HomeMy WebLinkAbout1981-11-17; City Council; 6737-1; Calavera Hills treatment plantI -
ClTl 3F CARLSBAD - AGENDA ALL
rB# 6737.T. /
ITG.11/17/81
)EPT.CM
TITLE:
CALAVERA HILLS TREATMENT PLANT
DEPT. HD. fc
CITY ATTYU
CITY MGR.~
RECOMMENDED ACTION:
That City Council adopt Resolutions Nos. 6 bb3 and b72r which, subject to certain conditions, rescinds the prior agreement dated 12/26/79 and sub- stitutes therefore a revised agreement, accepts transfer of capacity rights in the San Marcos County Water District Treated Effluent Outfall Pipeline, and authorizes the Mayor to sign both agreements on behalf of the City Council.
[TEM EXPLANATION:
The Council on September 22, 1981 held a public hearing on a revised agree- ment for the Lake Calavera Hills Sewage Treatment Plant. The revised agree- ment, negotiated for the City by City Manager Aleshire and reviewed by a Council subcommittee consisting of Council Members Anear and Lewis, provides for acceptance of the completed sewage treatment plant prior to completion of the Effluent Disposal Line (EDL) and prior to construction of any Advanced Waste Treatment (AWT) works required in order to reclaim treated effluent. It also provides for establishing "credit" against which the developer can pay for sewer connections until the credit is used up. hearing, Council instructed staff to prepare the final agreement and return it to Council for action.
After the public
The revised agreement is attached as an exhibit to the resolution of approval. The agreement has been signed by Mr. Ward - but must be changed, on page 6, Section 8 to reflect a construction refund. The revised amount should read $2,852,704. would be to approve the resolutions accepting the revised agreement and the EDL capacity rights.
If the agreement conforms with Council's wishes, their action
Some minor repair work is underway and may not be completed by November 17, 1981. completed. Staff will withhold the certificate of acceptance until the work is
FISCAL IMPACT:
The City would assume responsibility for constructing an EDL estimated to cost $1 million and, at some future date, the possibility of an AWT system estimated at $1 million. The City would receive approximately 3600 sewer connections over and above that reserved for the developer. are estimated to be of a value approximating $3.6 million. These connections
EXHIBITS :
A. Resolution No. 0 6p b3 with revised agreement attached. B. Resolution No. mp accepting pi pel ine capacity rights.
I
. . . .- . ., - . . - .t
*-
Jity Draft: 10/8/8.1
AGREEMENT
This Agreement is made and #entered into at Carlsbad,
. California, this - day of 'September, 1981 , by and between
City of Carlsbad, California, a municipal corporation
(hereinafter referred to as "City") , and Lake Calavera Hills
Associates, a California partnership (hereinafter referred to as
"Developer" ) .
RE C I T A L S:
A. City and Developer have previously entered into a
certain agreement, dated December 26, 1979, and entitled
"Agreement Between City of Carlsbad, California and Lake
Calavera Hill-s Associates for Construction of a 1.2 Million
Gallon Capacity Sewage Treatment and Waste Water Reclamation
,Facility arid Necessary Appurtenances and to Provide for the
Financing and Reimbursement for Costs of Oversizing Thereof".
B. Developer has undertaken performance under said
agreement and -has expended substantial sums of money in excess
of $2,000,000 in furtherance of the agreement.
C. Developer has completed construction of the sewage
treatment facility and portions of the effluent disposal line
and those facilities arc ready for delivery to and acceptance by
the City.
EXH I B IT ''A'' -- 4
..
D. By reason of certain intervening considerations,
the parties now agree that it is not in the best interests of
either the City or Developer to attempt to complete the
agreement in accordance with-its terms.
E. The parties desire to effect a novation of the
original agreement and enter into a new.agreement to establish
their rights and obligations.
F. The parties intend by this new agreement to
transfer all completed facilities to the City, with Developer
receiving appropriate credit for expenditures previously made
and appropriate reservations of sewage treatme'nt capacity in
those facilities.
NOW, THEREFORE, in consideration of the recitals and of
the mutual obligations of the parties established by this
agreement, City and. Developer agree as follows:
SECTION 1 : DEFINITIONS
' A. "Acceptance": A formal action by the City
accepting any offer of dedication of the sewage treatment
facility or any portion thereof. Acceptance shall not
constitute a waiver T of defects by City.
B. "Agreement" : This agreement, being a new
agreement in the place and stead of the original agreement dated
December 26, 1979.
C. "EDU": - EDU is an abbreviation of Equivalent
Dwelling Unit and j.s an approximati.on of that amount of sewage
2.
.'
'.
which is discharged daily by an average residential dwelling - unit. .
D. "EDL Line": EDL line is synonymous with the term .. ,
"fail-safe line" used in the original agreement and means any
effluent or excess effluent disposal line which would carry
effluent from the project to the ocean outfall.
E. "Master Plan Area or Calavera Hills": Master plan
area or Calavera Hills shall include all areas defined in the
Lake Calavera Hills Master Plan (MP-lSO(A)) on file with the
City and incorporated herein by reference.
..
F. "MGD" - : Plant capacity expressed in millions of
gallons per day.
G. "Original Agreement": - That certain original
agreement between the parties hereto, dated December 26, 1979
which agreement is novated and replaced by this agreernent.
SECTION 2: NOVATION - OF .ORIGINAL AGREEMENT
That certain agreement between the parties dated
December 26 , 1979, "the Original Agreement", is hereby
*
superseded and extinquished and this agreement shall establish
and control the rights and obligations of the parties in its
place and stead. .
-
.- SECTION 3: . RELEASE -- FROM MORATORIA -I
Upon the execution of this agreement by the parties and
the de1,ivery of the completed facilities to City, the City shall
3. '
-a
promptly undertake the steps necessary to remove the lands of
Developer within the Master Plan Area from the Planning moratoria
imposed by Chapter 21.49 of the Carlsbad . Municipal Code. City
will immediately make available to Developer and Developer's
successors in interest sewage treatment capacity at the Encina
Treatment Plant on the same basis as any other property owners
in the City's sewer service area. The availability of this
capacity is subject to the limitations of the existing system for
the transmission of sewage to the Encina Plant; provided,
however, that City shall not unreasonably discriminate against
Developer and Developer's successors in interest in access to
transmission capacity.
I
SECTION 4: DELIVERY OF COMPLOETED FACILITIES
Upon execution of this agreement by the parties,
Developer shall deliver to and offer to dedicate tQ City all
plans, land, rights-of-way, completed facilities, and Developer's
interests in the San Marcos Outfall Pipeline (hereinafter
"Completed Facilities"). The Completed Facilities are described
. on Exhibit "Aff, attached hereto and made a part hereof by this
reference. Developer will transfer a11 rights, title and
interest in the Completed Facilities to City free and clear of
all liens and encumbrances, subject only to any rights expressly
reserved herein.
SECTION 5 : WARRANTY
Developer shall fully guaranty and warrant'all work on '
.the Completed Facilities for a period of one year from the
4, 7
date of L,is agreement. If w thin said warranty period any
structure or part of any structure furnished, installed, or
constructed, or caused to be installed or constructed by
Developer, or any of the work related to the completed
facilities, fails to fulfill any of the requirements of the plans
and specifications referred to In the Original Agreement,
Developer shall without delay and without any cost to City,
repair, replace, or reconstruct any defective or otherwise
unsatisfactory part or parts of the work or structure. Developer
will be notified in writing of any deficiencies which must be
corrected, but failure on the part of City to 'notify Developer
ii
shall not affect any of City's rights under this provision.
c
Developer shall commence repair of any defect or
deficiency within ten working days after notification by City.
The repairs shall b,e compl-eted expedi.tiously and within a
reasonable period of time. If Developer fails to commence or
complete repairs within these time limits, City may undertake and
is hereby authorized by Developer to make, at City's option, the
repairs and assess the cost to Developer. Repairs pursuant to
this warranty shall be at the cost of Developer and no credit
shall be given therefor.
-
-*
SECTJON 6 : RELEASE FROM PUR'I'HER OBL,IGATIONS ~ND~~oXEIEKX~REEME~\~T -
Except as expressly provided herein, Deve.loper shall
have no further obligations under the Original Agreement and, in
*
5. .
,particular, shall have no obligation to complete the EDL Line
nor the' water reclamation fa;-ilities; provided , however, that
. this release shall not release Developer from liability for fees
.. or cliarges, if any, for water reclamation facilities which are
uniformly applied to all property owners within the City or
within the drainage basin.
SECTION 7: COMPLETION OF' TAMARACK AVENUE RIGHT-OF-WAY
ACQU I S 1 TI ON AND I t.iP ROVEElENT
Anything contained herein to the contrary
notwithstanding, Developer shall remain responsible for
completing the acquisition of Tamarack Avenue right-of-way as
shown on Exhibit IIB" attached hereto and made a part hereof by
this reference, and for the improvement of same.
Developer's claim for reimbursement '.from other property
owners adjoining Tamarack Avenue shall be presented to the City
Council to be resolved by it and its decision shall be final.
That matter is not a part of this agreement.
SECTION 8: CREDIT FOR PAST EXPENDITURES
In consideration of the construction and transfer of
the Completed'Facilities, Developer shall receive a credit with
City in an amount equal to the audited and agreed upon costs
incurred by Developer to date, including construction interest,
in completing the facilities, in an amount of $2,859,951.
This credit will be avail.ablc to be drawn upon by Developer to
pay sewer connection fees for developriicnt within the Master Plan
Area .
6.
*. .
.-
I .:
..
SECTION 9 : CONNECTION FEES
The City agrees that- the sewer connection fee for up to
I
'
a total of 1,000 EDU's of capacity for any development on
property within the Master Plan Area owned by Pacific Scene, Inc.
shall be $1,000 per EDU. City will assign a portion of
Developer's credit balance in the amount of $1,000,.000, to be
, drawn upon by Pacific Scene, Inc. or their successors in
.. interest, to pay sewer connection fees. The sewer connection fee
.. for other developments on property in the Master Plan Area shall
be the fee generally applicable to development of the same type
i
elsewhere in the City's sewer service area.
Until such tiine as Developer's credit is exhausted,
City shall not issue sewer permits for development in'the master
. plan area to other than Developer without either written
assignment of credit or written notification from Developer that
c
sewer permits may issue without credit. peveloper, in
exercising his rights under this section, shall not requj.re
other developers to pay more for sewer capacity than the current
city charge.
SECTION 10: SUCCESSORS AND ASSIGNS
The covenants and agreements contained in this agreement
will be binding upon and insure to the benefit of City and its
SUCC~SSO~S and assigns, and Developer and its successors and
assigns; provided, however, Developer shall not convey, assign or
otherwise transfer its rights or obligations hereunder without
.the prior writtcn consent of the City. .. 7.
SECTION 11: ASSIGNMENT OF CREDIT __I
In the event Developer sells portions of bhe property
within the Master Plan Area to other parties who become the
developers thereof, the credits available pursuant to this
agreement may be assigned by Developer to satisfy the obligations
of such developments for the payment of'sewer connection fees.
. Such assignment shall be in writing to the.City indicating the
amount of such credit to be made available.
No assignment shall be made without prior written
approval of City.
assignments so as not to be required to account for multiple
assignees under circumstances which may create an administrative
burden for City.
City reserves the right to limit the
SECTION 12: RESERVATION OF I_ CAPACITY IN LCH s EWAG E TREAT;^! ENT v mwr
City shall reserve sewage treatment capacity in the Lake
Calavera Hills Sewage Treatment Plant for Developer to the extent
of 41.77% of the rated capacity of the plant. The parties
contemplate that the rated capacity of the plant may increase or
decrease as conditions change and that Developer's reserve
capacity may increase or decrease accordingly. Determination of
rated capacity for the purpose of this agreement shall be in the
sole discretion of the City Council. The parties understand that
this facility will not he available for use until the EDL line is
completed in its entirety.
LCII Plant docs not constitute r? guaranty that sewage treatmcnt
.s
.
This reservation of capacity in the
8. .
-will in fact be available to serve the Master Plan Area. Any
connections made from development in the Master Plan Area to the
Encina Tr.eatment Plant will be deducted from the EDU's reserved
for Developer at the Lake Calavera Hills Plant.
Capacity reserved for Developer shall'not be used for
any development other than development within the Master Plan
%
.I .. Area.
..
SECTION 13: DEVELOPMENT SUBJECT TO ORDINANCES
Nothing in this agreement shall exempt Developer from
any local building or zoning ordinances.
subject to any existing or future zoning, building or other laws
established or adopted by City to regulate the location,
quality, quantity, pace or other aspects of development in City.
Developer shall also be subject to all general plan requirements
of the City, including any proposals adopted to implement any
element of the general plan and to the Lake Calavera Hills
Developer shall be
..
Master Plan conditions.
SECTION 14: COMPLETION OF EDL LINE
The timing of the construction by the City of the EDL .
line shall be at the discretion of the City.
cont&nplates undertaking to complete the line under the same
terms and conditions as any other City capital improvement
The .. City
project. as dictated by the needs of the City and available
,
L
financing.
la
SECTION 15: DEVELOPER'S OPTION TO COMPLETE EDL LINE
A. .. DeVelOpeK I s OpCion :
If the City or Developer determines that sewer
service is not available to the Master Plan Area and it becomes
necessary for Developer to use the capacity reserved in the Lake
Calavcra Hills Plant to serve such area and if the City is not
prepared to construct the EDL line, Developer shall have the
option, subject to the terms of this section, to complete or
cause to be completed the EDL line. De'veloper shall notify City
in writing of his intention to elect to exercise this option and
secure the consent of City before proceeding. The actual cost of
completing the EDL line will he added .to Developer's credit with
the City.
B. Cost Estimate:
No later than the time of submission of the plans and
specifications, Developer shall submit a d'etailed itemized cost
estimate for the EDL line and an estimated completion date. City
shall act upon the cost estimate and completion date no later
than thirty days after submission of such estimate in a complete
and approvable form. Upon approval of such estimate and date by
the City, they shall become a part of this agreement.
-
C. Actual. Cost To Build The EDL Line: -,
Actual cost to build the EDL line shall mean the sum
total. dollar cost of actual expenditures for construction
including, but not limited to, labor, materials, plan checking,
10. LI
13
i
engineering, surveying, design, interest during the construction
period of the EDL line on borrowed funds necessary for the actual
-
construction of the EDL line, fees for applicable permits, costs
attributable to land, rightsyof-way or other interests in real
property necessary for the EDL line not to exceed the fair market
value at the time of acquisition or acc.eptance of the EDL line,
whichever is less, and other costs necessary for the construction
in a good workmanlike manner in accordance with the plans and
specifications, but not including any preliminary reports,
studies, attorney's fees or other such charges. Actual costs to
build the EDL line shall be documented to the 'satisfaction of the
City and shall be approved by the City' Council.
D. Cost Limitation:
The actual. cost to build the EDL line shall not exceed
the estimates as approved pursuant to Section 15(B) above. Any
difference between actual costs and the estimates shall be
absorbed by Devel-oper and shall be disregarded for purposes of
the credit.
extend past tee estimated completion date, construction interest
accruing after that date shall not be included as p.art of the
actual costs and shall be disregarded for purposes of the
credit.
Notwithstanding the fact that construction may
11. .
c
, --
E. Risk of Development Prior to Approval of Developer:
City shall have no obligation - to give Developer any -
credit until the cost estimates required by Section 15(B) are
approved,by City. Developer shall bear the full risk of any
loss occasioned to Developer-because it commenced construction
prior to approval of the estimates. Developer shall receive no
credit and shall have no recourse against the City for any loss
occasioned to Developer because the estimates were not approved
or the agreement was otherwise terminated by Developer prior to
completion and acceptance of the project by the City.
F. Cost Monitoring:
In addition to the rights stated elsewhere in this
agreement, City shall have the right to monitor a11 costs for
the project. DeVelGper shall provide City with all receipts,
*. invoices, bills or other information requested by City to aid in
the cost monitoring.
G. Construction Agreement-:
If Developer exercises his option and undertakes to
complete the EDL line, the following provisions of the Original
Agreement shall apply and shall become part of this agreement:
SECTION 2: DEVELOPER’S OBLIGATIONS
A. Construct.
C. Dedication.
* ..
..
D. Warranty.
E. Acquisition of rights-of-way.
r
i
.. 12. 3.
* F. Permits.
G. Inspection.
H. Compliance with laws.
I. Compliance with the Precise Development
Plan.
J. Other responsibilities prior to acceptance.
SECTION 4: CITY s OBLIGATIONS AND RIG'HTS
B. Acceptance.
C. Inspection.
D. Cooperation. ,
SECTION 8 : GENERAL CONSTRUCTION
SECTION 16: SUBJECT TO FEES
Developer and the Master Plan Area are subject to all
City fees of general application including, but not limited to,
sewer connection, sewer service, line extension, pumping plant
and water reclamation, on the same basis as other similarly
situated properties within the City's sewer service area, except
that Developer may draw upon his credit with the City to pay
sewer connection fees in accordance with this agreement.
SECTION 17: MISCELLANEOUS PROVISIONS
A. - Indeiiqity of City:
Developer shall indemnify, assume the defense of, and
hold free and harmless, City, its officers, agents, employees
and any engineer, architect or other consultant utilized by City
on the project front any and all obligations, liabilities, liens,
claims, deinands, J.osses, damages and expenses, of whatever type
or nature including, 'but not limited to, attorney's fees and all
litigation costs arising outbf Developer's design or
construction of the proposed facilities or any other act or
omission to act by Developer, its agents, servants, employees,
invitees, or independent contractor's which are required by this
<
agreement . r
Notwithstanding the foregoing, the indemnity agreement
created by this section shall not indemnify the City, its
officers, agents or employees against any liability arising from
the negligence or willful misconduct of City, its officers,
directors, agents, employees or independent contractors.
B. Developer not agent of City:
Neither Developer nor any of Developer's agents or Y
, contractors are or shall be considered to be agents of City in ..
connection with the performance of Developer's obligations under
this agreement. .
* C. Records:
City will maintain complete records of all connection
fees received. Such records shall be open to Developer upon
reasonable notice to City.
9
D. Payments on notices:
All notices, demands and requests which may be or are
required to be given or made by either party to the other party
shall bc in writing. All notices, demands and requests by
14.
.. - . c
I '7
.Developer to City shall be sent by United States registered
mail, postage prepaid, addre&ed to City as follows:
.. City Manager City of Carlsbad
1200 Elm Avenue Carlsbad, California 92008
All notices, demands, requests and payments by City to Developer
shall be sent by United States registered mail, postage prepaid,
addressed to Developer as follows:
..
.. . Lake Calavera Hills Associ.ates
1267 Elm Avenue, Suite D
Carlsbad, California 92008 Attn: Roy J. Ward
or to such other addressee and to such othe: plac as Develop r
may from time to time designate in wri.tten notice to City.
E. Arbitration of Disputes:
Any controversy or claim between the parties to this
agreement including, but not limited to, any claims, disputes,
.demands, differences, controversies, or misunderstandings
arising under, out of, or in relation to this agreement, or any
alleged breach of this agreement, shall be submitted to and
determined by arbitration in accordance with the California.
Arbitration provisions contained in Code of Civil Procedure
Section 1280 et seq., as amended from time to time, except as to
those determinations under this agreement made in the sole
discretion of the City or its Council.
*
15. .
Subject to the provisions of Code of Civil Procedure
Section 1296, the arbitrator or arbitrators shall determine the
rights of the parties in accordance with the law and the award
shall be subject to review as.to the arbitrator's application of
the law by any court having jurisdiction of the matter, whether
or not any mistake of the law shall app.ear upon the face of the
award. As to all questions of fact, however, the determination
. . of the arbitrator or arbitrators shall be binding upon all
parties and shall be deemed final and conclusive. Each party
shall be entitled to written findings of fact and conclusions of
law as to all issues determined by the award. Subject to the
above limitations, the award granted by the arbitrator shall be
binding upon all parties to the arbitration and judgment upon
the award rendered by the arbitrzltor or arbitrators may be
entered in any cour. having jurisdiction over the matter.
F. Notice of Taxable Possessorv Interest:
If this agreement results in the creation of a
possessory interest, and such possessory interest is vested in a
1'
private party in this document, the private party may be
subjected to the payment of personal property taxes levied on
such interest.
G. Antitrust Claims of Developer or Successors:
By entering into this agreement or any subcontract
pursuant to this agreement, Developer, each contractor, and each
subcontractor who performs work or who supplies goods, or
.
16.
materials in accordance with the terms of this agreement hereby
of€ers'and agrees to assign co City all rights, title, and
interest in and to a11 causes of action it may have under
feder'al or state antitrust law including, but not limited to,
antitrust action any of them may have under Section 4 of the
Clayton Act (15 U.S.C. Section 15) or under the Cartwright Act
(Chapter 2 commencing with Section 16700 of Part 2 of Division 7
_. of the Business and Professions Code), arising from the
purchases of goods, services or materia-1s pursuant to this
agreement or any related subcontract. This assignment is made
and becomes effective at the time City accepts'the proposed
facilities and land transfer without further acknowledgment of
the parties. Developer agrees to insure that a comparable
provision is included in all contracts or subcontracts at all
tier levels which are executed pursuant to this agreement.
H. Venue:
In the event of any legal
enforce the terms or conditions of
agree that ventie shall lie only in
or equitable proceeding to
this agreement, the parties
the federal or state courts
in or nearest to the North County Judicial District, County of
San Diego, State of California.
-
I, Modification: This agreement may not be altered in
whole or in part except by modification in writing, executed by
both parties to this agreement.
17. .. .
J. Attorney's Fees:
In the event any arbitration proceeding, administrative
proceeding or litigation in law or in equity, including any
action for declaratory relief, is brought to enforce or
interpret the provisions or performance of this agreement, the
prevailing party or parties shall be entitled to an award of
reasonable attorney's fees and costs associ.ated with the
proceeding as determined by the court, the presiding officer, or
the arbitrator authorized to make a determination of the issues
in addition to any other relief to which the prevailing party
may be entitled.
In the event opposing parties have each prevailed on
one or more causes of action actually contested or admitted by
pleadings, discovery or prehearing documents on file, the
arbitrator or presiding officer may offset such fees and costs
between prevailing parties after considering the necessity of
the proceeding and the importance of the issue or issues upon
which each party has prevailed.
K. I Right of City to Inspect.
Both parties to this agreement understand that City
intends to approve, or inspect and approve, all phases of design
and construction of the proposed facilities. Developer shall
supply City with such information as City deems necessary from
time to time in Cj.ty's sole discretion to proper1.y review all
design and construction phases of the contract and to provide
18.
City with the opportunity to inspect the proposed facilities
from time to time upon request.
#
I,. Section Headings and Interpretation:
All clauses contained in this agreement shall be
interpreted in a manner which renders them valid under
applicable provisions of state or federal law to the maximum
feasible extent. By Resolution No. 5871 the City Council, of
City, approved a Precise Development Plan for the development of
the sewage treatment facility and all necessary appurtenances.
The provisions of the Precise Development Plan as adopted by
,
Resolution No. 5871 shall prevacl over any inconsistent
provisions of this agreement.
The headings of sections herein are used for
convenience only and shall not affect the meaning or the
contents thereof. .
M. Approval. by City:
Except as otherwise expressly provided herein, approval
by City shall mean written approval by the City-Manager. -
N. Risk of rms:
Prior to acceptance of the project, the risk of loss
shall be on Developer.
19. . .
IN WITNESS FIHEREOF, the parties have executed this
agreement in duplicate as of the day and year above-written.
ATTEST:
ALETHA L. RAUTGNKKANZ ,
City Clerk
APPROVED AS TO FORM:
CITY OE' CARLSBAD, a municipal
corporation of the State of
'California
By- RONALD C. PACKARD, IJlayor
LAKE CALRVERA HILLS ASSOCIATES,
a California partnership
VINCENT F. BIONDO, JR., City Attorney
.
.
.)
20.
I..
t
3
2
z
4
E Y
E
7
E
9
1c
11
12
13
14
15
16
17
18
19
20
' 21
22
23
24
25
26
27
28
EIESOLUITON NO. 6663
A RESOLUI'ION OF THE CITY CO&XL OF THE-CITY OF CARLSBAD, CALIRIRNIA, APPROVING, WITX
CONDITIONS, A REVISION TO AN AGREEMENT E"
'ME CITY AND TAKE CATAVERA HIU ASSOCIATES DATED DE-ER 26, 1979, AND AUIXORIZING 'ME MAYOR To SIGN FOR THE CITY.
WHEREAS City and Developer have previously entered into a certain
agreent, dated Decder 26 , 1979, and entitled "Agreement Pletween City
of Carlsbad, California and Lake Calavera Hills Associates for Construction
of a 1.2 Million Gallon Capacity Sewage Treatmat and Waste Water Reclamation
Facility and Necessary Appurtenances and to Provide for the Financing and
Reinbursanent for Costs of Oversizing Thereof," and;
WHEREAS Developer has undertaken performance under said agreement and
has expended substantial sums of moey in furtherance of the agreemmt, and;
WKEREAS Developer has campleted construction of the sewage treabnent
facility and portions of the effluent disposal line and those facilities
are ready for delivery to and acceptance by the City, and;
WHEREAS by reascm of certain intervening cmideraticms, the parties
now agree that it is not in the best interests of either the City or
Developer to attempt to ccxnplete the agrement in accordance with its
terms, and;
WHEREAS the parties desire to effect a novation of the original
agreement and enter into a new agreemnt to establish their rights and
obligations, and;
WW the parties intend by this nv agreement to transfer all
completed facilities to the City, with dveloper receiving appropriate
credit for expenditures previously =de and appropriate reservations of
sewage treatment capacity in those facilities.
f //I
*. i . . . . .. . . . .. - . ___ -. . . . .
1
2
3
4
5
6
7
8
9
10
11
12
3.3
14
15
16
17
18
19
20
' 21
22
23
24
25
26
27
28
NCW, THEREFORE, BE IT WOLVED that the City Comcil of the City of
Carlsbad approves that revised agreement identified as Exhibit "A" attached
hereto and made a part hereof and aut-Szorizes the Mayor of the City of
Carlsbad to sign said agreement on behalf of d.le City shject to the
follcx-dng conditions:
1. Submission by the Developer and approval by the City of a mLnor
subdivisionmap creating the Treatment Plant Site as a separate lot, and;
2. Submission by the Developer and acceptance by the City of suitable
docuwntatim transferring ownership to the City of and land and improwments
for the Treatment Plant Site, the access road to the Treatment Plant Site,
the rights of way for the reversible force main and pmp statim, and such
rights as the Developer possesses in the EDL mntructed by the San Marcos
County Water District, and;
3. Certification by the City Engineer that all facilities being
transferred to the City are complete and operable and that a11 warranties on
equipment are in hand.
PASSED, APPR#ED AND ADOWED at a regular n-eeting of the City Council
day of Noven-ber of the City of Carlsbad, California, held on the 17th
1981, by the following vote, to wit:
AYES: Council Mahers Packard, Casler, Anear, Lewis and Kulchin
NOES : None
tC ATEST:
(..
1
2
3
4
5
6
7
a
io
9
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
27
28
RESOLUTION No. 6728
A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF CARLSBAD ACCEPTING TRABSFER OF
ONNERSHIP OF CAPACITY RIGHTS IN THE SAN MARCOS COUNTY IIATER DISTRICT TREATED EFFLUENT OUTFALL PIPELINE FROM LAKE CALAVERA HILLS ASSOCIATES TO THE CITY OF CARL S BAD
WHEREAS, a Memorandum of Understanding dated June 16, 1980 was entered
into between the San Marcos County Water District and certain developers in-
cluding Lake Calavera Hills Associates; and
NHEREAS, the Memorandum of Understanding provided for the oversizing
of the treated effluent outfall pipeline to provide capacity to developers
upon payment of their share of costs; and
.
NHEREAS, the stated intent of the Nemorandum of Understanding was that
the capacity funded by the developers owning land within Carlsbad would be
assigned to the City of Carlsbad who would, in cooperation with the San Marcos
County \later District, share in the cost of operating and maintaining the
capacity; and
WHEREAS, the City of Carlsbad has entered into an agreement with the
San Marcos County Yater District which provides for sharing the cost of
operating and maintaining the treated effluent outfall pipeline subject to
the transfer of ownership in the capacity rights therein from the individual
developers to the City; and
NHEREAS, Lake Calavera Hills Associates has agreed to transfer ownership
of its capacity rights in the San Marcos treated effluent outfall pipeline
to the City of Carlsbad;
/I/
//I
//I
//I
._.
b
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
27
28
NOW, THEREFORE, BE IT RESOLVED by the City Council of the City of
Carlsbad, as follows:
1.) The above recitations are true and correct.
2.) The City of Carlsbad agrees to accept Lake Calavera Hills Associates'
share of capacity rights in the San Marcos County Iiater District Treated
Effluent Outfall Pipeline free and clear of all liens and encumbrances.
3.) The Mayor of the City of Carlsbad is authorized to sign the agree-
ment accepting ownership in said capacity rights on behalf of the City.
PASSED, APPROVED AND ADOPTED at a regular meeting of the Carlsbad City
Council held on the 17th day of Navenber , 1981 by the following vote,
to wit:
AYES: Council Menhers Packard, Casler, hear, LaJis and Kulchin
NOES: None
ABSENT: None
pAY/&kq
RONALD C. PACKARD, MAYOR
ATTEST:
ALETHA L-.-RAUTENKRANZ , CITY CLERK
(SEAL)