1 PAINT ............................................................................................................................ 97 210-6 CONCRETE SEALANT ................................................................................................. 97 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 3, CONSTRUCTION METHODS SECTION 304 METAL FABRICATION AND CONSTRUCTION 304-1 STRUCTURAL STEEL .................................................................................................. 98 SECTION 310 PAINTING 310-2 SURFACE PREPARATION FOR PAINTING STEEL STRUCTURES ............................ 98 310-6 SEAL CONCRETE SURFACES .................................................................................... 98 310-7 CLEAN AND PAINT STRUCTURAL STEEL .................................................................. 99 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 6 -TEMPORARY TRAFFIC CONTROL SECTION 600 ACCESS 600-2 VEHICULAR ACCESS ................................................................................................ 100 600-3 PEDESTRIAN ACCESS .............................................................................................. 100 SECTION 601 WORK AREA TRAFFIC CONTROL 601-2 TRAFFIC CONTROL PLAN (TCP) .............................................................................. 100 l' •,;' Revised 7/19/17 PWS 18-12 HRAN-Contract No. 3896 Page 3 of 101 Pages CITY OF CARLSBAD, CALIFORNIA NOTICE INVITING BIDS Until 11 a.m. on March 20, 2018, the City shall accept sealed bids, clearly marked as such, at the Faraday Center, 1635 Faraday Avenue, Carlsbad, CA 92008-7314, Attn: Purchasing Officer, by mail, delivery service or by deposit in the Bid Box located in the first floor lobby, at which time they will be opened and read, for performing the work as follows: remove existing damaged stair treads and corroded steel brackets, clean corroded steel, and install new stair treads. BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 PWS18-121TRAN INSTRUCTIONS TO BIDDERS AND BID REQUIREMENTS This bid and the terms of the Contract Documents and General Provisions constitute an irrevocable offer that shall remain valid and in full force for a period of 90 days and such additional time as may be mutually agreed upon by the City of Carlsbad and the Bidder. No bid will be received unless it is made on a proposal form furnished by the Purchasing Department. Each bid must be accompanied by security in a form and amount required by law. The bidder's security of the second and third next lowest responsive bidders may be withheld until the Contract has been fully executed. The security submitted by all other unsuccessful bidders shall be returned to them, or deemed void, within ten (10) days after the Contract is awarded. Pursuant to the provisions of law (Public Contract Code section 10263), appropriate securities may be substituted for any obligation required by this notice or for any monies withheld by the City to ensure performance under this Contract. Section 10263 of the Public Contract Code requires monies or securities to be deposited with the City or a state or federally chartered bank in California as the escrow agent. The escrow agent shall maintain insurance to cover negligent acts and omissions of the agent in connection with the handling of retentions under this section in an amount not less than $100,000 per contract. The City of Carlsbad may disqualify a contractor or subcontractor from participating in bidding when a contractor or subcontractor has been debarred by the City of Carlsbad or another jurisdiction in the State of California as an irresponsible bidder. The work shall be performed in strict conformity with the plans, provisions, and specifications as approved by the City Council of the City of Carlsbad on file with the Engineering Department. The specifications for the work include City of Carlsbad Technical Specifications and the Standard Specifications for Public Works Construction, Parts 2 & 3, current edition at time of bid opening and the supplements thereto as published by the "Greenbook" Committee of Public Works Standards, Inc., all hereinafter designated "SSPWC", as amended. Specification Reference is hereby made to the plans and specifications for full particulars and description of the work. The General Provisions (Part 1) to the SSPWC do not apply. The City of Carlsbad encourages the participation of minority and women-owned businesses. The City of Carlsbad encourages all bidders, suppliers, manufacturers, fabricators and contractors to utilize recycled and recyclable materials when available, appropriate and approved by the Engineer. BID DOCUMENTS The bid documents comprise the following documents which must be completed and properly executed including notarization, where indicated. l'\ •+' Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 4 of 101 Pages 1 . Contractor's Proposal 2. Bidder's Bond 3. Noncollusion Declaration 4. Designation of Subcontractor and Amount of Subcontractor's Bid 5. Bidder's Statement of Technical Ability and Experience 6. Acknowledgement of Addendum(a) 7. Certificate of Insurance. The riders covering the City, its officials, employees and volunteers may be omitted at the time of bid submittal but shall be provided by the Bidder prior to award of this contract. 8. Bidder's Statement Re Debarment 9. Bidder's Disclosure Of Discipline Record 1 O. Escrow Agreement for Security Deposits -(optional, must be completed if the Bidder wishes to use the Escrow Agreement for Security) ENGINEER'S ESTIMATE All bids will be compared on the basis of the Engineer's Estimate. The estimated quantities are approximate and serve solely as a basis for the comparison of bids. The Engineer's Estimate is $110,030. TIME OF COMPLETION The contractor shall complete the Work within the time set in the contract as defined in the General Provisions Section 6-7. SPECIAL TY CONTRACTORS: ACCEPTABLE LICENSE TYPES Except as provided herein a bid submitted to the City by a Contractor who is not licensed as a contractor pursuant to the Business and Professions Code shall be considered nonresponsive and shall be rejected by the City. In all contracts where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder to be licensed in accordance with California law. Where federal funds are involved the contractor shall be properly licensed at the time the contract is awarded. In all other cases the contractor shall state their license number, expiration date and classification in the proposal, under penalty of perjury. This invitation to bid does not include federal funds. The following classifications are acceptable for this contract: A: General Engineering or B: General Building. ESCROW AGREEMENT If the Contractor intends to utilize the escrow agreement included in the contract documents in lieu of the usual 5% retention from each payment, these documents must be completed and submitted with the signed contract. The escrow agreement may not be substituted at a later date. OBTAINING PLANS AND SPECIFICATIONS Bid packages various supplemental provisions and Contract documents may be obtained on the City of Carlsbad web site at www.carlsbadca.gov. Paper copies will not be sold. INTENT OF PLANS AND SPECIFICATIONS Any prospective bidder who is in doubt as to the intended meaning of any part of the drawings, specifications or other contract documents, or finds discrepancies in or omissions from the drawings and specifications may submit to the Engineer a written request for clarification or correction. Any response will be made only by a written addendum duly issued by the Engineer a copy of which will be mailed or delivered to each person receiving a set of the contract documents. No oral response will be made to such inquiry. Prior to the award of the contract, no addition to, modification of or interpretation of any provision in the contract documents will be given by any agent, employee or contractor of the City of Carlsbad except as hereinbefore specified. No bidder may rely on l' •+;' Revised 7/19/17 PWS 18-121 TRAN-Contract No. 3896 Page 5 of 101 Pages directions given by any agent, employee or contractor of the City of Carlsbad except as hereinbefore specified. REJECTION OF BIDS The City of Carlsbad reserves the right to reject any or all bids and to waive any minor irregularity or informality in such bids. PREVAILING WAGE TO BE PAID The general prevailing rate of wages for each craft or type of worker needed to execute the Contract shall be those as determined by the Director of Industrial Relations pursuant to the sections 1770, 1773, and 1773.1 of the Labor Code. Pursuant to section 1773.2 of the Labor Code, a current copy of applicable wage rates is on file in the Office of the City Engineer. The Contractor to whom the Contract is awarded shall not pay less than the said specified prevailing rates of wages to all workers employed by him or her in the execution of the Contract. The Prime Contractor shall be responsible for insuring compliance with provisions of section 1777.5 of the Labor Code and section 4100 et seq. of the Public Contracts Code, "Subletting and Subcontracting Fair Practices Act." The City Engineer is the City's "duly authorized officer" for the purposes of section 4107 and 4107.5. The provisions of Part 7, Chapter 1, of the Labor Code commencing with section 1720 shall apply to the Contract for work. A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, unless currently registered and qualified to perform public work pursuant to Section 1725.5. This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations. The Prime Contractor and all subcontractors shall comply with Section 1776 of the Labor Code, which generally requires keeping accurate payroll records, verifying and certifying payroll records, and making them available for inspection. Contractor shall require all subcontractors to comply with Section 1776. PRE BID MEETING A pre-bid meeting and tour of the project site will not be held. UNIT PRICES AND COMPUTATION OF BIDS All bids are to be computed on the basis of the given estimated quantities of work, as indicated in this proposal, times the unit price as submitted by the bidder. In case of a discrepancy between words and figures, the words shall prevail. In case of an error in the extension of a unit price, the corrected extension shall be calculated and the bids will be computed as indicated above and compared on the basis of the corrected totals. All prices must be in ink or typewritten. Changes or corrections may be crossed out and typed or written in with ink and must be initialed in ink by a person authorized to sign for the Contractor. l' •ff Revised 7 /19/17 PWS18-121TRAN-Contract No. 3896 Page 6 of 101 Pages BIDDER'S INQUIRIES Questions on the bid documents during the bid period shall be submitted in writing, via email, solely to: Eleida Felix Yackel, Senior Contract Administrator eleida.felixyackel@carlsbadca.gov Questions shall be definite and certain and shall reference applicable drawings sheets, notes, details or specification sheets. The cutoff date to submit questions regarding this project is 5 p.m. on March 12, 2018. No questions will be entertained after that date. The answers to questions submitted during the bidding period will be published in an addendum via PlanetBids. ADDENDUMS Bidders are advised to verify the issuance of all addenda and receipt thereof one day prior to bidding. Submission of bids without acknowledgment of addenda may be cause of rejection of bid. BOND AND INSURANCE REQUIREMENTS The Contractor shall provide bonds to secure faithful performance and warranty of the work in an amount equal to one hundred percent (100%) of the Contract price on this project. The Contractor shall provide bonds to secure payment of laborers and materials suppliers, in an amount equal to one hundred percent (100%) of the total amount payable by the terms of the contract. These bonds shall be kept in full force and effect during the course of this project, and shall extend in full force and effect and be retained by the City until they are released as stated in the General Provisions section of this contract. All bonds are to be placed with a surety insurance carrier admitted and authorized to transact the business of insurance in California and whose assets exceed their liabilities in an amount equal to or in excess of the amount of the bond. The bonds are to be accompanied by the following documents: 1) An original, or a certified copy, of the unrevoked appointment, power of attorney, by laws, or other instrument entitling or authorizing the person who executed the bond to do so. 2) A certified copy of the certificate of authority of the insurer issued by the insurance commissioner. If the bid is accepted, the City may require copies of the insurer's most recent annual statement and quarterly statement filed with the Department of Insurance pursuant to Article 10 (commencing with section 900) of Chapter 1 of Part 2 of Division 1 of the Insurance Code, within 10 calendar days of the insurer's receipt of a request to submit the statements. Insurance is to be placed with insurers that: 1) Have a rating in the most recent Best's Key Rating Guide of at least A-:VII 2) Are admitted and authorized to transact the business of insurance in the State of California by the Insurance Commissioner. Auto policies offered to meet the specification of this contract must: 1) Meet the conditions stated above for all insurance companies. 2) Cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. Workers' compensation insurance required under this contract must be offered by a company meeting the above standards with the exception that the Best's rating condition is waived. The City does accept l' • ., Revised 7/19/17 PWS 18-121 TRAN-Contract No. 3896 Page 7 of 101 Pages policies issued by the State Compensation Fund meeting the requirement for workers' compensation insurance. The Contractor shall be required to maintain insurance as specified in the Contract. Any additional cost of said insurance shall be included in the bid price. The award of the contract by the City Council is contingent upon the Contractor submitting the required bonds and insurance, as described in the contract, within twenty days of bid opening. If the Contractor fails to comply with these requirements, the City may award the contract to the second or third lowest bidder and the bid security of the lowest bidder may be forfeited. BUSINESS LICENSE The prime contractor and all subcontractors are required to have and maintain a valid City of Carlsbad Business License for the duration of the contract. March 6, 2018 Date ,, • ., Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 8 of 101 Pages CITY OF CARLSBAD BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN CONTRACTOR'S PROPOSAL City Council City of Carlsbad 1200 Carlsbad Village Drive Carlsbad, California 92008 .. ~ ... --;:,...,-.-.... •·-'-' The undersigned declares he/she has carefully examined the location of the work, read the Notice Inviting Bids, examined the Plans, Specifications, General Provisions, Contract Documents, and addenda thereto, and hereby proposes to furnish all labor, materials, equipment, transportation, and services required to do all the work to complete Contract No. 3896 in accordance with the Plans, Specifications, General Provisions, Contract Documents, and addenda thereto and that he/she will take in full payment therefore the following unit prices for each item complete, to wit: Item No. Description 1 Traffic Control and Traffic Contr:'j_J'lan a~ , '..-1:: 0~~%£:Jo(~WL (Unit Price in Words) 2 Remove an~Re-use Treads at "Wl't-~ ~ rlollaq (Uni;~n Words) 3 Remove and Replace Treads Approximate Quantity And Unit 1 LS Unit Price (Figures) 30 EA $ 25'-f 30 EA $ i2..z P1 II\ e. a~~~ t J ~ ~ -buo cloll01s (Unit Price in rds) 4 104 EA $ 1i2 (Unit Price in Words) 5 Clean and Paint Structural 1 LS .f!teel at j , ~~~~~I~ ,., • ., Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Total Amount (Figures) $ 1,800 • $ 7, G20 $ 2l-1 6GO ' $ ,i, 928 $ (0 ~00 7 Page 9 of 101 Pages Approximate Item Quantity Unit Price Total Amount No. Description And Unit (Figures} (Figures} (Price in Words) 6 Seal Concrete Stairway Treads 52 EA $ lOO $ c; ?_Ci) at doll(} C.S 1 Olt\e bLlJ(ed (Unit Price in Words) 7 Stormwater Pollution 1 LS $ :6 ~0() Protection Plan (SWPPP I ! (Unn Price in Words) 8 Mobilization at Stipulated $10,000 Ten Thousand Dollars (Unit Price in Words) T olal amount of bid in words: e; ~kfy-::,eue,n thou.) Q od i<JJo ½ (A V\ cl.red e~lJ: Total amount of bid in numbers: $ __ ____.1]..._._...,.1 .... 2......._:;;0;....o.,3.__ ______________ _ Price(s) given above are firm for 90 days after date of bid opening. Addendum(a} No(s}. __ ....,! _t-~2.__ ____ ha~ha'le been r~i"led aoo is/are inc\ut\ed in \his proposal. The Undersigned has carefully checked all of the above figures and understands that the City will not be responsible for any error or omission on the part of the Undersigned in preparing this bid. The Undersigned agrees that in case of default in executing the required Contract with necessary bonds and insurance policies within twenty (20) days from the date of award of Contract by the City Council of the City of Carlsbad, the City may administratively authorize award of the contract to the second or third lowest bidder and the bid security of the lowest bidder may be forfeited. The Undersigned bidder declares, under penalty of perjury, that the undersigned is licensed to do business or act in the capacity of a contractor within the State of California, validly licensed under license number 55'1 I 24 , classification B which expires on 3 / 31 / 1q , and that this statement is true and correct and has the legal effect of an affidavit. A bid submitted to the City by a Contractor who is not licensed as a contractor pursuant to the Business and Professions Code shall be considered nonresponsive and shall be rejected by the City § 7028.1 S(e). In all contracts where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder to be licensed in accordance with California law. However, at the time the contract is awarded, the contractor shall be properly licensed. " ..,-Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 10 of 101 Pages The Undersigned bidder hereby represents as follows: 5-2-cJ-'~ 1. That no Council member, officer agent, or employee of the City of Carlsbad is personally interested, directly or indirectly, in this Contract, or the compensation to be paid hereunder; that no representation, oral or in writing, of the City Council, its officers, agents, or employees has inducted him/her to enter into this Contract, excepting only those contained in this form of Contract and the papers made a part hereof by its terms; and 2. That this bid is made without connection with any person, firm, or corporation making a bid for the same work, and is in all respects fair and without collusion or fraud. Accompanying this proposal is ___ l)o.=..."""nd ___________ (Cash, Certified Check, Bond or Cashier's Check) for ten percent ( 10%) of the amount bid. The Undersigned is aware of the provisions of section 3700 of the Labor Code which requires every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and agrees to comply with such provisions before commencing the performance of the work of this Contract and continue to comply until the contract is complete. The Undersigned is aware of the provisions of the Labor Code, Part 7, Chapter 1, Article 2, relative to the general prevailing rate of wages for each craft or type of worker needed to execute the Contract and agrees to comply with its provisions. IF A SOLE OWNER OR SOLE CONTRACTOR SIGN HERE: (1) Name under which business is conducted ____ C.o...,. ..... 1 ....... 1 ..... i e.-~ ..... __,G ........ n ........... st-'--'r'--u~c;_+ ..... l ..... o'--'n___._ __ _ (2) Signature (given and surname) of proprietor -~-~-=~--"""'-=~:::w::..-~b----'-~~,,.......::~= ..... ~ .... ~-· "------ (3) Place of Business 3509 Dri:f±wd P!o.ce. 0 · d (Street and Number) City and State _ cea,0s1 _e I CA (4) Zip Code q2o56 Telephone No. ( 160) 703-12Z½ (s) E-Mail _b_~ _l lc ____ @~(I)_I_I i_er ___ c_o_fls_h_·;u_J-_io_vi_. _n_ef ___ _ " • ., Revised 7/19/17 PWS18-121TRAN-Contract No.~ Page 11 of 101 Pages ... CALJFORNIA NOTARY ACKT\:OWLEDGMENT For An Individual Acting In His/Her Own Right: State of California ~-------------·----------- A notary public or other officer cc,mple1ing t'.1is certificate verifies only the idcnfr,y of li:e ind;vidual vvht; signed the document to which '.iJJS certi i1c?te ic.; aliachec', and not the tru,hfulncss, ;,ccw:J.C:. or,, :.id1t:r 0+ document. ---------··-----·---------- County of~~j~ _ i ,~. On~ befm, ,,~/~ ,,,t,,, P"hl,c·, '"""""") ,,rr, ,,,,, --~~ '~-~-~-~ ---~-~ whoprovedtomeo thebasisofsatista:.:toryi,· nccf(i-;;;;-;c:,c··,,H,~·u,c ;,c1 ·s , .L:,',.i·h; J ',, within instrument and aiwledg:.:d to me th h ~e-~cxec,1t,2d :hs: sin:e 1, lw ' :utl'i(1·11c{' capacity~ and that b hi ~Jj;:errsignatur en l 1'.: :,1,:~~ :-re1t the r,er.,Gni r tiic cnt t'. ,.;',1' ',,,u, which £e person~ctc , xccutc<l :he nstnurc1tt [NOT ARIAL SEAL] •••1•11•11•111•11•1••1••1••••1•1••••1• $@·· · , ... ·. JOSEPH A. CALDARARO ~ .,.. ~ • COMM. #2179095 ~ , , NOTARY PUBLIC -CAUFOANIA § • , SAN DIEGO COUNTY • --: My CommiSSion ExDlres 01/26/2021 : •1111111111111111•1•11•11•••••1•••1••• My commission expire~: _.f2v/P, I HEL6850CA (1115) IF A PARTNERSHIP, SIGN HERE: (1) Name under which business is conducted ___ __,_LJ~{A.____,_ ____________ _ (2) Signature (given and surname and character of partner) (Note: Signature must be made by a general partner) (3) Place of Business ___________________________ _ (Street and Number) City and State ___________________ _ (4) Zip Code ______ _ Telephone No. ________________ _ (5) E-Mail _____________________ _ IF A CORPORATION, SIGN HERE: (1) Name under which business is conducted __ .a..N..;.+/_,_A _______________ _ (2) -------------------------(Signature) (Title) Impress Corporate Seal here (3) Incorporated under the laws of the State of _________ _ (4) Place of Business ___________________________ _ (Street and Number) City and State ____________________________ _ (5) Zip Code ________ _ Telephone No. _______________ _ (6) E-Mail ____________________ _ NOTARIAL ACKNOWLEDGMENT OF EXECUTION BY ALL SIGNATORIES MUST BE ATTACHED {'\ •ff Revised 7/19/17 PWS 18-121TRAN-Contract No. 3896 Page 12 of 101 Pages List below names of president, vice president, secretary and assistant secretary, if a corporation; if a partnership, list names of all general partners, and managing partners: LI/A (' •;, Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 13 of 101 Pages BIDDER'S BOND TO ACCOMPANY PROPOSAL BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN KNOW ALL PERSONS BY THESE PRESENTS: That we, Collier Construction as Principal, and Developers Surety and Indemnity Comp,;rny as Surety are held and firmly bound unto the City of Carlsbad, California, in an amount as follows: (must be at least ten percent (10%) of the bid amount) ten percent of total amount bid for which payment, well and truly made, we bind ourselves, our heirs, executors and administrators, successors or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH that if the proposal of the above- bounden Principal for: BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN in the City of Carlsbad, is accepted by the City Council, and if the Principal shall duly enter into and execute a Contract including required bonds and insurance policies within twenty (20) days from the date of award of Contract by the City Council of the City of Carlsbad, being duly notified of said award, then this obligation shall become null and void; otherwise, it shall be and remain in full force and effect, and the amount specified herein shall be forfeited to the said City. In the event Principal executed this bond as an individual, it is agreed that the death of Principal shall not exonerate the Surety from its obligations under this bond. SIGNED AND SEALED, this ___ 14_t_h ______ day of ___ Ma_rc_h ___ , 20_18'---_ _ co_ll_ie_r c_o_ns_tr_uc_ti_on _______ (SEAL) (Principal) By:~.-::__ £ ~ :# (Signature) W, I I ,4,.,. E~ I /,er ::J:C- (Print Nameitle) Developers Surety and Indemnity Company (SEAL) cs ,-~) s-:::;::;_ (Signature) Cyndi Beilman, Attorney-in-Fact (Print Nameffitle) (SEAL AND NOTARIAL ACKNOWLEDGEMENT OF SURETY -ATTACH ATTORNEY-IN-FACT CERTIFICATE) APPROVED AS TO FORM: CELIA A. BREWER City Attorney By:Dep~t:~ l\ • ., Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 15 of 101 Pages CALIFORNIAALL-PURPOSEACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA County of San Diego } On March 14, 2018 before me, Pam Davis , Notary Public, -----~------------------------Date Insert Name of Notary exactly as it appears on the official seal personally appeared Cyndi Beilman r ................................................................................................ 1 a PAM DAVIS ..-COMM. #2165394 en E NOTARY Pueuc • CALIFORNIA a l. .. w ................ ~~;~J.!a;~1K.~2~2.1 Place Notary Seal Above Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Witness my han9 and ~cial ~ Signature (~41,(t:=ba--- Signature of Notary Public Pam Davis OPTIONAL ----------- Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: ------------------------------- Document Date: __________________ _ Number of Pages: ________ _ Signer(s) Other Than Named Above: __________________________ _ Capacity(ies) Claimed by Signer(s) Signer's Name: _____________ _ O Individual O Corporate Officer -Title(s): ________ _ 0 Partner O Limited O General ~ Attorney in Fact O Trustee O Guardian or Conservator O Other: _______ _ Signer is Representing: RIGHT THUMBPRINT OF SIGNER Top of thumb here Signer's Name: _____________ _ O Individual O Corporate Officer -Title(s): ________ _ 0 Partner O Limited O General 0 Attorney in Fact O Trustee O Guardian or Conservator O Other: _______ _ Signer is Representing RIGHT THUMBPRINT OF SIGNER Top of thumb here POWER OF ATTORNEY FOR DEVELOPERS SURETY AND INDEMNITY COMPANY INDEMNITY COMPANY OF CALIFORNIA PO Box 19725, IRVINE, CA 92623 (949) 263-3300 KNOW ALL BY THESE PRESENTS that except as expressly limited, DEVELOPERS SURETY AND INDEMNllY COMPANY and INDEMNllY COMPANY OF CALIFORNIA, do each hereby make, constitute and appoint *** Anne Wright, Cyndi Beilman, Dana Michaelis, jointly or severally*** as their true and lawful Attorney(s)-ln-Fact, to make, execute, deliver and acknowledge, for and on behalf of said corporations, as sureties, bonds, undertakings and contracts of suretyshlp giving and granting unto said Attorney(s)-ln-Fact full power and authority to do and to perform every act necessary, requisite or proper to be done In connection therewith as each of said corporations could do, but reserving to each of said corporations full power of substitution and revocation, and all of the acts of said Attorney(s)-in-Fact, pursuant to these presents, are hen!by ratified and confirmed. This Power of Attorney is granted and is signed by facsimile under and by authority of the following resolutions adopted by the respective Boards of Directors of DEVELOPERS SURETY AND INDEMNllY COMPANY and INDEMNllY COMPANY OF CALIFORNIA, effective as of January 1s~ 2008. RESOLVED, that a combination of any two of the Chairman of the Board, the President, Executive Vice-Presiden~ Senior Vice-President or any Vice President of the corporations be, and that each of them hereby Is, authorized to execute this Power of Attorney, qualifying the attomey(s) named In the Power of Attorney to execute, on behalf of the corporations, bonds, undertakings and contracts of suretyshlp; and that the Secretary or any Assistant Seaetary of either of the corporations be, and each of them hereby is, authorized to attest the execution of any such Power of Attorney: RESOLVED, FURTHER, that the signatures of such officers may be affixed to any such Power of Attorney or to any certificate relatlng thereto by facsimile, and any such Power of Attorney or certificate bearing such facslmlle signatures shall be valid end binding upon the corporations when so affixed and In the future with respect to any bond, undertaking or contract of suretyship to which it is attached. IN WITNESS WHEREOF, DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA have severally caused these presents to be signed by their respective officers and attested by their respective Secretary or Assistant Secretary this 6th day of February, 2017. By:~~ Daniel Young, Senior Vice-President By: ~ ~ Mark Lansden, Vice-President A notary public or other officer completing this certificate verifies only the Identity of the individual who signed the document to which this certificate ls attached, and not the truthfulness, accura , or valid of that document State of Carlfomla County of Orange On -----'-F""eb:.:.:ru:::::a'-'-ry-"6L:, 20::..:..:17 ____ before me, ___________ ...,,L..,ucla,,11:l<,.e ~Ray=m""on~d~, N!l:o~ta~rv..:..P~ub~li:,.c ___________ _ Do Hen, Insert Nffll 111d Tm!, d U. Oftlcer personally appeared ________________ ...,Da::::.::nie,,,.l.:..:Yo::,::u,,.ngi.:a::..:nd~Ma:,:=rk:!.!La=nsdo=n,._ ________________ _ Nane(s) d Slgner(s) Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the person(s) whose neme(s) ls/are subscribed to the within Instrument and acknowledged to me that he/she/they executed the same In his/hedthelr authorized capaclty(ies), and that by his/her/their slgnature(s) on the Instrument the person(s), or the entity upon beha~ of which the person(s) acted, executed the Instrument I certify under PENAL 1Y OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESSmyhandandofficlalseal. ~· -~ Signature _________ ..._,1..p=. _____ __;:......:=4....;.. __ .=....:. ___ _ Luci! ond, Notary Public CERTIFICATE . The undersigned, as Secretary or Assistant Secretary of DEVELOPERS SURETY AND INDEMNITY COMPANY or INDEMNITY COMPANY OF CALIFORNIA, does hereby certify that the foregoing Power of Attorney remalns in full force and has not been revoked and, furthermore, that the provisions of the resolutlons of the respective Boards of Directors of said C0IJ)Ol'8llons set forth in lhe Power of Attorney are In force as of the date of this Certificate. This Certificate Is executed In the City of Irvine, Cafifomia, this 14th day of March , 2018, °'~,;,_~ ATS-1002 (02/17) GUIDE FOR COMPLETING THE "DESIGNATION OF SUBCONTRACTORS" FORM REFERENCES Prior to preparation of the following "Subcontractor Disclosure Form" Bidders are urged to review the definitions in section 1-2 of the General Provisions to this Contract, especially, "Bid", "Bidder'', "Contract", "Contractor", "Contract Price", "Contract Unit Price", "Engineer", "Own Organization", "Subcontractor", and "Work". Bidders are further urged to review sections 2-3 SUBCONTRACTS of the General Provisions. CAUTIONS This form will be used by the Agency to determine the percentage of work that the Bidder proposes to perform. Bidders are cautioned that failure to provide complete and correct information may result in rejection of the bid as non-responsive. Any bid that proposes performance of more than 50 percent of the work by subcontractors or otherwise to be performed by forces other than the Bidder's own organization will be rejected as non-responsive. Specialty items of work that may be so designated by the Engineer on the "Contractor's Proposal" are not included in computing the percentage of work proposed to be performed by the Bidder. INSTRUCTIONS The Bidder shall set forth the name and location of business of each and every subcontractor whom the Bidder proposes to perform work or labor or render service in or about the work or improvement, and every subcontractor licensed as a contractor by the State of California whom the Bidder proposes to specially fabricate and install any portion of the work or improvement according to detailed drawings contained in the plans and specifications in excess of one-half of one percent (0.5%) of the Bidder's total bid or, in the case of bids or offers for the construction of streets and highways, including bridges, in excess of one-half of one percent (0.5%) or ten thousand dollars ($10,000) whichever is greater. Said name(s) and location(s) of business of subcontractor(s) shall be set forth and included as an integral part of the bid offer. The Designation of Subcontractors form must be submitted as a part of the Bidder's sealed bid. Failure to provide complete and correct information may result in rejection of the bid as non-responsive. Suppliers of materials from sources outside the limits of work are not subcontractors. The value of materials and transport of materials from sources outside the limits of work, as shown on the plans, shall be assigned to the Contractor or the Subcontractor as the case may be, that the Bidder proposes as installer of said materials. The value of material incorporated in any Subcontractor-installed bid item that is supplied by the Bidder shall be included as a part of the work that the Bidder proposes to be performed by the Subcontractor installing said item. When a Subcontractor has a Carlsbad business license, the number must be entered on the proper form. If the Subcontractor does not have a valid business license, enter "NONE" in the appropriate space. When the Bidder proposes using a Subcontractor to construct or install less than 100 percent of a bid item, the Bidder shall attach an explanation sheet to the Designation of Subcontractor form. The explanation sheet shall clearly apprise the City of the specific facts that show the Bidder proposes to perform no less than fifty percent (50%) of the work with its own forces. Determination of the subcontract amounts for purposes of award of the contract shall be determined by the City Council in conformance with the provisions of the contract documents and the various supplemental provisions. The decision of the City Council shall be final. Contractor is prohibited from performing any work on this project with a subcontractor who is ineligible to perform work on a public works project pursuant to Labor Code Sections 1771.1 or 1777.7. {'\ •+' Revised 7/19/17 PWS 18-121 TRAN-Contract No. 3896 Page 16 of 101 Pages Bidders shall make any additional copies of the disclosure forms as may be necessary to provide the required information. The page number and total number of additional form pages shall be entered in the location provided on each type of form so duplicated. l' •ff Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 17 of 101 Pages DESIGNATION OF SUBCONTRACTOR AND AMOUNT OF SUBCONTRACTOR'S BID ITEMS (To Accompany Proposal) BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN The Bidder certifies that it has used the sub-bid of the following listed subcontractors in preparing this bid for the Work and that the listed subcontractors will be used to perform the portions of the Work as designated in this list in accordance with applicable provisions of the specifications and section 4100 et seq. of the Public Contract Code, "Subletting and Subcontracting Fair Practices Act." The Bidder further certifies that no additional subcontractor will be allowed to perform any portion of the Work in excess of one-half of one percent (0.5%) of the Bidder's total bid, or in the case of bids or offers for construction of streets and highways, including bridges, in excess of one-half of one percent (0.5%) or ten thousand dollars ($10,000), whichever is greater, and that no changes in the subcontractors listed work will be made except upon the prior approval of the Agency. SUBCONTRACTOR'S BID ITEMS Subcontractor Name Phone No. DIR Subcontractor's Amount of Portion and and Email Registration License No. and Work by of Work Subcontract Location of Business Address No. Classification* or in Dollars* 1\H) l H-· ,.., Page _l_ of _L pages of this Subcontractor Designation form * Pursuant to section 4104 (a)(3)(A) California Public Contract Code, receipt of the information preceded by an asterisk may be submitted by the Bidder up to 24 hours after the deadline for submitting bids contained in the "Notice Inviting Bids." ,, • ., Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 18 of 101 Pages BIDDER'S STATEMENT OF TECHNICAL ABILITY AND EXPERIENCE (To Accompany Proposal) BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN The Bidder is required to state what work of a similar character to that included in the proposed Contract he/she has successfully performed and give references, with telephone numbers, which will enable the City to judge his/her responsibility, experience and skill. An attachment can be used. Date Name and Address Name and Phone No. Amount Contract of the Employer of Person to Type of Work of Comoleted Contract Contract .c;F E ATT Ar J.l.tl r') p f\(ci,:: <; '/-·~ Pa-1'~ _I_ of~ fO-ies of f!>;dJu1 1 J-J-Me4 of +echnicoJ o..l.,; iJy llt)J e.ir,:erice ,., • ., Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 19 of 101 Pages l.N Date contract name and phone amount of completed name and address of employer number of contact Type of work contract person Matt Mccleod PE, Project Manager for 12/17/17 DGS Depart of Forestry Calfire CalFire: 951-901-5115 Install Metal siding at Cuyamaca Fire Station $87,240 Jeana Quirk, Project Sweetwater Unified High Manager for SUHSD: 10/31/16 School Dist. 619-585-4439 Rehab Metal Roof at San Ysidro HS $44,166 William Colllier served as Project manager for TBP Naval Facilities/TB Penick & Marc Penick, CEO: 619-on the BEQ Barracks: Structural steel prefab 6/1/14 Sons 249-1800 modular construction. $10,800,000 Collier Construction partnered with TB Penick to install "Double Bunks for Donovan Prison". Collier Construciton performed all work to weld steel California Dept. of Marc Penick, CEO: 619-framed bunks to wall mounted embed plates. 06/01/97 Correcrtions/TB Penick & Sons 249-1800 Collier parterned with TBP for Bonding purposes. $65,400 Please see attached resume with addition projects William Collier (Sole Owner of Collier Constuction) has completed. William Collier P.O. Box 460846 Escondido, CA 92046 * Phone 760-703-1284 * email billc@collierconstruction.net Construction Project Manager and Superintendent Areas of Expertise Skilled Project Manager and Superintendent for Public Works and Private Projects. Experience includes overall management for new and rehabilitation construction projects with value of $2M to $17M. Duties: Primary representative for client relations, create and maintain schedule, cost control, subcontractor buy out, draft subcontract agreements, negotiate/draft prime and subcontractor change orders, written correspondence with client and subcontractors, on-site Superintendent responsibilities and other duties. Clients include Naval Facilities (NavFac), San Diego Unified School District, US General Services, UCSD, SeaWorld of San Diego, San Diego Unified Port District and others. Proficient with the following Software: Prolog Project Manager, Excel, SureTrak scheduling, StreetSmarts accounting, CMIC accounting, Word and more. Experience 1979 to 1982: Daley Corp. Joined Labor union, worked during summer, winter and spring breaks while in school. Grading and asphalt repair. 1982 to 1988: Soltek of San Diego. Labor, carpenter helper and crew leader. Remodels and new construction. CIP concrete, drywall, metal stud framing, grading, demolition and more. 1989 to 1998: Founded Collier Construction CSL #559124. Sole Owner. Responsible for all safety, sales, field operations, accounts receivables, account payables, book keeping, contract/CO agreements and all other duties required of a sole proprietor. Most of my sales were as a subcontractor preforming selective demolition for public works projects. In the late 1990's I began performing Prime contract work. Clients include: Soltek, TB Penick & Sons, Straub, DPR, Barnhart, Navfac and others. 1998 to 2001: After a successful decade of operating Collier Construction I took a 3 year sabbatical to sail the south Pacific on my personal sail boat. This was a life time goal of mine. 2002 to 2015: T.B. Penick & Sons, Inc. Superintendent and Project Manager (PM). For most of my time I served TB Penick as a project manager for projects ranging from $2M-$17M. I was also an on-site CM on a multi-Prime project for Las Virgenes School District, Superintendent and PM for a San Diego Unified Schools Rehabilitation project, Project manager for following projects: New Restaurant "Dine with Shamu" (SeaWorld), New Church "Saint Stanislaus" (Catholic Diocese), SCIF addition/remodel at Naval Post Graduate School Monterey (NavFac), New Barracks on San Clemente Island (NavFac), and other projects. 2016 to Present: Collier Construction. Prime contractor for Pubic Works Projects including Sweetwater Union High School District, DGS Dept. of Forestry, Orange County Sanitation District. Education: 2 years Cuymaca College, Civil Engineering. 1 year SDSU, Civil Engineering BIDDER'S CERTIFICATE OF INSURANCE FOR GENERAL LIABILITY, EMPLOYERS' LIABILITY, AUTOMOTIVE LIABILITY AND WORKERS' COMPENSATION (To Accompany Proposal) BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN As a required part of the Bidder's proposal the Bidder must attach either of the following to this page. 1) Certificates of insurance showing conformance with the requirements herein for each of: D Comprehensive General Liability D Automobile Liability D Workers Compensation D Employer's Liability 2) Statement with an insurance carrier's notarized signature stating that the carrier can, and upon payment of fees and/or premiums by the Bidder, will issue to the Bidder Policies of insurance for Comprehensive General Liability, Automobile Liability, Workers Compensation and Employer's Liability in conformance with the requirements herein and Certificates of insurance to the Agency showing conformance with the requirements herein. All certificates of insurance and statements of willingness to issue insurance for auto policies offered to meet the specification of this contract must: 1) Meet the conditions stated in The Notice Inviting Bids and the General Provisions for this project for each insurance company that the Contractor proposes. 2) Cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. {'\ •+;' Revised 7 /19/17 PWS18-121TRAN-Contract No. 3896 Page 20 of 101 Pages I I ACORD® CERTIFICATE OF LIABILITY INSURANCE I DATE (MM/DD/YYYY) \. ..... --"' 03/28/2018 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS :ERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES 3ELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER($), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Stephen Webber NAME: Aloha West Insurance Agency PHONE (760) 547-2626 I rffc Nol: (760) 547-2627 fA/C No l'xtl: PO Box 128 ~*1nAJ~c:c:, steve@aloha12.com Carlsbad, CA 92018 INSURER(S) AFFORDING COVERAGE NAIC# Phone (760) 547-2626 Fax (760) 547-2627 INSURER A: Colony Insurance Company INSURED INSURERS: Collier Construction INSURERC: National Union Fire Insurance Company PO Box 460846 INSURER D: INSURER E: Escondido CA 92046 INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL ~UBR ,r:BM&;(..~I . ,~gr&ri'l'v~, LIMITS LTR 11.,C:D IW\/n POLICY NUMBER ~ COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000.00 D CLAIMS-MADE ~ OCCUR DAMAGE TO RENTED $ 100,000 PREMISES (Ea occurrence\ D MED EXP (Any one person $ 5,000.00 A D y y 101 GL 0060516-01 08/09/2017 08/09/2018 PERSONAL & ADV INJURY $ 1,000,000.00 GEN'L AGGREGATE LIMIT APPLIES PER GENERAL AGGREGATE $ 2,000,000.00 ~ POLICY D PRO-JECT D LOC PRODUCTS -COMP/OP AGG $ 2,000,000.00 D OTHER $ AUTOMOBILE LIABILITY YEo~~h~Je~t\'1NGLE LIMIT $ D ANYAUTO BODILY INJURY (Per person) $ D SCHEDULED B D f~~~DONL y AUTOS BODILY INJURY (Per accident) $ D .t0~6~ ONL y D NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY r Per accident\ D D $ D UMBRELLA LIAB ~OCCUR EACH OCCURRENCE $ 1,000,000 C ~ EXCESS LIAB D CLAIMS-MADE EBU 027548268 03/28/2018 03/28/2019 AGGREGATE $ 1,000,000 D DED D RETENTION $ $ WORKERS COMPENSATION D ~¥fTIITF onH- AND EMPLOYERS' LIABILITY YIN ANY PROPRIETORIPARTNER/EXECUTIVD E L EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? NIA (Mandatory in NH) E.L. DISEASE -EA EMPLOYE $ If yes, describe under E.L DISEASE -POLICY LIMIT $ DESCRIPTION OF OPERATIONS below DESCRIPTION OF OPERATIONS I LOCATIONS / VEHICLES (Attach ACORD 101, Additional Remarks Schedule, If more space Is required) The City of Carlsbad, its officials, employees and volunteers are named as additional insured hereunder as respects liability arising out of activities performed by or on behalf of the Named Insured. Coverage under this policy shall be primary insurance as repects the City, its officials, employees and volunteers. CERTIFICATE HOLDER I City of Carlsbad/ CMWD c/o EXIGIS Insurance Compliance Service P.O. Box4668-ECM 35050 New York, NY 10163-4668 ACORD 25 (2016/03) QF CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD 101 GL 0060516-01 ENDT. #002 EFF: 03/23/2018 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. POLICY CHANGES POLICY NUMBER 101 GL 0060516-01 NAMED INSURED Bill Collier POLICY CHANGES EFFECTIVE 03/23/2018 COVERAGE PARTS AFFECTED COMMERCIAL GENERAL LIABILITY COVERAGE PART CHANGES COMPANY Colony Insurance Company AUTHORIZED REPRESENTATIVE Craig Comeaux In consideration of the premium charged, it is understood and agreed that the policy is amended as follows: Premium for the following Coverages is Fully Earned: ONE ADDITIONAL INSURED (THE CITY OF CARLSBAD, ITS OFFICEIALS, EMPLOYEES AND VOLUNTEERS) IS ADDED AND MADE PART OF THE POLICY PER THE ATTACHED FORM CG2010. JS/LC 03/27/2018 ALL OTHER TERMS AND CONDITIONS OF THE POLICY REMAIN UNCHANGED Authorized Representative Signature IL12011185 Copyright, Insurance Services Office, Inc., 1983 Copyright, ISO Commercial Risk Services, Inc., 1983 Page 1 of 1 101 GL 0060516-01 ENDT. #002 EFF: 03/23/2018 COMMERCIAL GENERAL LIABILITY CG 2010 0413 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED -OWNERS, LESSEES OR CONTRACTORS -SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location(s) Of Covered Operations The City of Carlsbad, its officeials, employees and As required in written contract with the named insured volunteersService C/O EXIGIS Insurance Compliance Service P.O. Box 4668-ECM 35050 New York, NY 10163 Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II -Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured(s) at the location(s) designated above. However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to B. With respect to the insurance afforded to These additional insureds, the following additional exclusions apply: This insurance does not apply to "bodily injury" or "property damage" occurring after: 1. All work, including materials, parts or equipment furnished in connection with such work, on the project ( other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or 2. That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. CG 20 10 0413 © Insurance Services Office, Inc., 2012 Page 1 of 2 provide for such additional insured. C. With respect to the insurance afforded to these additional insureds, the following is added to Section Ill -Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or 101 GL 0060516-01 ENDT. #002 EFF: 03/23/2018 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the Applicable Limits of Insurance shown in The Declarations. Page 2 of 2 © Insurance Services Office, Inc., 2012 CG 2010 0413 ACORD® CERTIFICATE OF LIABILITY INSURANCE I DATE (MM/DD/YYYY) ...__,. 03-23-2018 I THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS -ERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES ELOW . THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED .. EPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: ABRAHAM RYNGLER INSURANCE SERVICES PHONE 661-726-3345 I FAX 661-726-5267 IAlr Nn Cv+\; /A/C Nol: 315 Arneill Rd Ste 202 E-MAIL ADDRESS: INSURER(S) AFFORDING COVERAGE NAIC# Camarillo CA 93010 INSURER A: INSURED INSURER B: California Automobile Insurance Company 38342 COLLIER CONSTRUCTION INSURER C: 3509 Driftwood Piace INSURER D: INSURER E: Oceanside CA 92056 INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR TYPE OF INSURANCE ,.,.,n wvn POLICY NUMBER /MM/DD/YYYY\ /MM/DD/YYYY\ COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ ~ D CLAIMS-MADE D OCCUR DAMAGE TO RENTED PREMISES (Ea occurrence) $ ~ MED EXP (Any one person) $ PERSONAL & ADV INJURY $ ~ GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ Fl DPRO-DLOC PRODUCTS -COMP/OP AGG $ POLICY JECT OTHER: $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ 1,000,000 BA040000028923 08-12-2017 08-12-2018 (Ea accident) L£ ANY AUTO BODILY INJURY (Per person) $ ALL OWNED -SCHEDULED B AUTOS AUTOS BODILY INJURY (Per accident) $ .L cL_ NON-OWNED PROPERTY DAMAGE $ HIRED AUTOS AUTOS (Per accident) $ UMBRELLA LIAB H OCCUR EACH OCCURRENCE $ - EXCESS LIAB CLAIMS-MADE AGGREGATE $ OED I I RETENTION $ $ WORKERS COMPENSATION I ~ftuTE I I OTH- AND EMPLOYERS' LIABILITY ER Y/N ANY PROPRIETOR/PARTNER/EXECUTIVE D N/A E.L. EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? (Mandatory in NH) E.L. DISEASE -EA EMPLOYEE $ If yes, describe under E.L. DISEASE -POLICY LIMIT $ DESCRIPTION OF OPERATIONS below DESCRIPTION OF OPERATIONS/ LOCATIONS/ VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) RE: Beach Access Stairway Repairs at Sycamore Avenue, BID NO. PWS18-121TRAIN, Project NO. 3896 CERTIFICATE HOLDER CANCELLATION City of Carlsbad/CMWD c/o EXIGIS Insurance Compliance Services SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Box 4668 -ECM #35050 I New York 1 ACORD 25 (2014/01) NY 10163-4668 AUTHORIZED REPRESENTATIVE J. \ © 1988-2014 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD California Automobile Insurance Company P.O. Box 10730 A MERCURY -'• INSURANCE Santa Ana, CA 92711-0730 Customer Service: {800) 503-3724 BUSINESS AUTO POLICY ADDITIONAL INSURED Amended Declarations Effective Date: 03/23/2018 NAMED INSURED: COLLIER CONSTRUCTION 3509 Driftwood Pl Oceanside, CA 92056-4733 Insurance Company: Policy Number: Policy Period: Additional Insured: Address: Endorsements Attached: AGENT: RYNGLER, ABRAHAM INS BRKRS 315 ARNE ILL AVE STE 202 CAMARILLO, CA 93010 (888) 799-0699 California Automobile Insurance Company BA040000028923 From: 08/12/2017 to 08/12/2018 at 12:01 AM Standard Time at your mailing address CITY OF CARLSBAD/CMWD C/O EXIGIS INSURANCE COMPLIANCE SVC PO Box 4668, New York NY 10163 CA 20 48 02 99 -Designated Insured Covered Autos: Limits of Insurance: MCADS910711 , AUTOMOBllfUAIII.ITY P Symbol 7 -Specifically Described "Autos", Symbol 8 -Hired "Autos" Only, Symbol 9 -Nonowned "Autos" Only $1,000,000 CSL Page 1 of 1 CERTHOLDER COPY STATE 1....-0MPENSA~IUN INSLJ~A.NCE P.O. BOX 8192, PLEASANTON, CA 94588 FUNO CERTIFICATE OF WORKERS' COMPENSATION INSURANCE ISSUE DATE: 03-27-2018 CITY DF CARLSBAD-CMWD EXIGIS INSURANCE COMPLIANCE SERVICES PO BOX 4668 NEW YORK NY 10163-4668 SP GROUP: POLICY NUMBER: 9164064-2017 CERTIFICATE ID: 8 CERTIFICATE EXPIRES: 08-06-2018 08-06-2017/08-06-2018 THIS CERTIFICATE SUPERSEDES AND CORRECTS CERTIFICATE# 7 DATED 03-23-2018 JOB:CARLSBAD CA This is to certify that we have issued a valid Workers' Compensation insurance policy in a form approved by the California Insurance Commissioner to the employer named below for the policy period indicated. This policy is not subject to cancellation by the Fund except upon 30 days advance written notice to the employer. We will also give you 30 days advance notice should this policy be cancelled prior to its normal expiration. This certificate of insurance is not an insurance policy and does not amend. extend or alter the coverage afforded by the policy listed herein. Notwithstanding any requirement, term or condition of any contract or other document with respect to which this certificate of insurance may be issued or to which it may pertain, the insurance afforded by the policy described herein is subject to all the terms, exclusions, and conditions, of such policy. ~ti~ d--dl~ Authorized Representative President and CEO UNLESS INDICATED OTHERWISE BY ENDORSEMENT, COVERAGE UNDER THIS POLICY EXCLUDES THE FOLLOWING: THOSE NAMED IN THE POLICY DECLARATIONS AS AN INDIVIDUAL EMPLOYER OR A HUSBAND AND WIFE EMPLOYER; EMPLOYEES COVERED ON A COMPREHENSIVE PERSONAL LIABILITY INSURANCE POLICY ALSO AFFORDING CALIFORNIA WORKERS' COMPENSATION BENEFITS; EMPLOYEES EXCLUDED UNDER CALIFORNIA WORKERS' COMPENSATION LAW. EMPLOYER'S LIABILITY LIMIT INCLUDING DEFENSE COSTS: $1,000,000 PER OCCURRENCE. ENDORSEMENT #0015 ENTITLED ADDITIONAL INSURED EMPLOYER EFFECTIVE 2018-03-23 IS ATTACHED TO AND FORMS A PART OF THIS POLICY. NAME OF ADDITIONAL INSURED: CITY OF CARLSBAD-CMWD ENDORSEMENT #2065 ENTITLED CERTIFICATE HOLDERS' NOTICE EFFECTIVE 08-06-2017 IS ATTACHED TO AND FORMS A PART OF THIS POLICY. ENDORSEMENT #2570 ENTITLED WAIVER OF SUBROGATION EFFECTIVE 2018-03-27 IS ATTACHED TO AND FORMS A PART OF THIS POLICY. THIRD PARTY NAME: CITY OF CARLSBAD-CMWD EMPLOYER COLLIER, WILLIAM DBA: COLLIER CONSTRUCTION 3509 DRIFTWOOD PL OCEANSIDE CA 92056 (REV.7-2014) PRINTED [DTG,VL] 03-27-2018 SP POLICYHOLDER COPY STATE i,_.UMPENSATIVN INSLJ~.A.NCE P.O. BOX 8192, PLEASANTON, CA 94588 FUND CERTIFICATE OF WORKERS' COMPENSATION INSURANCE ISSUE DATE: 03-27-2018 CITY OF CARLSBAD-CMWD EXIGIS INSURANCE COMPLIANCE SERVICES PO BOX 4668 NEW YORK NY 10163-4668 SP GROUP: POLICY NUMBER: 9164064-2017 CERTIFICATE ID: 8 CERTIFICATE EXPIRES: 08-06-2018 08-06-2017/08-06-2018 THIS CERTIFICATE SUPERSEDES AND CORRECTS CERTIFICATE# 7 DATED 03-23-2018 JOB:CARLSBAD CA This is to certify that we have issued a valid Workers' Compensation insurance policy in a form approved by the California Insurance Commissioner to the employer named below for the policy period indicated. This policy is not subject to cancellation by the Fund except upon 30 days advance written notice to the employer. We will also give you 30 days advance notice should this policy be cancelled prior to its normal expiration. This certificate of insurance is not an insurance policy and does not amend, extend or alter the coverage afforded by the policy listed herein. Notwithstanding any requirement, term or condition of any contract or other document with respect to which this certificate of insurance may be issued or to which it may pertain, the insurance afforded by the policy described herein is subject to all the terms, exclusions, and conditions, of such policy. ~tie,; d---.dl~ Authorized Representative President and CEO UNLESS INDICATED OTHERWISE BY ENDORSEMENT, COVERAGE UNDER THIS POLICY EXCLUDES THE FOLLOWING: THOSE NAMED IN THE POLICY DECLARATIONS AS AN INDIVIDUAL EMPLOYER OR A HUSBAND AND WIFE EMPLOYER; EMPLOYEES COVERED ON A COMPREHENSIVE PERSONAL LIABILITY INSURANCE POLICY ALSO AFFORDING CALIFORNIA WORKERS' COMPENSATION BENEFITS; EMPLOYEES EXCLUDED UNDER CALIFORNIA WORKERS' COMPENSATION LAW. EMPLOYER'S LIABILITY LIMIT INCLUDING DEFENSE COSTS: $1,000,000 PER OCCURRENCE. ENDORSEMENT #0015 ENTITLED ADDITIONAL INSURED EMPLOYER EFFECTIVE 2018-03-23 IS ATTACHED TO AND FORMS A PART OF THIS POLICY. NAME OF ADDITIONAL INSURED: CITY OF CARLSBAD-CMWD ENDORSEMENT #2065 ENTITLED CERTIFICATE HOLDERS' NOTICE EFFECTIVE 08-06-2017 IS ATTACHED TO AND FORMS A PART OF THIS POLICY. ENDORSEMENT #2570 ENTITLED WAIVER OF SUBROGATION EFFECTIVE 2018-03-27 IS ATTACHED TO AND FORMS A PART OF THIS POLICY. THIRD PARTY NAME: CITY OF CARLSBAD-CMWD EMPLOYER COLLIER, WILLIAM OBA: COLLIER CONSTRUCTION 3509 DRIFTWOOD PL OCEANSIDE CA 92056 (REV.7-2014) PRINTED [DTG,VL] 03-27-2018 SP WAIVER OF SUBROGATION NOTICE Enclosed is your copy of a certificate of insurance on which the certificate holder required a waiver of subrogation: 1. Please be advised that a waiver of subrogation requires that a 3% surcharge will be applied by State Fund ONLY to the premium assessed on the payroll of your employees earned while engaged in work for that certificate holder who requested the waiver. (Note: if you have no employee payroll on that job, then there is no charge.) 2. To apply the 3% surcharge, you must also agree to maintain accurately segregated payroll records for employees engaged in work on job/s for the certificate holder who has the waiver. The payroll records are subject to verification by an auditor. Example: Payroll for job: Sample Rate: Regular Premium equals: Surcharge: $5,000.00 13.30% $ 665.00 3.00% Additional Waiver charge: $ 19.95 Total premium equals $ 684.95 (665.00 + 19.95) BIDDER'S STATEMENT RE DEBARMENT (To Accompany Proposal) BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN 1) Have you or any of your subcontractors ever been debarred as an irresponsible bidder by another jurisdiction in the State of California? V yes no 2) If yes, what was/were the name(s) of the agency(ies) and what was/were the period(s) of debarment(s)? Attach additional copies of this page to accommodate more than two debarments. party debarred party debarred agency agency period of debarment period of debarment BY CONTRACTOR: Collier Coos±r11c±ion (name of Contractor) By:~~~ ~:;d (sign here) w'i\liam E-.~ll;er lL-OWV\U (print name/title) Page _L of __ \ _ pages of this Re Debarment form ('\ •tr' Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 21 of 101 Pages BIDDER'S DISCLOSURE OF DISCIPLINE RECORD (To Accompany Proposal) BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN Contractors are required by law to be licensed and regulated by the Contractors' State License Board which has jurisdiction to investigate complaints against contractors if a complaint regarding a patent act or omission is filed within four years of the date of the alleged violation. A complaint regarding a latent act or omission pertaining to structural defects must be filed within 10 years of the date of the alleged violation. Any questions concerning a contractor may be referred to the Registrar, Contractors' State License board, P.O. Box 26000, Sacramento, California 95826. 1) Have you ever had your contractor's license suspended or revoked by the California Contractors' State license Board two or more times within an eight year period? _L yes no 2) Has the suspension or revocation of your contractor's license ever been stayed? N /A- yes no 3) Have any subcontractors that you propose to perform any portion of the Work ever had their contractor's license suspended or revoked by the California Contractors' State license Board two or more times within an eight year period? V yes no 4) Has the suspension or revocation of the license of any subcontractor's that you propose to perform any portion of the Work ever been stayed? IJ / A yes no 5) If the answer to either of 1. or 3. above is yes fully identify, in each and every case, the party disciplined, the date of and violation that the disciplinary action pertain to, describe the nature of the violation and the disciplinary action taken therefore. NIA (If needed attach additional sheets to provide full disclosure.) Page -L of __l_ pages of this Disclosure of Discipline form ,., • ., Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 22 of 101 Pages BIDDER'S DISCLOSURE OF DISCIPLINE RECORD (CONTINUED) (To Accompany Proposal) BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN 1) If the answer to either of 2. or 4. above is yes fully identify, in each and every case, the party whose discipline was stayed, the date of the violation that the disciplinary action pertains to, describe the nature of the violation and the condition (if any) upon which the disciplinary action was stayed. hi/A (If needed attach additional sheets to provide full disclosure.) BY CONTRACTOR: GI /,'er Corotcttc:hon (name of Contractor) By:~~~~EF: (sign here) W; u;O,!M E. Collier Jr -OWV\e,C (print name/title) Page _1_ of _.2_ pages of this Disclosure of Discipline form ,, •+;' Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 23 of 101 Pages NONCOLLUSION DECLARATION TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID PUBLIC CONTRACT CODE SECTION 7106 BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN The undersigned declares: I am the Owtiec of Collier Gnstr., the party making the foregoing bid. The bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation. The bid is genuine and not collusive or sham. The bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid. The bidder has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or to refrain from bidding. The bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to fix any overhead, profit, or cost element of the bid price, or of that of any other bidder. All statements contained in the bid are true. The bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, to any corporation, partnership, company, association, organization, bid depository, or to any member or agent thereof, to effectuate a collusive or sham bid, and has not paid, and will not pay, any person or entity for such purpose. Any person executing this declaration on behalf of a bidder that is a corporation, partnership, joint venture, limited liability company, limited liability partnership, or any other entity, hereby represents that he or she has full power to execute, and does execute, this declaration on behalf of the bidder. I declare under penalty of perjury under the laws of the State of California that the foregoing is true and corrj: and that. this qeclaration is executed on Mo rc,.b 20 +b , 2oj!_ at Cl€0Nls-i e[cityJ,Cali:forn ,~state]. ,., •,;' Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 24 of 101 Pages CONTRACT PUBLIC WORKS This agreement is made this U [)-/;h day of___,.___-+-'......._........._ _ ___,_ _______ , 2018, by and between the City of Carlsbad, California, a munic· al corporation, (hereinafter called "City"), and Collier Construction, a sole proprietorship, whose principal place of business is 3509 Driftwood Place, Oceanside, CA 92056 (hereinafter called "Contractor"). City and Contractor agree as follows: 1. Description of Work. Contractor shall perform all work specified in the Contract documents for: BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN (hereinafter called "project") 2. Provisions of Labor and Materials. Contractor shall provide all labor, materials, tools, equipment, and personnel to perform the work specified by the Contract Documents. 3. Contract Documents. The Contract Documents consist of this Contract, Notice Inviting Bids, Contractor's Proposal, Bidder's Bond, Noncollusion Declaration, Designation of Subcontractors, Technical Ability and Experience, Bidder's Statement Re Debarment, Escrow Agreement, Release Form, the Plans and Specifications, the General Provisions, addendum(s) to said Plans and Specifications and General Provisions, and all proper amendments and changes made thereto in accordance with this Contract or the Plans and Specifications, and all bonds for the project; all of which are incorporated herein by this reference. Contractor, her/his subcontractors, and materials suppliers shall provide and install the work as indicated, specified, and implied by the Contract Documents. Any items of work not indicated or specified, but which are essential to the completion of the work, shall be provided at the Contractor's expense to fulfill the intent of said documents. In all instances through the life of the Contract, the City will be the interpreter of the intent of the Contract Documents, and the City's decision relative to said intent will be final and binding. Failure of the Contractor to apprise subcontractors and materials suppliers of this condition of the Contract will not relieve responsibility of compliance. 4. Payment. For all compensation for Contractor's performance of work under this Contract, City shall make payment to the Contractor per section 9-3 PAYMENT of the General Provisions section of this contract. The Engineer will close the estimate of work completed for progress payments on the last working day of each month. The City shall withhold retention as required by Public Contract Code Section 9203. l' •.--Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 25 of 101 Pages 5. Independent Investigation. Contractor has made an independent investigation of the jobsite, the soil conditions at the jobsite, and all other conditions that might affect the progress of the work, and is aware of those conditions. The Contract price includes payment for all work that may be done by Contractor, whether anticipated or not, in order to overcome underground conditions. Any information that may have been furnished to Contractor by City about underground conditions or other job conditions is for Contractor's convenience only, and City does not warrant that the conditions are as thus indicated. Contractor is satisfied with all job conditions, including underground conditions and has not relied on information furnished by City. 6. Hazardous Waste or Other Unusual Conditions. If the contract involves digging trenches or other excavations that extend deeper than four feet below the surface Contractor shall promptly, and before the following conditions are disturbed, notify City, in writing, of any: A. Hazardous Waste. Material that Contractor believes may be material that is hazardous waste, as defined in section 25117 of the Health and Safety Code, that is required to be removed to a Class I, Class 11, or Class 111 disposal site in accordance with provisions of existing law. B. Differing Conditions. Subsurface or latent physical conditions at the site differing from those indicated. C. Unknown Physical Conditions. Unknown physical conditions at the site of any unusual nature, different materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the contract. City shall promptly investigate the conditions, and if it finds that the conditions do materially so differ, or do involve hazardous waste, and cause a decrease or increase in contractor's costs of, or the time required for, performance of any part of the work shall issue a change order under the procedures described in this contract. In the event that a dispute arises between City and Contractor whether the conditions materially differ, or involve hazardous waste, or cause a decrease or increase in the contractor's cost of, or time required for, performance of any part of the work, contractor shall not be excused from any scheduled completion date provided for by the contract, but shall proceed with all work to be performed under the contract. Contractor shall retain any and all rights provided either by contract or by law which pertain to the resolution of disputes and protests between the contracting parties. 7. Immigration Reform and Control Act. Contractor certifies it is aware of the requirements of the Immigration Reform and Control Act of 1986 (8 USC sections 1101-1525) and has complied and will comply with these requirements, including, but not limited to, verifying the eligibility for employment of all agents, employees, subcontractors, and consultants that are included in this Contract. 8. Prevailing Wage. Pursuant to the California Labor Code, the director of the Department of Industrial Relations has determined the general prevailing rate of per diem wages in accordance with California Labor Code, section 1773 and a copy of a schedule of said general prevailing wage rates is on file in the office of the City Engineer, and is incorporated by reference herein. Pursuant to California Labor Code, section 1775, Contractor shall pay prevailing wages. Contractor shall post copies of all applicable prevailing wages on the job site. Contractor shall comply with California Labor Code, section 1776, which generally requires keeping accurate payroll records, verifying and certifying payroll records, and making them available for inspection. Contractor shall require all subcontractors to comply with Section 1776. l'\ •f' Revised 7 /19/17 PWS18-121TRAN-Contract No. 3896 Page 26 of 101 Pages 9. Indemnification. Contractor shall assume the defense of, pay all expenses of defense, and indemnify and hold harmless the City, and its officers and employees, from all claims, loss, damage, injury and liability of every kind, nature and description, directly or indirectly arising from or in connection with the performance of the Contract or work; or from any failure or alleged failure of Contractor to comply with any applicable law, rules or regulations including those relating to safety and health; and from any and all claims, loss, damages, injury and liability, howsoever the same may be caused, resulting directly or indirectly from the nature of the work covered by the Contract, except for loss or damage caused by the sole or active negligence or willful misconduct of the City. The expenses of defense include all costs and expenses including attorneys' fees for litigation, arbitration, or other dispute resolution method. Contractor shall also defend and indemnify the City against any challenges to the award of the contract to Contractor, and Contractor will pay all costs, including defense costs for the City. Defense costs include the cost of separate counsel for City, if City requests separate counsel. Contractor shall also defend and indemnify the City against any challenges to the award of the contract to Contractor, arising in whole or in part from alleged inaccuracies or misrepresentation by the Contractor, whether intentional or otherwise, and Contractor will pay all costs, including defense costs for the City. Defense costs include the cost of separate counsel for City, if City requests separate counsel. 10. Insurance. Contractor shall procure and maintain for the duration of the contract insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his or her agents, representatives, employees or subcontractors. Said insurance shall meet the City's policy for insurance as stated in City Council Policy# 70. (A) Coverages And Limits Contractor shall maintain the types of coverages and minimum limits indicted herein: a. Commercial General Liability Insurance: $2,000,000 combined single limit per occurrence for bodily injury and property damage. If the policy has an aggregate limit, a separate aggregate in the amounts specified shall be established for the risks for which the City or its agents, officers or employees are additional insured. b. Business Automobile Liability Insurance: $2,000,000 combined single limit per accident for bodily injury and property damage. In addition, the auto policy must cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. c. Workers' Compensation and Employers' Liability Insurance: Workers' compensation limits as required by the Labor Code of the State of California and Employers' Liability limits of $1,000,000 per incident. Workers' compensation offered by the State Compensation Insurance Fund is acceptable to the City. (B) Additional Provisions: Contractor shall ensure that the policies of insurance required under this agreement with the exception of Workers' Compensation and Business Automobile Liability Insurance contain, or are endorsed to contain, the following provisions. a. The City, its officials, employees and volunteers are to be covered as additional insured as respects: liability arising out of activities performed by or on behalf of the Contractor; products and completed operations of the contractor; premises owned, leased, hired or borrowed by the contractor. The coverage shall contain no special limitations on the scope of protection afforded to the City, its l' •+;' Revised 7/19/17 PWS 18-121 TRAN-Contract No. 3896 Page 27 of 101 Pages officials, employees or volunteers. All additional insured endorsements must be evidenced using separate documents attached to the certificate of insurance; one for each company affording general liability, and employers' liability coverage. b. The Contractor's insurance coverage shall be primary insurance as respects the City, its officials, employees and volunteers. Any insurance or self-insurance maintained by the City, its officials, employees or volunteers shall be in excess of the contractor's insurance and shall not contribute with it. c. Any failure to comply with reporting provisions of the policies shall not affect coverage provided to the City, its officials, employees or volunteers. d. Coverage shall state that the contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. (C) Notice Of Cancellation. Each insurance policy required by this agreement shall be endorsed to state that coverage shall not be nonrenewed, suspended, voided, canceled, or reduced in coverage or limits except after ten (10) days' prior written notice has been sent to the City by certified mail, return receipt requested. (D) Deductibles And Self-Insured Retention (S.I.R.) Levels. Any deductibles or self-insured retention levels must be declared to and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles or self-insured retention levels as respects the City, its officials and employees; or the contractor shall procure a bond guaranteeing payment of losses and related investigation, claim administration and defense expenses. (E) Waiver Of Subrogation. All policies of insurance required under this agreement shall contain a waiver of all rights of subrogation the insurer may have or may acquire against the City or any of its officials or employees. (F) Subcontractors. Contractor shall include all subcontractors as insured under its policies or shall furnish separate certificates and endorsements for each subcontractor. Coverages for subcontractors shall be subject to all of the requirements stated herein. (G) Acceptability Of Insurers. Insurance is to be placed with insurers that have a rating in Best's Key Rating Guide of at least A-:VII. Insurers must also be authorized to transact the business of insurance by the State of California Insurance Commissioner as admitted carriers as evidenced by a listing in the official publication of the Department of Insurance of the State of California and/or under the standards specified by City Council Policy# 70. (H) Verification Of Coverage. Contractor shall furnish the City with certificates of insurance and original endorsements affecting coverage required by this clause. The certificates and endorsements for each insurance policy are to be signed by a person authorized by that insurer to bind coverage on its behalf. The certificates and endorsements are to be in forms approved by the City and are to be received and approved by the City before the Contract is executed by the City. (I) Cost Of Insurance. The Cost of all insurance required under this agreement shall be included in the Contractor's bid. 11. Claims and Lawsuits. All claims by Contractor shall be resolved in accordance with Public Contract Code section 9204, which is incorporated by reference. A copy of Section 9204 is included in Section 3 of the General Provisions. In addition, all claims by Contractor for $375,000 or less shall be resolved in accordance with the provisions in the Public Contract Code, Division 2, Part 3, Chapter 1, Article 1.5 (commencing with section 20104) which are incorporated by reference. A copy of Article ('\ •tr Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 28 of 101 Pages 1.5 is included in Section 3 of the General Provisions. In the event of a conflict between Section 9204 and Article 1.5, Section 9204 shall apply. Notwithstanding the provisions of this section of the contract, all claims shall comply with the Government Tort Claim Act (section 900 et seq., of the California Government Code) for any claim or cause of action for money or damages prior to filing any lawsuit for breach of this agreement. (A) Assertion of Claims. Contractor hereby agrees that any contract claim submitted to the City must be asserted as part of the contract process as set forth in this agreement and not in anticipation of litigation or in conjunction with litigation. (B) False Claims. Contractor acknowledges that if a false claim is submitted to the City, it may be considered fraud and the Contractor may be subject to criminal prosecution. (C) Government Code. Contractor acknowledges that California Government Code sections 12650 et seq., the False Claims Act, provides for civil penalties where a person knowingly submits a false claim to a public entity. These provisions include false claims made with deliberate ignorance of the false information or in reckless disregard of the truth or falsity of the information. (D) Penalty Recovery. If the City of Carlsbad seeks to recover penalties pursuant to the False Claims Act, it is entitled to recover its litigation costs, including attorney's fees. (E) Debarment for False Claims. Contractor hereby acknowledges that the filing of a false claim may subject the Contractor to an administrative debarment proceeding wherein the Contractor may be prevented from further bidding on public contracts for a period of up to five years. (F) Carlsbad Municipal Code. The provisions of Carlsbad Municipal Code sections 3.32.025, 3.32.026, 3.32.027 and 3.32.028 pertaining to false claims are incorporated herein by reference. (G) Debarment from Other Jurisdictions. Contractor hereby acknowledges that debarment by another jurisdiction is grounds for the City of Carlsbad to disqualify the Contractor or subcontractor from participating in future contract bidding. (H) Jurisdiction. Contractor agrees and hereby stipulates that the proper venue and jurisdiction for resolution of any disputes between the parties arising out of this agreement is San Diego County, California. I have read and understand all provisions of Section 11 above. ~ init ____ init 12. Maintenance of Records. Contractor shall maintain and make available at no cost to the City, upon request, records in accordance with sections 1776 and 1812 of Part 7, Chapter 1, Article 2, of the Labor Code. If the Contractor does not maintain the records at Contractor's principal place of business as specified above, Contractor shall so inform the City by certified letter accompanying the return of this Contract. Contractor shall notify the City by certified mail of any change of address of such records. 13. Labor Code Provisions. The provisions of Part 7, Chapter 1, commencing with section 1720 of the Labor Code are incorporated herein by reference. 14. Security. Securities in the form of cash, cashier's check, or certified check may be substituted for any monies withheld by the City to secure performance of this contract for any obligation established by this contract. Any other security that is mutually agreed to by the Contractor and the City may be substituted for monies withheld to ensure performance under this Contract. l' •+' Revised 7 /19/17 PWS18-121TRAN-Contract No. 3896 Page 29 of 101 Pages 15. Unfair Business Practices. In entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or subcontractor offers and agrees to assign to the awarding body all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec. 15) or under the Cartwright Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or the subcontract. This assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment by the parties. 16. Provisions Required by Law Deemed Inserted. Each and every provision of law and clause required by law to be inserted in this Contract shall be deemed to be inserted herein and included herein, and if, through mistake or otherwise, any such provision is not inserted, or is not correctly inserted, then upon application of either party, the Contract shall forthwith be physically amended to make such insertion or correction. 17. Additional Provisions. Any additional provisions of this agreement are set forth in the "General Provisions" or "Supplemental Provisions" attached hereto and made a part hereof. NOTARIAL ACKNOWLEDGMENT OF EXECUTION BY ALL SIGNATORIES MUST BE ATTACHED (CORPORA TE SEAL) CONTRACTOR: Collier Construction a California -OorporatieR Ci;,..FC:.,, (name of Contractor) By: ·0-z;. L-c:: y" ~;C I (sign here) W; ll,1 a m G, Lr? /J/e r $- (print name and title) By: ____________ _ (sign here) (print name and title) CITY OF CARLSBAD a municipal corporation of the State of California PLEASESEEATTACHED CALIFORNIA 0 JURAT p ACKNOWLEDGEMENT President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under the corporate seal empowering that officer to bind the corporation. APPROVED AS TO FORM: CELIA A. BREWER CityAtto~ By:~ Deputy City ~'3 "-' • ., Revised 7/19/17 PWS18-121TRAN-Contract No. 3896 Page 30 of 101 Pages ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of ,{a._.-, 0, tj CJ On 2 b rn a...-rC.h 1.. CJ' ~ before me, f'.Je .. +-e..--.--,) c;S J.-i u&L C'(.(.__ s 1-,'J I O (insert name and title of the officer) personally appeared t,Ui'ti; lLrr, EOwc<-,-rd ·-yt::: Cc;//, 12-'c"' , who proved to me on the basis of satisfactory evidence to be the µefsonts} whose nam~e 7-Yl;)__scribed to the within instrument and acknowle_9.Q.,ed to me tha1(b9/SAe/they executed the same in ~/th'eu:..authorized capacity('tes-), and that b~/hsr/thQ.ir signaturetsl on the instrument the perso~. or the entity upon behalf of which the person{e.) acted, executed the instrument. I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. i············, . PETER JOSHUA CASTILLO : ~·::· · . Notary Public -California : i •:!>; ' · San Diego County ! . . Commission#2196475 My Comm, Eipires May 11, 2021 (Seal) CALIFORNIA ALL-PURPOS~ ACKNOWLEDGMENT CIVIL CODE§ 1189 • A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of :Sao D j -ee,o On h,c;.,c:. 3P J d--0 1 'iS Date before me, J,, o,,-b cJ aT. 1Ze ,y.e-~ j\)btg"i Pu.bl z c , Here Insert Name an& Title of the Officer personally appeared __ 6_____,A~''---''/~~L-·~-fu~_,-0~_:e:C~~;-c:::, ______________ _ Nameferof Signer(8)"' who proved to me on the basis of satisfactory evidence to be the person.(sf whose name~ is/ai:e. subscribed to the within instrument and acknowledged to me that hc.4.heftl"ley executed the same in his/h0r/tl"lei1 authorized capacity(iesr,'and that by his/hor/t19eir signatureMun the instrument the person.(ar, or the entity upon behalf of which the perso~acted, executed the instrument. .··, LETICIA T. REYES f -c5 -Notary Public -California i Z:-,f San Diego County i Commission# 2211528 - My Comm. Expires Aug 26, 2021 Place Notary Seal Above I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature~ T»O ~ T. ~D ~ Signature of Nota'Public ---------------OPTIONAL--------------- Though this section is optional, completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of hed Document Title or Type of Docume . =-.,=------------- Number of Pages: ___ Sign Capacity(ies) Claimed by Signer(s) Signer's Name:-------------,,.~- D Corporate Officer -Title(s): --~,e._ __ _ D Partner -D Limited D Gene D Individual D Attorne · Fact D Attorney in Fact D Trustee D G D Trustee ardian or Conservator D Other:--~-----------D Other: ______________ _ Signer Is Rep 014 National Notary Association • www.NationalNotary.org • 1-800-US NOTARY (1-800-876-6827) Premium will be adjusted based on final contract price Bond No.: 894419P LABOR AND MATERIALS BOND Premium: Included in Performance Bond WHEREAS, the City of Carlsbad, State of California, on March 20, 2018 has administratively awarded to COLLIER CONSTRUCTION (hereinafter designated as the "Principal"), a Contract for: BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN in the City of Carlsbad, in strict conformity with the drawings and specifications, and other Contract Documents now on file in the Office of the City Clerk of the City of Carlsbad and all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond, providing that if Principal or any of their subcontractors shall fail to pay for any materials, provisions, provender or other supplies or teams used in, upon or about the perfor- mance of the work agreed to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same to the extent hereinafter set forth. NOW, THEREFORE, WE, COLLIER CONSTRUCTION , as Principal, (hereinafter designated as the "Contractor"), and Developers Surety and Indemnity Company as Surety, are held firmly bound unto the City of Carlsbad in the sum of EIGHTY-SEVEN THOUSAND TWO HUNDRED EIGHT DOLLARS AND ZERO CENTS ($87,208.00), said sum being an amount equal to: One hun- dred percent ( 100%) of the total amount payable under the terms of the contract by the City of Carls- bad, and for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the Contractor or his/her subcontractors fail to pay for any materials, provisions, provender, supplies, or teams used in, upon, for, or about the performance of the work contracted to be done, or for any other work or labor thereon of any kind, consistent with California Civil Code section 9100, or for amounts due under the Unemployment In- surance Code with respect to the work or labor performed under this Contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of the contractor and subcontractors pursuant to section 13020 of the Unem- ployment Insurance Code with respect to the work and labor, that the Surety will pay for the same, and, also, in case suit is brought upon the bond, reasonable attorney's fees, to be fixed by the court consistent with California Civil Code section 9554. This bond shall inure to the benefit of any of the persons named in California Civil Code section 9100, so as to give a right of action to those persons or their assigns in any suit brought upon the bond. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed hereunder or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications. l'\ • ., Revised 7 /19/17 PWS18-121TRAN Page 31 of 101 Pages In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. Executed by CONTRACTOR this day of Ho vc k, CONTRACTOR: COLLIER CONSTRUCTION 2 b ti, . 20 I & (name of Contractor) By:?v:::~ ~ ~~ (sign here) /,,v';(l,owz £ Cr,tfit:-r :g:.. (print name here) (Title and Organization of Signatory) By:-------------(sign here) (print name here) (Title and Organization of signatory) Executed by SURETY this 26th day of March -----------' 20 18 SURETY: Developers Surety and Indemnity Company (name of Surety) 17771 Cowan, Ste. JOO, Irvine, CA 92614 (address of Surety) 619-521-9686 (telephone number of Surety) Q ' ~ 11 ;1 .1 /) {. . 7 """' By:~ VU.CVW~. (signature of Attorney-in-Fact) Dana Michaelis, Attorney-in-Fact (printed name of Attorney-in-Fact) (Attach corporate resolution showing current power of attorney.) (Proper notarial acknowledgment of execution by CONTRACTOR and SURETY must be attached.) (President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under corporate seal empowering that officer to bind the corporation.) APPROVED AS TO FORM: CELIA A. BREWER City Attorney By: ___ ~ ........... -...U .... '..L/.~-~--="'"'""--;;........::;..~----- Deputy City Attorney l' •+;' Revised 7/19/17 PWS18-121TRAN-Contract No.~ PLEASE SEE ATTACHED CALIFORNIA D JURAT ~ACKNO\Vr,EDGEMENT Page 34 of 101 Pages ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of s::'-I.),~ On 2 t ,n~ 2012 before me, P~ Josi, t.1 .. , {~.J h Ito' (insert name and title of the officer) personally appeared t,,,v /It, tJc.-n-, {:--; 0 d&h'l--r-ci ~ Coll,' e. r who proved to me on the basis of satisfactory evidence to be the ~son~ whose name~~ ~bscribed to the within instrument and acknowlejl.ged to me tha(b{A/~/ttrey executed the same in ~/her/the.ir authorized capacity{l'es-), and that b~/ttsr/thsu: signature('&) on the instrument the person(s), or the entity upon behalf of which the personfs).,_acted, executed the instrument. I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. _> (Seal) CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA County of San Diego } On March 26, 2018 before me, Pam Davis , Notary Public, ------------------------------Date Insert Name of Notary exactly as it appears on the official seal personally appeared Dana Michaelis f .......................................................................................... , a PAM DAVIS .-COMM. #2165394 rn E NOTARY Pueuc • CAL1roRHtA a l ......................... ~~&:~1~~!t,1K.~2~J>j Place Notary Seal Above Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Witness my hr1d ~llyi official s~al. Signature V&-nt~ Z[C_;, Signature of Notary Public Pam Davis OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: ------------------------------- Document Date: -------------------Number of Pages: ________ _ Signer(s) Other Than Named Above: __________________________ _ Capacity(ies) Claimed by Signer(s) Signer's Name: _____________ _ D Individual D Corporate Officer -Title(s): ________ _ D Partner D Limited D General ~ Attorney in Fact D Trustee D Guardian or Conservator D Other: _______ _ Signer is Representing: RIGHT THUMBPRINT OF SIGNER Top of thumb here Signer's Name: _____________ _ D Individual D Corporate Officer -Title(s): ________ _ D Partner D Limited D General D Attorney in Fact D Trustee D Guardian or Conservator D Other: _______ _ Signer is Representing: RIGHT THUMBPRINT OF SIGNER Top of thumb here POWER OF ATTORNEY FOR DEVELOPERS SURETY AND INDEMNITY COMPANY INDEMNITY COMPANY OF CALIFORNIA PO Box 19725, IRVINE, CA 92623 (949) 263-3300 KNOW ALL BY THESE PRESENTS that except as expressly limited, DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA, do each hereby make, constitute and appoint ***Anne Wright, Cyndi Beilman, Dana Michaelis, jointly or severally*** as their true and lawful Attomey(s)-ln-Fact. to make, execute, deliver and acknowledge, for and on behalf of said corporations, as sureties, bonds, undertakings and contracls of suretyshlp giving and granting unto said Attomey(s)-ln.fact full power and authority to do and to perform every act necessary, requisite or proper to be done In connection therewith as each of sald corporattons could do, but reserving to each of said corporattons full power of substitution and revocation, and all of the acls of said Attomey(s)-ln-Fact. pursuant to these presents, are hereby rat!fied and confirmed. This Power or Attorney is granted and is signed by facslmlle under and by authority of the following resolutions adopted by the respective Boards of Directors of DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA, effective as of January 1st 2008. RESOLVED, that a combination of any two of the Chairman of the Board, the President. Executive Vice-President Senior Vice-President or any Vice President of the corporations be, and that each of them hereby Is, authorized to execute this Power of Attorney, qualifying the attomey(s) named In the Power of Attorney to execute, on behalf of the corporations, bonds, undertaklngs and contracls of suretyshlp; and that the Secretary or any Assistant Secretary of either of the corporations be, and each of them hereby is, authorized to attest the executfon of any such Power or Attorney; RESOLVED, FURTHER, that the signatures of such officers may be affixed to any such Power of Attorney or to any certf!lcate rela1fng thereto by facslmHe, and any such Power of Attomey or certf!lcate bearing such facsimile signatures shall be vaDd and binding upon the corporations when so affixed and In the future with respect to any bond, undertaking or contract of suretyship to which it is attached. IN WITNESS WHEREOF, DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA have severally caused these presents to be signed by their respective officers and attested by their respeet/ve Secretary or Assistant Secretary this 6th day of February, 2017. By:~~ Daniel Young, Senior Vice-President By:~~ Mark Lansdon, V10e-Presldent A notary public or other officer completing this certificate verifies only the Identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accura , or valid of that document State of Cardomla County of Orange On ______ Fe=b~ru=;ary.._6,..,,..20=-1 .... 7 ____ before me, ___________ L,;.;u:::cl711e:..:..R=,ay~m=o:..::nd~1 N;;,o..,,ta,,_..ry...,,P.:;uo"'bli::.c ___________ _ Oala Hell lnscit NaN! 111d '111111 rl 1!11 Officer personally appeared ________________ .:::,Da::en::.:ie:....:l 'fl.,.,ou::::ng:La::::.n:::,d.:,:,Ma=rk=La"-"nsdo=n~---------------- Narne(•l rl Signer(&) Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) ls/are subscribed to the within Instrument and acknowledged to me that he/she/they executed the same in htsnler/lheir authorized capacity(ies), and that by his/her/their slgnature(s) on the Instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the Instrument I certlfy under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and oonect. WITNESS my hand and official seal. Signature ______ _;,_J_,~~~~-..!:..~'...!..~~~--- Lucll CERTIFICATE The undersigned, as Secretary or Assistant Seaetaiy of DEVELOPERS SURETY AND INDEMNITY COMPANY or INDEMNITY COMPANY OF CALIFORNIA does hereby certify that the foregoing Power of Attorney remains in full force and has not been revoked and, furthermore, that the provisions of th~ 1U10iu'dons of the respective Boards 00! Dlrectois of said OO!pOrations set forth In the Power of Attorney are In force as of the date of this Certificate. This CertH!cate Is executed In the City of lrvlne, Cellfomia, this 26th dayof March . 20!8. ~·~,~ ATS-1002 (02/17) Premium will be aAljusted based on final contract price FAITHFUL PERFORMANCE/WARRANTY BOND Bond No.: 894419P Premium: $2,180.00 · WHEREAS, the City of Carlsbad, State of California, on March 20, 2018 has administratively awarded to COLLIER CONSTRUCTION (hereinafter designated as the "Principal"), a Contract for: BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BIO NO. PWS18-121TRAN in the City of Carlsbad, in strict conformity with the contract, the drawings and specifications, and other Contract Documents now on file in the Office of the City Clerk of the City of Carlsbad, all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond for the faithful performance and warranty of said Contract; NOW, THEREFORE, WE, COLLIER CONSTRUCTION , as Principal, (hereinafter designated as the "Contractor"), and Developers Surety and Indemnity Company , as Surety, are held and firmly bound unto the City of Carlsbad, in the sum of EIGHTY-SEVEN THOUSAND TWO HUNDRED EIGHT DOLLARS AND ZERO CENTS ($87,208.00), said sum being equal to one hundred percent (100%} of the estimated amount of the Contract, to be paid to City or its certain attorney, its successors and assigns; for which payment, well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the above bounden Contractor, their heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions, and agreements in the Contract and any alter- ation thereof made as therein provided on their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City of Carlsbad, its officers, employees and agents, as therein stipulated, then this obligation shall become null and void; otherwise it shall remain In full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, in- curred by the City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed there under or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications. ft \iJ Revised 7 /19/17 PWS18-121TRAN Page 33 of 101 Pages In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. Executed by CONTRACTOR this dayof Ma""eL, CONTRACTOR: Collier Construction (name of Contractor) 2C ,20M By:~~~~¥: (sign here) M11 rt1in & C,//,~,. .:1Z (print name here) O'w11ec (title and organization of signatory) By: ____________ _ (sign here) (print name here) (title and organization of signatory) Executed by SURETY this _2_6_th ___ day of __ M_a_rc_h ________ , 20_!!_. SURETY: Developers Surety and Indemnity Company (name of Surety) 17771 Cowan, Ste. 100, Irvine, CA 92614 (address of Surety) 619-521-9686 1 l (telephone n~mber of ~urety) By: ~-\Q,_ ~rUcJ~,<, 1:) (signature of Attorney-in-Fact) Dana Michaelis, Attorney-in-Fact (printed name of Attorney-in-Fact) (attach corporate resolution showing current power of attorney) (Proper notarial acknowledgment of execution by CONTRACTOR and SURETY must be attached.) (President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under corporate seal empowering that officer to bind the corporation.) APPROVED AS TO FORM: CELIA A. BREWER City Attorney By: 'Uo~ Deputy City Attorney '-' -~ Revised 7/19/17 PWS18-121TRAN PLEASESEEATTACHED CALIFORNIA D JURAT ~ ACKNOWLEDGEMENT Page 32 of 101 Pages ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California Countyof ga,., O,W before me, f u-e.--r Josi, r.,.:-,. C.C~s.h /(() (insert name and title of the officer) I , personally appeared W, f I, 4-rt) e,dvv~d. lZ' Co/1,'~-f , who proved to me on the basis of satisfactory evidence to be the ,.P£trson(~hose name~~ J.Y~~cribed to the within instrument and acknowle~d to me thalb.fl/sf:\e/tl,Qy executed the same in ~her/th'eir authorized capacity(~. and that by(bwh'l?r/tl'reir signature~on the instrument the person~ or the entity upon behalf of which the person(~acted, executed the instrument. I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. 1············~ :@.· _--_ :, · ~E:i~~}~;~;~~ ~~~f~rln\~ z ~ · ·"•; ' , San Diego County S; :z , -: . Commission#21%475 My Comm, Expires Mdy 11, 2021 Signature 7--~ (Seal) CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA County of San Diego } On March 26, 2018 before me, Pam Davis , Notary Public, --------------------Date 1 n s e rt Name of Notary exactly as it appears on the official seal personally appeared ____ D_a_na_M_ic_h_a_e_li_s ____ ~~-c-c------c--ccc--~-------------- Name(s) of Signer(s) Place Notary Seal Above who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Witness my hand .¼~icial se_~~ Signature ~ . JFL~6=?4L£.~?L) Signature of Notary Public Pam Davis OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of the form to another document. Description of Attached Document Title or Type of Document: ------------------------------- Document Date: -------------------Number of Pages: ________ _ Signer(s) Other Than Named Above: ---------------------------- Capacity(ies) Claimed by Signer(s) Signer's Name: _____________ _ D Individual D Corporate Officer -Title(s): ________ _ D Partner D Limited D General ~ Attorney in Fact D Trustee D Guardian or Conservator D Other: _______ _ Signer is Representing: RIGHT THUMBPRINT OF SIGNER Top of thumb here Signer's Name: _____________ _ D Individual D Corporate Officer -Title(s): ________ _ D Partner D Limited D General D Attorney in Fact D Trustee D Guardian or Conservator D Other: -------- Signer is Representing: RIGHT THUMBPRINT OF SIGNER Top of thumb here POWER OF ATTORNEY FOR DEVELOPERS SURETY AND INDEMNITY COMPANY INDEMNITY COMPANY OF CALIFORNIA PO Box 19725, IRVINE, CA 92623 (949) 263-3300 KNOW ALL BY THESE PRESENTS that except as expressly limited, DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA, do each hereby make, constitute and appoint ***Anne Wright, Cyndi Beilman, Dana Mlchaeils, jointly or severally*** as their true and lawful Attomey(s)-in-Fact, to make, execute, deliver and acknowledge, for and on behalf of said corporations, as sureties, bonds, undertaklngs and contracts of suretyshlp givlng and granting unto said Attomey(s)-ln-Fact full power and authority to do and to perform every act necessary, requisite or proper to be done In connection therewith as each of said corporations could do, but reseNlng to each of said corporations full power of substitution and revocation, and all of the acts of said Attomey(s)-ln-Fact, pursuant to these presents, are hereby ratified and confinned. Tills Power of Attorney Is granted and Is signed by facsimile under and by authority of the falowing resolutions adopted by the respective Boards of Directors of DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA, effective as of January 1st, 2008. RESOLVED, that a combination of any two of the Chairman of the Board, the President, Executive Vioe-Presldent. Senior Vioe-President or any Vice President of the corporatlons be, and that each of them hereby Is, authorized to execute this Power of Attorney, qualifying the attomey(s) named In the Power of Attorney to execute, on behalf of the corporations, bonds, undertakings and contracts of suretyshlp; and that the Secretary or any Assistant Secretary of either of the corporations be, and each of them hereby Is, authorized to attest the execution of any such Power of Attorney; RESOLVED, FURTHER, that the signatures of such officers may be affixed to any such Power of Attorney or to any certlftcate rela1!ng thereto by facsimile, and any such Power of Attomey or certificate bearing such facsimile signatures shall be vaDd and binding upon the corporations when so affixed and In the future with 199pect to any bond, undertaking or contract of suretyshlp to which It is attached. IN WITNESS WHEREOF, DEVELOPERS SURETY AND INDEMNITY COMPANY and INDEMNITY COMPANY OF CALIFORNIA have severally caused these presents to be signed by their respective officers and attested by their respective Secretary or Assistant Secretary this 6th day of February, 2017. By:~~ Daniel Young, Senior Vice-President A notary public or other officer completing this certificate verifies only the Identity of the Individual who signed the document to which this certificate Is attached, and not the truthfulness, accura , or valid of that document State of Carrtomla County of Orange On ___ -'-'Fa.,.b_rua""ry.,_6..,.""20._.1~7 ____ before me, -------------'L,,,,u,,.,cll,,,.le""R,,.ay.,.,mo=nd~, N,;.:o~ta"-lryw.P..-u,.,,b!i,,._c ___________ _ Oall Herl IIU1 Hane andlllla d h 0ftlcer personally appeared ________________ .;;Da""n""ie:...;l~~ou:;;-:ng..._a~n::,d,:;Ma::::11t.:;,.;:La""nsdo=n'------------------ Nllllll(,J d Signer(&) Place Notary Seal Above who proved lo me on the basis of satisfactory evidence to be the person(s) whose name(s) ls/are subscribed to the within Instrument and acknowledged to me that he/she/they executed the same In hlsnler/lhelr authorized capacity(ies), and that by his/her/their slgnature(s) on the Instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the Instrument I certify under PENALTY OF PERJURY under the laws of the State of California the! the foregoing paragraph is true and correct WITNESS my hand and official seal. Signature ---------t-,~:..:....:. ___ ___::.....:~....:..-~~--- CERTIFICATE Tile und81Slgned, as Secretary or Assistant Secretary of DEVELOPERS SURETY AND INDEMNITY COMPANY or INDEMNITY COMPANY OF CALIFORNIA does herel7t certify that the foregoing Power of Attorney remains In full force and has not been revoked and, furthermore, that the provisions of the reso!utlom ol L".e respective Boards 'o1 Dlreclors of said corporations set forth In the Power of Attomey are In fon:e as of the date of this Certificate. Tllls Certfflcate Is executed In the City of Irvine, Cafflomla, this 26th dayof March . 2018. Br.~~ ATS-1002 (02/17) OPTIONAL ESCROW AGREEMENT FOR SECURITY DEPOSITS IN LIEU OF RETENTION This Escrow Agreement is made and entered into by and between the City of Carlsbad whose address is 1200 Carlsbad Village Drive, Carlsbad, California, 92008, hereinafter called "City" and whose address is -----------------------------______________________________ hereinafter called "Contractor" and _______________________ whose address is --------------------------------hereinafter called "Escrow Agent." For the consideration hereinafter set forth, the City, Contractor and Escrow Agent agree as follows: 1. Pursuant to section 22300 of the Public Contract Code of the State of California, the Contractor has the option to deposit securities with the Escrow Agent as a substitute for retention earnings required to be withheld by the City pursuant to the Construction Contract entered into between the City and Contractor for BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN in the amount of ____________ dated ______ (hereinafter referred to as the "Contract"). Alternatively, on written request of the Contractor, the City shall make payments of the retention earnings directly to the Escrow Agent. When the Contractor deposits the securities as a substitute for Contract earnings, the Escrow Agent shall notify the City within 1 0 days of the deposit. The market value of the securities at the time of the substitution shall be a least equal to the cash amount then required to be withheld as retention under the terms of the contract between the City and Contractor. Securities shall be held in the name of the City and shall designate the Contractor as the beneficial owner. 2. The City shall make progress payments to the Contractor for such funds which otherwise would be withheld from progress payments pursuant to the Contract provisions, provided that the Escrow Agent holds securities in the form and amount specified above. 3. When the City makes payment of retentions earned directly to the Escrow Agent, the Escrow Agent shall hold them for the benefit of the Contractor until such time as the escrow created under this contract is terminated. The Contractor may direct the investment of the payments into securities. All terms and conditions of this agreement and the rights and responsibilities of the parties shall be equally applicable and binding when the City pays the Escrow Agent directly. 4. The Contractor shall be responsible for paying all fees for the expenses incurred by the Escrow Agent in administering the Escrow Account and all expenses of the City. These expenses and payment terms shall be determined by the City, Contractor and Escrow Agent. 5. The interest earned on the securities or the money market accounts held in escrow and all interest earned on that interest shall be for the sole account of Contractor and shall be subject to withdrawal by Contractor at any time and from time to time without notice to the City. l' • .-, Revised 7 /19/17 PWS 18-121 TRAN-Contract No. 3896 Page 35 of 101 Pages 6. Contractor shall have the right to withdraw all or any part of the principal in the Escrow Account only by written notice to Escrow Agent accompanied by written authorization from City to the Escrow Agent that City consents to the withdrawal of the amount sought to be withdrawn by Contractor. 7. The City shall have a right to draw upon the securities in the event of default by the Contractor. Upon seven days' written notice to the Escrow Agent from the City of the default, the Escrow Agent shall immediately convert the securities to cash and shall distribute the cash as instructed by the City. 8. Upon receipt of written notification from the City certifying that the Contract is final and complete and that the Contractor has complied with all requirements and procedures applicable to the Contract, the Escrow Agent shall release to Contractor all securities and interest on deposit less escrow fees and charges of the Escrow Account. The escrow shall be closed immediately upon disbursement of all moneys and securities on deposit and payments of fees and charges. 9. The Escrow Agent shall rely on the written notifications from the City and the Contractor pursuant to sections (1) to (8), inclusive, of this agreement and the City and Contractor shall hold Escrow Agent harmless from Escrow Agent's release, conversion and disbursement of the securities and interest as set forth above. 10. The names of the persons who are authorized to give written notices or to receive written notice on behalf of the City and on behalf of Contractor in connection with the foregoing, and exemplars of their respective signatures are as follows: For City: Title _____ --'-Fl:.:...N;:.:...A.:.:..N.:..::C=-=E::....;D::;..l:.:...R=E=-=C'"""T--=O;..:..R..;....._ __ _ Name _________________ _ Signature ________________ _ Address 1635 Faraday Avenue, Carlsbad, CA 92008 For Contractor: Title _________________ _ Name _________________ _ Signature ________________ _ Address ________________ _ For Escrow Agent: Title _________________ _ Name _________________ _ Signature ________________ _ Address ________________ _ At the time the Escrow Account is opened, the City and Contractor shall deliver to the Escrow Agent a fully executed counterpart of this Agreement. l'l •+' Revised 7 /19/17 PWS 18-121 TRAN-Contract No. 3896 Page 36 of 101 Pages IN WITNESS WHEREOF, the parties have executed this Agreement by their proper officers on the date first set forth above. For City: Title. ________ ..:..:M~A..:..Y~O:::.:R~------ Name _________________ _ Signature ________________ _ Address 1200 Carlsbad Village Drive. Carlsbad. CA 92008 For Contractor: Title. __________________ _ Name _________________ _ Signature ________________ _ Address ________________ _ For Escrow Agent: Title. __________________ _ Name _________________ _ Signature ________________ _ Address ________________ _ l' •+;' Revised 7 /19/17 PWS 18-121 TRAN-Contract No. 3896 Page 37 of 101 Pages GENERAL PROVISIONS FOR BEACH ACCESS STAIRWAY REPAIR AT SYCAMORE AVE CONTRACT NO. 3896 BID NO. PWS18-121TRAN CITY OF CARLSBAD BIDDERS ARE ADVISED THAT THIS SECTION REPLACES PART 1 GENERAL PROVISIONS, OF THE STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION SECTION 1 -TERMS, DEFINITIONS, ABBREVIATIONS, AND SYMBOLS 1-1 TERMS -Unless otherwise stated, the words directed, required, permitted, ordered, instructed, designated, considered necessary, prescribed, approved, acceptable, satisfactory, or words of like meaning, refer to actions, expressions, and prerogatives of the Engineer. 1-1.1 Reference to Drawings. Where words "shown", "indicated", "detailed", "noted", "scheduled", or words of similar import are used, it shall be understood that reference is made to the plans accompanying these provisions, unless stated otherwise. 1-1.2 Directions. Where words "directed", "designated", "selected", or words of similar import are used, it shall be understood that the direction, designation or selection of the Engineer is intended, unless stated otherwise. The word "required" and words of similar import shall be understood to mean "as required to properly complete the work as required and as approved by the Engineer," unless stated otherwise. 1-1.3 Equals and Approvals. Where the words "equal", "approved equal", "equivalent", and such words of similar import are used, it shall be understood such words are followed by the expression "in the opinion of the Engineer", unless otherwise stated. Where the words "approved", "approval", "acceptance", or words of similar import are used, it shall be understood that the approval, acceptance, or similar import of the Engineer is intended. 1-1.4 Perform. The word "perform" shall be understood to mean that the Contractor, at its expense, shall perform all operations, labor, tools and equipment, and further, including the furnishing and installing of materials that are indicated, specified or required to mean that the Contractor, at its expense, shall furnish and install the work, complete in place and ready to use, including furnishing of necessary labor, materials, tools, equipment, and transportation. 1-2 Definitions. The following words, or groups of words, shall be exclusively defined by the definitions assigned to them herein. l' •,;' Revised 11/24/10 PWS 18-121 TRAN-Contract No. 3896 Page 38 of 101 Addendum -Written or graphic instrument issued prior to the opening of Bids which clarifies, corrects, or changes the bidding or Contract Documents. The term Addendum shall include bulletins and all other types of written notices issued to potential bidders prior to opening of Bids. Agency -The City of Carlsbad, California. Agreement -See Contract. Assessment Act Contract - A Contract financed by special assessments authorized under a State Act or procedural ordinance of a City or County. Base -A layer of specified material of planned thickness placed immediately below the pavement or surfacing. Bid -The offer or proposal of the Bidder submitted on the prescribed form setting forth the prices for the Work. Bidder -Any individual, firm, partnership, corporation, or combination thereof, submitting a Bid for the Work, acting directly or through a duly authorized representative. Board -The officer or body constituting the awarding authority of the Agency, which is the City Council for the City of Carlsbad or the Board of Directors of Carlsbad Municipal Water District. Bond -Bid, performance, and payment bond or other instrument of security. City Council -the City Council of the City of Carlsbad. City Manager -the City Manager of the City of Carlsbad or his/her approved representative. Cash Contract - A Contract financed by means other than special assessments. Change Order - A written order to the Contractor signed by the Agency directing an addition, deletion, or revision in the Work, or an adjustment in the Contract Price or the Contract time issued after the effective date of the Contract. A Change Order may or may not also be signed by the Contractor. Code -The terms Government Code, Labor Code, etc., refer to codes of the State of California. Construction Manager-the Project Inspector's immediate supervisor and first level of appeal for informal dispute resolution. Contract -The written agreement between the Agency and the Contractor covering the Work. Contract Documents -Including but not limited to; the Contract, any Addendum (which pertain to the contract documents), Notice Inviting Bids, Instructions to Bidders; Bid (including documentation accompanying the Bid and any post-bid documentation submitted prior to the Notice of Award) when attached as an exhibit to the Contract, the Bonds, the General Provisions, permits from other agencies, the Technical Specifications, the Supplemental Provisions, the Plans, Standard Plans, Standard Specifications, Reference Specifications, and all Modifications issued after the execution of the Contract. l'\ •+;' Revised 11/24/10 PWS18-121TRAN-Contract No. 3896 Page 39 of 101 Contractor -The individual, partnership, corporation, joint venture, or other legal entity having a Contract with the Agency to perform the Work. In the case of work being done under permit issued by the Agency, the permittee shall be constructed to be the Contractor. The term "prime contractor" shall mean Contractor. Contract Price -The total amount of money for which the Contract is awarded. Contract Unit Price -The amount stated in the Bid for a single unit of an item of work. County Sealer -The Sealer of Weights and Measures of the county in which the Contract is let. Days -Days shall mean consecutive calendar's days unless otherwise specified. Deputy City Engineer, Construction Management & Inspection -The Construction Manager's immediate supervisor and second level of appeal for informal dispute resolution. Dispute Board -Persons designated by the City Manager of the City of Carlsbad or Executive Manager of the Carlsbad Municipal Water District, to hear and advise the City Manager on claims submitted by the Contractor. The City Manager for the City of Carlsbad or the Executive Manager for the Carlsbad Municipal Water District is the last appeal level for informal dispute resolution. Electrolier -Street light assembly complete, including foundation, standard, luminaire arm, luminaire, etc. Engineer -The City Engineer of the City of Carlsbad or his/her approved representative. The Engineer is the third level of appeal for informal dispute resolution. Geotextile -Synthetic fiber used in civil engineering applications, serving the primary functions of separation and filtration. House Connection Sewer -A sewer, within a public street or right-of-way, proposed to connect any parcel, lot, or part of a lot with a mainline sewer. House Sewer -A sewer, wholly within private property, proposed to connect any building to a house connection sewer. Luminaire -The lamp housing including the optical and socket assemblies (and ballast if so specified). Luminaire Arm -The structural member, bracket, or mast arm, which, mounted on the standard, supports the luminaire. Minor Bid Item -A single contract item constituting less than 10 percent (10%) of the original Contract Price bid. Modification-Includes Change Orders and Supplemental Agreements. A Modification may only be used after the effective date of the Contract. Notice of Award -The written notice by the Agency to the successful Bidder stating that upon compliance by it with the required conditions, the Agency will execute the Contract. Notice to Proceed -A written notice given by the Agency to the Contractor fixing the date on which the Contract time will start. l' •+;' Revised 11/24/10 PWS 18-121 TRAN-Contract No. 3896 Page 40 of 101 Own Organization -When used in Section 2-3.1 -Employees of the Contractor who are hired, directed, supervised and paid by the Contractor to accomplish the completion of the Work. Further, such employees have their employment taxes, State disability insurance payments, State and Federal income taxes paid and administered, as applicable, by the Contractor. When used in Section 2-3.1 "own organization" means construction equipment that the Contractor owns or leases and uses to accomplish the Work. Equipment that is owner operated or leased equipment with an operator is not part of the Contractor's Own Organization and will not be included for the purpose of compliance with Section 2-3.1. Person -Any individual, firm, association, partnership, corporation, trust, joint venture, or other legal entity. Plans -The drawings, profiles, cross sections, working drawings, and supplemental drawings, or reproductions thereof, approved by the Engineer, which show the location, character, dimensions, or details of the Work. Private Contract -Work subject to Agency inspection, control, and approval, involving private funds, not administered by the Agency. Project Inspector -The Engineer's designated representative for inspection, contract administration and first level for informal dispute resolution. Proposal-See Bid. Reference Specifications -Those bulletins, standards, rules, methods of analysis or test, codes, and specifications of other agencies, engineering societies, or industrial associations referred to in the Contract Documents. These refer to the latest edition, including amendments in effect and published at the time of advertising the project or issuing the permit, unless specifically referred to by edition, volume, or date. Roadway-The portion of a street reserved for vehicular use. Service Connection -Service connections are all or any portion of the conduit, cable, or duct, including meter, between a utility distribution line and an individual consumer. Sewer -Any conduit intended for the reception and transfer of sewage and fluid industrial waste. Specifications -General Provisions, Standard Specifications, Technical Specifications, Reference Specifications, Supplemental Provisions, and specifications in Supplemental Agreements between the Contractor and the Board. Standard -The shaft or pole used to support street lighting luminaire, traffic signal heads, mast arms, etc. Standard Plans -Details of standard structures, devices, or instructions referred to on the Plans or in Specifications by title or number. Standard Specifications -The Standard Specifications for Public Works Construction (SSPWC), the "Greenbook". State -State of California. ,, •+; Revised 11/24/10 PWS18-121TRAN-Contract No. 3896 Page41 of101 Storm Drain -Any conduit and appurtenances intended for the reception and transfer of storm water. Street -Any road, highway, parkway, freeway, alley, walk, or way. Subbase -A layer of specified material of planned thickness between a base and the subgrade. Subcontractor -An individual, firm, or corporation having a direct contract with the Contractor or with any other Subcontractor for the performance of a part of the Work. Subgrade -For roadways, that portion of the roadbed on which pavement, surfacing, base, subbase, or a layer of other material is placed. For structures, the soil prepared to support a structure. Supervision -Supervision, where used to indicate supervision by the Engineer, shall mean the performance of obligations, and the exercise of rights, specifically imposed upon and granted to the Agency in becoming a party to the Contract. Except as specifically stated herein, supervision by the Agency shall not mean active and direct superintendence of details of the Work. Supplemental Agreement -A written amendment of the Contract Documents signed by both parties. Supplemental Provisions -Additions and revisions to the Standard Specifications setting forth conditions and requirements peculiar to the work. Surety-Any individual, firm, or corporation, bound with and for the Contractor for the acceptable performance, execution, and completion of the Work, and for the satisfaction of all obligations incurred. Tonne -Also referred to as "metric ton". Represents a unit of measure in the International System of Units equal to 1,000 kilograms. Utility -Tracks, overhead or underground wires, pipeline, conduits, ducts, or structures, sewers, or storm drains owned, operated, or maintained in or across a public right of way or private easement. Work -That which is proposed to be constructed or done under the Contract or permit, including the furnishing of all labor, materials, equipment, and services. 1-3ABBREVIATIONS 1-3.1 General. The abbreviation herein, together with others in general use, are applicable to these Standard Specifications and to project Plans or other Contract Documents. All abbreviations and symbols used on Plans for structural steel construction shall conform to those given by the "Manual of Steel Construction" published by the American Institute of Steel Construction, Inc. l' •ii Revised 11/24/10 PWS 18-12 HRAN-Contract No. 3896 Page 42 of 101 1-3.2 Common Usage Abbreviation Word or Words Abbreviation Word or Words ABAN ........................................................... Abandon D .............................................................. Load of pipe ASANO ....................................................... Abandoned dB ................................................................... Decibels ABS ........................ Acrylonitrile -butadiene -styrene DBL .................................................................. Double AC .................................................... Asphalt Concrete OF ............................................................... Douglas fir ACP ........................................... Asbestos cement pipe DIA ................................................................ Diameter ACWS ..................... Asphalt concrete wearing surface DIP ..................................................... Ductile iron pipe ALT ................................................................ Alternate DL ................................................................ Dead load APTS ................................. Apartment and Apartments DR ...................................................... Dimension Ratio AMER STD ................................... American Standard OT ................................................................. Drain Tile AWG ............... American Wire Gage (nonferrous wire) DWG ............................................................... Drawing BC .................................................. Beginning of curve DWY .............................................................. Driveway BCR ....................................... Beginning of curb return DWY APPR ................................... Driveway approach BORY ............................................................ Boundary E ....................................................................... Electric BF ..................................................... Bottom of footing EA ........................................................................ Each BLDG ........................................ Building and Buildings IT ............................................................ E~~~~ BM ............................................................. Bench mark ECR ................................................ End of curb return BVC .................................... Beginning of vertical curve EF ................................................................ Each face BM/ ........................................................... Back of wall EG ......................................................... Edge of gutter CIC ..................................................... Center to center EGL .................................................. Energy grade line CAB ...................................... Crushed aggregate base El ................................................................... Elevation CAUOSHA ............ California Occupational Safety and ELG ..................................... Electrolier lighting conduit ................................................... Health Administration EL T ........................................................ Extra long ton CalTrans ....... California Department of Transportation ENGR ....................................... Engineer, Engineering CAP .................................... Corrugated aluminum pipe EP ................................................... Edge of pavement CB ............................................................. Catch Basin ESMT ........................................................... Easement Cb ................................................... , .................... Curb ETB .......................................... Emulsion-treated base CBP ............................... Catch Basin Connection Pipe EVC ............................................... End of vertical curb CBR ....................................... California Bearing Ratio EWA ............................... Encina Wastewater Authority CCR ............................ California Code of Regulations EXC ............................................................ Excavation CCTV ............................................... Closed Circuit TV EXP JT ................................................. Expansion joint CES .......................... Carlsbad Engineering Standards EXST ............................................................... Existing CF ................................................................ Curb face F .................................................................. Fahrenheit CF ................................................................ Cubic foot F&C ................................................... Frame and cover C&G .................................................... Curb and gutter F&I .................................................. Furnish and install CFR ................................ Code of Federal Regulations FAB ............................................................... Fabricate CFS ......................................... Cubic Feet per Second FAS ............................................... Flashing arrow sign GIP ......................................................... Cast iron pipe FD ............................................................... Floor drain GIPP ................................................ Cast-in place pipe FON ............................................................ Foundation CL ............................................. Clearance, center line FED SPEC ................................. Federal Specification CLF .................................................... Chain link fence FG ........................................................ Finished grade CMB ............................... Crushed miscellaneous base FH ............................................................. Fire hydrant CMC ......................................... Cement mortar-coated FL. .................................................................. Flow line CML ............................................ Cement mortar-lined FS ...................................................... Finished surface CMWD .................... Carlsbad Municipal Water District FT-LB ......................................................... Foot-pound CO .................................................... Cleanout (Sewer) FTG .................................................................. Footing COL. ................................................................. Column FW ............................................................ Face of wall COMM ....................................................... Commercial G ........................................................................... GM CONG ........................................................... Concrete GA ..................................................................... Gauge CONN ........................................................ Connection GAL. .............................................. Gallon and Gallons CONST .................................. Construct, Construction GAL V ......................................................... Galvanized COORD ...................................................... Coordinate GAR ........................................... Garage and Garages CSP ............................................ Corrugated steel pipe GIP .............................................. Galvanized iron pipe CSD ............................... Carlsbad Standard Drawings GL ........................................ Ground line or grade line CTB ............................................ Cement treated base GM .............................................................. Gas meter CV ............................................................ Check valve GNV ............................................... Ground Not Visible CY ............................................................... Cubic yard GP .................................................................. Guy pole {'\ • ., Revised 11/24/10 PWS 18-121 TRAN-Contract No. 3896 Page 43 of 101 GPM ................................................ gallons per minute ORIG ................................................................ Original GR ...................................................................... Grade PB ................................................................... Pull box GRTG ............................................................. Grating PC .................................................... Point of curvature GSP ........................................... Galvanized steel pipe PCC ....................... Portland cement concrete or point H ............................................................ High or height ................................................ of compound curvature HB .................................................................. Hose bib PCVC ....................... Point of compound vertical curve HC .................................................. House connection PE ........................................................... Polyethylene HDWL ........................................................... Headwall Pl. ................................................. Point of intersection HGL. ............................................. Hydraulic grade line PL. ............................................................ Property line HORIZ .......................................................... Horizontal PMB ............................ Processed miscellaneous base HP ........................................................... Horsepower POC ...................................................... Point on curve HPG ................................................ High pressure gas POT...................... . ...................... Point on tangent HPS ................................ High pressure sodium (Light) PP .............................................................. Power pole HYDR ............................................................ Hydraulic PRC .......................................... Point of reverse curve IE ......................................................... Invert Elevation PRVC ............................ Point of reverse vertical curve ID ........................................................ Inside diameter PSI ......................................... Pounds per square inch INCL. .............................................................. Including PT .................................................... Point of tangency INSP ............................................................. lnspection PVC .................................................. Polyvinyl chloride INV ...................................................................... lnvert PVMT ........................................................... Pavement IP ................................................................... Iron pipe PVT R/W ....................................... Private right-of-way JC ..................................................... Junction chamber Q ........................ Rate of flow in cubic feet per second JCT ................................................................. Junction QUAD ....................................... Quadrangle, Quadrant JS ..................................................... Junction structure R ....................................................................... Radius JT ......................................................................... Joint R&O ......................................................... Rock and oil L ........................................................................ Length R/W .......................................................... Right-of-way LAB ............................................................. Laboratory RA ...................................................... Recycling agent LAT ................................................................... Lateral RAC ................................... Recycled asphalt concrete LB ...................................................................... Pound RAP ................................ Reclaimed asphalt pavement LD ..................................................... Local depression RBAC ............................. Rubberized asphalt concrete LF ................................................................ Linear foot RC ................................................ Reinforced concrete LH ............................................................... Lamp hole RCB ...................................... Reinforced concrete box LL ................................................................... Live load RCE ...................................... Registered civil engineer LOL ............................................................. Layout line RCP ..................................... Reinforced concrete pipe LONG ........................................................ Longitudinal RCV ........................................... Remote control valve LP ................................................................ Lamp post REF ............................................................. Reference LPS ................................. Low pressure sodium (Light) REINF .............................. Reinforced or reinforcement LS ................................................................ Lump sum RES ............................................................... Reservoir L TS .................................................... Lime treated soil RGE ........................ Registered geotechnical engineer LWD ............................... Leucadia Wastewater District ROW ....................................................... Right-of-Way MAINT ..................................................... Maintenance RR ................................................................... Railroad MAX ............................................................ Maximum RSE .............................. Registered structural engineer MCR ............................................ Middle of curb return RTE .................................... Registered traffic engineer MEAS ............................................................. Measure S .................................... Sewer or Slope, as applicable MH ................................... Manhole, maintenance hole SCCP ............................... Steel cylinder concrete pipe MIL SPEC .................................... Military specification SD ............................................................. Storm drain MISC ..................................................... Miscellaneous SDNR .............................. San Diego Northern Railway MOD ................................................... Modified, modify SDR ....... Standard thermoplastic pipe dimension ratio MON ............................................................ Monument ............. (ratio of pipe O.D. to minimum wall thickness) MSL.. Mean Sea Level (Reg. Standard Drawing M-12) SDRSD ......... San Diego Regional Standard Drawings MTBM ......................... Microtunneling Boring Machine SE ...................................................... Sand Equivalent MULT ............................................................... Muffip~ SEC .................................................................. Section MUTCD ..... Manual on Uniform Traffic Control Devices SF ............................................................. Square foot MVL. .............................................. Mercury vapor light SFM ................................................ Sewer Force Main NCTD .............................. North County Transit District SI. ...................... International System of Units (Metric) NRCP .............................. Nonreinforced concrete pipe SPEC ..................................................... Specifications OBS ............................................................... Obsolete SPPWC .......................................... Standard Plans for OC ................................................................ On center Public Works Construction OD ..................................................... Outside diameter SSPWC ............................. Standard Specifications for OE .............................................................. Outer edge ........................................... Public Works Construction OHE ................................................ Overhead Electric ST HWY ................................................ State highway OMWD ................. Olivenhain Municipal Water District STA............................. . ............................... Station OPP ............................................................... Opposite STD ............................................................... Standard ,, •+; Revised 11/24/10 PWS18-121TRAN-Contract No. 3896 Page 44 of 101 STR...................... ............... . ............ Straight STR GR ................................................ Straight grade STRUC ....................................... Structural/Structure SW ................................................................. Sidewalk SWD ...................................................... Sidewalk drain SY ............................................................ Square yard T.... . ....................................... Telephone TAN ........................................ . ............... Tangent TC .............................................................. Top of curb TEL ............................................................. Telephone TF ........................................................... Top of footing TOPO ........................................................ Topography IB ................................................................... fuct TRANS ......................................................... Transition TS ......................... Traffic signal or transition structure TSC ............................................. Traffic signal conduit TSS ........................................... Traffic signal standard TW .............................................................. Top of wall 1-3.3 Institutions. Abbreviation TYP ............................................................. Typical UE ............................................. Underground Electric USA. .................................. Underground Service Alert VAR ..................................................... Varies, Variable VB ................................................................ Valve box VC ....................................................... Vertical curve VCP ................................................... Vitrified clay pipe VERT ............................................................... Vertical VOL .................................................................. Volume VWD ....................................... Vallecitos Water District W. ....................... Water, Wider or Width, as applicable WATCH .............. Work Area Traffic Control Handbook WI. ........................................................... Wrought iron WM ........................................................... Water meter WPJ .......................................... Weakened plane joint XCONN ............................................ Cross connection XSEC ..................................................... Cross section Word or Words MSHTO ............... American Association of State Highway and Transportation Officials AISC ................................................................. American Institute of Steel Construction ANSI ................................................................... American National Standards Institute API ................................................................................... American Petroleum Institute AREA ......................................................... American Railway Engineering Association ASTM ......................................................... American Society for Testing and Materials AWPA. ............................................................. American Wood Preservers Association AWS ..................................................................................... American Welding Society AWWA. ................................................................... American Water Works Association FHWA ........................................................................... Federal Highway Administration GRI .............................................................................. Geosynthetic Research Institute NEMA ...................................................... National Electrical Manufacturers Association NOAA ............. National Oceanic and Atmospheric Administration (Dept. of Commerce) UL .................................................................................. Underwriters' Laboratories Inc. USGS .......................................................................... United States Geological Survey 1-4UNITS OF MEASURE. 1-4.1 General. U.S. Standard Measures, also called U.S. Customary System, are the principal measurement system in these specifications. However, certain material specifications and test requirements contained herein use SI units specifically and conversions to U.S. Standard Measures may or may not have been included in these circumstances. When U.S. Standard Measures are not included in parenthesis, then the SI units shall control. S.I. units and U.S. Standard Measures in parenthesis may or may not be exactly equivalent. Reference is also made to ASTM E 380 for definitions of various units of the SI system and a more extensive set of conversion factors. ,, •+;' Revised 11/24/10 PWS18-121TRAN-Contract No. 3896 Page 45 of 101 1-4.2 Units of Measure and Their Abbreviations. U.S. Customary Unit (Equal To) 51 Unit (Abbreviations) (Abbreviations) 1 mil (=0.001 in) ................................................................................. 25.4 micrometer (µm) 1 inch (in) ........................................................................................... 25.4 millimeter (mm) 1 inch (in) ........................................................................................... 2.54 centimeter (cm) 1 foot (ft) ............................................................................................. 0.3048 meter (m) 1 yard (yd) .......................................................................................... 0.9144 meter (m) 1 mile (mi) .......................................................................................... 1.6093 kilometer (km) 1 square foot (ft2) ............................................................................... 0.0929 square meter (m2) 1 square yard (yd2) ............................................................................ 0.8361 square meter (m2) 1 cubic foot (ft3) .................................................................................. 0.0283 cubic meter (m3) 1 cubic yard (yd3) ............................................................................... 0.7646 cubic meter (m3) 1 acre ................................................................................................. 0.4047 hectare (ha) 1 U.S. gallon (gal) .............................................................................. 3.7854 Liter (L) 1 fluid ounce (fl. oz.) ........................................................................... 29.5735 millileter (ml) 1 pound mass (lb) (avoirdupois) ........................................................ 0.4536 kilogram (kg) 1 ounce mass (oz) ............................................................................. 0.02835 kilogram (kg) 1 Ton (=2000 lb avoirdupois) ............................................................. 0.9072 Tonne(= 907 kg) 1 Poise ............................................................................................... 0.1 pascal · second (Pa · s) 1 centistoke (cs) ................................................................................. 1 square millimeters per second (mm2/s) 1 pound force (lbf) ............................................................................. .4.4482 Newton (N) 1 pounds per square inch (psi) .......................................................... 6.8948 Kilopascal (kPa) 1 pound force per foot (lbf/ft) ............................................................. 1.4594 Newton per meter (N/m) 1 foot-pound force (ft-lbf) ................................................................... 1.3558 Joules (J) 1 foot-pound force per second ([ft-lbf]/s) ........................................... 1.3558 Watt (W) 1 part per million (ppm) ...................................................................... 1 milligram/liter (mg/L) Temperature Units and Abbreviations Degree Fahrenheit (°F): .................................................................... .Degree Celsius (°C): °F = (1.8 x °C) + 32 ............................................................................ °C = (°F-32)/1.8 51 Units (abbreviation) Commonly Used in Both Systems 1 Ampere (A) 1 Volt (V) 1 Candela (cd) 1 Lumen (Im) 1 second (s) Common Metric Prefixes kilo (k) ................................................................................................ 103 centi (c) .............................................................................................. 10-2 milli (m) .............................................................................................. 10-3 micro (µ) ............................................................................................. 10-6 nano (n) .............................................................................................. 10-9 pico (p) ............................................................................................... 10-12 l' •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 46 of 101 Pages 1-5 SYMBOLS ~ L % I 0 PL CL SL Delta, the central angle or angle between tangents Angle Percent Feet or minutes Inches or seconds Number per or (between words) Degree Property line Centerline Survey line or station line SECTION 2 -SCOPE AND CONTROL OF WORK 2-1 AWARD AND EXECUTION OF CONTRACT. Award and execution of Contract will be as provided for in the Specifications, Instruction to Bidders, or Notice Inviting Bids. 2-2 ASSIGNMENT. No Contract or portion thereof may be assigned without consent of the Board, except that the Contractor may assign money due or which will accrue to it under the Contract. If given written notice, such assignment will be recognized by the Board to the extent permitted by law. Any assignment of money shall be subject to all proper withholdings in favor of the Agency and to all deductions provided for in the Contract. All money withheld, whether assigned or not, shall be subject to being used by the Agency for completion of the Work, should the Contractor be in default. 2-3SUBCONTRACTS. 2-3.1 General. Each Bidder shall comply with the Chapter of the Public Contract Code including Sections 4100 through 4113. The following excerpts or summaries of some of the requirements of this Chapter are included below for information: The Bidder shall set forth in the Bid, as provided in 4104: "(a) The name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the work or improvements, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specially fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of 1 percent of the prime contractor's total bid, or, in the case of bids or offers for the construction of streets or highways, including bridges, in excess of one-half of 1 percent of the prime contractor's total bid or ten thousand dollars ($10,000), whichever is greater." "(b) The portion of the work which will be done by each such subcontractor under this act. The prime contractor shall list only one subcontractor for each such portion as is defined by the prime contractor in his bid." {'. •,;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 47 of 101 Pages If the Contractor fails to specify a Subcontractor, or specifies more than one Subcontractor for the same portion of the work to be performed under the Contract (in excess of one-half of 1 percent of the Contractor's total Bid), the Contractor shall be qualified to perform that portion itself, and shall perform that portion itself, except as otherwise provided in the Code. As provided in Section 4107, no Contractor whose Bid is accepted shall substitute any person as Subcontractor in place of the Subcontractor listed in the original Bid, except for causes and by procedures established in Section 4107 .5. This section provides procedures to correct a clerical error in the listing of a Subcontractor. Section 411 0 provides that a Contractor violating any of the provisions of the Chapter violates the Contract and the Board may exercise the option either to cancel the Contract or assess the Contractor a penalty in an amount of not more than 10 percent of the subcontract involved, after a public hearing. Should the Contractor fail to adhere to the provisions requiring the Contractor to complete 50 percent of the contract price with its own organization, the Agency may at its sole discretion elect to cancel the contract or deduct an amount equal to 1 0 percent of the value of the work performed in excess of 50 percent of the contract price by other than the Contractor's own organization. The Board shall be the sole body for determination of a violation of these provisions. In any proceedings under this section, the prime contractor shall be entitled to a public hearing before the Board and shall be notified ten (10) days in advance of the time and location of said hearing. The determination of the City Council shall be final. 2-3.2 Additional Responsibility. The Contractor shall give personal attention to the fulfillment of the Contract and shall keep the Work under its control. The Contractor shall perform, with its own organization, Contract work amounting to at least 50 percent of the Contract Price except that any designated "Specialty Items" may be performed by subcontract, and the amount of any such "Specialty Items" so performed may be deducted from the Contract Price before computing the amount required to be performed by the Contractor with its own organization. "Specialty Items" will be identified by the Agency in the Bid or Proposal. Where an entire item is subcontracted, the value of work subcontracted will be based on the Contract Unit Price. When a portion of an item is subcontracted, the value of work subcontracted will be based on the estimated percentage of the Contract Unit Price. This will be determined from information submitted by the Contractor, and subject to approval by the Engineer. Before the work of any Subcontractor is started, the Contractor shall submit to the Engineer for approval a written statement showing the work to be subcontracted giving the name and business of each Subcontractor and description and value of each portion of the work to be so subcontracted. 2-3.3 Status of Subcontractors. Subcontractors shall be considered employees of the Contractor, and the Contractor shall be responsible for their work. 2-4 CONTRACT BONDS. Before execution of the Contract, the Bidder shall file surety bonds with the Agency to be approved by the Board in the amounts and for the purposes noted below. Bonds issued by a surety, who is authorized to issue bonds in California, and whose bonding limitation shown in said circular is sufficient to provide bonds in the amount required by the Contract shall be deemed to be approved unless specifically rejected by the Agency. Bonds from all other sureties shall be accompanied by all of the documents enumerated in Code of Civil Procedure 995.660 (a). The Bidder shall pay all bond premiums, costs, and incidentals. Each bond shall incorporate, by reference, the Contract and be signed by both the Bidder and Surety and the signature of the authorized agent of the Surety shall be notarized. l'\ •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 48 of 101 Pages The Contractor shall provide a faithful performance/warranty bond and payment bond (labor and materials bond) for this contract. The faithful performance/warranty bond shall be in a sum not less than one hundred percent of the total amount payable by the terms of this contract. The Contractor shall provide bonds to secure payment of laborers and materials suppliers in a sum not less than one hundred percent of the total amount payable by the terms of this contract. Both bonds shall extend in full force and effect and be retained by the Agency during this project until they are released according to the provisions of this section. The faithful performance/warranty bond will be reduced to 25 percent of the original amount 30 days after recordation of the Notice of Completion and will remain in full force and effect for the one year warranty period and until all warranty repairs are completed to the satisfaction of the Engineer. The bonds to secure payment of laborers and materials suppliers shall be released six months plus 30 days after recordation of the Notice of Completion if all claims have been paid. All bonds are to be placed with a surety insurance carrier admitted and authorized to transact the business of insurance in California and whose assets exceed their liabilities in an amount equal to or in excess of the amount of the bond. The bonds are to contain the following documents: 1) An original, or a certified copy, of the un-revoked appointment, power of attorney, by laws, or other instrument entitling or authorizing the person who executed the bond to do so. 2) A certified copy of the certificate of authority of the insurer issued by the insurance commissioner. If the bid is accepted, the Agency may require a financial statement of the assets and liabilities of the insurer at the end of the quarter calendar year prior to 30 days next preceding the date of the execution of the bond. The financial statement shall be made by an officer's certificate as defined in Section 173 of the Corporations Code. In the case of a foreign insurer, the financial statement may be verified by the oath of the principal officer or manager residing within the United States. Should any bond become insufficient, the Contractor shall renew the bond within 10 days after receiving notice from the Agency. Should any Surety at any time be unsatisfactory to the Board, notice will be given the Contractor to that effect. No further payments shall be deemed due or will be made under the contract until a new Surety shall qualify and be accepted by the Board. Changes in the Work or extensions of time, made pursuant to the Contract, shall in no way release the Contractor or Surety from its obligations. Notice of such changes or extensions shall be waived by the Surety. 2-5 PLANS AND SPECIFICATIONS. 2-5.1 General. The Contractor shall keep at the Work site a copy of the Plans, Contract Documents, and Specifications, to which the Engineer shall have access at all times. The construction plans consist of one set. The plan set is designated as City of Carlsbad Drawing No. 509-9 and consists of 6 sheets. l'\ •+;' Revised 2/27/18 PWS 18-12 HRAN-Contract No. 3896 Page 49 of 101 Pages The specifications for the work include the General Provisions, project technical specifications, Carlsbad Engineering Standards (CES), Standard Specifications for Public Works Construction, (SSPWC), Part 2 & 3, and the latest supplements thereto, current edition at the time of bid opening as published by the "Greenbook" Committee of Public Works Standards, Inc., hereinafter designated "SSPWC", as amended. The standard drawings used for this project are the latest edition of the San Diego Area Regional Standard Drawings, hereinafter designated SDRSD, as issued by the San Diego County Department of Public Works, together with the most recent editions of the City of Carlsbad Engineering Standards and Carlsbad Standard Drawings, as issued by the City of Carlsbad and the Carlsbad Municipal Water District, hereinafter designated as CES and CSD, respectively. The Plans, Specifications, and other Contract Documents shall govern the Work. The Contract Documents are intended to be complementary and cooperative. Anything specified in the Specifications and not shown on the Plans, or shown on the Plans and not specified in the Specifications, shall be as though shown on or specified in both. The Contractor shall ascertain the existence of any conditions affecting the cost of the Work through a reasonable examination of the Work site prior to submitting the Bid. Existing improvements visible at the Work site, for which no specific disposition is made, but which interfere with the completion of the Work, shall be removed and disposed of by the Contractor. The Contractor shall, upon discovering any error or omission in the Plans or Specifications, immediately call it to the attention of the Engineer. 2-5.2 Precedence of Contract Documents. If there is a conflict between Contract Documents, the document highest in precedence shall control. The precedence shall be the most recent edition of the following documents listed in order of highest to lowest precedence: 1) Permits from other agencies as may be required by law. 2) Change orders, whichever occurs last. 3) Contract addenda, whichever occurs last. 4) Contract 5) Carlsbad General Provisions, Technical Specifications, and Supplemental Provisions. 6) Plans. 7) Standards plans. a) City of Carlsbad Standard Drawings. b) Carlsbad Municipal Water District Standard Drawings. c) City of Carlsbad modifications to the San Diego Area Regional Standard Drawings. d) San Diego Area Regional Standard Drawings. e) Traffic Signal Design Guidelines and Standards. f) State of California Department of Transportation Standard Plans. g) State of California Department of Transportation Standard Specifications. h) California Manual on Uniform Traffic Control Devices (CA MUTCD). 8) Standard Specifications for Public Works Construction, as amended. ,, •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 50 of 101 Pages 9) Reference Specifications. 10) Manufacturer's Installation Recommendations Change Orders, Supplemental Agreements and approved revisions to Plans and Specifications will take precedence over items 2) through 9) above. Detailed plans and plan views shall have precedence over general plans. 2-5.3 Submittals. 2-5.3.1 General. Submittals shall be provided, at the Contractor's expense, as required in 2-5.3.2, 2-5.3.3 and 2-5.3.4, when required by the Plans or Special Provisions, or when requested by the Engineer. Materials shall neither be furnished nor fabricated, nor shall any work for which submittals are required by performed, before the required submittals have been reviewed and accepted by the Engineer. Neither review nor acceptance of submittals by the Engineer shall relieve the Contractor from responsibility for errors, omissions, or deviations from the Contract Documents, unless such deviations were specifically called to the attention of the Engineer in the letter of transmittal. The Contractor shall be responsible for the correctness of the submittals. The Contractor shall allow a minimum of 20 working days for review of submittals unless otherwise specified in the Special Provisions. Each submittal shall be accompanied by a letter of transmittal. Each submittal shall be consecutively numbered. Resubmittals shall be labeled with the number of the original submittal followed by an ascending alphabetical designation (e.g. The label '4-C' would indicate the third instance that the fourth submittal had been given to the Engineer). Each sheet of each submittal shall be consecutively numbered. Each set of shop drawings and submittals shall be accompanied by a letter of transmittal on the Contractor's letterhead. The Letter of Transmittal shall contain the following: 1) Project title and Agency contract number. 2) Number of complete sets. 3) Contractor's certification statement. 4) Specification section number(s) pertaining to material submitted for review. 5) Submittal number (Submittal numbers shall be consecutive including subsequent submittals for the same materials.) 6) Description of the contents of the submittal. 7) Identification of deviations from the contract documents. When submitted for the Engineer's review, Shop Drawings shall bear the Contractor's certification that the Contractor has reviewed, checked, and approved the Shop Drawings and that they are in conformance with the requirements of the Contract Documents. The Contractor shall subscribe to and shall place the following certification on all submittals: "I hereby certify that the (equipment, material) shown and marked in this submittal is that proposed to be incorporated into this Project, is in compliance with the Contract Documents, can be installed in the allocated spaces, and is submitted for approval." By: ___________ _ Title: _____________ _ Date: _____________ _ Company Name: ____________________________ _ l' •+; Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 51 of 101 Pages 2-5.3.2 Working Drawings. Working drawings are drawings showing details not shown on the Plans which are required to be designed by the Contractor. Working drawings shall be of a size and scale to clearly show all necessary details. Six copies and one reproducible shall be submitted. If no revisions are required, three of the copies will be returned to the Contractor. If revisions are required, the Engineer will return one copy along with the reproducible for resubmission. Upon acceptance, the Engineer will return two of the copies to the Contractor and retain the remaining copies and the reproducible. Working drawings are required in the following sections: TABLE 2-5.3.2 (A) It em ec1on um S f N b er T"tl I e s b" t U IJeC 1 7-10.4.1 Safety Orders Trench Shoring 2 207-2.5 Joints Reinforced Concrete Pipe 3 207-8.4 Joints Vitrified Clay Pipe 4 207-10.2.1 General Fabricated Steel Pipe 5 300-3.2 Cofferdams Structure Excavation & Backfill 6 303-1.6.1 General Falsework 7 303-1.7.1 General Placing Reinforcement 8 303-3.1 General Prestressed Concrete Construction 9 304-1.1.1 Shop Drawings Structural Steel 10 304-1.1.2 Falsework Plans Structural Steel 11 304-2.1 General Metal Hand Railings 12 306-2.1 General Jacking Operations 13 306-3.1 General Tunneling Operations 14 306-3.4 Tunnel Supports Tunneling Operations 15 306-6 Remodeling Existing Sewer Facilities Polyethylene Liner Installation 16 306-8 Microtunneling Microtunneling Operations 17 307-4.3 Controller Cabinet Wiring Diagrams Traffic Signal Construction Working drawings listed above as Items 5, 6, 8, 9, 10, 12, 13, 14 and 16 shall be prepared by a Civil or Structural Engineer registered by the State of California. 2-5.3.3 Shop Drawings. Shop drawings are drawings showing details of manufactured or assembled products proposed to be incorporated into the Work. Shop drawings required shall be as specified in the Special Provisions. 2-5.3.4 Supporting Information. Supporting information is information required by the Specifications for the purposes of administration of the Contract, analysis for verification of conformance with the Specifications, the operation and maintenance of a manufactured product or system to be constructed as part of the Work, and other information as may be required by the Engineer. Six copies of the supporting information shall be submitted to the Engineer prior to the start of the Work unless otherwise specified in the Special Provisions or directed by the Engineer. Supporting information for systems shall be bound together and include all manufactured items for the system. If resubmittal is not required, three copies will be returned to the Contractor. Supporting information shall consist of the following and is required unless otherwise specified in the Special Provisions: 1) List of Subcontractors per 2-3.2. 2) List of Materials per 4-1.4. 3) Certifications per 4-1.5. 4) Construction Schedule per 6-1. 5) Confined Space Entry Program per 7-10.4.4. l' •+' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 52 of 101 Pages 6) Concrete mix designs per 201-1.1. 7) Asphalt concrete mix designs per 203-6.1. 8) Data, including, but not limited to, catalog sheets, manufacturer's brochures, technical bulletins, specifications, diagrams, product samples, and other information necessary to describe a system, product or item. This information is required for irrigation systems, street lighting systems, and traffic signals, and may also be required for any product, manufactured item, or system. 2-5.4 Record Drawings. The Contractor shall provide and keep up-to-date a complete "as-built" record set of blue-line prints, which shall be corrected in red daily and show every change from the original drawings and specifications and the exact "as-built" locations, sizes and kinds of equipment, underground piping, valves, and all other work not visible at surface grade. Prints for this purpose may be obtained from the Agency at cost. This set of drawings shall be kept on the job and shall be used only as a record set and shall be delivered to the Engineer within ten (10) days of completion of the work. Payment for performing the work required by Section 2-5.4 shall be included considered incidental to the work and no additional payment will be made therefore. 2-6 WORK TO BE DONE. The Contractor shall perform all work necessary to complete the Contract in a satisfactory manner. Unless otherwise provided, the Contractor shall furnish all materials, equipment, tools, labor, and incidentals necessary to complete the Work. 2-7 SUBSURFACE DAT A. All soil and test hole data, water table elevations, and soil analyses shown on the drawings or included in the Specifications apply only at the location of the test holes and to the depths indicated. Soil test reports for test holes which have been drilled are available for inspection at the office of the Engineer. Any additional subsurface exploration shall be done by Bidders or the Contractor at their own expense. The indicated elevation of the water table is that which existed on the date when test hole data was determined. It is the Contractor's responsibility to determine and allow for the elevation of groundwater at the date of project construction. A difference in elevation between groundwater shown in soil boring logs and groundwater actually encountered during construction will not be considered as a basis for extra work. 2-8 RIGHT-OF-WAY. Rights-of-way, easements, or rights-of-entry for the Work will be provided by the Agency. Unless otherwise provided, the Contractor shall make arrangements, pay for, and assume all responsibility for acquiring, using, and disposing of additional work areas and facilities temporarily required. The Contractor shall indemnify and hold the Agency harmless from all claims for damages caused by such actions. 2-9 SURVEYING. 2-9.1 Permanent Survey Markers. The Contractor shall not cover or disturb permanent survey monuments or benchmarks without the consent of the Engineer. Where the Engineer concurs, in writing, with the Contractor that protecting an existing monument in place is impractical, the Contractor shall employ a licensed land surveyor or a registered civil engineer authorized to practice land surveying within the State of California, hereinafter Surveyor, to establish the location of the monument before it is disturbed. The Contractor shall have the monument replaced by the Surveyor no later than thirty (30) days after construction at the site of the replacement is completed. The Surveyor shall file corner record(s) as required by§§ 8772 and 8773, et seq. of the California Business and Professions Code. When a change is made in the finished elevation of the pavement of any roadway in which a permanent survey monument is located, the Contractor shall adjust the monument frame and cover l' •f' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 53 of 101 Pages to the new grade within 7 days of paving unless the Engineer shall approve otherwise. Monument frames and covers shall be protected during street sealing or painting projects or be cleaned to the satisfaction of the Engineer. 2-9.2 Survey Service. The Contractor shall hire and pay for the services of a Surveyor, hereinafter Surveyor to perform all work necessary for establishing control, construction staking, records research and all other surveying work necessary to construct the work, provide surveying services as required herein and provide surveying, drafting and other professional services required to satisfy the requirements of the Land Surveyors Act. Surveyor shall be resident on the site during all surveying operations and shall personally supervise and certify the surveying work. 2-9.2.3 Payment for Survey, Payment for work performed to satisfy the requirements of Sections 2-9.1 through 2-9.2.2 shall be included in the actual bid items requiring the survey work and no additional payment will be made. Extension of unit prices for extra work shall include full compensation for attendant survey work and no additional payment will be made. Payment for the replacement of disturbed monuments and the filing of records of survey and/or corner records, including filing fees, shall be incidental to the work necessitating the disturbance of said monuments and no additional payment will be made. 2-9.3 Private Engineers. Surveying by private engineers on the Work shall conform to the quality and practice required by the Engineer. 2-9.4 Line and Grade. All work shall conform to the lines, elevations, and grades shown on the Plans. Three consecutive points set on the same slope shall be used together so that any variation from a straight grade can be detected. Any such variation shall be reported to the Engineer. In the absence of such report, the Contractor shall be responsible for any error in the grade of the finished work. Grades for underground conduits will be set at the surface of the ground. The Contractor shall transfer them to the bottom of the trench. 2-10 AUTHORITY OF BOARD AND ENGINEER. The Board has the final authority in all matters affecting the Work. Within the scope of the Contract, the Engineer has the authority to enforce compliance with the Plans and Specifications. The Contractor shall promptly comply with instructions from the Engineer or an authorized representative. The decision of the Engineer is final and binding on all questions relating to: quantities; acceptability of material, equipment, or work; execution, progress or sequence of work; and interpretation of the Plans, Specifications, or other drawings. This shall be precedent to any payment under the Contract, unless otherwise ordered by the Board. 2-10.1 Availability of Records. The Contractor shall, at no charge to the Agency, provide copies of all records in the Contractor's or subcontractor's possession pertaining to the work that the Engineer may request. 2-10.2 Audit and Inspection Contractor agrees to maintain and/or make available, to the Engineer, within San Diego County, accurate books and accounting records relative to all its activities and to contractually require all subcontractors to this Contract to do the same. The Engineer shall have the right to monitor, assess, and evaluate Contractor's and its subcontractors performance pursuant to this Agreement, said monitoring, assessments, and evaluations to include, but not be limited to, audits, inspection of premises, reports, contracts, subcontracts and interviews of Contractor's staff and the staff of all subcontractors to this contract. At any time during normal l'\ •,r Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 54 of 101 Pages business hours and as often as the Engineer may deem necessary, upon reasonable advance notice, Contractor shall make available to the Engineer for examination, all of its, and all subcontractors to this contract, records with respect to all matters covered by this Contract and will permit the Engineer to audit, examine, copy and make excerpts or transcripts from such data and records, and to make audits of all invoices, materials, payrolls, records of personnel, and other data relating to all matters covered by this Contract. However, any such activities shall be carried out in a manner so as to not unreasonably interfere with Contractor's ongoing business operations. Contractor and all subcontractors to this contract shall maintain such data and records for as long as may be required by applicable laws and regulations. 2-11 INSPECTION. The Work is subject to inspection and approval by the Engineer. The Contractor shall notify the Engineer before noon of the working day before inspection is required. Work shall be done only in the presence of the Engineer, unless otherwise authorized. Any work done without proper inspection will be subject to rejection. The Engineer and any authorized representatives shall at all times have access to the Work during its construction at shops and yards as well as the project site. The Contractor shall provide every reasonable facility for ascertaining that the materials and workmanship are in accordance with these specifications. Inspection of the Work shall not relieve the Contractor of the obligation to fulfill all conditions of the Contract. SECTION 3 -CHANGES IN WORK 3-1 CHANGES REQUESTED BY THE CONTRACTOR. 3-1.1 General. Changes in the Plans and Specifications, requested in writing by the Contractor, which do not materially affect the Work and which are not detrimental to the Work or to the interests of the Agency, may be granted by the Engineer. Nothing herein shall be construed as granting a right to the Contractor to demand acceptance of such changes. 3-1.2 Payment for Changes Requested by the Contractor. If such changes are granted, they shall be made at a reduction in cost or no additional cost to the Agency. 3-2CHANGES INITIATED BY THE AGENCY. 3-2.1 General. The Agency may change the Plans, Specifications, character of the work, or quantity of work provided the total arithmetic dollar value of all such changes, both additive and deductive, does not exceed 25 percent of the Contract Price. Should it become necessary to exceed this limitation, the change shall be by written Supplemental Agreement between the Contractor and Agency, unless both parties agree to proceed with the change by Change Order. Change Orders shall be in writing and state the dollar value of the change or established method of payment, any adjustment in contract time of completion, and when negotiated prices are involved, shall provide for the Contractor's signature indicating acceptance. 3-2.2 Payment. 3-2.2.1 Contract Unit Prices. If a change is ordered in an item of work covered by a Contract Unit Price, and such change does not involve substantial change in character of the work from that l' •+' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 55 of 101 Pages shown on the Plans or specified in the Specifications, then an adjustment in payment will be made. This adjustment will be based upon the increase or decrease in quantity and the Contract Unit Price. If the actual quantity of an item of work covered by a Contract Unit Price and constructed in conformance with the Plans and Specifications varies from the Bid quantity by 50 percent or less, payment will be made at the Contract Unit Price. If the actual quantity of said item of work varies from the Bid quantity by more than 50 percent, payment will be made per Section 3-2.2.2 or 3-2.2.3 as appropriate. If a change is ordered in an item of work covered by a Contract Unit Price, and such change does involve a substantial change in the character of the work from that shown on the Plans or specified in the Specifications, an adjustment in payment will be made per Section 3-2.4. 3-2.2.2 Increases of More Than 50 Percent. Should the actual quantity of an item of work covered by a Contract Unit Price and constructed in conformance with the Plans and Specifications, exceed the Bid quantity by more than 50 percent, payment for the quantity in excess of 150 percent of the Bid quantity will be made on the basis of an adjustment in the Contract Unit Price mutually agreed to by the Contractor and the Agency, or at the option of the Engineer, on the basis of Extra Work per Section 3-3. The Extra Work per Section 3-3, basis of payment, shall not include fixed costs. Fixed costs shall be deemed to have been recovered by the Contractor through payment for 150 percent of the Bid quantity at the Contract Unit Price. 3-2.2.3 Decreases of More Than 50 Percent. Should the actual quantity of an item of work covered by a Contract Unit Price, and constructed in conformance with the Plans and Specifications, be less than 50 percent of the Bid quantity, an adjustment in payment will not be made unless so requested in writing by the Contractor. If the Contractor so requests, payment will be made on the basis of an adjustment in the Contract Unit Price mutually agreed to by the Contractor and the Agency, or at the option of the Engineer, on the basis of Extra Work per Section 3-3; however, in no case will payment be less than would be made for the actual quantity at the Contract Unit Price nor more than would be made for 50 percent of the Bid quantity at the Contract Unit Price. 3-2.3 Stipulated Unit Prices. Stipulated Unit Prices are unit prices established by the Agency in the Contract Documents as distinguished from Contract Unit Prices submitted by the Contractor. Stipulated Unit Prices may be used for the adjustment of Contract changes when so specified in the Special Provisions. 3-2.4 Agreed Prices. Agreed Prices are prices for new or unforeseen work, or adjustments in Contract Unit Prices per Section 3-2.2, established by mutual agreement between the Contractor and the Agency. If mutual agreement cannot be reached, the Engineer may direct the Contractor to proceed on the basis of Extra Work in accordance per Section 3-3, except as otherwise specified in Sections 3-2.2.2 and 3-2.2.3. 3.2.4.1 Schedule of Values. Prior to construction, Contractor shall provide a schedule of values for all lump sum bid items that shall be used for the purpose of progress payments. The prices shall be valid for the purpose of change orders to the project. 3.2.5 Eliminated Items. Should any Bid item be eliminated in its entirety, payment will be made to the Contractor for its actual costs incurred in connection with the eliminated item prior to notification in writing from the Engineer so stating its elimination. If material conforming to the Plans and Specifications is ordered by the Contractor for use in the eliminated item prior to the date of notification of elimination by the Engineer, and if the order for that material cannot be canceled, payment will be made to the Contractor for the actual cost of the material. In this case, the material shall become the property of the Agency. Payment will be made to the Contractor for its actual costs for any further l' •+' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 56 of 101 Pages handling. If the material is returnable, the material shall be returned and payment will be made to the Contractor for the actual cost of charges made by the supplier for returning the material and for handling by the Contractor. Actual costs, as used herein, shall be computed on the basis of Extra Work per Section 3-3. 3-3 EXTRA WORK. 3-3.1 General. New or unforeseen work will be classified as "extra work" when the Engineer determines that it is not covered by Contract Unit Prices or stipulated unit prices. 3-3.2 Payment. 3-3.2.1 General. When the price for the extra work cannot be agreed upon, the Agency will pay for the extra work based on the accumulation of costs as provided herein. 3-3.2.2 Basis for Establishing Costs. (a) Labor. The costs of labor will be the actual cost for wages of workers performing the extra work at the time the extra work is done, plus employer payments of payroll taxes, workers compensation insurance, liability insurance, health and welfare, pension, vacation, apprenticeship funds, and other direct costs, resulting from Federal, State, or local laws, as well as assessments or benefits required by lawful collective bargaining agreements. The use of a labor classification which would increase the extra work cost will not be permitted unless the Contractor establishes the necessity for such additional costs. Labor costs for equipment operators and helpers shall be reported only when such costs are not included in the invoice for equipment rental. The labor cost for foremen shall be proportioned to all of their assigned work and only that applicable to extra work will be paid. Nondirect labor costs, including superintendence, shall be considered part of the markup of Section 3-3.2.3 (a). (b) Materials. The cost of materials reported shall be at invoice or lowest current price at which such materials are locally available and delivered to the job site in the quantities involved, plus sales tax, freight, and delivery. The Agency reserves the right to approve materials and sources of supply, or to supply materials to the Contractor if necessary for the progress of the Work. No markup shall be applied to any material provided by the Agency. (c) Tool and Equipment Rental. No payment will be made for the use of tools which have a replacement value of $200 or less. Regardless of ownership, the rates and right-of-way delay factors to be used in determining rental and delay costs shall be the edition of the, "Labor Surcharge and Equipment Rental Rates" published by CAL TRANS, current at the time of the actual use of the tool or equipment. The right-of-way delay factors therein shall be used as multipliers of the rental rates for determining the value of costs for delay to the Contractor and subcontractors, if any. The labor surcharge rates published therein are not a part of this contract. The rental rates paid shall include the cost of fuel, oil, lubrication, supplies, small tools, necessary attachments, repairs and maintenance of any kind, depreciation, storage, insurance, and all ('\ •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 57 of 101 Pages incidentals. Necessary loading and transportation costs for equipment used on the extra work shall be included. If equipment is used intermittently and, when not in use, could be returned to its rental source at less expense to the Agency than holding it at the Work site, it shall be returned, unless the Contractor elects to keep it at the Work site, at no expense to the Agency. All equipment shall be acceptable to the Engineer, in good working condition, and suitable for the purpose for which it is to be used. Manufacturer's ratings and approved modifications shall be used to classify equipment and it shall be powered by a unit of at least the minimum rating recommended by the manufacturer. The reported rental time for equipment already at the Work site shall be the duration of its use on the extra work. This time begins when equipment is first put into actual operation on the extra work, plus the time required to move it from its previous site and back, or to a closer site. (d) Other Items. The Agency may authorize other items which may be required on the extra work, including labor, services, material, and equipment. These items must be different in their nature from those required for the Work, and be of a type not ordinarily available from the Contractor or Subcontractors. Invoices covering all such items in detail shall be submitted with the request for payment. (e) Invoices. Vendors' invoices for material, equipment rental and other expenditures shall be submitted with the request for payment. If the request for payment is not substantiated by invoices or other documentation, the Agency may establish the cost of the item involved at the lowest price which was current at the time of the report. 3-3.2.3 Markup. (a) Work by Contractor. The following percentages shall be added to the Contractor's costs and shall constitute the markup for all overhead and profits: 1) Labor ................................... 20 2) Materials . . .. .. .. . .. .. .. .. .. .. .. .. .. .. 15 3) Equipment Rental ................... 15 4) Other Items and Expenditures .. 15 To the sum of the costs and markups provided for in this section, 1 percent shall be added as compensation for bonding. (b) Work by Subcontractor. When all or any part of the extra work is performed by a Subcontractor, the markup established in Section 3-3.2.3(a) shall be applied to the Subcontractor's actual cost of such work. A markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of $5,000 of the subcontracted portion of the extra work may be added by the Contractor. 3-3.3 Daily Reports by Contractor. When the price for the extra work cannot be agreed upon, the Contractor shall submit a daily report to the Engineer on forms approved by the Agency. Included are applicable delivery tickets, listing all labor, materials, and equipment involved for that day, and other services and expenditures when authorized. Payment for extra work will not be made until such time that the Contractor submits completed daily reports and all supporting documents to the Engineer. Failure to submit the daily report by the close of the next working day may waive any rights for that day. An attempt shall be made to reconcile the report daily, and it shall be signed by the Engineer and ('\ •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 58 of 101 Pages the Contractor. In the event of disagreement, pertinent notes shall be entered by each party to explain points which cannot be resolved immediately. Each party shall retain a signed copy of the report. Reports by Subcontractors or others shall be submitted through the Contractor. The report shall: 1. Show names of workers, classifications, and hours worked. 2. Describe and list quantities of materials used. 3. Show type of equipment, size, identification number, and hours of operation, including loading and transportation, if applicable. 4. Describe other services and expenditures in such detail as the Agency may require. 3-4 CHANGED CONDITIONS. The Contractor shall promptly notify the Engineer of the following Work site conditions (hereinafter called changed conditions), in writing, upon their discovery and before they are disturbed: 1. Subsurface or latent physical conditions differing materially from those represented in the Contract; 2. Unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character being performed; and 3. Material differing from that represented in the Contract which the Contractor believes may be hazardous waste, as defined in Section 25117 of the Health and Safety Code, that is required to be removed to a Class I, Class 11, or Class 111 disposal site in accordance with provisions of existing law. The Engineer will promptly investigate conditions which appear to be changed conditions. If the Engineer determines that conditions are changed conditions and they will materially affect performance time, the Contractor, upon submitting a written request, will be granted an extension of time subject to the provisions of 6-6. If the Engineer determines that the conditions do not justify an adjustment in compensation, the Contractor will be notified in writing. This notice will also advise the Contractor of its obligation to notify the Engineer in writing if the Contractor disagrees. The Contractor's failure to give notice of changed conditions promptly upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith. The Contractor shall not be entitled to the payment of any additional compensation for any act, or failure to act, by the Engineer, including failure or refusal to issue a change order, or for the happening of any event, thing, occurrence, or other cause, unless the Contractor shall have first given the Engineer due written notice of potential claim as hereinafter specified. Compliance with this section shall not be required as a prerequisite to notice provisions in Section 6-7.3 Contract Time Accounting, nor to any claim that is based on differences in measurement or errors of computation as to contract quantities. The written notice of potential claim for changed conditions shall be submitted by the Contractor to the Engineer upon their discovery and prior to the time that the Contractor performs the work giving rise to the potential claim. The Contractor's failure to give written notice of potential claim for changed conditions to the agency upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith. The Contractor shall provide the City with a written document containing a description of the particular circumstances giving rise to the potential claim, the reasons for which the Contractor believes additional compensation may be due and nature of any and all costs involved within 20 working days l' •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 59 of 101 Pages of the date of service of the written notice of potential claim for changed conditions. Verbal notifications are disallowed. The potential claim shall include the following certification relative to the California False Claims Act, Government Code Sections 12650-12655. "The undersigned certifies that the above statements are made in full cognizance of the California False Claims Act, Government Code Sections 12650-12655. The undersigned further understands and agrees that this potential claim, unless resolved, must be restated as a claim in response to the City's proposed final estimate in order for it to be further considered." By: _____________ _ Title: _____________ _ Date: ______________ _ Company Name: _____________________________ _ The Contractor's estimate of costs may be updated when actual costs are known. The Contractor shall submit substantiation of its actual costs to the Engineer within 20 working days after the affected work is completed. Failure to do so shall be sufficient cause for denial of any claim subsequently filed on the basis of said notice of potential claim. It is the intention of this section that differences between the parties arising under and by virtue of the contract be brought to the attention of the Engineer at the earliest possible time in order that such matters be settled, if possible, or other appropriate action promptly taken. 3-5 DISPUTED WORK. The Contractor shall give the agency written notice of potential claim prior to commencing any disputed work. Failure to give said notice shall constitute a waiver of all claims in connection therewith. If the contractor and the agency are unable to reach agreement on disputed work, the Agency may direct the contractor to proceed with the work. Prior to proceeding with dispute resolution pursuant to Public Contract Code provisions specified hereinafter, the contractor shall attempt to resolve all disputes informally through the following dispute resolution chain of command: 1. Project Inspector 2. Construction Manager 3. Deputy City Engineer, Construction Management & Inspection 4. City Engineer 5. City Manager The Contractor shall submit a complete report within 20 working days after completion of the disputed work stating its position on the claim, the contractual basis for the claim, along with all documentation supporting the costs and all other evidentiary materials. At each level of claim or appeal of claim the City will, within 10 working days of receipt of said claim or appeal of claim, review the Contractor's report and respond with a position, request additional information or request that the Contractor meet and present its report. When additional information or a meeting is requested the City will provide its position within 10 working days of receipt of said additional information or Contractor's presentation ,, •+' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 60 of 101 Pages of its report. The Contractor may appeal each level's position up to the City Manager after which the Contractor may proceed under the provisions of the Public Contract Code. The authority within the dispute resolution chain of command is limited to recommending a resolution to a claim to the City Manager. Actual approval of the claim is subject to the change order provisions in the contract. All claims by the contractor for $375,000 or less shall be resolved in accordance with the procedures in the Public Contract Code, Division 2, Part 3, Chapter 1, Article 1.5 (commencing with Section 20104) which is set forth below: ARTICLE 1.5 RESOLUTION OF CONSTRUCTION CLAIMS 20104. (a)(1) This article applies to all public works claims of three hundred seventy-five thousand dollars ($375,000) or less which arise between a contractor and a local agency. (2) This article shall not apply to any claims resulting from a contract between a contractor and a public agency when the public agency has elected to resolve any disputes pursuant to Article 7.1 (commencing with Section 10240) of Chapter 1 of Part 2. (b)(1) "Public work" has the same meaning as in Sections 3100 and 3106 of the Civil Code, except that "public work" does not include any work or improvement contracted for by the state or the Regents of the University of California. (2) "Claim" means a separate demand by the contractor for (A) a time extension, (B) payment of money or damages arising from work done by, or on behalf of, the contractor pursuant to the contract for a public work and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to, or (C) an amount the payment of which is disputed by the local agency. (c) The provisions of this article or a summary thereof shall be set forth in the plans or specifications for any work which may give rise to a claim under this article. This article applies only to contracts entered into on or after January 1, 1991. 20104.2. For any claim subject to this article, the following requirements apply: (a) The claim shall be in writing and include the documents necessary to substantiate the claim. Claims must be filed on or before the date of final payment. Nothing in this subdivision is intended to extend the time limit or supersede notice requirements otherwise provided by contract for the filing of claims. (b)(1) For claims of less than fifty thousand dollars ($50,000), the local agency shall respond in writing to any written claim within 45 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant. (2) If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of the local agency and the claimant. (3) The local agency's written response to the claim, as further documented, shall be submitted to the claimant within 15 days after receipt of the further documentation or within a period of time no greater than that taken by the claimant in producing the additional information, whichever is greater. (c)(1) For claims of over fifty thousand dollars ($50,000) and less than or equal to three hundred seventy-five thousand dollars ($375,000), the local agency shall respond in writing to all written claims l"\ •;;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 61 of 101 Pages within 60 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant. (2) If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of the local agency and the claimant. (3) The local agency's written response to the claim, as further documented, shall be submitted to the claimant within 30 days after receipt of the further documentation, or within a period of time no greater than that taken by the claimant in producing the additional information or requested documentation, whichever is greater. (d) If the claimant disputes the local agency's written response, or the local agency fails to respond within the time prescribed, the claimant may so notify the local agency, in writing, either within 15 days of receipt of the local agency's response or within 15 days of the local agency's failure to respond within the time prescribed, respectively, and demand an informal conference to meet and confer for settlement of the issues in dispute. Upon a demand, the local agency shall schedule a meet and confer conference within 30 days for settlement of the dispute. (e) Following the meet and confer conference, if the claim or any portion remains in dispute, the claimant may file a claim as provided in Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the claimant submits his or her written claim pursuant to subdivision (a) until the time that claim is denied as a result of the meet and confer process, including any period of time utilized by the meet and confer process. (f) This article does not apply to tort claims and nothing in this article is intended nor shall be construed to change the time periods for filing tort claims or actions specified by Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. 20104.4. The following procedures are established for all civil actions filed to resolve claims subject to this article: (a) Within 60 days, but no earlier than 30 days, following the filing or responsive pleadings, the court shall submit the matter to non-binding mediation unless waived by mutual stipulation of both parties. The mediation process shall provide for the selection within 15 days by both parties of a disinterested third person as mediator, shall be commenced within 30 days of the submittal, and shall be concluded within 15 days from the commencement of the mediation unless a time requirement is extended upon a good cause showing to the court or by stipulation of both parties. If the parties fail to select a mediator within the 15-day period, any party may petition the court to appoint the mediator. (b)(1) If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 ( commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, notwithstanding Section 1141 .11 of that code. The Civil Discovery Act of 1986 (Article 3 ( commencing with Section 2016) of Chapter 3 of Title 3 of Part 4 of the Code of Civil procedure) shall apply to any proceeding brought under the subdivision consistent with the rules pertaining to judicial arbitration. (2) Notwithstanding any other provision of law, upon stipulation of the parties, arbitrators appointed for purposes of this article shall be experienced in construction law, and, upon stipulation of the parties, l' •+f Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 62 of 101 Pages mediators and arbitrators shall be paid necessary and reasonable hourly rates of pay not to exceed their customary rate, and such fees and expenses shall be paid equally by the parties, except in the case of arbitration where the arbitrator, for good cause, determines a different division. In no event shall these fees or expenses be paid by state or county funds. (3) In addition to Chapter 2.5 (commencing with Section 1141.10) Title 3 of Part 3 of the Code of Civil Procedure, any party who after receiving an arbitration award requests a trial de nova but does not obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, pay the attorney's fees of the other party arising out of the trial de nova. (c) The court may, upon request by any party, order any witnesses to participate in the mediation or arbitration process. 20104.6. (a) No local agency shall fail to pay money as to any portion of a claim which is undisputed except as otherwise provided in the contract. (b) In any suit filed under Section 20104.4, the local agency shall pay interest at the legal rate on any arbitration award or judgment. The interest shall begin to accrue on the date the suit is filed in a court of law. Although not to be construed as proceeding under extra work provisions, the Contractor shall keep and furnish records of disputed work in accordance with Section 3-3. SECTION 4 -CONTROL OF MATERIALS 4-1 MATERIALS AND WORKMANSHIP. 4-1.1. General. All materials, parts, and equipment furnished by the Contractor in the Work shall be new, high grade, and free from defects. Quality of work shall be in accordance with the generally accepted standards. Material and work quality shall be subject to the Engineer's approval. Materials and work quality not conforming to the requirements of the Specifications shall be considered defective and will be subject to rejection. Defective work or material, whether in place or not, shall be removed immediately from the site by the Contractor, at its expense, when so directed by the Engineer. If the Contractor fails to replace any defective or damaged work or material after reasonable notice, the Engineer may cause such work or materials to be replaced. The replacement expense will be deducted from the amount to be paid to the Contractor. Used or secondhand materials, parts, and equipment may be used only if permitted by the Specifications. 4-1.2 Protection of Work and Materials. The Contractor shall provide and maintain storage facilities and employ such measures as will preserve the specified quality and fitness of materials to be used in the Work. Stored materials shall be reasonably accessible for inspection. The Contractor shall also adequately protect new and existing work and all items of equipment for the duration of the Contract. l' •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 63 of 101 Pages The Contractor shall not, without the Agency's consent, assign, sell, mortgage, hypothecate, or remove equipment or materials which have been installed or delivered and which may be necessary for the completion of the Contract. 4-1.3 Inspection Requirements. 4-1.3.1 General. Unless otherwise specified, inspection is required at the source for such typical materials and fabricated items as bituminous paving mixtures, structural concrete, metal fabrication, metal casting, welding, concrete pipe manufacture, protective coating application, and similar shop or plant operations. Steel pipe in sizes less than 18 inches and vitrified clay and cast iron pipe in all sizes are acceptable upon certification as to compliance with the Specifications, subject to sampling and testing by the Agency. Standard items of equipment such as electric motors, conveyors, elevators, plumbing fixtures, etc., are subject to inspection at the job site only. Special items of equipment such as designed electrical panel boards, large pumps, sewage plant equipment, etc., are subject to inspection at the source, normally only for performance testing. The Specifications may require inspection at the source for other items not typical of those listed in this section. The Contractor shall provide the Engineer free and safe access to any and all parts of work at any time. Such free and safe access shall include means of safe access and egress, ventilation, lighting, shoring, dewatering and all elements pertaining to the safety of persons as contained in the State of California, California Code of Regulations, Title 8, Industrial Relations, Chapter 4, Division of Industrial Safety, Subchapter 4, Construction Safety Orders and such other safety regulations as may apply. Contractor shall furnish Engineer with such information as may be necessary to keep the Engineer fully informed regarding progress and manner of work and character of materials. Inspection or testing of the whole or any portion of the work or materials incorporated in the work shall not relieve Contractor from any obligation to fulfill this Contract. 4-1.3.2 Inspection of Materials Not Locally Produced. When the Contractor intends to purchase materials, fabricated products, or equipment from sources located more than 50 miles outside the geographical limits of the Agency, an inspector or accredited testing laboratory (approved by the Engineer), shall be engaged by the Contractor at its expense, to inspect the materials, equipment or process. This approval shall be obtained before producing any material or equipment. The inspector or representative of the testing laboratory shall judge the materials by the requirements of the Plans and Specifications. The Contractor shall forward reports required by the Engineer. No material or equipment shall be shipped nor shall any processing, fabrication or treatment of such materials be done without proper inspection by the approved agent. Approval by said agent shall not relieve the Contractor of responsibility for complying with the Contract requirements. 4-1.3.3 Inspection by the Agency. The Agency will provide all inspection and testing laboratory services within 50 miles of the geographical limits of the Agency. For private contracts, all costs of inspection at the source, including salaries and mileage costs, shall be paid by the permittee. 4-1.4 Test of Material. Before incorporation in the Work, the Contractor shall submit samples of materials, as the Engineer may require, at no cost to the Agency. The Contractor, at its expense, shall deliver the materials for testing to the place and at the time designated by the Engineer. Unless otherwise provided, all initial testing will be performed under the direction of the Engineer, and at no expense to the Contractor. If the Contractor is to provide and pay for testing, it will be stated in the Specifications. For private contracts, the testing expense shall be borne by the permittee. l' • ., Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 64 of 101 Pages The Contractor shall notify the Engineer in writing, at least 15 days in advance, of its intention to use materials for which tests are specified, to allow sufficient time to perform the tests. The notice shall name the proposed supplier and source of material. If the notice of intent to use is sent before the materials are available for testing or inspection, or is sent so far in advance that the materials on hand at the time will not last but will be replaced by a new lot prior to use on the Work, it will be the Contractor's responsibility to renotify the Engineer when samples which are representative may be obtained. Except as specified in these Provisions, the Agency will bear the cost of testing of locally produced materials and/or on-site workmanship where the results of such tests meet or exceed the requirements indicated in the Standard Specifications, Technical Specification, and any Supplemental Provisions. The cost of all other tests shall be borne by the Contractor. At the option of the Engineer, the source of supply of each of the materials shall be approved by the Engineer before the delivery is started. All materials proposed for use may be inspected or tested at any time during their preparation and use. If, after incorporating such materials into the Work, it is found that sources of supply that have been approved do not furnish a uniform product, or if the product from any source proves unacceptable at any time, the Contractor shall furnish approved material from other approved sources. If any product proves unacceptable after improper storage, handling or for any other reason it shall be rejected, not incorporated into the work and shall be removed from the project site all at the Contractor's expense. Compaction tests may be made by the Engineer and all costs for tests that meet or exceed the requirements of the specifications shall be borne by the Agency. Said tests may be made at any place along the work as deemed necessary by the Engineer. The costs of any retests made necessary by noncompliance with the specifications shall be borne by the Contractor. 4-1.5 Certification. The Engineer may waive materials testing requirements of the Specifications and accept the manufacturer's written certification that the materials to be supplied meet those requirements. Material test data may be required as part of the certification. 4-1.6 Trade Names or Equals. The Contractor may supply any of the materials specified or offer an equivalent. The Engineer shall determine whether the material offered is equivalent to that specified. Adequate time shall be allowed for the Engineer to make this determination. Whenever any particular material, process, or equipment is indicated by patent, proprietary or brand name, or by name of manufacturer, such wording is used for the purpose of facilitating its description and shall be deemed to be followed by the words or equal. A listing of materials is not intended to be comprehensive, or in order of preference. The Contractor may offer any material, process, or equipment considered to be equivalent to that indicated. The substantiation of offers shall be submitted as provided in the contract documents. The Contractor shall, at its expense, furnish data concerning items offered by it as equivalent to those specified. The Contractor shall have the material tested as required by the Engineer to determine that the quality, strength, physical, chemical, or other characteristics, including durability, finish, efficiency, dimensions, service, and suitability are such that the item will fulfill its intended function. Test methods shall be subject to the approval of the Engineer. Test results shall be reported promptly to the Engineer, who will evaluate the results and determine if the substitute item is equivalent. The Engineer's findings shall be final. Installation and use of a substitute item shall not be made until approved by the Engineer. l' •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 65 of 101 Pages If a substitute offered by the Contractor is not found to be equal to the specified material, the Contractor shall furnish and install the specified material. The specified Contract completion time shall not be affected by any circumstance developing from the provisions of this section. The Contractor is responsible for the satisfactory performance of substituted items. If, in the sole opinion of the Engineer, the substitution is determined to be unsatisfactory in performance, appearance, durability, compatibility with associated items, availability of repair parts and suitability of application the Contractor shall remove the substituted item and replace it with the originally specified item at no cost to the Agency. 4-1.7 Weighing and Metering Equipment. All scales and metering equipment used for proportioning materials shall be inspected for accuracy and certified within the past 12 months by the State of California Bureau of Weights and Measures, by the County Director or Sealer of Weights and Measures, or by a scale mechanic registered with or licensed by the County. The accuracy of the work of a scale service agency, except as stated herein, shall meet the standards of the California Business and Professions Code and the California Code of Regulations pertaining to weighing devices. A certificate of compliance shall be presented, prior to operation, to the Engineer for approval and shall be renewed whenever required by the Engineer at no cost to the Agency. All scales shall be arranged so they may be read easily from the operator's platform or area. They shall indicate the true net weight without the application of any factor. The figures of the scales shall be clearly legible. Scales shall be accurate to within 1 percent when tested with the plant shut down. Weighing equipment shall be so insulated against vibration or moving of other operating equipment in the plant area that the error in weighing with the entire plant running will not exceed 2 percent for any setting nor 1.5 percent for any batch. 4-1.8 Calibration of Testing Equipment. Testing equipment, such as, but not limited to pressure gages, metering devices, hydraulic systems, force (load) measuring instruments, and strain- measuring devices shall be calibrated by a testing agency acceptable to the Engineer at intervals not to exceed 12 months and following repairs, modification, or relocation of the equipment. Calibration certificates shall be provided when requested by the Engineer. 4-1.9 Construction Materials Dispute Resolution (Soils, Rock Materials, Concrete, Mortar and Related Materials, Masonry Materials, Bituminous Materials, Rock Products, and Modified Asphalts). In the interest of safety and public value, whenever credible evidence arises to contradict the test values of materials, the Agency and the Contractor will initiate an immediate and cooperative investigation. Test values of materials are results of the materials' tests, as defined by these Specifications or by the special provisions, required to accept the Work. Credible evidence is process observations or test values gathered using industry accepted practices. A contradiction exists whenever test values or process observations of the same or similar materials are diverse enough such that the work acceptance or performance becomes suspect. The investigation shall allow access to all test results, procedures, and facilities relevant to the disputed work and consider all available information and, when necessary, gather new and additional information in an attempt to determine the validity, the cause, and if necessary, the remedy to the contradiction. If the cooperative investigation reaches any resolution mechanism acceptable to both the Agency and the Contractor, the contradiction shall be considered resolved and the cooperative investigation concluded. Whenever the cooperative investigation is unable to reach resolution, the investigation may then either conclude without resolution or continue by written notification of one party to the other requesting the implementation of a resolution process by committee. The continuance of the investigation shall be contingent upon recipient's agreement and acknowledged in writing within 3 l' •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 66 of 101 Pages calendar days after receiving a request. Without acknowledgement, the investigation shall conclude without resolution. The committee shall consist of three State of California Registered Civil Engineers. Within 7 calendar days after the written request notification, the Agency and the Contractor will each select one engineer. Within 14 calendar days of the written request notification, the two selected engineers will select a third engineer. The goal in selection of the third member is to complement the professional experience of the first two engineers. Should the two engineers fail to select the third engineer, the Agency and the Contractor shall each propose 2 engineers to be the third member within 21 calendar days after the written request notification. The first two engineers previously selected shall then select one of the four proposed engineers in a blind draw. The committee shall be a continuance of the cooperative investigation and will re-consider all available information and if necessary gather new and additional information to determine the validity, the cause, and if necessary, the remedy to the contradiction. The committee will focus upon the performance adequacy of the material(s) using standard engineering principles and practices and to ensure public value, the committee may provide engineering recommendations as necessary. Unless otherwise agreed, the committee will have 30 calendar days from its formation to complete their review and submit their findings. The final resolution of the committee shall be by majority opinion, in writing, stamped and signed. Should the final resolution not be unanimous, the dissenter may attach a written, stamped, and signed minority opinion. Once started, the resolution process by committee shall continue to full conclusion unless: 1. Within 7 days of the formation of the committee, the Agency and the Contractor reach an acceptable resolution mechanism; or 2. Within 14 days of the formation of the committee, the initiating party withdraws its written notification and agrees to bear all investigative related costs thus far incurred; or 3. At any point by the mutual agreement of the Agency and the Contractor. Unless otherwise agreed, the Contractor shall bear and maintain a record for all the investigative costs until resolution. Should the investigation discover assignable causes for the contradiction, the assignable party, the Agency or the Contractor, shall bear all costs associated with the investigation. Should assignable causes for the contradiction extended to both parties, the investigation will assign costs cooperatively with each party or when necessary, equally. Should the investigation substantiate a contradiction without assignable cause, the investigation will assign costs cooperatively with each party or when necessary, equally. Should the investigation be unable to substantiate a contradiction, the initiator of the investigation shall bear all investigative costs. All claim notification requirements of the contract pertaining to the contradiction shall be suspended until the investigation is concluded. 4-2MATERIALS TRANSPORTATION, HANDLING AND STORAGE. The Contractor shall order, purchase, transport, coordinate delivery, accept delivery, confirm the quantity and quality received, prepare storage area(s), store, handle, protect, move, relocate, remove and dispose excess of all materials used to accomplish the Work. Materials shall be delivered to the site of the work only during working hours, as defined in Section 6-7.2, and shall be accompanied by bills of lading that shall clearly state for each delivery: the name of the Contractor as consignee, the project name and number, address of delivery and name of consignor and a description of the material(s) shipped. Prior to storage of any materials which have been shipped to or by the Contractor to any location within the Agency's boundaries the Contractor shall provide the Engineer a copy of lease agreements for each property where such materials are stored. The lease agreement shall clearly state the term of the lease, the description of materials allowed to be stored and shall provide for the removal of the materials and restoration of the storage site within the time allowed for the Work. All such storage shall conform to all laws and ordinances that may pertain to the materials stored and to preparation of the storage site and the location of the site on which the materials are stored. Loss, damage or deterioration of all stored materials shall be the Contractor's responsibility. Conformance to the requirements of this section, both within and outside the limits of work are a part of the Work. ('\ •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 67 of 101 Pages The Engineer shall have the right to verify the suitability of materials and their proper storage at any time during the Work. SECTION 5 -UTILITIES 5-1 LOCATION. The Agency and affected utility companies have, by a search of known records, endeavored to locate and indicate on the Plans, all utilities which exist within the limits of the work. However, the accuracy and/or completeness of the nature, size and/or location of utilities indicated on the Plans is not guaranteed. Where underground main distribution conduits such as water, gas, sewer, electric power, telephone, or cable television are shown on the Plans, the Contractor shall assume that every property parcel will be served by a service connection for each type of utility. As provided in Section 4216 of the California Government Code, at least 2 working days prior to commencing any excavation, the Contractor shall contact the regional notification center (Underground Service Alert of Southern California) and obtain an inquiry identification number. The California Department of Transportation is not required by Section 4216 to become a member of the regional notification center. The Contractor shall contact it for location of its subsurface installations. The Contractor shall determine the location and depth of all utilities, including service connections, which have been marked by the respective owners and which may affect or be affected by its operations. If no pay item is provided in the Contract for this work, full compensation for such work shall be considered as included in the prices bid for other items of work. 5-2 PROTECTION. The Contractor shall not interrupt the service function or disturb the support of any utility without authority from the owner or order from the Agency. All valves, switches, vaults, and meters shall be maintained readily accessible for emergency shutoff. Where protection is required to ensure support of utilities located as shown on the Plans or in accordance with Section 5-1, the Contractor shall, unless otherwise provided, furnish and place the necessary protection at its expense. Upon learning of the existence and location of any utility omitted from or shown incorrectly on the Plans, the Contractor shall immediately notify the Engineer in writing. When authorized by the Engineer, support or protection of the utility will be paid for as provided in Section 3-2.2.3 or 3-3. The Contractor shall immediately notify the Engineer and the utility owner if any utility is disturbed or damaged. The Contractor shall bear the costs of repair or replacement of any utility damaged if located as noted in Section 5-1. When placing concrete around or contiguous to any non-metallic utility installation, the Contractor shall at its expense: 1. Furnish and install a 2 inch cushion of expansion joint material or other similar resilient material; or 2. Provide a sleeve or other opening which will result in a 2 inch minimum-clear annular space between the concrete and the utility; or 3. Provide other acceptable means to prevent embedment in or bonding to the concrete. l'\ •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 68 of 101 Pages Where concrete is used for backfill or for structures which would result in embedment, or partial embedment, of a metallic utility installation; or where the coating, bedding or other cathodic protection system is exposed or damaged by the Contractor's operations, the Contractor shall notify the Engineer and arrange to secure the advice of the affected utility owner regarding the procedures required to maintain or restore the integrity of the system. 5-3 REMOVAL. Unless otherwise specified, the Contractor shall remove all interfering portions of utilities shown on the Plans or indicated in the Bid documents as "abandoned" or "to be abandoned in place". Before starting removal operations, the Contractor shall ascertain from the Agency whether the abandonment is complete, and the costs involved in the removal and disposal shall be included in the Bid for the items of work necessitating such removals. 5-4 RELOCATION. When feasible, the owners responsible for utilities within the area affected by the Work will complete their necessary installations, relocations, repairs, or replacements before commencement of work by the Contractor. When the Plans or Specifications indicate that a utility installation is to be relocated, altered, or constructed by others, the Agency will conduct all negotiations with the owners and work will be done at no cost to the Contractor, except for manhole frame and cover sets to be brought to grade. Utilities which are relocated in order to avoid interference shall be protected in their position and the cost of such protection shall be included in the Bid for the items of work necessitating such relocation. After award of the Contract, portions of utilities which are found to interfere with the Work will be relocated, altered or reconstructed by the owners, or the Engineer may order changes in the Work to avoid interference. Such changes will be paid for in accordance with Section 3-2. When the Plans or Specifications provide for the Contractor to alter, relocate, or reconstruct a utility, all costs for such work shall be included in the Bid for the items of work necessitating such work. Temporary or permanent relocation or alteration of utilities requested by the Contractor for its convenience shall be its responsibility and it shall make all arrangements and bear all costs. The utility owner will relocate service connections as necessary within the limits of the Work or within temporary construction or slope easements. When directed by the Engineer, the Contractor shall arrange for the relocation of service connections as necessary between the meter and property line, or between a meter and the limits of temporary construction or slope easements. The relocation of such service connections will be paid for in accordance with provisions of Section 3-3. Payment will include the restoration of all existing improvements which may be affected thereby. The Contractor may agree with the owner of any utility to disconnect and reconnect interfering service connections. The Agency will not be involved in any such agreement. In conformance with Section 5-6 the Contractor shall coordinate the work with utility agencies and companies. Prior to the installation of any and all utility structures within the limits of work by any utility agency or company, or its contractor, the Contractor shall place all curb or curb and gutter that is a part of the work and adjacent to the location where such utility structures are shown on the plans and are noted as being located, relocated or are otherwise shown as installed by others. In order to minimize delays to the Contractor caused by the failure of other parties to relocate utilities that interfere with the construction, the Contractor, upon the Engineer's approval, may be permitted to temporarily omit the portion of work affected by the utility. If such temporary omission is approved by the Engineer the Contractor shall place survey or other physical control markers sufficient to locate the curb or curb and gutter to the satisfaction of the utility agency or company. Such temporary omission shall be for the Contractor's convenience and no additional compensation will be allowed therefore or for additional work, materials or delay associated with the temporary omission. The portion thus omitted shall be constructed by the Contractor immediately following the relocation of the utility involved unless otherwise directed by the Engineer. l' •+' Revised 2/27/18 PWS 18-12 HRAN-Contract No. 3896 Page 69 of 101 Pages 5-5 DELAYS. The Contractor shall notify the Engineer of its construction schedule insofar as it affects the protection, removal, or relocation of utilities. Said notification shall be included as a part of the construction schedule required in Section 6-1. The Contractor shall notify the Engineer in writing of any subsequent changes in the construction schedule which will affect the time available for protection, removal, or relocation of utilities. The Contractor will not be entitled to damages or additional payment for delays attributable to utility relocations or alterations if correctly located, noted, and completed in accordance with Section 5-1. The Contractor may be given an extension of time for unforeseen delays attributable to unreasonably protracted interference by utilities in performing work correctly shown on the Plans. The Agency will assume responsibility for the timely removal, relocation, or protection of existing main or trunkline utility facilities within the area affected by the Work if such utilities are not identified in the Contract Documents. The Contractor will not be assessed liquidated damages for any delay caused by failure of Agency to provide for the timely removal, relocation, or protection of such existing facilities. If the Contractor sustains loss due to delays attributable to interferences, relocations, or alterations not covered by Section 5-1, which could not have been avoided by the judicious handling of forces, equipment, or plant, there shall be paid to the Contractor such amount as the Engineer may find to be fair and reasonable compensation for such part of the Contractor's actual loss as was unavoidable and the Contractor may be granted an extension of time. 5-6 COOPERATION. When necessary, the Contractor shall so conduct its operations as to permit access to the Work site and provide time for utility work to be accomplished during the progress of the Work. SECTION 6 -PROSECUTION, PROGRESS, AND ACCEPTANCE OF THE WORK 6-1 CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK. Except as otherwise provided herein and unless otherwise prohibited by permits from other agencies as may be required by law the Contractor shall begin work within seven (7) calendar days after receipt of the "Notice to Proceed". 6-1.1 Pre-Construction Meeting. After, or upon, notification of contract award, the Engineer will set the time and location for the Preconstruction Meeting. Attendance of the Contractor's management personnel responsible for the management, administration, and execution of the project is mandatory for the meeting to be convened. Failure of the Contractor to have the Contractor's responsible project personnel attend the Preconstruction Meeting will be grounds for default by Contractor per Section 6-4. No separate payment will be made for the Contractor's attendance at the meeting. The notice to proceed will only be issued on or after the completion of the preconstruction meeting. 6-1.1.1 Baseline Construction Schedule Submittal. The Contractor shall submit the Baseline Construction Schedule per the submittal requirements of Section 2-5.3. The submittal of the Baseline Construction Schedule shall include each item and element of Sections 6-1.2 through 6-1.2.9 and shall be on hard (paper) copy and electronic media conforming to Section 6-1.3.3 Electronic Media. l' •+; Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 70 of 101 Pages 6-1.2 Preparation and Review of the Baseline Construction Schedule. The Contractor shall prepare the Baseline Construction Schedule as a Critical Path Method (CPM) Schedule in the precedence diagram method (activity-on-node) format. The Baseline Construction Schedule shall depict a workable plan showing the sequence, duration, and interdependence of all activities required to represent the complete performance of all project work as well as periods where work is precluded. The Baseline Construction Schedule shall begin with the projected date of issuance of the notice to proceed and conclude with the date of final completion per the contract duration. The Baseline Construction Schedule shall include detail of all project phasing, staging, and sequencing, including all milestones necessary to define beginning and ending of each phase or stage. 6-1.2.1 Time-Scaled Network Diagram. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a complete time-scaled network diagram showing all of the activities, logic relationships, and milestones comprising the schedule. 6-1.2.2 Tabular Listing. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a tabular listing of all of the activities, showing for each activity the identification number, the description, the duration, the early start, the early finish, the late start, the late finish, the total float, and all predecessor and successor activities for the activity described. 6-1.2.3 Bar Chart. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a chart showing individual tasks and their durations arranged with the tasks on the vertical axis and duration on the horizontal axis. The bar chart shall use differing texture patterns or distinctive line types to show the critical path. 6-1.2.5 Schedule Activities. Except for submittal activities, activity durations shall not be shorter than 1 working day nor longer than 15 working days, unless specifically and individually allowed by the Engineer. The Baseline Construction Schedule shall include between 100 and 500 activities, including submittals, interfaces between utility companies and other agencies, project milestones and equipment and material deliveries. The number of activities will be sufficient, in the judgment of the Engineer, to communicate the Contractor's plan for project execution, to accurately describe the project work, and to allow monitoring and evaluation of progress and of time impacts. Each activity's description shall accurately define the work planned for the activity and each activity shall have recognizable beginning and end points. 6-1.2.6 Float. Float or slack time within the schedule is available without charge or compensation to whatever party or contingency first exhausts it. 6-1.2. 7 Restraints to Activities. Any submittals, utility interfaces, or any furnishing of Agency supplied materials, equipment, or services, which may impact any activity's construction shall be shown as a restraint to those activities. Time periods to accommodate the review and correction of submittals shall be included in the schedule. 6-1.2.8 Late Completion. A Baseline Construction Schedule showing a project duration longer than the specified contract duration will not be acceptable and will be grounds for determination of default by Contractor, per Section 6-4. 6-1.2.9 Early Completion. The Baseline Construction Schedule will show the Contractor's plan to support and maintain the project for the entire contractual time span of the project. Should the Contractor propose a project duration shorter than contract duration, a complete Baseline Construction Schedule must be submitted, reflecting the shorter duration, in complete accordance with all schedule requirements of Section 6-1. The Engineer may choose to accept the Contractor's proposal of a project duration shorter than the duration specified; provided the Agency is satisfied the shortened Baseline Construction Schedule is reasonable and the Agency and all other entities, public l' • ., Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 71 of 101 Pages and private, which interface with the project are able to support the provisions of the shortened Baseline Construction Schedule. The Agency's acceptance of a shortened duration project will be confirmed through the execution of a contract change order revising the project duration and implementing all contractual requirements including liquidated damages in accordance with the revised duration. 6-1.2.10 Engineer's Review. The Construction Schedule is subject to the review of the Engineer. The Engineer's determination that the Baseline Construction Schedule proposed by the Contractor complies with the requirements of these supplemental provisions shall be a condition precedent to issuance of the Notice to Proceed by the Engineer. If the Engineer determines that the Construction Schedule does not meet the requirements of these specifications the Contractor shall correct the Construction Schedule to meet these specifications and resubmit it to the Engineer. Failure of the Contractor to obtain the Engineer's determination that the initial Construction Schedule proposed by the Contractor complies with the requirements of these supplemental provisions within thirty (30) working days after the date of the preconstruction meeting shall be grounds for termination of the contract per Section 6-4. Days used by the Engineer to review the initial Construction Schedule will not be included in the 30 working days. The Engineer will review and return to the Contractor, with any comments, the Construction Schedule within 15 working days of submittal. 6-1.2.10.1 "Accepted." The Contractor may proceed with the project work upon issuance of the Notice to Proceed, and will receive payment for the schedule in accordance with Section 6-1.8.1. 6-1.2.10.2 "Accepted with Comments." The Contractor may proceed with the project work upon issuance of the Notice to Proceed. The Contractor must resubmit the schedule incorporating the comments prior to receipt of payment per Section 6-1.8.1. 6-1.2.10.3 "Not Accepted." The Contractor must resubmit the schedule incorporating the corrections and changes of the comments prior to receipt of payment per Section 6-1.8.1. The Notice to Proceed will not be issued by the Engineer if the changes of the comments are not submitted as required hereinbefore and marked "Accepted" or "Accepted with Comments" by the Engineer. The Contractor, at the sole option of the Engineer, may be considered as having defaulted the contract under the provisions of Section 6-4 DEFAULT BY CONTRACTOR if the changes of the comments are not submitted as required herein before and marked "Accepted" by the Engineer. 6-1.3 Preparation of Schedule Updates and Revisions. The Contractor shall meet with the Engineer during the last week of each month to agree upon each activity's schedule status and shall submit monthly updates of the Baseline Construction Schedule confirming the agreements no later than the fifth working day of the following month. The monthly update will be submitted on hard (paper) copy and electronic media conforming to Section 6-1.3.3 Electronic Media per the submittal requirements of Section 2-5.3 and will include each item and element of Sections 6-1.2 through 6- 1.2.9 and 6-1.3.1 through 6-1.3.7. 6-1.3.1 Actual Activity Dates. The actual dates each activity was started and/or completed during the month. After first reporting an actual date, the Contractor shall not change that actual date in later updates without specific notification to the Engineer with the update. 6-1.3.2 Activity Percent Complete. For each activity underway at the end of the month, the Contractor shall report the percentage determined by the Engineer as complete for the activity. 6-1.3.3 Electronic Media. The schedule data disk shall be a CD-ROM, labeled with the project name and number, the Contractor's name and the date of preparation of the schedule data disk. The l' •+r' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 72 of 101 Pages schedule data disk shall be readable by the software specified in Section 6-1.2.4 "Schedule Software" and shall be free of file locking, encryption or any other protocol that would impede full access of all data stored on it. 6-1.3.4 List of Changes. A list of all changes made to the activities or to the interconnecting logic, with an explanation for each change. 6-1.3.5 Change Orders. Each monthly update will include the addition of the network revisions reflecting the change orders approved in the previous month. The network revisions will be as agreed upon during the review and acceptance of the Contractor's change orders. 6-1.3.6 Bar Chart. Each monthly update will include a bar chart showing individual tasks and their durations arranged with the tasks on the vertical axis and duration on the horizontal axis. The bar chart shall use differing texture patterns or distinctive line types to show the critical path. 6-1.4 Engineer's Review of Updated Construction Schedule. The Engineer will review and return the Updated Construction Schedule to the Contractor, with any comments, within 5 working days of submittal. The Updated Construction Schedule will be returned marked as per Sections 6- 1.4.1 through 6-1.4.3. Any Updated Construction Schedule marked "Accepted with Comments" or "Not Accepted" by the Engineer will be returned to the Contractor for correction. Upon resubmittal the Engineer will review and return the resubmitted Updated Construction Schedule to the Contractor, with any comments, within 5 working days. Failure of the Contractor to submit a monthly updated construction schedule will invoke the same consequences as the Engineer returning a monthly updated construction schedule marked "Not Accepted". 6-1.4.1 "Accepted." The Contractor may proceed with the project work, and will receive payment for the schedule in accordance with Section 6-1.8.2. 6-1.4.2 "Accepted with Comments." The Contractor may proceed with the project work. The Contractor must resubmit the Updated Construction Schedule to the Engineer incorporating the corrections and changes noted in the Engineer's comments prior to receipt of payment per Section 6-1.8.2. 6-1.4.3 "Not Accepted." The Contractor must resubmit the Updated Construction Schedule to the Engineer incorporating the corrections and changes noted in the Engineer's comments prior to receipt of payment per Section 6-1.8.2. The Contractor, at the sole option of the Engineer, may be considered as having defaulted the contract under the provisions of Section 6-4 DEFAULT BY CONTRACTOR if the changes of the comments are not submitted and marked "Accepted" by the Engineer before the last day of the month in which the Updated Construction Schedule is due. If the Contractor fails to submit the corrected Updated Construction Schedule as required herein the Contractor may elect to proceed with the project at its own risk. Should the Contractor elect not to proceed with the project, any resulting delay, impact, or disruption to the project will be the Contractor's responsibility. 6-1.5 Late Completion or Milestone Dates. Should the Schedule Update indicate a completion or contractually required milestone date later than the properly adjusted contract or milestone duration, the Agency may withhold Liquidated Damages for the number of days late. Should a subsequent "Accepted" Schedule Update remove all or a portion of the delay, all or the allocated portion of the previously held Liquidated Damages shall be released in the monthly payment to the Contractor immediately following the "Accepted" schedule. 6-1.6 Interim Revisions. Should the actual or projected progress of the work become substantially different from that depicted in the Project Schedule, independently of and prior to the l' •+f Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 73 of 101 Pages next monthly update, the Contractor will submit a revised Baseline Construction Schedule, with a list and explanation of each change made to the schedule. The Revised Construction Schedule will be submitted per the submittal requirements of Section 2-5.3 and per the schedule review and acceptance requirements of Section 6-1, including but not limited to the acceptance and payment provisions. As used in this section "substantially different" means a time variance greater than 5 percent of the number of days of duration for the project. 6-1.7 Final Schedule Update. The Contractor shall prepare and submit a final schedule update when one hundred percent of the construction work is completed. The Contractor's Final Schedule Update must accurately represent the actual dates for all activities. The final schedule update shall be prepared and reviewed per Sections 6-1.3 Preparation of Schedule Updates and Revisions and 6-1. 4 Engineer's Review of Updated Construction Schedule. Acceptance of the final schedule update is required for completion of the project and release of any and all funds retained per Section 9-3.2. 6-1.8 Measurement and Payment of Construction Schedule. The Contractor's preparation, revision and maintenance of the Construction Schedule are incidental to the work and no separate payment will be made therefore. 6-2 PROSECUTION OF WORK. To minimize public inconvenience and possible hazard and to restore street and other work areas to their original condition and state of usefulness as soon as practicable, the Contractor shall diligently prosecute the Work to completion. If the Engineer determines that the Contractor is failing to prosecute the Work to the proper extent, the Contractor shall, upon orders from the Engineer, immediately take steps to remedy the situation. All costs of prosecuting the Work as described herein shall be included in the Contractor's Bid. Should the Contractor fail to take the necessary steps to fully accomplish said purposes, after orders of the Engineer, the Engineer may suspend the work in whole or part, until the Contractor takes said steps. As soon as possible under the provisions of the Specifications, the Contractor shall backfill all excavations and restore to usefulness all improvements existing prior to the start of the Work. If Work is suspended through no fault of the Agency, all expenses and losses incurred by the Contractor during such suspensions shall be borne by the Contractor. If the Contractor fails to properly provide for public safety, traffic, and protection of the Work during periods of suspension, the Agency may elect to do so, and deduct the cost thereof from monies due the Contractor. Such actions will not relieve the Contractor from liability. 6-2.1 Order of Work. The work to be done shall consist of furnishing all labor, equipment and materials, and performing all operations necessary to complete the Project Work as shown in the contract documents and as specified in the Specifications. 6-2.3 Project Meetings. The Engineer will establish the time and location of Project Meetings whenever necessary. The Contractor's Representative shall attend each Project Meeting. The Project Representative shall be the individual determined under Section 7-6, "The Contractor's Representative". No separate payment for attendance of the Contractor, the Contractor's Representative or any other employee or subcontractor or subcontractor's employee at these meetings will be made. 6-3 SUSPENSION OF WORK. 6-3.1 General. The Work may be suspended in whole or in part when determined by the Engineer that the suspension is necessary in the interest of the Agency. The Contractor shall comply ,, •,;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 74 of 101 Pages immediately with any written order of the Engineer. Such suspension shall be without liability to the Contractor on the part of the Agency except as otherwise specified in Section 6-6.3. 6-3.2 Archaeological and Paleontological Discoveries. If discovery is made of items of archaeological or paleontological interest, the Contractor shall immediately cease excavation in the area of discovery and shall not continue until ordered by the Engineer. When resumed, excavation operations within the area of discovery shall be as directed by the Engineer. Discoveries which may be encountered may include, but not be limited to, dwelling sites, stone implements or other artifacts, animal bones, human bones, and fossils. The Contractor shall be entitled to an extension of time and compensation in accordance with the provisions of Section 6-6. 6-4 DEFAULT BY CONTRACTOR. If the Contractor fails to begin delivery of material and equipment, to commence the Work within the time specified, to maintain the rate of delivery of material, to execute the Work in the manner and at such locations as specified, or fails to maintain the Work schedule which will insure the Agency's interest, or, if the Contractor is not carrying out the intent of the Contract, the Agency may serve written notice upon the Contractor and the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. The Contract may be canceled by the Board without liability for damage, when in the Board's opinion the Contractor is not complying in good faith, has become insolvent, or has assigned or subcontracted any part of the Work without the Board's consent. In the event of such cancellation, the Contractor will be paid the actual amount due based on Contract Unit Prices or lump sums bid and the quantity of the Work completed at the time of cancellation, less damages caused to the Agency by acts of the Contractor. The Contractor, in having tendered a Bid, shall be deemed to have waived any and all claims for damages because of cancellation of Contract for any such reason. If the Agency declares the Contract canceled for any of the above reasons, written notice to that effect shall be served upon the Surety. The Surety shall, within five (5) days, assume control and perform the Work as successor to the Contractor. If the Surety assumes any part of the Work, it shall take the Contractor's place in all respects for that part, and shall be paid by the Agency for all work performed by it in accordance with the Contract. If the Surety assumes the entire Contract, all money due the Contractor at the time of its default shall be payable to the Surety as the Work progresses, subject to the terms of the Contract. If the Surety does not assume control and perform the Work within 5 days after receiving notice of cancellation, or fails to continue to comply, the Agency may exclude the Surety from the premises. The Agency may then take possession of all material and equipment and complete the Work by Agency forces, by letting the unfinished Work to another Contractor, or by a combination of such methods. In any event, the cost of completing the Work shall be charged against the Contractor and its Surety and may be deducted from any money due or becoming due from the Agency. If the sums due under the Contract are insufficient for completion, the Contractor or Surety shall pay to the Agency within 5 days after the completion, all costs in excess of the sums due. The provisions of this section shall be in addition to all other rights and remedies available to the Agency under law. 6-5 TERMINATION OF CONTRACT. The Board may terminate the Contract at its own discretion or when conditions encountered during the Work make it impossible or impracticable to proceed, or when the Agency is prevented from proceeding with the Contract by act of God, by law, or by official action of a public authority. l' •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 75 of 101 Pages 6-6 DELAYS AND EXTENSIONS OF TIME. 6-6.1 General. If delays are caused by unforeseen events beyond the control of the Contractor, such delays will entitle the Contractor to an extension of time as provided herein, but the Contractor will not be entitled to damages or additional payment due to such delays, except as provided in 6-6.3. Such unforeseen events may include: war, government regulations, labor disputes, strikes, fires, floods, adverse weather or elements necessitating cessation of work, inability to obtain materials, labor or equipment, required extra work, or other specific events as may be further described in the Specifications. No extension of time will be granted for a delay caused by the Contractor's inability to obtain materials unless the Contractor furnishes to the Engineer documentary proof. The proof must be provided in a timely manner in accordance with the sequence of the Contractor's operations and the approved construction schedule. If delays beyond the Contractor's control are caused by events other than those mentioned above, the Engineer may deem an extension of time to be in the best interests of the Agency. The Contractor will not be entitled to damages or additional payment due to such delays, except as provided in Section 6-6.3. If delays beyond the Contractor's control are caused solely by action or inaction by the Agency, such delays will entitle the Contractor to an extension of time as provided in Section 6-6.2. 6-6.2 Extensions of Time. Extensions of time, when granted, will be based upon the effect of delays to the Work. They will not be granted for noncontrolling delays to minor portions of the Work unless it can be shown that such delays did or will delay the progress of the Work. 6-6.3 Payment for Delays to Contractor. The Contractor will be compensated for damages incurred due to delays for which the Agency is responsible. Such actual costs will be determined by the Engineer. The Agency will not be liable for damages which the Contractor could have avoided by any reasonable means, such as judicious handling of forces, equipment, or plant. The determination of what damages the Contractor could have avoided will be made by the Engineer. 6-6.4 Written Notice and Report. The Contractor shall provide written notice to the Engineer within two hours of the beginning of any period that the Contractor has placed any workers or equipment on standby for any reason that the Contractor has determined to be caused by the Agency or by any organization that the Agency may otherwise be obligated by. The Contractor shall provide continuing daily written notice to the Engineer, each working day, throughout the duration of such period of delay. The initial and continuing written notices shall include the classification of each workman and supervisor and the make and model of each piece of equipment placed on standby, the cumulative duration of the standby, the Contractor's opinion of the cause of the delay and a cogent explanation of why the Contractor could not avoid the delay by reasonable means. Should the Contractor fail to provide the notice(s) required by this section the Contractor agrees that no delay has occurred and that it will not submit any claim(s) therefore. l' •+' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 76 of 101 Pages 6-7 TIME OF COMPLETION. 6-7.1 General. The Contractor shall complete the Work within the time set forth in the Contract. The Contractor shall complete each portion of the Work within such time as set forth in the Contract for such portion. The time of completion of the Contract shall be expressed in working days. The Contractor shall diligently prosecute the work to completion within thirty five (35) working days after the starting date specified in the Notice to Proceed. 6-7.2 Working Day. A working day is any day within the period between the start of the Contract time as defined in Section 6-1 and the date provided for completion, or upon field acceptance by the Engineer for all work provided for in the Contract, whichever occurs first, other than: 1. Saturday 2. Sunday 3. any day designated as a holiday by the Agency, 4. any other day designated as a holiday in a Master Labor Agreement entered into by the Contractor or on behalf of the Contractor as an eligible member of a contractor association, 5. any day the Contractor is prevented from working at the beginning of the workday for cause as defined in Section 6-6.1, 6. any day the Contractor is prevented from working during the first 5 hours with at least 60 percent of the normal work force for cause as defined in Section 6-6.1. Unless superseded by the above paragraphs or the approved Traffic Control Plan, the hours of work shall be between the hours of 7:00 a.m. and 4:00 p.m. The Contractor shall obtain the written approval of the Engineer if the Contractor desires to work outside said hours, days, and/or holidays. This written permission must be obtained at least 48 hours prior to such work The Engineer may approve work outside the hours and/or days stated herein when, in his/her sole opinion, such work conducted by the Contractor is beneficial to the best interests of the Agency. The Contractor shall pay the inspection costs of such work. The Contractor shall incorporate the dates, areas and types of work prohibited in this section in the Construction Schedule required by Section 6.1. No additional payment, adjustment of bid prices or adjustment of contract time of completion will be allowed as a consequence of the prohibition of work being performed within the dates, areas and/or types of work prohibited in this section. 6-7.3 Contract Time Accounting. The Engineer will make a daily determination of each working day to be charged against the Contract time. These determinations will be discussed and the Contractor will be furnished a periodic statement showing allowable number of working days of Contract time, as adjusted, at the beginning of the reporting period. The statement will also indicate the number of working days charged during the reporting period and the number of working days of Contract time remaining. If the Contractor does not agree with the statement, it shall file a written protest within 15 days after receipt, setting forth the facts of the protest. Otherwise, the statement will be deemed to have been accepted. 6-8 COMPLETION, ACCEPTANCE, AND WARRANTY. The Work will be inspected by the Engineer for acceptance upon receipt of the Contractor's written assertion that the Work has been completed. The Engineer will not accept the Work or any portion of the Work before all of the Work is completed and all outstanding deficiencies that may exist are corrected by the Contractor and the Engineer is satisfied that all the materials and workmanship, and all other features of the Work, meet the requirements of all of the specifications for the Work. Use, temporary, interim or permanent, of all, or portions of, the Work does not constitute acceptance of the Work. If, in the Engineer's judgment, the l' •+f Revised 2/27/18 PWS 18-12 HRAN-Contract No. 3896 Page 77 of 101 Pages Work has been completed and is ready for acceptance the Engineer will so certify to the Board. Upon such certification by the Engineer the Board may accept the completed Work. Upon the Board's acceptance of the Work the Engineer will cause a "Notice of Completion" to be filed in the office of the San Diego County Recorder. The date of recordation shall be the date of completion of the Work. All work shall be warranted for one (1) year after recordation of the "Notice of Completion" and any faulty work or materials discovered during the warranty period shall be repaired or replaced by the Contractor, at its expense. Twenty-five percent of the faithful performance bond shall be retained as a warranty bond for the one year warranty period. The Contractor shall replace or repair any such defective work in a manner satisfactory to the Engineer, after notice to do so from the Engineer, and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the Agency may perform this work and the Contractor's sureties shall be liable for the cost thereof. 6-9 LIQUIDATED DAMAGES. Failure of the Contractor to complete the Work within the time allowed will result in damages being sustained by the Agency. For each consecutive calendar day in excess of the time specified for completion of Work, as adjusted in accordance with Section 6-6, the Contractor shall pay the Agency, or have withheld monies due it, the sum of five hundred dollars ($500) Such sum is liquidated damages and shall not be construed as a penalty, and may be deducted from payments due the Contractor if such delay occurs. Execution of the Contract shall constitute agreement by the Agency and Contractor that five hundred dollars ($500) per day is the minimum value of costs and actual damages caused by the Contractor to complete the Work within the allotted time. Any progress payments made after the specified completion date shall not constitute a waiver of this paragraph or of any damages. 6-10 USE OF IMPROVEMENT DURING CONSTRUCTION. The Agency reserves the right to take over and utilize all or part of any completed facility or appurtenance. The Contractor will be notified in writing in advance of such action. Such action by the Agency will relieve the Contractor of responsibility for injury or damage to said completed portions of the improvement resulting from use by public traffic or from the action of the elements or from any other cause, except Contractor operations or negligence. The Contractor will not be required to reclean such portions of the improvement before field acceptance, except for cleanup made necessary by its operations. Nothing in this section shall be construed as relieving the Contractor from full responsibility for correcting defective work or materials. In the event the Agency exercises its right to place into service and utilize all or part of any completed facility or appurtenance, the Agency will assume the responsibility and liability for injury to persons or property resulting from the utilization of the facility or appurtenance so placed into service, except for any such injury to persons or property caused by any willful or negligent act or omission by the Contractor, Subcontractor, their officers, employees, or agents. SECTION 7 -RESPONSIBILITIES OF THE CONTRACTOR 7-1 CONTRACTOR'S EQUIPMENT AND FACILITIES. The Contractor shall furnish and maintain in good condition all equipment and facilities as required for the proper execution and inspection of the Work. Such equipment and facilities shall meet all requirements of applicable ordinances and laws. l' •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 78 of 101 Pages 7-2 LABOR. 7-2.1 General. Only competent workers shall be employed on the Work. Any person employed who is found to be incompetent, intemperate, troublesome, disorderly, or otherwise objectionable, or who fails or refuses to perform work properly and acceptably, shall be immediately removed from the Work by the Contractor and not be reemployed on the Work. 7-2.2 Laws. The Contractor, its agents, and employees shall be bound by and comply with applicable provisions of the Labor Code and Federal, State, and local laws related to labor. The Contractor shall strictly adhere to the provisions of the Labor Code regarding minimum wages; the 8-hour day and 40-hour week; overtime; Saturday, Sunday, and holiday work; and nondiscrimination because of race, color, national origin, sex, or religion. The Contractor shall forfeit to the Agency the penalties prescribed in the Labor Code for violations. 7-3 LIABILITY INSURANCE. Insurance shall be required as specified in section 10 of the Public Works Contract. The cost of this insurance shall be included in the Contractor's Bid. 7-4 WORKERS' COMPENSATION INSURANCE. Before execution of the Contract by the Board, the Contractor shall file with the Engineer the following signed certification: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract." The Contractor shall also comply with Section 3800 of the Labor Code by securing, paying for, and maintaining in full force and effect for the duration of the contract, complete Workers' Compensation Insurance, and shall furnish a Certificate of Insurance to the Engineer before execution of the Contract. The Agency, its officers, or employees, will not be responsible for any claims in law or equity occasioned by failure of the Contractor to comply with this paragraph. All compensation insurance policies shall bear an endorsement or shall have attached a rider whereby it is provided that, in the event of expiration or proposed cancellation of such policies for any reason whatsoever, the Agency shall be notified by registered mail not less than 30 days before expiration or cancellation is effective. All insurance is to be placed with insurers that are admitted and authorized to conduct business in the state of California and are listed in the official publication of the Department of Insurance of the State of California. Policies issued by the State Compensation Fund meet the requirement for workers' compensation insurance. 7-5 PERMITS. Except as specified herein the Contractor will obtain, at no cost to the Contractor all City of Carlsbad encroachment, right-of-way, grading and building permits necessary to perform work for this contract on Agency property, streets, or other rights-of-way. Contractor shall not begin work until all permits incidental to the work are obtained. The Contractor shall obtain and pay for all permits for the disposal of all materials removed from the project. The cost of said permit(s) shall be included in the price bid for the appropriate bid item and no additional compensation will be allowed therefore. The Contractor shall obtain and pay for all costs incurred for permits necessitated by its operations such as, but not limited to, those permits required for night work, overload, blasting, and ,, •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 79 of 101 Pages demolition. For private contracts, the Contractor shall obtain all permits incidental to the Work or made necessary by its operations, and pay all costs incurred by the permit requirements. The Contractor shall pay all business taxes or license fees that are required for the work. 7-6 THE CONTRACTOR'S REPRESENTATIVE. Before starting work, the Contractor shall designate in writing a representative who shall have complete authority to act for it. An alternative representative may be designated as well. The representative or alternate shall be present at the Work site whenever work is in progress or whenever actions of the elements necessitate its presence to take measures necessary to protect the Work, persons, or property. Any order or communication given to this representative shall be deemed delivered to the Contractor. A joint venture shall designate only one representative and alternate. In the absence of the Contractor or its representative, instructions or directions may be given by the Engineer to the superintendent or person in charge of the specific work to which the order applies. Such order shall be complied with promptly and referred to the Contractor or its representative. In order to communicate with the Agency, the Contractor's representative, superintendent, or person in charge of specific work shall be able to speak, read, and write the English language. 7-7 COOPERATION AND COLLATERAL WORK. The Contractor shall be responsible for ascertaining the nature and extent of any simultaneous, collateral, and essential work by others. The Agency, its workers and contractors and others, shall have the right to operate within or adjacent to the Work site during the performance of such work. The Agency, the Contractor, and each of such workers, contractors and others, shall coordinate their operations and cooperate to minimize interference. The Contractor shall include in its Bid all costs involved as a result of coordinating its work with others. The Contractor will not be entitled to additional compensation from the Agency for damages resulting from such simultaneous, collateral, and essential work. If necessary to avoid or minimize such damage or delay, the Contractor shall redeploy its work force to other parts of the Work. Should the Contractor be delayed by the Agency, and such delay could not have been reasonably foreseen or prevented by the Contractor, the Engineer will determine the extent of the delay, the effect on the project, and any extension of time. 7-7.1 Coordination. The Contractor shall coordinate and cooperate with all the utility companies during the relocation or construction of their lines. The Contractor may be granted a time extension if, in the opinion of the Engineer, a delay is caused by the utility company. No additional compensation will be made to the Contractor for any such delay. 7-8 PROJECT SITE MAINTENANCE. 7-8.1 Cleanup and Dust Control. Throughout all phases of construction, including suspension of work, and until the final acceptance, the Contractor shall keep the site clean and free from rubbish and debris. The Contractor shall also abate dust nuisance by cleaning, sweeping and sprinkling with water, or other means as necessary. The use of water resulting in mud on public streets will not be permitted as a substitute for sweeping or other methods. Materials and equipment shall be removed from the site as soon as they are no longer necessary. Before the final inspection, the site shall be cleared of equipment, unused materials, and rubbish so as to present a satisfactory clean and neat appearance. All cleanup costs shall be included in the Contractor's Bid. l' •+;' Revised 2/27/18 PWS 18-12 HRAN-Contract No. 3896 Page 80 of 101 Pages Care shall be taken to prevent spillage on haul routes. Any such spillage shall be removed immediately and the area cleaned. Excess excavation material from catch basins or similar structures shall be removed from the site immediately. Sufficient material may remain for use as backfill if permitted by the Specifications. Forms and form lumber shall be removed from the site as soon as practicable after stripping. Failure of the Contractor to comply with the Engineer's cleanup orders may result in an order to suspend work until the condition is corrected. No additional compensation will be allowed as a result of such suspension. Cleanup and dust control required herein shall also be executed on weekends and other non-working days when needed to preserve the health safety or welfare of the public. The Contractor shall conduct effective cleanup and dust control throughout the duration of the Contract. The Engineer may require increased levels of cleanup and dust control that, in his/her sole discretion, are necessary to preserve the health, safety and welfare of the public. Cleanup and dust control shall be considered incidental to the items of work that they are associated with and no additional payment will be made therefore. 7-8.2 Air Pollution Control. The Contractor shall not discharge smoke, dust, or any other air contaminants into the atmosphere in such quantity as will violate the regulations of any legally constituted authority. 7-8.3 Vermin Control. At the time of acceptance, structures entirely constructed under the Contract shall be free of rodents, insects, vermin, and pests. Necessary extermination work shall be arranged and paid for by the Contractor as part of the Work within the Contract time, and shall be performed by a licensed exterminator in accordance with requirements of governing authorities. The Contractor shall be liable for injury to persons or property and responsible for the elimination of offensive odors resulting from extermination operations. 7-8.4 Sanitation. The Contractor shall provide and maintain enclosed toilets for the use of employees engaged in the Work. These accommodations shall be maintained in a neat and sanitary condition. They shall also comply with all applicable laws, ordinances, and regulations pertaining to public health and sanitation of dwellings and camps. Wastewater shall not be interrupted. Should the Contractor disrupt existing sewer facilities, sewage shall be conveyed in closed conduits and disposed of in a sanitary sewer system. Sewage shall not be permitted to flow in trenches or be covered by backfill. 7-8.5 Temporary Light, Power, and Water. The Contractor shall furnish, install, maintain, and remove all temporary light, power, and water at its own expense. These include piping, wiring, lamps, and other equipment necessary for the Work. The Contractor shall not draw water from any fire hydrant (except to extinguish a fire), without obtaining permission from the water agency concerned. The Contractor shall obtain a construction meter for water used for the construction, plant establishment, maintenance, cleanup, testing and all other work requiring water related to this contract. The Contractor shall contact the appropriate water agency for requirements. The Contractor shall pay all costs of temporary light, power and water including hookup, service, meter and any, and all, other charges, deposits and/or fees therefore. Said costs shall be considered incidental to the items of work that they are associated with and no additional payment will be made therefore. 7-8.6 Water Pollution Control. The Contractor shall exercise every reasonable precaution to protect channels, storm drains, and bodies of water from pollution. It shall conduct and schedule operations so as to minimize or avoid muddying and silting of said channels, drains, and waters. Water l' •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 81 of 101 Pages pollution control work shall consist of constructing those facilities which may be required to provide prevention, control, and abatement of water pollution. The Contractor shall comply with the California State Water Resources Control Board (SWRCB) Order Number 99-08-DWQ, National Pollutant Discharge Elimination System (NPDES) General Permit Number CAS000002, Waste Discharge Requirements (WDR's) for Discharges of Stormwater Runoff associated with Construction Activity (General Permit) and subsequent adopted modifications and with all requirements of the Storm Water Pollution Prevention and Monitoring Plans for this project in accordance with these regulations. 7-8.7 Drainage Control. The Contractor shall maintain drainage within and through the work areas. Earth dams will not be permitted in paved areas. Temporary dams of sandbags, asphaltic concrete, or other acceptable material will be permitted when necessary. Such dams shall be removed from the site as soon as their use is no longer necessary. 7-8.8 Noise Control. All internal combustion engines used in the construction shall be equipped with mufflers in good repair when in use on the project with special attention to the City Noise Control Ordinance, Carlsbad Municipal Code Chapter 8.48. 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS. The Contractor shall be responsible for the protection of public and private property adjacent to the Work and shall exercise due caution to avoid damage to such property. The Contractor shall repair or replace all existing improvements within the right-of-way which are not designated for removal (e.g., curbs, sidewalks, driveways, fences, walls, signs, utility installations, pavement, structures, etc.) which are damaged or removed as a result of its operations. When a portion of a sprinkler system within the right-of-way must be removed, the remaining lines shall be capped. Repairs and replacements shall be at least equal to existing improvements and shall match them in finish and dimension. Maintenance of street and traffic signal systems that are damaged, temporarily removed or relocated shall be done in conformance with 307-1.5. Trees, lawns, and shrubbery that are not to be removed shall be protected from damage or injury. If damaged or removed due to Contractor's operations, they shall be restored or replaced in as nearly the original condition and location as is reasonably possible. Lawns shall be reseeded and covered with suitable mulch. The Contractor shall give reasonable notice to occupants or owners of adjacent property to permit them to salvage or relocate plants, trees, fences, sprinklers, and other improvements, within the right- of-way which are designated for removal and would be destroyed because of the Work. All costs to the Contractor for protecting, removing, and restoring existing improvements shall be included in the Bid. 7-10 PUBLIC CONVENIENCE AND SAFETY. 7-10.1 Traffic and Access. The Contractor's operations shall cause no unnecessary inconvenience. The access rights of the public shall be considered at all times. Unless otherwise authorized, traffic shall be permitted to pass through the Work as per an approved Traffic Control Plan. Safe and adequate pedestrian and vehicular access shall be provided and maintained to: fire hydrants; commercial and industrial establishments; churches, schools and parking lots; service stations and l'\ •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 82 of 101 Pages motels; hospitals; police and fire stations; and establishments of similar nature. Access to these facilities shall be continuous and unobstructed unless otherwise approved by the Engineer. Safe and adequate pedestrian zones and public transportation stops, as well as pedestrian crossings of the Work at intervals not exceeding 90 m (300 feet), shall be maintained unless otherwise approved by the Engineer. Vehicular access to residential driveways shall be maintained to the property line except when necessary construction precludes such access for reasonable periods of time. If backfill has been completed to the extent that safe access may be provided, and the street is opened to local traffic, the Contractor shall immediately clear the street and driveways and provide and maintain access. The Contractor shall cooperate with the various parties involved in the delivery of mail and the collection and removal of trash and garbage to maintain existing schedules for these services. The Work shall be conducted by the Contractor in a manner to provide a satisfactory surface for traffic. Unless otherwise authorized, work on residential streets shall be performed in only one-half the roadway at one time. One half shall be kept open and unobstructed until the opposite side is ready for use. If one-half a street only is being improved, the other half shall be conditioned and maintained as a detour. The Contractor shall schedule the work so as to prevent damage by all traffic, including but not limited to mail delivery. The Contractor shall not schedule work so as to conflict with trash pickup. The trash hauling schedule can be obtained by calling the City's contracted waste disposal company, Coast Waste Management at 929-9417. During operations, the Contractor's schedule for resurfacing shall be designated to provide residents and business owners sufficient paved parking within an 800 foot distance from their homes or businesses. Public Notification of Work: Seventy-two hours prior to the start of any construction in the public right-of-way that affects vehicular traffic and/or parking or pedestrian routes, the Contractor shall give written notification of the impending disruption to all residences and/or businesses on the affected street or alley. For partial street closures, or curb, sidewalk and driveway repairs, the residences and/or businesses directly affected by the work shall be notified. The notification shall be hand delivered and shall state the date and time the work will begin and its anticipated duration. The notification shall list two telephone numbers that may be called to obtain additional information. One number shall be the Contractor's permanent office or field office and the other number shall be a 24-hour number answered by someone who is knowledgeable about the project. At least one of the phone numbers shall be in the (760) area code. An answering machine shall not be connected to either number. The notification shall also give a brief description of the work and simple instructions to the home or business owner on what they need to do to facilitate the construction. The Contractor shall submit the contents of the notification to the Engineer for approval. Notices shall not be distributed until approved by the Engineer. For residences, the notification shall be pre-cut in a manner that enables it to be affixed to a doorknob without adhesives. It shall be a minimum size of 3-1/2 inches by 8-1/2 inches and shall be brightly colored with contrasting printing. The material shall be equivalent in strength and durability to 65 lb. card stock. The printing on the notice shall be no smaller than 12 point. l' •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 83 of 101 Pages In addition to the notifications, the contractor shall post "No Parking" signs 72 hours in advance of the work being performed. The "No Parking" signs shall state the date and time of parking restriction for a duration not to exceed the time necessary to complete the work at that location. Failure of the contractor to meet the posted date requires re-posting the "No Parking" signs 72 hours in advance of the rescheduled work. If the work is delayed or rescheduled the "No Parking" signs shall be removed and re-posted 72 hours in advance of the rescheduled work. The preparation, materials, printing and distribution of the notifications shall be included in the Contractor's bid and will not be entitled to any additional compensation for printing and distributing these notices. The contractor shall replace all street markings and striping damaged by construction activities. The Contractor shall include in its Bid all costs for the above requirements. 7-10.2 Storage of Equipment and Materials in Public Streets. Construction materials shall not be stored in streets, roads, or highways for more than 5 days after unloading. All materials or equipment not installed or used in construction within 5 days after unloading shall be stored elsewhere by the Contractor at its expense unless authorized additional storage time. Construction equipment shall not be stored at the Work site before its actual use on the Work nor for more than 5 days after it is no longer needed. Time necessary for repair or assembly of equipment may be authorized by the Engineer. Excavated material, except that which is to be used as backfill in the adjacent trench, shall not be stored in public streets unless otherwise permitted. After placing backfill, all excess material shall be removed immediately from the site. 7-10.3 Street Closures, Detours, Barricades. The Contractor shall comply with all applicable State, County, and City requirements for closure of streets. The Contractor shall provide barriers, guards, lights, signs, temporary bridges, flagpersons, and watchpersons. The Contractor shall be responsible for compliance with additional public safety requirements which may arise. The Contractor shall furnish and install signs and warning devices and promptly remove them upon completion of the Work. The Contractor shall secure approval, in advance, from authorities concerned for the use of any bridges proposed by it for public use. Temporary bridges shall be clearly posted as to load limit, with signs and posting conforming to current requirements covering "signs" as set forth in the Traffic Manual published by the California Department of Transportation. This manual shall also apply to the street closures, barricades, detours, lights, and other safety devices required. All costs involved shall be included in the Bid. Traffic controls shall be in accordance with the plans, The California Manual on Uniform Traffic Control Devices (FHWA MUTCD 2012 Revision 1, as amended for use in California) and these provisions. If any component in the traffic control system is damaged, displaced, or ceases to operate or function as specified, from any cause, during the progress of the work, the Contractor shall immediately repair said component to its original condition or replace said component and shall restore the component to its original location. In the event that the Contractor fails to install and/or maintain barricades or such other traffic signs, markings, delineation or devices as may be required herein, the Engineer may, at his/her sole option, install the traffic signs, markings, delineation or devices and charge the Contractor twenty dollars ($25.00) per day per traffic sign or device, or the actual cost of providing such traffic control facility, whichever is the greater. l' •fi Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 84 of 101 Pages 7-10.3.1 Construction Area Signs and Control Devices. All construction traffic signs and control devices shall be maintained throughout the duration of work in good order and according to the approved traffic control plan. All construction area signs shall conform to the provisions of Section 206-7.2 et seq. All temporary reflective pavement markers shall conform to the provisions of Section 214-5.1.et seq. All temporary reflective channelizers shall conform to the provisions of Section 214- 5.2 et seq. All paint for temporary traffic striping, pavement marking, and curb marking shall conform to the provisions of Section 210-1.6 et seq. except that all temporary paint shall be rapid dry water borne conforming to Section 210-1.6 for materials and Section 310-5 et seq. For workmanship. Warning and advisory signs, lights and devices installed or placed to provide traffic control, direction and/or warning shall be furnished, installed and maintained by the Contractor. Warning and advisory signs, lights and devices shall be promptly removed by the Contractor when no longer required. Warning and advisory signs that remain in place overnight shall be stationary mounted signs. Stationary signs that warn of non-existent conditions shall be removed from the traveled way and from the view of motorists in the traveled way or shielded from the view of the traveling public during such periods that their message does not pertain to existing conditions. Care shall be used in performing excavation for signs in order to protect underground facilities. All excavation required to install stationary construction area signs shall be performed by hand methods without the use of power equipment. Warning and advisory signs that are used only during working hours may be portable signs. Portable signs shall be removed from the traveled way and shielded from the view of the traveling public during non-working hours. During the hours of darkness, as defined in Division 1, Section 280, of the California Vehicle Code, portable signs shall be illuminated or, at the option of the Contractor, shall be in conformance with the provisions in Section 206-7.2 et seq. If illuminated traffic cones rather than post-type delineators are used during the hours of darkness, they shall be affixed or covered with reflective cone sleeves as specified in CAL TRANS "Standard Specifications", except the sleeves shall be 7" long. Personal vehicles of the Contractor's employees shall not be parked within the traveled way, including any Section closed to public traffic. Whenever the Contractor's vehicles or equipment are parked on the shoulder within 6' of a traffic lane, the shoulder area shall be closed with fluorescent traffic cones or portable delineators placed on a taper in advance of the parked vehicles or equipment and along the edge of the pavement at not less than 25' intervals to a point not less than 25' past the last vehicle or piece of equipment. A minimum of nine (9) cones or portable delineators shall be used for the taper. A W20-1 (Road Work Ahead) or C24 (Shoulder Work Ahead) sign shall be mounted, as required herein, on a signpost or telescoping flag tree with flags. The signpost or flag tree shall be placed where directed by the Engineer. 7-10.3.2 Maintaining Traffic. The Contractor's personnel shall maintain a safe buffer distance from any traffic lane occupied by traffic. The Contractor's equipment shall maintain a safe distance from any traffic or pedestrians. 7-10.3.3Traffic Control System for Lane Closure. A traffic control system consists of closing traffic lanes or pedestrian walkways in accordance with the details shown on the plans, California Manual on Uniform Traffic Control Devices (FHWA MUTCD 2012 Revision 1, as amended for use in California) and provisions under "Maintaining Traffic" elsewhere in these Provisions. The provisions in this section will not relieve the Contractor from its responsibility to provide such additional devices or take such measures as may be necessary to maintain public safety. When lanes are closed for only the duration of work periods, all components of the traffic control system, except portable delineators placed along open trenches or excavation adjacent to the traveled way, shall be removed from the traveled way and shoulder at the end work period. If the Contractor so elects, said components may be stored at selected central locations, approved by the Engineer, within the limits of the right-of-way. 7-10.3.4Traffic Control for Permanent and Temporary Traffic Striping. During traffic stripe operations, traffic shall be controlled with lane closures, as provided for under "Traffic Control System l' •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 85 of 101 Pages for Lane Closure" of these Supplemental Provisions or by use of an alternative traffic control plan proposed by the Contractor and approved by the Engineer. The Contractor shall not start traffic striping operations using an alternative plan until the Contractor has submitted its plan to the Engineer and has received the Engineer's written approval of said plan. 7-10.3.5Temporary Pavement Delineation. Temporary pavement delineation shall be furnished, placed, maintained and removed in accordance with the minimum standards specified in the California Manual on Uniform Traffic Control Devices (FHWA MUTCD 2012 Revision 1, as amended for use in California) published by CAL TRANS. Whenever the work causes obliteration of pavement delineation, temporary or permanent pavement delineation shall be in place prior to opening the traveled way to public traffic. Lane line or centerline pavement delineation shall be provided at all times for traveled ways open to public traffic. All work necessary, including any required lines or marks, to establish the alignment of temporary pavement delineation shall be performed by the Contractor. When temporary pavement delineation is removed, all lines and marks used to establish the alignment of the temporary pavement delineation shall be removed by grinding. Surfaces to receive temporary pavement delineation shall be dry and free of dirt and loose material. Temporary pavement delineation shall not be applied over existing pavement delineation or other temporary pavement delineation. Temporary pavement delineation shall be maintained until superseded or replaced with permanent pavement delineation. Temporary pavement delineation shall be removed when, as determined by the Engineer, the temporary pavement delineation conflicts with the permanent pavement delineation or with a new traffic pattern for the area and is no longer required for the direction of public traffic. When temporary pavement delineation is required to be removed, all lines and marks used to establish the alignment of the temporary pavement delineation shall be removed. 7-10.3.6Preparation of New, or Modifications and Additions to Existing, Traffic Control Plan Sheets. If no traffic control plans (TCP) or Traffic Control Staging plans (TCP) are included in the project plans, the Contractor shall have a TCP prepared and submitted as a part of the Work for any and all construction activities that are located within the traveled way. The Contractor shall have TCP prepared and submitted as a part of the Work for any construction activities that are a part of this project that are not included in the project plans. The Contractor must submit the TCP for the Engineer's review in conformance with the requirements of Section 2-5.3, et seq. and obtain the Engineer's approval of the TCP prior to implementing them. The minimum 20-day review period specified in Section 2-5.3.1 for shop drawings and submittals shall pertain to each submittal of TCP, new, modified or added to, for the Engineer's review. New or revised TCP submittals shall include all TCP needed for the entire duration of the Work. Each phase of the TCP shall be shown in sufficient scale and detail to show the lane widths, transition lengths, curve radii, stationing of features affecting the traffic control plan and the methodology proposed to transition to the subsequent TCP phase. When the vertical alignment of the traveled surface differs from the finished pavement elevation vertical curves must also be shown. Such modifications, supplements and/or new design of TCP shall meet the requirements of the Engineer and the California Manual on Uniform Traffic Control Devices (FHWA MUTCD 200 Revision 1, as amended for use in California) as published by CALTRANS. Such modification, addition, supplement, and/or new design of TCP shall be prepared by a registered professional engineer appropriately registered in the State of California. The Engineer shall be the sole judge of the suitability and quality of any such modifications, supplements, and/or new designs to TCP. The Engineer may approve any such modifications, supplements, and/or new designs to the TCP when, in the Engineer's sole opinion, such modifications, supplements, and/or new designs to the TCP prepared by the registered professional engineer retained by the Contractor will be beneficial to the best interests of the Agency. Such modification, addition, supplement, and/or new design shall not be implemented and no work shall be commenced that is contingent on such approval until the changed TCP are approved by the Engineer. The preparation of such modification, addition, l' •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 86 of 101 Pages supplement, and/or new designs of TCP shall not presuppose their approval or obligate the Agency in any fashion. Submittal and review requirements for such modifications, supplements, and/or new designs to TCP shall conform to the requirements of Section 2-5.3 Shop Drawings and Submittals. 7-10.3. 7 Payment The Contractor shall provide traffic control at the contract lump sum price bid. The contract lump sum price paid for "traffic control" shall include full compensation for furnishing all labor (including flagging costs), materials (including signs), tools, equipment and incidentals, and for doing all the work involved in preparation, reproduction and changing of traffic control plans, placing, applying traffic stripes and pavement markers with bituminous adhesive, removing, storing, maintaining, moving to new locations, replacing, and disposing of the components of the traffic control system as shown on the plans and approved additions and modifications, as specified in these supplemental provisions, and as directed by the Engineer. All expenses and time to prepare and review modifications, additions, supplements and/or new TCP designs shall be included in the lump sum bid for traffic control and no additional payment will be made therefore. Flagging costs will be paid for as a part of the Lump Sum Amount for "Traffic Control." The cost of labor and material for portable concrete barriers will be paid for at the unit price bid. When there is no bid item the cost of labor and material for portable concrete barriers they will be paid as an incidental to the work being performed and no additional payment will be made therefore. Progress payments for "Traffic Control" will be based on the percentage of the improvement work completed. 7-10.4 Safety. 7-10.4.1 Safety Orders. The Contractor shall have at the Work site, copies or suitable extracts of: Construction Safety Orders, Tunnel Safety Orders and General Industry Safety Orders issued by the State Division of Industrial Safety. The Contractor shall comply with provisions of these and all other applicable laws, ordinances, and regulations. Before excavating any trench 5 feet or more in depth, the Contractor shall submit a detailed plan to the Agency showing the design of shoring, bracing, sloping, or other provisions to be made for the workers' protection from the hazard of caving ground during the excavation of such trench. If the plan varies from the shoring system standards, the plan shall be prepared by a registered Civil Engineer. No excavation shall start until the Engineer has accepted the plan and the Contractor has obtained a permit from the State Division of Industrial Safety. A copy of the permit shall be submitted to the Engineer. Payment for performing all work necessary to provide safety measures shall be included in the prices bid for other items of work except where separate bid items for excavation safety are provided, or required by law. 7-10.4.2Use of Explosives. Explosives may be used only when authorized in writing by the Engineer, or as otherwise stated in the Specifications. Explosives shall be handled, used, and stored in accordance with all applicable regulations. The Engineer's approval of the use of explosives shall not relieve the Contractor from liability for claims caused by blasting operations. 7-10.4.3Special Hazardous Substances and Processes. Materials that contain hazardous substances or mixtures may be required on the Work. A Material Safety Data Sheet as described in Section 5194 of the California Code of Regulations shall be requested by the Contractor from the manufacturer of any hazardous products used. l' •+; Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 87 of 101 Pages Material usage shall be accomplished with strict adherence to California Division of Industrial Safety requirements and all manufacturer warnings and application instructions listed on the Material Safety Data Sheet and on the product container label. The Contractor shall notify the Engineer if a specified product cannot be used under safe conditions. 7-10.4.4Confined Spaces. (a) Confined Space Entry Program. The Contractor shall be responsible for implementing, administering and maintaining a confined space entry program (CSEP) in accordance with Sections 5156, 5157 and 5158, Title 8, CCR. Prior to starting the Work, the Contractor shall prepare and submit its comprehensive CSEP to the Engineer. The CSEP shall address all potential physical and environmental hazards and contain procedures for safe entry into confined spaces, including, but not limited to the following: 1. Training of personnel 2. Purging and cleaning the space of materials and residue 3. Potential isolation and control of energy and material inflow 4. Controlled access to the space 5. Atmospheric testing of the space 6. Ventilation of the space 7. Special hazards consideration 8. Personal protective equipment 9. Rescue plan provisions The Contractor's submittal shall include the names of its personnel, including subcontractor personnel, assigned to the project who will have CSEP responsibilities, their CSEP training, and their specific assignment and responsibility in carrying out the CSEP. (b) Permit-Required Confined Spaces. Entry into permit-required confined spaces as defined in Section 5157, Title 8, CCR may be required as a part of the Work. All manholes, tanks, vaults, pipelines, excavations, or other enclosed or partially enclosed spaces shall be considered permit- required confined spaces until the pre-entry procedures demonstrate otherwise. The Contractor shall implement a permit space program prior to performing any work in a permit-required confined space. A copy of the permit shall be available at all times for review by Contractor and Agency personnel at the Work site. (c) Payment. Payment for implementing, administering, and providing all equipment and personnel to perform the CSEP shall be included in the bid items for which the CSEP is required. 7-10.4.SSafety and Protection of Workers and Public. The Contractor shall take all necessary precautions for the safety of employees on the work and shall comply with all applicable provisions of Federal, State and Municipal safety laws and building codes to prevent accidents or injury to persons on, about, or adjacent to the premises where the work is being performed. The Contractor shall erect and properly maintain at all times, as required by the conditions and progress of the work, all necessary safeguards for the protection of workers and public, and shall use danger signs warning against hazards created by such features of construction as protruding nails, hoists, well holes, and falling materials. 7-11 PATENT FEES OR ROYAL TIES. The Contractor shall absorb in its Bid the patent fees or royalties on any patented article or process furnished or used in the Work. The Contractor shall indemnify and hold the Agency harmless from any legal action that may be brought for infringement of patents. l'\ •+' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 88 of 101 Pages 7-12 ADVERTISING. The names, addresses and specialties of Contractors, Subcontractors, architects, or engineers may be displayed on removable signs. The size and location shall be subject to the Engineer's approval. Commercial advertising matter shall not be attached to or painted on the surfaces of buildings, fences, canopies, or barricades. 7-13 LAWS TO BE OBSERVED. The Contractor shall keep fully informed of State and National laws and County and Municipal ordinances and regulations which in any manner affect those employed in the Work or the materials used in the Work or in any way affect the conduct of the Work. The Contractor shall at all times observe and comply with such laws, ordinances, and regulations. Municipal ordinances that affect this work include Chapter 11.06. Excavation and Grading. If this notice specifies locations or possible materials, such as borrow pits or gravel beds, for use in the proposed construction project which would be subject to Section 1601 or Section 1603 of the Fish and Game Code, the conditions established pursuant to Section 1601 et seq. of the Fish and Game Code shall become conditions of the contract. 7-14 ANTITRUST CLAIMS. Section 7103.5 of the Public Contract Code provides: "In entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or subcontractor offers and agrees to assign to the awarding body all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec 15) or Cartwright Act (Chapter 2 [commencing with Section 16700] of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or subcontract. The assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment of the parties." SECTION 9 -MEASUREMENT AND PAYMENT 9-1 MEASUREMENT OF QUANTITIES FOR UNIT PRICE WORK. 9-1.1 General. Unless otherwise specified, quantities of work shall be determined from measurements or dimensions in horizontal planes. However, linear quantities of pipe, piling, fencing and timber shall be considered as being the true length measured along longitudinal axis. Unless otherwise provided in Specifications, volumetric quantities shall be the product of the mean area of vertical or horizontal sections and the intervening horizontal or vertical dimension. The planimeter shall be considered an instrument of precision adapted to measurement of all areas. 9-1.2 Methods of Measurement. Materials and items of work which are to be paid for on basis of measurement shall be measured in accordance with methods stipulated in the particular sections involved. 9-1.3 Certified Weights. When payment is to be made on the basis of weight, the weighing shall be done on certified platform scales or, when approved by the Engineer, on a completely automated weighing and recording system. The Contractor shall furnish the Engineer with duplicate licensed weighmaster's certificates showing actual net weights. The Agency will accept the certificates as evidence of weights delivered. l'\ •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 89 of 101 Pages 9-1.4 Units of Measurement. The system of measure for this contract shall be the U.S. Standard Measures. 9-2 LUMP SUM WORK. Items for which quantities are indicated "Lump Sum", "L.S.", or "Job", shall be paid for at the price indicated in the Bid. Such payment shall be full compensation for the items of work and all work appurtenant thereto. When required by the Specifications or requested by the Engineer, the Contractor shall submit to the Engineer within 15 days after award of Contract, a detailed schedule in triplicate, to be used only as a basis for determining progress payments on a lump sum contract or designated lump sum bid item. This schedule shall equal the lump sum bid and shall be in such form and sufficiently detailed as to satisfy the Engineer that it correctly represents a reasonable apportionment of the lump sum. 9-3PAYMENT 9-3.1 General. The quantities listed in the Bid schedule will not govern final payment. Payment to the Contractor will be made only for actual quantities of Contract items constructed in accordance with the Plans and Specifications. Upon completion of construction, if the actual quantities show either an increase or decrease from the quantities given in the Bid schedule, the Contract Unit Prices will prevail subject to the provisions of Section 3-2.2.1. The unit and lump sum prices to be paid shall be full compensation for the items of work and all appurtenant work, including furnishing all materials, labor, equipment, tools, and incidentals. Payment will not be made for materials wasted or disposed of in a manner not called for under the Contract. This includes rejected material not unloaded from vehicles, material rejected after it has been placed, and material placed outside of the Plan lines. No compensation will be allowed for disposing of rejected or excess material. Payment for work performed or materials furnished under an Assessment Act Contract will be made as provided in particular proceedings or legislative act under which such contract was awarded. Whenever any portion of the Work is performed by the Agency at the Contractor's request, the cost thereof shall be charged against the Contractor, and may be deducted from any amount due or becoming due from the Agency. Whenever immediate action is required to prevent injury, death, or property damage, and precautions which are the Contractor's responsibility have not been taken and are not reasonably expected to be taken, the Agency may, after reasonable attempt to notify the Contractor, cause such precautions to be taken and shall charge the cost thereof against the Contractor, or may deduct such cost from any amount due or becoming due from the Agency. Agency action or inaction under such circumstances shall not be construed as relieving the Contractor or its Surety from liability. Payment shall not relieve the Contractor from its obligations under the Contract; nor shall such payment be construed to be acceptance of any of the Work. Payment shall not be construed as the transfer of ownership of any equipment or materials to the Agency. Responsibility of ownership shall remain with the Contractor who shall be obligated to store any fully or partially ,, •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 90 of 101 completed work or structure for which payment has been made; or replace any materials or equipment required to be provided under the Contract which may be damaged, lost, stolen or otherwise degraded in any way prior to acceptance of the Work, except as provided in Section 6- 10. Guarantee periods shall not be affected by any payment but shall commence on the date of recordation of the "Notice of Completion." If, within the time fixed by law, a properly executed notice to stop payment is filed with the Agency, due to the Contractor's failure to pay for labor or materials used in the Work, all money due for such labor or materials will be withheld from payment to the Contractor in accordance with applicable laws. At the expiration of 35 days from the date of acceptance of the Work by the Board, or as prescribed by law, the amount deducted from the final estimate and retained by the Agency will be paid to the Contractor except such amounts as are required by law to be withheld by properly executed and filed notices to stop payment, or as may be authorized by the Contract to be further retained. 9-3.2 Partial and Final Payment. The Engineer will, after award of Contract, establish a closure date for the purpose of making monthly progress payments. The Contractor may request in writing that such monthly closure date be changed. The Engineer may approve such request when it is compatible with the Agency's payment procedure. Each month, the Engineer will make an approximate measurement of the work performed to the closure date as basis for making monthly progress payments. The estimated value will be based on contract unit prices, completed change order work and as provided for in Section 9-2 of these General Provisions. Progress payments shall be made no later than thirty (30) calendar days after the closure date. Five (5) working days following the closure date, the Engineer shall complete the detailed progress pay estimate and submit it to the Contractor for the Contractor's information. Should the Contractor assert that additional payment is due, the Contractor shall within ten (10) days of receipt of the progress estimate, submit a supplemental payment request to the Engineer with adequate justification supporting the amount of supplemental payment request. Upon receipt of the supplemental payment request, the Engineer shall, as soon as practicable after receipt, determine whether the supplemental payment request is a proper payment request. If the Engineer determines that the supplemental payment request is not proper, then the request shall be returned to the Contractor as soon as practicable, but not later than seven (7) days after receipt. The returned request shall be accompanied by a document setting forth in writing the reasons why the supplemental payment request was not proper. In conformance with Public Contract Code Section 20104.50, the City shall make payments within thirty (30) days after receipt of an undisputed and properly submitted supplemental payment request from the Contractor. If payment of the undisputed supplemental payment request is not made within thirty (30) days after receipt by the Engineer, then the City shall pay interest to the Contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.01 0 of the Code of Civil Procedure. From each progress estimate, 1 0 percent will be deducted and retained by the Agency, and the remainder less the amount of all previous payments will be paid. After 50 percent of the Work has been completed and if progress on the Work is satisfactory, the deduction to be made from remaining progress estimates and from the final estimate may be limited to $500 or 10 percent of the first half of total Contract amount, whichever is greater. ,., •ff Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 91 of 101 No progress payment made to the Contractor or its sureties will constitute a waiver of the liquidated damages under 6-9. As provided in Section 22300 of the California Public Contract Code, the Contractor may substitute securities for any monies withheld by the Agency to ensure performance under the Contract. After final inspection, the Engineer will make a Final Payment Estimate and process a corresponding payment. This estimate will be in writing and shall be for the total amount owed the Contractor as determined by the Engineer and shall be itemized by the contract bid item and change order item with quantities and payment amounts and shall show all deductions made or to be made for prior payments and amounts to be deducted under provisions of the contract. All prior estimates and progress payments shall be subject to correction in the Final Payment Estimate. The Contractor shall have 30 calendar days from receipt of the Final Payment Estimate to make written statement disputing any bid item or change order item quantity or payment amount. The Contractor shall provide all documentation at the time of submitting the statement supporting its position. Should the Contractor fail to submit the statement and supporting documentation within the time specified, the Contractor acknowledges that full and final payment has been made for all contract bid items and change order items. If the Contractor submits a written statement with documentation in the aforementioned time, the Engineer will review the disputed item within 30 calendar days and make any appropriate adjustments on the Final Payment. Remaining disputed quantities or amounts not approved by the Engineer will be subject to resolution as specified in Section 3-5, Disputed Work. The written statement filed by the Contractor shall be in sufficient detail to enable the Engineer to ascertain the basis and amount of said disputed items. The Engineer will consider the merits of the Contractor's claims. It will be the responsibility of the Contractor to furnish within a reasonable time such further information and details as may be required by the Engineer to determine the facts or contentions involved in its claims. Failure to submit such information and details will be sufficient cause for denying payment for the disputed items. 9-3.2.1 Payment for Claims. Except for those final payment items disputed in the written statement required in Section 9-3.2 all claims of any dollar amount shall be submitted in a written statement by the Contractor no later than the date of receipt of the final payment estimate. Those final payment items disputed in the written statement required in Section 9-3.2 shall be submitted no later than 30 days after receipt of the Final Payment estimate. No claim will be considered that was not included in this written statement, nor will any claim be allowed for which written notice or protest is required under any provision of this contract including Sections 3-4 Changed Conditions, 3-5 Disputed Work, 6-6.3 Payment for Delays to Contractor, 6-6.4 Written Notice and Report, or 6-7.3 Contract Time Accounting, unless the Contractor has complied with notice or protest requirements. The claims filed by the Contractor shall be in sufficient detail to enable the Engineer to ascertain the basis and amount of said claims. The Engineer will consider and determine the Contractor's claims and it will be the responsibility of the Contractor to furnish within a reasonable time such further information and details as may be required by the Engineer to determine the facts or contentions involved in its claims. Failure to submit such information and details will be sufficient cause for denying the claims. ,, •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 92 of 101 Payment for claims shall be processed within 30 calendar days of their resolution for those claims approved by the Engineer. The Contractor shall proceed with informal dispute resolution under Section 3-5, Disputed Work, for those claims remaining in dispute. 9-3.3 Delivered Materials. When provided for in the Specifications, and subject to the limitation and conditions therein, the cost of materials and equipment delivered but not incorporated into the Work will be included in the progress estimate. 9-3.3.1 Delivered Materials. The cost of materials and equipment delivered but not incorporated into the work will not be included in the progress estimate. 9-3.4.1 Mobilization and Preparatory Work. Payment for Mobilization and preparatory work will be made at the stipulated lump-sum price of $10,000, and includes full compensation for furnishing all insurance, bonds, licenses, permits, labor, materials, utilities, tools, equipment and incidentals, and for doing all the work involved in mobilization and preparatory work and operations, including, but not limited to, those necessary for the movement of personnel, equipment, supplies, and incidental to preparing to conduct work on and off the project site and other offsite facilities necessary for work on the project; for all other facilities, sureties, work and operations which must be performed or costs incurred prior to beginning work on various contract items on or off the project site, excepting those specifically paid for under separate sections of these specifications. The Contractor hereby agrees that the stipulated lump sum amount is sufficient for Mobilization and Preparatory Work, as described in this section, and that the Contractor shall have no right to additional compensation for Mobilization and Preparatory Work. Progress payments for Mobilization and Preparatory Work will be made as follows: For the first progress payment (after the issuance of the Notice to Proceed), forty percent (40%) of the amount bid for Mobilization And Preparatory Work will be allowed. For the second progress payment, an additional sixty percent (60%) of the amount bid for mobilization and preparatory work will be allowed therefore. 9-4 BID ITEMS. Payment for each Bid Item shall be made at the quantity and type as listed in the Contractor's Proposal. All work shown or mentioned on the plans, in the Contract Documents, General Provisions, or Technical Provisions/Specifications shall be considered as included in the Bid Items. Contractor must protect existing utilities, improvements, landscaping, irrigation systems, and vegetation in place. If damaged during the work, Contractor is responsible to repair or replace any utilities, improvements, landscaping, irrigation systems, and vegetation at his expense. Traffic Control and Traffic Control Plan (Bid Item No. 1) This item consists of preparing and implementing a traffic control plan for the area where work will be performed, as required to complete the items of work shown on the plans and as described in these special provisions. The contract lump sum price paid for traffic control and traffic control plan shall include full compensation for furnishing all labor, materials, tools, equipment and incidentals, and for doing all the work involved in preparing and implementing a traffic control plan, including all signs for staging construction and other signs as may be required, and for doing all the work involved in traffic control, including public notification, all flagging, signs, striping, chain link fence, and all ,., •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 93 of 101 other traffic control devices furnished, installed, maintained, and removed when no longer needed, as specified in the city standards, specifications and contract documents. Items of traffic control for which there is a contract item of work will be measured and paid for as that contract item of work. Remove and Re-use Treads (Bid Item No. 2) This item consists of removing undamaged stair treads where shown by removing welds between embed plates and support angles, lifting out existing treads and reinstalling treads after replacement of support angles. The contract prices paid per each for remove and re-use treads shall include full compensation for furnishing all labor, materials, tools, equipment and incidentals, and for doing all the work involved in removing and re-using existing stair treads, including temporary bracing of HSS stairway beams, removing welds between embedded steel plates in stair treads and support angles without damaging the embedded plates or the concrete stair treads, preparing embedded plate surfaces for welding, and reinstalling tread plates by welding to new support angles as shown, as specified in the city standards, specifications and contract documents. Remove and Replace Treads (Bid Item No. 3) This item consists of removing damaged stair treads where shown by removing welds between embed plates and support angles, lifting out existing and disposing of treads, fabricating new treads and installing new treads after replacement of support angles. The contract prices paid per each for remove and replace treads shall include full compensation for furnishing all labor, materials, tools, equipment and incidentals, and for doing all the work involved in removing and replacing stair treads, including temporary bracing of HSS stairway beams, protection of coastal bluff, removing welds between embedded steel plates in stair treads and support angles, furnishing precast concrete stair treads, including epoxy-coated reinforcement, galvanized embedded steel plates and studs, and installing tread plates by welding to new support angles as specified in the city standards, specifications and contract documents. Remove and Replace Steel Stairway Support Angles (Bid Item No. 4) This item consists of removing existing steel stairway support angles from HSS stairway beams, disposing of support angles, preparing HSS stairway beams for welding by removing existing rust and preparing surfaces per AWS D1 .1, and furnishing and installing new galvanized steel stairway support angles and reinforcing plates. The contract prices paid per each for remove and replace steel angle support brackets shall include full compensation for furnishing all labor, materials, tools, equipment and incidentals, and for doing all the work involved in removing and replacing steel stairway support angles support brackets, including removing welds between brackets and HSS stairway beams, removing rust form HSS stairway beams and preparation of stairway beams for welding, furnishing galvanized steel stairway support angles and reinforcing plates, and installing steel reinforcing plates and support angles by welding to existing HSS stairway beams, as specified in the city standards, specifications and contract documents. Clean and Paint Structural Steel (Bid Item No. 5) This item consists of cleaning, spot blast cleaning, and painting at the locations for attaching new galvanized steel reinforcing plates and stairway support angles to existing HSS stairway beams, and cleaning, blast cleaning, and painting all new galvanized steel embed plates, reinforcing plates and support angles. ,, •+;' Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 94 of 101 The contract lump sum price paid for clean and paint structural steel shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals, and for doing all the work involved in cleaning, spot blasting and painting existing structural steel, and cleaning, blast cleaning and painting new structural steel, including removing and disposing of all rust, existing paint, mill scale and slag, and furnishing and applying primer and finish coats, as shown on the plans, as specified in the city standards, specifications and contract documents. Seal Concrete Stairway Treads (Bid Item No. 6) This item consists of sealing new and existing concrete stair treads, and sealing joints between structural steel and concrete stair treads. The contract price paid per each for sealing new and existing concrete stairway treads shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals, and for doing all the work involved in sealing concrete stairway treads, including furnishing and applying sealer, and furnishing and installing polyurethane joint sealant, as shown on the plans, as specified in the city standards, specifications and contract documents. Stormwater Pollution Protection Plan (SWPPP) (Bid Item No. 7) This item consists of preparing and implementing a SWPPP. The contract lump sum price paid for SWPPP shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals, and for doing all the work involved in preparing and implementing a SWPPP, complete in place, as specified in the city standards, specifications and contract documents. Mobilization (Bid Item No. 8) The contract lump sum price paid for this bid item shall constitute full compensation for the costs of work in advance of and post construction operations that do not directly attribute to any specific bid item. Mobilization includes procurement of any required permits from the City. ,., -~ Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 95 of 101 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 2, CONSTRUCTION MATERIALS SECTION 201 -CONCRETE, MORTAR, AND RELATED MATERIALS 201-1 PORTLAND CEMENT CONCRETE Add the following: Concrete for precast stairway treads shall be designated by Special Exposure as follows: 650- CLE-4000P and shall contain 3 lbs/cy of Type Ill fiber reinforcement. 201-2 REINFORCEMENT FOR CONCRETE 201-2.2 Steel Reinforcement 201-2.2.1 Reinforcing Steel Add the following: Reinforcement for stairway treads shall be galvanized reinforcement in conformance with section 52-3 of the State Standard Specifications. 201-3 EXPANSION JOINT FILLER AND JOINT SEALANTS Add the following: Polyurethane joint sealant shall be Type "A" Sealant (Two-Part Polyurethane Sealant). Polyethylene foam or rod stock for retaining sealant shall be commercial quality with a continuous, impervious glazed surface. SECTION 206 -MISCELLANEOUS METAL ITEMS 206-1 STRUCTURAL STEEL, RIVETS, BOLTS, PINS, AND ANCHOR BOLTS 206-1.1 Requirements 206-1.1.1 General. Delete the first sentence and replace with: All steel for embed plates, support angles and reinforcing plates shall be structural steel and shall conform to the requirements of ASTM A36. Stud shear connectors shall conform to ASTM A 108. Add the following: All structural steel shall be galvanized after fabrication . .:, • ., Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 96 of 101 SECTION 210 -PAINT AND PROTECTIVE COATINGS 210-1 PAINT Delete Section 210-1.4 and replace with the following: 210-1.4 Paint Materials Paint materials shall conform to Section 91, "Paint" of the State Standard Specifications. Finish paint color shall match existing paint color. Delete Section 210-1.5 and replace with the following: 210-1.5 Paint Systems Paint systems shall be zinc in conformance with Section 59-2.01C(4)(b), "Zinc Coating System", of the State Standard Specifications. Add the following section: 210-6 CONCRETE SEALANT The concrete sealant shall be a product designed to seal concrete against moisture. The sealant shall be 40 percent, minimum, organosilane, diluted in a solvent recommended by the manufacturer and shall consist of alkyltrimethoxysilanes with an alkyl group of I-butyl, I-octyl, n- octyl, singularly or in combination. When applied to a concrete surface, that has been surface dry not less than 48 hours, the sealant shall seal the surface to the extent that 5 days after applying, a spray of water will not change the appearance of the concrete. The concrete sealant shall be tinted with a fugitive dye that colors the sealant on the concrete surface for at least four hours after the application and then disappears within seven days after application. Each shipment of concrete sealant shall be accompanied by the manufacturer's recommendations for application of the concrete sealant and a Certificate of Compliance conforming to Section 4-1.5, "Certification", of the Standards Specifications. ,, •,r Revised 2/27/18 PWS18-121TRAN-Contract No. 3896 Page 97 of 101 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 3, CONSTRUCTION METHODS SECTION 304 METAL FABRICATION AND CONSTRUCTION 304-1 STRUCTURAL STEEL 304-1.1 General Add the following: 304-1.1.3 Temporary Bracing Temporary bracing and/or temporary supports shall be provided, as necessary, to withstand all imposed loads and maintain existing grade and alignment of the HSS stairway beams during removal of treads and support angles, cleaning and painting of HSS stairway beams, reinforcing plates and support angles, installation of plates and angles and installation of precast concrete stair treads. SECTION 310 PAINTING 310-2 SURFACE PREPARATION FOR PAINTING STEEL STRUCTURES Add the following section: 310-6 SEAL CONCRETE SURFACES Sealing concrete surfaces shall consist of cleaning and placing a sealant on all concrete surfaces of new and existing concrete stairway treads, as specified in these special provisions. The concrete sealant shall comply with section 210-6 "Concrete Sealant", of these special provisions. Cleaning shall remove all dirt, sand, debris and other deleterious material. After cleaning, the concrete surface shall be air blown to remove loose surface materials. The concrete surface shall be dry when the sealant is applied. Concrete sealant shall be applied only during periods of weather as recommended by the manufacturer, except that the sealant shall be applied only when the atmospheric temperature is between 40°F and 100°F, and wind velocity is less than 5 miles per hour. The application of concrete sealant shall conform to the manufacturer's recommendations. One flood coat of sealant shall be applied to the concrete surface at the coverage rate of approximately 100 square feet per gallon. The sealant shall be applied using an airless sprayer with 20 psi pressure, maximum. The sprayer shall be equipped with a calibrated pressure gauge showing the pressure during the spraying operation. For small areas, if approved by the Engineer, rollers may be used to apply sealant. ,, •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 98 of 101 Approximately 24 hours after placement of the concrete sealer, the Contractor shall uniformly dampen the treated concrete surface using a fine water spray. The spray shell be sufficient to completely wet the surface without causing excessive runoff. Five days after sealant application the Contractor shall spray sealed concrete surfaces with a fresh water spray to verify sealant coverage. Surfaces determined to lack sufficient sealant coverage shall be resealed. Add the following section: 310-7 CLEAN AND PAINT STRUCTURAL STEEL Clean and paint structural steel shall apply to the entire inside face of the existing HSS stairway beams from which existing support angles are to be removed and new reinforcing plates and support angles are to be installed, and to new support angles, new embed plates, and new reinforcing plates, where required by the engineer. ,, •+;' Revised 2/27/18 PWS 18-121 TRAN-Contract No. 3896 Page 99 of 101 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 6 -TEMPORARY TRAFFIC CONTROL SECTION 600 ACCESS 600-2 VEHICULAR ACCESS Add the following: All traffic and bicycle lanes on Carlsbad Boulevard shall be maintained at all times. 600-3 PEDESTRIAN ACCESS Add the following: Safe access for pedestrian traffic along both side of and across Carlsbad Boulevard, and along the seawall path shall be maintained at all times, except where temporary closures are approved by the Engineer in advance. The westerly sidewalk along Carlsbad Boulevard shall remain open at all times. At no time shall material be staged on the sidewalk. A flagger shall be used for temporary stoppage of sidewalk traffic for movement of treads across the sidewalk. SECTION 601 WORK AREA TRAFFIC CONTROL 601-2 TRAFFIC CONTROL PLAN (TCP) Add the following: Traffic control devices, including signs, temporary traffic signals and temporary modifications to existing traffic signals, shall be utilized to route traffic and minimize impacts on the general public in conformance with these special provisions, as shown on the plans and as approved by the Engineer. The Contractor shall submit to the Engineer for review and approval, at least five (5) days prior to start of work, a plan showing traffic control measures for vehicles, bicyclists and pedestrians affected by the construction work. The traffic control plan shall include temporary signing and striping, denoting exact location of temporary sign placement. The plan shall be developed in accordance with the plans, the City of Carlsbad Traffic Control Plan requirements and the latest version of the California Manual on Traffic Control Devices. All work shall be performed during the daylight hours on Monday through Friday unless otherwise approved by the Engineer. Work that impacts traffic shall be limited to between 8:00 a.m. and 4:00 p.m., Monday through Friday, unless otherwise superseded by the approved traffic control plan. ,., •+;' Revised 2/27 /18 PWS 18-12 HRAN-Contract No. 3896 Page 100 of 101