Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
2015-07-28; City Council; 22045; Approving for Bids Synthetic Turf Aviara Park Soccer Field PKS16-02PKS
AB# MTG. DEPT. 22,Q4fr 7/28/15 P&R CITY OF CARLSBAD-AGENDA BILL ADOPT RESOLUTION APPROVING CONTRACT DOCUMENTS, PLANS, PROVISIONS AND SPECIFICATIONS, AND AUTHORIZING THE CITY CLERK TO ADVERTISE FOR BIDS THE REPLACEMENT OF THE SYNTHETIC TURF AT AVIARA COMMUNITY PARK SOCCER FIELD-CONTRACT NO. PKS16-02PKS DEPT. DIRECTOR CITY ATTY. CITVMGR. RECOMMENDED ACTION: Adopt Resolution No. 2015-199 approving contract documents, plans, provisions and 4 specifications, and authorizing the City Clerk to advertise for bids the replacement of the synthetic turf at the Aviara Community Park soccer field-Contract No. PKS16-02PKS. ITEM EXPLANATION: The existing synthetic turf soccer field at Aviara Community Park is almost 10 years old and is in need of replacement due to age and wear. The existing synthetic turf has surpassed its 8 year warranty period and its expected useful life. The heavy use of this soccer field over nearly the last decade has resulted in corresponding splits/tears and diminished overall quality of the synthetic turf. This replacement project includes removal of the existing synthetic turf from the soccer field, minor re- grading and re-compaction of the subsurface, and installation of a new high quality synthetic turf. The new synthetic turf is expected to meet the high usage demand of this field, and last at least another decade. The overall playability of the field will be considerably enhanced as a result of this project. ENVIRONMENTAL IMPACT This project has been determined to be exempt from environmental review per CEQA Guidelines Section 15301, minor alteration of existing facilities. FISCAL IMPACT: Funding for this project, in the amount of $867,412, was appropirated from the Infrastructure Replacement Fund in the FV 2015/16 Capital Improvement Program Budget. Maintenance costs for the field are expected to be reduced with the new synthetic turf, due to the fact that the repair of most splits/tears will be covered under a normal use warranty. EXHIBITS: 1. Resolution No. 2015-199 approving contract documents, plans, provisions and specifications, and authorizing the City Clerk to advertise for bids the replacement of the synthetic turf at the Aviara Community Park soccer field-Contract No. PKS16-02PKS. 2. Contract documents, plans, provisions and specifications for the replacement of the synthetic turf at the Aviara Community Park soccer field are on file at parks & recreation administration. DEPARTMENT CONTACT: Kyle Lancaster, 760-434-2941, kyle.lancaster@carlsbadca.gov FOR CLERK USE. ri COUNCIL ACTION: APPROVED CONTINUED TO DATE SPECIFIC D DENIED D CONTINUED TO DATE UNKNOWN D CONTINUED D RETURNED TO STAFF D WITHDRAWN D OTHER-SEE MINUTES D AMENDED D REPORT RECEIVED D c~=-=---~ _ _____c _______ ~ ------~~~- mm 1 RESOLUTION NO. 2015-199 3 2 A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF CARLSBAD, CALIFORNIA, APPROVING CONTRACT DOCUMENTS, PLANS, PROVISIONS AND SPECIFICATIONS, AND AUTHORIZING THE CITY 4 CLERK TO ADVERTISE FOR BIDS THE REPLACEMENT OF THE SYNTHETIC TURF AT THE AVIARA COMMUNITY PARK SOCCER 5 FIELD - CONTRACT NO. PKS16-02PKS 6 16 17 18 19 20 J WHEREAS, the contract documents, plans, provisions and specifications for the 8 furnishing of all labor, material and equipment necessary to replace the synthetic turf at the Aviara Community Park soccer field have been prepared, are on file in the parks & recreation administration office, and are incorporated by reference herein; and WHEREAS, the existing synthetic turf soccer field at Aviara Community Park is almost 10 years old and is in need of replacement due to age and wear; and 9 10 11 12 13 14 WHEREAS, the existing synthetic turf has surpassed its 8 year warranty period and its 15 expected useful life; and WHEREAS, the heavy use of this soccer field over nearly the last decade plus has resulted in corresponding splits/tears and diminished overall quality ofthe synthetic turf WHEREAS, this replacement project includes removal ofthe existing synthetic turf from the soccer field, minor re-grading and re-compaction of the subsurface, and installation of a 21 new high quality synthetic turf; and 22 WHEREAS, the new synthetic turf is expected to meet the high usage demand of this 23 field, and last at least another decade; and 24 WHEREAS, the overall playability ofthe field will be considerably enhanced as a result of 25 this project; and 26 27 28 1 WHEREAS, sufficient funds are available for this project in the Capital Improvement 2 Program Budget from the Infrastructure Replacement Fund. 3 NOW, THEREFORE, BE IT RESOLVED by the City Council of the City of Carlsbad, 4 5 California, as follows that: 6 1. The above recitations are true and correct. 7 2. The contract documents, plans, provisions and specifications for the 8 replacement of the synthetic turf at the Aviara Community Park soccer field as 9 referenced hereto are hereby approved. 10 3. That the City Clerk of the City of Carlsbad is hereby authorized and directed to 11 proceed to publish, in accordance with law. Notice Inviting Bids for the work of 12 proceed to publish, in accordance with law. Notice Inviting Bids for the work of 13 said contract documents, plans, provisions and specifications. 14 // 15 // 16 // 17 // 18 // 19 // 20 // 21 // 22 // 23 // 23 // 24 // 25 26 27 28 3 1 PASSED, APPROVED AND ADOPTED at a Regular Meeting of the City Council of the City 2 of Carlsbad on the 28th day of July, 2015, by the following vote to wit: 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 AVES: Council Members Hall, Blackburn, Schumacher, Wood, Packard. NOES: None. ABSENT: None. MATT HALL, Mayor ATTEST: ~~~~ RBARA ENGLESO 1ty Clerk (SEAL) EXHIBIT 2 CITY OF CARLSBAD San Diego County California CONTRACT DOCUMENTS, GENERAL PROVISIONS, SUPPLEMENTAL PROVISIONS, AND TECHNICAL SPECIFICATIONS FOR AVIARA COMMUNITY PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS 6 TABLE OF CONTENTS Item Page Notice Inviting Bids 1 Contractor's Proposal 5 Bid Security Form 10 Bidder's Bond to Accompany Proposal 11 Guide for Completing the "Designation of Subcontractors" Form 13 Designation of Subcontractor and Amount of Subcontractor's Bid Items 15 Bidder's Statement of Technical Ability and Experience 16 Bidder's Certificate of Insurance for General Liability, Employers' Liability, Automotive Liability and Workers' Compensation 17 Bidder's Statement Re Debarment 18 Bidder's Disclosure of Discipline Record 19 Non-collusion Declaration to Be Executed by Bidder and Submitted with Bid 21 Contract Public Works 22 Labor and Materials Bond 28 Faithful Performance/Warranty Bond 30 Optional Escrow Agreement for Surety Deposits in Lieu of Retention 32 Revised 07/17/2015 Contract No. PKSI6-02PKS GENERAL PROVISIONS Section 1 Terms, Definitions Abbreviations and Symbols 1-1 Terms 35 1-2 Definitions 36 1-3 Abbreviations 40 1-4 Units of Measure 43 1- 5 Symbols 44 Section 2 Scope and Control of the Work 2- 1 Award and Execution of Contract 45 2-2 Assignment 45 2-3 Subcontracts 45 2-4 Contract Bonds 46 2-5 Plans and Specifications 47 2-6 Work to be Done 50 2-10 Authority of Board and Engineer 50 2- 11 Inspection 51 Section 3 Changes in Work 3- 1 Changes Requested by the Contractor 52 3-2 Changes Initiated by the Agency 52 3-3 Extra Work 53 3-4 Changed Conditions 55 3- 5 Disputed Work 56 Section 4 Control of Materials 4- 1 Materials and Workmanship 60 4- 2 Materials Transportation, Handling and Storage 64 Section 5 Utilities 5- 1 Location 65 5-2 Protection 65 5-3 Removal 65 5-4 Relocation 65 5-5 Delays 66 5- 6 Cooperation 67 Section 6 Prosecution, Progress and Acceptance of the Work 6- 1 Construction Schedule and Commencement of Work 68 6-2 Prosecution of Work 70 6-3 Suspension of Work 70 6-4 Default by Contractor 70 6-5 Termination of Contract 71 6-6 Delays and Extensions of Time 71 6-7 Time of Completion 72 6-8 Completion, Acceptance, and Warranty 72 6-9 Liquidated Damages 72 6- 10 Use of Improvement during Construction 73 Section 7 Responsibilities of the Contractor 7- 1 Contractor's Equipment and Facilities 74 0 Revised 07/17/2015 Contract No. PKS16-02PKS 7-2 Labor 74 7-3 Liability Insurance.. 74 7-4 Workers' Compensation Insurance 74 7-5 Permits 74 7-6 The Contractor's Representative 75 7-7 Cooperation and Collateral Work 75 7-8 Project Site Maintenance 75 7-9 Protection and Restoration of Existing Improvements 77 7-10 Public Convenience and Safety 77 7-11 Patent Fees or Royalties 78 7-12 Advertising 78 7-13 Laws to be Observed 78 7- 14 Antitrust Claims 79 Section 8 Facilities for Agency Personnel 8- 1 General 80 Section 9 Measurement and Payment 9- 1 Measurement of Quantities for Unit Price Work 81 9-2 Lump Sum Work 81 9-3 Payment 81 SUPPLEMENTAL PROVISIONS TO PART 3 OF THE SSPWC PART 3 Construction Methods 300-9 Geotextiles for Erosion Control and Water Pollution Control 84 Appendix A Technical Specifications 86 Revised 07/17/15 Contract No. PKS16-02PKS CITY OF CARLSBAD, CALIFORNIA NOTICE INVITING BIDS Until 2:00 PM on September 24, 2015, the City shall accept sealed bids, clearly marked as such, at the Faraday Center, 1635 FaradayAvenue, Carisbad, CA 92008-7314, Attn: Purchasing Officer, by mail, delivery service or by deposit in the Bid Box located in the first floor lobby, at which time they will be opened and read, for performing the work as follows: Synthetic Turf Replacement at Aviara Community Park in Carisbad, CA. AVIARA COMMUNITY PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS INSTRUCTIONS TO BIDDERS AND BID REQUIREMENTS This bid and the terms of the Contract Documents and General Provisions constitute an irrevocable offer that shall remain valid and in full force for a period of 90 days and such additional time as may be mutually agreed upon by the City of Carisbad and the Bidder. No bid will be received unless it is made on a proposal form furnished by the Purchasing Department. Each bid must be accompanied by security in a form and amount required by law. The bidder's security of the second and third next lowest responsive bidders may be withheld until the Contract has been fully executed. The security submitted by all other unsuccessful bidders shall be returned to them, or deemed void, within ten (10) days after the Contract is awarded. Pursuant to the provisions of law (Public Contract Code section 10263), appropriate securities may be substituted for any obligation required by this notice or for any monies withheld by the City to ensure performance under this Contract. Section 10263 of the Public Contract Code requires monies or securities to be deposited with the City or a state or federally chartered bank in California as the escrow agent. The escrow agent shall maintain insurance to cover negligent acts and omissions of the agent in connection with the handling of retentions under this section in an amount not less than $100,000 per contract. The City of Carisbad may disqualify a contractor or subcontractor from participating in bidding when a contractor or subcontractor has been debarred by the City of Carisbad or another jurisdiction in the State of California as an irresponsible bidder. The work shall be performed in strict conformity with the plans, provisions, and specifications as approved by the City Council of the City of Carisbad on file with the Purchasing Department. The specifications for the work include City of Carisbad Technical Specifications and the Standard Specifications for Public Works Construction, Parts 2 & 3, 2012 Edition, all hereinafter designated "SSPWC", as amended. Specification Reference is hereby made to the plans and specifications for full particulars and description of the work. The General Provisions (Part 1) to the SSPWC do not apply. Revised 07/17/2015 Contract No. PKS16-02PKS 1 of 86 The City of Carisbad encourages the participation of minority and women-owned businesses. The City of Carisbad encourages all bidders, suppliers, manufacturers, fabricators and contractors to utilize recycled and recyclable materials when available, appropriate and approved by the Engineer. BID DOCUMENTS The bid documents comprise the following documents which must be completed and properly executed including notarization, where indicated. 1. Contractor's Proposal 2. Bidder's Bond 3. Non-collusion Declaration 4. Designation of Subcontractor and Amount of Subcontractor's Bid 5. Bidder's Statement of Technical Ability and Experience 6. Acknowledgement of Addendum (A) 7. Certificate of Insurance. The riders covering the City, its officials, employees and volunteers may be omitted at the time of bid submittal but shall be provided by the Bidder prior to award of this contract. 8. Bidder's Statement Re Debarment 9. Bidder's Disclosure of Discipline Record 10. Escrow Agreement for Security Deposits - (optional, must be completed if the Bidder wishes to use the Escrow Agreement for Security) 11. Required Submittal Information Checklist (Inclusive) ENGINEER'S ESTIMATE: All bids will be compared on the basis of the Engineer's Estimate. The estimated quantities are approximate and serve solely as a basis for the comparison of bids. The Engineer's Estimate is $800,000.00 TIME OF COMPLETION: The contractor shall complete the Work within the time set in the contract as defined in the General Provisions Section 6-7. SPECIALTY CONTRACTORS: ACCEPTABLE LICENSE TYPES Except as provided herein a bid submitted to the City by a Contractor who is not licensed as a contractor pursuant to the Business and Professions Code shall be considered nonresponsive and shall be rejected by the City. In all contracts where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder to be licensed in accordance with California law. Where federal funds are involved the contractor shall be properly licensed at the time the contract is awarded. In all other cases the contractor shall state their license number, expiration date and classification in the proposal, under penalty of perjury. This invitation to bid does not involve federal funds. The following classifications are acceptable for this contract: A - General Engineering Contractor and D-12 - Synthetic Products Contractor. ESCROW AGREEMENT If the Contractor intends to utilize the escrow agreement included in the contract documents in lieu of the usual 5% retention from each payment, these documents must be completed and submitted with the signed contract. The escrow agreement may not be substituted at a later date. OBTAINING PLANS OND SPECIFICATIONS Sets of plans, various supplemental provisions, and Contract documents may be obtained at the Cashier's Counter of the Faraday Center located at 1635 Faraday Avenue, Carisbad, California 92008-7314, for a non-refundable fee of (Twenty-five Dollars) $25.00 per set. If plans and /\ \o Revised 07/17/2015 Contract No. PKS16-02PKS 2 of 86 specifications are to be mailed, the cost for postage should be added. INTENT OF PLANS AND SPECIFICATIONS Any prospective bidder who is in doubt as to the intended meaning of any part of the drawings, specifications or other contract documents, or finds discrepancies in or omissions from the drawings and specifications may submit to the Engineer a written request for clarification or correction. Any response will be made only by a written addendum duly issued by the Engineer a copy of which will be mailed or delivered to each person receiving a set of the contract documents. No oral response will be made to such inquiry. Prior to the award of the contract, no addition to, modification of or interpretation of any provision in the contract documents will be given by any agent, employee or contractor of the City of Carlsbad except as hereinbefore specified. No bidder may rely on directions given by any agent, employee or contractor of the City of Carlsbad except as hereinbefore specified. REJECTION OF BIDS The City of Carisbad reserves the right to reject any or all bids and to waive any minor irregularity or informality in such bids. THE PAYMENT OF PREVAILING WAGES IS NOT REQUIRED The City of Carisbad is a Charter City. Carlsbad Municipal Code Section 3.28.130 supersedes the provisions of the California Labor Code when the public work is not a statewide concern. The City Council has determined that it is not in the best interest of the city to require the payment of prevailing wages for this project. Payment of prevailing wages is at contractor's discretion. PRE BID MEETING A MANDATORY pre-bid meeting will be held on September 1, 2015 at 11:00 AM at Aviara Community Park, 6440 Ambrosia Lane, Carisbad CA in the City of Carisbad. UNiT PRICES AND COMPUTATION OF BIDS All bids are to be computed on the basis of the given estimated quantities of work, as indicated in this proposal, times the unit price as submitted by the bidder, or a lump sum. In case of a discrepancy between words and figures, the words shall prevail. |n case of an error in the extension of a unit price, the corrected extension shall be calculated and the bids will be computed as indicated above and compared on the basis of the corrected totals. All prices must be in ink or typewritten. Changes or corrections may be crossed out and typed or written in with ink and must be initialed in ink by a person authorized to sign for the Contractor. ADDENDUMS Bidders are advised to verify the issuance of all addenda and receipt thereof one day prior to bidding. Submission of bids without acknowledgment of addenda may be cause of rejection of bid. BOND AND INSURANCE REQUIREMENTS The Contractor shall provide bonds to secure faithful performance and warranty of the work in an amount equal to one hundred percent (100%) of the Contract price on this project. The Contractor shall provide bonds to secure payment of laborers and materials suppliers, in an amount equal to one hundred percent (100%) ofthe total amount payable by the terms ofthe contract. These bonds shall be kept in full force and effect during the course of this project, and shall extend in full force and effect and be retained by the City until they are released as stated in the General Provisions section of this contract. All bonds are to be placed with a surety insurance carrier admitted and authorized to transact the business of insurance in California and whose assets exceed their liabilities in an amount equal to or in excess of the amount of the bond. The bonds are to be accompanied by the following documents: 1) An original, or a certified copy, of the unrevoked appointment, power of attorney, by laws, or other instrument entitiing or authorizing the person who executed the bond to do so. 2) A certified copy of the certificate of authority of the insurer issued by the insurance ^•''Revised 07/17/2015 Contract No. PKS16-02PKS 3 of 86 commissioner. If the bid is accepted, the City may require copies of the insurer's most recent annual statement and quarteriy statement filed with the Department of Insurance pursuant to Article 10 (commencing with section 900) of Chapter 1 of Part 2 of Division 1 of the Insurance Code, within 10 calendar days of the insurer's receipt of a request to submit the statements. Insurance is to be placed with insurers that: 1) Have a rating in the most recent Best's Key Rating Guide of at least A-:VII 2) Are admitted and authorized to transact the business of insurance in the State of California by the Insurance Commissioner. Auto policies offered to meet the specification of this contract must: 1) Meet the conditions stated above for all insurance companies. 2) Cover anv vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. Workers' compensation insurance required under this contract must be offered by a company meeting the above standards with the exception that the Best's rating condition is waived. The City does accept policies issued by the State Compensation Fund meeting the requirement for workers' compensation insurance. The Contractor shall be required to maintain insurance as specified in the Contract. Any additional cost of said insurance shall be included in the bid price. The award of the contract by the City Council is contingent upon the Contractor submitting the required bonds and insurance, as described in the contract, within twenty days of bid opening. If the Contractor fails to comply with these requirements, the City may award the contract to the second or third lowest bidder and the bid security ofthe lowest bidder may be forfeited. BUSINESS UCENSE The prime contractor and all subcontractors are required to have and maintain a valid City of Carlsbad Business License for the duration of the contract. Approved by the City Council of the City of Carisbad, California, by Resolution No. , adopted on the day of ^ , 20 . Date Deputy Qty Clerk Revised 07/17/2015 Contract No. PKS16-02PKS 4 of 86 CITY OF CARLSBAD AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS CONTRACTOR'S PROPOSAL City Council City of Carlsbad 1200 Carlsbad Village Drive Carlsbad, California 92008 The undersigned declares he/she has carefully examined the location of the work, read the Notice Inviting Bids, examined the Plans, Specifications, General Provisions, Contract Documents, and addenda thereto, and hereby proposes to furnish all labor, materials, equipment, transportation, and services required to do all the work to complete Contract No. PKS16-02PKS in accordance with the Plans, Specifications, General Provisions, Contract Documents, and addenda thereto and that he/she will take in full payment therefore the following unit prices for each item complete, to wit: AVIARA PARK SYNTHETIC TURF REPLACEMENT Approximate Item Quantity Unit Price Total Amount No. Description And Unit (Fiaures) (Figures) A-1 Aviara Park Synthetic Turf LS Replacement Total amount of bid in words for Schedule "A": Total amount of bid in numbers for Scheduie "A-1": $ A-2 SWPPP Plan and LS $ 15,000.00 $ 15.000.00 implementation including plan preparation, filing ofthe plan, maintenance of the plan and implementation of required elements throughout Construction. Total amount of bid in words for Schedule "A-2": Fifteen Thousand and no/100. Total amount of bid in numbers for Schedule "A-2": $ $15.000.00 The basis of award will be the sum of Schedule "A-1" and "A-2" to the extent monies are available only. Revised 07/17/2015 Contract No. PKS16-02PKS 5 of 86 Price(s) given above are firm for 90 days after date of bid opening. Addendum(a) No(s). ^ has/have been received and is/are included in this proposal. The Undersigned has carefully checked all of the above figures and understands that the City will not be responsible for any error or omission on the part of the Undersigned in preparing this bid. The Undersigned agrees that in case of default in executing the required Contract with necessary bonds and insurance policies within twenty (20) days from the date of award of Contract by the City Council of the City of Carisbad, the City may administratively authorize award of the contract to the second or third lowest bidder and the bid security of the lowest bidder may be forfeited. The Undersigned bidder declares, under penalty of perjury, that the undersigned is licensed to do business or act in the capacity of a contractor within the State of California, validly licensed under license number , classification which expires on , and that this statement is true and correct and has the legal effect of an affidavit A bid submitted to the City by a Contractor who is not licensed as a contractor pursuant to the Business and Professions Code shall be considered nonresponsive and shall be rejected by the City § 7028.15(e). In all contracts where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder to be licensed in accordance with California law. However, at the time the contract is awarded, the contractor shall be properly licensed. The Undersigned bidder hereby represents as follows: 1. That no Council member, officer agent, or employee of the City of Carisbad is personally interested, directly or indirectly, in this Contract, or the compensation to be paid hereunder; that no representation, oral or in writing, of the City Council, its officers, agents, or employees has inducted him/her to enter into this Contract, excepting only those contained in this form of Contract and the papers made a part hereof by its terms; and 2. That this bid is made without connection with any person, firm, or corporation making a bid for the same work, and is in all respects fair and without collusion or fraud. Accompanying this proposal is _(Cash, Certified Check, Bond or Cashier's Check) for ten percent (10%) ofthe amount bid. The Undersigned is aware of the provisions of section 3700 of the Labor Code which requires every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and agrees to comply with such provisions before commencing the performance of the work of this Contract and continue to comply until the contract is complete. Revised 07/17/2015 Contract No. PKS16-02PKS 6 of 86 IF A SOLE OWNER OR SOLE CONTRACTOR SIGN HERE: (1) Name under which business is conducted (2) Signature (given and surname) of proprietor (3) Place of Business City and State (4) Zip Code Telephone No. (5) E-Mail (Street and Number) IF A PARTNERSHIP, SIGN HERE: (1) Name under which business is conducted. (2) Signature (given and surname and character of partner) (Note: Signature must be made by a general partner) (3) Place of Business. City and State (4) Zip Code (5) E-Mail (Street and Number) Telephone No. Revised 07/17/2015 Contract No. PKS16-02PKS ft 7 of 86 IF A CORPORATION, SIGN HERE: (1) Name under which business is conducted (2), (Signature) (Title) Impress Corporate Seal here (3) Incorporated under the laws ofthe State of. (4) Place of Business (Street and Number) City and State (5) Zip Code Telephone No. (6) E-Mail NOTARIAL ACKNOWLEDGMENT OF EXECUTION BY ALL SIGNATORIES MUST BE ATTACHED List below names of president, vice president, secretary and assistant secretary, if a corporation; If a partnership, list names of all general partners, and managing partners: •F^ Revised 07/17/2015 Contract No. PKS16-02PKS 8 of 86 BID SECURITY FORM (Check to Accompany Bid) AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS (NOTE: The following form shall be used if check accompanies bid.) Accompanying this proposal is a *Certified *Cashiers check payable to the order of CITY OF CARLSBAD, in the sum of dollars ($ ), this amount being ten percent (10%) of the total amount of the bid. The proceeds of this check shall become the property of the City provided this proposal shall be accepted by the City through action of its legally constituted contracting authorities and the undersigned shall fail to execute a contract and furnish the required Performance, Warranty and Payment Bonds and proof of insurance coverage within the stipulated time; otherwise, the check shall be returned to the undersigned. The proceeds of this check shall also become the property of the City if the undersigned shall withdraw his or her bid within the period of fifteen (15) days after the date set for the opening thereof, unless otherwise required by law, and notwithstanding the award of the contract to another bidder. BIDDER Delete the inapplicable worid. (NOTE: If the Bidder desires to use a bond instead of check, the Bid Bond fonn on the following pages shall be executed-the sum of this bond shall be not less than ten percent (10%) of the total amount of the bid.) •F^Revised 07/17/2015 Contract No. PKS16-02PKS 9 of 86 BIDDER'S BOND TO ACCOMPANY PROPOSAL AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS KNOW ALL PERSONS BY THESE PRESENTS: That we, , as Principal, and as Surety are held and firmly bound unto the City of Carisbad, California, in an amount as follows: (must be at least ten percent (10%) of the bid amount) for which payment, well and truly made, we bind ourselves, our heirs, executors and administrators, successors or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH that if the proposal ofthe above- bounden Principal for: AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS in the City of Carisbad, is accepted by the City Council, and if the Principal shall duly enter into and execute a Contract including required bonds and insurance policies within twenty (20) days from the date of award of Contract by the City Council of the City of Carisbad, being duly notified of said award, then this obligation shall become null and void; otherwise, it shall be and remain in full force and effect, and the amount specified herein shall be forfeited to the said City. •F Revised 07/17/2015 Contract No. PKS16-02PKS 10 of 86 In the event Principal executed this bond as an individual, it is agreed that the death of Principal shall not exonerate the Surety from its obligations under this bond. Executed by PRINCIPAL this. PRINCIPAL: (name of Principal) By: (sign here) (print name here) day of. 20_ Executed by SURETY this of , 20_ SURETY: (name of Surety) day (Titie and Organization of Signatory) By: (sign here) (print name here) (address of Surety) (telephone number of Surety) By:_ (signature of Attorney-in-Fact) (titie and organization of signatory) (printed name of Attorney-in-Fact) (Attach corporate resolution showing current power of attorney.) (Proper notarial acknowledgment of execution by PRINCIPAL and SURETY must be attached.) (President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under corporate seal empowering that officer to bind the corporation.) APPROVED AS TO FORM: CELIA A. BREWER City Attorney By:. Assistant City Attorney Revised 07/17/2015 Contract No. PKS16-02PKS 11 of 86 GUIDE FOR COMPLETING THE "DESIGNATION OF SUBCONTRACTORS" FORM REFERENCES Prior to preparation of the following "Subcontractor Disclosure Form" Bidders are urged to review the definitions in section 1-2 of the General Provisions to this Contract, especially, "Bid", "Bidder", "Contract", "Contractor", "Contract Price", "Contract Unit Price", "Engineer", "Own Organization", "Subcontractor", and "Work". Bidders are further urged to review sections 2-3 SUBCONTRACTS of the General Provisions. CAUTIONS This form will be used by the Agency to determine the percentage of work that the Bidder proposes to perform. Bidders are cautioned that failure to provide complete and correct information may result in rejection of the bid as non-responsive. Any bid that proposes performance . of more than 50 percent of the work by subcontractors or otherwise to be performed by forces other than the Bidder's own organization will be rejected as non-responsive. Specialty items of work that may be so designated by the Engineer on the "Contractor's Proposal" are not included in computing the percentage of work proposed to be performed by the Bidder. INSTRUCTIONS The Bidder shall set forth the name and location of business of each and every subcontractor whom the Bidder proposes to perform work or labor or render service in or about the work or improvement, and every subcontractor licensed as a contractor by the State of California whom the Bidder proposes to specially fabricate and install any portion of the work or improvement according to detailed drawings contained in the plans and specifications in excess of one-half of one percent (0.5%) of the Bidder's total bid or, in the case of bids or offers for the construction of streets and highways, including bridges, in excess of one-half of one percent (0.5%) or ten thousand dollars ($10,000) whichever is greater. Said name(s) and location(s) of business of subcontractor(s) shall be set forth and included as an integral part of the bid offer. The Designation of Subcontractors form must be submitted as a part of the Bidder's sealed bid. Failure to provide complete and correct information may result in reiection of the bid as non- responsive. Suppliers of materials from sources outside the limits of work are not subcontractors. The value of materials and transport of materials from sources outside the limits of work, as shown on the plans, shall be assigned to the Contractor or the Subcontractor as the case may be, that the Bidder proposes as installer of said materials. The value of material incorporated in any Subcontractor- installed bid item that is supplied by the Bidder shall be included as a part of the work that the Bidder proposes to be performed by the Subcontractor installing said item. When a Subcontractor has a Carisbad business license, the number must be entered on the proper form. If the Subcontractor does not have a valid business license, enter "NONE" in the appropriate space. When the Bidder proposes using a Subcontractor to construct or install less than 100 percent of a bid item, the Bidder shall attach an explanation sheet to the Designation of Subcontractor form. The explanation sheet shall clearly apprise the City of the specific facts that show the Bidder proposes to perform no less than fifty percent (50%)) of the work with its own forces. Determination of the subcontract amounts for purposes of award of the contract shall be determined by the City Council in conformance with the provisions of the contract documents and the various supplemental provisions. The decision ofthe City Council shall be final. ' Revised 07/17/2015 Contract No. PKS16-02PKS 12 of 86 Contractor is prohibited from performing any work on this project with a subcontractor who is ineligible to perform work on a public works project pursuant to Labor Code Sections 1771.1 or 1777.7. Bidders shall make any additional copies of the disclosure forms as may be necessary to provide the required information. The page number and total number of additional form pages shall be entered in the location provided on each type of form so duplicated. ^¥ Revised 07/17/2015 Contract No. PKS16-02PKS 13 of 86 DESIGNATION OF SUBCONTRACTOR AND AMOUNT OF SUBCONTRACTOR'S BID ITEMS (To Accompany Proposal) AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS The Bidder certifies that it has used the sub-bid of the following listed subcontractors in preparing this bid for the Work and that the listed subcontractors will be used to perform the portions of the Work as designated in this list in accordance with applicable provisions of the specifications and section 4100 et seq. ofthe Public Contract Code, "Subletting and Subcontracting Fair Practices Act." The Bidder further certifies that no additional subcontractor will be allowed to perform any portion of the Work in excess of one-half of one percent (0.5%) of the Bidder's total bid, or in the case of bids or offers for construction of streets and highways, including bridges, in excess of one-half of one percent (0.5%) or ten thousand dollars ($10,000), whichever is greater, and that no changes in the subcontractors listed work will be made except upon the prior approval of the Agency. SUBCONTRACTOR'S BID ITE IVIS Portion of Work Subcontractor Name and Location of Business Subcontractor's License No. and Classification* Amount of Work by Subcontractor in Dollars* Page. of pages of this Subcontractor Designation form Pursuant to section 4104 (a)(2)(A) California Public Contract Code, receipt of the information preceded by an asterisk may be submitted by the Bidder up to 24 hours after the deadline for submitting bids contained In the "Notice Inviting Bids." '^Revised 07/17/2015 Contract No. PKS16-02PKS 14 of 86 BIDDER'S STATEMENT OF TECHNICAL ABILITY AND EXPERIENCE (To Accompany Proposal) AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTFIACT NO. PKS16-02PKS The Bidder is required to state what work of a similar character to that included in the proposed Contract he/she has successfully performed and give references, with telephone numbers, which will enable the City to judge his/her responsibility, experience and skill. An attachment can be used. Date Contract Completed Name and Address of the Employer Name and Phone No. of Person to Contract Type of Work Amount of Contract Revised 07/17/2015 Contract No. PKS16-02PKS 15 of 86 IPEI]BIDDER'S CERTIFICATE OF INSURANCE FOR GENERAL LIABILITY, EMPLOYERS' LIABILITY, AUTOMOTIVE LIABILITY AND WORKERS' COMPENSATION (To Accompany Proposal) AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS As a required part qf the Bidder's proposal the Bidder must attach either of the following to this page. 1) Certificates of insurance showing conformance with the requirements herein for each of: • Comprehensive General Liability • Automobile Liability • Workers Compensation • Employer's Liability 2) Statement with an insurance carrier's notarized signature stating that the carrier can, and upon payment of fees and/or premiums by the Bidder, will issue to the Bidder Policies of insurance for Comprehensive General Liability, Automobile Liability, Workers Compensation and Employer's Liability in conformance with the requirements herein and Certificates of insurance to the Agency showing conformance with the requirements herein. All certificates of insurance and statements of willingness to issue insurance for auto policies offered to meet the specification of this contract must: 1) Meet the conditions stated in The Notice Inviting Bids and the General Provisions for this project for each insurance company that the Contractor proposes. 2) Cover anv vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. 1^Revised 07/17/2015 Contract No. PKS16-02PKS 16 of 86 BIDDER'S STATEMENT RE DEBARMENT (To Accompany Proposal) AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS 1) Have you or any of your subcontractors ever been debarred as an irresponsible bidder by another jurisdiction in the State of California? yes no 2) If yes, what was/were the name(s) of the agency(ies) and what was/were the period(s) of debarment(s)? Attach additional copies of this page to accommodate more than two debar- ments. party debarred party debarred agency agency period of debarment period of debarment BY CONTRACTOR: By: (name of Contractor) (sign here) (print name/titie) Page. of pages of this Re Debarment form Revised 07/17/2015 Contract No. PKS16-02PKS 7-^ 17 of 86 BIDDER'S DISCLOSURE OF DISCIPLINE RECORD (To Accompany Proposal) AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS Contractors are required by law to be licensed and regulated by the Contractors' State License Board which has jurisdiction to investigate complaints against contractors if a complaint regarding a patent act or omission is filed within four years of the date of the alleged violation. A complaint regarding a latent act or omission pertaining to structural defects must be filed within 10 years ofthe date ofthe alleged violation. Any questions concerning a contractor may be referred to the Registrar, Contractors' State License board, P.O. Box 26000, Sacramento, California 95826. 1) Have you ever had your contractor's license suspended or revoked by the California Contractors' State license Board two or more times within an eight year period? yes no 2) Has the suspension or revocation of your contractor's license ever been stayed? yes no 3) Have any subcontractors that you propose to perform any portion of the Wori< ever had their contractor's license suspended or revoked by the California Contractors' State license Board two or more times within an eight year period? yes no 4) Has the suspension or revocation of the license of any subcontractor's that you propose to perform any portion of the Work ever been stayed? yes no 5) If the answer to either of 1. or 3. above is yes fully identify, in each and every case, the party disciplined, the date of and violation that the disciplinary action pertain to, describe the nature of • the violation and the disciplinary action taken therefore. (If needed attach additional sheets to provide full disclosure.) Page of pages of this Disclosure of Discipline form Revised 07/17/2015 Contract No. PKS 16-02PKS 18 of 86 BIDDER'S DISCLOSURE OF DISCIPLINE RECORD (CONTINUED) (To Accompany Proposal) AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS 6) If the answer to either of 2. or 4. above is yes fully identify, in each and every case, the party who's discipline was stayed, the date of the violation that the disciplinary action pertains to, describe the nature of the violation and the condition (if any) upon which the disciplinary action was stayed. (If needed attach additional sheets to provide full disclosure.) BY CONTF^CTOR: (name of Contractor) By: (sign here) (print name/title) Page of pages of this Disclosure of Discipline form ^¥ Revised 07/17/2015 Contract No. PKS16-02PKS 19 of 86 NONCOLLUSION DECLARATION TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID PUBLIC CONTRACT CODE SECTION 7106 AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS The undersigned declares: I am the of , the party making the foregoing bid. The bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation. The bid is genuine and not collusive or sham. The bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid. The bidder has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or to refrain from bidding. The bidder has not in any manner, directly or indirectiy, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to fix any overhead, profit, or cost element of the bid price, or of that of any other bidder. All statements contained in the bid are true. The bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, to any corporation, partnership, company, association, organization, bid depository, or to any member or agent thereof, to effectuate a collusive or sham bid, and has not paid, and will not pay, any person or entity for such purpose. Any person executing this declaration on behalf of a bidder that is a corporation, partnership, joint venture, limited liability company, limited liability partnership, or any other entity, hereby represents that he or she has full power to execute, and does execute, this declaration on behalf of the bidder. I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed on , 20 at [city], [state]. Signature of Bidder Revised 07/17/2015 Contract No. PKS16-02PKS CONTRACT PUBLIC WORKS This agreement is made this day of , 20 , by and between the City of Carisbad, California, a municipal corporation, (hereinafter called "City"), and whose principal place of business is (hereinafter called "Contractor"). City and Contractor agree as follows: 1. Description of Work. Contractor shall perform all work specified in the Contract documents for: AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS (hereinafter called "project") 2. Provisions of Labor and Materials. Contractor shall provide all labor, materials, tools, equipment, and personnel to perform the work specified by the Contract Documents. 3. Contract Documents. The Contract Documents consist of this Contract, Notice Inviting Bids, Contractor's Proposal, Bidder's Bond, Noncollusion Declaration, Designation of Subcontrac- tors, Technical Ability and Experience, Bidder's Statement Re Debarment, Escrow Agreement, Release Form, the Plans and Specifications, the General Provisions, addendum(s) to said Plans and Specifications and General Provisions, and all proper amendments and changes made thereto in accordance with this Contract or the Plans and Specifications, and all bonds for the project; all of which are incorporated herein by this reference. Contractor, her/his subcontractors, and materials suppliers shall provide and install the work as indicated, specified, and implied by the Contract Documents. Any items of work not indicated or specified, but which are essential to the completion of the work, shall be provided at the Contractor's expense to fulfill the intent of said documents. In all instances through the life of the Contract, the City will be the interpreter ofthe intent ofthe Contract Documents, and the City's decision relative to said intent will be final and binding. Failure ofthe Contractor to apprise subcontractors and materials suppliers of this condition of the Contract will not relieve responsibility of compliance. 4. Payment. For all compensation for Contractor's performance of work under this Contract, City shall make payment to the Contractor per section 9-3 PAYMENT of the General Provisions section of this contract. The Engineer will close the estimate of work completed for progress payments on the last working day of each month. The City shall withhold retention as required by Public Contract Code Section 9203. •F Revised 07/17/2015 Contract No. PKS16-02PKS 21 of 86 5. Independent Investigation. Contractor has made an independent investigation of the jobsite, the soil conditions at the jobsite, and all other conditions that might affect the progress of the work, and is aware of those conditions. The Contract price includes payment for all work that may be done by Contractor, whether anticipated or not, in order to overcome underground conditions. Any information that may have been furnished to Contractor by City about underground conditions or other job conditions is for Contractor's convenience only, and City does not warrant that the conditions are as thus indicated. Contractor is satisfied with all job conditions, including underground conditions and has not relied on information furnished by City. 6. Hazardous Waste or Other Unusual Conditions. If the contract involves digging trenches or other excavations that extend deeper than four feet below the surface Contractor shall promptly, and before the following conditions are disturbed, notify City, in writing, of any: (A) Hazardous Waste. Material that Contractor believes may be material that is hazardous waste, as defined in section 25117 of the Health and Safety Code, that is required to be removed to a Class I, Class 11, or Class III disposal site in accordance with provisions of existing law. (B) Differing Conditions. Subsurface or latent physical conditions at the site differing from those indicated. (C) Unknown Physical Conditions. Unknown physical conditions at the site of any unusual nature, different materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the contract. City shall promptly investigate the conditions, and if it finds that the conditions do materially so differ, or do involve hazardous waste, and cause a decrease or increase in contractor's costs of, or the time required for, performance of any part of the work shall issue a change order under the procedures described in this contract. In the event that a dispute arises between City and Contractor whether the conditions materially differ, or involve hazardous waste, or cause a decrease or increase in the contractor's cost of, or time required for, performance of any part of the work, contractor shall not be excused from any scheduled completion date provided for by the contract, but shall proceed with all work to be performed under the contract. Contractor shall retain any and all rights provided either by contract or by law which pertain to the resolution of disputes and protests between the contracting parties. 7. Immigration Reform and Control Act Contractor certifies it is aware of the requirements of the Immigration Reform and Control Act of 1986 (8 USC sections 1101-1525) and has complied and will comply with these requirements, including, but not limited to, verifying the eligibility for employment of all agents, employees, subcontractors, and consultants that are included in this Contract. 8. Indemnification. Contractor shall assume the defense of, pay all expenses of defense, and indemnify and hold harmless the City, and its officers and employees, from all claims, loss, damage, injury and liability of every kind, nature and description, directly or indirectly arising from or in connection with the performance of the Contract or work; or from any failure or alleged failure of Contractor to comply with any applicable law, rules or regulations including those relating to safety and health; and from any and all claims, loss, damages, injury and liability, howsoever the same may be caused, resulting directly or indirectly from the nature of the work covered by the Contract, except for loss or damage caused by the sole or active negligence or willful misconduct of the City. The expenses of defense include all costs and expenses including attorneys' fees for litigation, arbitration, or other dispute resolution method. Revised 07/17/2015 Contract No. PKS16-02PKS 22 of 86 Contractor shall also defend and indemnify the City against any challenges to the award of the contract to Contractor, and Contractor will pay all costs, including defense costs for the City. Defense costs include the cost of separate counsel for City, if City requests separate counsel. Contractor shall also defend and indemnify the City against any challenges to the award of the contract to Contractor, arising in whole or in part from alleged inaccuracies or misrepresentation by the Contractor, whether intentional or otherwise, and Contractor will pay all costs, including defense costs for the City. Defense costs include the cost of separate counsel for City, if City requests separate counsel. 9. Insurance. Contractor shall procure and maintain for the duration of the contract insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his or her agents, representatives, employees or subcontractors. Said insurance shall meet the City's policy for insurance as stated in City Council Policy # 70. (A) Coverages and Limits Contractor shall maintain the types of coverages and minimum limits indicted herein: a. Commercial General Liability Insurance: $1,000,000 combined single limit per occurrence for bodily injury and property damage. If the policy has an aggregate limit, a separate aggregate in the amounts specified shall be established for the risks for which the City or its agents, officers or employees are additional insured. b. Business Automobile Liability Insurance: $1,000,000 combined single limit per accident for bodily injury and property damage. In addition, the auto policy must cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. c. Workers' Compensation and Employers' Liability Insurance: Wori<ers' compensation limits as required by the Labor Code ofthe State of California. Workers' compensation offered by the State Compensation Insurance Fund is acceptable to the City. (B) Additional Provisions: Contractor shall ensure that the policies of insurance required under this agreement with the exception of Workers' Compensation and Business Automobile Liability Insurance contain, or are endorsed to contain, the following provisions. a. The City, its officials, employees and volunteers are to be covered as additional insured as respects: liability arising out of activities performed by or on behalf of the Contractor; products and completed operations of the contractor; premises owned, leased, hired or borrowed by the contractor. The coverage shall contain no special limitations on the scope of protection afforded to the City, its officials, employees or volunteers. All additional insured endorsements must be evidenced using separate documents attached to the certificate of insurance; one for each company affording general liability, and employers' liability coverage. b. The Contractor's insurance coverage shall be primary insurance as respects the City, its officials, employees and volunteers. Any insurance or self-insurance maintained by the City, its officials, employees or volunteers shall be in excess of the contractor's insurance and shall not contribute with it. c. Any failure to comply with reporting provisions of the policies shall not affect coverage provided to the City, its officials, employees or volunteers. d. Coverage shall state that the contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. 1^Revised 07/17/2015 Contract No. PKS16-02PKS 23 of 86 (C) Notice of Cancellation. Each insurance policy required by this agreement shall be endorsed to state that coverage shall not be nonrenewed, suspended, voided, canceled, or reduced in coverage or limits except after ten (10) days' prior written notice has been sent to the City by certified mail, return receipt requested. (D) Deductibles and Self-Insured Retention (S.I.R.) Levels. Any deductibles or self-insured retention levels must be declared to and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles or self-insured retention levels as respects the City, its officials and employees; or the contractor shall procure a bond guaranteeing payment of losses and related investigation, claim administration and defense expenses. (E) Waiver of Subrogation. All policies of insurance required under this agreement shall contain a waiver of all rights of subrogation the insurer may have or may acquire against the City or any of its officials or employees. (F) Subcontractors. Contractor shall include all subcontractors as insured under its policies or shall furnish separate certificates and endorsements for each subcontractor. Coverages for subcontractors shall be subject to all of the requirements stated herein. (G) Acceptability of Insurers. Insurance is to be placed with insurers that have a rating in Best's Key Rating Guide of at least A-:VII. Insurers must also be authorized to transact the business of insurance by the State of California Insurance Commissioner as admitted carriers as evidenced by a listing in the official publication ofthe Department of Insurance ofthe State of California and/or under the standards specified by City Council Policy # 70. (H) Verification of Coverage. Contractor shall furnish the City with certificates of insurance and original endorsements affecting coverage required by this clause. The certificates and endorsements for each insurance policy are to be signed by a person authorized by that insurer to bind coverage on its behalf The certificates and endorsements are to be in fomns approved by the City and are to be received and approved by the City before the Contract is executed by the City. (I) Cost Of Insurance. The Cost of all insurance required under this agreement shall be included in the Contractor's bid. 10. Claims and Lawsuits. All claims by contractor for $375,000 or less shall be resolved in accordance with the provisions in the Public Contract Code, Division 2, Part 3, Chapter 1, Article 1.5 (commencing with section 20104) which are incorporated by reference. A copy of Article 1.5 is included in Section 3 of the General Provisions. The contractor shall initially submit all claims over $375,000 to the City using the informal dispute resolution process described in Public Contract Code subsections 20104.2(a), (c), (d). Notwithstanding the provisions of this section of the contract, all claims shall comply with the Government Tort Claim Act (section 900 et seq., of the California Government Code) for any claim or cause of action for money or damages prior to filing any lawsuit for breach of this agreement. (A) Assertion of Claims. Contractor hereby agrees that any contract claim submitted to the City must be asserted as part of the contract process as set forth in this agreement and not in anticipation of litigation or in conjunction with litigation. (B) False Claims. Contractor acknowledges that if a false claim is submitted to the City, it may be considered fraud and the Contractor may be subject to criminal prosecution: (C) Government Code. Contractor acknowledges that California Government Code sections 12650 et seq., the False Claims Act, provides for civil penalties where a person knowingly submits a false claim to a public entity. These provisions include false claims made with deliberate ignorance of the false information or in reckless disregard of the truth or falsity of the information. •F Revised 07/17/2015 Contract No. PKS16-02PKS 24 of 86 (D) Penalty Recovery. If the City of Carisbad seeks to recover penalties pursuant to the False Claims Act, it is entitied to recover its litigation costs, including attorney's fees. (E) Debarment for False Claims. Contractor hereby acknowledges that the filing of a false claim may subject the Contractor to an administrative debarment proceeding wherein the Contractor may be prevented from further bidding on public contracts for a period of up to five years. (F) Carlsbad Municipal Code. The provisions of Carlsbad Municipal Code sections 3.32.025, 3.32.026, 3.32.027 and 3.32.028 pertaining to false claims are incorporated herein by reference. (G) Debarment from Other Jurisdictions. Contractor hereby acknowledges that debarment by another jurisdiction is grounds for the City of Carisbad to disqualify the Contractor or subcontractor from participating in future contract bidding. (H) Jurisdiction. Contractor agrees and hereby stipulates that the proper venue and jurisdiction for resolution of any disputes between the parties arising out of this agreement is San Diego County, California. I have read and understand all provisions of Section 10 above. init init 11. Security. Securities in the form of cash, cashier's check, or certified check may be substituted for any monies withheld by the City to secure performance of this contract for any obligation established by this contract. Any other security that is mutually agreed to by the Contractor and the City may be substituted for monies withheld to ensure performance under this Contract. 12. Unfair Business Practices. In entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or subcontractor offers and agrees to assign to the awarding body all rights, titie, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec. 15) or under the Cartwright Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or the subcontract. This assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment by the parties. 13. Provisions Required by Law Deemed Inserted. Each and every provision of law and clause required by law to be inserted in this Contract shall be deemed to be inserted herein and included herein, and if, through mistake or othenvise, any such provision is not inserted, or is not correctly inserted, then upon application of either party, the Contract shall forthwith be physically amended to make such insertion or correction. Revised 07/17/2015 Contract No. PKS16-02PKS 25 of 86 14. Additional Provisions. Any additional provisions of this agreement are set forth in the "General Provisions" or "Supplemental Provisions" attached hereto and made a part hereof NOTARIAL ACKNOWLEDGMENT OF EXECUTION BY ALL SIGNATORIES MUST BE ATTACHED (CORPOFIATE SEAL) CONTRACTOR: CITY OF CARLSBAD a municipal corporation of the State of California By: (name of Contractor) (sign here) By: Mayor ATTEST: By: (print name and title) (sign here) BARBARA ENGLESON, City Clerk (print name and titie) President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under the corporate seal empowering that officer to bind the corporation. APPROVED AS TO FORM: CELIA A. BREWER City Attorney By: Assistant City Attorney ••^Revised 07/17/2015 Contract No. PKS16-02PKS 26 of 86 LABOR AND MATERIALS BOND WHEREAS, the City Council of the City of Carlsbad, State of California, by Resolution No. __, adopted , has awarded to (hereinafter designated as the "Principal"), a Contract for: AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS in the City of Carisbad, in strict conformity with the drawings and specifications, and other Contract Documents now on file in the Office of the City Clerk of the City of Carisbad and all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond, providing that if Principal or any of their subcontractors shall fail to pay for any materials, provisions, provender or other supplies or teams used in, upon or about the performance of the work agreed to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same to the extent hereinafter set forth. NOW, THEREFORE, WE, , as Principal, (hereinafter designated as the "Contractor"), and as Surety, are held firmly bound unto the City of Carisbad in the sum of Dollars ($ - ), said sum being an amount equal to: One hundred percent (100%) ofthe total amount payable under the terms of the contract by the City of Carisbad, and for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the Contractor or his/her subcontractors fail to pay for any materials, provisions, provender, supplies, or teams used in, upon, for, or about the performance of the work contracted to be done, or for any other work or labor thereon of any kind, consistent with California Civil Code section 9100, or for amounts due under the Unemployment Insurance Code with respect to the work or labor performed under this Contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of the contractor and subcontractors pursuant to section 13020 ofthe Unemployment Insurance Code with respect to the work and labor, that the Surety will pay for the same, and, also, in case suit is brought upon the bond, reasonable attorney's fees, to be fixed by the court consistent with California Civil Code section 9554. This bond shall inure to the benefit of any of the persons named in California Civil Code section 9100, so as to give a right of action to those persons or their assigns in any suit brought upon the bond. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed hereunder or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications. ^•F Revised 07/17/2015 Contract No. PKS16-02PKS 27 of 86 In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. Executed by CONTRACTOR this day of , 20_ CONTRACTOR: Executed by SURETY this. of 20_ SURETY: day (name of Contractor) By: (sign here) (name of Surety) (address of Surety) By:_ (print name here) (title and organization of signatory) (sign here) (print name here) By:, (telephone number of Surety) (signature of Attorney-in-Fact) (printed name of Attorney-in-Fact) (attach corporate resolution showing current power of attomey) (title and organization of signatory) (Proper notarial acknowledgment of execution by CONTRACTOR and SURETY must be attached.) (President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under corporate seal empowering that officer to bind the corporation.) APPROVED AS TO FORM: CELIA A. BREWER City Attorney By: Assistant City Attorney Revised 07/17/2015 Contract No. PKS16-02PKS 28 of 86 FAITHFUL PERFORMANCE/WARRANTY BOND WHEREAS, the City Council of the City of Carisbad, State of California, by Resolution No. , adopted \ , has awarded to , (hereinafter designated as the "Principal"), a Contract for: AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKSI 6-02PKS in the City of Carisbad, in strict conformity with the contract, the drawings and specifications, and other Contract Documents now on file in the Ofl^ice of the City Clerk of the City of Carisbad, all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond for the faithful performance and warranty of said Contract; NOW, THEREFORE, WE, , , as Principal, (hereinafter designated as the "Contractor"), and as Surety, are held and firmly bound unto the City of Carisbad, in the sum of Dollars ($ ), said sum being equal to one hundred percent (100%) ofthe estimated amount ofthe Contract, to be paid to City or its certain attorney, its successors and assigns; for which payment, well and truly to be made, we bind ourselves, our heirs, executors and administrators, successors or assigns, jointly and Severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the above bounden Contractor, their heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions, and agreements in the Contract and any alteration thereof made as therein provided on their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City of Carisbad, its officers, employees and agents, as therein stipulated, then this obligation shall become null and void; othenwise it shall remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by the City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed there under or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications. Revised 07/17/2015 Contract No. PKS16-02PKS In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. Executed by CONTRACTOR this _ day of , 20_ CONTRACTOR: (name of Contractor) Executed by SURETY this. SURETY: (name of Surety) . day of 20_ By: (sign here) (print name here) By: (Titie and Organization of Signatory) (address of Surety) (telephone number of Surety) (signature of Attorney-in-Fact) By: (sign here) (print name here) (printed name of Attorney-in-Fact) (Attach corporate resolution showing current power of attorney.) (Titie and Organization of signatory) (Proper notarial acknowledgment of execution by CONTFIACTOR and SURETY must be attached.) (President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under corporate seal empowering that officer to bind the corporation.) APPROVED AS TO FORM: CELIA A. BREWER City Attorney By: Assistant City Attorney Revised 07/17/2015 Contract No. PKS16-02PKS 30 of 86 OPTIONAL ESCROW AGREEMENT FOR SECURITY DEPOSITS IN LIEU OF RETENTION This Escrow Agreement is made and entered into by and between the City of Carisbad whose address is 1200 Carisbad Village Drive, Carisbad, California, 92008, hereinafter called "City" and ^whose address is hereinafter called "Contractor" and whose address is hereinafter called "Escrow Agent." For the consideration hereinafter set forth, the City, Contractor and Escrow Agent agree as follows: 1. Pursuant to sections 22300 and 10263 of the Public Contract Code of the State of California, the Contractor has the option to deposit securities with the Escrow Agent as a substitute for retention earnings required to be withheld by the City pursuant to the Construction Contract entered into between the City and Contractor for AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS in the amount of dated (hereinafter referred to as the "Contract"). Alternatively, on written request ofthe Contractor, the City shall make payments of the retention earnings directiy to the Escrow Agent. When the Contractor deposits the securities as a substitute for Contract earnings, the Escrow Agent shall notify the City within 10 days of the deposit. The Escrow Agent shall maintain insurance to cover negligent acts and omissions of the Escrow Agent in connection with the handling of retentions under these sections in an amount not less than $100,000 per contract. The market value of the securities at the time of the substitution shall be a least equal to the cash amount then required to be withheld as retention under the terms of the contract between the City and Contractor. Securities shall be held in the name of the City and shall designate the Contractor as the beneficial owner. 2. The City shall make progress payments to the Contractor for such funds which othenvise would be withheld from progress payments pursuant to the Contract provisions, provided that the Escrow Agent holds securities in the form and amount specified above. 3. When the City makes payment of retentions earned directly to the Escrow Agent, the Escrow Agent shall hold them for the benefit of the Contractor until such time as the escrow created under this contract is terminated. The Contractor may direct the investment ofthe payments into securities. All terms and conditions of this agreement and the rights and responsibilities of the parties shall be equally applicable and binding when the City pays the Escrow Agent directly. 4. The Contractor shall be responsible for paying all fees for the expenses incurred by the Escrow Agent in administering the Escrow Account and all expenses of the City. These expenses and payment terms shall be determined by the City, Contractor and Escrow Agent. 5. The interest earned on the securities or the money market accounts held in escrow and all interest eamed on that interest shall be for the sole account of Contractor and shall be subject to withdrawal by Contractor at any time and from time to time without notice to the City. ^¥Revised 07/17/2015 Contract No. PKS16-02PKS 31 of 86 6. Contractor shall have the right to withdraw all or.any part of the principal in the Escrow Account only by written notice to Escrow Agent accompanied by written authorization from City to the Escrow Agent that City consents to the withdrawal of the amount sought to be withdrawn by Contractor. 7. The City shall have a right to draw upon the securities in the event of default by the Contractor. Upon seven days' written notice to the Escrow Agent from the City of the default, the Escrow Agent shall immediately convert the securities to cash and shall distribute the cash as instructed by the City. 8. Upon receipt of written notification from the City certifying that the Contract is final and complete and that the Contractor has complied with all requirements and procedures applicable to the Contract, the Escrow Agent shall release to Contractor all securities and interest on deposit less escrow fees and charges of the Escrow Account. The escrow shall be closed immediately upon disbursement of all moneys and securities on deposit and payments of fees and charges. 9. The Escrow Agent shall rely on the written notifications from the City and the Contractor pursuant to sections (1) to (8), inclusive, of this agreement and the City and Contractor shall hold Escrow Agent harmless from Escrow Agent's release, conversion and disbursement of the securities and interest as set forth above. 10. The names ofthe persons who are authorized to give written notices or to receive written notice on behalf ofthe City and on behalf of Contractor in connection with the foregoing, and exemplars of their respective signatures are as follows: For City: Title Finance Director Name Chuck McBride Signature. For Contractor: Address 1635 FaradayAvenue, Carisbad, CA92008 Title Name For Escrow Agent: Signature. Address _ Title Name Signature. Address Revised 07/17/2015 Contract No. PKS16-02PKS 40 32 of 86 At the time the Escrow Account is opened, the City and Contractor shall deliver to the Escrow Agent a fully executed counterpart of this Agreement. IN WITNESS WHEREOF, the parties have executed this Agreement by their proper officers on the date first set forth above. For City: Titie Mayor Name Matt Hall Signature. Address 1200 Carisbad Villaqe Drive. Carlsbad, CA 92008 For Contractor: Titie Name Signature. Address For Escrow Agent: Titie Approved as to Forni: CELIA A. BREWER, City Attorney Assistant City Attorney Name Signature. Address Revised 07/17/2015 Contract No. PKS16-02PKS 33 of 86 GENERAL PROVISIONS FOR AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS CITYOFCARLSBAD BIDDERS ARE ADVISED THAT THIS SECTION REPLACES PART 1, GENERAL PROVISIONS, OF THE STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION SECTION 1 - TERMS, DEFINITIONS, ABBREVIATIONS, AND SYMBOLS 1-1 TERMS - Unless otherwise stated, the words directed, required, permitted, ordered, instructed, designated, considered necessary, prescribed, approved, acceptable, satisfactory, or words of like meaning, refer to actions, expressions, and prerogatives of the Engineer. 1-1.1 Reference to Drawings. Where words "shown", "indicated", "detailed", "noted", "scheduled", or words of similar import are used, it shall be understood that reference is made to the plans accompanying these provisions, unless stated othenvise. 1-1.2 Directions. Where words "directed", "designated", "selected", or words of similar import are used, it shall be understood that the direction, designation or selection of the Engineer is intended, unless stated otherwise. The word "required" and words of similar import shall be understood to mean "as required to properly complete the work as required and as approved by the Engineer," unless stated otherwise. 1-1.3 Equals and Approvals. Where the words "equal", "approved equal", "equivalent", and such words of similar import are used, it shall be understood such words are followed by the expression "in the opinion of the Engineer", unless othenvise stated. Where the words "approved", "approval", "acceptance", or words of similar import are used, it shall be understood that the approval, acceptance, or similar import of the Engineer is intended. 1-1.4 Perform. The word "perform" shall be understood to mean that the Contractor, at its expense, shall perform all operations, labor, tools and equipment, and further, including the furnishing and installing of materials that are indicated, specified or required to mean that the Contractor, at its expense, shall furnish and install the work, complete in place and ready to use, including furnishing of necessary labor, materials, tools, equipment, and transportation. •F Revised 07/17/2015 Contract No. PKS16-02PKS 34 of 86 1-2 Definitions. The following words, or groups of words, shall be exclusively defined by the definitions assigned to them herein. Addendum - Written or graphic instrument issued prior to the opening of Bids which clarifies, corrects, or changes the bidding or Contract Documents. The term Addendum shall include bulletins and all other types of written notices issued to potential bidders prior to opening of Bids. Agency - The City of Carisbad, California. Agreement - See Contract. Assessment Act Contract - A Contract financed by special assessments authorized under a State Act or procedural ordinance of a City or County. Base - A layer of specified material of planned thickness placed immediately below the pavement or surfacing. Bid - The offer or proposal of the Bidder submitted on the prescribed form setting forth the prices for the Work. Bidder - Any individual, firm, partnership, corporation, or combination thereof, submitting a Bid for the Work, acting directly or through a duly authorized representative. Board - The officer or body constituting the awarding authority of the Agency, which is the City Council for the City of Carisbad or the Board of Directors of Carisbad Municipal Water District. Bond - Bid, performance, and payment bond or other instrument of security. City Council - the City Council of the City of Carisbad. City Manager - the City Manager of the City of Carisbad or his/her approved representative. Cash Contract - A Contract financed by means other than special assessments. Change Order - A written order to the Contractor signed by the Agency directing an addition, deletion, or revision in the Work, or an adjustment in the Contract Price or the Contract time issued after the effective date of the Contract. A Change Order may or may not also be signed by the Contractor. Code - The terms Govemment Code, Labor Code, etc., refer to codes of the State of California. Construction Manager (a.k.a. Parks Supervisor) - the Project Inspector's immediate supervisor and first level of appeal for informal dispute resolution. Contract - The written agreement between the Agency and the Contractor covering the Work. ¥ Revised 07/17/2015 Contract No. PKS16-02PKS 35 of 86 Contract Documents - Including but not limited to; the Contract, any Addendum (which pertain to the contract documents). Notice Inviting Bids, Instructions to Bidders; Bid (including documentation accompanying the Bid and any post-bid documentation submitted prior to the Notice of Award) when attached as an exhibit to the Contract, the Bonds, the General Provisions, permits from other agencies, the Technical Specifications, the Supplemental Provisions, the Plans, Standard Plans, Standard Specifications, Reference Specifications, and all Modifications issued after the execution ofthe Contract. Contractor - The individual, partnership, corporation, joint venture, or other legal entity having a Contract with the Agency to perform the Work. In the case of work being done under permit issued by the Agency, the permittee shall be constructed to be the Contractor. The term "prime contractor" shall mean Contractor. Contract Price - The total amount of money for which the Contract is awarded. Contract Unit Price - The amount stated in the Bid for a single unit of an item of work. County Sealer - The Sealer of Weights and Measures ofthe county in which the Contract is let. Days - Days shall mean consecutive calendar's days unless otherwise specified. Parks Superintendent - The Construction Manager's immediate supervisor and second level of appeal for informal dispute resolution. Dispute Board - Persons designated by the City Manager of the City of Carisbad or Executive Manager ofthe Carlsbad Municipal Water District, to hear and advise the City Manager on claims submitted by the Contractor. The City Manager for the City of Carisbad or the Executive Manager for the Carisbad Municipal Water District is the last appeal level for informal dispute resolution. Electrolier - Street light assembly complete, including foundation, standard, luminaire arm, luminaire, etc. Engineer - The City Engineer of the City of Carlsbad or his/her approved representative. The Engineer is the third level of appeal for informal dispute resolution. Geotextile - Synthetic fiber used in civil engineering applications, serving the primary functions of separation and filtration. House Connection Sewer - A sewer, within a public street or right-of-way, proposed to connect any parcel, lot, or part of a lot with a mainline sewer. House Sewer - A sewer, wholly within private properiy, proposed to connect any building to a house connection sewer. Luminaire - The lamp housing including the optical and socket assemblies (and ballast if so specified). Luminaire Arm - The structural member, bracket, or mast arm, which, mounted on the standard, supports the luminaire. Minor Bid Item - A single contract item constituting less than 10 percent (10%) ofthe original Contract Price bid. ¥ Revised 07/17/2015 Contract No. PKS16-02PKS 36 of 86 Modification - Includes Change Orders and Supplemental Agreements. A Modification may only be used after the effective date of the Contract. Notice of Award - The written notice by the Agency to the successful Bidder stating that upon compliance by it with the required conditions, the Agency will execute the Contract. Notice to Proceed - A written notice given by the Agency to the Contractor fixing the date on which the Contract time will start. Own Organization - When used in Section 2-3.1 - Employees of the Contractor who are hired, directed, supervised and paid by the Contractor to accomplish the completion of the Work. Further, such employees have their employment taxes. State disability insurance payments. State and Federal income taxes paid and administered, as applicable, by the Contractor. When used in Section 2-3.1 "own organization" means construction equipment that the Contractor owns or leases and uses to accomplish the Work. Equipment that is owner operated or leased equipment with an operator is not part of the Contractor's Own Organization and will not be included for the purpose of compliance with Section 2-3.1. Person - Any individual, firm, association, partnership, corporation, trust, joint venture, or other legal entity. Plans - The drawings, profiles, cross sections, working drawings, and supplemental drawings, or reproductions thereof, approved by the Engineer, which show the location, character, dimensions, or details of the Work. Private Contract - Work subject to Agency inspection, control, and approval, involving private funds, not administered by the Agency. Project Inspector (a.k.a. Parks Inspector) - The Agency's designated representative for inspection, contract administration and first level for informal dispute resolution. Proposal - See Bid. Reference Specifications - Those bulletins, standards, rules, methods of analysis or test, codes, and specifications of other agencies, engineering societies, or industrial associations referred to in the Contract Documents. These refer to the latest edition, including amendments in effect and published at the time of advertising the project or issuing the permit, unless specifically referred to by edition, volume, or date. Roadway - The portion of a street reserved for vehicular use. Service Connection - Service connections are all or any portion ofthe conduit, cable, or duct, including meter, between a utility distribution line and an individual consumer. Sewer - Any conduit intended for the reception and transfer of sewage and fluid industrial waste. Specifications - General Provisions, Standard Specifications, Technical Specifications, Reference Specifications, Supplemental Provisions, and specifications in Supplemental Agreements between the Contractor and the Board. Standard - The shaft or pole used to support street lighting luminaire, traffic signal heads, mast arms, etc. Revised 07/17/2015 Contract No. PKS16-02PKS 37 of 86 Standard Plans - Details of standard structures, devices, or instructions referred to on the Plans or in Specifications by titie or number. Standard Specifications - The Standard Specifications for Public Works Construction (SSPWC), the "Greenbook". State - State of California. Storm Drain - Any conduit and appurtenances intended for the reception and transfer of storm water. Street - Any road, highway, parkway, freeway, alley, walk, or way. Subbase - A layer of specified material of planned thickness between a base and the subgrade. Subcontractor - An individual, firm, or corporation having a direct contract with the Contractor or with any other Subcontractor for the performance of a part of the Work. Subgrade - For roadways, that portion ofthe roadbed on which pavement, surfacing, base, subbase, or a layer of other material is placed. For structures, the soil prepared to support a structure. Supervision - Supervision, where used to indicate supervision by the Engineer, shall mean the performance of obligations, and the exercise of rights, speciflcally imposed upon and granted to the Agency in becoming a party to the^Contract. Except as speciflcally stated herein, supervision by the Agency shall not mean active and direct superintendence of details of the Work. Supplemental Agreement - A written amendment of the Contract Documents signed by both parties. Supplemental Provisions - Additions and revisions to the Standard Specifications setting forth conditions and requirements peculiar to the work. Surety - Any individual, firm, or corporation, bound with and for the Contractor for the acceptable performance, execution, and completion of the Work, and forthe satisfaction of all obligations incurred. Tonne - Also referred to as "metric ton". Represents a unit of measure in the International System of Units equal to 1,000 kilograms. Utility - Tracks, overhead or underground wires, pipeline, conduits, ducts, or structures, sewers, or stomn drains owned, operated, or maintained in or across a public right of way or private easement. Work - That which is proposed to be constructed or done under the Contract or permit, including the furnishing of all labor, materials, equipment, and services. ^¥Revised 07/17/2015 Contract No. PKS16-02PKS 38 of 86 1-3 ABBREVIATIONS 1-3.1 General. The abbreviation herein, together with others in general use, are applicable to these Standard Speciflcations and to project Plans or other Contract Documents. All abbreviations and symbols used on Plans for structural steel construction shall conform to those given by the "Manual of Steel Construction" published by the American Institute of Steel Construction, Inc. 1-3.2 Common Usage Abbreviation Word or Words ABAN Abandon ABAND Abandoned ABS Acrylonitrile - butadiene - styrene AC Asphalt Concrete ACP Asbestos cement pipe ACWS Asphalt concrete wearing surface ALT Alternate APTS Apartment and Apartments AMER STD American Standard AWG American Wire Gage (nonferrous wire) BC Beginning of curve BCR Beginning of curb return BDRY Boundary BF Bottom of footing BLDG Building and Buildings BM Bench mark BVC Beginning of vertical curve B/W Back of wall C/C Center to center CAB Crushed aggregate base CAL/OSHA California Occupational Safety and Health Administration CalTrans Califomia Department of Transportation CAP Corrugated aluminum pipe CB Catch Basin Cb Curb CBP Catch Basin Connection Pipe CBR California Bearing Ratio CCR California Code of Regulations CCTV Closed Circuit TV CES Carlsbad Engineering Standards CF Curb face CF Cubic foot C&G Curb and gutter CFR Code of Federal Regulations CFS Cubic Feet per Second CIP Cast iron pipe CIPP Cast-in place pipe CL Clearance, center line CLF Chain link fence CMB Crushed miscellaneous base CMC Cement mortar-coated CML Cement mortar-lined CMWD Carlsbad Municipal Water District CO Cleanout (Sewer) COL Column COMM Commercial CONC Concrete CONN Connection CONST Construct, Construction COORD Coordinate CSP Corrugated steel pipe CSD Carlsbad Standard Drawings CTB Cement treated base CV Check valve CY Cubic yard D Load of pipe dB Decibels DBL Double DF Douglas fir DIA Diameter DIP Ductile iron pipe DL Dead load DR Dimension Ratio DT Drain Tile DWG Drawing DWY Driveway DWY APPR Driveway approach E Electric EA Each EC End of curve ECR End of curb return EF Each face EG Edge of gutter EGL Energy grade line El Elevation ELC Electrolier lighting conduit ELT Extra long ton ENGR Engineer, Engineering EP Edge of pavement ESMT Easement ETB Emulsion-treated base EVC End of vertical curb EWA Encina Wastewater Authority EXC Excavation EXP JT Expansion joint EXST Existing F Fahrenheit F&C Frame and cover F&l Furnish and install FAB Fabricate FAS Flashing arrow sign FD Floor drain FDN Foundation Revised 07/17/2015 Contract No. PKS16-02PKS 39 of 86 FED SPEC Federal Specification FG Finished grade FH Fire hydrant FL Flow line FS Finished surface FT-LB Foot-pound FTG Footing FW Face of wall G Gas GA Gauge GAL Gallon and Gallons GALV Galvanized GAR Garage and Garages GIP Galvanized iron pipe GL Ground line or grade line GM Gas meter GNV Ground Not Visible GP Guy pole GPM gallons per minute GR Grade GRTG Grating GSP Galvanized steel pipe H High or height HB Hose bib HC House connection HDWL Headwall HGL Hydraulic grade line HORIZ Horizontal HP Horsepower HPG High pressure gas HPS High pressure sodium (Light) HYDR Hydraulic IE Invert Elevation ID Inside diameter INCL Including INSP Inspection INV Invert IP Iron pipe JC Junction chamber JCT Junction JS Junction structure JT Joint L Length UKB Laboratory LAT Lateral LB Pound LD Local depression LF Linear foot LH Lamp hole LL Live load LOL Layout line LONG Longitudinal LP Lamp post LPS Low pressure sodium (Light) LS Lump sum LTS Lime treated soil LWD Leucadia Wastewater District MAINT Maintenance MAX Maximum MCR Middle of curb return MEAS Measure MH Manhole, maintenance hole MIL SPEC Military specification MISC Miscellaneous MOD Modified, modify MON Monument MSL.. Mean Sea Level (Reg. Standard Drawing M-12) MTBM Microtunneling Boring Machine MULT Multiple MUTCD Manual on Uniform Traffic Control Devices MVL Mercury vapor light NCTD North County Transit District NRCP Nonrelnforced concrete pipe OBS Obsolete oc On center OD Outside diameter OE Outer edge OHE Overhead Electric OMWD Olivenhain Municipal Water District OPP Opposite ORIG Original PB Pull box PC Point of curvature PCC Portland cement concrete or point of compound curvature PCVC Point of compound vertical curve PE Polyethylene Pl Point of intersection PL Property line PMB Processed miscellaneous base POC Point on curve POT Point on tangent PP Power pole PRC Point of reverse curve PRVC Point of reverse vertical curve PSI Pounds per square inch PT Point of tangency PVC... Polyvinyl chloride PVMT Pavement PVT R/W Private right-of-way Q Rate of flow in cubic feet per second QUAD Quadrangle, Quadrant R Radius R&O Rock and oil FWV Right-of-way RA Recycling agent F?AC Recycled asphalt concrete F^P Reclaimed asphalt pavement RBAC Rubberized asphalt concrete RC Reinforced concrete RCB Reinforced concrete box RCE Registered civil engineer RCP Reinforced concrete pipe RCV Remote control valve REF Reference REINF Reinforced or reinforcement RES Reservoir RGE Registered geotechnical engineer ROW Right-of-Way RR Railroad RSE Registered structural engineer RTE Registered traffic engineer S Sewer or Slope, as applicable SCCP Steel cylinder concrete pipe SD Stonn drain SDNR San Diego Northern Railway SDR Standard thennoplastic pipe dimension ratio (ratio of pipe O.D. to minimum wall thickness) SDRSD San Diego Regional Standard Drawings •''Revised 07/17/2015 Contract No. PKS16-02PKS 40 of 86 SE Sand Equivalent SEC Section SF Square foot SFM Sewer Force Main SI International System of Units (Metric) SPEC Specifications SPPWC Standard Plans for Public Works Construction SSPWC Standard Specifications for Public Works Construction ST HWY State highway STA Station STD Standard STR Straight STR GR Straight grade STRUC Structural/Structure SW Sidewalk SWD Sidewalk drain SY Square yard T Telephone TAN Tangent TC Top of curb TEL Telephone TF Top of footing TOPO Topography TR Tract TFiANS Transition TS Traffic signal or transition structure TSC Traffic signal conduit TSS Traffic signal standard TW Top of wall TYP Typical UE Underground Electric USA Underground Service Alert VAR Varies, Variable VB Valve box VC Vertical curve VCP Vitrified clay pipe VERT Vertical VOL Volume VWD Vallecitos Water District W Water, Wider or Width, as applicable WATCH Work Area Traffic Control Handbook Wl Wrought iron WM Water meter WPJ Weakened plane joint XCONN Cross connection XSEC Cross section '^Revised 07/17/2015 <S3 Contract No. PKS16-02PKS A 41 of 86 1-3.3 Institutions. Abbreviation Word or Words AASHTO American Association of State Highway and Transportation Officials AISC American Institute of Steel Construction ANSI American National Standards Institute API American Petroleum Institute AREA American Railway Engineering Association ASTM American Society for Testing and Materials AWPA American Wood Preservers Association AWS American Welding Society AWWA American Water Works Association FHWA Federal Highway Administration GRI Geosynthetic Research Institute NEMA National Electrical Manufacturers Association NOAA National Oceanic and Atmospheric Administration (Dept of Commerce) UL Underwriters' Laboratories Inc. USGS United States Geological Survey 1-4 UNITS OF MEASURE. 1-4.1 General. U.S. Standard Measures, also called U.S. Customary System, are the principal measurement system in these speciflcations. However, certain material speciflcations and test requirements contained herein use SI units speciflcally and conversions to U.S. Standard Measures may or may not have been included in these circumstances. When U.S. Standard Measures are not included in parenthesis, then the SI units shall control. S.l. units and U.S. Standard Measures in parenthesis may or may not be exactly equivalent. Reference is also made to ASTM E 380 for definitions of various units of the SI system and a more extensive set of conversion factors. 1-4.2 Units of Measure and Their Abbreviations. U.S. Customarv Unit (Equal To) SI IJnit (Abbreviations) (Abbreviations) 1 mil (=0.001 in) 25.4 micrometer (n.m) 1 inch (in) 25.4 millimeter (mm) 1 inch (in) 2.54 centimeter (cm) 1 foot (ft) 0.3048 meter (m) 1 yard (yd) 0.9144 meter (m) 1 mile (mi) ... 1.6093 kilometer (km) 1 square foot (ft^) 0.0929 square meter (m^) 1 square yard (yd^) 0.8361 square meter (m^) 1 cubic foot (ft^) 0.0283 cubic meter (m^) 1 cubic yard (yd^) 0.7646 cubic meter (m^) 1 acre 0.4047 hectare (ha) 1 U.S. gallon (gal) 3.7854 Liter (L) 1 fluid ounce (fl. oz.) 29.5735 millileter (mL) 1 pound mass (lb) (avoirdupois) 0.4536 kilogram (kg) 1 ounce mass (oz) 0.02835 kilogram (kg) 1 Ton (=2000 lb avoirdupois) 0.9072 Tonne (= 907 kg) 1 Poise 0.1 pascal • second (Pa s) 1 centistoke (cs) 1 square millimeters per second (mm^/s) 1 pound force (Ibf) 4.4482 Newton (N) 1 pounds per square inch (psi) 6.8948 Kilopascal (kPa) 1 pound force per foot (Ibf/ft) 1.4594 Newton per meter (N/m) 1 foot-pound force (ft-lbf) 1.3558 Joules (J) 1 foot-pound force per second ([ft-lbf]/s) 1.3558 Watt (W) 1 part: per million (ppm) 1 milligram/liter (mg/L) Temperature Units and Abbreviations Degree Fahrenheit (°F): Degree Celsius (°C): °F = (1.8 X °C) + 32 °C = (°F - 32)/1.8 SI Units (abbreviation) Commonly Used in Both Systems 1 Ampere (A) 1 Volt (V) 1 Candela (cd) 1 Lumen (lm) 1 second (s) Common Metric Prefixes kilo (k) : 103 centi (c) 10-2 milli (m) 10-^ micro (n) 10-^ nano(n) 10-9 pico(p) 10-12 1-5 SYMBOLS A Delta, the central angle or angle between tangents Z Angle % Percent /1 ^••''Revised 07/17/2015 Contract No. PKS16-02PKS 43 of 86 ( Feet or minutes tf Inches or seconds 1 Number / per or (between words) o Degree PL Property line CL Centeriine SL Survey line or station line ••''Revised 07/17/2015 Contract No. PKS16-02PKS 44 of 86 SECTION 2 - SCOPE AND CONTROL OF WORK 2-1 AWARD AND EXECUTION OF CONTRACT. Award and execution of Contract will be as provided for in the Specifications, Instruction to Bidders, or Notice Inviting Bids. 2-2 ASSIGNMENT. No Contract or portion thereof may be assigned without consent of the Board, except that the Contractor may assign money due or which will accrue to it under the Contract. If given written notice, such assignment will be recognized by the Board to the extent permitted by law. Any assignment of money shall be subject to all proper withholdings in favor of the Agency and to all deductions provided for in the Contract. All money withheld, whether assigned or not, shall be subject to being used by the Agency for completion of the Work, should the Contractor be in default 2-3 SUBCONTRACTS. 2-3.1 General. Each Bidder shall comply with the Chapter of the Public Contract Code including Sections 4100 through 4113. The following excerpts or summaries of some of the requirements of this Chapter are included below for information: The Bidder shall set forth in the Bid, as provided in 4104: "(a) The name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construc- tion of the work or improvements, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specially fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of 1 percent of the prime contractor's total bid, or, in the case of bids or ofl'ers for the construction of streets or highways, including bridges, in excess of one-half of 1 percent of the prime contractor's total bid or ten thousand dollars ($10,000), whichever is greater." "(b) The portion of the work which will be done by each such subcontractor under this act. The prime contractor shall list only one subcontractor for each such portion as is defined by the prime contractor in his bid." If the Contractor fails to specify a Subcontractor, or specifies more than one Subcontractor for the same portion of the work to be performed under the Contract (in excess of one-half of 1 percent of the Contractor's total Bid), the Contractor shall be qualified to perform that portion itself, and shall perfomi that portion itself, except as otherwise provided in the Code. As provided in Section 4107, no Contractor whose Bid is accepted shall substitute any person as Subcontractor in place ofthe Subcontractor listed in the original Bid, except for causes and by procedures established in Section 4107.5. This section provides procedures to correct a clerical error in the listing of a Subcontractor. Section 4110 provides that a Contractor violating any of the provisions of the Chapter violates the Contract and the Board may exercise the option either to cancel the Contract or assess the Contractor a penalty in an amount of not more than 10 percent ofthe subcontract involved, after a public hearing. Should the Contractor fail to adhere to the provisions requiring the Contractor to complete 50 percent of the contract price with its own organization, the Agency may at its sole discretion elect to cancel the contract or deduct an amount equal to 10 percent ofthe value ofthe work performed in excess of 50 percent ofthe contract price by other than the Contractor's own organization. The Board shall be the sole body for determination of a violation of these provisions. In any proceedings under this section, the prime contractor shall be entitied to a public hearing before the Board and shall be notified ten (10) days in advance of the time and location of said hearing. The determination of the City Council shall be final. ' Revised 07/17/2015 Contract No. PKS16-02PKS 45 of 86 6^ 2-3.2 Additional Responsibility. The Contractor shall give personal attention to the fulfillment ofthe Contract and shall keep the Work under its control. The Contractor shall perform, with its own organization. Contract work amounting to at least 50 percent of the Contract Price except that any designated "Specialty Items" may be performed by subcontract, and the amount of any such "Specialty Items" so performed may be deducted from the Contract Price before computing the amount required to be performed by the Contractor with its own organization. "Specialty Items" will be identified by the Agency in the Bid or Proposal. Where an entire item is subcontracted, the value of work subcontracted will be based on the Contract Unit Price. When a portion of an item is subcontracted, the value of work subcontracted will be based on the estimated percentage of the Contract Unit Price. This will be determined from information submitted by the Contractor, and subject to approval by the Engineer. Before the work of any Subcontractor is started, the Contractor shall submit to the Engineer for approval a written statement showing the work to be subcontracted giving the name and business of each Subcontractor and description and value of each portion of the work to be so subcontracted. 2-3.3 Status of Subcontractors. Subcontractors shall be considered employees of the Contractor, and the Contractor shall be responsible for their work. 2-4 CONTRACT BONDS. Before execution of the Contract, the Bidder shall flle surety bonds with the Agency to be approved by the Board in the amounts and for the purposes noted below. Bonds issued by a surety, who is authorized to issue bonds in California, and whose bonding limitation shown in said circular is sufficient to provide bonds in the amount required by the Contract shall be deemed to be approved unless specifically rejected by the Agency. Bonds from all other sureties shall be accompanied by all of the documents enumerated in Code of Civil Procedure 995.660 (a). The Bidder shall pay all bond premiums, costs, and incidentals. Each bond shall incorporate, by reference, the Contract and be signed by both the Bidder and Surety and the signature ofthe authorized agent of the Surety shall be notarized. The Contractor shall provide a faithful performance/wan-anty bond and payment bond (labor and materials bond) for this contract. The faithful performance/warranty bond shall be in a sum not less than one hundred percent of the total amount payable by the terms of this contract. The Contractor shall provide bonds to secure payment of laborers and materials suppliers in a sum not less than one hundred percent of the total amount payable by the terms of this contract. Both bonds shall extend in full force and effect and be retained by the Agency during this project until they are released according to the provisions of this section. The faithful performance/warranty bond will be reduced to 25 percent of the original amount 30 days after recordation of the Notice of Completion and will remain in full force and effect for the one year warranty period and until all warranty repairs are completed to the satisfaction of the Engineer The bonds to secure payment of laborers and materials suppliers shall be released six months plus 30 days after recordation of the Notice of Completion if all claims have been paid. All bonds are to be placed with a surety insurance carrier admitted and authorized to transact the business of insurance in Califomia and whose assets exceed their liabilities in an amount equal to or in excess ofthe amount ofthe bond. The bonds are to contain the following documents: 1) An original, or a certified copy, of the un-revoked appointment, power of attorney, by laws, or other instrument entitiing or authorizing the person who executed the bond to do so. 2) A certified copy of the certificate of authority of the insurer issued by the insurance commissioner. If the bid is accepted, the Agency may require a financial statement ofthe assets and liabilities ofthe insurer at the end of the quarter calendar year prior to 30 days next preceding the date of the execution of the bond. The financial statement shall be made by an ofl'icer's certificate as defined in Section 173 of the Corporations Code. In the case of a foreign insurer, the financial statement may be verified by the oath of the principal officer or manager residing within the United States. ^^Revised 07/17/2015 Contract No. PKS16-02PKS 46 of 86 6"^ Should any bond become insufficient, the Contractor shall renew the bond within 10 days after receiving notice from the Agency. Should any Surety at any time be unsatisfactory to the Board, notice will be given the Contractor to that effect. No further payments shall be deemed due or will be made under the contract until a new Surety shall qualify and be accepted by the Board. Changes in the Work or extensions of time, made pursuant to the Contract, shall in no way release the Contractor or Surety from its obligations. Notice of such changes or extensions shall be waived by the Surety. 2-5 PLANS AND SPECIFICATIONS. 2-5.1 General. The Contractor shall keep at the Work site a copy ofthe Plans and Specifications, to which the Engineer shall have access at all times. The specifications for the work include the General Provisions, project technical specifications, Carisbad Engineering Standards (CES), Standard Specifications for Public Works Construction, (SSPWC), Part 2 & 3, and the latest supplements thereto, current edition at the time of bid opening as published by the "Greenbook" Committee of Public Works Standards, Inc., hereinafter designated "SSPWC", as amended. The construction plans consist of illumination summaries, equipment layout and control system summaries. The standard drawings used for this project are the latest edition of the San Diego Area Regional Standard Drawings, hereinafter designated SDRSD, as issued by the San Diego County Department of Public Works, together with the most recent editions of the City of Carisbad Engineering Standards and Carisbad Standard Drawings, as issued by the City of Carisbad and the Carisbad Municipal Water District, hereinafter designated as CES and CSD, respectively. Copies of some of the pertinent standard drawings are enclosed as an appendix to these General Provisions. The Plans, Speciflcations, and other Contract Documents shall govern the Wori<. The Contract Documents are intended to be complementary and cooperative. Anything specified in the Specifications and not shown on the Plans, or show/n on the Plans and not specified In the Specifications, shall be as though shown on or specified in both. The Plans shall be supplemented by such working drawings and shop drawings as are necessary to adequately control the Work. The Contractor shall ascertain the existence of any conditions affecting the cost of the Work through a reasonable examination of the Work site prior to submitting the Bid. Existing improvements visible at the Work site, forwhich no specific disposition is made on the Plans,, but which interfere with the completion of the Work, shall be removed and disposed of by the Contractor. The Contractor shall, upon discovering any error or omission in the Plans or Specifications, immediately call it to the attention of the Engineer. 2-5.2 Precedence of Contract Documents. If there is a conflict between Contract Documents, the document highest in precedence shall control. The precedence shall be the most recent edition ofthe following documents listed in order of highest to lowest precedence: 1) Permits from other agencies as may be required by law. 2) Change orders, whichever occurs last. 3) Contract addenda, whichever occurs last. 4) Contract. 5) Carisbad General Provisions, Technical Specifications, and Supplemental Provisions. 6) Plans. 7) Standards plans. ^ ^¥ Revised 07/17/2015 Contract No. PKS16-02PKS 47 of 86 a) City of Carisbad Standard Drawings. b) Carisbad Municipal Water District Standard Drawings. c) City of Carlsbad modifications to the San Diego Area Regional Standard Drawings. d) San Diego Area Regional Standard Drawings. e) Traffic Signal Design Guidelines and Standards. f) State of California Department of Transportation Standard Plans. g) State of California Department of Transportation Standard Speciflcations. h) California Manual on Uniform Trafllc Control Devices (CA MUTCD). 8) Standard Speciflcations for Public Works Construction, as amended. 9) Reference Specifications. 10) Manufacturer's Installation Recommendations Detail drawings shall take precedence over general drawings. Change Orders, Supplemental Agreements and approved revisions to Plans and Specifications will take precedence over items 2) through 9) above. Detailed plans and plan views shall have precedence over general plans. 2-5.3 Submittals. 2-5.3.1 General. Submittals shall be provided, at the Contractor's expense, as required in 2-5.3.2, 2- 5.3.3 and 2-5.3.4, when required by the Plans or Special Provisions, or when requested by the Engineer. Materials shall neither be furnished nor fabricated, nor shall any work for which submittals are required by performed, before the required submittals have been reviewed and accepted by the Engineer. Neither review nor acceptance of submittals by the Engineer shall relieve the Contractor from responsibility for errors, omissions, or deviations from the Contract Documents, unless such deviations were specifically called to the attention of the Engineer in the letter of transmittal. The Contractor shall be responsible for the correctness of the submittals. The Contractor shall allow a minimum of 20 working days for review of submittals unless othenvise specified in the Special Provisions. Each submittal shall be accompanied by a letter of transmittal. Each submittal shall be consecutively numbered. Resubmittals shall be labeled with the number ofthe original submittal followed by an ascending alphabetical designation (e.g. The label '4-C' would indicate the third instance that the fourth submittal had been given to the Engineer). Each sheet of each submittal shall be consecutively numbered. Each set of shop drawings and submittals shall be accompanied by a letter of transmittal on the Contractor's letterhead. The Letter of Transmittal shall contain the following: 1) Project titie and Agency contract number. 2) Number of complete sets. 3) Contractor's certification statement. 4) Specification section number(s) pertaining to material submitted for review. 5) Submittal number (Submittal numbers shall be consecutive including subsequent submittals for the same materials.) 6) Description of the contents of the submittal. 7) Identification of deviations from the contract documents. Revised 07/17/2015 Contract No. PKS16-02PKS 48 of 86 6^ When submiti:ed for the Engineer's review. Shop Drawings shall bear the Contractor's certification that the Contractor has reviewed, checked, and approved the Shop Drawings and that they are in conformance with the requirements of the Contract Documents. The Contractor shall subscribe to and shall place the following certification on all submittals: "I hereby certify that the (equipment, material) shown and marked in this submittal is that proposed to be incorporated into this Project, is in compliance with the Contract Documents, can be installed in the allocated spaces, and is submitted for approval." By: Title: Date: Company Name: 2-5.3.2 Working Drawings. Working drawings are drawings showing details not shown on the Plans which are required to be designed by the Contractor. Working drawings shall be of a size and scale to clearly show all necessary details. Six copies and one reproducible shall be submitted. If no revisions are required, three ofthe copies will be returned to the Contractor. If revisions are required, the Engineer will return one copy along with the reproducible for resubmission. Upon acceptance, the Engineer will return two ofthe copies to the Contractor and retain the remaining copies and the reproducible. Working drawings are required in the following sections: TABLE 2-5.3.2 (A) Item Section Number Title Subject 2-5.3.3 Shop Drawings. Shop drawings are drawings showing details of manufactured or assembled products proposed to be incorporated into the Work. Shop drawings required shall be as specified in the Special Provisions. Revised 07/17/2015 Contract No. PKS16-02PKS 5'^ 49 of 86 2-5.3.4 Supporting Information. Supporting information is information required by the Specifications for the purposes of administration of the Contract analysis for verification of conformance with the Specifications, the operation and maintenance of a manufactured product or system to be constructed as part of the Work, and other information as may be required by the Engineer. Six copies of the supporting information shall be submitted to the Engineer prior to the start of the Work unless othenvise specified in the Special Provisions or directed by the Engineer. Supporting information for systems shall be bound together and include all manufactured items for the system. If resubmittal is not required, three copies will be returned to the Contractor. Supporting information shall consist ofthe following and is required unless otherwise specified in the Special Provisions: 1) List of Subcontractors per 2-3.2. 2) List of Materials per 4-1.4. 3) Certifications per 4-1.5. 4) Construction Schedule per 6-1. 5) Confined Space Entry Program per 7-10.4.4. 6) Concrete mix designs per 201-1.1. 7) Asphalt concrete mix designs per 203-6.1. 8) Data, including, but not limited to, catalog sheets, manufacturer's brochures, technical bulletins, specifications, diagrams, product samples, and other information necessary to describe a system, product or item. This information is required for irrigation systems, street lighting systems, and traffic signals, and may also be required for any product, manufactured item, or system. 2-5.4 RECORD DRAWINGS. The Contractor shall provide and keep up-to-date a complete "as-built" record set of blue-line prints, which shall be corrected in red daily and show every change from the original drawings and specifications and the exact "as-built" locations, sizes and kinds of equipment, underground piping, valves, and all other work not visible at surface grade. Prints for this purpose may be obtained from the Agency at cost. This set of drawings shall be kept on the job and shall be used only as a record set and shall be delivered to the Engineer within ten (10) days of completion ofthe work. Payment for performing the work required by Section 2-5.4 shall be included in the various bid items and no additional payment will be made therefore. 2-6 WORK TO BE DONE. The Contractor shall perform all work necessary to complete the Contract in a satisfactory manner. Unless otherwise provided, the Contractor shall furnish all materials, equipment, tools, labor, and incidentals necessary to complete the Work. 2-10 AUTHORITY OF BOARD AND ENGINEER. The Board has the flnal authority in all matters affecting the Work. Within the scope ofthe Contract, the Engineer has the authority to enforce compliance with the Plans and Speciflcations. The Contractor shall promptly comply with instructions from the Engineer or an authorized representative. The decision ofthe Engineer is final and binding on all questions relating to: quantities; acceptability of material, equipment, or work; execution, progress or sequence of work; and interpretation ofthe Plans, Specifications, or other drawings. This shall be precedent to any payment under the Contract, unless otherwise ordered by the Board. 2-10.1 Availability of Records, The Contractor shall, at no charge to the Agency, provide copies of all records in the Contractor's or subcontractor's possession pertaining to the work that the Engineer may request. 2-10.2 Audit and Inspection, Contractor agrees to maintain and/or make available, to the Engineer, within San Diego County, accurate books and accounting records relative to all its activities and to contractually require all subcontractors to this Contract to do the same. The Engineer shall have the right to monitor, assess, and evaluate Contractor's and its subcontractors performance pursuant to this Agreement, said monitoring, assessments, and evaluations to include, but not be limited to, audits, inspection of premises, reports, contracts, subcontracts and interviews of Contractor's staff and the staff of all subcontractors to this contract. At any time during normal business hours and as often as the Engineer may deem necessary, upon reasonable advance notice. Contractor shall make available to the Engineer for examination, all of its, and all subcontractors to this contract, records with respect to all matters covered by this Contract and will permit the Engineer to audit, examine, copy and make excerpts or transcripts from such data and records, and to make audits of all invoices, materials, payrolls, records of personnel, and other data relating to all matters covered by this Contract. However Revised 07/17/2015 Contract No. PKS16-02PKS 50^86 any such activities shall be carried out in a manner so as to not unreasonably interfere with Contractor's ongoing business operations. Contractor and all subcontractors to this contract shall maintain such data and records for as long as may be required by applicable laws and regulations. 2-11 INSPECTION. The Work is subject to inspection and approval by the Engineer. The Contractor shall notify the Engineer before noon ofthe working day before inspection is required. Work shall be done only in the presence ofthe Engineer, unless otherwise authorized. Any work done without proper inspection vvill be subject to rejection. The Engineer and any authorized representatives shall at all times have access to the Work during its construction at shops and yards as well as the project site. The Contractor shall provide every reasonable facility for ascertaining that the materials and workmanship are in accordance with these specifications. Inspection ofthe Work shall not relieve the Contractor of the obligation to fulfill all conditions of the Contract. ^•''Revised 07/17/2015 Contract No. PKS16-02PKS 51 of 86 SECTION 3 - CHANGES IN WORK 3-1 CHANGES REQUESTED BY THE CONTFIACTOR. 3-1.1 General. Changes in the Plans and Specifications, requested in writing by the Contractor, which do not materially affect the Work and which are not detrimental to the Work or to the interests ofthe Agency, may be granted by the Engineer. Nothing herein shall be construed as granting a right to the Contractor to demand acceptance of such changes. 3-1.2 Payment for Changes Requested by the Contractor. If such changes are granted, they shall be made at a reduction in cost or no additional cost to the Agency. 3-2 CHANGES INITIATED BY THE AGENCY. 3-2.1 General. The Agency may change the Plans, Specifications, character of the work, or quantity of work provided the total arithmetic dollar value of all such changes, both additive and deductive, does not exceed 25 percent ofthe Contract Price. Should it become necessary to exceed this limitation, the change shall be by written Supplemental Agreement between the Contractor and Agency, unless both parties agree to proceed with the change by Change Order. Change Orders shall be in writing and state the dollar value of the change or established method of payment, any adjustment in contract time of completion, and when negotiated prices are involved, shall provide for the Contractor's signature indicating acceptance. 3-2.2 Payment. 3-2.2.1 Contract Unit Prices. If a change is ordered in an item of work covered by a Contract Unit Price, and such change does not involve substantial change in character of the work from that shown on the Plans or specified in the Specifications, then an adjustment in payment will be made. This adjustment will be based upon the increase or decrease in quantity and the Contract Unit Price. If the actual quantity of an item of work covered by a Contract Unit Price and constructed in conformance with the Plans and Specifications varies from the Bid quantity by 50 percent or less, payment will be made at the Contract Unit Price. If the actual quantity of said item of work varies from the Bid quantity by more than 50 percent, payment will be made per Section 3-2.2.2 or 3-2.2.3 as appropriate. If a change is ordered in an item of work covered by a Contract Unit Price, and such change does involve a substantial change in the character ofthe work from that shown on the Plans or specified in the Specifications, an adjustment in payment will be made per Section 3-2.4. 3-2.2.2 Increases of More Than 50 Percent. Should the actual quantity of an item of work covered by a Contract Unit Price and constructed in conformance with the Plans and Speciflcations, exceed the Bid quantity by more than 50 percent, payment for the quantity in excess of 150 percent ofthe Bid quantity will be made on the basis of an adjustment in the Contract Unit Price mutually agreed to by the Contractor and the Agency, or at the option of the Engineer, on the basis of Extra Work per Section 3-3. The Extra Work per Section 3-3, basis of payment, shall not include fixed costs. Fixed costs shall be deemed to have been recovered by the Contractor through payment for 150 percent ofthe Bid quantity at the Contract Unit Price. 3-2.2.3 Decreases of More Than 50 Percent. Should the actual quantity of an item of work covered by a Contract Unit Price, and constructed in conformance with the Plans and Specifications, be less than 50 percent ofthe Bid quantity, an adjustment in payment will not be made unless so requested in writing by the Contractor. If the Contractor so requests, payment will be made on the basis of an Revised 07/17/2015 Contract No. PKS16-02PKS 52 of 86 adjustment in the Contract Unit Price mutually agreed to by the Contractor and the Agency, or at the option of the Engineer, on the basis of Extra Work per Section 3-3; however, in no case will payment be less than would be made for the actual quantity at the Contract Unit Price nor more than would be made for 50 percent of the Bid quantity at the Contract Unit Price. 3-2.3 Stipulated Unit Prices. Stipulated Unit Prices are unit prices established by the Agency in the Contract Documents as distinguished from Contract Unit Prices submitted by the Contractor. Stipulated Unit Prices may be used for the adjustment of Contract changes when so specified in the Special Provisions. 3-2.4 Agreed Prices. Agreed Prices are prices for new or unforeseen work, or adjustments in Contract Unit Prices per Section 3-2.2, established by mutual agreement between the Contractor and the Agency. If mutual agreement cannot be reached, the Engineer may direct the Contractor to proceed on the basis of Extra Work in accordance per Section 3-3, except as otherwise specified in Sections 3- 2.2.2 and 3-2.2.3. 3.2.4.1 Schedule of Values. Prior to construction. Contractor shall provide a schedule of values for all lump sum bid items that shall be used for the purpose of progress payments. The prices shall be valid for the purpose of change orders to the project. 3.2.5 Eliminated Items. Should any Bid item be eliminated in its entirety, payment will be made to the Contractor for its actual costs incurred in connection with the eliminated item prior to notification in writing from the Engineer so stating its elimination. If material conforming to the Plans and Specifications is ordered by the Contractor for use in the eliminated item prior to the date of notification of elimination by the Engineer, and if the order for that material cannot be canceled, payment will be made to the Contractor for the actual cost ofthe material. In this case, the material shall become the property of the Agency. Payment will be made to the Contractor for its actual costs for any further handling. If the material is returnable, the material shall be returned and payment will be made to the Contractor for the actual cost of charges made by the supplier for retuming the material and for handling by the Contractor. Actual costs, as used herein, shall be computed on the basis of Extra Work per Section 3-3. 3-3 EXTRA WORK. 3-3.1 General. New or unforeseen work will be classified as "extra work" when the Engineer determines that it is not covered by Contract Unit Prices or stipulated unit prices. 3-3.2 Payment. 3-3.2.1 General. When the price for the extra work cannot be agreed upon, the Agency will pay for the extra work based on the accumulation of costs as provided herein. 3-3.2.2 Basis for Establishing Costs. (a) Labor. The costs of labor will be the actual cost for wages of workers performing the extra work at the time the extra work is done, plus employer payments of payroll taxes, workers compensation insurance, liability insurance, health and welfare, pension, vacation, apprenticeship funds, and other direct costs, resulting from Federal, State, or local laws, as well as assessments or benefits required by lawful collective bargaining agreements. The use of a labor classiflcation which would increase the extra work cost will not be permitted unless the Contractor establishes the necessity for such additional costs. Labor costs for equipment operators and helpers shall be reported only when such costs are not included in the invoice for equipment rental. The labor cost for foremen shall be proportioned to all of their assigned work and only that applicable to extra work will be paid. 'Revised 07/17/2015 Contract No. PKS16-02PKS 53 of 86 IG.I Nondirect labor costs, including superintendence, shall be considered part of the markup of Section 3-3.2.3 (a). (b) Materials. The cost of materials reported shall be at invoice or lowest current price at which such materials are locally available and delivered to the job site in the quantities involved, plus sales tax, freight, and delivery. The Agency reserves the right to approve materials and sources of supply, or to supply materials to the Contractor if necessary for the progress of the Work. No markup shall be applied to any material provided by the Agency. (c) Tool and Equipment Rental. No payment will be made for the use of tools which have a replacement value of $200 or less. Regardless of ownership, the rates and right-of-way delay factors to be used in determining rental and delay costs shall be the edition ofthe, "Labor Surcharge and Equipment Rental Rates" published by CALTF?ANS, current at the time of the actual use of the tool or equipment. The right-of-way delay factors therein shall be used as multipliers of the rental rates for determining the value of costs for delay to the Contractor and subcontractors, if any The labor surcharge rates published therein are not a part of this contract. The rental rates paid shall include the cost of fuel, oil, lubrication, supplies, small tools, necessary attachments, repairs and maintenance of any kind, depreciation, storage, insurance, and all incidentals. Necessary loading and transportation costs for equipment used on the extra work shall be included. If equipment is used intermittently and, when not in use, could be returned to its rental source at less expense to the Agency than holding it at the Work site, it shall be returned, unless the Contractor elects to keep it at the Work site, at no expense to the Agency. All equipment shall be acceptable to the Engineer, in good working condition, and suitable forthe purpose for which it is to be used. Manufacturer's ratings and approved modifications shall be used to classify equipment and it shall be powered by a unit of at least the minimum rating recommended by the manufacturer. The reported rental time for equipment already at the Work site shall be the duration of its use on the extra work. This time begins when equipment is first put into actual operation on the extra work, plus the time required to move it from its previous site and back, or to a closer site. (d) Other Items. The Agency may authorize other items which may be required on the extra work, including labor, services, material, and equipment These items must be different in their nature from those required for the Work, and be of a type not ordinarily available from the Contractor or Subcontractors. Invoices covering all such items in detail shall be submitted with the request for payment (e) Invoices. Vendors' invoices for material, equipment rental and other expenditures shall be submitted with the request for payment If the request for payment is not substantiated by invoices or other documentation, the Agency may establish the cost of the item involved at the lowest price which was current at the time ofthe report. Revised 07/17/2015 Contract No. PKS16-02PKS 54 of 86 3-3.2.3 Markup. (a) Work by Contractor. The following percentages shall be added to the Contractor's costs and shall constitute the markup for all overhead and profits: 1) Labor 20 2) Materials 15 3) Equipment Rental 15 4) Other Items and Expenditures .. 15 To the sum ofthe costs and markups provided for in this section, 1 percent shall be added as compensation for bonding. (b) Work by Subcontractor. When all or any part of the extra work is performed by a Subcontractor, the mari^up established in Section 3-3.2.3(a) shall be applied to the Subcontractor's actual cost of such work. A markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of $5,000 ofthe subcontracted portion of the extra work may be added by the Contractor 3-3.3 Daily Reports by Contractor. When the price for the extra work cannot be agreed upon, the Contractor shall submit a daily report to the Engineer on forms approved by the Agency. Included are applicable delivery tickets, listing all labor, mate/ials, and equipment involved for that day, and other services and expenditures when authorized. Payment for extra work will not be made until such time that the Contractor submits completed daily reports and all supporting documents to the Engineer. Failure to submit the daily report by the close ofthe next working day may waive any rights for that day. An attempt shall be made to reconcile the report daily, and it shall be signed by the Engineer and the Contractor. In the event of disagreement, pertinent notes shall be entered by each party to explain points which cannot be resolved immediately. Each party shall retain a signed copy of the report. Reports by Subcontractors or others shall be submitted through the Contractor. The report shall: 1. Show names of workers, classifications, and hours worked. 2. Describe and list quantities of materials used. 3. Show type of equipment, size, identiflcation number, and hours of operation, including loading and transportation, if applicable. 4. Describe other services and expenditures in such detail as the Agency may require. 3-4 CHANGED CONDITIONS. The Contractor shall promptly notify the Engineer of the following Work site conditions (hereinafl:er called changed conditions), in writing, upon their discovery and before they are disturbed: 1. Subsurface or latent physical conditions differing materially from those represented in the Contract; 2. Unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character being performed; and 3. Material differing from that represented in the Contract which the Contractor believes may be hazardous waste, as deflned in Section 25117 ofthe Health and Safety Code, that is required to be removed to a Class I, Class 11, or Class 111 disposal site in accordance with provisions of existing law. The Engineer will promptly investigate conditions which appear to be changed conditions. If the Engineer determines that conditions are changed conditions and they will materially affect performance '•F Revised 07/17/2015 Contract No. PKS16-02PKS 55 of 86 time, the Contractor, upon submitting a written request, will be granted an extension of time subject to the provisions of 6-6. If the Engineer determines that the conditions do not justify an adjustment in compensation, the Contractor will be notified in writing. This notice will also advise the Contractor of its obligation to notify the Engineer in writing if the Contractor disagrees. The Contractor's failure to give notice of changed conditions promptly upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith. The Contractor shall not be entitled to the payment of any additional compensation for any act, or failure to act, by the Engineer, including failure or refusal to issue a change order, or for the happening of any event, thing, occurrence, or other cause, unless the Contractor shall have first given the Engineer due written notice of potential claim as hereinafter specified. Compliance with this section shall not be required as a prerequisite to notice provisions in Section 6-7.3 Contract Time Accounting, nor to any claim that is based on differences in measurement or errors of computation as to contract quantities. The written notice of potential claim for changed conditions shall be submitted by the Contractor to the Engineer upon their discovery and prior to the time that the Contractor performs the work giving rise to the potential claim. The Contractor's failure to give written notice of potential claim for changed conditions to the agency upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith. The Contractor shall provide the City with a written document containing a description ofthe particular circumstances giving rise to the potential claim, the reasons for which the Contractor believes additional compensation may be due and nature of any and all costs involved within 20 working days of the date of service of the written notice of potential claim for changed conditions. Verbal notifications are disallowed. The potential claim shall include the following certification relative to the California False Claims Act, Government Code Sections 12650-12655. "The undersigned certifies that the above statements are made in full cognizance of the California False Claims Act Government Code Sections 12650-12655. The undersigned further understands and agrees that this potential claim, unless resolved, must be restated as a claim in response to the City's proposed final estimate in order for it to be further considered." By: ^ Title: Date: Company Name: The Contractor's estimate of costs may be updated when actual costs are known. The Contractor shall submit substantiation of its actual costs to the Engineer within 20 working days after the affected work is completed. Failure to do so shall be sufficient cause for denial of any claim subsequently filed on the basis of said notice of potential claim. It is the intention of this section that differences between the parties arising under and by virtue of the contract be brought to the attention of the Engineer at the eariiest possible time in order that such matters be settled, if possible, or other appropriate action promptly taken. 3-5 DISPUTED WORK. The Contractor shall give the agency written notice of potential claim prior to commencing any disputed work. Failure to give said notice shall constitute a waiver of all claims in connection therewith. If the contractor and the agency are unable to reach agreement on disputed work, the Agency may direct the contractor to proceed with the work. Prior to proceeding with dispute resolution pursuant to Public Contract Code provisions specifled i Revised 07/17/2015 Contract No. PKS16-02PKS 56 of 86 hereinafter, the contractor shall attempt to resolve all disputes informally through the following dispute resolution chain of command: 1. Project Inspector (a.k.a. Parks Inspector) 2. Construction Manager (a.k.a. Parks Supervisor) 3. Parks Superintendent 4. Engineer (or Parks and Recreation Director, as Engineer's approved representative) 5. City Manager The Contractor shall submit a complete report within 20 working days after completion of the disputed work stating its position on the claim, the contractual basis for the claim, along with all documentation supporting the costs and all other evidentiary materials. At each level of claim or appeal of claim the City will, within 10 working days of receipt of said claim or appeal of claim, review the Contractor's report and respond with a position, request additional information or request that the Contractor meet and present its report. When additional information or a meeting is requested the City will provide its position within 10 working days of receipt ofsaid additional information or Contractor's presentation of its report. The Contractor may appeal each level's position up to the City Manager after which the Contractor may proceed under the provisions of the Public Contract Code. The authority within the dispute resolution chain of command is limited to recommending a resolution to a claim to the City Manager. Actual approval of the claim is subject to the change order provisions in the contract. All claims by the contractor for $375,000 or less shall be resolved in accordance with the procedures in the Public Contract Code, Division 2, Part 3, Chapter 1, Article 1.5 (commencing with Section 20104) which is set forth below: ARTICLE 1.5 RESOLUTION OF CONSTRUCTION CLAIMS 20104. (a)(1) This article applies to all public works claims ofthree hundred seventy-flve thousand dollars ($375,000) or less which arise between a contractor and a local agency. (2) This article shall not apply to any claims resulting from a contract between a contractor and a public agency when the public agency has elected to resolve any disputes pursuant to Article 7.1 (commencing with Section 10240) of Chapter 1 of Part 2. (b) (1) "Public work" has the same meaning as in Sections 3100 and 3106 ofthe Civil Code, except that "public work" does not include any work or improvement contracted for by the state or the Regents of the University of California. (2) "Claim" means a separate demand by the contractor for (A) a time extension, (B) payment of money or damages arising from work done by, or on behalf of, the contractor pursuant to the contract for a public work and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to, or (C) an amount the payment of which is disputed by the local agency. (c) The provisions of this article or a summary thereof shall be set forth in the plans or specifications for any work which may give rise to a claim under this article. (d) This article applies only to contracts entered into on or after January 1, 1991. 20104.2. For any claim subject to this article, the following requirements apply: (a) The claim shall be in writing and include the documents necessary to substantiate the claim. Claims must be filed on or before the date of final payment. Nothing in this subdivision is intended to extend the time limit or supersede notice requirements otherwise provided by contract for the filing of claims. (b) (1) For claims of less than fifty thousand dollars ($50,000), the local agency shall respond in writing to any written claim within 45 days of receipt ofthe claim, or may request, in writing, within 30 days of receipt ofthe claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant. (2) If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement ofthe local agency and the claimant. \sfb V Revised 07/17/2015 Contract No. PKS16-02PKS 57 of 86 (3) The local agency's written response to the claim, as further documented, shall be submitted to the claimant within 15 days after receipt of the further documentation or within a period of time no greater than that taken by the claimant in producing the additional information, whichever is greater. (c) (1) For claims of over fifty thousand dollars ($50,000) and less than or equal to three hundred seventy-five thousand dollars ($375,000), the local agency shall respond in writing to all written claims within 60 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant. (2) If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement ofthe local agency and the claimant. (3) The local agency's written response to the claim, as further documented, shall be submitted to the claimant within 30 days after receipt of the further documentation, or within a period of time no greater than that taken by the claimant in producing the additional information or requested documentation, whichever is greater. (d) If the claimant disputes the local agency's written response, or the local agency fails to respond within the time prescribed, the claimant may so notify the local agency, in writing, either within 15 days of receipt ofthe local agency's response or within 15 days ofthe local agency's failure to respond within the time prescribed, respectively, and demand an informal conference to meet and confer for settlement ofthe issues in dispute. Upon a demand, the local agency shall schedule a meet and confer conference within 30 days for settlement of the dispute. (e) Following the meet and confer conference, if the claim or any portion remains in dispute, the claimant may file a claim as provided in Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Titie 1 of the Government Code. For purposes of those provisions, the running ofthe period of time within which a claim must be filed shall be tolled from the time the claimant submits his or her written claim pursuant to subdivision (a) until the time that claim is denied as a result of the meet and confer process, including any period of time utilized by the meet and confer process. (f) This article does not apply to tort claims and nothing in this article is intended nor shall be construed to change the time periods for filing tort claims or actions specified by Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Titie 1 of the Government Code. Revised 07/17/2015 Contract No. PKS16-02PKS 58 of 86 20104.4. The following procedures are established for all civil actions filed to resolve claims subject to this article: (a) Within 60 days, but no eariier than 30 days, following the filing or responsive pleadings, the court shall submit the matter to non-binding mediation unless waived by mutual stipulation of both parties. The mediation process shall provide for the selection within 15 days by both parties of a disinterested third person as mediator, shall be commenced within 30 days of the submittal, and shall be concluded within 15 days from the commencement ofthe mediation unless a time requirement is extended upon a good cause showing to the court or by stipulation of both parties. If the parties fail to select a mediator within the 15-day period, any party may petition the court to appoint the mediator (b) (1) If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 ofthe Code of Civil Procedure, notwithstanding Section 1141.11 of that code. The Civil Discovery Act of 1986 (Article 3 (commencing with Section 2016) of Chapter 3 of Titie 3 of Part 4 of the Code of Civil procedure) shall apply to any proceeding brought under the subdivision consistent with the rules pertaining to judicial arbitration. (2) Notwithstanding any other provision of law, upon stipulation of the parties, arbitrators appointed for purposes of this article shall be experienced in construction law, and, upon stipulation ofthe parties, mediators and arbitrators shall be paid necessary and reasonable hourly rates of pay not to exceed their customary rate, and such fees and expenses shall be paid equally by the parties, except in the case of arbitration where the arbitrator, for good cause, determines a difl'erent division. In no event shall these fees or expenses be paid by state or county funds. (3) In addition to Chapter 2.5 (commencing with Section 1141.10) Title 3 of Part 3 ofthe Code of Civil Procedure, any party who after receiving an arbitration award requests a trial de novo but does not obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, pay the attorney's fees of the other pariy arising out of the trial de novo. (c) The court may, upon request by any party, order any witnesses to participate in the mediation or arbitration process. 20104.6. (a) No local agency shall fail to pay money as to any portion of a claim which is undisputed except as otherwise provided in the contract. (b) In any suit filed under Section 20104.4, the local agency shall pay interest at the legal rate on any arbitration award or judgment. The interest shall begin to accrue on the date the suit is filed in a court of law. Although not to be construed as proceeding under extra work provisions, the Contractor shall keep and furnish records of disputed work in accordance with Section 3-3. ^¥ Revised 07/17/2015 Contract No. PKS16-02PKS 59 of 86 SECTION 4 - CONTROL OF MATERIALS 4-1 MATERIALS AND WORKMANSHIP. 4-1.1. General. All materials, parts, and equipment furnished by the Contractor in the Work shall be new, high grade, and free from defects. Quality of work shall be in accordance with the generally accepted standards. Material and work quality shall be subject to the Engineer's approval. Materials and work quality not conforming to the requirements of the Specifications shall be considered defective and will be subject to rejection. Defective work or material, whether in place or not shall be removed immediately from the site by the Contractor, at its expense, when so directed by the Engineer. If the Contractor fails to replace any defective or damaged work or material after reasonable notice, the Engineer may cause such work or materials to be replaced. The replacement expense will be deducted from the amount to be paid to the Contractor. Used or secondhand materials, parts, and equipment may be used only if permitted by the Specifications. 4-1.2 Protection of Work and Materials. The Contractor shall provide and maintain storage facilities and employ such measures as will preserve the specified quality and fitness of materials to be used in the Work. Stored materials shall be reasonably accessible for inspection. The Contractor shall also adequately protect new and existing work and all items of equipment for the duration of the Contract. The Contractor shall not, without the Agency's consent, assign, sell, mortgage, hypothecate, or remove equipment or materials which have been installed or delivered and which may be necessary for the completion of the Contract. 4-1.3 Inspection Requirements. 4-1.3.1 General. Unless othenvise specified, inspection is required at the source for such typical materials and fabricated items as bituminous paving mixtures, structural concrete, metal fabrication, metal casting, welding, concrete pipe manufacture, protective coating application, and similar shop or plant operations. Steel pipe in sizes less than 18 inches and vitrified clay and cast iron pipe in all sizes are acceptable upon certification as to compliance with the Specifications, subject to sampling and testing by the Agency. Standard items of equipment such as electric motors, conveyors, elevators, plumbing fixtures, etc., are subject to inspection at the job site only. Special items of equipment such as designed electrical panel boards, large pumps, sewage plant equipment, etc., are subject to inspection at the source, normally only for performance testing. The Specifications may require inspection at the source for other items not typical of those listed in this section. The Contractor shall provide the Engineer free and safe access to any and all parts of work at any time. Such free and safe access shall include means of safe access and egress, ventilation, lighting, shoring, dewatering and all elements pertaining to the safety of persons as contained in the State of California, California Code of Regulations, Title 8, Industrial Relations, Chapter 4, Division of Industrial Safety, Subchapter 4, Construction Safety Orders and such other safety regulations as may apply Contractor shall furnish Engineer with such information as may be necessary to keep the Engineer fully informed regarding progress and manner of work and character of materials. Inspection or testing of the whole or any portion of the work or materials incorporated in the work shall not relieve Contractor from any obligation to fulfill this Contract. 4-1.3.2 Inspection of Materials Not Locally Produced. When the Contractor intends to purchase materials, fabricated products, or equipment from sources located more than 50 miles outside Revised 07/17/2015 Contract No. PKS16-02PKS geographical limits of the Agency, an inspector or accredited testing laboratory (approved by the Engineer), shall be engaged by the Contractor at its expense, to inspect the materials, equipment or process. This approval shall be obtained before producing any material or equipment. The inspector or representative of the testing laboratory shall judge the materials by the requirements of the Plans and Specifications. The Contractor shall forward reports required by the Engineer. No material or equipment shall be shipped nor shall any processing, fabrication or treatment of such materials be done without proper inspection by the approved agent. Approval by said agent shall not relieve the Contractor of responsibility for complying with the Contract requirements. 4-1.3.3 Inspection by the Agency. The Agency will provide all inspection and testing laboratory services within 50 miles of the geographical limits of the Agency. For private contracts, all costs of inspection at the source, including salaries and mileage costs, shall be paid by the permittee. 4-1.4 Test of Material. Before incorporation in the Work, the Contractor shall submit samples of materials, as the Engineer may require, at no cost to the Agency. The Contractor, at its expense, shall deliver the materials for testing to the place and at the time designated by the Engineer. Unless otherwise provided, all initial testing will be performed under the direction of the Engineer, and at no expense to the Contractor. If the Contractor is to provide and pay for testing, it will be stated in the Specifications. For private contracts, the testing expense shall be borne by the permittee. The Contractor shall notify the Engineer in writing, at least 15 days in advance, of its intention to use materials for which tests are specified, to allow sufficient time to perform the tests. The notice shall name the proposed supplier and source of material. If the notice of intent to use is sent before the materials are available for testing or inspection, or is sent so far in advance that the materials on hand at the time will not last but will be replaced by a new lot prior to use on the Work, it will be the Contractor's responsibility to renotify the Engineer when samples which are representative may be obtained. Except as specified in these Provisions, the Agency will bear the cost of testing of locally produced materials and/or on-site workmanship where the results of such tests meet or exceed the requirements indicated in the Standard Specifications, Technical Speciflcation, and any Supplemental Provisions. The cost of all other tests shall be borne by the Contractor At the option of the Engineer, the source of supply of each of the materials shall be approved by the Engineer before the delivery is started. All materials proposed for use may be inspected or tested at any time during their preparation and use. If, after incorporating such materials into the Work, it is found that sources of supply that have been approved do not furnish a uniform product, or if the product from any source proves unacceptable at any time, the Contractor shall furnish approved material from other approved sources. If any product proves unacceptable after improper storage, handling or for any other reason it shall be rejected, not incorporated into the work and shall be removed from the project site all at the Contractor's expense. Compaction tests may be made by the Engineer and all costs for tests that meet or exceed the requirements of the specifications shall be borne by the Agency. Said tests may be made at any place along the work as deemed necessary by the Engineer. The costs of any retests made necessary by noncompliance with the specifications shall be bome by the Contractor. 4-1.5 Certification. The Engineer may waive materials testing requirements of the Specifications and accept the manufacturer's written certification that the materials to be supplied meet those requirements. Material test data may be required as part ofthe certification. 4-1.6 Trade Names or Equals. The Contractor may supply any of the materials specified or offer an equivalent. The Engineer shall determine whether the material offered is equivalent to that specified. Adequate time shall be allowed for the Engineer to make this determination. Revised 07/17/2015 Contract No. PKS16-02PKS 61 of 86 Whenever any particular material, process, or equipment is indicated by patent, proprietary or brand name, or by name of manufacturer, such wording is used for the purpose of facilitating its description and shall be deemed to be followed by the words or equal. A listing of materials is not intended to be comprehensive, or in order of preference. The Contractor may offer any material, process, or equipment considered to be equivalent to that indicated. The substantiation of offers shall be submitted as provided in the contract documents. The Contractor shall, at its expense, furnish data concerning items offered by it as equivalent to those specifled. The Contractor shall have the material tested as required by the Engineer to determine that the quality, strength, physical, chemical, or other characteristics, including durability, flnish, efficiency, dimensions, service, and suitability are such that the item will fulfill its intended function. Test methods shall be subject to the approval of the Engineer. Test results shall be reported promptly to the Engineer, who will evaluate the results and determine if the substitute item is equivalent. The Engineer's findings shall be final. Installation and use of a substitute item shall not be made until approved by the Engineer. If a substitute offered by the Contractor is not found to be equal to the specifled material, the Contractor shall furnish and install the specified material. The specifled Contract completion time shall not be affected by any circumstance developing from the provisions of this section. The Contractor is responsible for the satisfactory performance of substituted items. If, in the sole opinion of the Engineer, the substitution is determined to be unsatisfactory in performance, appearance, durability, compatibility with associated items, availability of repair parts and suitability of application the Contractor shall remove the substituted item and replace it with the originally specified item at no cost to the Agency. 4-1.7 Weighing and Metering Equipment. All scales and metering equipment used for proportioning materials shall be inspected for accuracy and certified within the past 12 months by the State of California Bureau of Weights and Measures, by the County Director or Sealer of Weights and Measures, or by a scale mechanic registered with or licensed by the County. The accuracy of the work of a scale service agency, except as stated herein, shall meet the standards of the California Business and Professions Code and the Califomia Code of Regulations pertaining to weighing devices. A certificate of compliance shall be presented, prior to operation, to the Engineer for approval and shall be renewed whenever required by the Engineer at no cost to the Agency. All scales shall be arranged so they may be read easily from the operator's platform or area. They shall indicate the true net weight without the application of any factor. The figures of the scales shall be cleariy legible. Scales shall be accurate to within 1 percent when tested with the plant shut down. Weighing equipment shall be so insulated against vibration or moving of other operating equipment in the plant area that the error in weighing with the entire plant running will not exceed 2 percent for any setting nor 1.5 percent for any batch. 4-1.8 Calibration of Testing Equipment. Testing equipment, such as, but not limited to pressure gages, metering devices, hydraulic systems, force (load) measuring instruments, and strain-measuring devices shall be calibrated by a testing agency acceptable to the Engineer at intervals not to exceed 12 months and following repairs, modification, or relocation of the equipment Calibration certificates shall be provided when requested by the Engineer. 4-1.9 Construction Materials Dispute Resolution (Soils, Rock Materials, Concrete, Mortar and Related Materials, Masonry Materials, Bituminous Materials, Rock Products, and Modified Asphalts). In the interest of safety and public value, whenever credible evidence arises to contradict the test values of materials, the Agency and the Contractor will initiate an immediate and cooperative investigation. Test values of materials are results ofthe materials' tests, as defined by these _ .-^ Revised 07/17/2015 Contract No. PKS16-02PKS 62 of 86 Specifications or by the special provisions, required to accept the Work. Credible evidence is process observations or test values gathered using industry accepted practices. A contradiction exists whenever test values or process observations of the same or similar materials are diverse enough such that the work acceptance or performance becomes suspect The investigation shall allow access to all test results, procedures, and facilities relevant to the disputed work and consider all available information and, when necessary, gather new and additional information in an attempt to determine the validity, the cause, and if necessary, the remedy to the contradiction. If the cooperative investigation reaches any resolution mechanism acceptable to both the Agency and the Contractor, the contradiction shall be considered resolved and the cooperative investigation concluded. Whenever the cooperative investigation is unable to reach resolution, the investigation may then either conclude without resolution or continue by written notification of one party to the other requesting the implementation of a resolution process by committee. The continuance of the investigation shall be contingent upon recipient's agreement and acknowledged in writing within 3 calendar days after receiving a request. Without acknowledgement, the investigation shall conclude without resolution. The committee shall consist of three State of California Registered Civil Engineers. Within 7 calendar days after the written request notification, the Agency and the Contractor will each select one engineer. Within 14 calendar days of the written request notification, the two selected engineers will select a third engineer. The goal in selection of the third member is to complement the professional experience of the first two engineers. Should the two engineers fail to select the third engineer, the Agency and the Contractor shall each propose 2 engineers to be the third member within 21 calendar days after the written request notification. The flrst two engineers previously selected shall then select one of the four proposed engineers in a blind draw. The committee shall be a continuance of the cooperative investigation and will re-consider all available information and if necessary gather new and additional information to determine the validity, the cause, and if necessary, the remedy to the contradiction. The committee will focus upon the performance adequacy of the material(s) using standard engineering principles and practices and to ensure public value, the committee may provide engineering recommendations as necessary. Unless otherwise agreed, the committee will have 30 calendar days from its formation to complete their review and submit their findings. The final resolution ofthe committee shall be by majority opinion, in writing, stamped and signed. Should the final resolution not be unanimous, the dissenter may attach a written, stamped, and signed minority opinion. Once started, the resolution process by committee shall continue to full conclusion unless: 1. Within 7 days of the formation of the committee, the Agency and the Contractor reach an acceptable resolution mechanism; or 2. Within 14 days of the formation of the committee, the initiating party withdraws its written notification and agrees to bear all investigative related costs thus far incurred; or 3. At any point by the mutual agreement of the Agency and the Contractor. Unless otherwise agreed, the Contractor shall bear and maintain a record for all the investigative costs until resolution. Should the investigation discover assignable causes forthe contradiction, the assignable party, the Agency or the Contractor, shall bear all costs associated with the investi- gation. Should assignable causes for the contradiction extended to both parties, the investiga- tion will assign costs cooperatively with each party or when necessary, equally. Should the investigation substantiate a contradiction without assignable cause, the investigation will assign costs cooperatively with each party or when necessary, equally. Should the investigation be unable to substantiate a contradiction, the initiator ofthe investigation shall bear all investigative costs. All claim notification requirements of the contract pertaining to the contradiction shall be suspended until the investigation is concluded. 4-2 MATERIALS TRANSPORTATION, HANDLING AND STORAGE. The Contractor shall order, purchase, transport, coordinate delivery, accept delivery, confirm the quantity and quality received, prepare storage area(s), store, handle, protect, move, relocate, remove and dispose excess of all materials used to accomplish the Work. Materials shall be delivered to the site of the work only during working hours, as defined in Section 6-7.2, and shall be accompanied by bills of lading that shall clearly state for each delivery: the name of the Contractor as consignee, the Revised 07/17/2015 Contract No. PKS16-02PKS 63 of 86 project name and number, address of delivery and name of consignor and a description of the material(s) shipped. Prior to storage of any materials which have been shipped to or by the Contractor to any location within the Agency's boundaries the Contractor shall provide the Engineer a copy of lease agreements for each property where such materials are stored. The lease agreement shall clearly state the term of the lease, the description of materials allowed to be stored and shall provide for the removal of the materials and restoration of the storage site within the time allowed for the Work. All such storage shall conform to all laws and ordinances that may pertain to the materials stored and to preparation of the storage site and the location of the site on which the materials are stored. Loss, damage or deterioration of all stored materials shall be the Contractor's responsibility. Conformance to the requirements of this section, both within and outside the limits of work are a part ofthe Work. The Engineer shall have the right to verify the suitability of materials and their proper storage at any time during the Work. Revised 07/17/2015 Contract No. PKS16-02PKS 64 of 86 SECTION 5 - UTILITIES 5-1 LOCATION. The Agency and afl'ected utility companies have, by a search of known records, endeavored to locate and indicate on the Plans, all utilities which exist within the limits of the work. However, the accuracy and/or completeness of the nature, size and/or location of utilities indicated on the Plans is not guaranteed. Where underground main distribution conduits such as water, gas, sewer, electric power, telephone, or cable television are shown on the Plans, the Contractor shall assume that every property parcel will be served by a service connection for each type of utility. As provided in Section 4216 of the California Government Code, at least 2 working days prior to commencing any excavation, the Contractor shall contact the regional notification center (Underground Service Alert of Southern California) and obtain an inquiry identiflcation number. The California Department of Transportation is not required by Section 4216 to become a member of the regional notification center. The Contractor shall contact it for location of its subsurface installations. The Contractor shall determine the location and depth of all utilities, including service connections, which have been marked by the respective owners and which may affect or be affected by its operations. If no pay item is provided in the Contract for this work, full compensation for such work shall be considered as included in the prices bid for other items of work. 5-2 PROTECTION. The Contractor shall not interrupt the service function or disturb the support of any utility without authority from the owner or order from the Agency. All valves, switches, vaults, and meters shall be maintained readily accessible for emergency shutoff. Where protection is required to ensure support of utilities located as shown on the Plans or in accordance with Section 5-1, the Contractor shall, unless otherwise provided, furnish and place the necessary protection at its expense. Upon learning of the existence and location of any utility omitted from or shown incorrectly on the Plans, the Contractor shall immediately notify the Engineer in writing. When authorized by the Engineer, support or protection of the utility will be paid for as provided in Section 3-2.2.3 or 3-3. The Contractor shall immediately notify the Engineer and the utility owner if any utility is disturbed or damaged. The Contractor shall bear the costs of repair or replacement of any utility damaged if located as noted in Section 5-1. When placing concrete around or contiguous to any non-metallic utility installation, the Contractor shall at its expense: 1. Furnish and install a 2 inch cushion of expansion joint material or other similar resilient material; or 2. Provide a sleeve or other opening which will result in a 2 inch minimum-clear annular space between the concrete and the utility; or 3. Provide other acceptable means to prevent embedment in or bonding to the concrete. Where concrete is used for backfill or for structures which would result in embedment, or partial embedment, of a metallic utility installation; or where the coating, bedding or other cathodic protection system is exposed or damaged by the Contractor's operations, the Contractor shall notify the Engineer and arrange to secure the advice of the affected utility owner regarding the procedures required to maintain or restore the integrity of the system. •F' Revised 07/17/2015 Contract No. PKS16-02PKS 65 of 86 5-3 REMOVAL. Unless otherwise specifled, the Contractor shall remove all interfering portions of utilities shown on the Plans or indicated in the Bid documents as "abandoned" or "to be abandoned in place". Before starting removal operations, the Contractor shall ascertain from the Agency whether the abandonment is complete, and the costs involved in the removal and disposal shall be included in the Bid for the items of work necessitating such removals. 5-4 RELOCATION. When feasible, the owners responsible for utilities within the area affected by the Work will complete their necessary installations, relocations, repairs, or replacements before commencement of work by the Contractor. When the Plans or Speciflcations indicate that a utility installation is to be relocated, altered, or constructed by others, the Agency will conduct all negotiations with the owners and work will be done at no cost to the Contractor, except for manhole frame and cover sets to be brought to grade as provided in the Standard Specifications for Public Works Construction, 2012 Edition, and the supplements thereto. Utilities which are relocated in order to avoid interference shall be protected in their position and the cost of such protection shall be included in the Bid for the items of work necessitating such relocation. After award of the Contract, portions of utilities which are found to interfere with the Work will be relocated, altered or reconstructed by the owners, or the Engineer may order changes in the Work to avoid interference. Such changes will be paid for in accordance with Section 3-2. When the Plans or Specifications provide for the Contractor to alter, relocate, or reconstruct a utility, all costs for such work shall be included in the Bid for the items of work necessitating such work. Temporary or permanent relocation or alteration of utilities requested by the Contractor for its convenience shall be its responsibility and it shall make all arrangements and bear all costs. The utility owner will relocate service connections as necessary within the limits of the Work or within temporary construction or slope easements. When directed by the Engineer, the Contractor shall arrange for the relocation of service connections as necessary between the meter and property line, or between a meter and the limits of temporary construction or slope easements. The relocation of such service connections will be paid for in accordance with provisions of Section 3-3. Payment will include the restoration of all existing improvements which may be affected thereby. The Contractor may agree with the owner of any utility to disconnect and reconnect interfering service connections. The Agency will not be involved in any such agreement. In conformance with Section 5-6 the Contractor shall coordinate the work with utility agencies and companies. Prior to the installation of any and all utility structures within the limits of work by any utility agency or company, or its contractor, the Contractor shall place all curb or curb and gutter that is a part of the work and adjacent to the location where such utility structures are shown on the plans and are noted as being located, relocated or are otherwise shown as installed by others. In order to minimize delays to the Contractor caused by the failure of other parties to relocate utilities that interfere with the construction, the Contractor, upon the Engineer's approval, may be permitted to temporarily omit the portion of work affected by the utility. If such temporary omission is approved by the Engineer the Contractor shall place survey or other physical control markers sufficient to locate the curb or curb and gutter to the satisfaction of the utility agency or company. Such temporary omission shall be for the Contractor's convenience and no additional compensation will be allowed therefore or for additional work, materials or delay associated with the temporary omission. The portion thus omitted shall be constructed by the Contractor immediately following the relocation of the utility involved unless othenvise directed by the Engineer. 5-5 DELAYS. The Contractor shall notify the Engineer of its construction schedule insofar as it afl'ects the protection, removal, or relocation of utilities. Said notification shall be included as a part of the construction schedule required in Section 6-1. The Contractor shall notify the Engineer in writing of any subsequent changes in the construction schedule which will affect the time available for protection, removal, or relocation of utilities. The Contractor will not be entitled to damages or additional payment for delays attributable to utility relocations or alterations if correctiy located, noted, and completed in accordance with Section 5-1. Revised 07/17/2015 Contract No. PKS16-02PKS 66 of 86 The Contractor may be given an extension of time for unforeseen delays attributable to unreasonably protracted interference by utilities in performing work correctly shown on the Plans. The Agency will assume responsibility for the timely removal, relocation, or protection of existing main or trunkline utility facilities within the area affected by the Work if such utilities are not identifled in the Contract Documents. The Contractor will not be assessed liquidated damages for any delay caused by failure of Agency to provide for the timely removal, relocation, or protection of such existing facilities. If the Contractor sustains loss due to delays attributable to interferences, relocations, or alterations not covered by Section 5-1, which could not have been avoided by the judicious handling of forces, equipment, or plant, there shall be paid to the Contractor such amount as the Engineer may flnd to be fair and reasonable compensation for such part ofthe Contractor's actual loss as was unavoidable and the Contractor may be granted an extension of time. 5-6 COOPERATION. When necessary, the Contractor shall so conduct its operations as to permit access to the Work site and provide time for utility work to be accomplished during the progress of the Work. ¥ Revised 07/17/2015 Contract No. PKS16-02PKS 67 of 86 SECTION 6 - PROSECUTION, PROGRESS, AND ACCEPTANCE OF THE WORK 6-1 CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK. Except as otherwise provided herein and unless otherwise prohibited by permits from other agencies as may be required by law the Contractor shall begin work within 20 calendar days after receipt ofthe "Notice to Proceed". 6-1.1 Pre-Construction Meeting. After, or upon, notification of contract award, the Engineer will set the time and location forthe Preconstruction Meeting. Attendance ofthe Contractor's management personnel responsible for the management, administration, and execution of the project is mandatory for the meeting to be convened. Failure of the Contractor to have the Contractor's responsible project personnel attend the Preconstruction Meeting will be grounds for default by Contractor per Section 6-4. No separate payment will be made for the Contractor's attendance at the meeting. The notice to proceed will only be issued on or after the completion of the preconstruction meeting. 6-1.1.1 Baseline Construction Schedule Submittal. The Contractor shall submit the Baseline Construction Schedule per the submittal requirements of Section 2-5.3. The submittal of the Baseline Construction Schedule shall include each item and element of Sections 6-1.2 through 6-1.2.9 and shall be on hard (paper) copy and electronic media conforming to Section 6-1.3.3 Electronic Media. 6-1.2 Preparation and Review of the Baseline Construction Schedule. The Contractor shall prepare the Baseline Construction Schedule as a Critical Path Method (CPM) Schedule in the precedence diagram method (activity-on-node) format. The Baseline Construction Schedule shall depict a workable plan showing the sequence, duration, and interdependence of all activities required to represent the complete performance of all project work as well as periods where work is precluded. The Baseline Construction Schedule shall begin with the projected date of issuance ofthe notice to proceed and conclude with the date of final completion per the contract duration. The Baseline Construction Schedule shall include detail of ali project phasing, staging, and sequencing, including all milestones necessary to define beginning and ending of each phase or stage. 6-1.2.3 Bar Chart. As a part ofthe Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a chart showing individual tasks and their durations arranged with the tasks on the vertical axis and duration on the horizontal axis. The bar chart shall use differing texture patterns or distinctive line types to show the critical path. 6-1.2.4 Schedule Software. The Contractor shall use commercially available software equal to the Windows 2000 compatible "Suretrak" program by Primavera or "Project" program by Microsoft Corporation to prepare the Baseline Construction Schedule and all updates thereto. The Contractor shall submit to the Agency a CD-ROM data disk with all network information contained thereon, in a format readable by a Microsoft Windows 2000 system. The Agency will use a "Suretrak", "Project" or equal software program for review of the Contractor's schedule. Should the Contractor elect to use a scheduling program other than the "Suretrak" program by Primavera or "Project" program by Microsoft Corporation, the Contractor shall provide the Engineer three copies ofthe substituted program that are fully licensed to the Agency and 32 class hours of on-site training by the program publisher for up to eight Agency staff members. The classes shall be presented on Mondays through Thursdays, inclusive, between the hours of 8:00 a.m. and 5:00 p.m. The on-site training shall be held at 1635 Faraday Avenue, Carisbad, California. The dates and times of the on-site training shall be submitted to the Engineer for approval five working days before the start of the on-site training. The on-site training shall be completed prior to the submittal ofthe first Baseline Construction Schedule. 6-1.2.7 Restraints to Activities. Any submittals, utility interfaces, or any furnishing of Agency supplied materials, equipment, or services, which may impact any activity's construction shall be shown as a restraint to those activities. Time periods to accommodate the review and correction of submittals shall be included in the schedule. ••''Revised 07/17/2015 Contract No. PKS16-02PKS 68 of 86 6-1.2.8 Late Completion. A Baseline Construction Schedule showing a project duration longer than the specifled contract duration will not be acceptable and will be grounds for determination of default by Contractor, per Section 6-4. 6-1.2.9 Early Completion. The Baseline Construction Schedule will show the Contractor's plan to support and maintain the project for the entire contractual time span of the project. Should the Contractor propose a project duration shorter than contract duration, a complete Baseline Construction Schedule must be submitted, reflecting the shorter duration, in complete accordance with all schedule requirements of Section 6-1. The Engineer may choose to accept the Contractor's proposal of a project duration shorter than the duration specifled; provided the Agency is satisfied the shortened Baseline Construction Schedule is reasonable and the Agency and all other entities, public and private, which interface with the project are able to support the provisions of the shortened Baseline Construction Schedule. The Agency's acceptance of a shortened duration project will be confirmed through the execution of a contract change order revising the project duration and implementing all contractual requirements including liquidated damages in accordance with the revised duration. 6-1.2.10 Engineer's Review. The Construction Schedule is subject to the review ofthe Engineer. The Engineer's determination that the Baseline Construction Schedule propbsed by the Contractor complies with the requirements of these supplemental provisions shall be a condition precedent to issuance of the Notice to Proceed by the Engineer. If the Engineer determines that the Construction Schedule does not meet the requirements of these specifications the Contractor shall correct the Construction Schedule to meet these specifications and resubmit it to the Engineer. Failure of the Contractor to obtain the Engineer's determination thatthe initial Construction Schedule proposed by the Contractor complies with the requirements of these supplemental provisions within thirty (30) working days after the date ofthe preconstruction meeting shall be grounds for termination ofthe contract per Section 6-4. Days used by the Engineer to review the initial Construction Schedule will not be included in the 30 working days. The Engineer will review and return to the Contractor, with any comments, the Baseline Construction Schedule within 15 working days of submittal. The Baseline Construction Schedule will be returned marked as per Sections 6-1.2.10.1 through 6-1.2.10.3. 6-1.2.10.1 "Accepted." The Contractor may proceed with the project work upon issuance of the Notice to Proceed, and will receive payment for the schedule in accordance with Section 6-1.8.1. 6-1.2.10.2 "Accepted with Comments." The Contractor may proceed with the project work upon issuance ofthe Notice to Proceed. The Contractor must resubmit the schedule incorporating the comments prior to receipt of payment per Section 6-1.8.1. 6-1.2.10.3 "Not Accepted." The Contractor must resubmit the schedule incorporating the corrections and changes of the comments prior to receipt of payment per Section 6-1.8.1. The Notice to Proceed will not be issued by the Engineer if the changes of the comments are not submitted as required hereinbefore and marked "Accepted" or "Accepted with Comments" by the Engineer. The Contractor, at the sole option of the Engineer, may be considered as having defaulted the contract under the provisions of Section 6-4 DEFAULT BY CONTRACTOR if the changes of the comments are not submitted as required hereinbefore and marked "Accepted" by the Engineer. 6-1.8 Measurement and Payment of Construction Schedule. The Contractor's preparation, revision and maintenance ofthe Construction Schedule are incidental to the work and no separate payment will be made therefore. 6-2 PROSECUTION OF WORK. To minimize public inconvenience and possible hazard and to restore street and other work areas to their original condition and state of usefulness as soon as practicable, the Contractor shall diligentiy prosecute the Work to completion. If the Engineer determines that the Contractor is failing to prosecute the Work to the proper extent, the Contractor shall, upon orders from the Engineer, immediately take steps to remedy the situation. All costs of prosecuting the Work as described herein shall be included in •f' Revised 07/17/2015 Contract No. PKS16-02PKS 69 of 86 the Contractor's Bid. Should the Contractor fail to take the necessary steps to fully accomplish said purposes, after orders of the Engineer, the Engineer may suspend the work in whole or part, until the Contractor takes said steps. As soon as possible under the provisions of the Specifications, the Contractor shall backfill all excavations and restore to usefulness all improvements existing prior to the start of the Work. If Work is suspended through no fault of the Agency, all expenses and losses incurred by the Contractor during such suspensions shall be borne by the Contractor. If the Contractor fails to properly provide for public safety, traffic, and protection of the Work during periods of suspension, the Agency may elect to do so, and deduct the cost thereof from monies due the Contractor. Such actions will not relieve the Contractor from liability. 6-2.1 Order of Work. The work to be done shall consist of furnishing all labor, equipment and materials, and performing all operations necessary to complete the Project Work as shown on the Project Plans and as specified in the Specifications. The work includes removal of existing lamps, fixtures and wiring/wiring-harnesses, and installation of new lamps, fixtures and wiring/wiring- harnesses. 6-2.3 Project Meetings. The Engineer will establish the time and location of weekly Project Meetings. The Contractor's Representative shall attend each Project Meeting. The Project Representative shall be the individual determined under Section 7-6, "The Contractor's Representative". No separate payment for attendance of the Contractor, the Contractor's Representative or any other employee or subcontractor or subcontractor's employee at these meetings will be made. 6-3 SUSPENSION OF WORK. 6-3.1 General. The Work may be suspended in whole or in part when determined by the Engineer that the suspension is necessary in the interest of the Agency. The Contractor shall comply immediately with any written order of the Engineer. Such suspension shall be without liability to the Contractor on the part of the Agency except as otherwise specified in Section 6-6.3. 6-4 DEFAULT BY CONTRACTOR. If the Contractor fails to begin delivery of material and equipment, to commence the Wori< within the time specified, to maintain the rate of delivery of material, to execute the Work in the manner and at such locations as specified, or fails to maintain the Work schedule which will insure the Agency's interest, or, if the Contractor is not carrying out the intent of the Contract, the Agency may serve written notice upon the Contractor and the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. The Contract may be canceled by the Board without liability for damage, when in the Board's opinion the Contractor is not complying in good faith, has become insolvent, or has assigned or subcontracted any part of the Work without the Board's consent. In the event of such cancellation, the Contractor will be paid the actual amount due based on Contract Unit Prices or lump sums bid and the quantity of the Work completed at the time of cancellation, less damages caused to the Agency by acts of the Contractor. The Contractor, in having tendered a Bid, shall be deemed to have waived any and all claims for damages because of cancellation of Contract for any such reason. If the Agency declares the Contract canceled for any of the above reasons, written notice to that effect shall be served upon the Surety. The Surety shall, within five (5) days, assume control and perform the Work as successor to the Contractor. If the Surety assumes any part of the Work, it shall take the Contractor's place in all respects for that part, and shall be paid by the Agency for all work performed by it in accordance with the Contract. If the Surety assumes the entire Contract, all money due the Contractor at the time of its default shall be payable to the Surety as the Work progresses, subject to the terms of the Contract. If the Surety does not assume control and perform the Work within 5 days aflier receiving notice of cancellation, or fails to continue to comply, the Agency may exclude the Surety from the premises. The •f' Revised 07/17/2015 Contract No. PKS16-02PKS 70 of 86 Agency may then take possession of all material and equipment and complete the Work by Agency forces, by letting the unfinished Work to another Contractor, or by a combination of such methods. In any event, the cost of completing the Work shall be charged against the Contractor and its Surety and may be deducted from any money due or becoming due from the Agency. If the sums due under the Contract are insufficient for completion, the Contractor or Surety shall pay to the Agency within 5 days after the completion, all costs in excess of the sums due. The provisions of this section shall be in addition to all other rights and remedies available to the Agency under law. 6-5 TERMINATION OF CONTRACT. The Board may terminate the Contract at its own discretion or when conditions encountered during the Work make it impossible or impracticable to proceed, or when the Agency is prevented from proceeding with the Contract by act of God, by law, or by official action of a public authority. 6-6 DELAYS AND EXTENSIONS OF TIME. 6-6.1 General. If delays are caused by unforeseen events beyond the control of the Contractor, such delays will entitie the Contractor to an extension of time as provided herein, but the Contractor will not be entitied to damages or additional payment due to such delays, except as provided in 6-6.3. Such unforeseen events may include: war, government regulations, labor disputes, strikes, fires, floods, adverse weather or elements necessitating cessation of work, inability to obtain materials, labor or equipment, required extra work, or other speciflc events as may be further described in the Speciflcations. No extension of time will be granted for a delay caused by the Contractor's inability to obtain materials unless the Contractor furnishes to the Engineer documentary proof the proof must be provided in a timely manner in accordance with the sequence of the Contractor's operations and the approved construction schedule. If delays beyond the Contractor's control are caused by events other than those mentioned above, the Engineer may deem an extension of time to be in the best interests of the Agency. The Contractor will not be entitled to damages or additional payment due to such delays, except as provided in Section 6- 6.3. If delays beyond the Contractor's control are caused solely by action or inaction by the Agency, such delays will entitie the Contractor to an extension of time as provided in Section 6-6.2. 6-6.2 Extensions of Time. Extensions of time, when granted, will be based upon the effect of delays to the Work. They will not be granted for noncontrolling delays to minor portions of the Work unless it can be shown that such delays did or will delay the progress of the Work. 6-6.3 Payment for Delays to Contractor. The Contractor will be compensated for damages incurred due to delays for which the Agency is responsible. Such actual costs will be determined by the Engineer. The Agency will not be liable for damages which the Contractor could have avoided by any reasonable means, such as judicious handling offerees, equipment, or plant. The determination of what damages the Contractor could have avoided will be made by the Engineer. 6-6.4 Written Notice and Report. The Contractor shall provide written notice to the Engineer within two hours of the beginning of any period that the Contractor has placed any workers or equipment on standby for any reason that the Contractor has determined to be caused by the Agency or by any organization that the Agency may otherwise be obligated by The Contractor shall provide continuing daily written notice to the Engineer, each working day, throughout the duration of such period of delay. The initial and continuing written notices shall include the classiflcation of each workman and supervisor and the make and model of each piece of equipment placed on standby, the cumulative duration ofthe standby, the Contractor's opinion ofthe cause ofthe delay and a cogent explanation of why the Contractor could not avoid the delay by reasonable means. Should the Contractor fail to _ /\ ^ •f Revised 07/17/2015 Contract No. PKS16-02PKS 71 of 86 provide the notice(s) required by this section the Contractor agrees that no delay has occurred and that it will not submit any claim(s) therefore. 6-7 TIME OF COMPLETION. 6-7.1 General. The Contractor shall complete the Work within the time set forth in the Contract The Contractor shall complete each portion of the Work within such time as set forth in the Contract for such portion. The time of completion of the Contract shall be expressed in calendar days. The Contractor shall diligently prosecute the work to completion within 45 calendar days after the starting date specified in the Notice to Proceed. 6-7.2 Working Day. A working day is any day within the period between the start of the Contract time as defined in Section 6-1 and the date provided for completion, or upon fleld acceptance by the Engineer for all work provided for in the Contract, whichever occurs flrst, other than: 1. Saturday, 2. Sunday, 3. any day designated as a holiday by the Agency, 4. any other day designated as a holiday in a Master Labor Agreement entered info by the Contractor or on behalf of the Contractor as an eligible member of a contractor association, 5. any day the Contractor is prevented from working at the beginning of the workday for cause as defined in Section 6-6.1, 6. any day the Contractor is prevented from working during the first 5 hours with at least 60 percent of the normal work force for cause as defined in Section 6-6.1. Unless otherwise approved in writing by the Engineer, the hours of work shall be between the hours of 7:00 a.m. and 4:00 p.m. on Mondays through Fridays, excluding Agency holidays. The Contractor shall obtain the written approval of the Engineer if the Contractor desires to work outside said hours or at any time during weekends and/or holidays. This written permission must be obtained at least 48 hours prior to such work The Engineer may approve work outside the hours and/or days stated herein when, in his/her sole opinion, such work conducted by the Contractor is beneficial to the best interests ofthe Agency. The Contractor shall pay the inspection costs of such work. 6-8 COMPLETION, ACCEPTANCE, AND WARFIANTY. The Work will be inspected by the Engineer for acceptance upon receipt of the Contractor's written assertion that the Work has been completed. The Engineer will not accept the Work or any portion of the Work before all of the Work is completed and all outstanding deficiencies that may exist are corrected by the Contractor and the Engineer is satisfied that all the materials and workmanship, and all other features of the Work, meet the requirements of all of the specifications for the Work. Use, temporary, interim or permanent, of all, or portions of, the Work does not constitute acceptance of the Work. If, in the Engineer's judgment, the Work has been completed and is ready for acceptance the Engineer will so certify to the Board. Upon such certification by the Engineer the Board may accept the completed Work. Upon the Board's acceptance of the Work the Engineer will cause a "Notice of Completion" to be filed in the office of the San Diego County Recorder. The date of recordation shall be the date of completion of the Work. All work shall be warranted for one (1) year after recordation of the "Notice of Completion" and any faulty work or materials discovered during the warranty period shall be repaired or replaced by the Contractor, at its expense. In addition, an eight year warranty is required per the technical specification section for synthetic turf surfacing. Twenty-five percent of the faithful performance bond shall be retained as a warranty bond for the one year warranty period. The Contractor shall replace or repair any such defective work in a manner satisfactory to the Engineer, after notice to do so from the Engineer, and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the Agency may perform this work and the Contractor's sureties shall be liable for the cost thereof 6-9 LIQUIDATED DAMAGES. Failure of the Contractor to complete the Work within the time allowed will result in damages being sustained by the Agency. For each consecutive calendar day in f% ' bo •K Revised 07/17/2015 Contract No. PKS16-02PKS 72 of 86 excess of the time specified for completion of Work, as adjusted in accordance with Section 6-6, the Contractor shall pay the Agency, or have withheld monies due it, the sum of One Thousand Dollars ($1000.00). Such sum is liquidated damages and shall not be construed as a penalty, and may be deducted from payments due the Contractor if such delay occurs. Execution of the Contract shall constitute agreement by the Agency and Contractor that One Thousand Dollars ($1000.00) per day is the minimum value of costs and actual damages caused by the Contractor to complete the Work within the allotted time. Any progress payments made after the specified completion date shall not constitute a waiver of this paragraph or of any damages. 6-10 USE OF IMPROVEMENT DURING CONSTRUCTION. The Agency reserves the right to take over and utilize all or part of any completed facility or appurtenance. The Contractor will be notified in writing in advance of such action. Such action by the Agency will relieve the Contractor of responsibility for injury or damage to said completed portions of the improvement resulting from use by public traffic or from the action of the elements or from any other cause, except Contractor operations or negligence. The Contractor will not be required to re-clean such portions of the improvement before field acceptance, except for cleanup made necessary by its operations. Nothing in this section shall be construed as relieving the Contractor from full responsibility for correcting defective work or materials. In the event the Agency exercises its right to place into service and utilize all or part of any completed facility or appurtenance, the Agency will assume the responsibility and liability for injury to persons or property resulting from the utilization of the facility or appurtenance so placed into service, except for any such injury to persons or property caused by any willful or negligent act or omission by the Contractor, Subcontractor, their officers, employees, or agents. A 81 ^¥ Revised 07/17/2015 Contract No. PKS16-02PKS 73 of 86 SECTION 7 - RESPONSIBILITIES OF THE CONTRACTOR 7-1 CONTRACTOR'S EQUIPMENT AND FACILITIES. The Contractor shall fumish and maintain in good condition all equipment and facilities as required for the proper execution and inspection of the Work. Such equipment and facilities shall meet all requirements of applicable ordinances and laws. 7-2 LABOR. 7-2.1 General. Only competent workers shall be employed on the Work. Any person employed who is found to be incompetent, intemperate, troublesome, disorderly, or otherwise objectionable, or who fails or refuses to perform work properly and acceptably, shall be immediately removed from the Work by the Contractor and not be reemployed on the Work. 7- 2.2 Laws. The Contractor, its agents, and employees shall be bound by and comply with applicable provisions of the Labor Code and Federal, State, and local laws related to labor. The Contractor shall strictly adhere to the provisions of the Labor Code regarding minimum wages; the 8- hour day and 40-hour week; overtime; Saturday, Sunday, and holiday work; and nondiscrimination because of race, color, national origin, sex, or religion. The Contractor shall forfeit to the Agency the penalties prescribed in the Labor Code for violations. 7-3 LIABILITY INSURANCE. Insurance shall be required as specified in section 10 of the Public Works Contract. The cost of this insurance shall be included in the Contractor's Bid. 7-4 WORKERS' COMPENSATION INSURANCE. Before execution of the Contract by the Board, the Contractor shall flle with the Engineer the following signed certiflcation: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract." The Contractor shall also comply with Section 3800 of the Labor Code by securing, paying for, and maintaining in full force and effect for the duration of the contract, complete Workers' Compensation Insurance, and shall furnish a Certificate of Insurance to the Engineer before execution ofthe Contract. The Agency, its officers, or employees, will not be responsible for any claims in law or equity occasioned by failure ofthe Contractor to comply with this paragraph. All compensation insurance policies shall bear an endorsement or shall have attached a rider whereby it is provided that, in the event of expiration or proposed cancellation of such policies for any reason whatsoever, the Agency shall be notified by registered mail not less than 30 days before expiration or cancellation is effective. All insurance is to be placed with insurers that are admitted and authorized to conduct business in the state of California and are listed in the oflicial publication ofthe Department of Insurance ofthe State of California. Policies issued by the State Compensation Fund meet the requirement for workers' compensation insurance. 7-5 PERMITS. Except as specified herein the Contractor will obtain, at no cost to the Contractor all City of Carisbad encroachment, right-of-way, grading and building permits necessary to perform work for this contract on Agency property, streets, or other rights-of-way Contractor shall not begin work until all permits incidental to the work are obtained. The Contractor shall obtain and pay for all permits Revised 07/17/2015 Contract No. PKS16-02PKS 74of 86 for the disposal of all materials removed from the project. The cost of said permit(s) shall be included in the price bid for the appropriate bid item and no additional compensation will be allowed therefore. The Contractor shall obtain and pay for all costs incurred for permits necessitated by its operations such as, but not limited to, those permits required for night work, overioad, blasting, and demolition. For private contracts, the Contractor shall obtain all permits incidental to the Work or made necessary by its operations, and pay all costs incurred by the permit requirements. The Contractor shall pay all business taxes or license fees that are required for the work. 7-6 THE CONTFIACTOR'S REPRESENTATIVE. Before starting work, the Contractor shall designate in writing a representative who shall have complete authority to act for it. An alternative representative may be designated as well. The representative or alternate shall be present at the Work site whenever work is in progress or whenever actions of the elements necessitate its presence to take measures necessary to protect the Work, persons, or property. Any order or communication given to this representative shall be deemed delivered to the Contractor. A joint venture shall designate only one representative and alternate. In the absence of the Contractor or its representative, instructions or directions may be given by the Engineer to the superintendent or person in charge of the specific work to which the order applies. Such order shall be complied with promptly and referred to the Contractor or its representative. In order to communicate with the Agency, the Contractor's representative, superintendent, or person in charge of specific work shall be able to speak, read, and write the English language. 7-7 COOPERATION AND COLLATERAL WORK. The Contractor shall be responsible for ascertaining the nature and extent of any simultaneous, collateral, and essential work by others. The Agency, its workers and contractors and others, shall have the right to operate within or adjacent to the Work site during the performance of such work. The Agency, the Contractor, and each of such workers, contractors and others, shall coordinate their operations and cooperate to minimize interference. The Contractor shall include in its Bid all costs involved as a result of coordinating its work with others, the Contractor will not be entitied to additional compensation from the Agency for damages resulting from such simultaneous, collateral, and essential work. If necessary to avoid or minimize such damage or delay, the Contractor shall redeploy its work force to other parts of the Work. Should the Contractor be delayed by the Agency, and such delay could not have been reasonably foreseen or prevented by the Contractor, the Engineer will determine the extent of the delay, the effect on the project and any extension of time. 7-7.1 Coordination. The Contractor shall coordinate and cooperate with all the utility companies during the relocation or construction of their lines. The Contractor may be granted a time extension if, in the opinion of the Engineer, a delay is caused by the utility company. No additional compensation will be made to the Contractor for any such delay 7-8 PROJECT SITE MAINTENANCE. 7-8.1 Cleanup and Dust Control. Throughout all phases of construction, including suspension of work, and until the flnal acceptance, the Contractor shall keep the site clean and free from rubbish and debris. The Contractor shall also abate dust nuisance by cleaning, sweeping and sprinkling with water, or other means as necessary. The use of water resulting in mud on public streets will not be permitted as a substitute for sweeping or other methods. When required by the Plans or Specifications, the Contractor shall furnish and operate a self-loading motor sweeper with spray nozzles at least once each working day for the purpose of keeping paved areas acceptably clean wherever construction, including restoration, is incomplete. Revised 07/17/2015 Contract No. PKS16-02PKS 75 ol Materials and equipment shall be removed from the site as soon as they are no longer necessary. Before the final inspection, the site shall be cleared of equipment, unused materials, and rubbish so as to present a satisfactory clean and neat appearance. All cleanup costs shall be included in the Contractor's Bid. Care shall be taken to prevent spillage on haul routes. Any such spillage shall be removed immediately and the area cleaned. Excess excavation material from catch basins or similar structures shall be removed from the site immediately. Sufficient material may remain for use as backfill if permitted by the Specifications. Forms and form lumber shall be removed from the site as soon as practicable after stripping. Failure of the Contractor to comply with the Engineer's cleanup orders may result in an order to suspend work until the condition is corrected. No additional compensation will be allowed as a result of such suspension. Cleanup and dust control required herein shall also be executed on weekends and other non-working days when needed to preserve the health safety or welfare of the public. The Contractor shall conduct effective cleanup and dust control throughout the duration of the Contract. The Engineer may require increased levels of cleanup and dust control that, in his/her sole discretion, are necessary to preserve the health, safety and welfare of the public. Cleanup and dust control shall be considered incidental to the items of work that they are associated with and no additional payment will be made therefore. 7-8.2 Air Pollution Control. The Contractor shall not discharge smoke, dust, or any other air contaminants into the atmosphere in such quantity as will violate the regulations of any legally constituted authority. 7-8.4 Sanitation. The Contractor shall provide and maintain enclosed toilets for the use of employees engaged in the Work. These accommodations shall be maintained in a neat and sanitary condition. They shall also comply with all applicable laws, ordinances, and regulations pertaining to public health and sanitation of dwellings and camps. Wastewater shall not be interrupted. Should the Contractor disrupt existing sewer facilities, sewage shall be conveyed in closed conduits and disposed of in a sanitary sewer system. Sewage shall not be permitted to flow in trenches or be covered by backfill. 7-8.6 Water Pollution Control. The Contractor shall exercise every reasonable precaution to protect channels, storm drains, and bodies of water from pollution. It shall conduct and schedule operations so as to minimize or avoid muddying and silting of said channels, drains, and waters. Water pollution control work shall consist of constructing those facilities which may be required to provide prevention, control, and abatement of water pollution. The Contractor shall comply with the California State Water Resources Control Board (SWRCB) Order Number 99-08-DWQ, National Pollutant Discharge Elimination System (NPDES) General Permit Number CAS000002, Waste Discharge Requirements (WDR's) for Discharges of Stormwater Runoflf associated with Construction Activity (General Permit) and subsequent adopted modifications and with all requirements of the Storm Water Pollution Prevention and Monitoring Plans for this project in accordance with these regulations. The Notice of Intent (NOl) shall not be filed for the project 7-8.7 Drainage Control. The Contractor shall maintain drainage within and through the work areas. Earth dams will not be permitted in paved areas. Temporary dams of sandbags, asphaltic concrete, or other acceptable material will be permitted when necessary. Such dams shall be removed from the site as soon as their use is no longer necessary. %J On •f Revised 07/17/2015 Contract No. PKS16-02PKS 76 of 86 7-8.8 Noise Control. All internal combustion engines used in the construction shall be equipped with mufflers in good repair when in use on the project with special attention to the City Noise Control Ordinance, Carlsbad Municipal Code Chapter 8.48. 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS. The Contractor shall be responsible for the protection of public and private property adjacent to the Work and shall exercise due caution to avoid damage to such property. The Contractor shall repair or replace all existing improvements within the right-of-way which are not designated for removal (e.g., curbs, sidewalks, driveways, fences, walls, signs, utility installations, pavement, structures, etc.) which are damaged or removed as a result of its operations. When a portion of a sprinkler system within the right-of-way must be removed, the remaining lines shall be capped. Repairs and replacements shall be at least equal to existing improvements and shall match them in finish and dimension. Maintenance of street and traffic signal systems that are damaged, temporarily removed or relocated shall be done in conformance with 307-1.5. Trees, lawns, and shrubbery that are not to be removed shall be protected from damage or injury. If damaged or removed due to Contractor's operations, they shall be restored oi" replaced in as neariy the original condition and location as is reasonably possible. Lawns shall be reseeded and covered with suitable mulch. The Contractor shall give reasonable notice to occupants or owners of adjacent property to permit them to salvage or relocate plants, trees, fences, sprinklers, and other improvements, within the right-of-way which are designated for removal and would be destroyed because of the Work. The Contractor shall utilize plywood of %" thickness or greater on all artificial turf surfaces for vehicles or equipment weighing more than (one-half) 1/2 ton G.W. (Gross Weight). All costs to the Contractor for protecting, removing, and restoring existing improvements shall be included in the Bid. 7-10 PUBLIC CONVENIENCE AND SAFETY. 7-10.1 Traffic and Access. The Contractor's operations shall cause no unnecessary inconvenience. The access rights of the public shall be considered at all times. Unless otherwise authorized, traffic shall be permitted to pass through the Work, or an approved detour shall be provided. Safe and adequate pedestrian and vehicular access shall be provided and maintained to: fire hydrants; commercial and industrial establishments; churches, schools and parking lots; service stations and motels; hospitals; police and fire stations; and establishments of similar nature. Access to these facilities shall be continuous and unobstructed unless otherwise approved by the Engineer. The Contractor shall include in its Bid all costs for the above requirements. 7-10.2 Storage of Equipment and Materials in Public Streets. Construction materials shall not be stored in streets, roads, or highways for more than 5 days after unloading. All materials or equipment not installed or used in construction within 5 days after unloading shall be stored elsewhere by the Contractor at its expense unless authorized additional storage time. Construction equipment shall not be stored at the Wori< site before its actual use on the Work nor for more than 5 days after it is no longer needed. Time necessary for repair or assembly of equipment may be authorized by the Engineer. 7-10.4 Safety. ••^Revised 07/17/2015 Contract No. PKS16-02PKS 77 of 86 7-10.4.1 Safety Orders. The Contractor shall have at the Work site, copies or suitable extracts of Construction Safety Orders, Tunnel Safety Orders and General Industry Safety Orders issued by the State Division of Industrial Safety. The Contractor shall comply with provisions of these and all other applicable laws, ordinances, and regulations. Before excavating any trench 5 feet or more in depth, the Contractor shall submit a detailed plan to the Agency showing the design of shoring, bracing, sloping, or other provisions to be made for the workers' protection from the hazard of caving ground during the excavation of such trench. If the plan varies from the shoring system standards, the plan shall be prepared by a registered Civil Engineer. No excavation shall start until the Engineer has accepted the plan and the Contractor has obtained a permit from the State Division of Industrial Safety. A copy of the permit shall be submitted to the Engineer. Payment for performing all work necessary to provide safety measures shall be included in the prices bid for other items of work except where separate bid items for excavation safety are provided, or required by law. 7-10.4.3 Special Hazardous Substances and Processes. Materials that contain hazardous substances or mixtures may be required on the Work. A Material Safety Data Sheet as described in Section 5194 of the California Code of Regulations shall be requested by the Contractor from the manufacturer of any hazardous products used. Material usage shall be accomplished with strict adherence to California Division of Industrial Safety requirements and all manufacturer warnings and application instructions listed on the Material Safety Data Sheet and on the product container label. The Contractor shall notify the Engineer if a specified product cannot be used under safe conditions. 7-10.4.5 Safety and Protection of Workers and Public. The Contractor shall take all necessary precautions for the safety of employees on the work and shall comply with all applicable provisions of Federal, State and Municipaf safety laws and building codes to prevent accidents or injury to persons on, about, or adjacent to the premises where the work is being performed. The Contractor shall erect and properiy maintain at all times, as required by the conditions and progress of the work, all necessary safeguards for the protection of workers and public, and shall use danger signs warning against hazards created by such features of construction as protruding nails, hoists, well holes, and falling materials. 7-11 PATENT FEES OR ROYALTIES. The Contractor shall absorb in its Bid the patent fees or royalties on any patented article or process furnished or used in the Work. The Contractor shall indemnify and hold the Agency harmless from any legal action that may be brought for infringement of patents. 7-12 ADVERTISING. The names, addresses and specialties of Contractors, Subcontractors, architects, or engineers may be displayed on removable signs. The size and location shall be subject to the Engineer's approval. Commerciai advertising matter shall not be attached to or painted on the surfaces of buildings, fences, canopies, or barricades. 7-13 LAWS TO BE OBSERVED. The Contractor shall keep fully informed of State and National laws and County and Municipal ordinances and regulations which in any manner affect those employed in the Work or the materials used in the Work or in any way affect the conduct of the Work. The Contractor shall at all times observe and comply with such laws, ordinances, and regulations. Municipal ordinances that affect this work include Chapter 11.06. Excavation and Grading. If this notice specifies locations or possible materials, such as borrow pits or gravel beds, for use in the proposed construction project which would be subject to Section 1601 or Section 1603 of the Fish and Game Code, the ••''Revised 07/17/2015 Contract No. PKS16-02PKS 78 of 86 conditions established pursuant to Section 1601 et seq. of the Fish and Game Code shall become conditions of the contract 7-14 ANTITRUST CLAIMS. Section 7103.5 ofthe Public Contract Code provides: "In entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or subcontractor offers and agrees to assign to the awarding body all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec 15) or Cartwright Act (Chapter 2 [commencing with Section 16700] of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or subcontract The assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment ofthe parties." •F^Revised 07/17/2015 Contract No. PKS16-02PKS 79 of 86 SECTION 8 - FACILITIES FOR AGENCY PERSONNEL 8-1 GENEERAL. A field office for agency personnel is not required. ^¥Revised 07/17/2015 Contract No. PKS16-02PKS 80 of 86 SECTION 9 - MEASUREMENT AND PAYMENT 9-1.1 General. Unless otherwise specified, quantities of work shall be determined from measurements or dimensions in horizontal planes. However, linear quantities of pipe, piling, fencing and timber shall be considered as being the true length measured along longitudinal axis. Unless otherwise provided in Specifications, volumetric quantities shall be the product ofthe mean area of vertical or horizontal sections and the intervening horizontal or vertical dimension. The planimeter shall be considered an instrument of precision adapted to measurement of all areas. 9-1.2 Methods of Measurement. Materials and items of work which are to be paid for on basis of measurement shall be measured in accordance with methods stipulated in the particular sections involved. 9-2 LUMP SUM WORK. Items for which quantities are indicated "Lump Sum", "L.S.", or "Job", shall be paid for at the price indicated in the Bid. Such payment shall be full compensation for the items of work and all work appurtenant thereto. When required by the Specifications or requested by the Engineer, the Contractor shall submit to the Engineer within 15 days after award of Contract, a detailed schedule in triplicate, to be used only as a basis for determining progress payments on a lump sum contract or designated lump sum bid item. This schedule shall equal the lump sum bid and shall be in such form and sufficiently detailed as to satisfy the Engineer that it correctly represents a reasonable apportionment of the lump sum. 9-3 PAYMENT 9-3.1 General. The quantities listed in the Bid schedule will not govern final payment Payment to the Contractor will be made only for actual quantities of Contract items constructed in accordance with the Plans and Specifications. Upon completion of construction, if the actual quantities show either an increase or decrease from the quantities given in the Bid schedule, the Contract Unit Prices will prevail subject to the provisions of Section 3-2.2.1. The unit and lump sum prices to be paid shall be full compensation for the items of work and all appurtenant work, including furnishing all materials, labor, equipment, tools, and incidentals. Payment will not be made for materials wasted or disposed of in a manner not called for under the Contract. This includes rejected material not unloaded from vehicles, material rejected after it has been placed, and material placed outside of the Plan lines. No compensation will be allowed for disposing of rejected or excess material. Payment for work performed or materials furnished under an Assessment Act Contract will be made as provided in particular proceedings or legislative act under which such contract was awarded. Whenever any portion of the Work is performed by the Agency at the Contractor's request, the cost thereof shall be charged against the Contractor, and may be deducted from any amount due or becoming due from the Agency. Whenever immediate action is required to prevent injury, death, or property damage, and precautions which are the Contractor's responsibility have not been taken and are not reasonably expected to be taken, the Agency may, after reasonable attempt to notify the Contractor, cause such precautions to be taken and shall charge the cost thereof against the Contractor, or may deduct such cost from any amount due or becoming due from the Agency. Agency action or inaction under such circumstances shall not be construed as relieving the Contractor or its Surety from liability. Payment shall not relieve the Contractor from its obligations under the Contract; nor shall such payment be construed to be acceptance of any of the Work. Payment shall not be construed as the transfer of ownership of any equipment or materials to the Agency. Responsibility of ownership shall remain with -*\ ¥ Revised 07/17/2015 Contract No. PKS16-02PKS 81 of 86 the Contractor who shall be obligated to store any fully or partially completed work or structure for which payment has been made; or replace any materials or equipment required to be provided under the Contract which may be damaged, lost, stolen or otherwise degraded in any way prior to acceptance of the Work, except as provided in Section 6-10. Guarantee periods shall not be affected by any payment but shall commence on the date of recordation of the "Notice of Completion." If, within the time fixed by law, a properly executed notice to stop payment is filed with the Agency, due to the Contractor's failure to pay for labor or materials used in the Work, all money due for such labor or materials will be withheld from payment to the Contractor in accordance with applicable laws. At the expiration of 35 days from the date of acceptance of the Work by the Board, or as prescribed by law, the amount deducted from the final estimate and retained by the Agency will be paid to the Contractor except such amounts as are required by law to be withheld by properiy executed and filed notices to stop payment, or as may be authorized by the Contract to be further retained. 9-3.2 Partial and Final Payment. The Engineer will, after award of Contract, establish a closure date for the purpose of making monthly progress payments. The Contractor may request in writing that such monthly closure date be changed. The Engineer may approve such request when it is compatible with the Agency's payment procedure. Each month, the Engineer will make an approximate measurement of the work performed to the closure date as basis for making monthly progress payments. The estimated value will be based on contract unit prices, completed change order work and as provided for in Section 9-2 of these General Provisions. Progress payments shall be made no later than thirty (30) calendar days after the closure date. Five (5) working days following the closure date, the Engineer shall complete the detailed progress pay estimate and submit it to the Contractor for the Contractor's information. Should the Contractor assert that additional payment is due, the Contractor shall within ten (10) days of receipt of the progress estimate, submit a supplemental payment request to the Engineer with adequate justification supporting the amount of supplemental payment request. Upon receipt ofthe supplemental payment request, the Engineer shall, as soon as practicable after receipt, determine whether the supplemental payment request is a proper payment request. If the Engineer determines that the supplemental payment request is not proper, then the request shall be returned to the Contractor as soon as practicable, but not later than seven (7) days after receipt. The returned request shall be accompanied by a document setting forth in writing the reasons why the supplemental payment request was not proper In conformance with Public Contract Code Section 20104.50, the City shall make payments within thirty (30) days after receipt of an undisputed and properly submitted supplemental payment request from the Contractor. If payment of the undisputed supplemental payment request is not made within thirty (30) days after receipt by the Engineer, then the City shall pay interest to the Contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure. From each progress estimate, 10 percent will be deducted and retained by the Agency, and the remainder less the amount of all previous payments will be paid. After 50 percent of the Work has been completed and if progress on the Work is satisfactory, the deduction to be made from remaining progress estimates and from the final estimate may be limited to $500 or 10 percent of the first half of total Contract amount, whichever is greater. No progress payment made to the Contractor or its sureties will constitute a waiver of the liquidated damages under 6-9. As provided in Section 22300 of the California Public Contract Code, the Contractor may substitute securities for any monies withheld by the Agency to ensure performance under the Contract. After final inspection, the Engineer will make a Final Payment Estimate and process a corresponding payment. This estimate will be in writing and shall be for the total amount owed the Contractor as •f Revised 07/17/2015 Contract No. PKS16-02PKS 82 of 86 determined by the Engineer and shall be itemized by the contract bid item and change order item with quantities and payment amounts and shall show all deductions made or to be made for prior payments and amounts to be deducted under provisions ofthe contract. All prior estimates and progress payments shall be subject to correction in the Final Payment Estimate. The Contractor shall have 30 calendar days from receipt of the Final Payment Estimate to make written statement disputing any bid item or change order item quantity or payment amount. The Contractor shall provide all documentation at the time of submitting the statement supporting its position. Should the Contractor fail to submit the statement and supporting documentation within the time specified, the Contractor acknowledges that full and final payment has been made for all contract bid items and change order items. If the Contractor submits a written statement with documentation in the aforementioned time, the Engineer will review the disputed item within 30 calendar days and make any appropriate adjustments on the Final Payment. Remaining disputed quantities or amounts not approved by the Engineer will be subject to resolution as specified in Section 3-5, Disputed Work. The written statement filed by the Contractor shall be in sufiicient detail to enable the Engineer to ascertain the basis and amount of said disputed items. The Engineer will consider the merits of the Contractor's claims. It will be the responsibility of the Contractor to furnish within a reasonable time such further information and details as may be required by the Engineer to determine the facts or contentions involved in its claims. Failure to submit such information and details will be sufficient cause for denying payment for the disputed items. 9-3.2.1 Payment for Claims. Except for those flnal payment items disputed in the written statement required in Section 9-3.2 all claims of any dollar amount shall be submitted in a written statement by the Contractor no later than the date of receipt of the final payment estimate. Those final payment items disputed in the written statement required in Section 9-3.2 shall be submitted no later than 30 days after receipt ofthe Final Payment estimate. No claim will be considered that was not included in this written statement, nor will any claim be allowed for which written notice or protest is required under any provision of this contract including Sections 3-4 Changed Conditions, 3-5 Disputed Work, 6-6.3 Payment for Delays to Contractor, 6-6.4 Written Notice and Report, or 6-7.3 Contract Time Accounting, unless the Contractor has complied with notice or protest requirements. The claims filed by the Contractor shall be in sufficient detail to enable the Engineer to ascertain the basis and amount of said claims. The Engineer will consider and determine the Contractor's claims and it will be the responsibility of the Contractor to furnish within a reasonable time such further information and details as may be required by the Engineer to determine the facts or contentions involved in its claims. Failure to submit such information and details will be sufficient cause for denying the claims. Payment for claims shall be processed within 30 calendar days of their resolution for those claims approved by the Engineer. The Contractor shall proceed with informal dispute resolution under Section 3-5, Disputed Work, for those claims remaining in dispute. 9-3.3.1 Delivered Materials. The cost of materials and equipment delivered but not incorporated into the work will not be included in the progress estimate. 9-3.4.1 Mobilization and Preparatory Work. Payment for mobilization and preparatory Work will be included in the various items of work and no other payment will be made. Revised 07/17/2015 Contract No. PKS16-02PKS 83 of 86 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 2, CONSTRUCTION MATERIALS NONE SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 3, CONSTRUCTION METHODS NONE 84 of 86 Revised 07/17/2015 Contract No. PKS16-02PKS APPENDIX A SUPLEMENTAL PROVISIONS FOR AVIARA PARK SYNTHETIC TURF REPLACEMENT CONTRACT NO. PKS16-02PKS TECHNICAL SPECIFICATIONS / SPECIAL CONSTRUCTION PROVISIONS Table of Contents July 17, 2015 DIVISION 01 - General Requirements Section 01010 Summary of Work DIVISION 02 - Technical Specifications Section 02110 Site Preparation Section 02500 Sitework Concrete Section 02860 Exterior Athletic Equipment Section 02964 Infilled Synthetic Turf SPECIFICATIONS ON THE FOLLOWING PAGES ••''Revised 07/17/2015 Contract No. PKS16-02PKS 85 of 86 city of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 01010 SUMMARY OF WORK PART 1 - GENERAL 1.01 SCOPE OF WORK A. This contract includes work as described below. The description is summarized and may not include specific reference to all incidental work elements required to complete the contract. Include all labor, materials, equipment and incidentals required for completion of the work as shown on the Drawings and specified herein, at the following Project Location; Aviara Community Park 6440 Ambrosia Lane Carisbad, CA 92011 B. The work consists of Base Bid items generally described as follows; 1. The work includes installation and maintenance of temporary erosion and sedimentation controls; demolition and disposal of existing infilled synthetic turf and infill materials; re-use of existing permeable aggregate base materials; finish grading of existing permeable aggregate surface with addition of new material as required; installation of a new perimeter edge nailer to existing concrete paving and curbs; furnish and install soccer goals and anchors; installation of infilled synthetic turf surfacing including tufted and inlaid lines and markings; clean-up and demobilization. C. Achieve Final Completion within the allotted time, 1.05.B. D. Sequencing of work to achieve and maintain compliance with all applicable codes, regulations, and permits. See Paragraph 1.05 below. 1.02 CONTRACTS A. There will be one Contract for the project, which includes the Work described in the Project Manual and Drawings. B. The Contractor shall provide all items, articles, materials, operations or methods listed, noted or scheduled on the Drawings and/or Project Manual, including all labor, equipment and incidentals necessary and required for proper and timely completion of the Work. The Contractor shall use new materials unless specifically noted or directed. C. Work not specifically covered in the project manual and or drawings shall be performed in accordance with the current Greenbook Standard Specifications and Plans or City, County, State or National reference standards. 1.03 USE OF DOCUMENTS '•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 1 OF 6 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 01010 SUMMARY OF WORK A. Technical Specifications are enumerated in the Table of Contents of the Project Manual. The numbering of Sections is for identification only and may not be consecutive. The Contractor shall check his/her copies of the Specifications with the Table of Contents to verify that they are complete. The Contractor shall notify the Engineer of incomplete copies. 1.04 COPIES FURNISHED A. The Contractor shall be furnished five (5) copies of the Contract Documents without charge. Contractor may obtain additional partial or complete copies as the existing supply allows and when depleted, from the City at the cost of reproduction. 1.05 WORK SEQUENCE AND SCHEDULES A. Permits covering the work may have specific constraints related to weather etc. The Contractor will conform to all requirements and reflect same on all Construction Progress Schedules. B. Notice to Proceed and Contract Time for Completion 1. Notice to Proceed will be issued as soon as practical following Award and Execution ofthe Contract, approximately November 23, 2015. 2. Construction activities can commence on site not eariier than November 30, 2015. 3. Final Completion ofthe project will be achieved by February 1, 2016. 1.06 ORDERING LONG LEAD EQUIPMENT/MATERIAL ITEMS A. The Contractor shall schedule and prioritize the ordering and delivery of material as required insuring that the Work can be completed within the Contract Time. 1.07 ENGINEER FURNISHED WORK, MATERIALS, AND OR EQUIPMENT A. The Engineer will provide, at the request of the Contractor, electronic data to be used in the horizontal and vertical control of the work. Electronic Data is provided exclusively at the convenience of the Contractor. It will remain the responsibility of the Contractor to verify the accuracy ofthe data prior to any construction. 1.08 RECORD OF EXISTING IMPROVEMENTS A. Contractor shall provide to the Engineer a digital video recording that thoroughly documents the existing conditions ofthe entire project site and immediate vicinity, specifically including but not limited to all perimeter edge conditions, driveways, sidewalks, and roads adjacent to the site, all landscape elements and features, utility structures, and structures and surfaces on the site not scheduled for removal or repair. The Contractor shall have a responsible representative perform the recording or hire a digital recording production consultant that specializes in this function, and alert the Engineer as to the scheduled time and date ofthe recording ••'^ Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 2 OF 6 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 01010 SUMMARY OF WORK in the event that the Engineer exercises the option of being present. One copy of the completed digital record shall be submitted to the Engineer prior to beginning work. One copy of the digital record shall be kept on file with the Contractor. B. During the course of inspection and video documentation, the Contractor shall identify existing improvements to remain that, in the opinion of the Contractor, are beyond any reasonable potential for repair should they become damaged during the course of the execution of the Contract The Contractor shall submit in writing for the Engineers concurrence a list and description of all such existing improvements. D. Where damage to existing improvements to remain that are not previously documented as described in paragraph 1.1 O.B above occurs as a result ofthe execution of the Contract, the Contractor agrees to provide repair to, or replacement of the improvement as described by the City of Carisbad Standard Plans and Specifications (most recent edition) and/or the City of Carisbad Design Standards, regardless ofthe condition ofthe improvement priorto proceeding with the work. 1.09 NOTUSED 1.10 CONTRACTOR'S USE OF PREMISES A. Hours of Work: The contractor shall limit their work to between the hours of 7 am and 6 pm, Monday through Friday. Any other times of work shall be by approval of the Engineer. B. Keys: Access to certain utilities will require that the Contractor coordinate their initial access with the Engineer. The Contractor will anticipate this need and schedule accordingly, allowing a minimum of 48 hours of confirmed advanced notice prior to any need. C. Access: 1. The Contractor and their subcontractors will be allowed on site only during the established working periods. The Contractor shall only use the designated location for site access. 2. The Contractor shall also cooperatively address issues such as the City's normal maintenance activities, service truck routes, special events, and other adjacent work that may be taking place. These issues will be addressed as needed at regular weekly construction progress meetings. 3. The Contractor shall provide temporary fencing and other protection of the work area to limit public access in to and throughout the work area. D. Parking: '•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 3 OF 6 City of Carlsbad Avia ra Com m u n ity Pa rk Synthetic Turf Replacement SECTION 01010 SUMMARY OF WORK 1. The Contractor shall utilize the work site only for all parking. 2. Keep all fire lanes clear and store no materials in facility parking areas unless specifically identified for such use on the contract drawings. E. Staging: 1. The Contractor shall prepare a staging plan to show locations of materials, trailers, and fencing layouts. F. Miscellaneous: Other items of Contractor Responsibility include, but are not limited to: 1. Maintaining pedestrian and vehicular access to and around existing facilities. 2. Not unreasonably encumbering site with materials or equipment 3. Assuming full responsibility for protection and safekeeping of products stored on the premises. 4. Obtaining and paying for use of additional storage or work areas needed for operation. 5. Patching any damaged existing paving on adjacent properties. 6. Keeping roads and other areas clean of dirt and other debris. 1.11 STORAGE AND PROTECTION A. Store products in accordance with manufacturer's instruction, seals and labels intact and legible. 1. Store products subject to damage by the elements in weather-tight enclosures. 2. Maintain temperature and humidity within the ranges required by manufacturer's instructions. 3. Storage of hazardous materials and wastes shall be in accordance with local. State and Federal fire codes and regulations. 4. Note requirements on Materials Safety Data Sheets (MSDS). B. Exterior Storage: 1. Store fabricated products above ground. Position on blocking or skids; prevent soiling or staining. Cover products subject to deterioration with impervious sheet coverings. Provide adequate ventilation to avoid condensation. 2. Store loose granular materials in well-drained areas on solid surfaces. Prevent mixing with foreign matter. C. Do not store materials for other projects on sites unless speciflcally approved by the Engineer. 1.12 SALVAGED MATERIALS ^•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 4 OF 6 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 01010 SUMMARY OF WORK A. Salvage only those items that are noted in the Contract Documents. The City retains flrst right of refusal to all salvaged materials, equipment, and or products identified or not identified in the Contract Documents that are affected as part of the Contract Work. 1.13 DISPOSAL OF DEBRIS A. All disposal of debris resulting from the Contract Work, unless speciflcally allocated to another scope of work, shall be the responsibility ofthe Contractor. This includes scheduling, costs and interference in the use of trash collecting, containers, trucks, etc. The Contractor is responsible for awareness of, understanding of, and compliance with all local, state and federal regulation regarding the disposal of any hazardous and non-hazardous wastes. 1.14 SAFETY AND ENVIRONMENTAL CONCERNS A. Material Safety Data Sheets (MSDS) for all chemicals (including adhesives and paints) used in the performance of the contractors duties must be identified in advance to the Engineer, posted on a specified bulletin board at least 10 working days before first using the material, and comply with MSDS recommended practice. B. Section 02110 Site Preparation includes requirements related to the handling and disposal of existing materials on the site. C. The Contractor shall provide barricades, safety guards, temporary fencing, signage and/or other methods to secure trenches, open excavations, and other unsafe conditions resulting from this construction. Contractor shall adhere to all safety regulations. 1.15 WORK QUALITY STANDARDS A. The Technical Specifications of the Contract reference specific published standards for materials and craftsmanship. 1.16 PROJECT MANAGEMENT A. Management of the project shall conform to the requirements established by the General Conditions of the Contract Further to those requirements refer to the requirements identified in Section 7-6 regarding the Contractor's Representative. Contractor shall have a responsible representative with authority on the project at all times when work is in progress. The Superintendent of the work shall have experience in the management of projects of a similar scope of work and nature, and shall be familiar with all aspects ofthe proposed construction. Experience of the Superintendent shall include at least five (5) previous projects that include demolition, grading of permeable aggregate materials, and installation of synthetic turf surfacing. Documentation of experience shall be provided as a ^¥ Revised 07/17/2015 Contract No. PKSI6-02PKS PAGE 5 OF 6 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 01010 SUMMARY OF WORK required submittal that is subject to approval and acceptance by the City and the Engineer. PART 2 - PRODUCTS: (Not Used) PART 3 - EXECUTION: (Not Used) - END OF SECTION - ••''Revised 07/17/2015 Contract No. PKSI6-02PKS PAGE 6 OF 6 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02110 SITE PREPARATION PART 1 - GENERAL 1.01 SUMMARY A. Work specified in this section includes, but is not necessarily limited to, the following: 1. Prepare and submit for approval the Regional Water Quality Control Board and State of California Removal a Storm Water Pollution and Protection Plan for the proposed work. Preparation of the plan shall be complete by a certified QSD and maintained by a QSP, as required by State of California and City of Carisbad. 2. Removal and off site disposal of existing synthetic turf and infill materials from the field area. Contractor shall make every effort to recycle the turf and infill materials to the greatest extent practical. 3. Demolition and removal of other items as shown on the plans and as required for the construction activities. 4. Protecting from harm objects selected to remain. 5. The Contractor shall take all precautions to protect the existing permeable aggregate base materials to remain during the removal ofthe existing synthetic turf. Construction traffic should be limited to areas ofthe existing synthetic turf rather than on the surface of the permeable aggregate base. 6. The Contractor shall re-grade and compact the permeable aggregate base areas to remain that are damaged, disturbed and displaced by the turf removal activities, as well as provide new planarity for the entire permeable aggregate surface. 7. Specific areas requiring removal and replacement of permeable aggregate materials have been identified on the contract documents. Import of materials shall include a combination of top course permeable aggregate, washed plaster sand or C-Mix. 8. The Contractor shall establish planarity for the entire field surface. For field adjustments where permeable aggregate top course or C-Mix material is not used, washed plaster sand may be used as specified. 9. For purposes of quantity measurement, the contractor shall assume a minimum import requirement of 200 ton of material shall be imported and placed, of various types. 10. Install new perimeter edge nailer at the perimeter of the field. 1.02 RELATED WORK SPECIFIED IN OTHER SECTIONS A. Section 02964 - Infilled Synthetic Turf 1.03 EXISTING SITE CONDITIONS A. Refer to drawings for existing condition information. B. Owner not responsible for changes in the topography after survey record drawing verification was made or for accuracy of survey information. ^•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 1 OF 10 to City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02110 SITE PREPAFJATION C. Carefully maintain benchmarks, monuments and other reference points. If disturbed or destroyed, replace as directed. It is the responsibility ofthe Contractor to familiarize themselves with all records of existing utilities in area of site work. D. The Contractor shall contact the appropriate utility agencies for identification of underground utility location. 1.04 TEMPORARY EROSION AND SILTATION CONTROL A. All work shall conform to City of Carisbad Erosion and Sedimentation Control requirements including installation of siltation control such as filter fabric fences check dams, catch basin inserts. Baker tanks, etc. Contractor shall prepare and submit any and all required SWPPP plans or approvals to the California Regional Water Quality Control Board for the proposed work and site. 1.05 EXISTING UTILITIES A. The Contractor shall call for utilities locate prior to commencing with demolition activities. B. The Contractor shall coordinate all existing utilities prior to proceeding with demolition activity. Protect any active pipes encountered; notify Engineer of their existence and record on "as-built" drawings. 1.06 DUST CONTROL A. Protect persons and property from damage and discomfort caused by dust Water as necessary to quell dust. 1.07 ROADWAY PROTECTION A. Provide wheel-cleaning stations to clean wheels and undercarriage of trucks before leaving site, as necessary to prevent dirt from being carried onto public streets. If streets are fouled, they must be cleaned immediately in conformance with City of Carisbad requirements, as applicable. This requirement applies to all vehicle movements for the entire period of construction. 1.08 TRAFFIC REGULATION A. Conduct operations in such a manner to avoid unnecessary interference to existing traffic. Minimize heavy vehicle traffic to and from site during peak traffic hours. Do not park vehicles in traffic lanes. Provide flagmen as required. Conform to City of Carisbad traffic control requirements. B. Contractor shall be responsible for all traffic control and emergency call outs resulting from Contractor operations. lol '•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 2 OF 10 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02110 SITE PREPARATION C. Maintain fire lanes, roadways and alleys to existing buildings continuously, as required by the fire department having jurisdiction. D. Existing walkways and roadways leading past the constmction shall remain clear and safe at all times. Provide barriers, flashing lights, walkways, guardrails and night lighting as required for safety and control. 1.09 DIMENSIONS AND LAYOUT A. The Contractor shall be responsible for furnishing, setting and marking all line, grade, and location stakes, including offsets and general construction staking, together with clearing limits. B. There shall be on site at all times, when work-requiring control is being performed, all necessary equipment, supplies, and instruments related thereto. A qualified layout engineer, surveyor, or technical specialist must be assigned to the Contractor's crew for this work. This equipment and personnel must be available at no additional cost to the Owner for the purpose of verifying layout and certifying the accuracy of work on the site. C. The Contractor is responsible for preserving all benchmarks and stakes and replacing any that are displaced or missing as a result of the Contractor's operations. D. The Contractor is responsible for review of all Owner and city records relative to the existing underground utilities. The Contractor is responsible to avoid damaging these facilities and shall repair all recorded utilities at no additional cost to the Owner. E. The Contractor shall notify the Owner's Representative immediately of underground utilities encountered, which are not shown on the Owner's record. 1.05 QUALIFICATIONS A. The subcontractor responsible for field base establishment and field permeable aggregate placement and compaction shall be submitted to the Engineer for approval. Specific qualification requirements are included as follows: 1. The subcontractor shall be and has been actively and directly engaged in constructing similar natural or synthetic field projects and shall provide proof of ten (10) or more full size (75,000SF) sports field base installations completed in the past three (3) years. The Contractor's experience shall include completion of middle school, high school, college, or professional level competition fields. The playing field system shall include earthwork, field subgrade establishment, subsurface drainage systems and base aggregate or sand placement and compaction. Provide a listing of all construction contracts (whether completed or in progress) entered into or performed by the subcontractor and completed © 102 ^¥Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 3 OF 10 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02110 SITE PREPARATION with the subcontractor's staff within the past three years for projects similar in scope, time and complexity of the work called for under this Contract; include the names of the contracts, and the names and contact information of the owners, and the subcontractors staff who have completed the work. Qualification experience requirement cannot be satisfied with personnel who will not be actively involved with this project. PART 2 - MATERIALS 2.01 TOP COURSE PERMEABLE AGGREGATE A. The top course permeable aggregate shall be installed over the base course permeable aggregate in the synthetic turf. B. Aggregate to be open-graded, fractured, durable, friction course. To ensure free drainage, material to be clean with minimal flnes. The compacted top course permeable aggregate shall have a minimum infiltration rate of 20 inches per hour when the material is compacted to a minimum density of not less than 98% of maximum dry density as determined by ASTM D698. C. Material Strength and Durability 1. The material shall demonstrate a compressive strength sufficient to support the anticipated construction loading without significant breakage of individual particles, resulting in a significant alteration of the particle gradation as approved. 2. Where the compressive strength is suspect, the Engineer will remove a sample of the material that has been placed by the Contractor at the specified density and perform a particle gradation, the results of which will be compared to previous production test results (approved baseline values). If the results of this test indicate higher passing values for any given screen exceeding 10%) of the baseline, the material may be considered noncompliant. D. Gradation: Aggregate to meet the following particle size limitations: Sieve Size Percent Passing bv Weight 3/4" 100 1/2" 90 -100 3/8" 70 -90 No.4 30 -60 No. 8 20 -40 No. 30 5-15 No. 100 2-•5 No. 200 (Wet Sieve) 0-3.0 No. 270 (Wet Sieve) 0-1.5 2.02 WASHED PLASTER SAND ^•f'^ Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 4 OF 10 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02110 SITE PREPARATION A. Washed plaster sand shall be installed in areas where the finished surface of the top course permeable aggregate requires fill adjustment of less than 3/8" depth in the areas where the existing permeable aggregate has been displaced. Material shall be installed at such depth to meet and match the top ofthe existing, adjacent permeable aggregate areas. B. Gradation: Sand to meet the following particle size limitations: Sieve Size Percent Passing bv Weight No.4 100 No. 8 95-100 No. 30 75-85 No. 100 0-4 No. 200 (WetSieve) 0-2 No. 270 (WetSieve) 0-1 2.03 C-MIX A. C-mix aggregate may be utilized in areas where the finished surface of the top course permeable aggregate requires fill adjustment of less than 3/8" depth in the areas where the existing permeable aggregate has been displaced. Material shall be installed at such depth to meet and match the top ofthe existing, adjacent permeable aggregate areas. B. Gradation: C-Mix to meet the following particle size limitations: Sieve Size Percent Passing bv Weight 1/2" 100 3/8" 90-95 No.4 50-60 No. 8 40-50 No. 16 30-35 No. 30 15-25 No. 50 5-10 No. 100 0-3 No. 200 (Wet Sieve) 0-2 2.04 RECYCLED PLASTIC EDGE ANCHOR A. Includes all materials required to provide a secure recycled plastic edge for establishment of Permeable Aggregate grade and anchoring of synthetic turf. B. A recycled plastic lumber nailer board shall be installed per the details to secure the turf. Product shall be manufactured from 100% recycled materials, consisting of HDPE Plastic Lumber. Material should be dimensional lumber in lengths no shorter than 6'. '•'Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 5 OF 10 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02110 SITE PREPARATION 1. Where attachment is scheduled to concrete curbing, provide minimum 2"x4" nominal dimensional lumber. C. Manufacturer's reference: Product is available from RESCO Plastics, Inc., Coos Bay, Oregon. (800) 266-5097. D. Concrete Anchoring: Concrete wedge anchor, zinc plated, 3/8" x5" length, partially threaded, with zinc plated washer and nut. E. Steel power-load driven or ram-set Concrete Anchor Nail, minimum shank diameter 5/32", minimum head/washer diameter 3/8", sufficient length to insure a minimum 2" embedment. Individual anchors shall develop a minimum 450 lb. shear, 350 lb. tension in 4,000 psi concrete at 2" embedment. PART 3 - EXECUTION 3.01 FIELD LAYOUT AND ENGINEERING A. The General Contractor shall be responsible for the layout of all the demolition work required to construct all work in accordance with the drawings and specifications. 3.02 EXISTING CONDITIONS A. Provide, erect and maintain barricades, coverings, or other types of protection necessary to prevent damage to existing trees indicated to remain in place. B. Do not shut off or cap utilities without prior notice. Coordinate work with Division 1 requirements. Maintain storm drains and sewers open for free drainage: 1. Provide storm drain inlet protection at catch basins in accordance with plans. C. Objectionable noises: Limit use of air hammers and other noisy equipment as much as possible. Conform to Owner requirements regarding noise control. D. Maintain vehicular and pedestrian traffic routes: 1. Ensure minimum interference with roads, sidewalks, and adjacent facilities. 2. Do not close or obstruct streets, sidewalks, alleys or passageways without permission from Owner. 3. If required by Owner or city, provide alternate routes around closed or obstructed traffic ways. 3.03 DEMOLITION A. Completely remove and dispose of the existing synthetic turf surfacing system. Care shall be taken when removing the existing turf system so that damage does "¥Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 6 OF 10 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02110 SITE PREPARATION not occur to the existing permeable aggregate base that is to remain. Every effort shall be made to recycle existing turf and infill materials to the greatest extent practical. Sawcut and remove existing concrete paving where indicated. Legally dispose off site. Carefully dismantie and remove items, if any, to be salvaged. The salvaged items shall then be labeled, bundled, and delivered to a storage site specified by the Owner's Representative. 3.04 DISPOSAL OF MATERIALS A. The Contractor in a manner consistent with all government regulations shall dispose the refuse resulting from synthetic turf removal. 1. Do not leave refuse material on the project site, shoved onto abutting private properties, or buried in embankments or trenches on the project site. 2. Maintain hauling routes clean and free of debris resulting from work of this section. 3.05 SELECTIVE DEMOLITION & SALVAGE A. Carefully mark or flag items to be returned or reused for inspection by the Engineer prior to commencing demolition work. Coordinate functional testing of such operable equipment as valves, gates, electrical components. B. Where indicated, neatly separate components to be salvaged for return or reuse from assemblies or equipment to remain or be demolished in their entirety by an approved means including cutting, grinding, drilling, or disassembling. C. Clean and repair any damage caused by the demolition or salvage operation. D. Owner shall temporarily relocate existing soccer goals outside of the work area. 3.06 AGGREGATE PLACEMENT A. Moisture Content: Aggregate to contain 3.5%i to 4.0% moisture content to ensure that fines do not migrate and to facilitate proper compaction. Contractor must ensure that aggregate leaving the source plant meets this requirement and is required to apply water to aggregate on site to attain and maintain this minimum moisture content in stockpile and during all placement operations. B. Should there occur during any stage of the spreading or stockpiling a separation of the material particles, the Contractor must immediately remove and dispose of /\ ••'' Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 7 OF 10 city of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02110 SITE PREPARATION segregated material and correct or change handling procedures to prevent any further separation. 3.07 REMOVAL AND PLACEMENT OF MATERIALS A. Top course permeable aggregate, washed plaster sand, or C-Mix shall be carefully compacted to 90-95% maximum dry density. The top surface shall meet and match the top of the adjacent areas. Surface tolerance for all areas within the playfield shall not vary by more than 1/4". B. The entire surface area of the permeable aggregate base shall be verified for planarity. The synthetic turf installation foreman and the Engineer shall confirm planarity by pulling a string line taut across the width and length of the field, at a minimum 2' interval. Any areas deviating more than %" shall be modified/reworked by the contractor to the required tolerance. C. Turf installation cannot begin until aggregate base is accepted in writing by the turf vendor. 3.08 SCARIFY, REGRADE, COMPACTION A. If required to achieve planarity, uniformly finish grade the permeable aggregate surface using existing permeable aggregate material with equipment that will not cause perceptible separation in gradation (segregation). Supplement as required with Top Course Permeable Aggregate, Washed Plaster Sand or C-Mix to achieve required planarity. B. Contractor shall apply supplemental water to maintain moisture content in permeable aggregate throughout grading process as required to not cause perceptible segregation of materials. C. Use Static Tandem Drum-type roller of not less than five tons weight. D. The contractor shall monitor compaction levels to insure the aggregate materials are not over-compacted resulting in infiltration rates less than 20 inches/hour. 3.09 AGGREGATE TOLERANCES A. The Contractor shall utilize a laser plane system for grade control. B. The surface of the top course permeable aggregate shall not deviate from designated compacted grade within the range of-0.00" and -1-0.25" and shall not deviate more than %" as measured by a 10 foot straight edge. C. Upon completion ofthe fine grading, compaction, and Contractor confirmation of conformance with the tolerances, the Contractor shall notify the Engineer and schedule an inspection for approval. The Contractor shall have a laser plane system available to the Engineer for the inspections. The Contractor shall not be ¥ Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 8 OF 10 city of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02110 SITE PREPARATION authorized to install synthetic turf over the permeable aggregate until it has been inspected and approved by the Engineer. D. Upon completion of elevation verification, the entire permeable aggregate surface shall be inspected for planarity. Planarity inspection shall be completed in conjunction, coordination with the synthetic turf vendor. The installation foreman for the synthetic turf shall be present at the time of the inspection. Inspection shall consist of stretching a string line taut over the finished permeable aggregate surface at such interval as may be required to confirm surface planarity and acceptance for installation of synthetic turf surface. Any deviation greater than VA shall require remediation efforts as may be required to meet subgrade tolerance. 3.10 RECYCLED PLASTIC EDGE ANCHOR A. Prior to proceeding with Edge Anchor installation, confirm with the Engineer the final elevation for installation relative to adjacent surfaces. B. The Edge Anchor may be temporarily set with temporary hardware to establish the proper line and grade. This temporary hardware may remain after flnal installation. 1. Wedge Anchor a. The Plastic Edge Anchor may be temporarily set with power-loads to establish the proper line and grade. This temporary hardware may remain after final installation. b. Once the initial line and grade has been established, pre-drill the edge anchor and establish a void in the adjacent concrete surface that meets the approved anchor supplier's requirements for proper securing of the anchor. c. Minimum requirements for anchor installation: 1) . Depth of Embedment: 3" or as recommended by the anchor supplier, whichever is greater. 2) . Horizontal Spacing: no greater than 36" on center and 12" from end of any length of lumber. 3) . Nut Torque: Per approved manufacturer's recommendation. 4) . Do not trim bolt ends. Bolts with trimmed or damaged ends will be rejected and must be removed. 2. Concrete Anchor Nail a. The Plastic Edge Anchor may be temporarily set with power-loads placed at the Contractors option to assist in establishing the proper line and grade. This temporary hardware may remain after final installation. b. Once the initial line and grade has been established, install the specified ram-set or power-load driven Concrete Anchoring Nails in manner consistent with the approved manufacturers printed instruction and the specified spacing. c. Minimum requirements for Concrete Anchor Nail installation: 1). Depth of Embedment: 2" or as recommended by the anchor supplier, whichever is greater. ••^ Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 9 OF 10 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02110 SITE PREPARATION 2) . Horizontal Spacing: no greater than 21" on center and 6" from end of any length of lumber. 3) . Stagger the spacing of each Anchor up and down within the middle one-half the face ofthe Recycled Edge Anchor. - END OF SECTION - Copyright D.A. Hogan & Associates Inc. 2015 ^¥ Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 10 OF 10 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02500 SITEWORK CONCRETE PART 1 - GENERAL 1.01 SCOPE OF WORK A. Furnish all labor, material and equipment for the concrete work indicated below and shown on the drawings. Work includes but is not limited to: 1. Assist Engineer in acquiring test cylinders for compression testing. 2. Install concrete footings for goal anchors and plates, etc. 1.02 STANDARD SPECIFICATIONS A. Standard Specifications for Road, Bridge and Municipal Construction, American Public Works Association (APWA) B. American Concrete Institute (ACI) C. American Society of Testing and Materials (ASTM) D. The Green Book Standard Specifications for Municipal Public Works Construction, California State Chapter (latest edition). 1.03 RELATED WORK IN OTHER SECTIONS A. Exterior Athletic Equipment PART 2 - PRODUCTS 2.01 CONCRETE A. Refer to APWA Section 5-05, "Cement Concrete Pavement." B. Expansion Joints: Provide expansion joints at 10' o.c. maximum, equally spaced unless otherwise shown in the drawings. C. Joint Filler: Use non-staining, non-extruding, compressible and resilient closed cell joint filler of neoprene foam conforming to ASTM Dl 752, Type RE-42. Joint fillers with contain or have been treated with oil, grease or bituminous materials are prohibited. Test joint fillers for compatibility with proposed sealant. 1. Acceptable joint filler: Neoprene Sponge Rubberjoint Filler by the Burke Company, or other accepted by Project Representative. 2. Joint Sealant ASTM C920, Grade NS, Class 25, Type M; multi-component, chemical curing, non-staining, non-bleeding, capable of continuous water immersion, non-sagging type; color to be selected. D. Preformed Expansion Joint Strips: Vinylex Corporation "VP 1391", or approved 1/2 •f' Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 1 OF 5 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02500 SITEWORK CONCRETE inch wide vinyl joint strip with removable cap. E. Control Joints: Provide control joints midway between expansion joints unless otherwise called for in the plans. F. Reinforcing: Utilize reinforcing as specified in the details. 1. Reinforcing steel shall be Grade 60 deformed bars (number 3 and larger) conforming to ASTM A 615. 2. Tie wire shall be black annealed No. 16 AWG or heavier. 3. Welded deformed steel wire fabric shall conform to ASTM A 497. 4. Epoxy coated reinforcing steel shall conform to AASHTO M-284. G. Cast-in-place Concrete components 1. Aggregate: Clean, hard, durable particles of natural sand conforming to ASTM C33 for fine aggregate. Clean, uniformly hard, durable particles of gravel or crushed stone conforming to ASTM 033 for coarse aggregate. 2. Cement: Conform to requirements of ASTM 0150. Use Type I, IV or V at Contractor's option. Type 111. Any change in type or admix use shall be at approved locations. 3. Ready-mixed Concrete: Conform to requirements of ASTM 094 Alternative #3. 4. Maximum Size of Coarse Aggregate: Conform to requirements of ACI 301, Paragraph 3.6. 5. Minimum Cement Content: Six sacks per cubic yard. 6. Admixtures: Conform to requirements of ACI 301 and ASTM 0260 for air entrainment. Use of accelerators or water-reducing retarders is prohibited. 7. Maximum Water Content Six gallons of water per sack of cement. Free of injurious amounts of oil, acids, alkali, salts, vegetable matter, and fit to drink. 8. Minimum Concrete Compressive Strengths: A minimum compressive strength of 3.000 PSI shall be achieved in 28 days using Type I cement and in seven days using Type 111 cement, unless otherwise shown on drawings. 9. Slump in Inches: Unless otherwise shown on drawings, conform to ASTM 0143 procedures for concrete to be vibrated: Maximum = 4", Minimum = 1". 10. Control Joints: Not less than 3/8" thick x 3/8" minimum depth with tooled edges. 11. Speed Dowel: #3, 18" long at 24" O.C: Green Streak (800) 325-9504 2.02 FORMWORK A. Forms: Wood, plywood, metal, other verified material to provide continuous, straight, structurally sound formwork and to produce specified concrete flnish. Wood to be defect-free or properiy corrected to provide straight lines and smooth, even surfaces. B. Form-coating compound: Commercial formulation form-coating compound that will not bond with, stain, nor adversely affect concrete surfaces requiring bond or adhesion, nor impede the wetting of surfaces to be cured with water or curing Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 2 OF City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02500 SITEWORK CONCRETE compounds, nor interfere with subsequent applications of finish such as paints or stains. C. Miscellaneous: Verified-type material and hardware for forming chamfers, recesses, openings, control joints, etc. D. Design of Formwork 1. Design of formwork is Contractor's responsibility. Conform to shape, lines, and dimensions shown on the drawings. Design for adequate strength to sustain all construction loads without deformation or defiection. 2. Make joints tight to prevent leakage of mortar. Properly brace and tie together to maintain position and shape. Truss for support if adequate foundation for shores cannot be provided. Fabricate accurately to minimize development of irregularities at panel joints. Construct to accommodate control, expansion, or other type joints shovvn on the drawings or as specified. 3. Coordinate with all other trades to accommodate their work. PART 3 - EXECUTION 3.01 SUBGRADE ESTABLISHMENT A. Establish subgrade at elevations required to achieve the slopes and finish grade elevations designated on the drawings. The Contractor shall schedule the Engineer for a subgrade inspection prior to installation of the concrete. B. The subgrade shall be compacted to a minimum of 95% maximum dry density. The subgrade shall be moistened to minimize absorption of water from fresh concrete. 3.02 FORMWORK INSTALLATION A. Thoroughly clean forms and adjacent surfaces to receive concrete. Remove chips, wood, sawdust, dirt or other debris just before concrete is placed. Prepare form surfaces by coating the contact surfaces of forms with a form-coating compound before reinforcement is placed. B. The form-coating compounds shall be thinned only with thinning agent of type, and in amount and under conditions of the form-coating compound manufacturer's directions. Do not allow excess form-coating material to accumulate in the forms or to come into contact with concrete surfaces against which fresh concrete will be placed. Apply in compliance with manufacturer's instructions. C. Coat steel forms with a non-staining, rust-preventative form oil or othenvise protect against rusting. Rust-stained steel formwork is not acceptable. D. Place and secure forms to correct location, dimension and profile. Assemble formwork to permit easy stripping and dismantling without damaging concrete. •''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 3 OF 5 \ V2^ City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02500 SITEWORK CONCRETE E. Place joint fillers vertical in position, in straight lines. Secure to formwork during concrete placement. 3.03 CONCRETE MIXING AND PLACING A. Conform to the requirements of ACI 301, Chapters 7 and 8, and ACI 304. Clean and free of all foreign matter, and all mixing and transporting equipment and subgrade and forms to receive concrete. Clean reinforcement of deleterious coatings. B. Notice of intention to place concrete shall be given to the Engineer at least 24 hours before an intended pour. C. Conform to ACI 305 "Recommended Practice for Hot Weather Concreting". Take steps to reduce concrete temperature and water evaporation by proper attention to ingredients, production methods, handling, placing, protection and curing. D. Conveying: Conform to ACI 301, Paragraph 8.2. Convey concrete from mixer to place of final deposit by methods preventing separation or loss of materials. Use pump, crane bucket, wheelbarrow, or buggies to deliver concrete to placing location. Chuting permitted only by methods to ensure a practically continuous flow of concrete at delivery end to prevent material separation. E. Finishes: 1. For walkways, curbing and slabs provide medium broom finish and provide chamfer edges as shown in the details. 2. For concrete curbs exposed above grade, provide smooth sack finish on exposed surfaces. F. Curing Materials 1. Absorptive Cover: Buriap cloth made from jute or kenaf weighing approximately 9 oz. per square yard, complying with AASHO Ml82. Class 3. 2. Moisture-retaining Cover: Either waterproof paper. Polyethylene film, or Polyethylene-coated buriap, complying with ASTM 0171. 3. Membrane-forming Curing Compound: ASTM C309. Type 1, unless other type acceptable to the Engineer. 3.04 FORMWORK REMOVAL A. All formwork shall be removed after proper curing of concrete. Protect surfaces of concrete during removal operations. B. Formwork not supporting weight of concrete may be removed after cumulatively curing at not less than 50 degrees F for 24 hours after placing concrete, provided concrete is sufficientiy hard to not be damaged by form removal operations and provided curing and protection operations are maintained. ••''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 4 OF 5 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02500 SITEWORK CONCRETE 3.05 REUSE OF FORMWORK A. Clean and repair surfaces of forms to be reused in work. Split, frayed, delaminated or otherwise damaged form-facing materials will not be acceptable for reuse. Apply new form-coating material as necessary, as specified for new formwork. 3.06 REPAIR OF SURFACE DEFECTS A. General: Conform to ACI 301. Chapters 9 and 13. After removal of forms, repair or patch concrete not formed as shown, out of alignment or level beyond required tolerances or that shows surface defects, to condition as verified by Engineer. Immediately after form removal, patch all tie holes and repairable defective areas. B. Honeycombed areas shall be removed to sound concrete but not less than 1" minimum depth. Dampen area and to 6" width around same; let evaporate only to loss of sheen. Provide a bond of neat cement and water slurry well brushed into area to be patched. Provide patching mixture of 1:2 (cement:sand) or verified proprietary patching mixture or color to match adjacent surfaces; use water quantity only as required for mixing and placing. Leave patched surface slightiy high; after one hour, float to level with adjacent surface. Keep patched areas damp for seven days. 3.07 PROTECTION A. Protect freshly-placed concrete from premature drying and excessive cold or hot temperature, and maintain without drying at a relatively constant temperature for a period of time necessary for hydration of cement and proper hardening. Provide protection from vandalism. B. Protect all concrete during curing period from all damaging mechanical disturbances, more especially load stresses, heavy shock and excessive vibration. Protect finish surfaces from all damage. 3.08 TOLERANCES A. The surface elevation, in the finished condition, shall not deviate more than 1/8" from specifled elevations. Trueness measurement to be taken from 10' long straight edge placed in all directions. 3.09 CLEANUP A. At project completion, leave all work clean, defect-free, with uniform finish and color. - END OF SECTION - Copyright D.A. Hogan & Associates Inc. 2015 ^•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 5 OF-5 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02860 EXTERIOR ATHLETIC EQUIPMENT PART 1 - GENERAL 1.01 SCOPE OF WORK A. Furnish and install Soccer Goal Anchors as follows; 1. Primary Soccer Field: Two (2) anchors at each goal (total of 4) 2. Modified Soccer Field: Two (2) anchors at each goal (total of 8) B. Furnish and install Portable Soccer Goals (6 total); C. Furnish and install Soccer Corner Flags (8 total) 1.02 RELATED WORK IN OTHER SECTIONS A. Section 02500 - Sitework Concrete 1.03 SUBMITTALS A. The Contractor shall submit four copies of catalog information and manufacturer's data of all equipment to the Engineer for approval. B. The Contractor shall submit color options for all site furnishings for the Owner's selection. PART 2 - MATERIALS 2.01 SOCCER GOAL ANCHOR A. Units shall be pre-manufactured unit consisting of an access box, cover and tethering assembly suitable for securing the backstay of a soccer goal unit. Provide two per goal. B. Access box to be fabricated of .125" aluminum and 16 ga. stainless steel. C. Cover to be fabricated of .25" aluminum and %" marine plywood. D. Tethering to be steel chain or aircraft cable. E. All connections to be welded or secured with stainless steel hardware. F. Manufacturer Reference: Soccer Goal Anchor shall be Aluminum Athletic Equipment or approved equal. G. Synthetic Turf Cover to identically match synthetic turf system used for field surfaces. 2.02 PORTABLE SOCCER GOALS '•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE IOF 3 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02860 EXTERIOR ATHLETIC EQUIPMENT A. General: Soccer goals to be in full compliance with National Federation of State High School Associates. Goals to provide an 8' x 24' front inside opening. Goals to be portable. B. Crossbar and Uprights: The crossbars and uprights shall consist of a single length of 4.5 inch OD 6063 T-5 aluminum D shaped tubing or 4-3/8 inch OD Rams Aluminum tubing. C. The goals shall be finished with a white polyester powder coat finish. D. Each goal shall have a wheel kit. E. All hardware and fasteners shall be stainless steel. F. The goals shall include 4mm polyethylene twine nets. Nets shall be secured with removable clips G. Warranty: Goals to be warranted by manufacturer for a minimum period of 5 years. H. Manufacturer Reference: Kwik Goal 2B2001 Pro Premier European Match Goal with net. Contact (800) 531-4252, AAE, SGR-P (800) 523-5471, or approved equal 2.03 SOCCER CORNER FLAG A. Furnish at each corner of soccer field, four (4) weighted soccer flags. The soccer flags shall be weighted base, portable type which will topple over on impact. The soccer flags shall be 70" high and shall meet NFSHSA requirements. B. Soccer Corner Flags to be 1. Gilman WSF 2. KwikGoal 6B1404 3. AAE CFS-B 4. or approved equal. PART 3 - EXECUTION 3.01 GENERAL A. Install all equipment and furnishing according to manufacturers suggested installation methods. 3.02 SOCCER GOAL ANCHOR A. Assemble soccer goal anchor per manufacturer's installation instructions. B. Secure to concrete foundation. , , ^¥Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 2 OF 3 city of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02860 EXTERIOR ATHLETIC EQUIPMENT C. Unit shall be pre-manufactured unit consisting of an access box, cover and clamping assembly suitable for securing the back bar of a soccer goal unit D. Modify unit to remove hinge assembly, resulting in a removable lid to the assembly. 3.03 PORTABLE SOCCER GOAL A. Assemble soccer goal per manufacturer's installation instructions. B. Install new goal nets per manufacturer's installation instructions. C. Secure to anchor system. - END OF SECTION - Copyright D.A. Hogan & Associates Inc. 2015 •F Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 3 OF 3 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF PART 1 - GENEFIAL 1.01 SCOPE OF WORK A. Scope of work to include all labor, material, equipment, transportation and services to install complete new vertical draining in-filled synthetic turf surfacing system for the play field area. System to be as herein specified including, but not specifically limited to the following: 1. Independent testing of the synthetic turf materials prior to shipment to the project site; 2. Delivery of the synthetic turf materials (not including infill) a minimum of 1 week prior to the scheduled installation of the materials; 3. Review and acceptance or certification ofthe existing permeable aggregate as it applies to installation of turf system, planarity, permeability and warranty implementation; 4. Installation of complete vertical draining synthetic turf surfacing system. Field system shall consist of a sand and rubber infill composition. 5. Installation of tufted and inlaid fleld lines and markings as indicated on the drawings. 6. Provide extra turf materials to the Owner for future repair and protective purposes. 7. Provide all appropriate maintenance and repair manuals and warranty package to Owner. Warranty shall include a pre-paid insurance policy in support ofthe warranty required for the field, for the entire warranty period from an A-rated domestic insurance carrier. 8. Complete specific maintenance activities at 6 months and 1 year after the date of acceptance. 1.02 SYNTHETIC TURF SURFACING PERFORMANCE & PAYMENT BOND A. The Synthetic Turf Contractor shall provide a performance and payment bond to the General Contractor for the full subcontract amount of the synthetic turf surfacing system. A copy of the performance and payment bond must be provided to the Owner within 14 days of the issuance of the notice to proceed. B. It is strongly recommended that General Contractors obtain proof of bondability from the Synthetic Turf Contractors prior to inclusion of synthetic turf bid proposals in their bids to the Owner. C. The performance and payment bond must be provided in the name of the same corporate entity that provides the warranty for the synthetic turf surfacing system to the Owner. 1.03 SYNTHETIC TURF SURFACING A. The following vendors and corresponding products are pre-approved for the Synthetic Turf Field surface: ••'' Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 1 OF 19 city of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF Astroturf - Game Day Grass 3D Extreme 52, 2" (760) 500-7071 B. Any vendor that is not included as a pre-approved product shall submit a substitution request in accordance with the Instructions to Bidders. The substitution request must be submitted a minimum of 14 calendar days prior to the bid opening. Substitution requests must include the following information for evaluation by the Owner and Project Engineer. 1. Vendor Background and Experience: Describe your firm's history. Include information identifying the firm's annual volume and the firm's stability in the marketplace. Also include the firm's record relating to installation schedules and performance. Provide additional information regarding local representation, and post-installation support. 2. Product Manufacturer Background and Experience: Describe the history and experience ofthe product manufacturer with this specific product including years of experience and a count and listing of North American and woridwide synthetic turf fleld installations. The list shall include fleld locations, client, client contact names, address, telephone, material installed, date of installation, and general contractor (if any). 3. Product Installer Background and Experience: Describe the history and experience of the product installer with this speciflc product including years of experience and a count and listing of fleld installations. The list shall include fleld locations, client client contact names, address, telephone, material installed, date of installation, and general contractor (if any). If the installer is not the manufacturer or vendor of the product, describe the experience the installer has with this speciflc product. 4. Product Samples: Provide the following samples with the substitution request. a) Two 8"x 12" samples each of green turf with out inflll material showing backing with perforations. b) Two 8" X12" samples each of turf with the infill material. c) Two samples of the proposed in-fill material. 5. Product Specification: Provide specification for the proposed synthetic turf product. Note any required deviations from the In-filled Synthetic Turf Technical Specifications included in this section. 6. Product Performance: The samples submitted with the proposal will be reviewed and evaluated. As a supplement to the samples, provide a written description ofthe following performance criteria for the proposed synthetic turf surfacing system: a) Abrasive characteristics b) Weekly, Monthly, and Annual Maintenance Requirements c) Playability for Soccer d) Wet and Dry Traction 7. References: Supply a minimum of three references, including contact name and telephone number, for other installations of this product. Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 2 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF 1.04 APPROVED FIBER MANUFACTURERS A. The following fiber manufacturers are pre-approved for the monofilament and long parallel slit film fibers and nylon fibers within the In-filled Synthetic Turf System: 1. TenCate Tapeslide XP, Monoslide; Astroturf. B. The synthetic turf vendor shall provide written documentation in the form of a signed affidavit certifying the source of the fiber used for the field including both green and any other colors used for the lines and markings. C. Fiber shall be certified to have less than 50 ppm or less of lead from both the fiber supplier and the turf vendor. 1.05 MINIMUM QUALIFICATIONS FOR SYNTHETIC TURF SYSTEM A. The synthetic turf system shall be manufactured, sold, and warranted by a single vendor. Manufacture ofthe system shall include, at a minimum, assembly ofthe constituent components, i.e. tufting, of the specifled fiber into an approved backing and application of the secondary coated backing. B. The manufacturer of the synthetic turf system must have produced a minimum of twenty (20) successful in-filled fields of full size (70,000 sf or larger) and outdoors within the past two (2) years of the exact product proposed for use. C. Installer of the synthetic turf system must have installed either a minimum of ten (10) successful in-filled synthetic turf fields of full size (70,000 sf or larger) in North America within the past two (2) years or a minimum of twenty (20) fields of full size (70,000 sf or larger) in North America within the past five (5) years. D. The installer of the synthetic turf system shall have installed a minimum of five (5) successful in-filled synthetic flelds of full size (70,000 sf or larger) in North America with the product vendor and the exact product proposed for use. E. The synthetic turf surfacing system vendor shall have a designated employed representative available for service based in Southern California. 1.06 RELATED WORK SPECIFIED IN OTHER SECTIONS A. Section 02110 Site Preparation 1.07 STANDARD SPECIFICATIONS A. For standards: Applicable American Society for Testing Materials (ASTM), (latest edition). ••''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 3 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF 1.08 SURFACE PERFORMANCE REQUIREMENTS FOR SOCCER A. Performance of fleld surface shall conform to FIFA Performance Guidelines and Synthetic Turf Council as follows: Standard Description Field Reguirement ASTM F1936 FIFA 04 and FIFA 09 FIFA 05 and FIFA 09 FIFA 06 and FIFA 09 FIFA 07 FIFA 07 FIFA 08 FIFA 08 FIFA 01 and FIFA 09 FIFA 02 FIFA 03 Impact Attenuation Shock Absorption Vertical Deformation (foot stability) Rotational Resistance (traction) Linear Friction - Deceleration Linear Friction - Slide Skin Abrasion (dry) Skin / Surface Frication (dry) Vertical Ball Rebound (Soccer) Angled Ball Behavior (Soccer) Ball Roll (Soccer Specific) below 165 60% to 70% 4mm to Smm 30n to 45n 3.0g to 5.5g 130 to 210 <30% 0.25 to 0.75 60 cm to 85 cm 45% to 60% 4 to 8 meters 1.09 POST AWARD SUBMITTALS A. Shop Drawings: Within 14 calendar days after issuance of Notice to Proceed, submit to the Project Engineer five (5) copies of complete and detailed drawings showing all component parts of the synthetic turf system. The shop drawings shall be drawing to scale (1"=30' minimum) and shall include: 1. total depth of infill 2. edge details 3. insert details including backing material 4. seam details 5. seam layout 6. gluing patterns 7. dimensional shop drawing for all field lines, markings and boundaries B. Synthetic Turf Samples: Within 14 calendar days after issuance of Notice to Proceed submit to the Project Engineer: 1. Two 6" X 12" samples each of each green turf showing backing with perforations. 2. Two 6" X 12" samples each of turf showing method of seam makeup with perforations. One sample to have example of inlaid lines. 3. Two 6" X 12" samples each of the other colors proposed for use on the field for lines and markings. 4. Two 1-pound samples ofthe proposed In-fill material. C. Manufacturer's Specifications and Warranty: 1. Within 14 calendar days after issuance of Notice to Proceed submit to the Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 4 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF Project Engineer five (5) copies each of selected manufacturer's material specifications and installation instructions. Include detailed specifications of manufacturer's provisions for achieving permeability, stating rate in infiltration and permeability in inches per hour of system materials for the vertical draining system. 2. Within 28 calendar days after Notice to Proceed, submit to the Project Engineer five (5) sample copies of warranty package herein specified for review. D. Testing and Quality Control: Within 5 calendar days after issuance of Notice to Proceed, submit to the Project Engineer the following test results for the system specified. An independent testing laboratory experience with testing of synthetic turf or carpeting materials shall certify these tests. The qualifications of the testing laboratory to be utilized for the submittal and the pre-shipment testing shall be submitted to the Engineer for approval. Applicable minimum material ASTM tests: 1. Dynamic Cushion Test - ASTM F355, Procedure A, (system); ASTM F355 procedure A at the 24" drop. 2. Yarn and fabric characteristics. 3. Pill Burn Test - ASTM D2859 E. Maintenance and Operating Data: 1. Prior to acceptance and/or occupancy by the Owner, furnish to the Project Engineer five (5) copies in hard cover form of maintenance and operating data with imprinted Project, Owner, Project Engineer, Contractor and Turf Subcontractor names, and date of turf system installation. 2. In addition, provide descriptions of any equipment recommended for maintenance and repair, citing specific vendors for each unit. 3. Use and Limitations - Provide a separate page stating approved activity usage for the turf and activities not recommended relative to warranty. 4. Index - Index with tab dividers for data as follows: Materials installed with their characteristics: a. General maintenance b. Small repair procedures c. Minor seam repair d. Discussion of precautions to be practiced, general maintenance, and uses to avoid to protect turf surface and to maintain installation's warranty e. Recommendations for paint application and removal of lines and markings f Recommendations for snow removal procedures. 1.09 PRE-SHIPMENT SUBMITTALS A. Prior to shipment of the synthetic turf materials to the job site, synthetic turf material from every sixth roll shall be randomly sampled and the tested by an independent testing laboratory experience with testing synthetic turf materials. The testing laboratory shall be completely independent with no ties to the turf manufacturer. The testing shall include the following: Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 5 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF Item ASTM Property 1. FTIR Spectrograph Pile Composition 2. D418 Pile Weight 3. D418 TotalWeight 4. D418 Pile Height 5. D418 Backing Perforation Diameter and Spacing 6. D1335 Tuft Bind (without infill) 7. D1682 Grab/Tear Strength. B. Copies of the test results shall be transmitted to the Owner and Engineer directly from the testing laboratory. The synthetic turf materials shall not be shipped to the site without written authorization from the Engineer after the Owner and Engineer have approved the test results. C. Samples of the synthetic turf material tested from every sixth roll shall also be transmitted to the Engineer for approval by the independent testing laboratory prior to shipment of the synthetic turf materials to the job site. Sample size shall be minimum 12"x 12". D. All fees and costs associated with the pre-shipment sampling and testing shall be paid by the Contractor. 1.10 CERTIFICATION OF THE BASE A. The Synthetic Turf Surfacing Contractor shall furnish to the Owner, prior to the synthetic turf installation, a written certification ofthe acceptability by the turf vendor of the new and existing permeable aggregate for installation and warranty validation. 1.11 TURF SYSTEM HOLD HARMLESS A. The synthetic turf manufacturer and installer shall not infringe upon any current or pending patents held by other synthetic turf manufacturers or installers. B. The Contractor, their synthetic turf subcontractor, and the synthetic turf manufacturer shall hold the Owner, Owner's Representative, and the Engineer harmless from infringement of any current or future patent issued for the synthetic turf surfacing system, installation methods and vertical draining characteristics. A notarized statement shall be provided as part ofthe submittal package. 1.12 WARRANTY OF SYNTHETIC TURF A. Warranty shall cover, in general, the usability of the turf surface, accessories, use characteristics, and suitability of the installation. All items covered by warranty are to be replaced or repaired with new materials, including installation at the sole expense of the warranting contractor for the period of eight (8) years to the Owner, for the designated uses enumerated as follows: '•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 6 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF 1. Soccer 2. Baseball 3. Kickball 4. Lacrosse 5. Ultimate 6. Physical exercises 7. Physical education activities 8. Pneumatic rubber-tired maintenance and service vehicles 9. Pedestrian traffic and other similar uses 10. Ceremonial and Entertainment Events B. A principal ofthe applicable firm, duly-authorized to make contracts, shall sign the turf vendor warranty. If the turf vendor is not the manufacturer, the manufacturing firm shall also sign the warranty. The term "Contractor" contained herein means the firm furnishing warranty. "Owner" is the City of Carisbad. Warranty period shall be a minimum of eight years from date of acceptance of the installed system by the Owner. C. Furnish a pre-paid insurance policy in support of the warranty required for the field, for the entire warranty period from an A-rated domestic insurance carrier. The warranty shall be secured to the Owner with an insurance policy of not less than $300,000 per claim and an aggregate of $5,000,000. 1.13 FORM OF WARFIANTY OF SYNTHETIC TURF SYSTEM A. Contractor hereby warrants to Owner, subject to the limitations and conditions set forth below, that its synthetic turf system consisting of synthetic turf described as , is free from defects in material and workmanship and shall, for a period of eight years as applicable from the date of acceptance by the Owner, remain serviceable for multiple sports activities. B. Contractor warrants to the Owner that its synthetic turf materials shall not fade, fail, shrink, wrinkle, or reflect excessive wear. Contractor shall, at their sole expense and cost, replace such areas ofthe synthetic turf system not performing to these standards for the life of the warranty. C. Deflnitions 1. The term "not fade" in the context of this warranty shall mean that the synthetic turf material shall remain a uniform shade of green, or other colors installed, with no significant loss of color. 2. The term "not fail" or "excessive wear" as used in the context of this warranty shall mean that the length and weight of the face yarn or pile material in the synthetic turf surface above the infill materials shall not have been decreased by more than 10% per year according to ASTM D418, nor exceed 50% during the warranty period. In the event that the synthetic turf system does not retain its flber height or shock absorbency and is consequentiy no longer serviceable during the warranty period, the Contractor shall, at their sole expense, replace ••''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 7 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF such portion of the system that is no longer serviceable. , 3. The term "serviceable" in the context of this warranty shall mean that the synthetic turf system for the multi-purpose fleld shall have a maximum "G" value according to ASTM Fl 936-10 and Procedure A, ASTM F355, not to exceed 130G's at any location upon installation and shall not exceed 175G's throughout life ofthe warranty period. This shall be determined by conducting dynamic cushioning tests at the locations designated in ASTM Fl 936-10 and at corners of the soccer penalty boxes at opposite sides of the fleld. Any increase from 130G's to allowable 175G's maximum shall be at a relative uniform rate not to exceed 15 G's in any single yearly period. D. Where applicable, the fabric seams shall remain attached to the underlying surface over the warranty period and shall not separate or become unglued or unattached, as applicable. E. Contractor warrants to the Owner that the permeable synthetic system shall drain vertically a minimum of 20 inches precipitation per hour without visible surface ponding. F. Contractor shall replace with new materials, at their sole expense, any damage to the synthetic turf system that extends more than 3 feet beyond the location of foreign combustibles, which may ignite and fire-damage the synthetic turf system. The Contractor shall not be held liable for any incidental or consequential damages. These warranties and the Contractor's obligations here-under are expressly conditioned upon; 1. The Owner making all minor repairs to the synthetic turf system upon the discovery of the need for such repairs; 2. The Owner maintaining and properiy caring for the synthetic turf system in accordance with the Contractor's maintenance manual and instructions; 3. The Owner complying with the dynamic and static load speciflcations established by the Contractor. G. The warranty is not to cover any defect, failure, damage or undue wear in or to the synthetic turf system caused by or connected with abuse, neglect, deliberate acts, act of God, casualty, static or dynamic loads exceeding Contractor's recommendations, footwear having cleats, spikes, or similar projections other than conventional baseball, football, soccer, or rugby shoes having cleats of not more than 1/2" in length, or use of improper cleaning methods. H. Contractor shall be allowed to examine the synthetic turf system regarding any claim that the Owner makes to be present at any time, to analyze the results of all tests conducted by the Owner or others, and to conduct such tests of their own. Contractor shall not be responsible for any costs or expenses incurred by the Owner or others with respect to such tests, except the Contractor shall pay for costs of all tests and analysis conducted or directed by their representative. J I. Contractor shall complete all repairs within 72 hours of written notiflcation by the Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 8 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF Owner. J. In the event the Contractor does not respond to the Owner's written notice within 72 hours of receipt of notice or does not submit, schedule and execute corrective work within7 days, the Owner has the option of having the work performed at the. expense of the Contractor without impact or affect to the warranty. K. Sample form of warranty herein set forth is a suggested form for use for the work under this section. Manufacturer's standard form of warranty may be used provided all conditions specified are incorporated. All claims by the Owner under this warranty must be made in writing to Contractor's address at within 30 days after the Owner learns of the defect giving rise to the claim. This warranty shall constitute a contract made in the State of California and shall be governed by the laws thereof 1.14 WARRANTY TESTING A. The turf for the multi-purpose field is to be tested for dynamic cushioning ("G" Test) by an experienced independent testing laboratory acceptable to the Engineer or Owner at the completion of the installation shortly prior to acceptance inspection by the Owner/Engineer, at the anniversary date of the first year, second year, fourth year, sixth year, and 60 days prior to the anniversary date of the warranty expiration. If conditions of the Specifications and/or Warranty are not met, the Contractor has the option of corrective work or replacement. In the event corrective work does not meet the requirements of the Specifications after a second attempt to bring the system within these limits, then the Contractor is to replace non- conforming areas or sections solely at the Owner's discretion and direction. B. Tests shall be performed in accordance with ASTM F-1936-98 and F355. C. Test locations as designated in F-1936-10, Paragraph 8.1. Included in the report shall be the measured depth of the inflll material at all test locations. D. All costs for the stated testing shall be paid by the Synthetic Turf Surfacing Contractor. E. If the Contractor does not have the tests performed within 10 days of specifled times listed, the Owner has the option of ordering the testing work at the expense of the Synthetic Turf Surfacing Contractor. PART 2 - MATERIALS 2.01 GENERAL A. Infilled Synthetic Turf: The turf system shall be a vertical-draining permeable synthetic turf system. The turf system shall consist of a synthetic grass like surface pile, which shall be tufted into a synthetic backing. .•^ \^ '•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 9 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF B. All backing layers and coatings shall be firmly bonded together. Coating materials must be completely cured and bonded to the other backing layers. Synthetic turf panels or rolls that do not meet this requirement will be rejected. C. The entire system shall be resistant to weather, insects, rot, mildew, and fungus growth, and be non-allergenic and non-toxic. The entire system shall be constructed to maximize dimensional stability, to resist damage and normal wear and tear from its designated use, and to minimize ultraviolet degradation. D. All adhesives used in bonding the system together shall be resistant to moisture, bacterial and fungus attacks, and resistant to ultraviolet rays at any location upon installation. 2.02 DYNAMIC CUSHIONING REQUIREMENTS A. The dynamic cushioning ofthe system shall not exceed a maximum value of 130 G's per ASTM, Fl 936-10 snf ASTM, F355, procedure A at any location upon installation. 2.03 PERMEABILITY REQUIREMENTS OF THE SYNTHETIC TURF SYSTEM A. The system including the synthetic turf, infill materials shall drain vertically a minimum of 20 inches precipitation per hour without visible surface ponding. 2.04 SYNTHETIC TURF PILE SURFACE A. The pile surface shall provide good traction in all types of weather with the use of conventional "sneaker-type shoes" and composition, molded-sole athletic shoes. B. The pile surface shall be suitable for both temporary and permanent line markings using paint as approved by the synthetic turf vendor where applicable. C. Pile surface shall be nominally uniform in length for all portions of the field. Synthetic turf panels or rolls with irregular pile heights or with "J hooked" fibers that extend more than 1/4 inch above the surrounding fibers will be rejected. 2.05 SYNTHETIC TURF FABRIC SURFACE A. The fabric surface shall be constructed and installed in minimum 15-foot widths with no longitudinal or transverse seams, except for head or tee seams at field boundaries and inlaid lines w/ithin a finished roll assembly. The seams shall be 15'- 0" spacing. All turf panel seams shall be sewn with high strength cord material or glued with a hot melt glue system. B. Fabric backing for the in-filled synthetic turf systems can be loose laid and anchored at the perimeter of the fields as shown in the details or adhered to the base. ••'^Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 10 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF C. Rolls that do not lay evenly and with full dimension width will be rejected. No fitted pieces or cutting within the panels will be allowed to provide true alignment or to eliminate wrinkles. D. The color shall be uniform with no visible deviations in shade permitted. Rolls that do not meet this requirement may be rejected at any time during the installation process. Pile fibers shall resemble freshly-grown natural grass in appearance, texture and colors. 2.06 SYNTHETIC TURF PERFORATIONS A. Synthetic turf with tufted fibers and a coated backing must include either perforations in the backing for vertical drainage, or the turf shall include a partially coated backing providing permeability without the use of perforations. Certified independent test results indicating a minimum drainage rate of 40 inches per hour for the permeable backing must be provided. B. Perforations in turf backing to be a minimum of 3/16" diameter clear opening and shall be spaced a maximum of 4" uniformly on-center. C. The turf shall be perforated with a minimum of 95% integrity over entire surface. Holes must be full diameter, completely through the underside of the turf backing with no material residue or fragmented fibers remaining. D. Owner's Representative shall approve the turf perforations prior to shipment upon shipment onsite, or during on-site perforating operations as applicable. E. If the non-permeable backing material exceeds 12 inches in width it shall be perforated in accordance with paragraph 2.08 of this section. Perforations shall be drilled from the surface after the adhesive has set 2.07 LINES AND MARKINGS A. A complete field lining, marking and field boundary system with team area limits, etc., shall be provided with the initial installation ofthe surfacing system. Layouts shall be accurately surveyed and marked priorto installation. Installation ofthe lines and markings shall not deviate more than 0.25 inches from the dimensions shown on the plans. B. All soccer boundary lines shall be tufted into the synthetic turf panels. Primarv Soccer: 1. Playing field boundaries: 4" wide white lines, tufted 2. Mid-field line: 4" wide white line, tufted 3. Goal and penalty boxes: 4" wide white lines, inlaid 4. Center circle & penalty arc: 4" wide white lines, inlaid 5. Corner kick arc: 4" wide white lines, inlaid 6. Corner kick hash marks: 4" wide x 3' white lines, inlaid '•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 11 OF 19 €3 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF 7. Center spot: 8. Team box: 9" diameter white dot, inlaid 4" wide white lines, inlaid Modified Soccer 1. Playing field boundaries: 4" wide yellow lines, tufted 2. Mid-field line: 4" wide yellow line, inlaid 3. Goal and penalty boxes: 4" wide yellow lines, inlaid 4. Center circle & penalty arc: 4" wide yellow lines, inlaid 5. Corner kick arc: 4" wide yellow lines, inlaid 6. Corner kick hash marks: 4" wide x 3' yellow lines, inlaid 7. Center spot: 9" diameter yellow dot, inlaid C. Manufacturer shall guarantee the synthetic turf is adaptable to painted lines in the event additional painting is utilized in the future. 2.08 MINIMUM SPECIFICATIONS FOR SYNTHETIC TURF SYSTEM MATERIALS A. The minimum material will be verified and enforced and will be the basis for Owner's testing. Material that fails to meet these minimum specifications will be rejected. The material speciflcations in this section are minimums. The manufacturer of the synthetic turf fiber and fabric may elect to exceed these specifications to insure compliance with all requirements and the warranty as specified in this section. B. Color of synthetic turf to be green as approved by Owner with white, and yellow/gold, as required in Section 2.0^7 for the lines and markings. The fiber used for the lines and markings shall be of the same composition as that used for the green field areas. 2.09 MINIMUM SPECIFICATIONS FOR SYNTHETIC TURF SYSTEM MATERIALS B. The minimum material will be verified and enforced and will be the basis for Owner's testing. Material that fails to meet these minimum specifications will be rejected. The material specifications in this section are minimums. The manufacturer of the synthetic turf fiber and fabric may elect to exceed these specifications to insure compliance with all requirements and the warranty as specifled in this section. Color of synthetic turf to be medium green as approved by Owner's Representative. The fiber used for the lines and markings shall be of the same composition as that used for the green areas. Revised 07/17/2015 Item ASTM Property Minimum Specifications 1. D418 Pile Weight (PE) 37 oz/sq yard 2. D418 Pile Weight (Nylon) 15 oz/sq yard 3. D418 Pile Weight (Total) 52 oz/sq yard 4. D418 Primary Backing 8 oz/sq yard total 5. D418 Back Coating 26 oz/sq yard 6. D418 Total Weight 86 oz/sq yard Contract No. PKS16-02PKS PAGE 12 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF 7. D418 Pile Height 2.00"-2.25" 8. D1335 Tuft Bind (without infill) 8 Ibs. 9. D1682 Grab/Tear Strength 200 lbs. 10. D2859 Pill Burn Test Pass C. The primary pile fiber shall be 100% polyethylene athletic quality yarn designed specifically for outdoor use and stabilized to resist the effects of ultra-violet degradation, heat, wear, water and airborne pollution. They shall include a uniform blend of both long parallel slit-film and monofilament fibers. The fabric shall include a highly texturized secondary fiber in the lower portion of the profile for infill stabilization. The secondary infill stabilization fiber shall be 100%) nylon. The coating and backing materials shall assure suitable tuft bind strength, dimensional stability, and long-term wearing properties. D. Fiber shall be certified to have less than 50 ppm or less of lead from both the fiber supplier and the turf vendor. E. The primary monofilament fiber shall meet the following requirements: Item ASTM Property Minimum Specifications 1. D1577 Yarn Denier / Ply 12,000/6 2. D1577 Base Filament Thickness 130 U Micron 3. D1577 Monofilament Width 1.40 mm 4. D2256 Yarn Breaking Strength 20 Ibs 5. D2256 Yarn Elongation to Break 50% 6. D789 Yarn Melting Point 240° F. primary parallel long slit film fiber shall meet the following requirements: Item ASTM Property Minimum Specifications 1. D1577 Yarn Denier / Ply 8,000 /1 2. D1577 Base Filament Thickness 100 U Micron 3. D2256 Yarn Breaking Strength 20 Ibs 4. D2256 Yarn Elongation to Break 50% 5. D789 Yarn Melting Point 240° F. G. The secondary infill stabilization nylon fiber shall meet the following requirements: Item ASTM Property Minimum Specifications 1. D1577 Yarn Denier/Ply 2. D2256 Yarn Breaking Strength 3. D789 Yarn Melting Point 5,000 / 8 2.3 grams/denier 490° F. H. Fiber Wear Simulation: Fiber shall exhibit no splitting or appreciable degradation Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 13 OF 19 city of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF after a minimum of 12,000 cycles of simulated Lisport wear testing and shall remain serviceable without appreciable face weight loss after a minimum of 40,000 cycles of simulated Lisport wear testing. 2.10 INFILL MATERIALS A. The synthetic turf shall utilize a combination of sand and ambient or cryogenic rubber infill materials. The maximum sand content shall not exceed 30% by volume and shall not be less than 20% by volume. The exact in-fill material ratio may be altered to provide strength, shock attenuation, and to provide permeability by the vendor/installer as approved by the Engineer. B. Infill material shall be applied in a dried condition when the turf is dry. It shall be applied in uniform layers effectively dragged to distribute the material uniformly to the backing of the turf. C. The sand infill material shall be graded silica sand, sub-round to round, compaction resistant, washed and dried. The sand shall meet the following criteria: Percent Silica 80-95% Shape Round to Sub-round Sphericity 0.65 - 0.85 Roundness 0.60 - 0.70 Hardness (Moh) 7 The sand gradation shall meet the following wet sieve analysis: Sieve Size Percent Retained #16 0%-5% #20 10%-20% #30 50% - 70% #40 15%-25% #50 0%-10% #100 0%-5% Pan 0% - 2% E. Rubber shall be ambient or cryogenically produced SBR free of any tire cord and steel materials. Infill shall be free of Kevlar. Only automotive or truck tires manufactured in North America may be used forthe SBR infill material. Tires more than 10 year old from date of production are not allowed. The infill material gradation shall meet the following size requirements: 2.0-1.5 mm 0%-10% 1.5-1.0 mm 10%-30% 1.0-0.5 mm 40%-80% 0.5-0.0 mm 0%-10% F. SBR rubber shall be certified to have less than 50 ppm or less of lead from both the /\ \u\ ^•''Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 14 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF rubber supplier and the turf vendor. G. Inflll material shall be applied in a dried condition when the turf is dry. It shall be applied in uniform layers effectively dragged to distribute the material uniformly to the backing of the turf. H. The application rate shall provide a total minimum weight of 2.50 lbs of rubber inflll material per square foot of the turf area, or more as required providing a maximum exposed fiber height of %" after infill placement, settling, and compaction. PART 3 - EXECUTION 3.01 CERTIFICATION OF FIELD BASE INSTALLATION A. The Contractor or the Contractor's subcontractor shall perform an inspection of the existing permeable aggregate and submit written certiflcation of acceptance of the base for the installation of the synthetic turf system. B. Summary of certification shall include, but not be limited to: 1. Acceptance of the base construction "finish surfaces" as totally suitable for the application of work specified under this section. 2. Veriflcation and certification of the infiltration and permeability rates of the permeable aggregate as applying to the warranty. C. All discrepancies between the required materials, application and tolerance requirements noted by the turf installer shall be brought immediately to the attention of the Contractor and the Project Engineer. Failure of the turf installer to immediately inform the Contractor and Project Engineer of any prior work that does not meet the required specifications will result in the turf installer being required to perform any work needed to bring the base to acceptable condition. 3.02 INSPECTION OF MATERIALS A. Prior to installation, and immediately upon delivery of synthetic turf system materials to the project site, the Synthetic Turf Surfacing Contractor shall inspect material as follows: 1. For damaged or defective items; 2. Measure turf pile height and thickness of each roll; 3. Measure backing perforation diameter and spacing; 4. Reject damaged materials and all materials out of tolerance with this specification. B. After installation, inspect project area for acceptable seaming, adhesive bonding, uniformity of color of turf, bubble-free surface smoothness as laid, field lines and markings, insert installations, edge details. Remove and/or repair deficient ¥ Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 15 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF workmanship prior to requesting the Project Engineer's inspection pursuant to completion and acceptance of the work. 3.03 OWNER'S TEST A. Owner may have samples of the turf submitted and tested for verification of conformance to specifications. Turf system acceptance is subject to the results of these tests. B. Any material so tested and found not conforming to specification will be rejected and replaced with material conforming to the specification at Synthetic Turf Surfacing Contractor's expense. Re-submittal shall be required. 3.04 SYNTHETIC TURF INSTALLATION A. Perform all work in strict accordance to the drawings, shop drawings and manufacturer's speciflcations and instructions. B. Veriflcation: The Contractor is responsible for inspecting, verifying, and accepting all installed work of this section. C. Preparation: 1. Accept base onto which the synthetic turf surfacing system and the anchoring system are to be applied, as specified above. 2. Immediately prior to application of the synthetic turf, the base shall be thoroughly cleaned of all foreign material, soil, or any other substances that may be detrimental to permeabilify and the installation of the turf system. D. Equipment and Access: 1. Passenger vehicles shall not be allowed to park or staged upon the completed aggregate surface either prior to or during installation of the synthetic turf. 2. Equipment utilized during construction including compressors, generators, etc. shall be in complete working order, with exhaust systems oriented vertically and away from the synthetic turf surface. At any location where equipment is parked and/or staged on the turf surface during installation, adequate protection ofthe finish turf surface will be required including, but not limited to heat resistant panels to ensure 100% viability ofthe finish turf surface and fibers. Should a portion of the turf be damaged as a result of installation techniques, the entire turf panel may be subject to rejection and replacement at the direction of the Engineer. E. The fabric surface shall be constructed and installed in 15 foot minimum widths with no longitudinal or transverse seams, except for head or tee seams at field boundaries and inlaid lines within a finished roll assembly. F. No head seams shall be permitted inside of the primary soccer field boundaries. A ••'^Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 16 OF 19 \ J / City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF single head seam will be permitted in the quarter turned panels outside of the soccer sidelines. G. Rolls that do not lay evenly and with full dimension width will be rejected. No fitted pieces will be allowed to true alignment. No fitted pieces or cutting within the panels will be allowed to provide true alignment or to eliminate wrinkles. H. Seams (Joint) 1. All turf panel seams within the soccer field grid and the % turn sideline panels shall be sewn with high strength cord. Use of a cart sewing machine suitable for completion of butt seams is preferred to minimize overiap and excess selvage of material at sewn seams. Alternate seaming methods including heat actuated seaming tape with polyurethane based binders will be considered as an alternate to sewn seams. 2. Perimeter panels and seams may be cemented with a supplemental backing material. 3. The seam gaps between fiber courses shall not exceed the tufting gauge for the material. 4. All sewn seams shall be brushed to provide full coverage of fiber over the thread. 5. Seams must maintain their integrity for total length of warranty period. I. Turf Edges: Turf edges to be as shown on the edge fastening detail and nailed and glued at the turf perimeter. 3.05 LINING / MARKING INSTALLATION A. Complete field markings shall be provided with the initial installation ofthe surfacing system. Provide lines and markings in conformance with these specifications. Layouts shall be accurately surveyed and marked prior to installation. B. If overiapping backing materials are utilized for the inlaid lines and markings resulting in a non-permeable surface in excess of 12 inches wide, the backing materials shall be perforated in conformance with section 2.06 from the surfacing after gluing and prior to installation of the infill material. C. To the greatest extent practical, lines and markings shall be installed without compromising the primary backing. 3.06 IN-FILL INSTALLATION A. Prior to application of infill, the entire turf area shall be vacuumed clean from of all debris, loose fiber or other construction materials. Brushing/brooming of fibers to the fleld perimeter as a primary means of debris clean-up is not acceptable. B. The in-flll material shall be applied in a dry condition and when the synthetic turf is dry. Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 17 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF C. The synthetic turf installer shall not infringe upon any current or pending patents held by other synthetic turf manufacturers or installers with the installation ofthe in- fill materials. D. For sand and rubber infill systems, the infill materials will be installed with a minimum of 12 applications. E. The infill installation shall not result in fiber material trapped below the surface of the infill material. If fiber is trapped below the surface, a portion or all ofthe infill material must be removed and reinstalled. F. The infill material shall be installed at a uniform depth across the entire field area. Infill depths shall not vary by more than Smm across the field area. G. The brushing ofthe in-fill material shall provide fiber fibrillation resulting in a natural surface appearance. H. The in-fill materials shall water settled to provide accelerated consolidation of the in- fill material prior to use by the Owner. Water is available from quick coupling valves located around the field. The Synthetic Turf Contractor shall utilize portable sprinkler heads to evenly apply a minimum of 1 inch of water over the entire field area for water settlement Upon completion of the initial water settlement, the surface will be inspected the Owner and Engineer for footing stability and in-fill consolidation. The Synthetic Turf Contractor shall provide any additional water settling as required by the Owner and Engineer to achieve the desired level of in-fill stability and consolidation. 3.07 CLEANING A. Remove all excess materials of all types, equipment, debris, etc., from the site immediately after completion of the work. Remove all stains and other blemishes from all finished surfaces. Leave work in clean, new appearing condition, ready for use by Owner. B. The Contractor shall inspect the entire field area with a hand held metal detector to identify any construction materials or tools left on the field. Inspection with metal detector shall be observed by the Engineer. All such materials shall be removed prior to Owner occupancy of the field. 3.08 PROTECTION A. Adequate protection of materials and work from damage will be the responsibility of the installer during installation and until acceptance of their work. Synthetic Turf Surfacing Contractor will be responsible for protection after the acceptance of the work until final acceptance of all contract work by the Owner. All material damaged prior to acceptance by the Owner shall be replaced at no cost to the Owner. 0^ ^ •F Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 18 OF 19 City of Carlsbad Aviara Community Park Synthetic Turf Replacement SECTION 02964 IN-FILLED SYNTHETIC TURF 3.09 EXTRA MATERIALS A. Deliver to Owner all extra materials herein specified. Receive Owner's written receipt for all materials. Deliver receipt to Project Engineer. B. Infill Materials: Provide four (4) 33 gallon rubber trash containers with lids of each infill material used. C. Turf for Future Repairs: Material may be roll ends or cutoffs; however, each piece of fabric shall be at least 5' x 10'. At least one green turf piece shall be at least 10' x 15'. The following are minimum areas for the extra synthetic turf materials to be provided by the Synthetic Turf Surfacing Contractor to the Owner: Minimum Quantities for each site: 1. Green Turf: 1000 sf 2. White Turf: 100 If of 4" wide lines 3. Yellow/Gold Turf: 100 LF of 4" wide lines 3.10 MAINTENANCE A. Vendor shall complete maintenance of the synthetic turf field at both 6 months and 1 year after the date of Substantial Completion. Minimum maintenance activities shall include: 1. Inspect and repair as required each seam. 2. Brush and remove surface debris, loose fibers and any other deleterious material. Use of a rotating, mechanical brush is recommended. 3. Decompact and re-level infill materials. Import and place /top dress new infill material matching original infill materials as needed to establish original infill depth, with %" of exposed fiber. 4. All maintenance activities shall be as approved and directed by the original manufacturer. 5. All maintenance activities shall be coordinated with scheduled use ofthe facility and completed at the convenience ofthe owner and applicable user groups. - END OF SECTION - Copyright DA Hogan & Associates Inc. 2015 €5 ••'^Revised 07/17/2015 Contract No. PKS16-02PKS PAGE 19 OF 19 ^ / .. il Receive -Agenda Item #I 4 For the Information of the: CITY COUNCIL AC~~CA v CC ,/ D~te ~City Manager / Memorandum July 28, 2015 Ccicyof Carlsbad To: Mayor and City Council Members . From: ~ Kyle lancaster, Parks Superintendent Re: • ERRATA SHEET FOR AGENDA ITEM #4-ADOPT RESOLUTION APPROVING CONTRACT DOCUMENTS, PlANS, PROVISIONS AND SPECIFICATIONS-' AND AUTHORIZING THE CITY ClERK TO ADVERTISE FOR BIOS THE REPlACEMENT OF THE SYNTHETIC TURF AT AVIARA COMMUNITY PARK SOCCER FIElD- CONTRACT NO. PKS16-02PKS Staff is recomme!nding that the City Council include the following revisions: '1. ltem #4 -Agenda Bill # 22,045 entitled; ADOPT RESOLUTION APPROVING CONTRACT DOCUMENTS, PLANS, PROVISIONS AND SPECIFICATIONS, AND AUTHORIZING THE CITY CLERK TO ADVERTISE FOR BIDS THE REPLACEMENT OF THE SYNTHETIC TURF AT AVIARA COMMUNITY PARK SOCCER FJELD-CONTRACT NO. PKS16-02PKS a. Exhibit 2 -Contract documents, plans, provisions and specifications for the replacement of the synthetiC turf at the Aviara Community Park soccer field i. Section 02500-Sitework Concrete, Part 2 -Products, Subsection 2.01 - Concrete, G. -Cast-in-place Concrete components, 10. Control Joints: replace 'Wot less than 3/8" thick x 3/8" minimum depth with tooled edqesJI, with "Per SSPWC 305-5.4.3.b" Date: iti/~? 4{s Dlstribut on: 1 City Clerk ASst. City Clerk Deputy Clerk Book