Loading...
HomeMy WebLinkAboutBlue Pacific Engineering and Construction; 2021-04-20; PWS21-1369TRANCITY OF CARLSBAD San Diego County Calif ornia CONTRACT DOCUMENTS, GENERAL PROVISIONS, SUPPLEMENTAL PROVISIONS, AND TECHNICAL SPECIFICATIONS FOR TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 BID NO. PWS21-1369TRAN - Bidding tat Revised 6/12/18 Contract No 6335 Page 1 of 176 TABLE OF CONTENTS Item Page Notice Inviting Bids 7 Contractor's Proposal 14 Bid Security Form 21 Bidder's Bond to Accompany Proposal 22 Guide for Completing the "Designation of Subcontractors" Form 23 Designation of Subcontractor and Amount of Subcontractor's Bid Items 25 Bidder's Statement of Technical Ability and Experience 26 Bidder's Certificate of Insurance for General Liability, Employers' Liability, Automotive Liability and Workers' Compensation 27 Bidder's Statement Re Debarment 28 Bidder's Disclosure of Discipline Record 29 Noncollusion Declaration to Be Executed by Bidder and Submitted with Bid 31 Contract Public Works 32 Labor and Materials Bond 39 Faithful Performance/Warranty Bond 41 Optional Escrow Agreement for Surety Deposits in Lieu of Retention 43 1 % 01- Revised 6/12/18 Contract No. 6335 Page 2 of 176 GENERAL PROVISIONS Terms, Definitions Abbreviations and Symbols Terms 46 Definitions 46 Abbreviations 50 Units of Measure 53 Symbols 54 Scope and Control of The Work Award and Execution of Contract 55 Assignment 55 Subcontracts 55 Contract Bonds 56 Plans and Specifications 57 Work to be Done 61 Subsurface Data 61 Right-of-Way 61 Surveying 62 Authority of Board and Engineer 66 Inspection 66 Changes in Work Changes Requested by the Contractor 67 Changes Initiated by the Agency 67 Extra Work 68 Changed Conditions 71 Disputed Work 72 Control of Materials Materials and Workmanship 78 Materials Transportation, Handling and Storage 82 Utilities Location 83 Protection 83 Removal 84 Relocation 84 Delays 85 Cooperation 85 Prosecution, Progress and Acceptance of the Work Construction Schedule and Commencement of Work 86 Prosecution of Work 90 Suspension of Work 91 Default by Contractor 91 Termination of Contract 92 Delays and Extensions of Time 92 Time of Completion 93 Section 1 1-1 1-2 1-3 1-4 1-5 Section 2 2-1 2-2 2-3 2-4 2-5 2-6 2-7 2-8 2-9 2-10 2-11 Section 3 3-1 3-2 3-3 3-4 3-5 Section 4 4-1 4-2 Section 5 5-1 5-2 5-3 5-4 5-5 5-6 Section 6 6-1 6-2 6-3 6-4 6-5 6-6 6-7 1 % 01- Revised 6/12/18 Contract No. 6335 Page 3 of 176 6-8 Completion, Acceptance, and Warranty 94 6-9 Liquidated Damages 94 6-10 Use of Improvement During Construction 94 Section 7 Responsibilities of the Contractor 7-1 Contractor's Equipment and Facilities 96 7-2 Labor 96 7-3 Liability Insurance 96 7-4 Workers' Compensation Insurance 96 7-5 Permits 97 7-6 The Contractor's Representative 97 7-7 Cooperation and Collateral Work 97 7-8 Project Site Maintenance 98 7-9 Protection and Restoration of Existing Improvements 100 7-10 Public Convenience and Safety 100 7-11 Patent Fees or Royalties 107 7-12 Advertising 107 7-13 Laws to be Observed 107 7-14 Antitrust Claims 107 Section 8 Facilities for Agency Personnel 8-1 General 108 Section 9 Measurement and Payment 9-1 Measurement of Quantities for Unit Price Work 110 9-2 Lump Sum Work 110 9-3 Payment 110 9-4 Bid Items 113 4P-1k —r• Revised 6/12/18 Contract No: 6335 Page 4 of 176 SUPPLEMENTAL PROVISIONS TO PART 2 AND 3 OF THE SSPWC PART 2 CONSTRUCTION MATERIALS Section 200 Rock Materials 200-1 Rock Products 118 200-2 Untreated Base Materials 119 Section 201 Concrete, Mortar and Related Materials 201-1 Portland Cement Concrete 120 201-3 Expansion Joint Filler and Joint Sealants 120 Section 203 Bituminous Materials 203-6 Asphalt Concrete 122 203-11 Asphalt Rubber Hot Mix (ARHM) Wet Process 123 Section 204 Lumber and Treatment with Preservatives 204-1 Lumber and Plywood 123 Section 206 Miscellaneous Metal Items 206-7 Traffic Signs 123 206-8 Light Gage Steel Tubing and Connectors 126 206-9 Portable Changeable Message Sign 127 206-10 Steel Gratings 128 Section 207 Pipe 207-2 Reinforced Concrete Pipe 129 207-9 Iron Pipe and Fittings 129 207-10 Steel Pipe 129 207-25 Underground Utility Marking Tape 130 Section 209 Electrical Components 131 209-6 Measurement and Payment 148 Section 210 Paint and Protective Coatings 210-1 Paint 148 210-3 Galvanizing 149 Section 212 Landscape and Irrigation Materials 212-4 Hydrants 150 Section 213 Engineering Fabrics 213-2 Geotextiles 150 213-3 Erosion Control Specialties 150 Section 214 Pavement Markers 214-5 Reflective Pavement Markers 151 Section 215 Fencing 215-1 Environmental Fencing 152 PART 3 CONSTRUCTION METHODS Section 300 Earthwork 300-1 Clearing and Grubbing 153 300-5 Borrow Excavation 153 41M ta w. —1- Revised 6/12/18 Contract No. 6335 Page 5 of 176 300-9 Geotextiles for Erosion Control and Water Pollution Control. 300-13 Storm Water Pollution Prevention Plan 154 155 Treated Soil, Subgrade Preparation and Placement of Base Materials Subgrade Preparation 158 Roadway Surfacing Asphalt Concrete Pavement 160 Asphalt Pavement Repairs and Remediation 161 Concrete and Masonry Construction. Concrete Structures 162 Air-Placed Concrete 163 Concrete Curbs, Walks, Gutters, Cross Gutters, Alley Intersections, Access Ramps, And Driveways 163 Trench Drain/Curb Channel Construction 164 Underground Conduit Construction Open Trench Operations 165 Abandonment of Conduits and Structures 168 168 Painting Painting Various Surfaces 169 Permanent Signing 170 Pavement Marker Placement and Removal Placement 170 Temporary Traffic Control Devices Temporary Traffic Pavement Markers 171 Temporary Traffic Signing 172 Temporary Railing (Type K) and Crash Cushions 172 Measurement and Payment 173 Modified Asphalt, Pavement and Processes Rubberized Emulsion — Aggregate Slurry 175 176 Section 301 301-1 Section 302 302-5 302-11 Section 303 303-1 303-2 303-5 303-9 Section 306 306-1 306-5 307 Street Lighting and Traffic Signals Section 310 310-5 310-7 Section 312 312-1 Section 313 313-1 313-2 313-3 313-4 Part 6 600-3 Appendix A 1% Revised 6/12/18 Contract No. 6335 Page 6 of 176 CITY OF CARLSBAD, CALIFORNIA NOTICE INVITING BIDS Until 11 a.m. on February 18, 2021, the City shall accept bids via electronic format via the City of Carlsbad Electronic Bidding Site, PlanetBids, which may be accessed at https://www.carlsbadca.ov/services/depts/finance/contractinq/defauffasp, for performing the work as follows: Remove existing RRFB, install HAWK and curb extensions at Tamarack Avenue and Valley Street. TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6336 BID NO. PWS21-1369TRAN ELECTRONIC FORMAT RECEIPT AND OPENING OF BIDS: Bids will be received in electronic format (eBids) EXCLUSIVELY at the City of Carlsbad's electronic bidding (eBidding) site, at: https://www.carlsbadca.gov/services/depts/finance/contractinq/default.asp and are due by the date and time shown on the cover of this solicitation. BIDDERS MUST BE PRE-REGISTERED with the City's bidding system and possess a system-assigned Digital ID in order to submit an electronic bid. The City's electronic bidding (eBidding) system will automatically track information submitted to the site including IP addresses, browsers being used and the URLs from which information was submitted. In addition, the City's bidding system will keep a history of every login instance including the time of login, and other information about the user's computer configuration such as the operating system, browser type, version, and more. Because of these security features, Bidders who disable their browsers' cookies will not be able to log in and use the City's bidding system. The City's electronic bidding system is responsible for bid tabulations. Upon the bidder's or proposer's entry of their bid, the system will ensure that all required fields are entered. The system will not accept a bid for which any required information is missing. This includes all necessary pricing, subcontractor listing(s) and any other essential documentation and supporting materials and forms requested or contained in these solicitation documents. BIDS REMAIN SEALED UNTIL DUE DATE AND TIME. eBids are transmitted into the City's bidding system via hypertext transfer protocol secure (https) mechanism using SSL 128-256-bit security certificates issued from Verisign/Thawte which encrypts data being transferred from client to server. Bids submitted prior to the Due Date and Time are not available for review by anyone other than the submitter, who will have until the Due Date and Time to change, rescind or retrieve its bid should they desire to do so. BIDS MUST BE SUBMITTED BY DUE DATE AND TIME. Once the deadline is reached, no further submissions are accepted into the system. Once the Due Date and Time has passed, bidders, proposers, the general public, and City staff are able to immediately see the results online. City staff may then begin reviewing the submissions for responsiveness, compliance and other issues. tat, •—v- Revised 6/12/18 Contract No. 6335 Page 7 of 176 RECAPITULATION OF THE WORK. Bids shall not contain any recapitulation of the Work. Conditional Bids may be rejected as being non-responsive. Alternative proposals will not be considered unless called for. BIDS MAY BE WITHDRAWN by the Bidder prior to, but not after, the time set as Due Date and Time. Important Note: Submission of the electronic bid into the system may not be instantaneous. Due to the speed and capabilities of the user's internet service provider (ISP), bandwidth, computer hardware and other variables, it may take time for the bidder's submission to upload and be received by the City's eBidding system. It is the bidder's sole responsibility to ensure their bids are received on time by the City's eBidding system. The City of Carlsbad is not responsible for bids that do not arrive by the Due Date and Time. ELECTRONIC SUBMISSIONS CARRY FULL FORCE AND EFFECT. The Bidder, by submitting their electronic proposal, agrees to and certifies under penalty of perjury under the laws of the State of California, that the certification, forms and affidavits submitted as part of this proposal are true and correct. The bidder, by submitting its electronic bid, acknowledges that doing so carries the same force and full legal effect as a paper submission with a longhand (wet) signature. By submitting an electronic bid, the bidder certifies that the bidder has thoroughly examined and understands the entire Contract Documents (which consist of the plans and specifications, drawings, forms, affidavits and the solicitation documents), and that by submitting the eBid as its bid proposal, the bidder acknowledges, agrees to and is bound by the entire Contract Documents, including any addenda issued thereto, and incorporated by reference in the Contract Documents. BIDS ARE PUBLIC RECORDS Upon receipt by the City, bids shall become public records subject to public disclosure. It is the responsibility of the Bidder to clearly identify any confidential, proprietary, trade secret or otherwise legally privileged information contained within the proposal's General references to sections of the California Public Records Act (PRA) will not suffice. If the Bidder does not provide applicable case law that clearly establishes that the requested information is exempt from the disclosure requirements of the PRA, the City shall be free to release the information when required in accordance with the PRA, pursuant to any other applicable law, or by order of any court or government agency, and the Bidder agrees to hold the City harmless for any such release of this information. This bid and the terms of the Contract Documents and Supplemental Provisions constitute an irrevocable offer that shall remain valid and in full force for a period of 90 days and such additional time as may be mutually agreed upon by the City of Carlsbad and the Bidder. INSTRUCTIONS TO BIDDERS AND BID REQUIREMENTS This bid and the terms of the Contract Documents and General Provisions constitute an irrevocable offer that shall remain valid and in full force for a period of 90 days and such additional time as may be mutually agreed upon by the City of Carlsbad and the Bidder. No bid will be received unless it is made on a proposal form furnished by the Purchasing Department. Each bid must be accompanied by security in a form and amount required by law. The bidder's security of the second and third next lowest responsive bidders may be withheld until the Contract has been fully executed. The security submitted by all other unsuccessful bidders shall be returned to them, or deemed void, within ten (10) days after the Contract is awarded. —3- Revised 6/12/18 Contract No. 6335 Page 8 of 176 Pursuant to the provisions of law (Public Contract Code section 10263), appropriate securities may be substituted for any obligation required by this notice or for any monies withheld by the City to ensure performance under this Contract. Section 10263 of the Public Contract Code requires monies or securities to be deposited with the City or a state or federally chartered bank in California as the escrow agent. The escrow agent shall maintain insurance to cover negligent acts and omissions of the agent in connection with the handling of retentions under this section in an amount not less than $100,000 per contract. The City of Carlsbad may disqualify a contractor or subcontractor from participating in bidding when a contractor or subcontractor has been debarred by the City of Carlsbad or another jurisdiction in the State of California as an irresponsible bidder. The work shall be performed in strict conformity with the plans, provisions, and specifications as approved by the City Council of the City of Carlsbad on file with the City Clerk's Office. The specifications for the work include City of Carlsbad Technical Specifications and the Standard Specifications for Public Works Construction, Parts 2 & 3, current edition at time of bid opening and the supplements thereto as published by the "Greenbook" Committee of Public Works Standards, Inc., all hereinafter designated "SSPWC", as amended. Specification Reference is hereby made to the plans and specifications for full particulars and description of the work. The General Provisions (Part 1) to the SSPWC do not apply. The City of Carlsbad encourages the participation of minority and women-owned businesses. The City of Carlsbad encourages all bidders, suppliers, manufacturers, fabricators and contractors to utilize recycled and recyclable materials when available, appropriate and approved by the Engineer. BID DOCUMENTS The bid documents comprise the following documents which must be completed and properly executed including notarization, where indicated. 1.Contractor's Proposal 2.Bidder's Bond (At Time of Bid Submit PDF Copy via PlanetBids / All Bidders). Bid Bond (Original) Due within Two Business Days After Bid Opening/ 3 Apparent Low Bidders. 3.Noncollusion Declaration 4.Designation of Subcontractor and Amount of Subcontractor's Bid 5.Bidder's Statement of Technical Ability and Experience 6.Acknowledgement of Addendum(a) 7.Certificate of Insurance. The riders covering the City, its officials, employees and volunteers may be omitted at the time of bid submittal but shall be provided by the Bidder prior to award of this contract. 8.Bidder's Statement Re Debarment 9.Bidder's Disclosure of Discipline Record 10.Escrow Agreement for Security Deposits - (optional, must be completed if the Bidder wishes to use the Escrow Agreement for Security) BIDDER'S GUARANTEE OF GOOD FAITH (BID SECURITY) At the time of bid submission, bidders must upload and submit an electronic PDF copy of the aforementioned bid security. Whether in the form of a cashiers check, a properly certified check or an approved corporate surety bond payable to the City of Carlsbad, the bid security must be —r- Revised 6/12/18 Contract No. 6335 Page 9 of 176 uploaded to the City's eBidding system. Within two (2) business days after the bid opening date, the first three (3) apparent low bidders must provide the City with the original bid security. Failure to submit the electronic version of the bid security at time of bid submission shall cause the bid to be rejected and deemed non-responsive. Only the three (3) apparent low-bidders are required to submit original bid security to the city within two (2) business days after bid opening date. Failure to provide the original within two (2) business days may deem the bidder non- responsive. Due to COVID-19, the City of Carlsbad offices are closed to the Public. Bidder's Bid Bond (Original) will be accepted via USPS, UPS or any other courier service during regular business hours. ENGINEER'S ESTIMATE All bids will be compared on the basis of the Engineer's Estimate. The estimated quantities are approximate and serve solely as a basis for the comparison of bids. The Engineer's Estimate is $372,529. TIME OF COMPLETION The contractor shall complete the Work within the time set in the contract as defined in the General Provisions Section 6-7. SPECIALTY CONTRACTORS: ACCEPTABLE LICENSE TYPES Except as provided herein a bid submitted to the City by a Contractor who is not licensed as a contractor pursuant to the Business and Professions Code shall be considered nonresponsive and shall be rejected by the City. In all contracts where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder to be licensed in accordance with California law. Where federal funds are involved the contractor shall be properly licensed at the time the contract is awarded. In all other cases the contractor shall state their license number, expiration date and classification in the proposal, under penalty of perjury. This invitation to bid does not include federal funds. The following classifications are acceptable for this contract: A — General Engineering or C10 - General Electrical. ESCROW AGREEMENT If the Contractor intends to utilize the escrow agreement included in the contract documents in lieu of the usual 5% retention from each payment, these documents must be completed and submitted with the signed contract. The escrow agreement may not be substituted at a later date. OBTAINING PLANS AND SPECIFICATIONS Bid packages, various supplemental provisions and Contract Documents may be obtained on the City of Carlsbad website at www.carlsbadca.gov. Paper copies will not be sold. INTENT OF PLANS AND SPECIFICATIONS Any prospective bidder who is in doubt as to the intended meaning of any part of the drawings, specifications or other contract documents, or finds discrepancies in or omissions from the drawings and specifications may submit to the Engineer a written request for 'clarification or correction. Any response will be made only by a written addendum duly issued by the Engineer a copy of which will be mailed or delivered to each person receiving a set of the contract documents. No oral response will be made to such inquiry. Prior to the award of the contract, no addition to, modification of or interpretation of any provision in the contract documents will be (psi 0 1- Revised 6/12/18 Contract No. 6335 Page 10 of 176 given by any agent, employee or contractor of the City of Carlsbad except as hereinbefore specified. No bidder may rely on directions given by any agent, employee or contractor of the City of Carlsbad except as hereinbefore specified. REJECTION OF BIDS The City of Carlsbad reserves the right to reject any or all bids and to waive any minor irregularity or informality in such bids. PREVAILING WAGE TO BE PAID The general prevailing rate of wages for each craft or type of worker needed to execute the Contract shall be those as determined by the Director of Industrial Relations pursuant to the sections 1770, 1773, and 1773.1 of the Labor Code. Pursuant to section 1773.2 of the Labor Code, a current copy of applicable wage rates is on file in the Office of the City Engineer. The Contractor to whom the Contract is awarded shall not pay less than the said specified prevailing rates of wages to all workers employed by him or her in the execution of the Contract. The Prime Contractor shall be responsible for insuring compliance with provisions of section 1777.5 of the Labor Code and section 4100 et seq. of the Public Contracts Code, "Subletting and Subcontracting Fair Practices Act." The City Engineer is the City's "duly authorized officer" for the purposes of section 4107 and 4107.5. The provisions of Part 7, Chapter 1, of the Labor Code commencing with section 1720 shall apply to the Contract for work. A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, unless currently registered and qualified to perform public work pursuant to Section 1725.5. This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations. The Prime Contractor and all subcontractors shall comply with Section 1776 of the Labor Code, which generally requires keeping accurate payroll records, verifying and certifying payroll records, and making them available for inspection. Contractor shall require all subcontractors to comply with Section 1776. PRE BID MEETING A pre-bid meeting and tour of the project site will not be held. UNIT PRICES AND COMPUTATION OF BIDS All bids are to be computed on the basis of the given estimated quantities of work, as indicated in this proposal, times the unit price as submitted by the bidder. All bids are to be complete work including all fees, equipment, labor and materials associated with carrying out the work in accordance with plans and specifications. BIDDER'S INQUIRIES Questions on the bid documents during the bid period shall be submitted in writing, via email, solely to: Graham Jordan, Contract Administrator qraham.iordanacarlsbadca.qov t Al Revised 6/12/18 Contract No. 6335 Page 11 of 176 Questions shall be definite and certain and shall reference applicable drawing sheets, notes, details or specification sheets. Pre-bid substitution request shall be submitted to Contract Administrator in accordance with the Instructions to Bidders and Technical Specifications Section 002600 a minimum of 14 calendar days prior to bid opening. The cutoff date to submit pre-bid substitution requests or questions regarding this project is February 5, 2021. No questions will be entertained after that date. The answers to questions submitted during the bidding period will be published in an addendum and provided to those bidding on the project by February 11, 2021. ADDENDA Bidders are advised to verify the issuance of all addenda and receipt thereof one day prior to bidding. Submission of bids without acknowledgment of addenda may be cause of rejection of bid. BOND AND INSURANCE REQUIREMENTS The Contractor shall provide bonds to secure faithful performance and warranty of the work in an amount equal to one hundred percent (100%) of the Contract price on this project. The Contractor shall provide bonds to secure payment of laborers and materials suppliers, in an amount equal to one hundred percent (100%) of the total amount payable by the terms of the contract. These bonds shall be kept in full force and effect during the course of this project and shall extend in full force and effect and be retained by the City until they are released as stated in the General Provisions section of this contract. All bonds are to be placed with a surety insurance carrier admitted and authorized to transact the business of insurance in California and whose assets exceed their liabilities in an amount equal to or in excess of the amount of the bond. The bonds are to be accompanied by the following documents: 1)An original, or a certified copy, of the unrevoked appointment, power of attorney, by laws, or other instrument entitling or authorizing the person who executed the bond to do so. 2)A certified copy of the certificate of authority of the insurer issued by the insurance commissioner. If the bid is accepted, the City may require copies of the insurer's most recent annual statement and quarterly statement filed with the Department of Insurance pursuant to Article 10 (commencing with section 900) of Chapter 1 of Part 2 of Division 1 of the Insurance Code, within 10 calendar days of the insurer's receipt of a request to submit the statements. Insurance is to be placed with insurers that: 1)Have a rating in the most recent Best's Key Rating Guide of at least A-:VII 2)Are admitted and authorized to transact the business of insurance in the State of California by the Insurance Commissioner. Auto policies offered to meet the specification of this contract must: 1)Meet the conditions stated above for all insurance companies. 2)Cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. 1P-11, Revised 6/12/18 Contract No. 6335 Page 12 of 176 Workers' compensation insurance required under this contract must be offered by a company meeting the above standards with the exception that the Best's rating condition is waived. The City does accept policies issued by the State Compensation Fund meeting the requirement for workers' compensation insurance. The Contractor shall be required to maintain insurance as specified in the Contract. Any additional cost of said insurance shall be included in the bid price. The award of the contract by the City Council is contingent upon the Contractor submitting the required bonds and insurance, as described in the contract, within twenty days of bid opening. If the Contractor fails to comply with these requirements, the City may award the contract to the second or third lowest bidder and the bid security of the lowest bidder may be forfeited. BUSINESS LICENSE The prime contractor and all subcontractors are required to have and maintain a valid City of Carlsbad Business License for the duration of the contract. Approved by the City Council of the City of Carlsbad, California, by Resolution No. 2020-159, adopted on the 28th day of July 2020. January 13, 2021 Date Graham Jdrdan, Deputy Clerk 411,' t ie. Ur- Revised 6/12/18 Contract No. 6335 Page 13 of 176 CITY OF CARLSBAD TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 CONTRACTOR'S PROPOSAL City Council City of Carlsbad 1200 Carlsbad Village Drive Carlsbad, California 92008 The undersigned declares he/she has carefully examined the location of the work, read the Notice Inviting Bids, examined the Plans, Specifications, General Provisions, Contract Documents, and addenda thereto, and hereby proposes to furnish all labor, materials, equipment, transportation, and services required to do all the work to complete Contract No. 6335 in accordance with the Plans, Specifications, General Provisions, Contract Documents, and addenda thereto and that he/she will take in full payment therefore the following unit prices for each item complete, to wit: SCHEDULE "A" ROAD IMPROVEMENTS Item No. Description Approximate Quantity and Unit Unit Price (Figures) Total Amount (Figures) 1 Traffic Signal Improvements at 1 LS $ 177,672.00 One Hundred Seventy Seven Thousand, Six Hundred Seventy Two (Price in Words) 2 Sawcut at 275 LF $ 5.00 $ 1,375.00 Five Dollars (Price in Words) 3 Construct 6" Type G-2 Curb & Gutter per 120 LF $ 60.00 $ 7,200.00 SDRSD G-2 at Sixty Dollars (Price in Words) 4 Hot Mix Asphalt at 4 Ton $ 400.00 $ 1,600.00 Four Hundred Dollars (Unit Price in Words) 41pw fa, Revised 6/12/18 Contract No. 6335 Page 14 of 176 Item No. Description Approximate Quantity and Unit Unit Price (Figures) Total Amount (i ila ) 5 Class 2 Aggregate Base at 30 Ton $ 80.00 $ Eighty Dollars 19,500.00 (Price in Words) 13.00 6 Construct 4" PCC Sidewalk per SDRSD 1,500 SF $ G-7 and G-9 at Thirteen Dollars (Price in Words) 7 Construct Curb Ramp per G-31 with 3 EA $ 4,500.00 13,500.00 Federal Yellow Truncated Domes per SDRSD G-30 at Four Thousand Five Hundred Dollars (Unit Price in Words) 40.00 1,000.00 8 Construct PPC Cross Gutter at 25 SF $ Forty Dollars (Unit Price in Words) 9 Furnish and Install Curb Channel and 80 LF $ 450.00 $ 36'000.00 Metal Grate at Four Hundred Fifty Dollars (Unit Price in Words) 1,000.00 2,000.00 10 Remove and Salvage Existing Flashing 2 EA $ Beacon Assembly complete. Break foundation down 3' below grade at One Thousand (Unit Price in Words) 11 Adjust to Grade Existing Water Meter 1 EA $ 500.00 500.00 Box at Five Hundred (Unit Price in Words) 4p'w Revised 6/12/18 Contract No. 6335 Page 15 of 176 Approximate Item Quantity Unit Price Total Amount No. Description and Unit (Figures) (Figures) 12 Remove Existing Fire Hydrant and 1 EA $ 10,000.00 $ 10,000.00 Lateral. Furnish and Install New Fire Hydrant with Lateral and Valve at Ten Thousand Dollars and No Cents (Unit Price in Words) 13 Coordinate with SDG&E for Service Point Requirements and Install as at Five Thousand Dollars and No Cents 1 LS $ 5,000.00 (Unit Price in Words) 14 Signing, Striping and Pavement 1 LS Markings at Tan Thousand Six Hundred Forty Four Dollars and No Cents $ 10,644.00 (Unit Price in Words) $ 23'000.00 15 Mobilization at 1 LS Twenty Three Thousand Dollars and No Cents (Unit Price in Words) s 12'000.00 16 Clearing and Grubbing at 1 LS Twelve Thousand Dollars and No Cents (Unit Price in Words) 17 Traffic Control at 1 LS $ 10.000.00 Ten Thousand Dollars and No Cents (Unit Price in Words) 18 Construction Staking Surveying at Seven Thousand Dollars and No Cents 1 LS $ 7,000.00 (Unit Price in Words) 19 _Erosion Corttrol at Ten Thousand Dollars and No Cents 1 LS $ 10,000.00 (Unit Price in Words) Ur. Revised 6/12/18 Contract No. 6335 Page 16 of 176 Approximate Item Quantity Unit Price Total Amount No. Description and Unit (Figures) (Figures) 20 Grind and Overlay at 1 LS $ 8,000.00 Eight Thousand Dollars and No Cents (Unit Price in Words) Total amount of bid in words for Schedule "A": Three Hundred Fifty Eight, Three Hundred and Ninety One Dollars Total amount of bid in numbers for Schedule "A": $ 358,391.00 Price(s) given above are firm for 90 days after date of bid opening. Addendum(a) No(s). N/A None has/have been received and is/are included in this proposal. The Undersigned has carefully checked all of the above figures and understands that the City will not be responsible for any error or omission on the part of the Undersigned in preparing this bid. The Undersigned agrees that in case of default in executing the required Contract with necessary bonds and insurance policies within twenty (20) days from the date of award of Contract by the City Council of the City of Carlsbad, the City may administratively authorize award of the contract to the second or third lowest bidder and the bid security of the lowest bidder may be forfeited. The Undersigned bidder declares, under penalty of perjury, that the undersigned is licensed to do business or act in the capacity of a contractor within the State of California, validly licensed under license number 824455 , classification A, B, CB, C27, C10 which expires on 09/30/2021 , and Department of Industrial Relations PWC registration number 1000003217 which expires on 6/30/2021 , and that this statement is true and correct and has the legal effect of an affidavit. A bid submitted to the City by a Contractor who is not licensed as a contractor pursuant to the Business and Professions Code shall be considered nonresponsive and shall be rejected by the City § 7028.15(e). In all contracts where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder to be licensed in accordance with California law. However, at the time the contract is awarded, the contractor shall be properly licensed. The Undersigned bidder hereby represents as follows: 1.That no Council member, officer agent, or employee of the City of Carlsbad is personally interested, directly or indirectly, in this Contract, or the compensation to be paid hereunder; that no representation, oral or in writing, of the City Council, its officers, agents, or employees has inducted him/her to enter into this Contract, excepting only those contained in this form of Contract and the papers made a part hereof by its terms; and 2.That this bid is made without connection with any person, firm, or corporation making a bid for the same work, and is in all respects fair and without collusion or fraud. 411-11,2 t 4 Revised 6/12/18 Contract No 6335 Page 17 of 176 Accompanying this proposal is a bid bond (Cash, Certified Check, Bond or Cashier's Check) for ten percent (10%) of the amount bid. The Undersigned is aware of the provisions of section 3700 of the Labor Code which requires every employer to be insured against liability for workers' compensation or to undertake self- insurance in accordance with the provisions of that code, and agrees to comply with such provisions before commencing the performance of the work of this Contract and continue to comply until the contract is complete. The Undersigned is aware of the provisions of the Labor Code, Part 7, Chapter 1, Article 2, relative to the general prevailing rate of wages for each craft or type of worker needed to execute the Contract and agrees to comply with its provisions. Or. Revised 6/12/18 Contract No. 6335 Page 18 of 176 IF A SOLE OWNER OR SOLE CONTRACTOR SIGN HERE: (1)Name under which business is conducted Blue P cific En ineering & C n Vuction (2)Signature (given and surname) of proprietor (3)Place of Business 7330 Opportunity Road, Suite A City and State San Diego, CA (Street and Number) (4)Zip Code 92111 Telephone No. 858-956-1456 (5)E-Mail selihu@bluepacificeng.com IF A PARTNERSHIP, SIGN HERE: (1)Name under which business is conducted (2)Signature (given and surname and character of partner) (Note: Signature must be made by a general partner) (3)Place of Business (Street and Number) City and State (4)Zip Code Telephone No. (5)E-Mail 403fr t Ur- Revised 6/12/18 Contract No. 6335 Page 19 of 176 RICHARD WILLIAM EGAN comm. # 2305457 re NOTARY PUBLIC•CALIFORNIA 9 SAN DIEGO COUNTY My Comm. Exp. September 20,2034 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of San Diego On 02/18/2021 before me, Date Richard William Egan, Notary Public Here Insert Name and Title of the Officer personally appeared Shahram Elihu Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(e) whose name(s) is/arc subscribed to the within instrument and acknowledged to me that he/shc/thcy executed the same in his/hcr/thcir authorized capacity(ies), and that by his/hcr/thcir signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature 7 / -7? ignature of Notary Pu lic Place Notary Seal and/or Stamp Above OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: 02/18/2021 Signer(s) Other Than Named Above: Number of Pages: Capacity(ies) Claimed by Signer(s) Signer's Name: Shahram Elihu Ll Corporate Officer — Title(s): 0 Partner — LI Limited E General 0 Individual 0 Attorney in Fact 0 Trustee 0 Guardian or Conservator li Other: Sole Proprietor/Sole Owner of Blue Pacific Signer Is Representing: Signer's Name: Li Corporate Officer — Title(s): El Partner — 111 Limited CI General El Individual El Attorney in Fact CI Trustee Li Guardian or Conservator LI Other: Signer Is Representing: IF A CORPORATION, SIGN HERE: (1) Name under which business is conducted (2) (Signature) (Title) Impress Corporate Seal here (3)Incorporated under the laws of the State of (4)Place of Business (Street and Number) City and State (5)Zip Code Telephone No. (6)E-Mail NOTARIAL ACKNOWLEDGMENT OF EXECUTION BY ALL SIGNATORIES MUST BE ATTACHED List below names of president, vice president, secretary and assistant secretary, if a corporation; if a partnership, list names of all general partners, and managing partners: ink fr Revised 6/12/18 Contract No. 6335 Page 20 of 176 BID SECURITY FORM (Check to Accompany Bid) TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6336 (NOTE: The following form shall be used if check accompanies bid.) Accompanying this proposal is a *Certified *Cashiers check payable to the order of CITY OF CARLSBAD, in the sum of dollars ($ ), this amount being ten percent (10%) of the total amount of the bid. The proceeds of this check shall become the property of the City provided this proposal shall be accepted by the City through action of its legally constituted contracting authorities and the undersigned shall fail to execute a contract and furnish the required Performance, Warranty and Payment Bonds and proof of insurance coverage within the stipulated time; otherwise, the check shall be returned to the undersigned. The proceeds of this check shall also become the property of the City if the undersigned shall withdraw his or her bid within the period of fifteen (15) days after the date set for the opening thereof, unless otherwise required by law, and notwithstanding the award of the contract to another bidder. BIDDER *Delete the inapplicable word. (NOTE: If the Bidder desires to use a bond instead of check, the Bid Bond form on the following pages shall be executed--the sum of this bond shall be not less than ten percent (10%) of the total amount of the bid.) 41. t Ur- Revised 6/12/18 Contract No. 6336 Page 21 of 176 (SEAL) THE OHIO CASUALTY INSURANCE COMPANY (SEAL) (Surety By: By: (Signature) 414ANAA rtf c.:AA V, V.INER., MARK D. IATAROLA, ATTORNEY-1N-FACT (Print Name/Title) (Print Name/Title) BIDDER'S BOND TO ACCOMPANY PROPOSAL TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 KNOW ALL PERSONS BY THESE PRESENTS: That we, BLUE PACIFIC ENGINEERING & CONSTRUCTION , as Principal, and THE OHIO CASUALTY INSURANCE COMPANY, as Surety are held and firmly bound unto the City of Carlsbad, California, in an amount as follows: (must be at least ten percent (10%) of the bid amount) TEN PERCENT OF GREATER AMOUNT BID (10%) for which payment, well and truly made, we bind ourselves, our heirs, executors and administrators, successors or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH that if the proposal of the above-bounden Principal for: TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 in the City of Carlsbad, is accepted by the City Council, and if the Principal shall duly enter into and execute a Contract including required bonds and insurance policies within twenty (20) days from the date of award of Contract by the City Council of the City of Carlsbad, being duly notified of said award, then this obligation shall become null and void; otherwise, it shall be and remain in full force and effect, and the amount specified herein shall be forfeited to the said City. In the event Principal executed this bond as an individual, it is agreed that the death of Principal shall not exonerate the Surety from its obligations under this bond. SIGNED AND SEALED, this 11TH day of FEBRUARY , 20 21 (SEAL AND NOTARIAL ACKNOWLEDGEMENT OF SURETY — ATTACH ATTORNEY-IN-FACT CERTIFICATE) APPROVED AS TO FORM: CELIA A. B EWER City Attorney By: Assistant City Attorney tat —1- Revised 6/12/18 Contract No 6335 Page 22 of 176 OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: MARK D. IATAROLA Corporate Officer — Title(s): O Partner — 0 Limited 0 General •Individual i Attorney in Fact O Trustee 0 Guardian of Conservator O Other: Signer is Representing: Signer's Name: 0 Corporate Officer — Title(s): O Partner — 0 Limited 0 General O Individual 0 Attorney in Fact O Trustee 0 Guardian of Conservator O Other: Signer is Representing: Number of Pages: CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of SAN DIEGO On 2/11/2021 before me, TRACY LYNN RODRIGUEZ, NOTARY PUBLIC , Date Here Insert Name and Title of the Officer personally appeared MARK D. IATAROLA Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s)istsFe-subscribed to the within instrument and acknowledged to me that he/heft-hey executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. — TRACY LYNN RODRIGUE4 COMM. # 2318838 SAN DIEGO COUNTY )14 NOTARY PUBLIC-CALIFORNIAZ MY COMMISSION EXPIRESS ANUARY 11, 2024 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature Place Notary Seal and/or Stamp Above Si Public ©2017 National Notary Association COMMONWEALTH OF PENNSYLVANIA Notarial Seal Teresa Pasleile, Notary Public Upper MerionTwp., Montgomery County My Commission Expires March 28,2021 This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated. Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company Liberty Mutual. SURETY Certificate No: 8204105-024100 POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Men Maloney; Jessica Schmal; John G. Maloney; Mark D. Iatarola; Sandra Figueroa; Tracy Lynn Rodriguez all of the city of Escondido state of CA each individually if there be more than one named, its true and lawful attorney-in-fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 7th day of August , 2020 . Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company By: David M. Carey, Assistant Secretary State of PENNSYLVANIA County of MONTGOMERY ss On this 7th day of August , 2020 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written. It. PAZ\ ae-.16) Teresa Pastella, Notary Public r4Py Member, Pennsylvania AssOdallOn Of Nolaries This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: ARTICLE IV - OFFICERS: Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys-in-fact, subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney-in-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE XIII - Execution of Contracts: Section 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings bonds, recognizances and other surety obligations. Such attorneys-in-fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation - The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys-in- fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization - By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certi5/ that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 11111 day of FEBRUARY , 2021 . By: OF By: Renee C. Llewellyn, Assistant Secretary LMS-12873 LMIC OCIC WAIC Multi Co_12/19 GUIDE FOR COMPLETING THE "DESIGNATION OF SUBCONTRACTORS" FORM REFERENCES Prior to preparation of the following "Subcontractor Disclosure Form" Bidders are urged to review the definitions in section 1-2 of the General Provisions to this Contract, especially, "Bid", "Bidder", "Contract", "Contractor", "Contract Price", "Contract Unit Price", "Engineer", "Own Organization", "Subcontractor", and "Work". Bidders are further urged to review sections 2-3 SUBCONTRACTS of the General Provisions. CAUTIONS This form will be used by the Agency to determine the percentage of work that the Bidder proposes to perform. Bidders are cautioned that failure to provide complete and correct information may result in rejection of the bid as non-responsive. Any bid that proposes performance of more than 50 percent of the work by subcontractors or otherwise to be performed by forces other than the Bidder's own organization will be rejected as non-responsive. Specialty items of work that may be so designated by the Engineer on the "Contractor's Proposal" are not included in computing the percentage of work proposed to be performed by the Bidder. INSTRUCTIONS The Bidder shall set forth the name and location of business of each and every subcontractor whom the Bidder proposes to perform work or labor or render service in or about the work or improvement, and every subcontractor licensed as a contractor by the State of California whom the Bidder proposes to specially fabricate and install any portion of the work or improvement according to detailed drawings contained in the plans and specifications in excess of one-half of one percent (0.5%) of the Bidder's total bid or, in the case of bids or offers for the construction of streets and highways, including bridges, in excess of one-half of one percent (0.5%) or ten thousand dollars ($10,000) whichever is greater. Said name(s) and location(s) of business of subcontractor(s) shall be set forth and included as an integral part of the bid offer. The Designation of Subcontractors form must be submitted as a part of the Bidder's sealed bid. Failure to provide complete and correct information may result in rejection of the bid as non- responsive. Suppliers of materials from sources outside the limits of work are not subcontractors. The value of materials and transport of materials from sources outside the limits of work, as shown on the plans, shall be assigned to the Contractor or the Subcontractor as the case may be, that the Bidder proposes as installer of said materials. The value of material incorporated in any Subcontractor-installed bid item that is supplied by the Bidder shall be included as a part of the work that the Bidder proposes to be performed by the Subcontractor installing said item. When a Subcontractor has a Carlsbad business license, the number must be entered on the proper form. If the Subcontractor does not have a valid business license, enter "NONE" in the appropriate space. When the Bidder proposes using a Subcontractor to construct or install less than 100 percent of a bid item, the Bidder shall attach an explanation sheet to the Designation of Subcontractor form. The explanation sheet shall clearly apprise the City of the specific facts that show the Bidder proposes to perform no less than fifty percent (50%) of the work with its own forces. Determination of the subcontract amounts for purposes of award of the contract shall be determined by the City Council in conformance with the provisions of the contract documents and the various supplemental provisions. The decision of the City Council shall be final. 4111frt ta —1- Revised 6/12/18 Contract No. 6335 Page 23 of 176 Contractor is prohibited from performing any work on this project with a subcontractor who is ineligible to perform work on a public works project pursuant to Labor Code Sections 1771.1 or 1777.7. Bidders shall make any additional copies of the disclosure forms as may be necessary to provide the required information. The page number and total number of additional form pages shall be entered in the location provided on each type of form so duplicated. IM n r- t i al — Revised 6/12/18 Contract No. 6335 Page 24 of 176 DESIGNATION OF SUBCONTRACTOR AND AMOUNT OF SUBCONTRACTOR'S BID ITEMS (To Accompany Proposal) TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 The Bidder certifies that it has used the sub-bid of the following listed subcontractors in preparing this bid for the Work and that the listed subcontractors will be used to perform the portions of the Work as designated in this list in accordance with applicable provisions of the specifications and section 4100 et seq. of the Public Contract Code, "Subletting and Subcontracting Fair Practices Act." The Bidder further certifies that no additional subcontractor will be allowed to perform any portion of the Work in excess of one-half of one percent (0.5%) of the Bidder's total bid, or in the case of bids or offers for construction of streets and highways, including bridges, in excess of one-half of one percent (0.5%) or ten thousand dollars ($10,000), whichever is greater, and that no changes in the subcontractors listed work will be made except upon the prior approval of the Agency. SUBCONTRACTOR'S BID ITEMS Portion of Work Subcontractor Name and Location of Business Phone No. and Email Address DIR Registration No. Subcontractor's License No. and Classification Amount of Work by Subcontract or in Dollars* Bid Item 14 Statewide Stripes 858-560-6887 1000001334 788286 8,515.00 Striping 7320 Mission Gorge Road sean@ C-32,C-33,D38,D42 San Diego, CA, 92120 statewide stripes.com 1 1 Page of pages of this Subcontractor Designation form " Pursuant to section 4104 (a)(3)(A) California Public Contract Code, receipt of the information preceded by an asterisk may be submitted by the Bidder up to 24 hours after the deadline for submitting bids contained in the "Notice Inviting Bids." to: Revised 6/12/18 Contract No. 6335 Page 25 of 176 Date Contract Completed Name and Address ..of the Employer ame. aeKI.Phon0. Q. Of Person to. Contract mount of Contract Type of Work SEE ATTACHED BIDDER'S STATEMENT OF TECHNICAL ABILITY AND EXPERIENCE (To Accompany Proposal) TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 The Bidder is required to state what work of a similar character to that included in the proposed Contract he/she has successfully performed and give references, with telephone numbers, which will enable the City to judge his/her responsibility, experience and skill. An attachment can be used. —1- Revised 6/12/18 Contract No. 6335 Page 26 of 176 BLUE PACIFIC ENGINEERING & CONSTRUCTION CURRENT AND COMPLETED PROJECTS IN THE LAST 5 YEARS PROJECT NAME DESCRIPTION OF WORK OWNER/CONTACT INFO AMOUNT START END Parkside Sewer Pump Station City of Chula Vista Upgrade controls, pumps, SCADA and install site improvements to sewer pump station Daniel Deets CM 858-634-8180 PPC danielAppc-sd.corn 1,345,770.00 416120 9/25/2020 Del Mar Bluffs Reconstruction SANDAG Construction of CIDH pile support for 3 existing sea walls, slope stabillization, drainage channels and access path Irfan Kalhoro, CM 949-422-8304 AECOM irfan.kalhoro@aecom.com 2,738,800.00 3/2712C 8/21/2020 Sewer Access Road City of Chula Vista Clear and grubbing, grading, compaction install base and pavement Mike Schedine RE 619-397-6119 City of Chula Vista MSchedineAci.chula-vista.ca.us 192,089.00 5/11/20 8/21/2020 Martinccit Road Sewer Upsize City of Poway Upsizing of existing sewer mains along Martincoit Rd. and within an existing easement along creek bank Brian Banzuelo, PE (858) 668-4623 City of Poway bbanzueloRpoway.org 2,414,880.00 5/22/20 8/21/2020 SR94 Euclid Interchange Paving, ADA ramps K-17-1581-DBB-3 Install Drainage, Landscaping, Irrigation Modify Traffic Signals, Sidewalk, Pedestrian Barricades, Paving ADA ramps and Striping City of San Diego Ricardo Sanchez (619) 980-6310 RSanchez@sandiego.gov 0 Chris Naval, PE (619) 980-7748 CNaval@sandiego.gov 3,739,993.00 5/29/18 6/26/20 Carlsbad City Hall Exterior Safety Accessibility Improvements Upgrades for ADA compliance,Parking Lot Shade Structures, Storm Drain, Slope Repair Landscaping and Hardscape Improvements Robert Liles, CM 760-672-2101 SchneiderCM, Inc. robert.)ilesASchneiderCM.net 1,911,565 7/9/20':9 6/19/2020 South Coast Highway 101 City of Encinitas Repair asphalt, install wheel stops, delineators, guardrail, ADA improvements, signage and striping John Gentry CM 619-433-2514 TRCcompanies.com igentry@trccompanies.com 653,400.00 2/24/20 5/29/2020 Villa La ,;olla MTS Bus Stop City of San Diego - MTS Install sidewalk, driveways, ADA ramps, curb and gutter, landscaping and traffic signal modifications Ivan Torres RE 619-862-3150 City of San Diego ITorresAsandiego.gov 227,430.00 2/24/20 5/15/2020 Pavement Rehabilitation and Roadway Sealing FY 2018-2019 (CS19A) Dig Outs, Asphalt, RPMS, Striping, Guardrail Sidewalk, Curb & Gutter City of Encinitas Pete Milligan (760) 633-2775 PMilligan@encinitasca,gov (760) 522-2535 Shawn Stewart CM SStewart@kleinfelder.com 843,402.71 11/28/18 6/1119 Track ADA Improvements at Grossmont College B19.006 Concrete Ped Ramps, Retaining Wall AC Paving, Storm Water Drainage, irrigation system and planting Grossmont-Cuyamaca Community College District Gaby Arana (619) 817-9287 GArana@gafcon.com 978,123.00 5/11/19 101';8/19 Big Trees - Purchase and Install Install Trees at Various Parks in San Diego County County of San Diego Dario Lombardo 858-966-1334 Dariolombardo@sdcounty.ca.gov 577,500.00 10/22/18 5124/19 DMP Phase 1 & 2 Cycle Track Street Improvements Paving, Striping and Signage City of San Diego Natalia Torres (619) 527-8044 TorresN@sandiego.gov 2,011,719.53 10/30/18 1/11119 LID Landscape at Chet Harrit Install drought tollerant landscaping and irrigation system Santee School District Nancy Stasch (619) 258-2329 nancy.stasch@santeesd.net 48,500.00 7/24/18 8/23/18 LID Landscape at Carlton Oaks Install drought tolerant landscaping and irrigation system Santee School District Nancy Stasch (619) 258-2329 nancy.stasch@santeesd.net 33,400,00 7/24/18 8123/18 LID Landscape at Cajon Park Install Biofiltration detention basin, drought tolerant landscaping and irrigation system Santee School District Nancy Stasch (619) 258-2329 nancy.stasch@santeesd.net 26,625.00 7/24/18 8/23/18 LID Landscape at Pride Academy Install drought tolerant landscaping and irrigation system Santee School District Nancy Stasch (619) 258-2329 nancy.stasch@santeesd.net 12760.00 7/24118 8123/18 PROJECT NAME DESCRIPTION OF WORK OWNER/CONTACT INFO AMOUNT START END Interior Courtyard Landscape at Knox Middle School Install plants with drip irrigation system and DG walking paths San Diego Unified School District Jerry Ricks 619-843-2973 81,750.00 13/25/18 12/14118 ADA Barrier Removal Remove old hardscape and install new ADA compliant access City of Poway Christine Pawlik 858-668-4605 CPawlik@poway,org 110,175.00 10/29/18 11/9/18 North Santa Fe Storm Drain Repair Install Type 5 Cleanout, Type B Curb Inlet 18", 24" and 36" RCP, Stamped Concrete City of Oceanside Darra Woods, PM 760-435-5094 DLWoods@ci.oceanside.caus 192,000.00 r 8/13118 11/2/18 LRC Sidewalk Connector Install Concrete, Street Light, Curb and Gutter Paving and Striping Palomar Community college Diane Malone, PM 760.798.1607 dmalone@galcon.com 164,160.00 8/13/18 10/5/18 Canyon Crest Landscaping Install lighted DG path through sculpture garden and surrounding landscaping SDURSD Caroline Roberts 760-753-6491 x5624 caroline.roberts@sduhsd.net 164,000.00 6/15/18 9/27/18 LID Landscape at Pepper Install drought tolerant landscaping and irrigation system Santee School District Nancy Stasch 619-258-2329 nancy.stasch@santeesd.riet 28,730.00 61'.4118 7/27118 :ID Landscape at Rio Seco Install drought tolerant landscaping and irrigation system Santee School District Nancy Stasch 619-258-2329 nancy.stasch@santeesd.net 31,500.00 6118/18 7/27/18 Five Points Neighborhood Pad. Impr. L-16-1391-DBB-2 Install Traffic Signal Modifications, Pushbuttons Polara Voice Crossing, Sidewalk and Striping City of San Diego RE Ricardo Sanchez 619-980-6310 RicSanchezesandiego.gov 369,698.00 911/16 11/18/18 South Mission Valley Trunk Sewer Excavate and Replace Sewer Pipe Excavate and Replace Sewer Pipe City of San Diego Justin Garcia 619-990-3979 GarciaJM@sandiego.gov '`,013,093.00 10/1 8/16 6/27/18 Airports JOC Asphalt, Concrete, Interior Renovations Painting, Signage City of San Diego Rodel Riego (858) 573-1434 RDRiego@sandiego.gov 500,000.00 1/1/18 12131/18 Alvarado Channel Landscaping Slope stabilization with turf mat and anchors landscaping and irrigation City of La Mesa Jeff Mancheste:. 619-667-1152 imanchester@ci.la-mesa.ca.us 525,848.09 8/17/16 8110117 Mt Miguel Install landscaping and irrigation Grossmont Unified High School District Alicia Lutc'nansky 760.690,6710 alutchansky@ericksonhall.com 269,295.00 10/20/17 10119/18 CV Raised Median Install median, delineators and striping City of Chula Vista Joselito Castillo PE 619.397.6081 joselitoc@chulavistaca.gov 226,621.11 4/16/18 7/25/18 Powers Road Install Sidewalk, Driveways, Curb and Gutter City of Poway Brian Banzuelo 858-668-4623 bbanzuelo@poway.org 137,218.00 6/5/18 8115118 Canyonside Recycled WPS Drain Waterline, Water Pump Station Drain ADA parking, RPMS, Striping City of San Diego Joseph Ecclesine (619) 520-8773 JI-.-...cclesine@sandiego.govt 407,105.00 12/6/17 10/3/18 Ocean St Beach Access PWS18-33 P KS Install Stain.vays, Railings, Bioilltration Sys. Signs, Boulders, Irrigation and Landscaping City of Carlsbad Robert Liles 760-672-2101 robert.liles@SchneiderCM.net 3,303,559.29 2/5118 12/26/18 Elle:y Reservoir Landscaping Irrigation System and Planting at Ellery Reservoir Tower Foundations Stanley Stanton 406-842-7260 depotstan@gmail.com 25,800.00 5/9/18 10123/18 Tecoiote Canyon K/i6-1363-DBB-3 Clear and grub, Excavate and Backlit], U Type Headwalls, Bridge Pier Demolition, Shoring, Install 8in Sewer main, Install Bridge, 2 manholes, Archeological and Native American Monitoring City of San Diego Loretta Graham (619) 889-3076 LLGraham@sandiego.gov 518,000.00 1/30/17 9112/17 PROJECT NAME DESCRIPTION OF WORK OWNER/CONTACT INFO AMOUNT START END Safe Route to School Install Sidewalk, Driveways, Curb and Gutter Silva Cells and Tree Grates City of La Mesa Michael Kinnard 619-667-1155 mkinnard@cila-mesa.ca.us 648,519.96 817/18 6/28/18 Copley Park Curb and Gutter Asphalt, Concrete, Crack Repair MIS Elias Belknap (619) 557-4566 Elias.Belknap@sdmts.com 87,300.00 1/8118 2/13118 Paul Ec".<e Central Improvements: CS16D Install Sidewalk, Driveways, Curb and Gutter Storm drain, masonry block wail City of Encinitas Matt Widelski (760) 633-2862 mwielski§encinitasca.gov] 348,376.00 7120116 9113116 La Costa Canyon High School Learning Commons Landscape Project Install Landscaping and Irrigation San Dieguito Union High School District, 684 Requeza Street, Encinitas, CA 92024 Rosella Arca rosella.arce§sduhscl.net (760) 118,000.00 C 811/17 12112117 Creekside Marketplace Install landscaping and irrigation IDS Real Estate and City of San Marcos Christopher Maurer 310-433-8337tmaurer@idsrealestate.comll 224900.00 8/7/17 1/31/18 Bicentennial Triangle Install Concrete Mosaic, Custom Benches Lighting, Landscaping and Irrigation City of Imperial Beach Juan Larios 619-423-8311 flarios§imperialbeachca.gov 322,630.00 7/30118 10119/18 Industrial Blvd Sewer ClP S‘A/292 Install Sewer lines and Manholes City of Chula Vista - Mike Schedine 619-397-6119 MSchedine@ci.chula-vista.ca.us 394,799.00 1015117 12/5117 Trail for All People L-16-1240-DBB-1 DG path, Shade Structures, native Planting with biological monitoring required City of San Diego Nick D'Amico 858-627-3283 NDAmico@sandiego.gov 238,500.00 10/26115 5/27116 N Harbor Dr Pedestrian Access Improvements K-16-1298-DBB-3 Install Asphalt, Curb and Gutter, pushbuttons Signal Modification and Striping City of San Diego Jared Skinner 858-495-4710 JSkinner§sandiego.gov 598,570.00 2/16/16 5/15/16 Richland Elementary CIP 88520 Sidewalk, Asphalt, Striping, Electrical City of San Marcos Perryn White 619-850-3851 PWhite§san-marcos.net 707,000.00 7/27115 4122116 CMP Replacement La Gran Via 6607 Type B Cleanout and 24" Storm Drain City of Carlsbad (Sherri Howard) CM Marius Jaskula 760-744-4578 mjaskula§dudek.com 95,110.00 12/28/15 414116 Lake Poway Parking Expansion Install Performance Stage and Landscaping City of Poway Jeff Beers 858-668-4624 JBeers@poway.org 152:955.00 11/16/15 3/21/16 Sunset Cliffs Park L-15-5667-DBB-1-A Demo, Grading, Planting & Irrigation City of San Diego Samuel Portillo 619-379-9117 SPortillo§sandiego.gov 246,777.00 9/21/15 3118116 North Sidewalk Santa Fe Dr. Sidewalk, Asphalt, Striping, Electrical City of Encinitas Stephanie Kellar 760-633- 2839 Skellar§encinitasca.gov 550,646.02 2/11/15 3115/16 Repair, Replacement and Construction of Concrete Curbs, Gutter, Sidewalks, Countywide Oracle Prob No. 1018524 Install Concrete Countywide County of San Diego Hashem El-Bahsh 619-306-8151 HashemEl-bahsh@sandiegocounty.ca.gov 226,970.00 10/22/14 3/6/15 Maryland Avenue Improvements 13-19 Sidewalk, Asphalt, Striping, Electrical City of La Mesa Kathy Feilen 619-667-1347 kfeilen§ci.la-mesa.ca.us 503,000.00 7115/15 2/23/16 Bayshore Bikeway Segment 4 Pavement, PCC, Dike, Inlet, Guard Rail SANDAG Solomon Choi (619) 458-4428 SolomonChoi@caltrop.com 1,136,000.00 9/29/14 7/15/15 Annual Main Line Repairs W12-202 Micro tunneling Micro tunneling Repairs to Sewer City of Imperial Beach Peter Lau 619-628-1371 PLau@imperialbeachca.gov 726,000.00 6/30/14 1019/15 Drought Tolerant Landscaping Landscaping, Irrigation, Planting Grossmont-Cuyamaca Community College District Don Kramer 619-644-7055 dkramer§gatcon.com 428,000.00 211/14 8/26/15 King Street Drainage Improvements Retaining Wall, AC, Atrium Drains City of La Mesa Don Laslo 619-667-1151 DLaslo@ci.la-mesa.ca.us 299,266.00 9/22114 6/18/15 PROJECT NAME DESCRIPTION OF WORK OWNER/CONTACT INFO AMOUNT START END Sewer Rehab Project FY 11/12 Trench, Remove and Replace Sewer City of Chula Vista - Mike Schedine 619-397-6119 MSchedine@ci.chula-vista.ca.us 410,350.00 113/14 5114/15 Del Mar Shores Beach Access Concrete stairs, railing, install drainage and timbers on slope City of Solana Beach Dan Goldberg 858-720-2474 dgoldberg@cosb.org_ 1,218,000.00 2/14/14 1/12/15 Rattlesnake Creek Streambank Stabilization Landscaping, Irrigation, Planting City of Poway Melody Rocco 858-668-4653 MRocco@poway.org 298,932.09 11/20113 9/19114 Montiel Park Enhancement Stone Walls, Fencing, Landscaping City of San Marcos Perryn White 760-744-1050 P/Vhite@san-marcos.net 436,900.00 11110/13 4128/14 Fuerte Drive Slope Repairs RFB 6097 Slope repair with steel pilings, timbers and concrete installation on a limited access street on Mount Helix County of San Diego Adofo Cacho 619-306-8165 Adolfo.Cacho@sdcounty.ca.gov 400,127.00 11/9/13 414/14 Furnish & Install Concrete Stairs at Marshall Middle School Install Concrete Stairs and Railing San Diego Unified School District Juan Gonzalez 619-665-7358 JGonzalez32@sancii.net 55,460.35 3/28113 3/31/14 BIDDER'S CERTIFICATE OF INSURANCE FOR GENERAL LIABILITY, EMPLOYERS' LIABILITY, AUTOMOTIVE LIABILITY AND WORKERS' COMPENSATION (To Accompany Proposal) TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 As a required part of the Bidder's proposal the Bidder must attach either of the following to this page. 1)Certificates of insurance showing conformance with the requirements herein for each of: El Comprehensive General Liability Li Automobile Liability LII Workers Compensation El Employer's Liability 2)Statement with an insurance carrier's notarized signature stating that the carrier can, and upon payment of fees and/or premiums by the Bidder, will issue to the Bidder Policies of insurance for Comprehensive General Liability, Automobile Liability, Workers Compensation and Employer's Liability in conformance with the requirements herein and Certificates of insurance to the Agency showing conformance with the requirements herein. All certificates of insurance and statements of willingness to issue insurance for auto policies offered to meet the specification of this contract must: 1)Meet the conditions stated in The Notice Inviting Bids and the General Provisions for this project for each insurance company that the Contractor proposes. 2)Cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. SEE ATTACHED 4PIlk tr. —1- Revised 6/12/18 Contract No. 6335 Page 27 of 176 City of Carlsbad/CMWD 1200 Carlsbad Village Drive Carlsbad, CA 92008 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE Caleaax„ SHAHELI-01 ACALDWELL "ACCPREY CERTIFICATE OF LIABILITY INSURANCE DATE (MMIDD1YYYY) 412712021 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Teague Insurance Agency, Inc. 1100 Spring St., #400 La Mesa, CA 91942-0275 INSURED Shahram Elihu DBA: Blue Pacific Engineering Construction 3545 Camino Del Rio So, Suite A San Diego, CA 92108 CONTACT NAME: PHONE (A/C, No, Ext): (619) 464-6851 E-MAIL info@teagueins.com ADDREss: INSURER(S) AFFORDING COVERAGE NAIC # INSURER A : James River Insurance Company 12203 INSURER B : California Automobile Insurance Com an 38342 INSURER C :Scottsdale Insurance Co. 41297 INSURER D : Redwood Fire & Casualty 11673 INSURER E : Westchester Surplus Lines Insurance Company 10172 INSURER F: (NC, No(619) 668-4715 COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTVVITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR I/VVD POLICY EFF POLICY EXP POLICY NUMBER IMM/DDNYYY1 (MM/DIWYYY1 LIMITS A x COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE X OCCUR X x 000734304 8/2012020 8/20/2021 PlaCc(Eir occurrence)' $ 50,000 MED EXP (Any one person) 1,000 $ PERSONAL & ADV INJURY 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE 2,000,000 S —7 POLICY Ix] JPERa- p LOC PRODUCTS - COMP/OP AGG S 2,000,000 OTHER: $ B AUTOMOBILE LIABIUTY COMBINED SINGLE LIMIT (Ea accident) 1,000,000 $ — ANY AUTO X x BA040000044356 4/20/2021 4/20/2022 BODILY INJURY no person) $ ___ OWNED AUTOS ONLY y " SCHEDULED AUTOS BODILY INJURY (Ear accident), $ V ,, AUTOS ONLY X I;L'ElPer0' NI B 1..1,11? W ein t DAMAGE $ S UMBRELLA LIAB X OCCUR EACH OCCURRENCE S 5,000,000 X EXCESS LIAB CLAIMS-MADE X X XLS0114429 8/20/2020 8/20/2021 AGGREGATE $ 5,000,000 DED X RETENTIONS 0 D WORKERS COMPENSATION AND EMPLOYERS' LIABILITY y PER I 0TH- A" STATUTE I ER YI N ANY PROPRIETOR/PARTNER/EXECUTIVE 1--1 X SHWC245587 3/1/2021 3/1/2022 E.L. EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? NIA (Mandatory in NH) I— EL DISEASE - EA EMPLOYEE S 1,000,000 If yes, describe under DESCRIPTION OF OPERATIONS below El. DISEASE - POLICY LIMIT 1,000,000 S E Pollution Liability G284Q637A001 I 9/7/2020 I 9/7/2021 Ea Occurrence/Agg 2,000,000 DESCRIPTION OF OPERATIONS! LOCATIONS / VEHICLES (ACORD 101, Addftional Remarks Schedule, may be attached if more space is required) RE: ALL PROJECTS The City of Carlsbad, its officals, employees and volunteers are included when required by written contract/agreement as additional insured for ongoing and completed operations with primary non-contributory and waiver of subrogation with per project aggregate language with respects to the general liability and additional insured with primary non-contributory and waiver of subrogation with respects to the auto liability and waiver of subrogation with respects to the workers compensation, excess liability follows all primary policies per forms attached. CERTIFICATE HOLDER CANCELLATION ACORD 26 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD POLICY NUMBER: 000734304 COMMERCIAL GENERAL LIABILITY CG 20 10 07 04 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s): Location(s) Of Covered Operations Where required by written contract or written agreement. All operations of the Named Insureds. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II — Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: 1.Your acts or omissions; or 2.The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured(s) at the location(s) desig- nated above. B. With respect to the insurance afforded to these additional insureds, the following additional exclu- sions apply: This insurance does not apply to "bodily injury" or "property damage" occurring after: 1.All work, including materials, parts or equip- ment furnished in connection with such work, on the project (other than service, mainte- nance or repairs) to be performed by or on be- half of the additional insured(s) at the location of the covered operations has been completed; or 2.That portion of "your work" out of which the injury or damage arises has been put to its in- tended use by any person or organization other than another contractor or subcontractor en- gaged in performing operations for a principal as a part of the same project. CG 20 10 07 04 © ISO Properties, Inc., 2004 Page 1 of 1 0 POLICY NUMBER: 000734304 COMMERCIAL GENERAL LIABILITY CG 20 37 07 04 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s): Location And Description Of Completed Opera- lions Where required by written contract or written agreement. All operations of the Named Insureds. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. Section II — Who Is An Insured is amended to include as an additional insured the person(s) or organiza- tion(s) shown in the Schedule, but only with respect to liability for "bodily injury" or "property damage" caused, in whole or in part, by "your work" at the location des- ignated and described in the schedule of this endorse- ment performed for that additional insured and includ- ed in the "products-completed operations hazard". CG 20 37 07 04 @ ISO Properties, Inc., 2004 Page 1 of 1 13 Policy Number: 000734304 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. PRIMARY AND NON CONTRIBUTORY ENDORSEMENT This endorsement modifies insurance provided under the following: ALL COVERAGE PARTS Name Of Additional Insured Person(s) Or Organization(s): Where required by written contract or written agreement If no entry appears above, this endorsement applies to all Additional Insureds covered under this policy. Any coverage provided to an Additional Insured under this policy shall be excess over any other valid and collectible insurance available to such Additional Insured whether primary, excess, contingent or on any other basis unless a written contract or written agreement specifically requires that this insurance apply on a primary and noncontributory basis. ALL OTHER TERMS AND CONDITIONS OF THE POLICY REMAIN UNCHANGED. AP5031US 04-10 Page 1 of 1 POLICY NUMBER: 000734304 COMMERCIAL GENERAL LIABILITY CG 24 04 05 09 WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Person Or Organization: Where required by written contract or written agreement. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV — Conditions: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products- completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. CG 24 04 05 09 @ Insurance Services Office, Inc., 2008 Page 1 of 1 0 Policy Number: 000734304 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. POLICY LIMITATION - AMENDED AGGREGATE LIMITS OF INSURANCE PER PROJECT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART CONTRACTORS COMBINED LIABILITY POLICY SECTION III — LIMITS OF INSURANCE - The General Aggregate Limit applies separately to each "Project" of the Named Insured. Notwithstanding the application of the General Aggregate Limit to each "Project" of the Named Insured, under no circumstances will we pay more than $5,000,000 for all claims under this policy that are subject to the General Aggregate limit. For the purpose of this endorsement, the following definition is added: "Project" means all work done by you or on your behalf, away from premises owned or rented to you, to complete an individual bid or negotiated contract to provide services for a specified period of time. Multiple jobs, work orders, purchase orders, or work done at multiple "locations" under one contract are not separate "projects" within the meaning of this coverage. ALL OTHER TERMS AND CONDITIONS OF THE POLICY REMAIN UNCHANGED. AP5012US 12-03 Page 1 of 1 Policy Number: 840400000044356 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Business Auto Broadening Endorsement This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM I. NEWLY ACQUIRED OR FORMED ENTITY (BROAD FORM NAMED INSURED) EMPLOYEES AS INSUREDS AUTOMATIC ADDITIONAL INSURED IV.EMPLOYEE HIRED AUTO LIABILITY V.SUPPLEMENTARY PAYMENTS VI.FELLOW EMPLOYEE COVERAGE VII.ADDITIONAL TRANSPORTATION EXPENSE VIII.HIRED AUTO PHYSICAL DAMAGE COVERAGE IX.ACCIDENTAL AIRBAG DEPLOYMENT COVERAGE X.LOAN/LEASE GAP COVERAGE XI.GLASS REPAIR — DEDUCTIBLE WAIVER XII.TWO OR MORE DEDUCTIBLES XIII.AMENDED DUTIES IN EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS XIV, WAIVER OF SUBROGATION XV.UNINTENTIONAL ERROR, OMISSION, OR FAILURE TO DISCLOSE HAZARDS XVI.EMPLOYEE HIRED AUTO PHYSICAL DAMAGE XVII, PRIMARY AND NONCONTRIBUTORY IF REQUIRED BY CONTRACT XVIII.HIRED AUTO —COVERAGE TERRITORY XIX.BODILY INJURY REDEFINED TO INCLUDE RESULTANT MENTAL ANGUISH Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 1 of 6 BUSINESS AUTO COVERAGE FORM NEWLY ACQUIRED OR FORMED ENTITY (Broad Form Named Insured) SECTION ll - LIABILITY COVERAGE, A. Coverage, 1. Who Is An Insured, the following is added: d.Any business entity newly acquired or formed by you during the policy period provided you own 50% or more of the business entity and the business entity is not separately insured for Business Auto Coverage. Coverage is extended up to a maximum of 180 days following acquisition or formation of the business entity. Coverage under this provision is afforded only until the end of the policy period. Coverage does not apply to an "accident" which occurred before you acquired or formed the organization. EMPLOYEES AS INSUREDS SECTION fl - LIABILITY COVERAGE, A. Coverage, 1. Who Is An Insured, the following is added: e.Any "employee" of yours is an "insured" while using a covered "auto" you don't own, hire or borrow in your business or your personal affairs. AUTOMATIC ADDITIONAL INSURED SECTION II - LIABILITY COVERAGE, A. Coverage, 1. Who Is An Insured, the following is added: f.Any person or organization that you are required to include as additional insured on the Coverage Form in a written contract or agreement that is signed and executed by you before the "bodily injury" or "property damage" occurs and that is in effect during the policy period is an "insured" for Liability Coverage, but only for damages to which this insurance applies and only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured provision contained in Section IV.EMPLOYEE HIRED AUTO LIABILITY SECTION II - LIABILITY COVERAGE, A. Coverage, 1. Who Is An Insured, the following is added: g- An "employee" of yours is an "insured" while operating an "auto" hired or rented under a contract or agreement in that "employee's" name, with your permission, while performing duties related to the conduct of your business. V.SUPPLEMENTARY PAYMENTS SECTION II — LIABILITY COVERAGE, A. Coverage, 2. Coverage Extensions, a. Supplementary Payments, Subparagraphs (2) and (4) are replaced by the following: (2) Up to $3,000 for cost of bail bonds (including bonds for related traffic law violations) required because of an "accident" we cover. We are not obligated to furnish these bonds. (4) All reasonable expenses incurred by the "insured" at our request, including actual loss of earnings up to $500 a day because of time off from work. Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 2 of 6 VI. FELLOW EMPLOYEE COVERAGE: SECTION II — LIABILITY COVERAGE, B. Exclusions, 5. Fellow Employee This exclusion does not apply if you have workers' compensation insurance in-force covering all of your "employees". Coverage is excess over any other collectible insurance. VII. ADDITIONAL TRANSPORTATION EXPENSE SECTION III - PHYSICAL DAMAGE COVERAGE, A. Coverage, 4. Coverage Extensions, a. Transportation Expenses, is replaced with the following: We will pay up to $50 per day to a maximum of $1000 for temporary transportation expense incurred by you because of the total theft of a covered "auto" of the private passenger type. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. We will pay for temporary transportation expenses incurred during the period beginning 48 hours after the theft and ending, regardless of the policy's expiration, when the covered "auto" is returned to use or we pay for its "loss". If your business shown in the Declarations is other than an auto dealership, we will also pay up to $1,000 for reasonable and necessary costs incurred by you to return a stolen covered auto from the place where it is recovered to its usual garaging location. VIII. HIRED AUTO PHYSICAL DAMAGE COVERAGE SECTION III — PHYSICAL DAMAGE COVERAGE, A. Coverage, 4. Coverage Extensions, the following is added: c. If Liability Coverage is provided in this policy on a Symbol 1 or a Symbol 8 basis and Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this coverage form for any "auto" you own, then the Physical Damage Coverages provided are extended to "autos" you hire, subject to the following limit: (1)The most we will pay for "loss" to any hired "auto" is $50,000 or Actual Cash Value or Cost of Repair, whichever is less (2)$500 deductible will apply to any loss under this coverage extension, except that no deductible shall apply to "loss" caused by fire or lightning Subject to the above limit and deductible we will provide coverage equal to the broadest coverage applicable to any covered "auto" you own of similar size and type. This coverage extension is excess coverage over any other collectible insurance. IX. ACCIDENTAL AIRBAG DEPLOYMENT COVERAGE SECTION III - PHYSICAL DAMAGE COVERAGE, B. Exclusions, 3.a., is amended to add the following: This exclusion does not apply to the accidental discharge of an airbag. Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 3 of 6 X. LOAN/LEASE GAP COVERAGE SECTION III - PHYSICAL DAMAGE COVERAGE C. Limit of Insurance, the following is added: 4. In the event of a "total loss" to a covered "auto" shown in the schedule or declarations for which Collision and Comprehensive Coverage apply, we will pay any unpaid amount due on the lease or loan for that covered "auto," less: a.The amount paid under the Physical Damage Coverage Section of the policy; and b.Any: (1)Overdue lease/loan payments at the time of the "loss"; (2)Financial penalties imposed under a lease for excessive use, abnormal wear and tear or high mileage. (3)Security deposits not returned by the lessor; (4)Costs for extended warranties, Credit Life Insurance, Health, Accident or Disability Insurance purchased with the loan or lease; and (5)Carry-over balances from previous loans or leases. The most we will pay under Auto Loan/Lease Gap Coverage for an insured auto is 25% of the actual cash value of that insured auto at the time of the loss. XI. GLASS REPAIR — DEDUCTIBLE WAIVER SECTION III - PHYSICAL DAMAGE COVERAGE, D. Deductible, the following is added: No deductible applies to glass damage if the glass is repaired rather than replaced. XII. TWO OR MORE DEDUCTIBLES SECTION III -PHYSICAL DAMAGE COVERAGE, D. Deductible, the following is added: If two or more "company" policies or coverage forms apply to the same accident: 1.If the applicable Business Auto deductible is the smallest, it will be waived; or 2.If the applicable Business Auto deductible is not the smallest, it will be reduced by the amount of the smallest deductible; or 3.If the loss involves two or more Business Auto coverage forms or policies the smallest deductible will be waived. For the purpose of this endorsement "company" means the company providing this insurance and any of the affiliated members of the Mercury Insurance Group of companies. XIII. AMENDED DUTIES IN EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS The requirement in SECTION IV, BUSINESS AUTO CONDITIONS, A. Loss Conditions, 2. Duties In The Event Of Accident, Claim, Suit, Or Loss, a., In the event of "accident", you must notify us of an "accident" applies only when the "accident" is known to: (1)You, if you are an individual; (2)A partner, if you are a partnership; (3)A member, if you are a limited liability company; or (4)An executive officer or insurance manager, if you are a corporation. Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 4 of 6 XIV. WAIVER OF SUBROGATION SECTION IV - BUSINESS AUTO CONDITIONS, A. Loss Conditions, 5. Transfer of Rights Of Recovery Against Others To Us, section is replaced by the following: 5. Transfer Of Rights Of Recovery Against Others To Us We waive any right of recovery we may have against any person or organization to the extent required of you by a written contract executed prior to any "accident" or "loss", provided that the "accident" or "loss" arises out of the operations contemplated by such contract. The waiver applies only to the person or organization designated in such contract. XV. UNINTENTIONAL ERROR, OMISSION, OR FAILURE TO DISCLOSE HAZARDS SECTION IV - BUSINESS AUTO CONDITIONS, B. General Conditions, 2. Concealment, Misrepresentation, or Fraud, the following is added: Any unintentional omission of or error in information given by you, or unintentional failure to disclose all exposures or hazards existing as of the effective date or at any time during the policy period shall not invalidate or adversely affect the coverage for such exposure or hazard or prejudice your rights under this insurance. However, you must report the undisclosed exposure or hazard to us as soon as reasonably possible after its discovery. This provision does not affect our right to collect additional premium or exercise our right of cancellation or non-renewal. XVI. EMPLOYEE HIRED AUTO PHYSICAL DAMAGE SECTION IV — BUSINESS AUTO CONDITIONS, B. General Conditions, 5. Other Insurance, b. For Hired Auto Physical Damage Coverage, is replaced by the following: b. For Hired Auto Physical Damage Coverage, the following are deemed to be covered "autos" you own: 1.Any covered "auto" you lease, hire, rent or borrow; and 2.Any covered "auto" hired or rented by your "employee" under a contract in that individual "employee's" name, with your permission, while performing duties related to the conduct of your business. However, any "auto" that is leased, hired, rented or borrowed with a driver is not a covered "auto". XVII. PRIMARY AND NONCONTRIBUTORY IF REQUIRED BY CONTRACT SECTION IV—BUSINESS AUTO CONDITIONS, B. General Conditions, 5. Other Insurance, the following is added and supersedes any provision to the contrary: e. This insurance is primary to and will not seek contribution from any other insurance available to an additional insured under your policy provided that: (1)The additional insured is a Named Insured under such other insurance; and (2)You have agreed in writing in a contract or agreement that this insurance would be primary and would not seek contribution from any other insurance available to the additional insured. Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 5 of 6 XVIII. HIRED AUTO - COVERAGE TERRITORY SECTION IV - BUSINESS AUTO CONDITIONS, B. General Conditions, 7. Policy Period, Coverage Territory, e. Anywhere in the world if:, is replaced by the following: e. Anywhere in the world if: (1)A covered "auto" is leased, hired, rented or borrowed without a driver for a period of 30 days or less; and (2)The "insured's" responsibility to pay damages is determined in a "suit" on the merits, in the United States of America, the territories and possessions of the United States of America, Puerto Rico, or Canada or in a settlement we agree to. XIX. BODILY INJURY REDEFINED TO INCLUDE RESULTANT MENTAL ANGUISH SECTION V — DEFINITIONS, C. "Bodily Injury" is amended by adding the following: "Bodily injury" also includes mental anguish but only when the mental anguish arises from other bodily injury, sickness, or disease. Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 6 of 6 WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 99 04 10 C (Ed. 01-19) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT-CALIFORNIA BLANKET BASIS We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) The additional premium for this endorsement shall be calculated by applying a factor of 2% to the total manual premium, with a minimum initial charge of $350, then applying all other pricing factors for the policy to this calculated charge to derive the final cost of this endorsement. This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule Blanket Waiver Person/Organization Blanket Waiver — Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver. Job Description Waiver Premium (prior to adjustments) All CA Operations This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective: 3/1/2021 Policy No.: SHWC245587 Endorsement No.: Insured: Shahram Elihu DBA: Blue Pacific Engineering Construction Premium $ Insurance Company: Countersigned by WC 99 04 10 C (Ed. 01-19) Blue Pacif c Engineering & Co str tion lame f Contract r) , By: BIDDER'S STATEMENT RE DEBARMENT (To Accompany Proposal) TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 1)Have you or any of your subcontractors ever been debarred as an irresponsible bidder by another jurisdiction in the State of California? x no yes 2)If yes, what was/were the name(s) of the agency(ies) and what was/were the period(s) of debarment(s)? Attach additional copies of this page to accommodate more than two debarments. party debarred party debarred agency agency period of debarment period of debarment BY CONTRACTOR: (sign here) Shahram Elihu, Sole Proprietor/Owner (print name/title) Page 1 of 1 pages of this Re Debarment formn 4r-se Revised 6/12/18 Contract No. 6335 Page 28 of 176 RICHARD WILLIAM EGAN1, comm.# 2305457 55 NOTARY PUBLIC•CALIFORNIA 0 SAN DIEGO COUNTY My Comm. Exp. September 20,2023 - Signature Ignature of Notary Public CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of San Diego On 02/18/2021 before me, Date Richard William Egan, Notary Public Here Insert Name and Title of the Officer personally appeared Shahrann Elihu Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/aro subscribed to the within instrument and acknowledged to me that he/shc/thcy executed the same in hisitier-Alffeir authorized capacity(ics), and that by his/hcrithcir signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Place Notary Seal and/or Stamp Above OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: 02/18/2021 Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Shahram Elihu 0 Corporate Officer — Title(s): 0 Partner — 0 Limited 0 General El Individual E Attorney in Fact Li Trustee 0 Guardian or Conservator X Other: Sole Proprietor/Sole Owner of Blue Pacific Signer Is Representing: Number of Pages: Signer's Name: Li Corporate Officer — Title(s): 0 Partner — 0 Limited 0 General 11 Individual Li Attorney in Fact El Trustee 0 Guardian or Conservator 0 Other: Signer Is Representing: BIDDER'S DISCLOSURE OF DISCIPLINE RECORD (To Accompany Proposal) TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 Contractors are required by law to be licensed and regulated by the Contractors' State License Board which has jurisdiction to investigate complaints against contractors if a complaint regarding a patent act or omission is filed within four years of the date of the alleged violation. A complaint regarding a latent act or omission pertaining to structural defects must be filed within 10 years of the date of the alleged violation. Any questions concerning a contractor may be referred to the Registrar, Contractors' State License Board, P.O. Box 26000, Sacramento, California 95826. 1)Have you ever had your contractor's license suspended or revoked by the California Contractors' State License Board two or more times within an eight year period? X yes no 2)Has the suspension or revocation of your contractor's license ever been stayed? X yes no 3)Have any subcontractors that you propose to perform any portion of the Work ever had their contractor's license suspended or revoked by the California Contractors' State License Board two or more times within an eight year period? X yes no 4)Has the suspension or revocation of the license of any subcontractor's that you propose to perform any portion ofX the Work over been stayed? yes no 5)If the answer to either of 1. or 3. above is yes fully identify, in each and every case, the party disciplined, the date of and violation that the disciplinary action pertains to, describe the nature of the violation and the disciplinary action taken therefore. (If needed attach additional sheets to provide full disclosure.) Page 1 of 2 pages of this Disclosure of Discipline form r' Revised 6/12/18 Contract No. 6335 Page 29 of 176 BY CONTRACTOR: Blue Paci c Engine ring & Cons tion me of C ntractor By: (sign here) Shahram Bhp, Sole Proprietor/Owner BIDDER'S DISCLOSURE OF DISCIPLINE RECORD (CONTINUED) (To Accompany Proposal) TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 1) If the answer to either of 2. or 4. above is yes fully identify, in each and every case, the party whose discipline was stayed, the date of the violation that the disciplinary action pertains to, describe the nature of the violation and the condition (if any) upon which the disciplinary action was stayed. (If needed attach additional sheets to provide full disclosure.) (print name/title) Page 2 of 2 pages of this Disclosure of Discipline form 411V —1- Revised 6/12/18 Contract No. 6335 Page 30 of 176 RICIMMAMEGANz comm.# 2305457 NOTARY PUBLIC-CALIFORNIA o SAN DIEGO COUNTY My Comm. Exp. September 20,2023 — WITNESS my hand and official seal. Signature Signature of Notary Public CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of San Diego On 02/18/2021 before me, Richard William Egan, Notary Public Date Here Insert Name and Title of the Officer personally appeared Shahram Elihu Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/arc subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/hcr/thcir authorized capacity(ics), and that by his/her/thcir signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Place Notary Seal and/or Stamp Above OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: 02/18/2021 Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Shahram Elihu Li Corporate Officer — Title(s): 0 Partner — El Limited 0 General E Individual LI Attorney in Fact E Trustee 0 Guardian or Conservator Dti Other: Sole Proprietor/Sole Owner of Blue Pacific Signer Is Representing: Number of Pages: Signer's Name: 0 Corporate Officer — Title(s): 0 Partner — 0 Limited E General El Individual El Attorney in Fact El Trustee 0 Guardian or Conservator 0 Other: Signer Is Representing: Signatur of Bidder inv — r- Revised 6/12/18 NONCOLLUSION DECLARATION TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID PUBLIC CONTRACT CODE SECTION 7106 TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 The undersigned declares: Blue Pacific Engineering & I am the Sole Proprietor of Construction , the party making the foregoing bid. The bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation. The bid is genuine and not collusive or sham. The bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid. The bidder has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or to refrain from bidding. The bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to fix any overhead, profit, or cost element of the bid price, or of that of any other bidder. All statements contained in the bid are true. The bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, to any corporation, partnership, company, association, organization, bid depository, or to any member or agent thereof, to effectuate a collusive or sham bid, and has not paid, and will not pay, any person or entity for such purpose. Any person executing this declaration on behalf of a bidder that is a corporation, partnership, joint venture, limited liability company, limited liability partnership, or any other entity, hereby represents that he or she has full power to execute, and does execute, this declaration on behalf of the bidder. declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct and that this declaration is executed on February 18 2021 at San Diego [city],California [state]. Contract No. 6335 Page 31 of 176 RICHARD WILLIAM EGAN i COMN1.# 2305457 NOTARY PUBLIC-CALIFORNIA 2 SAN DIEGO COUNTY My Comm. Exp. September 20,2023 WITNESS my hand and official seal. Signature Ignature of Notary Public CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of San Diego On 02/18/2021 before me, Richard William Egan, Notary Public Date Here Insert Name and Title of the Officer personally appeared Shahram Elihu Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(e) whose name(s) is/aro subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/hcr/thcir authorized capacity(icc;), and that by his/hcr/thcir signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. Place Notary Seal and/or Stamp Above OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: 02Z18/2021 Signer(s) Other Than Named Above: Number of Pages: Capacity(ies) Claimed by Signer(s) Signer's Name: Shahram Elihu U Corporate Officer — Title(s): Li Partner — 0 Limited 0 General 0 Individual 0 Attorney in Fact Li Trustee 0 Guardian or Conservator D__1( Other: Sole Proprietor/Sole Owner of Blue Pacific Signer Is Representing: Signer's Name: 0 Corporate Officer — Title(s): 0 Partner — 0 Limited 0 General 0 Individual 0 Attorney in Fact 0 Trustee El Guardian or Conservator rl Other: Signer Is Representing: CONTRACT PUBLIC WORKS This agreement is made this day of 2021, by and between the City of Carlsbad, California, a municipal corporation, (hereinafter called "City"), and Blue Pacific Engineering & Construction whose principal place of business is 7330 Opportunity Road, Suite A, San Diego, CA 92111 (hereinafter called "Contractor"). City and Contractor agree as follows: 1.Description of Work. Contractor shall perform all work specified in the Contract documents for: TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6336 (hereinafter called "project") 2.Provisions of Labor and Materials. Contractor shall provide all labor; materials, tools; equipment, and personnel to perform the work specified by the Contract Documents. 3.Contract Documents. The Contract Documents consist of this Contract, Notice Inviting Bids, Contractor's Proposal, Bidder's Bond, Noncollusion Declaration, Designation of Subcontractors, Technical Ability and Experience, Bidder's Statement Re Debarment, Escrow Agreement, Release Form, the Plans and Specifications, the General Provisions, addendum(s) to said Plans and Specifications and General Provisions, and all proper amendments and changes made thereto in accordance with this Contract or the Plans and Specifications, and all bonds for the project; all of which are incorporated herein by this reference. Contractor, her/his subcontractors, and materials suppliers shall provide and install the work as indicated; specified, and implied by the Contract Documents. Any items of work not indicated or specified, but which are essential to the completion of the work, shall be provided at the Contractor's expense to fulfill the intent of said documents. In all instances through the life of the Contract, the City will be the interpreter of the intent of the Contract Documents, and the City's decision relative to said intent will be final and binding. Failure of the Contractor to apprise subcontractors and materials suppliers of this condition of the Contract will not relieve responsibility of compliance. 4.Payment. For all compensation for Contractor's performance of work under this Contract, City shall make payment to the Contractor per section 9-3 PAYMENT of the General Provisions section of this contract. The Engineer will close the estimate of work completed for progress payments on the last working day of each month. The City shall withhold retention as required by Public Contract Code Section 9203. 5.Independent Investigation. Contractor has made an independent investigation of the jobsite, the soil conditions at the jobsite, and all other conditions that might affect the progress of the work, and is aware of those conditions. The Contract price includes payment for all work that may be done by Contractor, whether anticipated or not, in order to overcome underground conditions. Any information that may have been furnished to Contractor by City about 1011' aw. Revised 6/12/18 Contract No. 6335 Page 32 of 176 underground conditions or other job conditions is for Contractor's convenience only, and City does not warrant that the conditions are as thus indicated. Contractor is satisfied with all job conditions, including underground conditions and has not relied on information furnished by City. 6. Hazardous Waste or Other Unusual Conditions. If the contract involves digging trenches or other excavations that extend deeper than four feet below the surface Contractor shall promptly, and before the following conditions are disturbed, notify City, in writing, of any: A.Hazardous Waste. Material that Contractor believes may be material that is hazardous waste, as defined in section 25117 of the Health and Safety Code, that is required to be removed to a Class I, Class II, or Class III disposal site in accordance with provisions of existing law. B.Differing Conditions. Subsurface or latent physical conditions at the site differing from those indicated. C.Unknown Physical Conditions. Unknown physical conditions at the site of any unusual nature, different materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the contract. City shall promptly investigate the conditions, and if it finds that the conditions do materially so differ, or do involve hazardous waste, and cause a decrease or increase in contractor's costs of, or the time required for, performance of any part of the work shall issue a change order under the procedures described in this contract. In the event that a dispute arises between City and Contractor whether the conditions materially differ, or involve hazardous waste, or cause a decrease or increase in the contractor's cost of, or time required for, performance of any part of the work, contractor shall not be excused from any scheduled completion date provided for by the contract, but shall proceed with all work to be performed under the contract. Contractor shall retain any and all rights provided either by contract or by law which pertain to the resolution of disputes and protests between the contracting parties. 7. Immigration Reform and Control Act. Contractor certifies it is aware of the requirements of the Immigration Reform and Control Act of 1986 (8 USC sections 1101-1525) and has complied and will comply with these requirements, including, but not limited to, verifying the eligibility for employment of all agents, employees, subcontractors, and consultants that are included in this Contract. 8. Prevailing Wage. Pursuant to the California Labor Code, the director of the Department of Industrial Relations has determined the general prevailing rate of per diem wages in accordance with California Labor Code, section 1773 and a copy of a schedule of said general prevailing wage rates is on file in the office of the City Engineer, and is incorporated by reference herein. Pursuant to California Labor Code, section 1775, Contractor shall pay prevailing wages. Contractor shall post copies of all applicable prevailing wages on the job site. Contractor shall comply with California Labor Code, section 1776, which generally requires keeping accurate payroll records, verifying and certifying payroll records, and making them available for inspection. Contractor shall require all subcontractors to comply with Section 1776. 9. Indemnification. Contractor shall assume the defense of, pay all expenses of defense, and indemnify and hold harmless the City, and its officers and employees, from all claims, loss, damage, injury and liability of every kind, nature and description, directly or indirectly arising from or in connection with the performance of the Contract or work; or from any failure or alleged failure 4111-1fr —9- Revised 6/12/18 Contract No. 6335 Page 33 of 176 of Contractor to comply with any applicable law, rules or regulations including those relating to safety and health; and from any and all claims, loss, damages, injury and liability, howsoever the same may be caused, resulting directly or indirectly from the nature of the work covered by the Contract, except for loss or damage caused by the sole or active negligence or willful misconduct of the City. The expenses of defense include all costs and expenses including attorneys' fees for litigation, arbitration, or other dispute resolution method. Contractor shall also defend and indemnify the City against any challenges to the award of the contract to Contractor, and Contractor will pay all costs, including defense costs for the City. Defense costs include the cost of separate counsel for City, if City requests separate counsel. Contractor shall also defend and indemnify the City against any challenges to the award of the contract to Contractor, arising in whole or in part from alleged inaccuracies or misrepresentation by the Contractor, whether intentional or otherwise, and Contractor will pay all costs, including defense costs for the City. Defense costs include the cost of separate counsel for City, if City requests separate counsel. 10. Insurance. Contractor shall procure and maintain for the duration of the contract insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his or her agents, representatives, employees or subcontractors. Said insurance shall meet the City's policy for insurance as stated in City Council Policy # 70. (A) Coverages and Limits Contractor shall maintain the types of coverages and minimum limits indicted herein: a.Commercial General Liability (CGL) Insurance: Insurance written on an "occurrence" basis, including products-completed operations, personal & advertising injury, with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location or the general aggregate limit shall be twice the required occurrence limit. b.Business Automobile Liability Insurance: $2,000,000 combined single limit per accident for bodily injury and property damage. In addition, the auto policy must cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. c.Workers' Compensation and Employers' Liability Insurance: Workers' compensation limits as required by the Labor Code of the State of California and Employers' Liability limits of $1,000,000 per incident. Workers' compensation offered by the State Compensation Insurance Fund is acceptable to the City. (13) Additional Provisions: Contractor shall ensure that the policies of insurance required under this agreement with the exception of Workers' Compensation and Business Automobile Liability Insurance contain, or are endorsed to contain, the following provisions. a. The City, its officials, employees and volunteers are to be covered as additional insured as respects: liability arising out of activities performed by or on behalf of the Contractor; products and completed operations of the contractor: premises owned, leased, hired or borrowed by the contractor. The coverage shall contain no special limitations on the scope of protection afforded to the City, its officials, employees or volunteers. All additional insured endorsements must be —1- Revised 6/12/18 Contract No. 6335 Page 34 of 176 evidenced using separate documents attached to the certificate of insurance; one for each company affording general liability, and employers' liability coverage. b.The Contractor's insurance coverage shall be primary insurance as respects the City, its officials, employees and volunteers. Any insurance or self-insurance maintained by the City, its officials, employees or volunteers shall be in excess of the contractor's insurance and shall not contribute with it. c.Any failure to comply with reporting provisions of the policies shall not affect coverage provided to the City, its officials, employees or volunteers. d.Coverage shall state that the contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. (C)Notice of Cancellation. Each insurance policy required by this agreement shall be endorsed to state that coverage shall not be nonrenewed, suspended, voided, canceled, or reduced in coverage or limits except after ten (10) days' prior written notice has been sent to the City by certified mail, return receipt requested. (D)Deductibles and Self-Insured Retention (S.I.R.) Levels. Any deductibles or self-insured retention levels must be declared to and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles or self-insured retention levels as respects the City, its officials and employees; or the contractor shall procure a bond guaranteeing payment of losses and related investigation, claim administration and defense expenses. (E)Waiver of Subrogation. All policies of insurance required under this agreement shall contain a waiver of all rights of subrogation the insurer may have or may acquire against the City or any of its officials or employees. (F)Subcontractors. Contractor shall include all subcontractors as insured under its policies or shall furnish separate certificates and endorsements for each subcontractor. Coverages for subcontractors shall be subject to all of the requirements stated herein. (G)Acceptability of Insurers. Insurance is to be placed with insurers that have a rating in Best's Key Rating Guide of at least A-:VII. Insurers must also be authorized to transact the business of insurance by the State of California Insurance Commissioner as admitted carriers as evidenced by a listing in the official publication of the Department of Insurance of the State of California and/or under the standards specified by City Council Policy # 70. (H)Verification of Coverage. Contractor shall furnish the City with certificates of insurance and original endorsements affecting coverage required by this clause. The certificates and endorsements for each insurance policy are to be signed by a person authorized by that insurer to bind coverage on its behalf. The certificates and endorsements are to be in forms approved by the City and are to be received and approved by the City before the Contract is executed by the City. (I)Cost of Insurance. The Cost of all insurance required under this agreement shall be included in the Contractor's bid. t at Revised 6/12/18 Contract No. 6335 Page 35 of 176 11. Claims and Lawsuits. All claims by Contractor shall be resolved in accordance with Public Contract Code section 9204, which is incorporated by reference. A copy of Section 9204 is included in Section 3 of the General Provisions. In addition, all claims by Contractor for $375,000 or less shall be resolved in accordance with the provisions in the Public Contract Code, Division 2, Part 3, Chapter 1, Article 1.5 (commencing with section 20104) which are incorporated by reference. A copy of Article 1.5 is included in Section 3 of the General Provisions. In the event of a conflict between Section 9204 and Article 1.5, Section 9204 shall apply. Notwithstanding the provisions of this section of the contract, all claims shall comply with the Government Tort Claim Act (section 900 et seq., of the California Government Code) for any claim or cause of action for money or damages prior to filing any lawsuit for breach of this agreement. (A)Assertion of Claims. Contractor hereby agrees that any contract claim submitted to the City must be asserted as part of the contract process as set forth in this agreement and not in anticipation of litigation or in conjunction with litigation. (B)False Claims. Contractor acknowledges that if a false claim is submitted to the City, it may be considered fraud and the Contractor may be subject to criminal prosecution. (C)Government Code. Contractor acknowledges that California Government Code sections 12650 et seq., the False Claims Act, provides for civil penalties where a person knowingly submits a false claim to a public entity. These provisions include false claims made with deliberate ignorance of the false information or in reckless disregard of the truth or falsity of the information. (D)Penalty Recovery. If the City of Carlsbad seeks to recover penalties pursuant to the False Claims Act, it is entitled to recover its litigation costs, including attorney's fees. (E)Debarment for False Claims. Contractor hereby acknowledges that the filing of a false claim may subject the Contractor to an administrative debarment proceeding wherein the Contractor may be prevented from further bidding on public contracts for a period of up to five years. (F)Carlsbad Municipal Code. The provisions of Carlsbad Municipal Code sections 3.32.025, 3.32.026, 3.32.027 and 3.32.028 pertaining to false claims are incorporated herein by reference. (G)Debarment from Other Jurisdictions. Contractor hereby acknowledges that debarment by another jurisdiction is grounds for the City of Carlsbad to disqualify the Contractor or subcontractor from participating in future contract bidding. (H)Jurisdiction. Contractor agrees and hereby stipulates that the proper venue and jurisdiction for resolution of any disputes between the parties arising out of this agreement is San Diego County, California. I have read and understand all provisions of Section 11 above. 12. Maintenance of Records. Contractor shall maintain and make available at no cost to the City, upon request, records in accordance with sections 1776 and 1812 of Part 7, Chapter 1, Article 2, of the Labor Code. If the Contractor does not maintain the records at Contractor's principal place of business as specified above, Contractor shall so inform the City by certified letter accompanying the return of this Contract. Contractor shall notify the City by certified mail of any change of address of such records. F', —1- Revised 6/12/18 Contract No. 6335 Page 36 of 176 init init 13.Labor Code Provisions. The provisions of Part 7, Chapter 1, commencing with section 1720 of the Labor Code are incorporated herein by reference. 14.Security. Securities in the form of cash, cashier's check, or certified check may be substituted for any monies withheld by the City to secure performance of this contract for any obligation established by this contract. Any other security that is mutually agreed to by the Contractor and the City may be substituted for monies withheld to ensure performance under this Contract. 15.Unfair Business Practices. In entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or subcontractor offers and agrees to assign to the awarding body all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec. 15) or under the Cartwright Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or the subcontract. This assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment by the parties. 16.Provisions Required by Law Deemed Inserted. Each and every provision of law and clause required by law to be inserted in this Contract shall be deemed to be inserted herein and included herein, and if, through mistake or otherwise, any such provision is not inserted, or is not correctly inserted, then upon application of either party, the Contract shall forthwith be physically amended to make such insertion or correction. 41-11r %al —1- Revised 6/12/18 Contract No. 6335 Page 37 of 176 CITY OF CARLSBAD a municipal corporation of the State of lifor By: ( Matt Hall, Mayor ATTEST: APPROVED AS TO FORM: CELIA A. B City Attorney 17. Additional Provisions. Any additional provisions of this agreement are set forth in the "General Provisions" or "Supplemental Provisions" attached hereto and made a part hereof. NOTARIAL ACKNOWLEDGMENT OF EXECUTION BY ALL SIGNATORIES MUST BE ATTACHED (CORPORATE SEAL) CONTRACTOR: F)iik copprrni C6(15411ActiOn ConYac t) (sign here) ShJ411?4,41 — MI e,r (print name and title) By: (sign here) (print name and title) fr/(1.D .-elV1/1A tY . Barbara Engleson, Cit Clerk By: President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under the corporate seal empowering that officer to bind the corporation. A istant City Attorney pm, rs Revised 6/12/18 Contract No. 6335 Page 38 of 176 RICHARD WILLIAM EGAN i comm.# 2305457 73 NOTARY PUBLIC-CALIFORNIA 2 SAN DIEGO COUNTY My Comm. Exp. September 20, 2024 — Signature Signature of Notaty Public CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of San Diego On 03/31/2021 before me, Richard William Egan, Notary Public Date Here Insert Name and Title of the Officer personally appeared Shahram Elihu Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/arc subscribed to the within instrument and acknowledged to me that he/and/they executed the same in his/hcr/thcir authorized capacity(i-es), and that by his/hcr/thcir signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Place Notary Seal and/or Stamp Above OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: 03/31/2021 Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Shahram Elihu O Corporate Officer — Title(s): O Partner — 0 Limited 0 General LI Individual El Attorney in Fact 0 Trustee 0 Guardian or Conservator •Other: Sole Proprietor/Sole Owner of Blue Pacific Signer Is Representing: Number of Pages: Signer's Name: O Corporate Officer — Title(s): O Partner — 0 Limited LI General O Individual 0 Attorney in Fact 0 Trustee LI Guardian or Conservator O Other: Signer Is Representing: BOND NO. 024251141 PREMIUM INCLUDED IN PERFORMANCE BOND LABOR AND MATERIALS BOND WHEREAS, the City Council of the City of Carlsbad, State of California, has awarded to Blue Pacific Engineering & Construction, (hereinafter designated as the "Principal"), a Contract for: TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 in the City of Carlsbad, in strict conformity with the drawings and specifications, and other Contract Documents now on file in the Office of the City Clerk of the City of Carlsbad and all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond, providing that if Principal or any of their subcontractors shall fail to pay for any materials, provisions, provender or other supplies or teams used in, upon or about the performance of the work agreed to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same to the extent hereinafter set forth. NOW, THEREFORE, WE, Blue Pacific Engineering & Construction, as Principal, (hereinafter designated as the "Contractor"), and THE OHIO CASUALTY INSURANCE COMPANY as Surety, are held firmly bound unto the City of Carlsbad in the sum of three hundred fifty-eight thousand three hundred ninety-one Dollars ($358,391), said sum being an amount equal to: One hundred percent (100%) of the total amount payable under the terms of the contract by the City of Carlsbad, and for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the Contractor or his/her subcontractors fail to pay for any materials, provisions, provender, supplies, or teams used in, upon, for, or about the performance of the work contracted to be done, or for any other work or labor thereon of any kind, consistent with California Civil Code section 9100, or for amounts due under the Unemployment Insurance Code with respect to the work or labor performed under this Contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of the contractor and subcontractors pursuant to section 13020 of the Unemployment Insurance Code with respect to the work and labor, that the Surety will pay for the same, and, also, in case suit is brought upon the bond, reasonable attorney's fees, to be fixed by the court consistent with California Civil Code section 9554. This bond shall inure to the benefit of any of the persons named in California Civil Code section 9100, so as to give a right of action to those persons or their assigns in any suit brought upon the bond. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed hereunder or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications. 4P1fr —r- Revised 6/12/18 Contract No 6335 Page 39 of 176 BLUE PACIFIC ENGINEERING & CONSTRUCTION THE OHIO (SEAL) CASUALTY INSURANCE COMPANY (SEAL) (Surety) By: /O. (Signature) shAra" erthu -Owner MARK D. IATAROLA, ATTORNEY-IN-FACT (Print Name & Title) (Print Name & Title) CELIA A. EWER City Attorney By: In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. SIGNED AND SEALED, this 24TH day of MARCH , 20 21 (SEAL AND NOTARIAL ACKNOWLEDGEMENT OF SURETY — ATTACH ATTORNEY-IN-FACT CERTIFICATE) APPROVED AS TO FORM: ssistanrCity Attorney 4,31' t el 1- Revised 6/12/18 Contract No. 6335 Page 40 of 176 CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of San Diego On 03/31/2021 before me, Richard William Egan, Notary Public Date Here Insert Name and Title of the Officer personally appeared Shahram Elihu Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) subscribed to the within instrument and acknowledged to me that helshc/thcy executed the same in his/hcr/thcir authorized capacity(ies), and that by his/hcr/thcir signature(e) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature Signature of Notary Public WO AM EGAN comm. # 2305457 73 re NOTARY PUBLIC-CALIFORNIA SAN DIEGO COUNTY 0 My Comm. Exp. September 20,2023 Place Notary Seal and/or Stamp Above OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: 03/31/2021 Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Shahram Elihu PI Corporate Officer — Title(s): E Partner — Li Limited Li General 0 Individual 0 Attorney in Fact 0 Trustee Li Guardian or Conservator l. Other: Sole Proprietor/Sole Owner of Blue Pacific Signer Is Representing: Number of Pages: Signer's Name: [Ti Corporate Officer — Title(s): 0 Partner — 0 Limited 0 General El Individual El Attorney in Fact 0 Trustee 0 Guardian or Conservator TI Other: Signer Is Representing: Signature 110 CE' at o o Public a OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: MARK D. IATAROLA O Corporate Officer — Title(s): O Partner — 0 Limited 0 General O Individual l& Attorney in Fact O Trustee 0 Guardian of Conservator •Other: Signer is Representing: Signer's Name: 0 Corporate Officer — Title(s): o Partner — 0 Limited 0 General O Individual 0 Attorney in Fact o Trustee 0 Guardian of Conservator 0 Other: Signer is Representing: CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 NiggaggileggCM A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of SAN DIEGO On 3/24/2021 before me, TRACY LYNN RODRIGUEZ, NOTARY PUBLIC , Date Here Insert Name and Title of the Officer personally appeared MARK D. IATAROLA Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/s1=teithey executed the same in hisiher-itheif authorized capacity(4es), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(a) acted, executed the instrument. " SAN DIEGO COUNTY > NOTARY PUB LIC-CALIFOFINIA Z MY COMMISSION EXPIRES' JANUARY 11,2024 I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. co...#23.18838 TRACY LYNN RODRIGUEZ Place Notary Seal and/or Stamp Above ©2017 National Notary Association This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated. Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company Liberty Mutual.. SURETY Certificate No: 8204105-024100 POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Helen Maloney; Jessica Selma]; John G. Maloney; Mark D. tatarola; Sandra Figueroa; Tracy Lynn Rodriguez all of the city of Escondido state of CA each individually if there be more than one named, its true and lawful attorney-in-fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 7th day of August , 2020 . Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company By: David M. Carey, Assistant Secretary State of PENNSYLVANIA County of MONTGOMERY Ss On this 7th day of August , 2020 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written. COMMONWEALTH OF PENNSYLVANIA Notarial Seal Teresa Pastella. Notary Public Upper Marion Two., Montgomery County My Commission Expires March 28.2021 Meinbor, Pennsylvania Assccialionut Nulenes i pzAisij Ltd& eresa Pastella, Notary Public By: This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: ARTICLE IV — OFFICERS: Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations Such attorneys-in-fact, subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney-in-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE XIII — Execution of Contracts: Section 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attomeys-in-fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys-in- fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization — By unanimous consent of the Compel-ills Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 24TH day of MARCH , 2021 . By: Renee C. Llewellyn, Assistant Secretary LMS-12873 LMIC OCIC WAIC Mult Co_12/19 BOND NO. 024251141 PREMIUM: $6,376.00 PREMIUM IS FOR CONTRACT TERM AND IS SUBJECT TO ADJUSTMENT BASED ON FINAL CONTRACT PRICE FAITHFUL PERFORMANCE/WARRANTY BOND WHEREAS, the City Council of the City of Carlsbad, State of California, has awarded to Blue Pacific Engineering & Construction, (hereinafter designated as the "Principal"), a Contract for: TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 in the City of Carlsbad, in strict conformity with the contract, the drawings and specifications, and other Contract Documents now on file in the Office of the City Clerk of the City of Carlsbad, all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond for the faithful performance and warranty of said Contract; NOW, THEREFORE, WE, Blue Pacific Engineering & Construction, as Principal, (hereinafter designated as the "Contractor"), and THE OHIO CASUALTY INSURANCE COMPANY as Surety, are held firmly bound unto the City of Carlsbad in the sum of three hundred fifty-eight thousand three hundred ninety-one Dollars ($358,391), said sum being an amount equal to: One hundred percent (100%) of the total amount payable under the terms of the contract by the City of Carlsbad, and for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the above bounden Contractor, their heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions, and agreements in the Contract and any alteration thereof made as therein provided on their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City of Carlsbad, its officers, employees and agents, as therein stipulated, then this obligation shall become null and void; otherwise it shall remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by the City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed there under or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications. Ark tat —r- Revised 6/12/18 Contract No. 6335 Page 41 of 176 ENGINEERING & CONSTRUCTION n (SEAL) By: (Sig na ure) APPROVED AS TO FORM: CELIA A. B EWER City Attorney By: Assistant City Attorney In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. SIGNED AND SEALED, this 24TH BLUE PACIFIC day of MARCH , 20 21 THE OHIO CASUALTY INSURANCE COMPANY (SEAL) (Surety) By: (Signature) Skaivw 1iIiu. Owner MARK D. IATAROLA, ATTORNEY-IN-FACT (Print Name & Title) (Print Name & Title) (SEAL AND NOTARIAL ACKNOWLEDGEMENT OF SURETY — ATTACH ATTORNEY-IN-FACT CERTIFICATE) tAr. -r" Revised 6/12/18 Contract No. 6335 Page 42 of 176 RICHARD WILLIAM EGAN1 CO MM 2305457 73 NOTARY PUBL1C-CALIFORNIA SAN DIEGO COUNTY My Comm. Exp. September 20, 2023 Signature ignature of Notary Public CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of San Diego On 03/31/2021 before me, Richard William Egan, Notary Public Date Here Insert Name and Title of the Officer personally appeared Shahram Elihu Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/hcr/thcir signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Place Notary Seal and/or Stamp Above OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: 03/31/2021 Number of Pages: Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer(s) Signer's Name: Shahram Elihu I 1 Corporate Officer — Title(s): LI Partner — Li Limited Li General 0 Individual Li Attorney in Fact Li Trustee Li Guardian or Conservator lxi Other: Sole Proprietor/Sole Owner of Blue Pacific Signer Is Representing: Signer's Name: 71 Corporate Officer — Title(s): Li Partner — 0 Limited 0 General LI Individual 0 Attorney in Fact Trustee 0 Guardian or Conservator PI Other: Signer Is Representing: I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. OPTIONAL Completing this information can deter alteration of the document or fraudulent reattachment of this form to an unintended document. Description of Attached Document Title or Type of Document: Document Date: Number of Pages: Signer(s) Other Than Named Above: Capacity(les) Claimed by Signer(s) Signer's Name: MARK D. IATAROLA 0 Corporate Officer - Title(s): O Partner.- 0 Limited 0 General o Individual I!3 Attorney in Fact O Trustee 0 Guardian of Conservator O Other: Signer is Representing: Signer's Name: o Corporate Officer - Title(s): O Partner - 0 Limited 0 General O Individual 0 Attorney in Fact O Trustee o Guardian of Conservator O Other: Signer is Representing: CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT CIVIL CODE § 1189 A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of SAN DIEGO On 3/24/2021 TRACY LYNN RODRIGUEZ, NOTARY PUBLIC , Here Insert Name and Title of the Officer personally appeared MARK D. IATAROLA Name(s) of Signer(s) who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) istar-e- subscribed to the within instrument and acknowledged to me that he/ohc/thcy executed the same in hishlierit+reif authorized capacity(tes), and that by his/Her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. Place Notary Seal and/or Stamp Above ©2017 National Notary Association before me, Date TRACY LYNN RODRIGUEZ/ COMM. # 2318838 I> SAN DIEGO COUNTY > NOTARY PUBLIC-CALIFORNIAZ MY COMMISSION EXPIRES "J JANUARY 11,2024 Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company /owl/ By: David M. Carey, Assistant Secretary This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated. Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company Liberty Mutual.. SURETY Certificate No: 8204105-024100 POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Helen Maloney; Jessica Schmal; John G. Maloney; Mark D. Iatarola; Sandra Figueroa; Tracy Lynn Rodriguez all of the city of Escondido state of CA each individually if there be more than one named, its true and lawful attorney-in-fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 7th day of August , 2020 . State of PENNSYLVANIA ss County of MONTGOMERY On this 7th day of August , 2020 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written. ooriVA 124/4y This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: ARTICLE IV— OFFICERS: Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys-in-fact, subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney-in-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE XIII — Execution of Contracts: Section 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys-in-fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation — The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys-in- fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization — By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Renee C. Uewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 241'11 day of MARC!) , 2021 . cn in a) _0 >ft ca 0 _ 0) o 4>;" E c. c> ;,•-x- o c a> E 0 ft3 0- o cr, CD LEO) 0 a) 575 T:15 > "zr _C CNI CO — oo c 00 0 (9 COMMONWEALTH OF PENNSYLVANIA OF By: =1/ eresa Pastella, Notary Public Notarial Seal Teresa Pastella. Notary Public Upper Merlon Twp., Montgomery County My Commission Expires March 28.2021 Member, PermsylvanaP.sudaciuri el Naiades By: Renee C. Llewellyn, Assistant Secretary LMS-12873 LMIC OCIC WAIC Multi Co_12/19 OPTIONAL ESCROW AGREEMENT FOR SECURITY DEPOSITS IN LIEU OF RETENTION This Escrow Agreement is made and entered into by and between the City of Carlsbad whose address is 1200 Carlsbad Village Drive, Carlsbad, California, 92008, hereinafter called "City" and whose address is hereinafter called "Contractor" and whose address is hereinafter called "Escrow Agent." For the consideration hereinafter set forth, the City, Contractor and Escrow Agent agree as follows: 1.Pursuant to section 22300 of the Public Contract Code of the State of California, the Contractor has the option to deposit securities with the Escrow Agent as a substitute for retention earnings required to be withheld by the City pursuant to the Construction Contract entered into between the City and Contractor for TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 in the amount of dated (hereinafter referred to as the "Contract"). Alternatively, on written request of the Contractor, the City shall make payments of the retention earnings directly to the Escrow Agent. When the Contractor deposits the securities as a substitute for Contract earnings, the Escrow Agent shall notify the City within 10 days of the deposit. The market value of the securities at the time of the substitution shall be a least equal to the cash amount then required to be withheld as retention under the terms of the contract between the City and Contractor. Securities shall be held in the name of the City and shall designate the Contractor as the beneficial owner. 2.The City shall make progress payments to the Contractor for such funds which otherwise would be withheld from progress payments pursuant to the Contract provisions, provided that the Escrow Agent holds securities in the form and amount specified above. 3.When the City makes payment of retentions earned directly to the Escrow Agent, the Escrow Agent shall hold them for the benefit of the Contractor until such time as the escrow created under this contract is terminated. The Contractor may direct the investment of the payments into securities. All terms and conditions of this agreement and the rights and responsibilities of the parties shall be equally applicable and binding when the City pays the Escrow Agent directly. 4.The Contractor shall be responsible for paying all fees for the expenses incurred by the Escrow Agent in administering the Escrow Account and all expenses of the City. These expenses and payment terms shall be determined by the City, Contractor and Escrow Agent. 5.The interest earned on the securities or the money market accounts held in escrow and all interest earned on that interest shall be for the sole account of Contractor and shall be subject to withdrawal by Contractor at any time and from time to time without notice to the City. Revised 6/12/18 Contract No. 6335 Page 43 of 176 6.Contractor shall have the right to withdraw all or any part of the principal in the Escrow Account only by written notice to Escrow Agent accompanied by written authorization from City to the Escrow Agent that City consents to the withdrawal of the amount sought to be withdrawn by Contractor. 7.The City shall have a right to draw upon the securities in the event of default by the Contractor. Upon seven days' written notice to the Escrow Agent from the City of the default, the Escrow Agent shall immediately convert the securities to cash and shall distribute the cash as instructed by the City. 8.Upon receipt of written notification from the City certifying that the Contract is final and complete and that the Contractor has complied with all requirements and procedures applicable to the Contract, the Escrow Agent shall release to Contractor all securities and interest on deposit less escrow fees and charges of the Escrow Account. The escrow shall be closed immediately upon disbursement of all moneys and securities on deposit and payments of fees and charges. 9.The Escrow Agent shall rely on the written notifications from the City and the Contractor pursuant to sections (1) to (8), inclusive, of this agreement and the City and Contractor shall hold Escrow Agent harmless from Escrow Agent's release, conversion and disbursement of the securities and interest as set forth above. 10.The names of the persons who are authorized to give written notices or to receive written notice on behalf of the City and on behalf of Contractor in connection with the foregoing, and exemplars of their respective signatures are as follows: For City: Title FINANCE DIRECTOR Name Signature Address 1635 Faraday Avenue, Carlsbad, CA 92008 For Contractor: Title Name Signature Address For Escrow Agent: Title Name Signature Address *‘' ta r. Revised 6/12/18 Contract No. 6335 Page 44 of 176 At the time the Escrow Account is opened, the City and Contractor shall deliver to the Escrow Agent a fully executed counterpart of this Agreement. IN WITNESS WHEREOF, the parties have executed this Agreement by their proper officers on the date first set forth above. For City: Title MAYOR Name Signature Address 1200 Carlsbad Village Drive. Carlsbad. CA 92008 For Contractor: Title Name Signature Address For Escrow Agent: Title Name Signature Address IS'i t —r- Revised 6/12/18 Contract No. 6335 Page 45 of 176 GENERAL PROVISIONS FOR TAMARACK AVENUE AND VALLEY STREET PEDESTRIAN IMPROVEMENTS CONTRACT NO. 6335 CITY OF CARLSBAD BIDDERS ARE ADVISED THAT THIS SECTION REPLACES PART 1, GENERAL PROVISIONS, OF THE STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION SECTION 1 -- TERMS, DEFINITIONS, ABBREVIATIONS, AND SYMBOLS 1-1 TERMS — Unless otherwise stated, the words directed, required, permitted, ordered, instructed, designated, considered necessary, prescribed, approved, acceptable, satisfactory, or words of like meaning, refer to actions, expressions, and prerogatives of the Engineer. 1-1.1 Reference to Drawings. Where words "shown", "indicated", "detailed", "noted", "scheduled", or words of similar import are used, it shall be understood that reference is made to the plans accompanying these provisions, unless stated otherwise. 1-1.2 Directions. Where words "directed", "designated", "selected", or words of similar import are used, it shall be understood that the direction, designation or selection of the Engineer is intended, unless stated otherwise. The word "required" and words of similar import shall be understood to mean "as required to properly complete the work as required and as approved by the Engineer," unless stated otherwise. 1-1.3 Equals and Approvals. Where the words "equal", "approved equal", "equivalent", and such words of similar import are used, it shall be understood such words are fogo‘nied by the expression "in the opinion of the Engineer", unless otherwise stated. Where the words "approved", "approval", "acceptance", or words of similar import are used, it shall be understood that the approval, acceptance, or similar import of the Engineer is intended. 1-1.4 Perform. The word "perform" shall be understood to mean that the Contractor, at its expense, shall perform all operations, labor, tools and equipment, and further, including the furnishing and installing of materials that are indicated, specified or required to mean that the Contractor, at its expense, shall furnish and install the work, complete in place and ready to use, including furnishing of necessary labor, materials, tools, equipment, and transportation. 1-2 DEFINITIONS. The following words, or groups of words, shall be exclusively defined by the definitions assigned to them herein. tA.e. —1- Revised 6/15/17 Contract No. 6335 Page 46 of 176 Addendum — Written or graphic instrument issued prior to the opening of Bids which clarifies, corrects, or changes the bidding or Contract Documents. The term Addendum shall include bulletins and all other types of written notices issued to potential bidders prior to opening of Bids. Agency — The City of Carlsbad, California. Agreement — See Contract. Assessment Act Contract — A Contract financed by special assessments authorized under a State Act or procedural ordinance of a City or County. Base — A layer of specified material of planned thickness placed immediately below the pavement or surfacing. Bid — The offer or proposal of the Bidder submitted on the prescribed form setting forth the prices for the Work. Bidder — Any individual, firm, partnership, corporation, or combination thereof, submitting a Bid for the Work, acting directly or through a duly authorized representative. Board — The officer or body constituting the awarding authority of the Agency, which is the City Council for the City of Carlsbad or the Board of Directors of Carlsbad Municipal Water District. Bond — Bid, performance, and payment bond or other instrument of security. City Council — the City Council of the City of Carlsbad. City Manager — the City Manager of the City of Carlsbad or his/her approved representative. Cash Contract — A Contract financed by means other than special assessments. Change Order — A written order to the Contractor signed by the Agency directing an addition, deletion, or revision in the Work, or an adjustment in the Contract Price or the Contract time issued after the effective date of the Contract. A Change Order may or may not also be signed by the Contractor. Code — The terms Government Code, Labor Code, etc., refer to codes of the State of California. Construction Manager— the Project Inspector's immediate supervisor and first level of appeal for informal dispute resolution. Contract — The written agreement between the Agency and the Contractor covering the Work. Contract Documents — Including but not limited to; the Contract, any Addendum (which pertain to the contract documents), Notice Inviting Bids, Instructions to Bidders; Bid (including documentation accompanying the Bid and any post-bid documentation submitted prior to the Notice of Award) when attached as an exhibit to the Contract, the Bonds, the General Provisions, permits from other agencies, the Technical Specifications, the Supplemental Provisions, the Plans, Standard Plans, Standard Specifications, Reference Specifications, and all Modifications issued after the execution of the Contract. 111). tAw. Revised 6/15/17 Contract No. 6335 Page 47 of 176 Contractor — The individual, partnership, corporation, joint venture, or other legal entity having a Contract with the Agency to perform the Work. In the case of work being done under permit issued by the Agency, the permittee shall be constructed to be the Contractor. The term "prime contractor" shall mean Contractor. Contract Price — The total amount of money for which the Contract is awarded. Contract Unit Price — The amount stated in the Bid for a single unit of an item of work. County Sealer — The Sealer of Weights and Measures of the county in which the Contract is let. Days — Days shall mean consecutive calendar's days unless otherwise specified. Deputy City Engineer, Construction Management & Inspection —The Construction Manager's immediate supervisor and second level of appeal for informal dispute resolution. Dispute Board — Persons designated by the City Manager of the City of Carlsbad or Executive Manager of the Carlsbad Municipal Water District, to hear and advise the City Manager on claims submitted by the Contractor. The City Manager for the City of Carlsbad or the Executive Manager for the Carlsbad Municipal Water District is the last appeal level for informal dispute resolution. Eiectrolier — Street light assembly complete, including foundation, standard, luminaire arm, luminaire, etc. Engineer — The City Engineer of the City of Carlsbad or his/her approved representative. The Engineer is the third level of appeal for informal dispute resolution. Geotextile — Synthetic fiber used in civil engineering applications, serving the primary functions of separation and filtration. House Connection Sewer — A sewer, within a public street or right-of-way, proposed to connect any parcel, lot, or part of a lot with a mainline sewer. House Sewer — A sewer, wholly within private property, proposed to connect any building to a house connection sewer. Luminaire — The lamp housing including the optical and socket assemblies (and ballast if so specified). Luminaire Arm — The structural member, bracket, or mast arm, which, mounted on the standard, supports the luminaire. Minor Bid Item — A single contract item constituting less than 10 percent (10%) of the original Contract Price bid. Modification — Includes Change Orders and Supplemental Agreements. A Modification may only be used after the effective date of the Contract. Notice of Award — The written notice by the Agency to the successful Bidder stating that upon compliance by it with the required conditions, the Agency will execute the Contract. tal Revised 6/15/17 Contract No. 6335 Page 48 of 176 Notice to Proceed — A written notice given by the Agency to the Contractor fixing the date on which the Contract time will start. Own Organization - When used in Section 2-3.1 — Employees of the Contractor who are hired, directed, supervised and paid by the Contractor to accomplish the completion of the Work. Further, such employees have their employment taxes, State disability insurance payments, State and Federal income taxes paid and administered, as applicable, by the Contractor. When used in Section 2-3.1 "own organization" means construction equipment that the Contractor owns or leases and uses to accomplish the Work. Equipment that is owner operated or leased equipment with an operator is not part of the Contractor's Own Organization and will not be included for the purpose of compliance with Section 2-3.1. Person — Any individual, firm, association, partnership, corporation, trust, joint venture, or other legal entity. Plans — The drawings, profiles, cross sections, working drawings, and supplemental drawings, or reproductions thereof, approved by the Engineer, which show the location, character, dimensions, or details of the Work. Private Contract — Work subject to Agency inspection, control, and approval, involving private funds, not administered by the Agency. Project Inspector — The Engineer's designated representative for inspection, contract administration and first level for informal dispute resolution. Proposal — See Bid. Reference Specifications— Those bulletins, standards, rules, methods of analysis or test, codes, and specifications of other agencies, engineering societies, or industrial associations referred to in the Contract Documents. These refer to the latest edition, including amendments in effect and published at the time of advertising the project or issuing the permit, unless specifically referred to by edition, volume, or date. Roadway — The portion of a street reserved for vehicular use. Service Connection — Service connections are all or any portion of the conduit, cable, or duct, including meter, between a utility distribution line and an individual consumer. Sewer — Any conduit intended for the reception and transfer of sewage and fluid industrial waste. Specifications — General Provisions, Standard Specifications, Technical Specifications, Reference Specifications, Supplemental Provisions, and specifications in Supplemental Agreements between the Contractor and the Board. Standard — The shaft or pole used to support street lighting luminaire, traffic signal heads, mast arms, etc. Standard Plans — Details of standard structures, devices, or instructions referred to on the Plans or in Specifications by title or number. —1- Revised 6/15/17 Contract No. 6335 Page 49 of 176 Standard Specifications — The Standard Specifications for Public Works Construction (SSPWC), the "Greenbook". State— State of California. Storm Drain — Any conduit and appurtenances intended for the reception and transfer of storm water. Street —Any road, highway, parkway, freeway, alley, walk, or way. Subbase— A layer of specified material of planned thickness between a base and the subgrade. Subcontractor — An individual, firm, or corporation having a direct contract with the Contractor or with any other Subcontractor for the performance of a part of the Work. Subgrade — For roadways, that portion of the roadbed on which pavement, surfacing, base, subbase, or a layer of other material is placed. For structures, the soil prepared to support a structure. Supervision — Supervision, where used to indicate supervision by the Engineer, shall mean the performance of obligations, and the exercise of rights, specifically imposed upon and granted to the Agency in becoming a party to the Contract. Except as specifically stated herein, supervision by the Agency shall not mean active and direct superintendence of details of the Work. Supplemental Agreement — A written amendment of the Contract Documents signed by both parties. Supplemental Provisions — Additions and revisions to the Standard Specifications setting forth conditions and requirements peculiar to the work. Surety — Any individual, firm, or corporation, bound with and for the Contractor for the acceptable performance, execution, and completion of the Work, and for the satisfaction of all obligations incurred. Tonne—Also referred to as "metric ton". Represents a unit of measure in the International System of Units equal to 1,000 kilograms. Utility — Tracks, overhead or underground wires, pipeline, conduits, ducts, or structures. sewers, or storm drains owned, operated, or maintained in or across a public right of way or private easement. Work— That which is proposed to be constructed or done under the Contract or permit, including the furnishing of all labor, materials, equipment, and services. 1-3 ABBREVIATIONS 1-3.1 General. The abbreviation herein, together with others in general use, are applicable to these Standard Specifications and to project Plans or other Contract Documents. te4: Revised 6/15/17 Contract No. 6335 Page 50 of 176 All abbreviations and symbols used on Plans for structural steel construction shall conform to those given by the "Manual of Steel Construction" published by the American Institute of Steel Construction, Inc. 1-3.2 Common Usage Abbreviation Word or Words ABAN Abandon ABAND Abandoned ABS Acrylonitrile — butadiene — styrene AC Asphalt Concrete ACP Asbestos cement pipe ACWS Asphalt concrete wearing surface ALT Alternate APTS Apartment and Apartments AMER STD American Standard AWG American Wire Gage (nonferrous wire) BC • Beginning of curve. BCR Beginning of curb return BDRY Boundary BE Bottom of footing BLDG Building and Buildings BM Bench mark BVC Beginning of vertical curve B/W Back of wall C/C Center to center CAB Crushed aggregate base CAUOSHA California Occupational Safety and Health Administration CalTrans California Department of Transportation CAP Corrugated aluminum pipe CB Catch Basin Cb Curb CBI? Catch Basin Connection Pipe CBR California Bearing Ratio CCR California Code of Regulations CCTV Closed Circuit W CES Carlsbad Engineering Standards CF Curb face CF Cubic foot C&G Curb and gutter CFR Code of Federal Regulations C FS Cubic Feet per Second CIP Cast iron pipe CIPP Cast-in place pipe CL Clearance, center line CLF Chain link fence CMB Crushed miscellaneous base CMC Cement mortar-coated CML Cement mortar-lined CMWD Carlsbad Municipal Water District CO Cleanout (Sewer) COL Column COMM Commercial CONC Concrete CONN Connection CONST Construct, Construction COORD Coordinate CSP Corrugated steel pipe CSD Carlsbad Standard Drawings CTB Cement treated base CV Check valve CY Cubic yard Load of pipe dB Decibels DB L Double DF Douglas fir DIA Diameter DIP Ductile iron pipe DL Dead load DR Dimension Ratio DT Drain Tile DWG Drawing DVVY Driveway DWY APPR Driveway approach Electric EA Each EC End of curve ECR End of curb return EF Each face EG Edge of gutter EGL Energy grade line El Elevation ELC Electrolier lighting conduit ELT Extra long ton ENGR Engineer, Engineering EP Edge of pavement ESMT Easement ETB Emulsion-treated base EVC End of vertical curb EWA Encina Wastewater Authority EXC Excavation EXP JT Expansion joint EXST Existing Fahrenheit F&C Frame and cover F&I Furnish and install FAB Fabricate FAS Flashing arrow sign FD Floor drain FDN Foundation FED SPEC Federal Specification FG Finished grade FH Fire hydrant FL Flow line FS Finished surface FT-LB Foot-pound FTG Footing FVV Face of wall o Gas GA Gauge GAL Gallon and Gallons GALV Galvanized 4P), tat —T- Revised 6/15/17 Contract No. 6335 Page 51 of 176 GAR Garage and Garages GIP Galvanized iron pipe GL Ground line or grade line GM Gas meter GNV Ground Not Visible GP Guy pole GPM gallons per minute GR Grade GRTG Grating GSP Galvanized steel pipe High or height HB Hose bib HC House connection HOWL Headwall HGL Hydraulic grade line HORIZ Horizontal HP Horsepower HPG High pressure gas HPS High pressure sodium (Light) HYDR Hydraulic IE Invert Elevation ID Inside diameter INCL Including INSP Inspection INV Invert IP Iron pipe JC Junction chamber JOT Junction JS Junction structure JT Joint Length LAB Laboratory LAT Lateral LB Pound LD Local depression LF Linear foot LH Lamp hole LL Live load LOL Layout line LONG Longitudinal LP Lamp post LPS Low pressure sodium (Light) LS • Lump sum LTS Lime treated soil LWD Leucadia Wastewater District MAI NT Maintenance MAX Maximum MCR Middle of curb return MEAS Measure MH Manhole, maintenance hole MIL SPEC Military specification MISC Miscellaneous MOD Modified, modify MON Monument MSL.. Mean Sea Level (Reg. Standard Drawing M-12) MTBM Microtunneling Boring Machine MULT Multiple MUTCD Manual on Uniform Traffic Control Devices MVL Mercury vapor light NCTD North County Transit District NI RCP "1,1,-,reinforced concrete pipe OBS Obsolete OC On center OD Outside diameter OE Outer edge OHE Overhead Electric OMWD Olivenhain Municipal Water District OPP Opposite ORIG Original PB Pull box PC Point of curvature PCC Portland cement concrete or point of compound curvature PCVC Point of compound vertical curve PE Polyethylene PI Point of intersection PL Property line PMB Processed miscellaneous base POC Point on curve POT Point on tangent PP Power pole PRC Point of reverse curve PRVC • Point of reverse vertical curve PSI Pounds per square inch PT Point of tangency PVC Polyvinyl chloride PVMT Pavement PVT RAN Private right-of-way Rate of flow in cubic feet per second QUAD Quadrangle, Quadrant Radius R&O Rock and oil RNV Right-of-way RA Recycling agent RAC Recycled asphalt concrete RAP Reclaimed asphalt pavement RBAC Rubberized asphalt concrete RC Reinforced concrete RCB Reinforced concrete box RC E Registered civil engineer RCP Reinforced concrete pipe RCV Remote control valve REF Reference REINF Reinforced or reinforcement RES Reservoir RGE Registered geotechnical engineer ROW Right-of-Way RR Railroad RSE Registered structural engineer RTE Registered traffic engineer Sewer or Slope, as applicable SCCP Steel cylinder concrete pipe SD Storm drain SDNR San Diego Northern Railway SDR Standard thermoplastic pipe dimension ratio (ratio of pipe O.D. to minimum wall thickness) SDRSD San Diego Regional Standard Drawings SE Sand Equivalent SEC Section • SF. Square foot SFM Sewer Force Main SI International System of Units (Metric) SPEC Specifications SPPWC Standard Plans for Public Works Construction SSPwr) . . . . . st9nciprrr cnosfirir,+inns cr,r Public Works Construction ST HWY State highway STA Station tale —1- Revised 6/15/17 Contract No. 6335 Page 52 of 176 STD Standard TVV Top of wall STR Straight TYP Typical STR GR Straight grade UE Underground Electric STRUC Structural/Structure USA Underground Service Alert SW Sidewalk VAR Varies, Variable SWD Sidewalk drain VB Valve box SY Square yard VC Vertical curve Telephone VCP Vitrified clay pipe TAN Tangent VERT Vertical IC Top of curb VOL Volume TEL Telephone VVVD Val lecitos Water District TF Top of footing Water, Wider or Width, as applicable TOPO Topography WATCH Work Area Traffic Control Handbook TR Tract WI Wrought iron TRANS Transition WM Water meter IS Traffic signal or transition structure WPJ Weakened plane joint TSC Traffic signal conduit XCONN Cross connection TSS Traffic signal standard XSEC Cross section 1-3.3 Institutions. Abbreviation Word or Words AASHTO American Association of State Highway and Transportation Officials AI SC American Institute of Steel Construction ANSI American National Standards Institute API American Petroleum Institute AREA American Railway Engineering Association ASTM American Society for Testing and Materials AWPA American Wood Preservers Association AWS American Welding Society AVVWA American Water Works Association FHWA Federal Highway Administration GRI Geosynthetic Research Institute NEMA National Electrical Manufacturers Association NOAA National Oceanic and Atmospheric Administration (Dept. of Commerce) UL Underwriters' Laboratories Inc. USGS United States Geological Survey 1-4 UNITS OF MEASURE. 1-4.1 General. U.S. Standard Measures, also called U.S. Customary System, are the principal measurement system in these specifications. However, certain material specifications and test requirements contained herein use SI units specifically and conversions to U.S. Standard Measures may or may not have been included in these circumstances. When U.S. Standard Measures are not included in parenthesis, then the SI units shall control. S.I. units and U.S. Standard Measures in parenthesis may or may not be exactly equivalent. Reference is also made to ASTM E 380 for definitions of various units of the SI system and a more extensive set of conversion factors. ta w. —1- Revised 6/15/17 Contract No. 6335 Page 53 of 176 1-4.2 Units of Measure and Their Abbreviations. U.S. Customary Unit (Equal To) SI Unit (Abbreviations) (Abbreviations) 1 mil (=0.001 in) 25.4 micrometer (gm) 1 inch (in) 25.4 millimeter (mm) 1 inch (in) 2.54 centimeter (cm) 1 foot (ft) 0.3048 meter (m) 1 yard (yd) 0.9144 meter (m) 1 mile (mi) 1.6093 kilometer (km) 1 square foot (ft2) 0.0929 square meter (m2) 1 square yard (yd2) 0.8361 square meter (m2) 1 cubic foot (ft3) 0.0283 cubic meter (m3) 1 cubic yard (yd3) 0.7646 cubic meter (m3) 1 acre 0.4047 hectare (ha) 1 U.S. gallon (gal) 3.7854 Liter (L) 1 fluid ounce (fl. oz.) 29.5735 millileter (mL) 1 pound mass (lb) (avoirdupois) 0.4536 kilogram (kg) 1 ounce mass (oz) 0.02835 kilogram (kg) 1 Ton (=2000 lb avoirdupois) 0.9072 Tonne (= 907 kg) 1 Poise 0.1 pascal - second (Pa • s) 1 centistoke (cs) 1 square millimeters per second (mm2/s) 1 pound force (lbf) 4.4482 Newton (N) 1 pounds per square inch (psi) 6.8948 Kilopascal (kPa) 1 pound force per foot (lbf/ft) 1.4594 Newton per meter (N/m) 1 foot-pound force (ft-lbf) 1.3558 Joules (J) 1 foot-pound force per second ([ft-lbf]/s) 1.3558 Watt (W) 1 part per million (ppm) 1 milligram/liter (mg/L) TEMPERATURE UNITS AND ABBREVIATIONS Degree Fahrenheit (°F): Degree Celsius (°C): °F=(1.8 x°C)+ 32 °C = (°F — 32)/1.8 SI UNITS (ABBREVIATION) COMMONLY USED IN BOTH SYSTEMS 1 Ampere (A) 1 Volt (V) 1 Candela (cd) 1 Lumen (Im) 1 second (s) COMMON METRIC PREFIXES kilo (k) 103 centi (c) 10-2 milli (m) 10-3 micro (E1.) 10-6 nano (n) 10-6 pico (p) 10-12 1-5 SYMBOLS A Delta, the central angle or angle between tangents Angle Percent Feet or minutes Inches or seconds 1 Number per or (between words) PL Property line CL Centerline SL Survey line or station line 4/plfrt ta —1- Revised 6/15/17 Contract No. 6335 Page 54 of 176 SECTION 2 - SCOPE AND CONTROL OF WORK 2-1 AWARD AND EXECUTION OF CONTRACT. Award and execution of Contract will be as provided for in the Specifications, Instruction to Bidders, or Notice Inviting Bids. 2-2 ASSIGNMENT. No Contract or portion thereof may be assigned without consent of the Board, except that the Contractor may assign money due or which will accrue to it under the Contract. If given written notice, such assignment will be recognized by the Board to the extent permitted by law. Any assignment of money shall be subject to all proper withholdings in favor of the Agency and to all deductions provided for in the Contract. All money withheld, whether assigned or not, shall be subject to being used by the Agency for completion of the Work, should the Contractor be in default. 2-3 SUBCONTRACTS. 2-3.1 General. Each Bidder shall comply with the Chapter of the Public Contract Code including Sections 4100 through 4113. The following excerpts or summaries of some of the requirements of this Chapter are included below for information: The Bidder shall set forth in the Bid, as provided in 4104: "(a)The name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the work or improvements, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specially fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of 1 percent of the prime contractor's total bid, or, in the case of bids or offers for the construction of streets or highways, including bridges, in excess of one-half of 1 percent of the prime contractor's total bid or ten thousand dollars ($10,000), whichever is greater." "(b)The portion of the work which will be done by each such subcontractor under this act. The prime contractor shall list only one subcontractor for each such portion as is defined by the prime contractor in his bid." If the Contractor fails to specify a Subcontractor, or specifies more than one Subcontractor for the same portion of the work to be performed under the Contract (in excess of one-half of 1 percent of the Contractor's total Bid), the Contractor shall be qualified to perform that portion itself, and shall perform that portion itself, except as otherwise provided in the Code. As provided in Section 4107, no Contractor whose Bid is accepted shall substitute any person as Subcontractor in place of the Subcontractor listed in the original Bid, except for causes and by procedures established in Section 4107.5. This section provides procedures to correct a clerical error in the listing of a Subcontractor. Section 4110 provides that a Contractor violating any of the provisions of the Chapter violates the Contract and the Board may exercise the option either to cancel the Contract or assess the Contractor a penalty in an amount of not more than 10 percent of the subcontract involved, after a public hearing. Revised 6/15/17 Contract No. 6335 Page 55 of 176 Should the Contractor fail to adhere to the provisions requiring the Contractor to complete 60 percent of the contract price with its own organization, the Agency may at its sole discretion elect to cancel the contract or deduct an amount equal to 10 percent of the value of the work performed in excess of 50 percent of the contract price by other than the Contractor's own organization. The Board shall be the sole body for determination of a violation of these provisions. In any proceedings under this section, the prime contractor shall be entitled to a public hearing before the Board and shall be notified ten (10) days in advance of the time and location of said hearing. The determination of the City Council shall be final. 2-3.2 Additional Responsibility. The Contractor shall give personal attention to the fulfillment of the Contract and shall keep the Work under its control. The Contractor shall perform, with its own organization, Contract work amounting to at least 50 percent of the Contract Price except that any designated "Specialty Items" may be performed by subcontract, and the amount of any such "Specialty Items" so performed may be deducted from the Contract Price before computing the amount required to be performed by the Contractor with its own organization. "Specialty Items" will be identified by the Agency in the Bid or Proposal. Where an entire item is subcontracted, the value of work subcontracted will be based on the Contract Unit Price. When a portion of an item is subcontracted, the value of work subcontracted will be based on the estimated percentage of the Contract Unit Price. This will be determined from information submitted by the Contractor, and subject to approval by the Engineer. Before the work of any Subcontractor is started, the Contractor shall submit to the Engineer for approval a written statement showing the work to be subcontracted giving the name and business of each Subcontractor and description and value of each portion of the work to be so subcontracted. 2-3.3 Status of Subcontractors. Subcontractors shall be considered employees of the Contractor, and the Contractor shall be responsible for their work. 2-4 CONTRACT BONDS. Before execution of the Contract, the Bidder shall file surety bonds with the Agency to be approved by the Board in the amounts and for the purposes noted below. Bonds issued by a surety, who is authorized to issue bonds in California, and whose bonding limitation shown in said circular is sufficient to provide bonds in the amount required by the Contract shall be deemed to be approved unless specifically rejected by the Agency. Bonds from all other sureties shall be accompanied by all of the documents enumerated in Code of Civil Procedure 995.660 (a). The Bidder shall pay all bond premiums, costs, and incidentals. Each bond shall incorporate, by reference, the Contract and be signed by both the Bidder and Surety and the signature of the authorized agent of the Surety shall be notarized. The Contractor shall provide a faithful performance/warranty bond and payment bond (labor and materials bond) for this contract. The faithful performance/warranty bond shall be in a sum not less than one hundred percent of the total amount payable by the terms of this contract. The Contractor shall provide bonds to secure payment of laborers and materials suppliers in a sum not less than one hundred percent of the total amount payable by the terms of this contract. Both bonds shall extend in tun Torce and ertect and be retained by the Agency during this project until they are released according to the provisions of this section. —1- Revised 6/15/17 Contract No 6335 Page 56 of 176 The faithful performance/warranty bond will be reduced to 25 percent of the original amount 30 days after recordation of the Notice of Completion and will remain in full force and effect for the one year warranty period and until all warranty repairs are completed to the satisfaction of the Engineer. The bonds to secure payment of laborers and materials suppliers shall be released six months plus 30 days after recordation of the Notice of Completion if all claims have been paid. All bonds are to be placed with a surety insurance carrier admitted and authorized to transact the business of insurance in California and whose assets exceed their liabilities in an amount equal to or in excess of the amount of the bond. The bonds are to contain the following documents: 1)An original, or a certified copy, of the un-revoked appointment, power of attorney, by laws, or other instrument entitling or authorizing the person who executed the bond to do so. 2)A certified copy of the certificate of authority of the insurer issued by the insurance commissioner. If the bid is accepted, the Agency may require a financial statement of the assets and liabilities of the insurer at the end of the quarter calendar year prior to 30 days next preceding the date of the execution of the bond. The financial statement shall be made by an officer's certificate as defined in Section 173 of the Corporations Code. In the case of a foreign insurer, the financial statement may be verified by the oath of the principal officer or manager residing within the United States. Should any bond become insufficient, the Contractor shall renew the bond within 10 days after receiving notice from the Agency. Should any Surety at any time be unsatisfactory to the Board, notice will be given the Contractor to that effect. No further payments shall be deemed due or will be made under the contract until a new Surety shall qualify and be accepted by the Board. Changes in the Work or extensions of time, made pursuant to the Contract, shall in no way release the Contractor or Surety from its obligations. Notice of such changes or extensions shall be waived by the Surety. 2-5 PLANS AND SPECIFICATIONS. 2-5.1 General. The Contractor shall keep at the Work site a copy of the Plans and Specifications, to which the Engineer shall have access at all times. The specifications for the work include the General Provisions, project technical specifications, Carlsbad Engineering Standards (CES), Standard Specifications for Public Works Construction, (SSPWC), Part 2 & 3, and the latest supplements thereto, current edition at the time of bid opening as published by the "Greenbook" Committee of Public Works Standards, Inc., hereinafter designated "SSPWC", as amended. The construction plans consist of one set. The set is designated as City of Carlsbad Drawing No. 522-7 and consists of six sheets. The standard drawings used for this project are the latest edition of the San Diego Area Regional Standard Drawings, hereinafter designated SDRSD, as issued by the San Diego County Department of Public Works, together with the most recent editions of the City of Carlsbad Engineering Standards and Carlsbad Standard Drawings, as issued by the City of Carlsbad and the Carlsbad Municipal Water District, hereinafter designated as CES and CSD, respectively. Copies of some of the pertinent standard drawings are enclosed as an appendix to these General Provisions. —1- Revised 6/15/17 Contract No 6335 Page 57 of 176 The Plans, Specifications, and other Contract Documents shall govern the Work. The Contract Documents are intended to be complementary and cooperative. Anything specified in the Specifications and not shown on the Plans, or shown on the Plans and not specified in the Specifications, shall be as though shown on or specified in both. The Plans shall be supplemented by such working drawings and shop drawings as are necessary to adequately control the Work. The Contractor shall ascertain the existence of any conditions affecting the cost of the Work through a reasonable examination of the Work site prior to submitting the Bid. Existing improvements visible at the Work site, for which no specific disposition is made on the Plans, but which interfere with the completion of the Work, shall be removed and disposed of by the Contractor. The Contractor shall, upon discovering any error or omission in the Plans or Specifications, immediately call it to the attention of the Engineer. 2-5.2 Precedence of Contract Documents. If there is a conflict between Contract Documents, the document highest in precedence shall control. The precedence shall be the most recent edition of the following documents listed in order of highest to lowest precedence: 1.Permits from other agencies as may be required by law. 2.Change orders, whichever occurs last. 3.Contract addenda, whichever occurs last. 4.Contract. 5.Carlsbad General Provisions, Technical Specifications, and Supplemental Provisions. 6.Plans. 7.Standards plans. 7.1. City of Carlsbad Standard Drawings. 7,2. Carlsbad Municipal Water District Standard Drawings. 7.3. City of Carlsbad modifications to the San Diego Area Regional Standard Drawings. 7.4. San Diego Area Regional Standard Drawings. 7.5. Traffic Signal Design Guidelines and Standards. 7.6. State of Caiifornia Department of Transportation Standard Plans. 7.7. State of California Department of Transportation Standard Specifications. 7.8. California Manual on Uniform Traffic Control Devices (CA MUTCD). 8.Standard Specifications for Public Works Construction, as amended. 9.Reference Specifications. 10.Manufacturer's Installation Recommendations Detail drawings shall take precedence over general drawings. Change Orders, Supplemental Agreements and approved revisions to Plans and Specifications will take precedence over items 2) through 9) above. Detailed plans and plan views shall have precedence over general plans. 2-5.2.1 Precedence of Contract Documents, add the following: Where CALTRANS specifications are used to modify the SSPWC or added to the SSPWC by any of the contract RN- Revised 6/15/17 Contract No. 6335 Page 58 of 176 documents the CALTRANS specifications shall have precedence only in reference to the materials and construction materials referred to in the CALTRANS specifications. The Invitation to Bid, Contract for Public Works, Part 1 of these Supplemental Provisions and Part 1 of the SSPWC, in the order of precedence in Section 2-5.2 of the SSPWC, shall prevail over the CALTRANS specifications in all other matters. 2-5.3 Submittals. 2-5.3.1 General. Submittals shall be provided, at the Contractor's expense, as required in 2-5.3.2, 2-5.3.3 and 2-5.3.4, when required by the Plans or Special Provisions, or when requested by the Engineer. Materials shall neither be furnished nor fabricated, nor shall any work for which submittals are required by performed, before the required submittals have been reviewed and accepted by the Engineer. Neither review nor acceptance of submittals by the Engineer shall relieve the Contractor from responsibility for errors, omissions, or deviations from the Contract Documents, unless such deviations were specifically called to the attention of the Engineer in the letter of transmittal. The Contractor shall be responsible for the correctness of the submittals. The Contractor shall allow a minimum of 20 working days for review of submittals unless otherwise specified in the Special Provisions. Each submittal shall be accompanied by a letter of transmittal. Each submittal shall be consecutively numbered. Resubmittals shall be labeled with the number of the original submittal followed by an ascending alphabetical designation (e.g. The label '4-C' would indicate the third instance that the fourth submittal had been given to the Engineer). Each sheet of each submittal shall be consecutively numbered. Each set of shop drawings and submittals shall be accompanied by a letter of transmittal on the Contractor's letterhead. The Letter of Transmittal shall contain the following: 1.Project title and Agency contract number. 2.Number of complete sets. 3.Contractor's certification statement. 4.Specification section number(s) pertaining to material submitted for review. 5.Submittal number (Submittal numbers shall be consecutive including subsequent submittals for the same materials.) 6.Description of the contents of the submittal. 7.Identification of deviations from the contract documents. When submitted for the Engineer's review, Shop Drawings shall bear the Contractor's certification that the Contractor has reviewed, checked, and approved the Shop Drawings and that they are in conformance with the requirements of the Contract Documents. The Contractor shall subscribe to and shall place the following certification on all submittals: "I hereby certify that the (equipment, material) shown and marked in this submittal is that proposed to be incorporated into this Project, is in compliance with the Contract Documents, can be installed in the allocated spaces, and is submitted for approval." glk tA, Revised 6/15/17 Contract No. 6335 Page 59 of 176 By: Title: Date: Company Name: 2-5.3.2 Working Drawings. Working drawings are drawings showing details not shown on the Plans which are required to be designed by the Contractor. Working drawings shall be of a size and scale to clearly show all necessary details. Six copies and one reproducible shall be submitted. If no revisions are required, three of the copies will be returned to the Contractor. If revisions are required, the Engineer will return one copy along with the reproducible for resubmission. Upon acceptance, the Engineer will return two of the copies to the Contractor and retain the remaining copies and the reproducible. Working drawings are required in the following sections: TABLE 2-5.3.2 (A) Item Section Title Subject Number 1 7-10.4.1 Safety Orders Trench Shoring 2 207-2.5 Joints Reinforced Concrete Pipe 3 207-8.4 Joints Vitrified Clay Pipe 4 207-10.2.1 General Fabricated Steel Pipe 5 300-3.2 Cofferdams Structure Excavation & Backfill 6 303-1.6.1 General Falsework 7 303-1.7.1 General Placing Reinforcement 8 303-3.1 General Prestressed Concrete Construction 9 304-1.1.1 Shop Drawings Structural Steel 10 304-1.1.2 Falsework Plans Structural Steel 11 304-2.1 General Metal Hand Railings 12 306-2.1 General Jacking Operations 13 306-3.1 General Tunneling Operations 14 306-3.4 Tunnel Supports Tunneling Operations 15 306-6 Remodeling Existing Sewer Polyethylene Liner Installation Facilities 16 306-8 Microtunneling Microtunneling Operations 17 307-4.3 Controller Cabinet INirina Diaarams Traffic Signal Construction Working drawings listed above as Items 5, 6, 8, 9, 10, 12, 13, 14 and 16 shall be prepared by a Civil or Structural Engineer registered by the State of California. 2-6.3.3 Shop Drawings. Shop drawings are drawings showing details of manufactured or assembled products proposed to be incorporated into the Work. Shop drawings required shall be as specified in the Special Provisions. 2-5.3.4 Supporting Information. Supporting information is information required by the Specifications for the purposes of administration of the Contract, analysis for verification of conformance with the Specifications, the operation and maintenance of a manufactured product or system to be Constructer] as part of thp Work, and other infrwmation as may be required hy the Engineer. Six copies of the supporting information shall be submitted to the Engineer prior to the start of the Work unless otherwise specified in the Special Provisions or directed by the Engineer. Revised 6/15/17 Contract No. 6335 Page 60 of 176 Supporting information for systems shall be bound together and include all manufactured items for the system. If resubmittal is not required, three copies will be returned to the Contractor. Supporting information shall consist of the following and is required unless otherwise specified in the Special Provisions: 1.List of Subcontractors per 2-3.2. 2.List of Materials per 4-1.4. 3.Certifications per 4-1.5. 4.Construction Schedule per 6-1. 5.Confined Space Entry Program per 7-10.4.4. 6.Concrete mix designs per 201-1.1. 7.Asphalt concrete mix designs per 203-6.1. 8.Data, including, but not limited to, catalog sheets, manufacturer's brochures, technical bulletins, specifications, diagrams, product samples, and other information necessary to describe a system, product or item. This information is required for irrigation systems, street lighting systems, and traffic signals, and may also be required for any product, manufactured item, or system. 2-5.4 Record Drawings. The Contractor shall provide and keep up-to-date a complete "as-built" record set of blue-line prints, which shall be corrected in red daily and show every change from the original drawings and specifications and the exact "as-built" locations, sizes and kinds of equipment, underground piping, valves, and all other work not visible at surface grade. Prints for this purpose may be obtained from the Agency at cost. This set of drawings shall be kept on the job and shall be used only as a record set and shall be delivered to the Engineer within ten (10) days of completion of the work. Payment for performing the work required by Section 2-5.4 shall be included in the various bid items and no additional payment will be made therefore. 2-6 WORK TO BE DONE. The Contractor shall perform all work necessary to complete the Contract in a satisfactory manner. Unless otherwise provided, the Contractor shall furnish all materials, equipment, tools, labor, and incidentals necessary to complete the Work. 2-7 SUBSURFACE DATA. All soil and test hole data, water table elevations, and soil analyses shown on the drawings or included in the Specifications apply only at the location of the test holes and to the depths indicated. Soil test reports for test holes which have been drilled are available for inspection at the office of the Engineer. Any additional subsurface exploration shall be done by Bidders or the Contractor at their own expense. The indicated elevation of the water table is that which existed on the date when test hole data was determined. It is the Contractor's responsibility to determine and allow for the elevation of groundwater at the date of project construction. A difference in elevation between groundwater shown in soil boring logs and groundwater actually encountered during construction will not be considered as a basis for extra work. 2-8 RIGHT-OF-WAY. Rights-of-way, easements, or rights-of-entry for the Work will be provided by the Agency. Unless otherwise provided, the Contractor shall make arrangements, pay for, and assume all responsibility for acquiring, using, and disposing of additional work areas and facilities temporarily required. The Contractor shall indemnify and hold the Agency harmless from all claims for damages caused by such actions. taw. —1- Revised 6/15/17 Contract No. 6335 Page 61 of 176 2-9 SURVEYING. 2-9.1 Permanent Survey Markers. The Contractor shall not cover or disturb permanent survey monuments or benchmarks without the consent of the Engineer. Where the Engineer concurs, in writing, with the Contractor that protecting an existing monument in place is impractical, the Contractor shall employ a licensed land surveyor or a registered civil engineer authorized to practice land surveying within the State of California, hereinafter Surveyor, to establish the location of the monument before it is disturbed. The Contractor shall have the monument replaced by the Surveyor no later than thirty (30) days after construction at the site of the replacement is completed. The Surveyor shall file corner record(s) as required by §§ 8772 and 8773, et seq. of the California Business and Professions Code. When a change is made in the finished elevation of the pavement of any roadway in which a permanent survey monument is located, the Contractor shall adjust the monument frame and cover to the new grade within 7 days of paving unless the Engineer shall approve otherwise. Monument frames and covers shall be protected during street sealing or painting projects or be cleaned to the satisfaction of the Engineer. 2-9.2 Survey Service. The Contractor shall hire and pay for the services of a Surveyor, hereinafter Surveyor to perform all work necessary for establishing control, construction staking, records research and all other surveying work necessary to construct the work, provide surveying services as required herein and provide surveying, drafting and other professional services required to satisfy the requirements of the Land Surveyors Act. Surveyor shall be resident on the site during all surveying operations and shall personally supervise and certify the surveying work. 2-9.2.1 Submittal of Surveying Data. All surveying data submittals shall conform to the requirements of Section 2-5.3.3, "Submittals", herein. The Contractor shall submit grade sheets to the Engineer before commencing work in the area affected by the grade sheets. The Contractor shall submit field notes for all surveying required herein to the Engineer within ten days of performing the survey. All surveying field notes, grade sheets and survey calculations shall be submitted in bound form on 215mm by 280 mm (8h/2" by 11") paper. The field notes, calculations and supporting data shall be clear and complete. Supporting data shall include all maps, affidavits, plats, field notes from earlier surveys and all other evidence used by the Surveyor to determine the location of the monuments set. The field notes and calculations will be labeled with name of the Surveyor, the party chief, the field crewmembers and the author of the field notes or calculations. They shall be annotated with the date of observation or calculation, be numbered with consecutive page numbers and shall be readable without resort to any electronic aid, computer program or documentation for any computer program. The field notes shall be prepared in conformance with the CALTRANS "Surveys Manual". The Contractor shall have a Record of Survey prepared by the Surveyor and file it in conformance with §§ 8700 - 8805 of the State of California Business and Professions Code when the Surveyor performs any surveying that such map is required under §§ 8762 of the State of California Business and Professions Code and whenever the Surveyor shall establish, set or construct any permanent survey monument. SDRS drawing M-10 type monuments, bolts, spikes, leaded tacks and nails (when set in concrete), iron pipes, reinforcing steel and all monuments and marks that are at, or accessory to, property corners and street centerlines are permanent survey monuments. The Record of Survey shall show all monuments set, control monuments used, the basis of bearings and all other data needed to determine the procedure of survey and the degree of accuracy attained by the field surveying including the unadjusted ratio of closure. The unadjusted ratio of closure shall not exceed 1 part in 40,000. The record of survey shall show the location and justification of location of all permanent monuments set and their relation to the street right-of-way. Record(s) of —1- Revised 6/15/17 Contract No. 6335 Page 62 of 176 Survey(s) shall be submitted for the Engineer's review and approval before submittal to the County Surveyor and before submittal to the County Recorder. 2-9.2.2 Survey Requirements. Stakes shall be set at offsets approved by the Engineer at no greater intervals than specified in TABLE 2-9.2.2(A) as measured along the project stationing. Stakes shall be set to show the location and grade of future curbs adjacent to traffic signal locations where the curb is not being built as a part of this contract. Staking and marking shall be completed by the Surveyor and inspected and approved by the Engineer before the start of construction in the area marked. Centerline monument shall have the disk stamped with the date the monument was set and the registration number of the Surveyor. Habitat mitigation sites and other areas to be preserved that are shown on the plans shall be staked and flagged prior to the start of any other activities within the limits of the work. When curb and gutter does not exist and is not being installed as a part of the project the location of adjacent facilities being constructed as a part of the contract the Contractor shall place stakes defining the horizontal and vertical location of such adjacent utility vaults, poles or other facilities that are being installed as parts of, or adjunct to, the project either by the Contractor and/or those noted on the plans as to be installed by others. TABLE 2-9.2.2(A) Survey Re uirements for Construction Stakin Feature Staked Stake Description 0 Centerline or Parallel to Centerline Spacing®, ® Lateral Spacing e, ® Setting Tolerance (Within) Street Centerline SDRS M-10 Monument £1000', Street Intersections, Begin and end of curves, only when shown on the plans on street centerline 0.02' Horizontal, also see Section 2-9.2.1 herein Clearing Lath in soil, painted line D n PCC & AC surfaces lath - lntervisible, £ 50' on tangents & £ 25' on curves, Painted line - continuous at clearing line 1' Horizontal Slope RP + Marker Stake Intervisible and £ 50' Grade Breaks & £ 25' 0.1' Vertical & Horizontal Fence RP + Marker Stake £ 200' on tangents, £ 50' on curves when R³ 1000' & 25' on curves when R£ 1000' N/A (constant offset) 0.1' Horizontal Rough Grade Cuts or Fills ³ 10 m (33') RP + Marker Stake £ 50' N/A 0.1' Vertical & Horizontal Final Grade (includes top of: Basement soil, subbase and base) RP + Marker Stake, Blue- top in grading area £ 50' on tangents & curves when R³ 1000' & £ 25' on curves when R < 1000' £ 22' 3je Horizontal & 1/4" Vertical Asphalt Pavement Finish Course RP, paint on previous course £ 25' or as per the intersection grid points shown on the plan whichever provides the denser information edge of pavement, paving pass ,width, crown line & grade breaks 3/8" Horizontal & 1/4" Vertical Drainage Structures, Pipes & similar Facilities®, 0 RP + Marker Stake intervisible & < 25', beginning and end, BC & EC of facilities, Grade breaks, Alignment breaks, Junctions, Inlets & similar facilities, Risers & similar facilities (except plumbing), Skewed cut-off lines as appropriate 3/8" Horizontal & 1/4" Vertical •‘• lt.41 -r- Revised 6/15/17 Contract No. 6335 Page 63 of 176 Feature Staked Curb Stake Description 0 RP + Marker Stake Centerline or Parallel to Centerline Spacing®, 0 < 25', BC & EC, at 1/4& %A & 3/46. on curb returns & at beginning & end Lateral Spacing e, 0 (constant offset) Setting Tolerance (Within) 3/8" Horizontal & 1/4" Vertical Traffic Signal 0 Vertical locations shall be based on the ultimate elevation of curb and sidewalk Signal Poles & Controller 0 RP + Marker Stake at each pole & controller location as appropriate 3/8" Horizontal & 1/4" Vertical Junction Box 0 RP + Marker Stake at each junction box location as appropriate 3/8" Horizontal & 1/4" Vertical Conduit 0 RP + Marker Stake < 60' on tangents & curves when R> 1000' & £ 25' on curves when R £ 1000' or where grade £ 0.30% as appropriate 3/8" Horizontal & when depth cannot be measured from existing pavement 1/4" Vertical Minor Structure 0 RP + Marker Stake + Line Stake for catch basins: at centerline of box, ends of box & wings & at each end of the local depression OD as appropriate 3/8. Horizontal & 1/4" Vertical (when vertical data needed) Abutment Fill RP + Marker Stake + Line Stake £ 50' & along end slopes & conic transitions as appropriate 0.1' Vertical & Horizontal Wall 0 RP + Marker Stake + Line Point +Guard Stake £ 50' and at beginning & end of: each wall, BC & EC, layout line angle points, changes in footing dimensions &/or elevation & wall height as appropriate Ye Horizontal &1/4" Vertical Major Structure (i) Footings, Bents, Abutments & Wingwalls RP + Marker Stake + Line Point +Guard Stake 10' to 33' as required by the Engineer, BC & EC, transition points & at beginning & end. Elevation points on footings at bottom of columns as appropriate 3/8" Horizontal & 1/4" Vertical Superstructures RP 10' to 33' sufficient to use string lines, BC & EC, transition points & at beginning & end. Elevation points on footings at bottom of columns as appropriate 3/8" Horizontal & 1/4" Vertical Miscellaneous CD Contour Grading 0 RP + Marker Stake £ 50' along contour line 0.1' Vertical & Horizontal Utilities 0, 0 RP + Marker Stake < 50' on tangents & curves when R> 1000' & £ 25' on curves when R £ 1000' or where grade £ 0.30% as appropriate 3/8" Horizontal & 1/4" Vertical Channels, Dikes & Ditches 0 RP + Marker Stake I intervisible & £ 100', BC & EC of facilities, Grade breaks, Alignment breaks, Junctions, Inlets & similar facilities as appropriate 0.1' Horizontal & 1/4" Vertical Signs 0 RP + Marker Stake + Line Point +Guard Stake At sign location Line point 0.1' Vertical & Horizontal Subsurface Drains 0 RP + Marker Stake intervisible & £ 50', BC & EC of facilities, Grade breaks, Alignment breaks, Junctions, Inlets & similar facilities, Risers & similar facilities as appropriate 0.1' Horizontal & 1/4" Vertical Overside Drains 0 RP + Marker Stake longitudinal location At beginning & end 0.1' Horizontal & 1/4" Vertical Markers 0 RP + Marker Stake for asphalt street surfacing £ 50' on tangents & curves when R³ 1000' & £ 25' on curves when R £ 1000'. At marker location(s) 1/4" Horizontal Railings & Bai riei s J.) RP + Marker Stake At beginning & end and £ 50' on tangents & curves when R ³ 1000' & < 25' on curves when R 5_ b oo' at railing & ri Darner location(s) 3/8" Horizontal & vertical AC Dikes (D RP + Marker 1 Stake At beginning & end as appropriate 0.1' Horizontal & Vertical Revised 6/15/17 Contract No. 6335 Page 64 of 176 Feature Staked Stake Description 0 Centerline or Parallel to Centerline Spacing0, es Lateral Spacing 0, 0 Setting Tolerance (Within) Box Culverts 10' to 33' as required by the Engineer, BC & EC, transition points & at beginning & end. Elevation points on footings & at invert as appropriate 3/e." Horizontal & 1/4" Vertical Pavement Markers@ RP 200' on tangents, 50' on curves when R ³ 1000' & 25' on curves when R lc 1000'. For PCC surfaced streets lane cold joints will suffice at pavement marker location(s) 1/4" Horizontal @ Staking for feature may be omitted when adjacent marker stakes reference the offset and elevation of those features and the accuracy requirements of the RP meet the requirements for the feature. CD Reference points shall be sufficiently durable and set securely enough to survive with accuracy intact throughout the installation & inspection of the features or adjacent facilities for which they provide control. RP means reference point for the purposes of this table. •Perpendicular to centerline. •Some features are not necessarily parallel to centerline but are referenced thereto. O Multi-plane surfaced features shall be staked so as to provide line & grade information for each plane of the feature. 0 ³ means greater than, or equal to, the number following the symbol. £ means less than, or equal to, the number following the symbol. O The cut datum for storm drainage & sanitary sewer pipes & similar structures shall be their invert. The cut datum for all other utilities shall be the top of their pipe or conduit. All guard stakes, line stakes and lath shall be flagged. Unless otherwise approved by the Engineer flagging, paint and marking cards shall be the color specified in TABLE 2-9.2.2(B) TABLE 2-9.2.2(B) Survey Stake Color Code for Construction Stakin Type of Stake Description Color* Horizontal Control Coordinated control points, control lines, control reference points, centerline, alignments, etc. White/Red Vertical Control Bench marks White/Orange Clearing Limits of clearing Yellow/Black Grading Slope, intermediate slope, abutment fill, rough grade, contour grading, final grade, etc. Yellow Structure Bridges, sound and retaining walls, box culverts, etc. White Drainage, Sewer, Curb Pipe culverts, junction boxes, drop inlets, headwalls, sewer lines, storm drains, slope protection, curbs, gutters, etc. Blue Right-of-Way Fences, R/ W lines, easements, property monuments, etc. White/Yellow Miscellaneous Signs, railings, barriers, lighting, etc. Orange * Flagging and marking cards, if used. 2-9.2.3 Payment for Survey. Payment for work performed to satisfy the requirements of Sections 2-9.1 through 2-9.2.2 shall be included in the actual bid items requiring the survey work and no additional payment will be made. Extension of unit prices for extra work shall include full compensation for attendant survey work and no additional payment will be made. Payment for the replacement of disturbed monuments and the filing of records of survey and/or corner records, including filing fees, shall be incidental to the work necessitating the disturbance of said monuments and no additional payment will be made. 2-9.3 Private Engineers. Surveying by private engineers on the Work shall conform to the quality and practice required by the Engineer. 2-9.4 Line and Grade. All work shall conform to the lines, elevations, and grades shown on the Plans. tad" —I- Revised 6/15/17 Contract No. 6335 Page 65 of 176 Three consecutive points set on the same slope shall be used together so that any variation from a straight grade can be detected. Any such variation shall be reported to the Engineer. In the absence of such report, the Contractor shall be responsible for any error in the grade of the finished work. Grades for underground conduits will be set at the surface of the ground. The Contractor shall transfer them to the bottom of the trench. 2-10 AUTHORITY OF BOARD AND ENGINEER. The Board has the final authority in all matters affecting the Work. Within the scope of the Contract, the Engineer has the authority to enforce compliance with the Plans and Specifications. The Contractor shall promptly comply with instructions from the Engineer or an authorized representative. The decision of the Engineer is final and binding on all questions relating to: quantities; acceptability of material, equipment, or work; execution, progress or sequence of work; and interpretation of the Plans, Specifications, or other drawings. This shall be precedent to any payment under the Contract, unless otherwise ordered by the Board. 2-10.1 Availability of Records. The Contractor shall, at no charge to the Agency, provide copies of all records in the Contractor's or subcontractor's possession pertaining to the work that the Engineer may request. 2-10.2 Audit and Inspection. Contractor agrees to maintain and/or make available, to the Engineer, within San Diego County, accurate books and accounting records relative to all its activities and to contractually require all subcontractors to this Contract to do the same. The Engineer shall have the right to monitor, assess, and evaluate Contractor's and its subcontractors' performance pursuant to this Agreement, said monitoring, assessments, and evaluations to include, but not be limited to, audits, inspection of premises, reports, contracts, subcontracts and interviews of Contractor's staff and the staff of all subcontractors to this contract. At any time during normal business hours and as often as the Engineer may deem necessary, upon reasonable advance notice, Contractor shall make available to the Engineer for examination, all of its, and all subcontractors to this contract, records with respect to all matters covered by this Contract and will permit the Engineer to audit, examine, copy and make excerpts or transcripts from such data and records, and to make audits of all invoices, materials, payrolls, records of personnel, and other data relating to all matters covered by this Contract. However, any such activities shall be carried out in a manner so as to not unreasonably interfere with Contractor's ongoing business operations. Contractor and all subcontractors to this contract shall maintain such data and records for as long as may be required by applicable laws and regulations. 2-11 INSPECTION. The Work is subject to inspection and approval by the Engineer. The Contractor shall notify the Engineer before noon of the working day before inspection is required. Work shall be done only in the presence of the Engineer, unless otherwise authorized. Any work done without proper inspection will be subject to rejection. The Engineer and any authorized representatives shall at all times have access to the Work during its construction at shops and yards as well as the project site. The Contractor shall provide every reasonable facility for ascertaining that the materials and workmanship are in accordance with these specifications. Inspection of the Work shall not relieve the Contractor of the obligation to fulfill all conditions of the Contract. lirr Revised 6/15/17 Contract No. 6335 Page 66 of 176 SECTION 3 - CHANGES IN WORK 3-1 CHANGES REQUESTED BY THE CONTRACTOR. 3-1.1 General. Changes in the Plans and Specifications, requested in writing by the Contractor, which do not materially affect the Work and which are not detrimental to the Work or to the interests of the Agency, may be granted by the Engineer. Nothing herein shall be construed as granting a right to the Contractor to demand acceptance of such changes. 3-1.2 Payment for Changes Requested by the Contractor. If such changes are granted, they shall be made at a reduction in cost or no additional cost to the Agency. 3-2 CHANGES INITIATED BY THE AGENCY. 3-2.1 General. The Agency may change the Plans, Specifications, character of the work, or quantity of work provided the total arithmetic dollar value of all such changes, both additive and deductive, does not exceed 25 percent of the Contract Price. Should it become necessary to exceed this limitation, the change shall be by written Supplemental Agreement between the Contractor and Agency, unless both parties agree to proceed with the change by Change Order. Change Orders shall be in writing and state the dollar value of the change or established method of payment, any adjustment in contract time of completion, and when negotiated prices are involved, shall provide for the Contractor's signature indicating acceptance. 3-2.2 Payment. 3-2.2.1 Contract Unit Prices. If a change is ordered in an item of work covered by a Contract Unit Price, and such change does not involve substantial change in character of the work from that shown on the Plans or specified in the Specifications, then an adjustment in payment will be made. This adjustment will be based upon the increase or decrease in quantity and the Contract Unit Price. If the actual quantity of an item of work covered by a Contract Unit Price and constructed in conformance with the Plans and Specifications varies from the Bid quantity by 50 percent or less, payment will be made at the Contract Unit Price. If the actual quantity of said item of work varies from the Bid quantity by more than 50 percent, payment will be made per Section 3-2.2.2 or 3- 2.2.3 as appropriate. If a change is ordered in an item of work covered by a Contract Unit Price, and such change does involve a substantial change in the character of the work from that shown on the Plans or specified in the Specifications, an adjustment in payment will be made per Section 3-2.4. 3-2.2.2 Increases of More Than 50 Percent. Should the actual quantity of an item of work covered by a Contract Unit Price and constructed in conformance with the Plans and Specifications, exceed the Bid quantity by more than 50 percent, payment for the quantity in excess of 150 percent of the Bid quantity will be made on the basis of an adjustment in the Contract Unit Price mutually agreed to by the Contractor and the Agency, or at the option of the Engineer, on the basis of Extra Work per Section 3-3. The Extra Work per Section 3-3, basis of payment, shall not include fixed costs. Fixed costs shall be deemed to have been recovered by the Contractor through payment for 150 percent of the Bid quantity at the Contract Unit Price. —1- Revised 6/15/17 Contract No. 6335 Page 67 of 176 3-2.2.3 Decreases of More Than 60 Percent. Should the actual quantity of an item of work covered by a Contract Unit Price, and constructed in conformance with the Plans and Specifications, be less than 50 percent of the Bid quantity, an adjustment in payment will not be made unless so requested in writing by the Contractor. If the Contractor so requests, payment will be made on the basis of an adjustment in the Contract Unit Price mutually agreed to by the Contractor and the Agency, or at the option of the Engineer, on the basis of Extra Work per Section 3-3; however, in no case will payment be less than would be made for the actual quantity at the Contract Unit Price nor more than would be made for 50 percent of the Bid quantity at the Contract Unit Price. 3-2.3 Stipulated Unit Prices. Stipulated Unit Prices are unit prices established by the Agency in the Contract Documents as distinguished from Contract Unit Prices submitted by the Contractor. Stipulated Unit Prices may be used for the adjustment of Contract changes when so specified in the Special Provisions. 3-2.4 Agreed Prices. Agreed Prices are prices for new or unforeseen work, or adjustments in Contract Unit Prices per Section 3-2.2, established by mutual agreement between the Contractor and the Agency. If mutual agreement can not be reached, the Engineer may direct the Contractor to proceed on the basis of Extra Work in accordance per Section 3-3, except as otherwise specified in Sections 3-2.2.2 and 3-2.2.3. 3.2.4.1 Schedule of Values. Prior to construction, Contractor shall provide a schedule of values for all lump sum bid items that shall be used for the purpose of progress payments. The prices shall be valid for the purpose of change orders to the project. 3.2.5 Eliminated Items. Should any Bid item be eliminated in its entirety, payment will be made to the Contractor for its actual costs incurred in connection with the eliminated item prior to notification in writing from the Engineer so stating its elimination. If material conforming to the Plans and Specifications is ordered by the Contractor for use in the eliminated item prior to the date of notification of elimination by the Engineer, and if the order for that material can not be canceled, payment will be made to the Contractor for the actual cost of the material. In this case, the material shall become the property of the Agency. Payment will be made to the Contractor for its actual costs for any further handling. If the material is returnable, the material shall be returned and payment will be made to the Contractor for the actual cost of charges made by the supplier for returning the material and for handling by the Contractor. Actual costs, as used herein, shall be computed on the basis of Extra Work per Section 3-3. 3-3 EXTRA WORK. 3-3.1 General. New or unforeseen work will be classified as "extra work" when the Engineer determines that it is not covered by Contract Unit Prices or stipulated unit prices. 3-3.2 Payment. 3-3.2.1 General. When the price for the extra work cannot be agreed upon, the Agency will pay for the extra work based on the accumulation of costs as provided herein. 3-3.2.2 Basis for Establishing Costs. (a) Labor. The costs of labor will be the actual cost for wages of workers performing the extra work at the time the extra work is done, plus employer payments of payroll taxes, workers 41P), twat Revised 6/15/17 Contract No. 6335 Page 68 of 176 compensation insurance, liability insurance, health and welfare, pension, vacation, apprenticeship funds, and other direct costs, resulting from Federal, State, or local laws, as well as assessments or benefits required by lawful collective bargaining agreements. The use of a labor classification which would increase the extra work cost will not be permitted unless the Contractor establishes the necessity for such additional costs. Labor costs for equipment operators and helpers shall be reported only when such costs are not included in the invoice for equipment rental. The labor cost for foremen shall be proportioned to all of their assigned work and only that applicable to extra work will be paid. Nondirect labor costs, including superintendence, shall be considered part of the markup of Section 3-3.2.3 (a). (b)Materials. The cost of materials reported shall be at invoice or lowest current price at which such materials are locally available and delivered to the job site in the quantities involved, plus sales tax, freight, and delivery. The Agency reserves the right to approve materials and sources of supply, or to supply materials to the Contractor if necessary for the progress of the Work. No markup shall be applied to any material provided by the Agency. (c)Tool and Equipment Rental. No payment will be made for the use of tools which have a replacement value of $200 or less. Regardless of ownership, the rates and right-of-way delay factors to be used in determining rental and delay costs shall be the edition of the, "Labor Surcharge and Equipment Rental Rates" published by CALTRANS, current at the time of the actual use of the tool or equipment. The right- of-way delay factors therein shall be used as multipliers of the rental rates for determining the value of costs for delay to the Contractor and subcontractors, if any. The labor surcharge rates published therein are not a part of this contract. The rental rates paid shall include the cost of fuel, oil, lubrication, supplies, small tools, necessary attachments, repairs and maintenance of any kind, depreciation, storage, insurance, and all incidentals. Necessary loading and transportation costs for equipment used on the extra work shall be included. If equipment is used intermittently and, when not in use, could be returned to its rental source at less expense to the Agency than holding it at the Work site, it shall be returned, unless the Contractor elects to keep it at the Work site, at no expense to the Agency. All equipment shall be acceptable to the Engineer, in good working condition, and suitable for the purpose for which it is to be used. Manufacturer's ratings and approved modifications shall be used to classify equipment and it shall be powered by a unit of at least the minimum rating recommended by the manufacturer. The reported rental time for equipment already at the Work site shall be the duration of its use on the extra work. This time begins when equipment is first put into actual operation on the extra work, plus the time required to move it from its previous site and back, or to a closer site. (d)Other Items. The Agency may authorize other items which may be required on the extra work, including labor, services, material, and equipment. These items must be different in their .1k —1- Revised 6/15/17 Contract No. 6335 Page 69 of 176 nature from those required for the Work, and be of a type not ordinarily available from the Contractor or Subcontractors. Invoices covering all such items in detail shall be submitted with the request for payment. (e) Invoices. Vendors' invoices for material, equipment rental and other expenditures shall be submitted with the request for payment. If the request for payment is not substantiated by invoices or other documentation, the Agency may establish the cost of the item involved at the lowest price which was current at the time of the report. 3-3.2.3 Markup. (a) Work by Contractor. The following percentages shall be added to the Contractor's costs and shall constitute the markup for all overhead and profits: 1) Labor 20 2) Materials ... 15 3) Equipment Rental 15 4) Other Items and Expenditures 15 To the sum of the costs and markups provided for in this section, 1 percent shall be added as compensation for bonding. (b) Work by Subcontractor. When all or any part of the extra work is performed by a Subcontractor, the markup established in Section 3-3.2.3(a) shall be applied to the Subcontractor's actual cost of such work. A markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of $5,000 of the subcontracted portion of the extra work may be added by the Contractor. 3-3.3 Daily Reports by Contractor. When the price for the extra work cannot be agreed upon, the Contractor shall submit a daily report to the Engineer on forms approved by the Agency. Included are applicable delivery tickets, listing all labor, materials, and equipment involved for that day, and other services and expenditures when authorized. Payment for extra work will not be made until such time that the Contractor submits completed daily reports and all supporting documents to the Engineer. Failure to submit the daily report by the close of the next working day may waive any rights for that day. An attempt shall be made to reconcile the report daily, and it shall be signed by the Engineer and the Contractor. In the event of disagreement, pertinent notes shall be entered by each party to explain points which cannot be resolved immediately. Each party shall retain a signed copy of the report. Reports by Subcontractors or others shall be submitted through the Contractor. The report shall: 1.Show names of workers, classifications, and hours worked. 2.Describe and list quantities of materials used. 3.Show type of equipment, size, identification number, and hours of operation, including loading and transportation, if applicable. 4.Describe other services and expenditures in such detail as the Agency may require. te4: Revised 6/15/17 Contract No. 6335 Page 70 of 176 3-4 CHANGED CONDITIONS. The Contractor shall promptly notify the Engineer of the following Work site conditions (hereinafter called changed conditions), in writing, upon their discovery and before they are disturbed: 1.Subsurface or latent physical conditions differing materially from those represented in the Contract; 2.Unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character being performed; and 3.Material differing from that represented in the Contract which the Contractor believes may be hazardous waste, as defined in Section 25117 of the Health and Safety Code, that is required to be removed to a Class I, Class II, or Class III disposal site in accordance with provisions of existing law. The Engineer will promptly investigate conditions which appear to be changed conditions. If the Engineer determines that conditions are changed conditions and they will materially affect performance time, the Contractor, upon submitting a written request, will be granted an extension of time subject to the provisions of 6-6. If the Engineer determines that the conditions do not justify an adjustment in compensation, the Contractor will be notified in writing. This notice will also advise the Contractor of its obligation to notify the Engineer in writing if the Contractor disagrees. The Contractor's failure to give notice of changed conditions promptly upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith. The Contractor shall not be entitled to the payment of any additional compensation for any act, or failure to act, by the Engineer, including failure or refusal to issue a change order, or for the happening of any event, thing, occurrence, or other cause, unless the Contractor shall have first given the Engineer due written notice of potential claim as hereinafter specified. Compliance with this section shall not be required as a prerequisite to notice provisions in Section 6-7.3 Contract Time Accounting, nor to any claim that is based on differences in measurement or errors of computation as to contract quantities. The written notice of potential claim for changed conditions shall be submitted by the Contractor to the Engineer upon their discovery and prior to the time that the Contractor performs the work giving rise to the potential claim. The Contractor's failure to give written notice of potential claim for changed conditions to the agency upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith. The Contractor shall provide the City with a written document containing a description of the particular circumstances giving rise to the potential claim, the reasons for which the Contractor believes additional compensation may be due and nature of any and all costs involved within 20 working days of the date of service of the written notice of potential claim for changed conditions. Verbal notifications are disallowed. The potential claim shall include the following certification relative to the California False Claims Act, Government Code Sections 12650-12655. "The undersigned certifies that the above statements are made in full cognizance of the California False Claims Act, Government Code Sections 12650-12655. The undersigned further understands and agrees that this potential claim, unless resolved, must be restated as a claim in response to the City's proposed final estimate in order for it to be further considered." taw. —r- Revised 6/15/17 Contract No. 6335 Page 71 of 176 By: Title: Date: Company Name: The Contractor's estimate of costs may be updated when actual costs are known. The Contractor shall submit substantiation of its actual costs to the Engineer within 20 working days after the affected work is completed. Failure to do so shall be sufficient cause for denial of any claim subsequently filed on the basis of said notice of potential claim. It is the intention of this section that differences between the parties arising under and by virtue of the contract be brought to the attention of the Engineer at the earliest possible time in order that such matters be settled, if possible, or other appropriate action promptly taken. 3-6 DISPUTED WORK. The Contractor shall give the agency written notice of potential claim prior to commencing any disputed work. Failure to give said notice shall constitute a waiver of all claims in connection therewith. If the contractor and the agency are unable to reach agreement on disputed work, the Agency may direct the contractor to proceed with the work. Prior to proceeding with dispute resolution pursuant to Public Contract Code provisions specified hereinafter, the contractor shall attempt to resolve all disputes informally through the following dispute resolution chain of command: 1.Project Inspector 2.Construction Manager 3.Deputy City Engineer, Construction Management & Inspection 4.City Engineer 5.City Manager The Contractor shall submit a complete report within 20 working days after completion of the disputed work stating its position on the claim, the contractual basis for the claim, along with all documentation supporting the costs and all other evidentiary materials. At each level of claim or appeal of claim the City will, within 10 working days of receipt of said claim or appeal of claim, review the Contractor's report and respond with a position, request additional information or request that the Contractor meet and present its report. When additional information or a meeting is requested the City will provide its position within 10 working days of receipt of said additional information or Contractor's presentation of its report. The Contractor may appeal each level's position up to the City Manager after which the Contractor may proceed under the provisions of the Public Contract Code. The authority within the dispute resolution chain of command is limited to recommending a resolution to a claim to the City Manager. Actual approval of the claim is subject to the change order provisions in the contract. All claims by the -Contractor shall be resolved in accordance with Public Contract Code section 9204, which is set forth below: Revised 6/15/17 Contract No. 6335 Page 72 of 176 9204. (a) The Legislature finds and declares that it is in the best interests of the state and its citizens to ensure that all construction business performed on a public works project in the state that is complete and not in dispute is paid in full and in a timely manner. (b) Notwithstanding any other law, including, but not limited to, Article 7.1 (commencing with Section 10240) of Chapter 1 of Part 2, Chapter 10 (commencing with Section 19100) of Part 2, and Article 1.5 (commencing with Section 20104) of Chapter 1 of Part 3, this section shall apply to any claim by a contractor in connection with a public works project. (c) For purposes of this section: (1) "Claim" means a separate demand by a contractor sent by registered mail or certified mail with return receipt requested, for one or more of the following: (A)A time extension, including, without limitation, for relief from damages or penalties for delay assessed by a public entity under a contract for a public works project. (B)Payment by the public entity of money or damages arising from work done by, or on behalf of, the contractor pursuant to the contract for a public works project and payment for which is not otherwise expressly provided or to which the claimant is not otherwise entitled. (C)Payment of an amount that is disputed by the public entity. (2) "Contractor" means any type of contractor within the meaning of Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code who has entered into a direct contract with a public entity for a public works project. (3) (A) "Public entity" means, without limitation, except as provided in subparagraph (B), a state agency, department, office, division, bureau, board, or commission, the California State University, the University of California, a city, including a charter city, county, including a charter county, city and county, including a charter city and county, district, special district, public authority, political subdivision, public corporation, or nonprofit transit corporation wholly owned by a public agency and formed to carry out the purposes of the public agency. (B) "Public entity" shall not include the following: (i)The Department of Water Resources as to any project under the jurisdiction of that department. (ii)The Department of Transportation as to any project under the jurisdiction of that department. (iii)The Department of Parks and Recreation as to any project under the jurisdiction of that department. (iv)The Department of Corrections and Rehabilitation with respect to any project under its jurisdiction pursuant to Chapter 11 (commencing with Section 7000) of Title 7 of Part 3 of the Penal Code. (v)The Military Department as to any project under the jurisdiction of that department. (vi)The Department of General Services as to all other projects. (vii)The High-Speed Rail Authority. (4) "Public works project" means the erection, construction, alteration, repair, or improvement of any public structure, building, road, or other public improvement of any kind. (5) "Subcontractor" means any type of contractor within the meaning of Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code who either is in direct contract with a contractor or is a lower tier subcontractor. (d) (1) (A) Upon receipt of a claim pursuant to this section, the public entity to which the claim applies shall conduct a reasonable review of the claim and, within a period not to exceed 45 days. shall provide the claimant a written statement identifying what portion of the claim is disputed and what portion is undisputed. Upon receipt of a claim, a public entity and a contractor may, by mutual agreement, extend the time period provided in this subdivision. (B)The claimant shall furnish reasonable documentation to support the claim. (C)If the public entity needs approval from its governing body to provide the claimant a written statement identifying the disputed portion and the undisputed portion of the claim, and the 41), —1- Revised 6/15/17 Contract No. 6335 Page 73 of 176 governing body does not meet within the 45 days or within the mutually agreed to extension of time following receipt of a claim sent by registered mail or certified mail, return receipt requested, the public entity shall have up to three days following the next duly publicly noticed meeting of the governing body after the 45-day period, or extension, expires to provide the claimant a written statement identifying the disputed portion and the undisputed portion. (D) Any payment due on an undisputed portion of the claim shall be processed and made within 60 days after the public entity issues its written statement. If the public entity fails to issue a written statement, paragraph (3) shall apply. (2) (A) If the claimant disputes the public entity's written response, or if the public entity fails to respond to a claim issued pursuant to this section within the time prescribed, the claimant may demand in writing an informal conference to meet and confer for settlement of the issues in dispute. Upon receipt of a demand in writing sent by registered mail or certified mail, return receipt requested, the public entity shall schedule a meet and confer conference within 30 days for settlement of the dispute. (B)Within 10 business days following the conclusion of the meet and confer conference, if the claim or any portion of the claim remains in dispute, the public entity shall provide the claimant a written statement identifying the portion of the claim that remains in dispute and the portion that is undisputed. Any payment due on an undisputed portion of the claim shall be processed and made within 60 days after the public entity issues its written statement. Any disputed portion of the claim, as identified by the contractor in writing, shall be submitted to nonbinding mediation, with the public entity and the claimant sharing the associated costs equally. The public entity and claimant shall mutually agree to a mediator within 10 business days after the disputed portion of the claim has been identified in writing. If the parties cannot agree upon a mediator, each party shall select a mediator and those mediators shall select a qualified neutral third party to mediate with regard to the disputed portion of the claim. Each party shall bear the fees and costs charged by its respective mediator in connection with the selection of the neutral mediator. If mediation is unsuccessful, the parts of the claim remaining in dispute shall be subject to applicable procedures outside this section. (C)For purposes of this section, mediation includes any nonbinding process, including, but not limited to, neutral evaluation or a dispute review board, in which an independent third party or board assists the parties in dispute resolution through negotiation or by issuance of an evaluation. Any mediation utilized shall conform to the timeframes in this section. (D)Unless otherwise agreed to by the public entity and the contractor in writing, the mediation conducted pursuant to this section shall excuse any further obligation under Section 20104.4 to mediate after litigation has been commenced. (E)This section does not preclude a public entity from requiring arbitration of disputes under private arbitration or the Public Works Contract Arbitration Program, if mediation under this section does not resolve the parties' dispute. (3) Failure by the public entity to respond to a claim from a contractor within the time periods described in this subdivision or to otherwise meet the time requirements of this section shall result in the claim being deemed rejected in its entirety. A claim that is denied by reason of the public entity's failure to have responded to a claim, or its failure to otherwise meet the time requirements of this section, shall not constitute an adverse finding with regard to the merits of the claim or the responsibility or qualifications of the claimant. (4) Amounts not paid in a timely manner as required by this section shall bear interest at 7 percent per annum. (5) If a subcontractor or a lower tier subcontractor lacks legal standing to assert a claim against a public entity because privity of contract does not exist, the contractor may present to the public entity a claim on behalf of a subcontractor or lower tier subcontractor. A subcontractor may request in writing, either on his or her own behalf or on behalf of a lower tier subcontractor, that the contractor present a claim for work which was performed by the subcontractor or by a lower —1- Revised 6/15/17 Contract No. 6335 Page 74 of 176 tier subcontractor on behalf of the subcontractor. The subcontractor requesting that the claim be presented to the public entity shall furnish reasonable documentation to support the claim. Within 45 days of receipt of this written request, the contractor shall notify the subcontractor in writing as to whether the contractor presented the claim to the public entity and, if the original contractor did not present the claim, provide the subcontractor with a statement of the reasons for not having done so. (e)The text of this section or a summary of it shall be set forth in the plans or specifications for any public works project that may give rise to a claim under this section. (1) A waiver of the rights granted by this section is void and contrary to public policy, provided, however, that (1) upon receipt of a claim, the parties may mutually agree to waive, in writing, mediation and proceed directly to the commencement of a civil action or binding arbitration, as applicable; and (2) a public entity may prescribe reasonable change order, claim, and dispute resolution procedures and requirements in addition to the provisions of this section, so long as the contractual provisions do not conflict with or otherwise impair the timeframes and procedures set forth in this section. (g)This section applies to contracts entered into on or after January 1, 2017. (h)Nothing in this section shall impose liability upon a public entity that makes loans or grants available through a competitive application process, for the failure of an awardee to meet its contractual obligations. (i)This section shall remain in effect only until January 1, 2020, and as of that date is repealed, unless a later enacted statute, that is enacted before January 1, 2020, deletes or extends that date. In addition, all claims by Contractor for $375,000 or less shall be resolved in accordance with the procedures in the Public Contract Code, Division 2, Part 3, Chapter 1, Article 1.5 (commencing with Section 20104) which is set forth below ARTICLE 1.5 RESOLUTION OF CONSTRUCTION CLAIMS 20104. (a)(1) This article applies to all public works claims of three hundred seventy-five thousand dollars ($375,000) or less which arise between a contractor and a local agency. (2) This article shall not apply to any claims resulting from a contract between a contractor and a public agency when the public agency has elected to resolve any disputes pursuant to Article 7.1 (commencing with Section 10240) of Chapter 1 of Part 2. (b)(1) "Public work" has the same meaning as in Sections 3100 and 3106 of the Civil Code, except that "public work" does not include any work or improvement contracted for by the state or the Regents of the University of California. (2) "Claim" means a separate demand by the contractor for (A) a time extension, (B) payment of money or damages arising from work done by, or on behalf of, the contractor pursuant to the contract for a public work and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to, or (C) an amount the payment of which is disputed by the local agency. (c)The provisions of this article or a summary thereof shall be set forth in the plans or specifications for any work which may give rise to a claim under this article. (d)This article applies only to contracts entered into on or after January 1, 1991. 20104.2. For any claim subject to this article, the following requirements apply: (a) The claim shall be in writing and include the documents necessary to substantiate the claim. Claims must be filed on or before the date of final payment. Nothing in this subdivision is intended to extend the time limit or supersede notice requirements otherwise provided by contract for the filing of claims. Revised 6/15/17 Contract No. 6335 Page 75 of 176 (b)(1) For claims of less than fifty thousand dollars ($50,000), the local agency shall respond in writing to any written claim within 45 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant. (2)If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of the local agency and the claimant. (3)The local agency's written response to the claim, as further documented, shall be submitted to the claimant within 15 days after receipt of the further documentation or within a period of time no greater than that taken by the claimant in producing the additional information, whichever is greater. (c)(1) For claims of over fifty thousand dollars ($50,000) and less than or equal to three hundred seventy-five thousand dollars ($375,000), the local agency shall respond in writing to all written claims within 60 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant. (2)If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of the local agency and the claimant. (3)The local agency's written response to the claim, as further documented, shall be submitted to the claimant within 30 days after receipt of the further documentation, or within a period of time no greater than that taken by the claimant in producing the additional information or requested documentation, whichever is greater. (d)If the claimant disputes the local agency's written response, or the local agency fails to respond within the time prescribed, the claimant may so notify the local agency, in writing, either within 15 days of receipt of the local agency's response or within 15 days of the local agency's failure to respond within the time prescribed, respectively, and demand an informal conference to meet and confer for settlement of the issues in dispute. Upon a demand, the local agency shall schedule a meet and confer conference within 30 days for settlement of the dispute. (e)Following the meet and confer conference, if the claim or any portion remains in dispute, the claimant may file a claim as provided in Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the claimant submits his or her written claim pursuant to subdivision (a) until the time that claim is denied as a result of the meet and confer process, including any period of time utilized by the meet and confer process. (f)This article does not apply to tort claims and nothing in this article is intended nor shall be construed to change the time periods for filing tort claims or actions specified by Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. 20104.4. The following procedures are established for all civil actions filed to resolve claims subject to this article: (a) Within 60 days, but no earlier than 30 days, following the filing or responsive pleadings, the court shall submit the matter to non-binding mediation unless waived by mutual stipulation of both parties. The mediation process shall provide for the selection within 15 days by both parties of a disinterested third person as mediator, shall be commenced within 30 days of the submittal, and shall be concluded within 15 days from the commencement of the mediation unless a time requirement is extended upon a good cause showing to the court or by stipulation of both parties. If the parties fail to select a mediator within the 15-day period, any party may petition the court to appoint 'me mediator. (b)(1) If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil 17k t Revised 6/15/17 Contract No. 6335 Page 76 of 176 Procedure, notwithstanding Section 1141.11 of that code. The Civil Discovery Act of 1986 (Article 3 (commencing with Section 2016) of Chapter 3 of Title 3 of Part 4 of the Code of Civil procedure) shall apply to any proceeding brought under the subdivision consistent with the rules pertaining to judicial arbitration. (2)Notwithstanding any other provision of law, upon stipulation of the parties, arbitrators appointed for purposes of this article shall be experienced in construction law, and, upon stipulation of the parties, mediators and arbitrators shall be paid necessary and reasonable hourly rates of pay not to exceed their customary rate, and such fees and expenses shall be paid equally by the parties, except in the case of arbitration where the arbitrator, for good cause, determines a different division. In no event shall these fees or expenses be paid by state or county funds. (3)In addition to Chapter 2.5 (commencing with Section 1141.10) Title 3 of Part 3 of the Code of Civil Procedure, any party who after receiving an arbitration award requests a trial de nova but does not obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, pay the attorney's fees of the other party arising out of the trial de novo. (c) The court may, upon request by any party, order any witnesses to participate in the mediation or arbitration process. 20104.6. (a) No local agency shall fail to pay money as to any portion of a claim which is undisputed except as otherwise provided in the contract. (b) In any suit filed under Section 20104.4, the local agency shall pay interest at the legal rate on any arbitration award or judgment. The interest shall begin to accrue on the date the suit is filed in a court of law. Although not to be construed as proceeding under extra work provisions, the Contractor shall keep and furnish records of disputed work in accordance with Section 3-3. 4". —1- Revised 6/15/17 Contract No. 6335 Page 77 of 176 SECTION 4 - CONTROL OF MATERIALS 4-1 MATERIALS AND WORKMANSHIP. 4-1.1. General. All materials, parts, and equipment furnished by the Contractor in the Work shall be new, high grade, and free from defects. Quality of work shall be in accordance with the generally accepted standards. Material and work quality shall be subject to the Engineer's approval. Materials and work quality not conforming to the requirements of the Specifications shall be considered defective and will be subject to rejection. Defective work or material, whether in place or not, shall be removed immediately from the site by the Contractor, at its expense, when so directed by the Engineer. If the Contractor fails to replace any defective or damaged work or material after reasonable notice, the Engineer may cause such work or materials to be replaced. The replacement expense will be deducted from the amount to be paid to the Contractor. Used or secondhand materials, parts, and equipment may be used only if permitted by the Specifications. 4-1.2 Protection of Work and Materials. The Contractor shall provide and maintain storage facilities and employ such measures as will preserve the specified quality and fitness of materials to be used in the Work. Stored materials shall be reasonably accessible for inspection. The Contractor shall also adequately protect new and existing work and all items of equipment for the duration of the Contract. The Contractor shall not, without the Agency's consent, assign, sell, mortgage, hypothecate, or remove equipment or materials which have been installed or delivered and which may be necessary for the completion of the Contract. 4-1.3 Inspection Requirements. 4-1.3.1 General. Unless otherwise specified, inspection is required at the source for such typical materials and fabricated items as bituminous paving mixtures, structural concrete, metal fabrication, metal casting, welding, concrete pipe manufacture, protective coating application, and similar shop or plant operations. Steel pipe in sizes less than 18 inches and vitrified clay and cast iron pipe in all sizes are acceptable upon certification as to compliance with the Specifications, subject to sampling and testing by the Agency. Standard items of equipment such as electric motors, conveyors, elevators, plumbing fixtures, etc., are subject to inspection at the job site only. Special items of equipment such as designed electrical panel boards, large pumps, sewage plant equipment, etc., are subject to inspection at the source, normally only for performance testing. The Specifications may require inspection at the source for other items not typical of those listed in this section. The Contractor shall provide the Engineer free and safe access to any and all parts of work at any time. Such free and safe access shall include means of safe access and egress, ventilation, lighting, shoring, dewatering and all elements pertaining to the safety of persons as contained in the State of California, California Code of Regulations, Title 8, Industrial Relations, Chapter 4, —1- Revised 6/15/17 Contract No. 6335 Page 78 of 176 Division of Industrial Safety, Subchapter 4, Construction Safety Orders and such other safety regulations as may apply. Contractor shall furnish Engineer with such information as may be necessary to keep the Engineer fully informed regarding progress and manner of work and character of materials. Inspection or testing of the whole or any portion of the work or materials incorporated in the work shall not relieve Contractor from any obligation to fulfill this Contract. 4-1.3.2 Inspection of Materials Not Locally Produced. When the Contractor intends to purchase materials, fabricated products, or equipment from sources located more than 50 miles outside the geographical limits of the Agency, an inspector or accredited testing laboratory (approved by the Engineer), shall be engaged by the Contractor at its expense, to inspect the materials, equipment or process. This approval shall be obtained before producing any material or equipment. The inspector or representative of the testing laboratory shall judge the materials by the requirements of the Plans and Specifications. The Contractor shall forward reports required by the Engineer. No material or equipment shall be shipped nor shall any processing, fabrication or treatment of such materials be done without proper inspection by the approved agent. Approval by said agent shall not relieve the Contractor of responsibility for complying with the Contract requirements. 4-1.3.3 Inspection by the Agency. The Agency will provide all inspection and testing laboratory services within 50 miles of the geographical limits of the Agency. For private contracts, all costs of inspection at the source, including salaries and mileage costs, shall be paid by the permittee. 4-1.4 Test of Material. Before incorporation in the Work, the Contractor shall submit samples of materials, as the Engineer may require, at no cost to the Agency. The Contractor, at its expense, shall deliver the materials for testing to the place and at the time designated by the Engineer. Unless otherwise provided, all initial testing will be performed under the direction of the Engineer, and at no expense to the Contractor. If the Contractor is to provide and pay for testing, it will be stated in the Specifications. For private contracts, the testing expense shall be borne by the permittee. The Contractor shall notify the Engineer in writing, at least 15 days in advance, of its intention to use materials for which tests are specified, to allow sufficient time to perform the tests. The notice shall name the proposed supplier and source of material. If the notice of intent to use is sent before the materials are available for testing or inspection, or is sent so far in advance that the materials on hand at the time will not last but will be replaced by a new lot prior to use on the Work, it will be the Contractor's responsibility to renotify the Engineer when samples which are representative may be obtained. Except as specified in these Provisions, the Agency will bear the cost of testing of locally produced materials and/or on-site workmanship where the results of such tests meet or exceed the requirements indicated in the Standard Specifications, Technical Specification, and any Supplemental Provisions. The cost of all other tests shall be borne by the Contractor. At the option of the Engineer, the source of supply of each of the materials shall be approved by the Engineer before the delivery is started. All materials proposed for use may be inspected or tested at any time during their preparation and use. If, after incorporating such materials into the Work, it is found that sources of supply that have been approved do not furnish a uniform product, or if the product from any source proves unacceptable at any time, the Contractor shall furnish approved material from other approved sources. If any product proves unacceptable after —1- Revised 6/15/17 Contract No. 6335 Page 79 of 176 improper storage, handling or for any other reason it shall be rejected, not incorporated into the work and shall be removed from the project site all at the Contractor's expense. Compaction tests may be made by the Engineer and all costs for tests that meet or exceed the requirements of the specifications shall be borne by the Agency. Said tests may be made at any place along the work as deemed necessary by the Engineer. The costs of any retests made necessary by noncompliance with the specifications shall be borne by the Contractor. 4-1.5 Certification. The Engineer may waive materials testing requirements of the Specifications and accept the manufacturer's written certification that the materials to be supplied meet those requirements. Material test data may be required as part of the certification. 4-1.6 Trade Names or Equals. The Contractor may supply any of the materials specified or offer an equivalent. The Engineer shall determine whether the material offered is equivalent to that specified. Adequate time shall be allowed for the Engineer to make this determination. Whenever any particular material, process, or equipment is indicated by patent, proprietary or brand name, or by name of manufacturer, such wording is used for the purpose of facilitating its description and shall be deemed to be followed by the words or equal. A listing of materials is not intended to be comprehensive, or in order of preference. The Contractor may offer any material, process, or equipment considered to be equivalent to that indicated. The substantiation of offers shall be submitted as provided in the contract documents. The Contractor shall, at its expense, furnish data concerning items offered by it as equivalent to those specified. The Contractor shall have the material tested as required by the Engineer to determine that the quality, strength, physical, chemical, or other characteristics, including durability, finish, efficiency, dimensions, service, and suitability are such that the item will fulfill its intended function. Test methods shall be subject to the approval of the Engineer. Test results shall be reported promptly to the Engineer, who will evaluate the results and determine if the substitute item is equivalent. The Engineer's findings shall be final. Installation and use of a substitute item shall not be made until approved by the Engineer. If a substitute offered by the Contractor is not found to be equal to the specified material, the Contractor shall furnish and install the specified material. The specified Contract completion time shall not be affected by any circumstance developing from the provisions of this section. The Contractor is responsible for the satisfactory performance of substituted items. If, in the sole opinion of the Engineer, the substitution is determined to be unsatisfactory in performance, appearance, durability, compatibility with associated items, availability of repair parts and suitability of application the Contractor shall remove the substituted item and replace it with the originally specified item at no cost to the Agency. 4-1.7 Weighing and Metering Equipment. All scales and metering equipment used for proportioning materials shall be inspected for accuracy and certified within the past 12 months by the State of ualifornia Bureau of Weights ana Measures, by the County Director or Sealer of Weights and Measures, or by a scale mechanic registered with or licensed by the County. %O. Revised 6/15/17 Contract No. 6335 Page 80 of 176 The accuracy of the work of a scale service agency, except as stated herein, shall meet the standards of the California Business and Professions Code and the California Code of Regulations pertaining to weighing devices. A certificate of compliance shall be presented, prior to operation, to the Engineer for approval and shall be renewed whenever required by the Engineer at no cost to the Agency. All scales shall be arranged so they may be read easily from the operator's platform or area. They shall indicate the true net weight without the application of any factor. The figures of the scales shall be clearly legible. Scales shall be accurate to within 1 percent when tested with the plant shut down. Weighing equipment shall be so insulated against vibration or moving of other operating equipment in the plant area that the error in weighing with the entire plant running will not exceed 2 percent for any setting nor 1.5 percent for any batch. 4-1.8 Calibration of Testing Equipment. Testing equipment, such as, but not limited to pressure gages, metering devices, hydraulic systems, force (load) measuring instruments, and strain-measuring devices shall be calibrated by a testing agency acceptable to the Engineer at intervals not to exceed 12 months and following repairs, modification, or relocation of the equipment. Calibration certificates shall be provided when requested by the Engineer. 4-1.9 Construction Materials Dispute Resolution (Soils, Rock Materials, Concrete, Mortar and Related Materials, Masonry Materials, Bituminous Materials, Rock Products, and Modified Asphalts). In the interest of safety and public value, whenever credible evidence arises to contradict the test values of materials, the Agency and the Contractor will initiate an immediate and cooperative investigation. Test values of materials are results of the materials' tests, as defined by these Specifications or by the special provisions, required to accept the Work. Credible evidence is process observations or test values gathered using industry accepted practices. A contradiction exists whenever test values or process observations of the same or similar materials are diverse enough such that the work acceptance or performance becomes suspect. The investigation shall allow access to all test results, procedures, and facilities relevant to the disputed work and consider all available information and, when necessary, gather new and additional information in an attempt to determine the validity, the cause, and if necessary, the remedy to the contradiction. If the cooperative investigation reaches any resolution mechanism acceptable to both the Agency and the Contractor, the contradiction shall be considered resolved and the cooperative investigation concluded. Whenever the cooperative investigation is unable to reach resolution, the investigation may then either conclude without resolution or continue by written notification of one party to the other requesting the implementation of a resolution process by committee. The continuance of the investigation shall be contingent upon recipient's agreement and acknowledged in writing within 3 calendar days after receiving a request. Without acknowledgement, the investigation shall conclude without resolution. The committee shall consist of three State of California Registered Civil Engineers. Within 7 calendar days after the written request notification, the Agency and the Contractor will each select one engineer. Within 14 calendar days of the written request notification, the two selected engineers will select a third engineer. The goal in selection of the third member is to complement the professional experience of the first two engineers. Should the two engineers fail to select the third engineer, the Agency and the Contractor shall each propose 2 engineers to be the third member within 21 calendar days after the written request notification. The first two engineers previously selected shall then select one of the four proposed engineers in a blind draw. The committee shall be a continuance of the cooperative investigation and will re-consider all available information and if necessary gather new and additional information to determine the validity, the cause, and if necessary, the remedy to the contradiction. The committee will focus upon the performance adequacy of the material(s) using standard engineering principles and practices and to ensure public value, the *7* —1- Revised 6/15/17 Contract No 6335 Page 81 of 176 committee may provide engineering recommendations as necessary. Unless otherwise agreed, the committee will have 30 calendar days from its formation to complete their review and submit their findings. The final resolution of the committee shall be by majority opinion, in writing, stamped and signed. Should the final resolution not be unanimous, the dissenter may attach a written, stamped, and signed minority opinion. Once started, the resolution process by committee shall continue to full conclusion unless: 1.Within 7 days of the formation of the committee, the Agency and the Contractor reach an acceptable resolution mechanism; or 2.Within 14 days of the formation of the committee, the initiating party withdraws its written notification and agrees to bear all investigative related costs thus far incurred; or 3.At any point by the mutual agreement of the Agency and the Contractor. Unless otherwise agreed, the Contractor shall bear and maintain a record for all the investigative costs until resolution. Should the investigation discover assignable causes for the contradiction, the assignable party, the Agency or the Contractor, shall bear all costs associated with the investigation. Should assignable causes for the contradiction extended to both parties, the investigation will assign costs cooperatively with each party or when necessary, equally. Should the investigation substantiate a contradiction without assignable cause, the investigation will assign costs cooperatively with each party or when necessary, equally. Should the investigation be unable to substantiate a contradiction, the initiator of the investigation shall bear all investigative costs. All claim notification requirements of the contract pertaining to the contradiction shall be suspended until the investigation is concluded. 4-2 MATERIALS TRANSPORTATION, HANDLING AND STORAGE. The Contractor shall order, purchase, transport, coordinate delivery, accept delivery, confirm the quantity and quality received, prepare storage area(s), store, handle, protect, move, relocate, remove and dispose excess of all materials used to accomplish the Work. Materials shall be delivered to the site of the work only during working hours, as defined in Section 6-7.2, and shall be accompanied by bills of lading that shall clearly state for each delivery: the name of the Contractor as consignee, the project name and number, address of delivery and name of consignor and a description of the material(s) shipped. Prior to storage of any materials which have been shipped to or by the Contractor to any location within the Agency's boundaries the Contractor shall provide the Engineer a copy of lease agreements for each property where such materials are stored. The lease agreement shall clearly state the term of the lease, the description of materials allowed to be stored and shall provide for the removal of the materials and restoration of the storage site within the time allowed for the Work. All such storage shall conform to all laws and ordinances that may pertain to the materials stored and to preparation of the storage site and the location of the site on which the materials are stored. Loss, damage or deterioration of all stored materials shall be the Contractor's responsibility. Conformance to the requirements of this section, both within and outside the limits of work are a part of the Work. The Engineer shall have the right to verify the suitability of materials and their proper storage at any time during the Work. 0% —1- Revised 6/15/17 Contract No. 6335 Page 82 of 176 SECTION 5 - UTILITIES 5-1 LOCATION. The Agency and affected utility companies have, by a search of known records, endeavored to locate and indicate on the Plans, all utilities which exist within the limits of the work. However, the accuracy and/or completeness of the nature, size and/or location of utilities indicated on the Plans is not guaranteed. Where underground main distribution conduits such as water, gas, sewer, electric power, telephone, or cable television are shown on the Plans, the Contractor shall assume that every property parcel will be served by a service connection for each type of utility. As provided in Section 4216 of the California Government Code, at least 2 working days prior to commencing any excavation, the Contractor shall contact the regional notification center (Underground Service Alert of Southern California) and obtain an inquiry identification number. The California Department of Transportation is not required by Section 4216 to become a member of the regional notification center. The Contractor shall contact it for location of its subsurface installations. The Contractor shall determine the location and depth of all utilities, including service connections, which have been marked by the respective owners and which may affect or be affected by its operations. If no pay item is provided in the Contract for this work, full compensation for such work shall be considered as included in the prices bid for other items of work. 5-2 PROTECTION. The Contractor shall not interrupt the service function or disturb the support of any utility without authority from the owner or order from the Agency. All valves, switches, vaults, and meters shall be maintained readily accessible for emergency shutoff. Where protection is required to ensure support of utilities located as shown on the Plans or in accordance with Section 5-1, the Contractor shall, unless otherwise provided, furnish and place the necessary protection at its expense. Upon learning of the existence and location of any utility omitted from or shown incorrectly on the Plans, the Contractor shall immediately notify the Engineer in writing. When authorized by the Engineer, support or protection of the utility will be paid for as provided in Section 3-2.2.3 or 3-3. The Contractor shall immediately notify the Engineer and the utility owner if any utility is disturbed or damaged. The Contractor shall bear the costs of repair or replacement of any utility damaged if located as noted in Section 5-1. When placing concrete around or contiguous to any non-metallic utility installation, the Contractor shall at its expense: 1.Furnish and install a 2 inch cushion of expansion joint material or other similar resilient material; or 2.Provide a sleeve or other opening which will result in a 2 inch minimum-clear annular space between the concrete and the utility; or 3.Provide other acceptable means to prevent embedment in or bonding to the concrete. 'kuf Revised 6/15/17 Contract No. 6335 Page 83 of 176 Where concrete is used for backfill or for structures which would result in embedment, or partial embedment, of a metallic utility installation; or where the coating, bedding or other cathodic protection system is exposed or damaged by the Contractor's operations, the Contractor shall notify the Engineer and arrange to secure the advice of the affected utility owner regarding the procedures required to maintain or restore the integrity of the system. 5-3 REMOVAL. Unless otherwise specified, the Contractor shall remove all interfering portions of utilities shown on the Plans or indicated in the Bid documents as "abandoned" or "to be abandoned in place". Before starting removal operations, the Contractor shall ascertain from the Agency whether the abandonment is complete, and the costs involved in the removal and disposal shall be included in the Bid for the items of work necessitating such removals. 5-4 RELOCATION. When feasible, the owners responsible for utilities within the area affected by the Work will complete their necessary installations, relocations, repairs, or replacements before commencement of work by the Contractor. When the Plans or Specifications indicate that a utility installation is to be relocated, altered, or constructed by others, the Agency will conduct all negotiations with the owners and work will be done at no cost to the Contractor, except for manhole frame and cover sets to be brought to grade as provided in the Standard Specifications for Public Works Construction, Section 301-1.6, 2006 Edition. Utilities which are relocated in order to avoid interference shall be protected in their position and the cost of such protection shall be included in the Bid for the items of work necessitating such relocation. After award of the Contract, portions of utilities which are found to interfere with the Work will be relocated, altered or reconstructed by the owners, or the Engineer may order changes in the Work to avoid interference. Such changes will be paid for in accordance with Section 3-2. When the Plans or Specifications provide for the Contractor to alter, relocate, or reconstruct a utility, all costs for such work shall be included in the Bid for the items of work necessitating such work. Temporary or permanent relocation or alteration of utilities requested by the Contractor for its convenience shall be its responsibility and it shall make all arrangements and bear all costs. The utility owner will relocate service connections as necessary within the limits of the Work or within temporary construction or slope easements. When directed by the Engineer, the Contractor shall arrange for the relocation of service connections as necessary between the meter and property line, or between a meter and the limits of temporary construction or slope easements. The relocation of such service connections will be paid fcr in accordance with provisions of Section 3-3. Payment will include the restoration of all existing improvements which may be affected thereby. The Contractor may agree with the owner of any utility to disconnect and reconnect interfering service connections. The Agency will not be involved in any such agreement. In conformance with Section 5-6 the Contractor shall coordinate the work with utility agencies and companies. Prior to the installation of any and all utility structures within the limits of work by any utility agency or company, or its contractor, the Contractor shall place all curb or curb and gutter that is a part of the work and adjacent to the location where such utility structures are shown on the plans and are noted as being located, relocated or are otherwise shown as installed by others. In order to minimize delays to the Contractor caused by the failure of other parties to relocate utilities that interfere with the construction, the Contractor, upon the Engineer's approval, may be permitted to temporarily omit the portion of work affected by the utility. If such temporary omission is approved by the trigineer the contractor shall place survey or other physical control markers sufficient to locate the curb or curb and gutter to the satisfaction of the utility agency or company. Such temporary omission shall be for the Contractor's convenience and no additional 4ipm, IT- Revised 6/15/17 Contract No. 6335 Page 84 of 176 compensation will be allowed therefore or for additional work, materials or delay associated with the temporary omission. The portion thus omitted shall be constructed by the Contractor immediately following the relocation of the utility involved unless otherwise directed by the Engineer. 5-5 DELAYS. The Contractor shall notify the Engineer of its construction schedule insofar as it affects the protection, removal, or relocation of utilities. Said notification shall be included as a part of the construction schedule required in Section 6-1. The Contractor shall notify the Engineer in writing of any subsequent changes in the construction schedule which will affect the time available for protection, removal, or relocation of utilities. The Contractor will not be entitled to damages or additional payment for delays attributable to utility relocations or alterations if correctly located, noted, and completed in accordance with Section 5-1. The Contractor may be given an extension of time for unforeseen delays attributable to unreasonably protracted interference by utilities in performing work correctly shown on the Plans. The Agency will assume responsibility for the timely removal, relocation, or protection of existing main or trunkline utility facilities within the area affected by the Work if such utilities are not identified in the Contract Documents. The Contractor will not be assessed liquidated damages for any delay caused by failure of Agency to provide for the timely removal, relocation, or protection of such existing facilities. If the Contractor sustains loss due to delays attributable to interferences, relocations, or alterations not covered by Section 5-1, which could not have been avoided by the judicious handling of forces, equipment, or plant, there shall be paid to the Contractor such amount as the Engineer may find to be fair and reasonable compensation for such part of the Contractor's actual loss as was unavoidable and the Contractor may be granted an extension of time. 5-6 COOPERATION. When necessary, the Contractor shall so conduct its operations as to permit access to the Work site and provide time for utility work to be accomplished during the progress of the Work. —r- Revised 6/15/17 Contract No 6335 Page 85 of 176 SECTION 6 - PROSECUTION, PROGRESS, AND ACCEPTANCE OF THE WORK 6-1 CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK. Except as otherwise provided herein and unless otherwise prohibited by permits from other agencies as may be required by law the Contractor shall begin work within seven (7) calendar days after receipt of the "Notice to Proceed". 6-1.1 Pre-Construction Meeting. After, or upon, notification of contract award, the Engineer will set the time and location for the Preconstruction Meeting. Attendance of the Contractor's management personnel responsible for the management, administration, and execution of the project is mandatory for the meeting to be convened. Failure of the Contractor to have the Contractor's responsible project personnel attend the Preconstruction Meeting will be grounds for default by Contractor per Section 6-4. No separate payment will be made for the Contractor's attendance at the meeting. The notice to proceed will only be issued on or after the completion of the preconstruction meeting. 6-1.1.1 Baseline Construction Schedule Submittal. The Contractor shall submit the Baseline Construction Schedule per the submittal requirements of Section 2-5.3. The submittal of the Baseline Construction Schedule shall include each item and element of Sections 6-1.2 through 6-1.2.9 and shall be on hard (paper) copy and electronic media conforming to Section 6-1.3.3 Electronic Media. 6-1.2 Preparation and Review of the Baseline Construction Schedule. The Contractor shall prepare the Baseline Construction Schedule as a Critical Path Method (CPM) Schedule in the precedence diagram method (activity-on-node) format. The Baseline Construction Schedule shall depict a workable plan showing the sequence, duration, and interdependence of all activities required to represent the complete performance of all project work as well as periods where work is precluded. The Baseline Construction Schedule shall begin with the projected date of issuance of the notice to proceed and conclude with the date of final completion per the contract duration. The Baseline Construction Schedule shall include detail of all project phasing, staging, and sequencing, including all milestones necessary to define beginning and ending of each phase or stage. 6-1.2.1 Time-Scaled Network Diagram. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a complete time-scaled network diagram showing all of the activities, logic relationships, and milestones comprising the schedule. 6-1.2.2 Tabular Listing. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a tabular listing of all of the activities, showing for each activity the identification number, the description, the duration, the early start, the early finish, the late start, the late finish, the total float, and all predecessor and successor activities for the activity described. 6-1.2.3 Bar Chart. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a chart showing individual tasks and their durations arranged with the tasks on the vertical axis and duration on the horizontal axis. The bar chart shall use differing texture patterns or distinctive line types to show the r,•rtioz! path. —r- Revised 6/15/17 Contract No. 6335 Page 86 of 176 6-1.2.4 Schedule Software. The Contractor shall use commercially available software equal to the Windows 2000 compatible "Suretrak" program by Primavera or "Project" program by Microsoft Corporation to prepare the Baseline Construction Schedule and all updates thereto. The Contractor shall submit to the Agency a CD-ROM data disk with all network information contained thereon, in a format readable by a Microsoft Windows 2000 system. The Agency will use a "Suretrak", "Project" or equal software program for review of the Contractor's schedule. Should the Contractor elect to use a scheduling program other than the "Suretrak" program by Primavera or "Project" program by Microsoft Corporation the Contractor shall provide the Engineer three copies of the substituted program that are fully licensed to the Agency and 32 class hours of on- site training by the program publisher for up to eight Agency staff members. The classes shall be presented on Mondays through Thursdays, inclusive, between the hours of 8:00 a.m. and 5:00 p.m. The on-site training shall be held at 1635 Faraday Avenue, Carlsbad, California. The dates and times of the on-site training shall be submitted to the Engineer for approval five working days before the start of the on-site training. The on-site training shall be completed prior to the submittal of the first Baseline Construction Schedule. 6-1.2.5 Schedule Activities. Except for submittal activities, activity durations shall not be shorter than 1 working day nor longer than 15 working days, unless specifically and individually allowed by the Engineer. The Baseline Construction Schedule shall include between 100 and 500 activities, including submittals, interfaces between utility companies and other agencies, project milestones and equipment and material deliveries. The number of activities will be sufficient, in the judgment of the Engineer, to communicate the Contractor's plan for project execution, to accurately describe the project work, and to allow monitoring and evaluation of progress and of time impacts. Each activity's description shall accurately define the work planned for the activity and each activity shall have recognizable beginning and end points. 6-1.2.6 Float. Float or slack time within the schedule is available without charge or compensation to whatever party or contingency first exhausts it. 6-1.2.7 Restraints to Activities. Any submittals, utility interfaces, or any furnishing of Agency supplied materials, equipment, or services, which may impact any activity's construction shall be shown as a restraint to those activities. Time periods to accommodate the review and correction of submittals shall be included in the schedule. 6-1.2.8 Late Completion. A Baseline Construction Schedule showing a project duration longer than the specified contract duration will not be acceptable and will be grounds for determination of default by Contractor, per Section 6-4. 6-1.2.9 Early Completion. The Baseline Construction Schedule will show the Contractor's plan to support and maintain the project for the entire contractual time span of the project. Should the Contractor propose a project duration shorter than contract duration, a complete Baseline Construction Schedule must be submitted, reflecting the shorter duration, in complete accordance with all schedule requirements of Section 6-1. The Engineer may choose to accept the Contractor's proposal of a project duration shorter than the duration specified; provided the Agency is satisfied the shortened Baseline Construction Schedule is reasonable and the Agency and all other entities, public and private, which interface with the project are able to support the provisions of the shortened Baseline Construction Schedule. The Agency's acceptance of a shortened duration project will be confirmed through the execution of a contract change order revising the project duration and implementing all contractual requirements including liquidated damages in accordance with the revised duration. tat —1- Revised 6/15/17 Contract No. 6335 Page 87 of 176 6-1.2.10 Engineer's Review. The Construction Schedule is subject to the review of the Engineer. The Engineer's determination that the Baseline Construction Schedule proposed by the Contractor complies with the requirements of these supplemental provisions shall be a condition precedent to issuance of the Notice to Proceed by the Engineer. If the Engineer determines that the Construction Schedule does not meet the requirements of these specifications the Contractor shall correct the Construction Schedule to meet these specifications and resubmit it to the Engineer. Failure of the Contractor to obtain the Engineer's determination that the initial Construction Schedule proposed by the Contractor complies with the requirements of these supplemental provisions within thirty (30) working days after the date of the preconstruction meeting shall be grounds for termination of the contract per Section 6-4. Days used by the Engineer to review the initial Construction Schedule will not be included in the 30 working days. The Engineer will review and return to the Contractor, with any comments, the Baseline Construction Schedule within 15 working days of submittal. The Baseline Construction Schedule will be returned marked as per Sections 6-1.2.10.1 through 6-1.2.10.3. 6-1.2.10.1 "Accepted." The Contractor may proceed with the project work upon issuance of the Notice to Proceed, and will receive payment for the schedule in accordance with Section 6-1.8.1. 6-1.2.10.2 "Accepted with Comments." The Contractor may proceed with the project work upon issuance of the Notice to Proceed. The Contractor must resubmit the schedule incorporating the comments prior to receipt of payment per Section 6-1.8.1. 6-1.2.10.3 "Not Accepted." The Contractor must resubmit the schedule incorporating the corrections and changes of the comments prior to receipt of payment per Section 6-1.8.1. The Notice to Proceed will not be issued by the Engineer if the changes of the comments are not submitted as required hereinbefore and marked "Accepted" or "Accepted with Comments" by the Engineer. The Contractor, at the sole option of the Engineer, may be considered as having defaulted the contract under the provisions of Section 6-4 DEFAULT BY CONTRACTOR if the changes of the comments are not submitted as required hereinbefore and marked "Accepted" by the Engineer. 6-1.3 Preparation of Schedule Updates and Revisions. The Contractor shall meet with the Engineer during the last week of each month to agree upon each activity's schedule status and shall submit monthly updates of the Baseline Construction Schedule confirming the agreements no later than the fifth working day of the following month. The monthly update will be submitted on hard (paper) copy and electronic media conforming to Section 6-1.3.3 Electronic Media per the submittal requirements of Section 2-5.3 and will include each item and element of Sections 6- 1.2 through 6-1.2.9 and 6-1.3.1 through 6-1.3.7. 6-1.3.1 Actual Activity Dates. The actual dates each activity was started and/or completed during the month. After first reporting an actual date, the Contractor shall not change that actual date in later updates without specific notification to the Engineer with the update. 6-1.3.2 Activity Percent Complete. For each activity underway at the end of the month, the Contractor shall report the percentage determined by the Engineer as complete for the activity. 6-1.3.3 Electronic Media. The schedule data disk shall be a CD-ROM, labeled with the project name ana numoer, me uontractor's name and the date of preparation of the schedule data disk. The schedule data disk shall be readable by the software specified in Section 6-1.2.4 "Schedule os, —r- Revised 6/15/17 Contract No. 6335 Page 88 of 176 Software" and shall be free of file locking, encryption or any other protocol that would impede full access of all data stored on it. 6-1.3.4 List of Changes. A list of all changes made to the activities or to the interconnecting logic, with an explanation for each change. 6-1.3.5 Change Orders. Each monthly update will include the addition of the network revisions reflecting the change orders approved in the previous month. The network revisions will be as agreed upon during the review and acceptance of the Contractor's change orders. 6-1.3.6 Bar Chart. Each monthly update will include a chart showing individual tasks and their durations arranged with the tasks on the vertical axis and duration on the horizontal axis. The bar chart shall use differing texture patterns or distinctive line types to show the critical path. 6-1.4 Engineer's Review of Updated Construction Schedule. The Engineer will review and return the Updated Construction Schedule to the Contractor, with any comments, within 5 working days of submittal. The Updated Construction Schedule will be returned marked as per Sections 6-1.4.1 through 6-1.4.3. Any Updated Construction Schedule marked "Accepted with Comments" or "Not Accepted" by the Engineer will be returned to the Contractor for correction. Upon resubmittal the Engineer will review and return the resubmitted Updated Construction Schedule to the Contractor, with any comments, within 5 working days. Failure of the Contractor to submit a monthly updated construction schedule will invoke the same consequences as the Engineer returning a monthly updated construction schedule marked "Not Accepted". 6-1.4.1 "Accepted." The Contractor may proceed with the project work, and will receive payment for the schedule in accordance with Section 6-1.8.2. 6-1.4.2 "Accepted with Comments." The Contractor may proceed with the project work. The Contractor must resubmit the Updated Construction Schedule to the Engineer incorporating the corrections and changes noted in the Engineer's comments prior to receipt of payment per Section 6-1.8.2. 6-1.4.3 "Not Accepted." The Contractor must resubmit the Updated Construction Schedule to the Engineer incorporating the corrections and changes noted in the Engineer's comments prior to receipt of payment per Section 6-1.8.2. The Contractor, at the sole option of the Engineer, may be considered as having defaulted the contract under the provisions of Section 6-4 DEFAULT BY CONTRACTOR if the changes of the comments are not submitted and marked "Accepted" by the Engineer before the last day of the month in which the Updated Construction Schedule is due. If the Contractor fails to submit the corrected Updated Construction Schedule as required herein the Contractor may elect to proceed with the project at its own risk. Should the Contractor elect not to proceed with the project, any resulting delay, impact, or disruption to the project will be the Contractor's responsibility. 6-1.5 Late Completion or Milestone Dates. Should the Schedule Update indicate a completion or contractually required milestone date later than the properly adjusted contract or milestone duration, the Agency may withhold Liquidated Damages for the number of days late. Should a subsequent "Accepted" Schedule Update remove all or a portion of the delay, all or the allocated portion of the previously held Liquidated Damages shall be released in the monthly payment to the Contractor immediately following the "Accepted" schedule. tad" —1- Revised 6/15/17 Contract No. 6335 Page 89 of 176 6-1.6 Interim Revisions. Should the actual or projected progress of the work become substantially different from that depicted in the Project Schedule, independently of and prior to the next monthly update, the Contractor will submit a revised Baseline Construction Schedule, with a list and explanation of each change made to the schedule. The Revised Construction Schedule will be submitted per the submittal requirements of Section 2-5.3 and per the schedule review and acceptance requirements of Section 6-1, including but not limited to the acceptance and payment provisions. As used in this section "substantially different" means a time variance greater than 5 percent of the number of days of duration for the project. 6-1.7 Final Schedule Update. The Contractor shall prepare and submit a final schedule update when one hundred percent of the construction work is completed. The Contractor's Final Schedule Update must accurately represent the actual dates for all activities. The final schedule update shall be prepared and reviewed per Sections 6-1.3 Preparation of Schedule Updates and Revisions and 6-1. 4 Engineer's Review of Updated Construction Schedule. Acceptance of the final schedule update is required for completion of the project and release of any and all funds retained per Section 9-3.2. 6-1.8 Measurement and Payment of Construction Schedule. The Contractor's preparation, revision and maintenance of the Construction Schedule are incidental to the work and no separate payment will be made therefore. 6-2 PROSECUTION OF WORK. To minimize public inconvenience and possible hazard and to restore street and other work areas to their original condition and state of usefulness as soon as practicable, the Contractor shall diligently prosecute the Work to completion. If the Engineer determines that the Contractor is failing to prosecute the Work to the proper extent, the Contractor shall, upon orders from the Engineer, immediately take steps to remedy the situation. All costs of prosecuting the Work as described herein shall be included in the Contractor's Bid. Should the Contractor fail to take the necessary steps to fully accomplish said purposes, after orders of the Engineer, the Engineer may suspend the work in whole or part, until the Contractor takes said steps. As soon as possible under the provisions of the Specifications, the Contractor shall backfill all excavations and restore to usefulness all improvements existing prior to the start of the Work. If Work is suspended through no fault of the Agency, all expenses and losses incurred by the Contractor during such suspensions shall be borne by the Contactor. If the Contractor fails to properly provide for public safety, traffic, and protection of the Work during periods of suspension, the Agency may elect to do so, and deduct the cost thereof from monies due the Contractor. Such actions will not relieve the Contractor from liability. 6-2.1 Order of Work. The work to be done shall consist of furnishing all labor, equipment and materials, and performing all operations necessary to complete the Project Work as shown on the Project Plans and as specified in the Specifications. 6-2.3 Project Meetings. The Engineer will establish the time and location of weekly Project Meetings. The Contractor's Representative shall attend each Project Meeting. The Project Representative shall be the individual determined under Section 7-6, "The Contractor's Representative". No separate payment for attendance of the Contractor, the Contractor's Representative or any other employee or subcontractor or subcontractor's employee at these meetings will be made. t at —1- Revised 6/15/17 Contract No 6335 Page 90 of 176 6-3 SUSPENSION OF WORK. 6-3.1 General. The Work may be suspended in whole or in part when determined by the Engineer that the suspension is necessary in the interest of the Agency. The Contractor shall comply immediately with any written order of the Engineer. Such suspension shall be without liability to the Contractor on the part of the Agency except as otherwise specified in Section 6-6.3. 6-3.2 Archaeological and Paleontological Discoveries. If discovery is made of items of archaeological or paleontological interest, the Contractor shall immediately cease excavation in the area of discovery and shall not continue until ordered by the Engineer. When resumed, excavation operations within the area of discovery shall be as directed by the Engineer. Discoveries which may be encountered may include, but not be limited to, dwelling sites, stone implements or other artifacts, animal bones, human bones, and fossils. The Contractor shall be entitled to an extension of time and compensation in accordance with the provisions of Section 6-6. 6-4 DEFAULT BY CONTRACTOR. If the Contractor fails to begin delivery of material and equipment, to commence the Work within the time specified, to maintain the rate of delivery of material, to execute the Work in the manner and at such locations as specified, or fails to maintain the Work schedule which will insure the Agency's interest, or, if the Contractor is not carrying out the intent of the Contract, the Agency may serve written notice upon the Contractor and the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. The Contract may be canceled by the Board without liability for damage, when in the Board's opinion the Contractor is not complying in good faith, has become insolvent, or has assigned or subcontracted any part of the Work without the Board's consent. In the event of such cancellation, the Contractor will be paid the actual amount due based on Contract Unit Prices or lump sums bid and the quantity of the Work completed at the time of cancellation, less damages caused to the Agency by acts of the Contractor. The Contractor, in having tendered a Bid, shall be deemed to have waived any and all claims for damages because of cancellation of Contract for any such reason. If the Agency declares the Contract canceled for any of the above reasons, written notice to that effect shall be served upon the Surety. The Surety shall, within five (5) days, assume control and perform the Work as successor to the Contractor. If the Surety assumes any part of the Work, it shall take the Contractor's place in all respects for that part, and shall be paid by the Agency for all work performed by it in accordance with the Contract. If the Surety assumes the entire Contract, all money due the Contractor at the time of its default shall be payable to the Surety as the Work progresses, subject to the terms of the Contract. If the Surety does not assume control and perform the Work within 5 days after receiving notice of cancellation, or fails to continue to comply, the Agency may exclude the Surety from the premises. The Agency may then take possession of all material and equipment and complete the Work by Agency forces, by letting the unfinished Work to another Contractor, or by a combination of such methods. In any event, the cost of completing the Work shall be charged against the Contractor and its Surety and may be deducted from any money due or becoming due from the Agency. If the sums due under the Contract are insufficient for completion, the Contractor or Surety shall pay to the Agency within 5 days after the completion, all costs in excess of the sums due. ti —1- Revised 6/15/17 Contract No. 6335 Page 91 of 176 The provisions of this section shall be in addition to all other rights and remedies available to the Agency under law. 6-5 TERMINATION OF CONTRACT. The Board may terminate the Contract at its own discretion or when conditions encountered during the Work make it impossible or impracticable to proceed, or when the Agency is prevented from proceeding with the Contract by act of God, by law, or by official action of a public authority. 6-6 DELAYS AND EXTENSIONS OF TIME. 6-6.1 General. If delays are caused by unforeseen events beyond the control of the Contractor, such delays will entitle the Contractor to an extension of time as provided herein, but the Contractor will not be entitled to damages or additional payment due to such delays, except as provided in 6-6.3. Such unforeseen events may include: war, government regulations, labor disputes, strikes, fires, floods, adverse weather or elements necessitating cessation of work, inability to obtain materials, labor or equipment, required extra work, or other specific events as may be further described in the Specifications. No extension of time will be granted for a delay caused by the Contractor's inability to obtain materials unless the Contractor furnishes to the Engineer documentary proof. the proof must be provided in a timely manner in accordance with the sequence of the Contractor's operations and the approved construction schedule. If delays beyond the Contractor's control are caused by events other than those mentioned above, the Engineer may deem an extension of time to be in the best interests of the Agency. The Contractor will not be entitled to damages or additional payment due to such delays, except as provided in Section 6-6.3. If delays beyond the Contractor's control are caused solely by action or inaction by the Agency, such delays will entitle the Contractor to an extension of time as provided in Section 6-6.2. 6-6.2 Extensions of Time. Extensions of time, when granted, will be based upon the effect of delays to the Work. They will not be granted for noncontrolling delays to minor portions of the Work unless it can be shown that such delays did or will delay the progress of the Work. 6-6.3 Payment for Delays to Contractor. The Contractor will be compensated for damages incurred due to delays for which the Agency is responsible. Such actual costs will be determined by the Engineer. The Agency will not be liable for damages which the Contractor could have avoided by any reasonable means, such as judicious handling of forces, equipment, or plant. The determination of what damages the Contractor could have avoided will be made by the Engineer. 6-6.4 Written Notice and Report. The Contractor shall provide written notice to the Engineer within two hours of the beginning of any period that the Contractor has placed any workers or equipment on standby for any reason that the Contractor has determined to be caused by the Agency or by any organization that the Agency may otherwise be obligated by. The Contractor shall provide continuing daily written notice to the Engineer, each working day, throughout the duration of such period of delay. The initial and continuing written notices shall include the classification of each workman and supervisor and the make and model of each piece of equipment placed on standby, the cumulative duration of the standby, the Contractor's opinion of the cause of the delay and a cogent explanation of why the Contractor could not avoid the delay t 1 1- Revised 6/15/17 Contract No. 6335 Page 92 of 176 by reasonable means. Should the Contractor fail to provide the notice(s) required by this section the Contractor agrees that no delay has occurred and that it will not submit any claim(s) therefore. 6-7 TIME OF COMPLETION. 6-7.1 General. The Contractor shall complete the Work within the time set forth in the Contract. The Contractor shall complete each portion of the Work within such time as set forth in the Contract for such portion. The time of completion of the Contract shall be expressed in working days. The Contractor shall diligently prosecute the work to completion within ninety (90) working days after the starting date specified in the Notice to Proceed. 6-7.2 Working Day. A working day is any day within the period between the start of the Contract time as defined in Section 6-1 and the date provided for completion, or upon field acceptance by the Engineer for all work provided for in the Contract, whichever occurs first, other than: 1.Saturday, 2.Sunday, 3.any day designated as a holiday by the Agency, 4.any other day designated as a holiday in a Master Labor Agreement entered into by the Contractor or on behalf of the Contractor as an eligible member of a contractor association, 5.any day the Contractor is prevented from working at the beginning of the workday for cause as defined in Section 6-6.1, 6.any day the Contractor is prevented from working during the first 5 hours with at least 60 percent of the normal work force for cause as defined in Section 6-6.1. Unless otherwise approved in writing by the Engineer, the hours of work shall be between the hours of 8:30 a.m. and 3:30 p.m. on Mondays through Fridays, excluding Agency holidays. The Contractor shall obtain the written approval of the Engineer if the Contractor desires to work outside said hours or at any time during weekends and/or holidays. This written permission must be obtained at least 48 hours prior to such work The Engineer may approve work outside the hours and/or days stated herein when, in his/her sole opinion, such work conducted by the Contractor is beneficial to the best interests of the Agency. The Contractor shall pay the inspection costs of such work. The Contractor shall incorporate the dates, areas and types of work prohibited in this section in the Construction Schedule required by Section 6.1. No additional payment, adjustment of bid prices or adjustment of contract time of completion will be allowed as a consequence of the prohibition of work being performed within the dates, areas and/or types of work prohibited in this section. 6-7.3 Contract Time Accounting. The Engineer will make a daily determination of each working day to be charged against the Contract time. These determinations will be discussed and the Contractor will be furnished a periodic statement showing allowable number of working days of Contract time, as adjusted, at the beginning of the reporting period. The statement will also indicate the number of working days charged during the reporting period and the number of working days of Contract time remaining. If the Contractor does not agree with the statement, it shall file a written protest within 15 days after receipt, setting forth the facts of the protest. Otherwise, the statement will be deemed to have been accepted. d„. el- Revised 6/15/17 Contract No. 6335 Page 93 of 176 6-8 COMPLETION, ACCEPTANCE, AND WARRANTY. The Work will be inspected by the Engineer for acceptance upon receipt of the Contractor's written assertion that the Work has been completed. The Engineer will not accept the Work or any portion of the Work before all of the Work is completed and all outstanding deficiencies that may exist are corrected by the Contractor and the Engineer is satisfied that all the materials and workmanship, and all other features of the Work, meet the requirements of all of the specifications for the Work. Use, temporary, interim or permanent, of all, or portions of, the Work does not constitute acceptance of the Work. If, in the Engineer's judgment, the Work has been completed and is ready for acceptance the Engineer will so certify to the Board. Upon such certification by the Engineer the Board may accept the completed Work. Upon the Board's acceptance of the Work the Engineer will cause a "Notice of Completion" to be filed in the office of the San Diego County Recorder. The date of recordation shall be the date of completion of the Work. All work shall be warranted for one (1) year after recordation of the "Notice of Completion" and any faulty work or materials discovered during the warranty period shall be repaired or replaced by the Contractor, at its expense. Twenty-five percent of the faithful performance bond shall be retained as a warranty bond for the one year warranty period. The Contractor shall replace or repair any such defective work in a manner satisfactory to the Engineer, after notice to do so from the Engineer, and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the Agency may perform this work and the Contractor's sureties shall be liable for the cost thereof. 6-9 LIQUIDATED DAMAGES. Failure of the Contractor to complete the Work within the time allowed will result in damages being sustained by the Agency. For each consecutive calendar day in excess of the time specified for completion of Work, as adjusted in accordance with Section 6- 6, the Contractor shall pay the Agency, or have withheld monies due it, the sum of one thousand five hundred Dollars ($1500.00). Such sum is liquidated damages and shall not be construed as a penalty and may be deducted from payments due the Contractor if such delay occurs. Execution of the Contract shall constitute agreement by the Agency and Contractor that one thousand five hundred Dollars ($1,500.00) per day is the minimum value of costs and actual damages caused by the Contractor to complete the Work within the allotted time. Any progress payments made after the specified completion date shall not constitute a waiver of this paragraph or of any damages. 6-10 USE OF IMPROVEMENT DURING CONSTRUCTION. The Agency reserves the right to take over and utilize all or part of any completed facility or appurtenance. The Contractor will be notified in writing in advance of such action. Such action by the Agency will relieve the Contractor of responsibility for injury or damage to said completed portions of the improvement resulting from use by public traffic or from the action of the elements or from any other cause, except Contractor operations or negligence. The Contractor will not be required to reclean such portions of the improvement before field acceptance, except for cleanup made necessary by its operations. Nothing in this section shall be construed as relieving the Contractor from full responsibility for correcting defective work or materials. In the event the Agency exercises its right to place into service and utilize all or part of any completed facility or appurtenance, the Agency will assume the responsibility and liability for injury to persons or property resulting from the utilization of the facility or appurtenance so placed into tat , —1- Revised 6/15/17 Contract No. 6335 Page 94 of 176 service, except for any such injury to persons or property caused by any willful or negligent act or omission by the Contractor, Subcontractor, their officers, employees, or agents. 4r. t all --i- Revised 6/15/17 Contract No. 6335 Page 95 of 176 SECTION 7 - RESPONSIBILITIES OF THE CONTRACTOR 7-1 CONTRACTOR'S EQUIPMENT AND FACILITIES. The Contractor shall furnish and maintain in good condition all equipment and facilities as required for the proper execution and inspection of the Work. Such equipment and facilities shall meet all requirements of applicable ordinances and laws. 7-2 LABOR. 7-2.1 General. Only competent workers shall be employed on the Work. Any person employed who is found to be incompetent, intemperate, troublesome, disorderly, or otherwise objectionable, or who fails or refuses to perform work properly and acceptably, shall be immediately removed from the Work by the Contractor and not be reemployed on the Work. 7-2.2 Laws. The Contractor, its agents, and employees shall be bound by and comply with applicable provisions of the Labor Code and Federal, State, and local laws related to labor. The Contractor shall strictly adhere to the provisions of the Labor Code regarding minimum wages; the 8-hour day and 40-hour week; overtime; Saturday, Sunday, and holiday work; and nondiscrimination because of race, color, national origin, sex, or religion. The Contractor shall forfeit to the Agency the penalties prescribed in the Labor Code for violations. In accordance with the Labor Code, the Board has on file and will publish a schedule of prevailing wage rates for the types of work to be done under the Contract. The Contractor shall not pay less than these rates. Each worker shall be paid subsistence and travel as required by the collective bargaining agreement on file with the State of California Department of Industrial Relations. The Contractor's attention is directed to Section 1776 of the Labor Code which imposes responsibility upon the Contractor for the maintenance, certification, and availability for inspection of such records for all persons employed by the Contractor or Subcontractor in connection with the project. The Contractor shall agree through the Contract to comply with this Section and the remaining provisions of the Labor Code. 7-3 LIABILITY INSURANCE. Insurance shall be required as specified in section 10 of the Public Works Contract. The cost of this insurance shall be included in the Contractor's Bid. 7-4 WORKERS' COMPENSATION INSURANCE. Before execution of the Contract by the Board, the Contractor shall file with the Engineer the following signed certification: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract." fa4: Revised 6/15/17 Contract No. 6335 Page 96 of 176 The Contractor shall also comply with Section 3800 of the Labor Code by securing, paying for, and maintaining in full force and effect for the duration of the contract, complete Workers' Compensation Insurance, and shall furnish a Certificate of Insurance to the Engineer before execution of the Contract. The Agency, its officers, or employees, will not be responsible for any claims in law or equity occasioned by failure of the Contractor to comply with this paragraph. All compensation insurance policies shall bear an endorsement or shall have attached a rider whereby it is provided that, in the event of expiration or proposed cancellation of such policies for any reason whatsoever, the Agency shall be notified by registered mail not less than 30 days before expiration or cancellation is effective. All insurance is to be placed with insurers that are admitted and authorized to conduct business in the state of California and are listed in the official publication of the Department of Insurance of the State of California. Policies issued by the State Compensation Fund meet the requirement for workers' compensation insurance. 7-6 PERMITS. Except as specified herein the Contractor will obtain, at no cost to the Contractor all City of Carlsbad encroachment, right-of-way, grading and building permits necessary to perform work for this contract on Agency property, streets, or other rights-of-way. Contractor shall not begin work until all permits incidental to the work are obtained. The Contractor shall obtain and pay for all permits for the disposal of all materials removed from the project. The cost of said permit(s) shall be included in the price bid for the appropriate bid item and no additional compensation will be allowed therefore. The Contractor shall obtain and pay for all costs incurred for permits necessitated by its operations such as, but not limited to, those permits required for night work, overload, blasting, and demolition. For private contracts, the Contractor shall obtain all permits incidental to the Work or made necessary by its operations, and pay all costs incurred by the permit requirements. The Contractor shall pay all business taxes or license fees that are required for the work. 7-6 THE CONTRACTOR'S REPRESENTATIVE. Before starting work, the Contractor shall designate in writing a representative who shall have complete authority to act for it. An alternative representative may be designated as well. The representative or alternate shall be present at the Work site whenever work is in progress or whenever actions of the elements necessitate its presence to take measures necessary to protect the Work, persons, or property. Any order or communication given to this representative shall be deemed delivered to the Contractor. A joint venture shall designate only one representative and alternate. In the absence of the Contractor or its representative, instructions or directions may be given by the Engineer to the superintendent or person in charge of the specific work to which the order applies. Such order shall be complied with promptly and referred to the Contractor or its representative. In order to communicate with the Agency, the Contractor's representative, superintendent, or person in charge of specific work shall be able to speak, read, and write the English language. 7-7 COOPERATION AND COLLATERAL WORK. The Contractor shall be responsible for ascertaining the nature and extent of any simultaneous, collateral, and essential work by others. The Agency, its workers and contractors and others, shall have the right to operate within or adjacent to the Work site during the performance of such work. The Agency, the Contractor, and each of such workers, contractors and others, shall coordinate their operations and cooperate to minimize interference. Revised 6/15/17 Contract No. 6335 Page 97 of 176 The Contractor shall include in its Bid all costs involved as a result of coordinating its work with others. the Contractor will not be entitled to additional compensation from the Agency for damages resulting from such simultaneous, collateral, and essential work. If necessary to avoid or minimize such damage or delay, the Contractor shall redeploy its work force to other parts of the Work. Should the Contractor be delayed by the Agency, and such delay could not have been reasonably foreseen or prevented by the Contractor, the Engineer will determine the extent of the delay, the effect on the project, and any extension of time. 7-7.1 Coordination. The Contractor shall coordinate and cooperate with all the utility companies during the relocation or construction of their lines. The Contractor may be granted a time extension if, in the opinion of the Engineer, a delay is caused by the utility company. No additional compensation will be made to the Contractor for any such delay. 7-8 PROJECT SITE MAINTENANCE. 7-8.1 Cleanup and Dust Control. Throughout all phases of construction, including suspension of work, and until the final acceptance, the Contractor shall keep the site clean and free from rubbish and debris. The Contractor shall also abate dust nuisance by cleaning, sweeping and sprinkling with water, or other means as necessary. The use of water resulting in mud on public streets will not be permitted as a substitute for sweeping or other methods. When required by the Plans or Specifications, the Contractor shall furnish and operate a self- loading motor sweeper with spray nozzles at least once each working day for the purpose of keeping paved areas acceptably clean wherever construction, including restoration, is incomplete. Materials and equipment shall be removed from the site as soon as they are no longer necessary. Before the final inspection, the site shall be cleared of equipment, unused materials, and rubbish so as to present a satisfactory clean and neat appearance. All cleanup costs shall be included in the Contractor's Bid. Care shall be taken to prevent spillage on haul routes. Any such spillage shall be removed immediately and the area cleaned. Excess excavation material from catch basins or similar structures shall be removed from the site immediately. Sufficient material may remain for use as backfill if permitted by the Specifications. Forms and form lumber shall be removed from the site as soon as practicable after stripping. Failure of the Contractor to comply with the Engineer's cleanup orders may result in an order to suspend work until the condition is corrected. No additional compensation will be allowed as a result of such suspension. Cleanup and dust control required herein shall also be executed on weekends and other non-working days when needed to preserve the health safety or welfare of the public. The Contractor shall conduct effective cleanup and dust control throughout the duration of the Contract. The Engineer may require increased levels of cleanup and dust control that, in his/her sole discretion, are necessary to preserve the health, safety and welfare of the public. Cleanup and dust control shall be considered incidental to the items of work that they are associated with and no additional payment will be made therefore. 4r. —1- Revised 6/15/17 Contract No. 6335 Page 98 of 176 7-8.2 Air Pollution Control. The Contractor shall not discharge smoke, dust, or any other air contaminants into the atmosphere in such quantity as will violate the regulations of any legally constituted authority. 7-8.3 Vermin Control. At the time of acceptance, structures entirely constructed under the Contract shall be free of rodents, insects, vermin, and pests. Necessary extermination work shall be arranged and paid for by the Contractor as part of the Work within the Contract time, and shall be performed by a licensed exterminator in accordance with requirements of governing authorities. The Contractor shall be liable for injury to persons or property and responsible for the elimination of offensive odors resulting from extermination operations. 7-8.4 Sanitation. The Contractor shall provide and maintain enclosed toilets for the use of employees engaged in the Work. These accommodations shall be maintained in a neat and sanitary condition. They shall also comply with all applicable laws, ordinances, and regulations pertaining to public health and sanitation of dwellings and camps. Wastewater shall not be interrupted. Should the Contractor disrupt existing sewer facilities, sewage shall be conveyed in closed conduits and disposed of in a sanitary sewer system. Sewage shall not be permitted to flow in trenches or be covered by backfill. 7-8.6 Temporary Light, Power, and Water. The Contractor shall furnish, install, maintain, and remove all temporary light, power, and water at its own expense. These include piping, wiring, lamps, and other equipment necessary for the Work. The Contractor shall not draw water from any fire hydrant (except to extinguish a fire), without obtaining permission from the water agency concerned. The Contractor shall obtain a construction meter for water used for the construction, plant establishment, maintenance, cleanup, testing and all other work requiring water related to this contract. The Contractor shall contact the appropriate water agency for requirements. The Contractor shall pay all costs of temporary light, power and water including hookup, service, meter and any, and all, other charges, deposits and/or fees therefore. Said costs shall be considered incidental to the items of work that they are associated with and no additional payment will be made therefore. 7-8.6 Water Pollution Control. The Contractor shall exercise every reasonable precaution to protect channels, storm drains, and bodies of water from pollution. It shall conduct and schedule operations so as to minimize or avoid muddying and silting of said channels, drains, and waters. Water pollution control work shall consist of constructing those facilities which may be required to provide prevention, control, and abatement of water pollution. The Contractor shall comply with the California State Water Resources Control Board (SWRCB) Order Number 99-08-DWQ, National Pollutant Discharge Elimination System (NPDES) General Permit Number CAS000002, Waste Discharge Requirements for Discharges of Stormwater Runoff associated with Construction Activity (General Permit) and subsequent adopted modifications and with all requirements of the Storm Water Pollution Prevention and Monitoring Plans for this project in accordance with these regulations. 7-8.7 Drainage Control. The Contractor shall maintain drainage within and through the work areas. Earth dams will not be permitted in paved areas. Temporary dams of sandbags, asphaltic concrete, or other acceptable material will be permitted when necessary.' Such dams shall be removed from the site as soon as their use is no longer necessary. Revised 6/15/17 Contract No. 6335 Page 99 of 176 7-8.8 Noise Control. All internal combustion engines used in the construction shall be equipped with mufflers in good repair when in use on the project with special attention to the City Noise Control Ordinance, Carlsbad Municipal Code Chapter 8.48. 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS. The Contractor shall be responsible for the protection of public and private property adjacent to the Work and shall exercise due caution to avoid damage to such property. The Contractor shall repair or replace all existing improvements within the right-of-way which are not designated for removal (e.g., curbs, sidewalks, driveways, fences, walls, signs, utility installations, pavement, structures, etc.) which are damaged or removed as a result of its operations. When a portion of a sprinkler system within the right-of-way must be removed, the remaining lines shall be capped. Repairs and replacements shall be at least equal to existing improvements and shall match them in finish and dimension. Maintenance of street and traffic signal systems that are damaged, temporarily removed or relocated shall be done in conformance with 307-1.5. Trees, lawns, and shrubbery that are not to be removed shall be protected from damage or injury. If damaged or removed due to Contractor's operations, they shall be restored or replaced in as nearly the original condition and location as is reasonably possible. Lawns shall be reseeded and covered with suitable mulch. The Contractor shall give reasonable notice to occupants or owners of adjacent property to permit them to salvage or relocate plants, trees, fences, sprinklers, and other improvements, within the right-of-way which are designated for removal and would be destroyed because of the Work. All costs to the Contractor for protecting, removing, and restoring existing improvements shall be included in the Bid. 7-10 PUBLIC CONVENIENCE AND SAFETY. 7-10.1 Traffic and Access. The Contractor's operations shall cause no unnecessary inconvenience. The access rights of the public shall be considered at all times. Unless otherwise authorized, traffic shall be permitted to pass through the Work, or an approved detour shall be provided. Safe and adequate pedestrian and vehicular access shall be provided and maintained to: fire hydrants; commercial and industrial establishments; churches, schools and parking lots; service stations and motels; hospitals; police and fire stations; and establishments of similar nature. Access to these facilities shall be continuous and unobstructed unless otherwise approved by the Engineer. Safe and adequate pedestrian zones and public transportation stops, as well as pedestrian crossings of the Work at intervals not exceeding 90 m (300 feet), shall be maintained unless otherwise approved by the Engineer. Vehicular access to residential driveways shall be maintained to the property line except when necessary construction precludes such access for reasonable periods of time. If backfill has been completed to the extent that safe access may be provided, and the street is opened to local traffic, the Contractor shall immediately clear the street and driveways and provide and maintain access. Ofk %IP Revised 6/15/17 Contract No. 6335 Page 100 of 176 The Contractor shall cooperate with the various parties involved in the delivery of mail and the collection and removal of trash and garbage to maintain existing schedules for these services. Grading operations, roadway excavation and fill construction shall be conducted by the Contractor in a manner to provide a reasonably satisfactory surface for traffic. When rough grading is completed, the roadbed surface shall be brought to a smooth, even condition satisfactory for traffic. Unless otherwise authorized, work shall be performed in only one-half the roadway at one time. One half shall be kept open and unobstructed until the opposite side is ready for use. If one-half a street only is being improved, the other half shall be conditioned and maintained as a detour. The Contractor shall schedule the work so as to prevent damage by all traffic, including but not limited to mail delivery. The Contractor shall not schedule work so as to conflict with trash pickup. The trash hauling schedule can be obtained by calling the City's contracted waste disposal company, Coast Waste Management at 929-9417. During overlay operations, the Contractors schedule for overlay application shall be designated to provide residents and business owners whose streets are to be overlaid sufficient paved parking within an 800 foot distance from their homes or businesses. Seventy-two hours prior to the start of any construction in the public right-of-way that affects vehicular traffic and/or parking or pedestrian routes, the Contractor shall give written notification of the impending disruption. For a full street closure, all residences and/or businesses on the affected street or alley shall be notified. For partial street closures, or curb, sidewalk and driveway repairs, the residences and/or businesses directly affected by the work shall be notified. The notification shall be hand delivered and shall state the date and time the work will begin and its anticipated duration. The notification shall list two telephone numbers that may be called to obtain additional information. One number shall be the Contractor's permanent office or field office and the other number shall be a 24-hour number answered by someone who is knowledgeable about the project. At least one of the phone numbers shall be in the (760) area code. An answering machine shall not be connected to either number. The notification shall also give a brief description of the work and simple instructions to the home or business owner on what they need to do to facilitate the construction. The Contractor shall submit the contents of the notification to the Engineer for approval. Notices shall not be distributed until approved by the Engineer. For residences, the notification shall be pre-cut in a manner that enables it to be affixed to a doorknob without adhesives. It shall be a minimum size of 3-1/2 inches by 8-1/2 inches and shall be brightly colored with contrasting printing. The material shall be equivalent in strength and durability to 65 lb. card stock. The printing on the notice shall be no smaller than 12 point. An example of such notice is provided in Appendix "A". In addition to the notifications, the contractor shall post no parking signs 72 hours in advance of the work being performed. The no parking signs shall state the date and time of parking restriction for a duration not to exceed the time necessary to complete the work at that location. Failure of the contractor to meet the posted date requires re-posting the no parking signs 72 hours in advance of the rescheduled work. If the work is delayed or rescheduled the no parking signs shall be removed and re-posted 72 hours in advance of the rescheduled work. fiNj Revised 6/15/17 Contract No. 6335 Page 101 of 176 The preparation, materials, printing and distribution of the notifications shall be included in the contract price bid for traffic control and the Contractor will not be entitled to any additional compensation for printing and distributing these notices. The contractor shall replace all street markings and striping damaged by construction activities. The Contractor shall include in its Bid all costs for the above requirements. 7-10.2 Storage of Equipment and Materials in Public Streets. Construction materials shall not be stored in streets, roads, or highways for more than 5 days after unloading. All materials or equipment not installed or used in construction within 5 days after unloading shall be stored elsewhere by the Contractor at its expense unless authorized additional storage time. Construction equipment shall not be stored at the Work site before its actual use on the Work nor for more than 5 days after it is no longer needed. Time necessary for repair or assembly of equipment may be authorized by the Engineer. Excavated material, except that which is to be used as backfill in the adjacent trench, shall not be stored in public streets unless otherwise permitted. After placing backfill, all excess material shall be removed immediately from the site. 7-10.3 Street Closures, Detours, Barricades. The Contractor shall comply with all applicable State, County, and City requirements for closure of streets. The Contractor shall provide barriers, guards, lights, signs, temporary bridges, flagpersons, and watchpersons. The Contractor shall be responsible for compliance with additional public safety requirements which may arise. The Contractor shall furnish and install signs and warning devices and promptly remove them upon completion of the Work. After obtaining the Engineers approval and at least 5 working days before closing, detouring, partially closing or reopening any street, alley or other public thoroughfare the Contractor shall notify the following: 1. The Engineer 760-602-2720 2. Carlsbad Fire Department Dispatch 760-931-2197 3. Carlsbad Police Department Dispatch 760-931-2197 4. Carlsbad Traffic Signals Maintenance (extension 2937) 760-438-2980 5. Carlsbad Traffic Signals Operations 760-602-2752 6. North County Transit District 760-967-2828 7. Waste Management 760-929-9400 The Contractor shall comply with their requirements. The Contractor shall obtain the Engineer's written approval prior to deviating from the requirements of 2) through, and including, 7) above. The Contractor shall obtain the written approval no less than five working days prior to placing any traffic control that affects bus stops. The Contractor shall secure approval, in advance, from authorities concerned for the use of any bridges proposed by it for public use. Temporary bridges shall be clearly posted as to load limit, with signs and posting conformina to nurrp.nt requiremonts noverina "signs" as set forth in the Traffic Manual published by the California Department of Transportation. This manual shall also apply to the street closures, barricades, detours, lights, and other safety devices required. 1%41' Revised 6/15/17 Contract No. 6335 Page 102 of 176 All costs involved shall be included in the Bid. Traffic controls shall be in accordance with the plans, The California Manual on Uniform Traffic Control Devices (FHWA MUTCD latest edition, as amended for use in California) and these provisions. If any component in the traffic control system is damaged, displaced, or ceases to operate or function as specified, from any cause, during the progress of the work, the Contractor shall immediately repair said component to its original condition or replace said component and shall restore the component to its original location. In the event that the Contractor fails to install and/or maintain barricades or such other traffic signs, markings, delineation or devices as may be required herein, the Engineer may, at his/her sole option, install the traffic signs, markings, delineation or devices and charge the Contractor twenty dollars ($25.00) per day per traffic sign or device, or the actual cost of providing such traffic control facility, whichever is the greater. 7-10.3.1 Construction Area Signs and Control Devices. All construction traffic signs and control devices shall be maintained throughout the duration of work in good order and according to the approved traffic control plan. All construction area signs shall conform to the provisions of Section 206-7.2 et seq. All temporary reflective pavement markers shall conform to the provisions of Section 214-5.1.et seq. All temporary reflective channelizers shall conform to the provisions of Section 214-5.2 et seq. All paint for temporary traffic striping, pavement marking, and curb marking shall conform to the provisions of Section 210-1.6 et seq. except that all temporary paint shall be rapid dry water borne conforming to Section 210-1.6 for materials and Section 310-5 et seq. For workmanship. Warning and advisory signs, lights and devices installed or placed to provide traffic control, direction and/or warning shall be furnished, installed and maintained by the Contractor. Warning and advisory signs, lights and devices shall be promptly removed by the Contractor when no longer required. Warning and advisory signs that remain in place overnight shall be stationary mounted signs. Stationary signs that warn of non-existent conditions shall be removed from the traveled way and from the view of motorists in the traveled way or shielded from the view of the traveling public during such periods that their message does not pertain to existing conditions. Care shall be used in performing excavation for signs in order to protect underground facilities. All excavation required to install stationary construction area signs shall be performed by hand methods without the use of power equipment. Warning and advisory signs that are used only during working hours may be portable signs. Portable signs shall be removed from the traveled way and shielded from the view of the traveling public during non-working hours. During the hours of darkness, as defined in Division 1, Section 280, of the California Vehicle Code, portable signs shall be illuminated or, at the option of the Contractor, shall be in conformance with the provisions in Section 206-7.2 et seq. If illuminated traffic cones rather than post-type delineators are used during the hours of darkness, they shall be affixed or covered with reflective cone sleeves as specified in CALTRANS "Standard Specifications", except the sleeves shall be 7" long. Personal vehicles of the Contractor's employees shall not be parked within the traveled way, including any Section closed to public traffic. Whenever the Contractor's vehicles or equipment are parked on the shoulder within 6' of a traffic lane, the shoulder area shall be closed with fluorescent traffic cones or portable delineators placed on a taper in advance of the parked vehicles or equipment and along the edge of the pavement at not less than 25' intervals to a point not less than 25' past the last vehicle or piece of equipment. A minimum of nine (9) cones or portable delineators shall be used for the taper. A W20-1 (Road Work Ahead) or C24 (Shoulder Work Ahead) sign shall be mounted, as required herein, on a signpost or telescoping flag tree with flags. The signpost or flag tree shall be placed where directed by the Engineer. 7-10.3.2 Maintaining Traffic. The Contractor's personnel shall not work closer than six feet minimum acceptable lateral safety buffer distance, nor operate equipment within two feet from II* fail --r- Revised 6/15/17 Contract No. 6335 Page 103 of 176 any traffic lane occupied by traffic. The minimum acceptable distance of two feet shall be measured from the closest approach of any part of the equipment as it is operated and/or maneuvered in performing the work. This requirement may be waived when the Engineer has given written authorization to the reduction in clearance that is specific to the time, duration and location of such waiver, when such reduction is shown on the traffic control plans included in these contract documents, when such reduction is shown on the traffic control plans prepared by the Contractor and approved by the Engineer or for the work of installing, maintaining and removing traffic control devices. As a condition of such waiver the Engineer may require the Contractor to detour traffic, adjust the width of, or realign the adjacent traffic lane, close the adjacent traffic lane or provide barriers. During the entire construction, a minimum of one paved traffic lanes, not less than twelve feet wide, shall be open for use by public traffic in each direction of travel. 7-10.3.3 Traffic Control System for Lane Closure. A traffic control system consists of closing traffic lanes or pedestrian walkways in accordance with the details shown on the plans, California Manual on Uniform Traffic Control Devices (FHWA MUTCD latest edition, as amended for use in California) and provisions under "Maintaining Traffic" elsewhere in these Provisions. The provisions in this section will not relieve the Contractor from its responsibility to provide such additional devices or take such measures as may be necessary to maintain public safety. When lanes are closed for only the duration of work periods, all components of the traffic control system, except portable delineators placed along open trenches or excavation adjacent to the traveled way, shall be removed from the traveled way and shoulder at the end work period. If the Contractor so elects, said components may be stored at selected central locations, approved by the Engineer, within the limits of the right-of-way. 7-10.3.4 Traffic Control for Permanent and Temporary Traffic Striping. During traffic stripe operations, traffic shall be controlled with lane closures, as provided for under "Traffic Control System for Lane Closure" of these Supplemental Provisions or by use of an alternative traffic control plan proposed by the Contractor and approved by the Engineer. The Contractor shall not start traffic striping operations using an alternative plan until the Contractor has submitted its plan to the Engineer and has received the Engineer's written approval of said plan. 7-10.3.5 Temporary Pavement Delineation. Temporary pavement delineation shall be furnished, placed, maintained and removed in accordance with the minimum standards specified in the California Manual on Uniform Traffic Control Devices (FHWA MUTCD latest edition, as amended for use in California) published by CALTRANS. Whenever the work causes obliteration of pavement delineation, temporary or permanent pavement delineation shall be in place prior to opening the traveled way to public traffic. Lane line or centerline pavement delineation shall be provided at all times for traveled ways open to public traffic. All work necessary, including any required lines or marks, to establish the alignment of temporary pavement delineation shall be performed by the Contractor. When temporary pavement delineation is removed, all lines and marks used to establish the alignment of the temporary pavement delineation shall be removed by grinding. Surfaces to receive temporary pavement delineation shall be dry and free of dirt and loose material. Temporary pavement delineation shall not be applied over existing pavement delineation or other temporary pavement delineation. Temporary pavement delineation shall be maintained until superseded or replaced with permanent pavement delineation. —1- Revised 6/15/17 Contract No. 6335 Page 104 of 176 Temporary pavement delineation shall be removed when, as determined by the Engineer, the temporary pavement delineation conflicts with the permanent pavement delineation or with a new traffic pattern for the area and is no longer required for the direction of public traffic. When temporary pavement delineation is required to be removed, all lines and marks used to establish the alignment of the temporary pavement delineation shall be removed. 7-10.3.6 Preparation of New, or Modifications and Additions to Existing, Traffic Control Plan Sheets. If no traffic control plans (TCP) or Traffic Control Staging plans (TCP) are included in the project plans, or if the Contractor elects to modify TCP included in the project plans, the Contractor shall have such new or modified TCP prepared and submitted as a part of the Work for any and all construction activities that are located within the traveled way. The Contractor shall have TCP prepared and submitted as a part of the Work for any construction activities that are a part of this project that are not included in the project plans. The Contractor must submit the TCP for the Engineer's review in conformance with the requirements of Section 2-5.3, et seq. and obtain the Engineer's approval of the TCP prior to implementing them. The minimum 20-day review period specified in Section 2-5.3.1 for shop drawings and submittals shall pertain to each submittal of TCP, new, modified or added to, for the Engineer's review. New or revised TCP submittals shall include all TCP needed for the entire duration of the Work. Each phase of the TCP shall be shown in sufficient scale and detail to show the lane widths, transition lengths, curve radii, stationing of features affecting the traffic control plan and the methodology proposed to transition to the subsequent TCP phase. When the vertical alignment of the traveled surface differs from the finished pavement elevation vertical curves must also be shown. Such modifications, supplements and/or new design of TCP shall meet the requirements of the Engineer and the California Manual on Uniform Traffic Control Devices (FHWA MUTCD latest edition, as amended for use in California as published by CALTRANS. Such modification, addition, supplement, and/or new design of TCP shall be prepared by a registered professional engineer appropriately registered in the State of California. The Engineer shall be the sole judge of the suitability and quality of any such modifications, supplements, and/or new designs to TCP. The Engineer may approve any such modifications, supplements, and/or new designs to the TCP when, in the Engineer's sole opinion, such modifications, supplements, and/or new designs to the TCP prepared by the registered professional engineer retained by the Contractor will be beneficial to the best interests of the Agency. Such modification, addition, supplement, and/or new design shall not be implemented and no work shall be commenced that is contingent on such approval until the changed TCP are approved by the Engineer. The preparation of such modification, addition, supplement, and/or new designs of TCP shall not presuppose their approval or obligate the Agency in any fashion. Submittal and review requirements for such modifications, supplements, and/or new designs to TCP shall conform to the requirements of Section 2-5.3 Shop Drawings and Submittals. 7-10.3.7 Payment. The Contractor shall prepare and implement traffic control plans and shall furnish all labor and materials to perform, install, maintain, replace and remove all traffic control as incidentals to the work with which they are associated and no other compensation will be allowed therefore. 7-10.4 Safety. 7-10.4.1 Safety Orders. The Contractor shall have at the Work site, copies or suitable extracts of: Construction Safety Orders, Tunnel Safety Orders and General Industry Safety Orders issued by the State Division of Industrial Safety. The Contractor shall comply with provisions of these and all other applicable laws, ordinances, and regulations. •‘' Revised 6/15/17 Contract No. 6335 Page 105 of 176 Before excavating any trench 5 feet or more in depth, the Contractor shall submit a detailed plan to the Agency showing the design of shoring, bracing, sloping, or other provisions to be made for the workers' protection from the hazard of caving ground during the excavation of such trench. If the plan varies from the shoring system standards, the plan shall be prepared by a registered Civil Engineer. No excavation shall start until the Engineer has accepted the plan and the Contractor has obtained a permit from the State Division of Industrial Safety. A copy of the permit shall be submitted to the Engineer. Payment for performing all work necessary to provide safety measures shall be included in the prices bid for other items of work except where separate bid items for excavation safety are provided, or required by law. 7-10.4.2 Use of Explosives. Explosives may be used only when authorized in writing by the Engineer, or as otherwise stated in the Specifications. Explosives shall be handled, used, and stored in accordance with all applicable regulations. The Engineer's approval of the use of explosives shall not relieve the Contractor from liability for claims caused by blasting operations. 7-10.4.3 Special Hazardous Substances and Processes. Materials that contain hazardous substances or mixtures may be required on the Work. A Material Safety Data Sheet as described in Section 5194 of the California Code of Regulations shall be requested by the Contractor from the manufacturer of any hazardous products used. Material usage shall be accomplished with strict adherence to California Division of Industrial Safety requirements and all manufacturer warnings and application instructions listed on the Material Safety Data Sheet and on the product container label. The Contractor shall notify the Engineer if a specified product cannot be used under safe conditions. 7-10.4.4 Confined Spaces. (a) Confined Space Entry Program. The Contractor shall be responsible for implementing, administering and maintaining a confined space entry program (CSEP) in accordance with Sections 5156, 5157 and 5158, Title 8, CCR. Prior to starting the Work, the Contractor shall prepare and submit its comprehensive CSEP to the Engineer. The CSEP shall address all potential physical and environmental hazards and contain procedures for safe entry into confined spaces, including, but not limited to the following: 1.Training of personnel 2.Purging and cleaning the space of materials and residue 3.Potential isolation and control of energy and material inflow 4.Controlled access to the space 5.Atmospheric testing of the space 6.Ventilation of the space 7.Special hazards consideration 8.Personal protective equipment 9.Rescue plan provisions 4% t —1- Revised 6/15/17 Contract No. 6335 Page 106 of 176 The Contractor's submittal shall include the names of its personnel, including subcontractor personnel, assigned to the project who will have CSEP responsibilities, their CSEP training, and their specific assignment and responsibility in carrying out the CSEP. (b)Permit-Required Confined Spaces. Entry into permit-required confined spaces as defined in Section 5157, Title 8, CCR may be required as a part of the Work. All manholes, tanks, vaults, pipelines, excavations, or other enclosed or partially enclosed spaces shall be considered permit- required confined spaces until the pre-entry procedures demonstrate otherwise. The Contractor shall implement a permit space program prior to performing any work in a permit-required confined space. A copy of the permit shall be available at all times for review by Contractor and Agency personnel at the Work site. (c)Payment. Payment for implementing, administering, and providing all equipment and personnel to perform the CSEP shall be included in the bid items for which the CSEP is required. 7-10.4.5 Safety and Protection of Workers and Public. The Contractor shall take all necessary precautions for the safety of employees on the work and shall comply with all applicable provisions of Federal, State and Municipal safety laws and building codes to prevent accidents or injury to persons on, about, or adjacent to the premises where the work is being performed. The Contractor shall erect and properly maintain at all times, as required by the conditions and progress of the work, all necessary safeguards for the protection of workers and public, and shall use danger signs warning against hazards created by such features of construction as protruding nails, hoists, well holes, and falling materials. 7-11 PATENT FEES OR ROYALTIES. The Contractor shall absorb in its Bid the patent fees or royalties on any patented article or process furnished or used in the Work. The Contractor shall indemnify and hold the Agency harmless from any legal action that may be brought for infringement of patents. 7-12 ADVERTISING. The names, addresses and specialties of Contractors, Subcontractors, architects, or engineers may be displayed on removable signs. The size and location shall be subject to the Engineer's approval. Commercial advertising matter shall not be attached to or painted on the surfaces of buildings, fences, canopies, or barricades. 7-13 LAWS TO BE OBSERVED. The Contractor shall keep fully informed of State and National laws and County and Municipal ordinances and regulations which in any manner affect those employed in the Work or the materials used in the Work or in any way affect the conduct of the Work. The Contractor shall at all times observe and comply with such laws, ordinances, and regulations. Municipal ordinances that affect this work include Chapter 11.06. Excavation and Grading. If this notice specifies locations or possible materials, such as borrow pits or gravel beds, for use in the proposed construction project which would be subject to Section 1601 or Section 1603 of the Fish and Game Code, the conditions established pursuant to Section 1601 et seq. of the Fish and Game Code shall become conditions of the contract. 7-14 ANTITRUST CLAIMS. Section 7103.5 of the Public Contract Code provides: "In entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or subcontractor offers and agrees to assign to the awarding body all rights, title, and interest in and tm, Revised 6/15/17 Contract No. 6335 Page 107 of 176 to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec 15) or Cartwright Act (Chapter 2 [commencing with Section 16700] of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or subcontract. The assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment of the parties." ta rt —1- Revised 6/15/17 Contract No. 6335 Page 108 of 176 SECTION 8 - FACILITIES FOR AGENCY PERSONNEL 8-1 GENERAL. No facilities provided for Agency personnel shall be required. Revised 6/15/17 Contract No. 6335 Page 109 of 176 SECTION 9 - MEASUREMENT AND PAYMENT 9-1 MEASUREMENT OF QUANTITIES FOR UNIT PRICE WORK. 9-1.1 General. Unless otherwise specified, quantities of work shall be determined from measurements or dimensions in horizontal planes. However, linear quantities of pipe, piling, fencing and timber shall be considered as being the true length measured along longitudinal axis. Unless otherwise provided in Specifications, volumetric quantities shall be the product of the mean area of vertical or horizontal sections and the intervening horizontal or vertical dimension. The planimeter shall be considered an instrument of precision adapted to measurement of all areas. 9-1.2 Methods of Measurement. Materials and items of work which are to be paid for on basis of measurement shall be measured in accordance with methods stipulated in the particular sections involved. 9-1.3 Certified Weights. When payment is to be made on the basis of weight, the weighing shall be done on certified platform scales or, when approved by the Engineer, on a completely automated weighing and recording system. The Contractor shall furnish the Engineer with duplicate licensed weighmaster's certificates showing actual net weights. The Agency will accept the certificates as evidence of weights delivered. 9-1.4 Units of Measurement. The system of measure for this contract shall be the U.S. Standard Measures. 9-2 LUMP SUM WORK. Items for which quantities are indicated "Lump Sum", "L.S.", or "Job", shall be paid for at the price indicated in the Bid. Such payment shall be full compensation for the items of work and all work appurtenant thereto. When required by the Specifications or requested by the Engineer, the Contractor shall submit to the Engineer within 15 days after award of Contract, a detailed schedule in triplicate, to be used only as a basis for determining progress payments on a lump sum contract or designated lump sum bid item. This schedule shall equal the lump sum bid and shall be in such form and sufficiently detailed as to satisfy the Engineer that it correctly represents a reasonable apportionment of the lump sum. 9-3 PAYMENT 9-3.1 General. The quantities listed in the Bid schedule will not govern final payment. Payment to the Contractor will be made only for actual quantities of Contract items constructed in accordance with the Plans and Specifications. Upon completion of construction, if the actual quantities show either an increase or decrease from the quantities given in the Bid schedule, the Contract Unit Prices will prevail subject to the provisions of Section 3-2.2.1. The unit and lump sum prices to be paid shall be full compensation for the items of work and all appurtenant work, including furnishing all materials, labor, equipment, tools, and incidentals. Payment will not be made for materials wasted or disposed of in a manner not called for under the Contract. This includes rejected material not unloaded from vehicles, material rejected after it t41"Me 0 1- Revised 6/15/17 Contract No. 6335 Page 110 of 176 has been placed, and material placed outside of the Plan lines. No compensation will be allowed for disposing of rejected or excess material. Payment for work performed or materials furnished under an Assessment Act Contract will be made as provided in particular proceedings or legislative act under which such contract was awarded. Whenever any portion of the Work is performed by the Agency at the Contractor's request, the cost thereof shall be charged against the Contractor, and may be deducted from any amount due or becoming due from the Agency. Whenever immediate action is required to prevent injury, death, or property damage, and precautions which are the Contractor's responsibility have not been taken and are not reasonably expected to be taken, the Agency may, after reasonable attempt to notify the Contractor, cause such precautions to be taken and shall charge the cost thereof against the Contractor, or may deduct such cost from any amount due or becoming due from the Agency. Agency action or inaction under such circumstances shall not be construed as relieving the Contractor or its Surety from liability. Payment shall not relieve the Contractor from its obligations under the Contract; nor shall such payment be construed to be acceptance of any of the Work. Payment shall not be construed as the transfer of ownership of any equipment or materials to the Agency. Responsibility of ownership shall remain with the Contractor who shall be obligated to store any fully or partially completed work or structure for which payment has been made; or replace any materials or equipment required to be provided under the Contract which may be damaged, lost, stolen or otherwise degraded in any way prior to acceptance of the Work, except as provided in Section 6- 10. Guarantee periods shall not be affected by any payment but shall commence on the date of recordation of the "Notice of Completion." If, within the time fixed by law, a properly executed notice to stop payment is filed with the Agency, due to the Contractor's failure to pay for labor or materials used in the Work, all money due for such labor or materials will be withheld from payment to the Contractor in accordance with applicable laws. At the expiration of 35 days from the date of acceptance of the Work by the Board, or as prescribed by law, the amount deducted from the final estimate and retained by the Agency will be paid to the Contractor except such amounts as are required by law to be withheld by properly executed and filed notices to stop payment, or as may be authorized by the Contract to be further retained. 9-3.2 Partial and Final Payment. The Engineer will, after award of Contract, establish a closure date for the purpose of making monthly progress payments. The Contractor may request in writing that such monthly closure date be changed. The Engineer may approve such request when it is compatible with the Agency's payment procedure. Each month, the Engineer will make an approximate measurement of the work performed to the closure date as basis for making monthly progress payments. The estimated value will be based on contract unit prices, completed change order work and as provided for in Section 9-2 of these General Provisions. Progress payments shall be made no later than thirty (30) calendar days after the closure date. Five (5) working days following the closure date, the Engineer shall complete ir1W tat --r- Revised 6/15/17 Contract No. 6335 Page 111 of 176 the detailed progress pay estimate and submit it to the Contractor for the Contractor's information. Should the Contractor assert that additional payment is due, the Contractor shall within ten (10) days of receipt of the progress estimate, submit a supplemental payment request to the Engineer with adequate justification supporting the amount of supplemental payment request. Upon receipt of the supplemental payment request, the Engineer shall, as soon as practicable after receipt, determine whether the supplemental payment request is a proper payment request. If the Engineer determines that the supplemental payment request is not proper, then the request shall be returned to the Contractor as soon as practicable, but not later than seven (7) days after receipt. The returned request shall be accompanied by a document setting forth in writing the reasons why the supplemental payment request was not proper. In conformance with Public Contract Code Section 20104.50, the City shall make payments within thirty (30) days after receipt of an undisputed and properly submitted supplemental payment request from the Contractor. If payment of the undisputed supplemental payment request is not made within thirty (30) days after receipt by the Engineer, then the City shall pay interest to the Contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure. From each progress estimate, 10 percent will be deducted and retained by the Agency, and the remainder less the amount of all previous payments will be paid. After 50 percent of the Work has been completed and if progress on the Work is satisfactory, the deduction to be made from remaining progress estimates and from the final estimate may be limited to $500 or 10 percent of the first half of total Contract amount, whichever is greater. No progress payment made to the Contractor or its sureties will constitute a waiver of the liquidated damages under 6-9. As provided in Section 22300 of the California Public Contract Code, the Contractor may substitute securities for any monies withheld by the Agency to ensure performance under the Contract. After final inspection, the Engineer will make a Final Payment Estimate and process a corresponding payment. This estimate will be in writing and shall be for the total amount owed the Contractor as determined by the Engineer and shall be itemized by the contract bid item and change order item with quantities and payment amounts and shall show all deductions made or to be made for prior payments and amounts to be deducted under provisions of the contract. All prior estimates and progress payments shall be subject to correction in the Final Payment Estimate. The Contractor shall have 30 calendar days from receipt of the Final Payment Estimate to make written statement disputing any bid item or change order item quantity or payment amount. The Contractor shall provide all documentation at the time of submitting the statement supporting its position. Should the Contractor fail to submit the statement and supporting documentation within the time specified, the Contractor acknowledges that full and final payment has been made for all contract bid items and change order items. If the Contractor submits a written statement with documentation in the aforementioned time, the Engineer will review the disputed item within 30 calendar days and make any appropriate adjustments on the Final Payment. Remaining disputed quantities or amounts not approved by the Engineer will be subject to resolution as specified in Section 3-5, Disputed Work. The written statement filed by the Contractor shall be in sufficient detail to enable the Engineer to ascertain the basis and amount of said disputed items. The Engineer will consider the merits of —1- Revised 6/15/17 Contract No. 6335 Page 112 of 176 the Contractor's claims. It will be the responsibility of the Contractor to furnish within a reasonable time such further information and details as may be required by the Engineer to determine the facts or contentions involved in its claims. Failure to submit such information and details will be sufficient cause for denying payment for the disputed items. 9-3.2.1 Payment for Claims. Except for those final payment items disputed in the written statement required in Section 9-3.2 all claims of any dollar amount shall be submitted in a written statement by the Contractor no later than the date of receipt of the final payment estimate. Those final payment items disputed in the written statement required in Section 9-3.2 shall be submitted no later than 30 days after receipt of the Final Payment estimate. No claim will be considered that was not included in this written statement, nor will any claim be allowed for which written notice or protest is required under any provision of this contract including Sections 3-4 Changed Conditions, 3-5 Disputed Work, 6-6.3 Payment for Delays to Contractor, 6-6.4 Written Notice and Report, or 6-7.3 Contract Time Accounting, unless the Contractor has complied with notice or protest requirements. The claims filed by the Contractor shall be in sufficient detail to enable the Engineer to ascertain the basis and amount of said claims. The Engineer will consider and determine the Contractor's claims and it will be the responsibility of the Contractor to furnish within a reasonable time such further information and details as may be required by the Engineer to determine the facts or contentions involved in its claims. Failure to submit such information and details will be sufficient cause for denying the claims. Payment for claims shall be processed within 30 calendar days of their resolution for those claims approved by the Engineer. The Contractor shall proceed with informal dispute resolution under Section 3-5, Disputed Work, for those claims remaining in dispute. 9-3.3 Delivered Materials. When provided for in the Specifications, and subject to the limitation and conditions therein, the cost of materials and equipment delivered but not incorporated into the Work will be included in the progress estimate. 9-3.3.1 Delivered Materials. The cost of materials and equipment delivered but not incorporated into the work will not be included in the progress estimate. 9-3.4 Mobilization. When a bid item is included in the Proposal form for mobilization and subject to the conditions and limitations in the Specifications, the costs of work in advance of construction operations and not directly attributable to any specific bid item will be included in the progress estimate. When no such bid item is provided, payment for such costs will be considered to be included in the other items of work. 9-3.4.1 Mobilization and Preparatory Work. 9-3.4.1 Mobilization and Preparatory Work. Payment for mobilization and preparatory Work will be included in the various items of work and no other payment will be made. 9-4 BID ITEMS. Payment for each Bid Item shall be made at the quantity and type as listed in the Contractor's Proposal. All work shown or mentioned on the plans, in the Contract Documents, General Provisions, or Technical Provisions/Specifications shall be considered as included in the Bid Items. Contractor must protect existing utilities, improvements, landscaping, irrigation systems, and vegetation in place. If damaged during the work, Contractor is responsible to repair 0/k tat Revised 6/15/17 Contract No. 6335 Page 113 of 176 or replace any utilities, improvements, landscaping, irrigation systems, and vegetation at his expense. Traffic Signal Improvements (Bid Item No. 1) Lump Sum The contract lump sum price paid for this bid item shall constitute full compensation for furnishing all labor, materials, tools, equipment, incidentals, and for all work involved in the installation of "HAWK" pedestrian hybrid beacon. This includes, but is not limited to, the installation of a traffic signal cabinet and controller, service pedestal, conduit and wiring/cabling, traffic signal poles with foundation per Caltrans standard plans, pull boxes, blank-out signs, EVP detection system, vehicle and pedestrian detection system, etc. The contract lump sum price paid shall be considered full compensation for furnishing all materials, labor, tools, equipment, and all incidentals, necessary to complete the work in accordance with the General Provisions, the Special Provisions, Standard Specifications, plans and as directed by the Engineer. Sawcut as Shown on Plans (Bid Item No.2) Linear Feet The contract unit price paid for this bid item shall constitute full compensation for the sawcutting in accordance with the specifications and contract documents. Construct 6" Type G-2 Curb & Gutter per SDRSD G-2 (Bid Item No.3) Linear Feet The contract unit price paid for this bid item shall constitute full compensation to construct 6" Type G-2 Curb and Gutter per San Diego Regional Standard Drawings G-2 in accordance with the specifications and contract documents. This includes, but is not limited to, surveying, connections, excavation, forming, backfill, base material, compaction, sawcutting, and removing existing sidewalk. Hot Mix Asphalt as Shown on Plans (Bid Item No.4) Ton The contract unit price paid for this bid item shall constitute full compensation to apply Hot Mix Asphalt in accordance with the specifications and contract documents. This includes, but is not limited to, surveying, connections, excavation, forming, backfill, base material, compaction, sawcutting, and removing existing sidewalk. Class 2 Aggregate Base as Shown on Plans (Bid Item No.6) Ton The contract unit price paid for this bid item shall constitute full compensation to apply Class 2 Aggregate Base in accordance with the specifications and contract documents. This includes, but is not limited to, surveying, connections, excavation, forming, backfill, base material, compaction, sawcutting, and removing existing sidewalk. Construct 4" PCC Sidewalk per SDRSD G-7 and G-9 (Bid Item No.6) Square Feet The contract unit price paid for this bid item shall constitute full compensation to construct PCC sidewalk per San Diego Regional Standard Drawings G-7 and G-9 in accordance with the specifications and contract documents. This includes, but is not limited to, surveying, connections, excavation, forming, backfill, base material, compaction, sawcutting, and removing existing sidewalk. Construct Curb Ramp per 6-31 with Federal Yellow Truncated Domes per SDRSD G-30 (Bid Item No.7) Each The contract unit price paid for this bid item shall constitute full compensation to construct curb ramp in accordance with plans and Drawing No. G-30 and G-31 of the 2018 San Diego Regional Standard Drawings, and Sections 201-1, 301-1, and 303-5 of the Standard Specifications of Public Works Construction, 2018 Edition and contract plans. This includes, but is not limited to all —1- Revised 6/15/17 Contract No. 6335 Page 114 of 176 labor, materials, equipment, and other incidentals required for demolition, forming, placing and no additional compensation will be allowed therefor. Construct PPC Cross Gutter as Shown on Plans (Bid Item No. 8) Lump Sum The contract unit price paid for this bid item shall constitute full compensation to furnish and install concrete cross gutter in accordance with Sections 201-1, 301-1, and 303-5 of the Standard Specifications of Public Works Construction, 2018 Edition; Drawing No. G-12 of the San Diego Regional Standard Drawings, the plans and contract documents. This includes, but is not limited to all labor, materials, equipment, and other incidentals required for demolition, forming, placing and no additional compensation will be allowed therefor. Furnish and Install Curb Channel and Metal Grate (Bid Item No. 9) Linear Feet The contract unit price paid for this bid item shall include providing complete furnishing and installing of curb channel and metal grate per plan. The contract unit price paid shall be considered full compensation for furnishing all materials, labor, tools, equipment, and all incidentals, necessary to complete the work in accordance with the General Provisions, the Special Provisions, Standard Specifications, plans and as directed by the Engineer. Remove and Salvage Existing Flashing Beacon Assembly complete. Break foundation down 3' below grade (Bid Item No. 10) Each The contract unit price paid for this bid item shall include providing complete removal of existing flashing beacon assembly and returning to City yard. The foundation shall be broken down 3; below grade. The contract unit price paid shall be considered full compensation for furnishing all materials, labor, tools, equipment, and all incidentals, necessary to complete the work in accordance with the General Provisions, the Special Provisions, Standard Specifications, plans and as directed by the Engineer. Adjust to Grade Existing Water Meter Box (Bid Item No. 11) Each The contract unit price paid for this bid item shall include providing complete adjustment to grade existing water meter box. The contract unit price paid shall be considered full compensation for furnishing all materials, labor, tools, equipment, and all incidentals, necessary to complete the work in accordance with the General Provisions, the Special Provisions, Standard Specifications, plans and as directed by the Engineer. Remove Existing Fire Hydrant and Lateral. Furnish and Install New Fire Hydrant with Lateral and Valve (Bid Item No. 1-2) Each The contract unit price paid for this bid item shall include providing complete removal of existing fire hydrant and lateral and furnishing and installing new fire hydrant assembly with lateral and valve per Carlsbad Municipal Water District (CMWD) Standard Drawing No. W-12 and trench per Drawing No. W-2. Backfill and resurface shall be per City of Carlsbad Supplemental Standard No. GS-24 and GS-28. The contract unit price paid shall be considered full compensation for furnishing all materials, labor, tools, equipment, and all incidentals, necessary to complete the work in accordance with the General Provisions, the Special Provisions, Standard Specifications, plans and as directed by the Engineer. Coordinate with SDG&E for Service Point Requirements and Install as Required (Bid Item No. 13) Lump Sum The contract lump sum price paid for this bid item shall constitute fill compensation for furnishing all labor, materials, tools, equipment, incidentals, and for all work involved in the installation of an SDG&E service point. This includes, but is not limited to, the installation of SDG&E approved pull tale Revised 6/15/17 Contract No. 6335 Page 115 of 176 box, 3" PVC conduit up to 400' in length to SDG&E assigned point-of-connection, 3" PVC conduit riser on power pole to SDG&E assigned transformer, coordination with SDG&E planner and inspector, installation of SDG&E approved conductors, etc. The contract lump sum price paid shall be considered full compensation for furnishing all materials, labor, tools, equipment, and all incidentals, necessary to complete the work in accordance with the General Provisions, the Special Provisions, Standard Specifications, plans and as directed by the Engineer. Signing, Striping and Pavement Markings (Bid Item No. 14) Lump Sum The contract lump sum price paid for this bid item shall constitute full compensation for the signing and striping in accordance with Section 701 of Standard Specifications for Public Works Construction, the plans and contract documents. This includes, but is not limited to all labor, materials, equipment, and other incidentals required for removal, layout, placement, and no additional compensation will be allowed therefor. Mobilization (Bid Item No.15) Lump Sum Mobilization shall consist of all preparatory work and operations which must be performed, or costs incurred prior to beginning work on the various Contract items on all project sites. Mobilization shall include but not be limited to the following items: 1.Obtaining and paying for all required Bonds, Insurance Policies (including premiums and incidentals), and Permits 2.Submittal of required construction schedule(s). 3.Establishment of all offices, buildings, construction yards, sanitary facilities, and any other facilities necessary for work at all project sites. 4.Posting all OSHA required notices and establishment of safety programs. 5.Posting all Department of Labor required notice, regulations and prevailing wages. 6.The movement of personnel, equipment, supplies, and incidentals to all project sites. 7.Developing and installing construction water supply. 8.Notification of residents and businesses No additional compensation will be allowed for additional mobilizations required, including but not limited to delays caused by the relocation of existing utility facilities shown on the Plans or discovered during construction operations. The deletion of work or the addition of extra work as provided for herein shall be reflected in Contract Change Orders and shall not affect the price paid for "Initial Mobilization." Payment for "Mobilization" will be made at the lump allowance named in the Bid Schedule, which price shall constitute full compensation for all such work. Payment for Initial Mobilization will be made as follows: The bid item for mobilization and related items shall not exceed fifteen percent (15%) of the total contract items. The deletion of work or the addition of extra work as provided for herein shall not affect the price paid for Mobilization. z,um price paid for rr,,;;Aization shall include full comper,scia•ni ig di; labor, materials, tool, equipment, the cost of all bonds and insurance policies, and incidentals, and for doing the work involved in mobilization as specified herein. t at -,- Revised 6/15/17 Contract No. 6335 Page 116 of 176 Clearing and Grubbing (Bid Item No. 16) Lump Sum The contract lump sum price paid for this bid item shall constitute full compensation to perform Clearing and Grubbing, including all the operations and requirements in accordance with the contract documents. This includes, but is not limited to, removal and legal disposal of objectionable material including concrete, masonry, vegetation, debris, etc., and no additional compensation will be allowed therefor. Traffic Control (Bid Item No. 17) Lump Sum The contract lump sum price shall constitute full compensation for all traffic control, traffic control plans, and public notification in accordance with the specifications and contract documents. This includes, but is not limited to, preparation and reproduction of traffic control plans, submitting and obtaining traffic control permit from the City of Carlsbad, implementing traffic control, signing, striping, flagging operations, arrow boards, resident notification letters, door hangers, and "NO PARKING" signs. Construction Staking Surveying (Bid Item No. 18) Lump Sum The contract lump sum price shall include providing complete Construction Staking and Surveying. The contract lump sum price paid shall be considered full compensation for furnishing all materials, labor, tools, equipment, and all incidentals, necessary to complete the work in accordance with the General Provisions, the Special Provisions, Standard Specifications, plans and as directed by the Engineer. Erosion Control (Bid Item No. 19) Lump Sum The contract lump sum price shall include providing complete Erosion Control. The contract lump sum price paid shall be considered full compensation for furnishing all materials, labor, tools, equipment, and all incidentals, necessary to complete the work in accordance with the General Provisions, the Special Provisions, Standard Specifications, plans and as directed by the Engineer. Grind and Overlay (Bid Item No. 20) Lump Sum The contract lump sum price shall include grinding 2" of existing pavement 5 feet beyond the sawcut line and overlay with asphalt concrete to transition into new curb line. The contract lump sum price paid shall be considered full compensation for furnishing all materials, labor, tools, equipment, and all incidentals, necessary to complete the work in accordance with the General Provisions, the Special Provisions, Standard Specifications, plans and as directed by the Engineer. This contract lump sum also included any restriping that is impacted. .1k t 43) Revised 6/15/17 Contract No. 6335 Page 117 of 176 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 2, CONSTRUCTION MATERIALS SECTION 200 - ROCK MATERIALS 200-1 ROCK PRODUCTS Add the following section: 200-1.2.2 Permeable Material. Permeable material shall consist of hard, durable, clean sand, gravel, or crushed stone, and shall be free from organic material, clay balls, or other deleterious substances. Class 1 and Class 2 permeable material shall have a Durability Index of not less than 40. Class 2 Permeable material shall have a Sand Equivalent value of not less than 75. Class 1 permeable material shall conform to the requirements in this section and Table 200-1.2.2(A). Class 2 permeable material shall conform to the requirements in this section and Table 200- 1.2.2(B). When permeable material is required and the class or kind is not specified, Class 1 permeable material shall be used. The alternative gradings within Class 1 permeable material are identified by types. Unless otherwise shown on the plans the Contractor will be permitted to furnish and place any one of the types provided for this class. The percentage composition by mass of permeable material in place shall conform to the gradings in Tables 200-1.2.2(A) and 200- 1.2.2(B). TABLE 200-1.2.2(A) CLASS 1 PERMEABLE MATERIAL Sieve Sizes Percentage Type A Passing Type B 50-mm (2") --- 100 37.5-mm (11/2") --- 95-100 19-mm (3/4") 100 50-100 12.5-mm (1/2") 95-100 --- 9.5-mm (3/8") 70-100 15-55 4.75-mm (No. 4) 0-55 0-25 2.36-mm (No. 8) 0-10 0-5 75-pm (no. 200) I 0-3 0-3 TABLE 200-1.2.2(B) CLASS 2 PERMEABLE MATERIAL Sieve Sizes Percentage Passing 25-mm (1") 100 19-mm (3/4 ) 90-100 9.5-mm (3/8") 40-100 4.75-mm (No. 4) 25-40 2.36-mm (No. 8) 18-33 600-pm (No. .30) 5-15 300-pm (No. 50) 0-7 75-pm (no. 200) 0-3 *IP —7- Revised 6/15/17 Contract No 6335 Page 118 of 176 200-2 UNTREATED BASE MATERIALS 200-2.1 General. Add the following: Aggregate base shall be Class 2 Aggregate Base per Ca!trans Standard Specification, July 1999, Section 26: Aggregate Bases, Subsection 26-1.02A Class 2 Aggregate Base and as specified herein. Add the following section: 200-2.7 Class 2 Aggregate Base. Aggregate for Class 2 aggregate base shall be free from organic matter and other deleterious substances and shall be of such nature that it can be compacted readily under watering and rolling to form a firm, stable base. Aggregate may include material processed from reclaimed asphalt concrete, portland cement concrete, lean concrete base, cement treated base or a combination of any of these materials. Aggregate shall conform to the grading and quality requirements shown in the following tables. At the option of the Contractor, the grading for either the 11/2-inch maximum or 3/4 inch maximum shall be used, except that once a grading is selected it shall not be changed without the Engineer's written approval. AGGREGATE GRADING REQUIREMENTS Percentage Passing Sieve Sizes 2" 11/2" 11/2" Maximum 3/4" Maximum Operating Range 100 90-100 Operating Range — — 1" — 100 3/4" 50-85 90-100 No. 4 25-45 35-60 No. 30 10-25 10-30 No. 200 2-9 2-9 QUALITY REQUIREMENTS Operating Tests Range Resistance (R-value) 78 Min. Sand Equivalent 25 Min. Durability Index 35 Min. The aggregate shall not be treated with lime, cement or other chemical material before the Durability Index test is performed. If the results of either or both the aggregate grading and Sand Equivalent tests do not meet the requirements specified for "Operating Range" but meet the "Contract Compliance" requirements, placement of the aggregate base may be continued for the remainder of that day. However, another day's work may not be started until tests, or other information, indicate to the satisfaction of the Engineer that the next material to be used in the work will comply with the requirements specified for "Operating Range." ink Revised 6/15/17 Contract No. 6335 Page 119 of 176 If the results of either or both the aggregate grading and Sand Equivalent tests do not meet the requirements specified for "Contract Compliance," the aggregate base which is represented by these tests shall be removed. However, if requested by the Contractor and approved by the Engineer, the aggregate base may remain in place and the Contractor shall pay to the City $2.25 per cubic yard for such aggregate base left in place. The City may deduct this amount from any moneys due, or that may become due, the Contractor under the contract. If both the aggregate grading and Sand Equivalent do not conform to the "Contract Compliance" requirements, only one adjustment shall apply. No single aggregate grading or Sand Equivalent test shall represent more than 500 cubic yards or one day's production, whichever is smaller. SECTION 201 - CONCRETE, MORTAR, AND RELATED MATERIALS 201-1 PORTLAND CEMENT CONCRETE TABLE 201-1.1.2(A) Modify as follows: TABLE 201-1.1.2(A) (3) PORTLAND CEMENT CONCRETE Type of Construction Concrete Maximum Class Slump mm (Inches) All Concrete Used Within the Right-of-Way 330-C-23 (2) (560-C-3250) (1) Trench Backfill Slurry 115-E-3 200 (8") (190-E-400) Street Light Foundations and Survey 330-C-23 100 (4") Monuments (560-C-3250) Traffic Signal Foundations 350-C-27 100 (4") (590-C-3750) Concreted-Rock Erosion Protection 310-C-17 per Table 300-11.3.1 (520-C-2500 P) (1)Except that concrete required to be of higher strength by Table 201-1.1.2(A) SSPWC shall be as per Table 201- 1.1.2(A) SSPWC. (2)As per Table 201-1.1.2(A) SSPWC. (3)Portions of Table 201-1.1.2(A) of the Standard Specifications for Public Works Construction not shown herein as changed are not affected by this table. 201-1.2 Materials. 201-3 EXPANSION JOINT FILLER AND JOINT SEALANTS 201-3.4 Type "A" Sealant (Two-Part Polyurethane Sealant). Add the following: All finished concrete surfaces shall have a W continuous expansion joint at locations indicated on the plans and notes and shall be located either parallel to perpendicular to the curb line. When not otherwis indicated, all expansion joints locatsd adjar...ont to colorod concrete sha!! he sealant Type "A" and colored to match the color of the concrete surface. ta r. Revised 6/15/17 Contract No. 6335 Page 120 of 176 Contractor shall provide joint sealants that have been produced and installed to establish and to maintain watertight and airtight continuous seals without causing staining or deterioration of joint substrates. Contractor shall submit product data from the manufacturer of each joint sealant product required, including instructions for joint preparation and joint sealer application. Contractor shall also submit samples for initial selection purposes in form of manufacturer's standard bead samples, consisting of strips of actual products showing full range of colors available, for each product exposed to view. Samples shall be submitted to Engineer. Submit complete schedule of type (and location where type is to be used) of each sealant. Contractor shall engage an experienced installer who has completed joint sealant applications similar in material, design and extent to that indicated for Project that have resulted in construction with a record of successful in-service performance. Provide joint sealants, joint fillers, and other related materials that are compatible with one another and with joint substrates under conditions of service and application, as demonstrated by sealant manufacturer based on testing and field experience. Provide color selections made by Engineer from manufacturer's full range of standard colors for products of type indicated. Sealant color parallel to curb line shall match color of Paving Treatment Type "A" as specified in Section 201-1.2.4(a) of these Special Provisions. Joint sealants shall be multi-component polyurethane sealant. Except as otherwise indicated, provide manufacturer's standard, non-modified, 2-or-more-part, polyurethane-based, elastomeric sealant; complying with either ASTM-C-920-87, Type M, Grade P, Class 25, or FS IT-S 0227E Class A, non-sag, Type II. Acceptable Products: "Sonneborn NPII"; Sonneborn Building Products Division; "Scofield Lithoseal Trafficalk 3-G", L.M. Scofield Company; or equivalent, as approved by the Engineer. Provide sealant backings of material and type that are nonstaining; are compatible with joint substrates, sealants, primers and other joint fillers; and are approved for applications indicated by sealant manufacturer based on field experience and laboratory testing. Plastic foam joint fillers shall be preformed, compressible, resilient, nonstaining, nonwaxing, nonextruding strips of flexible plastic foam either open-cell polyurethane foam or closed-cell polyethylene foam, subject to approval of sealant manufacturer, for cold-applied sealants only. Polystyrene foam is not acceptable. 201-3.7 Type "0" Joint Sealant. Add the following: Hot-melt rubberized asphalt shall be in solid form at room temperature and fluid at an application temperature of 190°C (375°F) to 205°C (400°F). Fumes from the material shall be non-toxic. Sealant shall be suitable for use in both asphalt concrete and portland cement concrete. Performance characteristics of the cured hot- melt rubberized asphalt shall be as per Table 201-3.7(A). Revised 6/15/17 Contract No. 6335 Page 121 of 176 TABLE 201-3.7(A) CURED HOT-MELT RUBBERIZED ASPHALT Property Measuring Standard (ASTM Designation) Results Conditions Cone Penetration ASTM D 3407, Sec. 5 3.5 mm, max. 25°C, 150 g, 5 s Flow, 60°C ASTM D 3407, Sec. 6 5 mm, max. Resilience ,ASTM D 3407, Sec. 8 25%, min. 25°C Softening Point, ASTM D 36 82 °C, min. Ductility, ASTM D 113 300 mm, min. 25°C, 50 mm/min Flash Point, COC, °C ASTM D 92 288 °C, min. Viscosity, Brookfield Thermosel, ASTM D 4402 2.5-3.5 Pas No. 27 Spindle, 20 rpm, 190°C, SECTION 203 - BITUMINOUS MATERIALS 203-6 ASPHALT CONCRETE. Add the following: 203-6.2.1 Acceptance. Wet Mix or Core sampled asphalt concrete will be considered in conformance with the mix design when the Asphalt Binder content is within +/-0.5% of the design mix and the gradation conforms to the grading as shown in Table 203-6.4.3 (A). Deviations in gradation may be considered in conformance with the mix design provided the stability of the completed mix complies with the requirements for Stabilometer Value per Table 203-6.4.3 (A) Plant inspected asphalt concrete will be considered in conformance with the mix design when visually inspected and the combined gradation of the Bin samples show conformance to the grading as shown in Table 203-6.4.3 (A). 203-6.4 Asphalt Concrete Mixtures. Add the following: Conventional Asphalt concrete shall be class C2-PG64-10-RAP for surface course, and B-PG64-10-RAP for base course. Asphalt concrete shall be class D2-PG70-10 for dikes and class E-PG70-10 ditches. 203-6.4.3 Composition aim; Grading. Add the following: Evaluation of asphalt concrete shall be determined from samples of asphalt concrete taken after completion of all processing (Wet Mix) or by core sample analysis of the in-place asphalt concrete or by direct central plant inspection that confirms the production of a particular mix design and verifies using samples of aggregate taken before the addition of asphalt and mineral filler (Bin). All samples shall be taken in accordance with Calif. Test 125. When Wet Mix or Core samples of asphalt concrete are to be used for evaluation, sufficient size samples shall be taken to ensure representative and adequate quantity of material for: 1.Asphalt Content and Gradation of Extraction using Calif. Test 382 or ASTM 2172, and Calif. Test 202. 2.Stability using: a. Hveem stability Value using Calif. Tests 304 and 366 shall be the average of three individual Values 4,pm. fa4, Revised 6/15/17 Contract No. 6335 Page 122 of 176 USES GRADES Headers for bituminous pavement up to 50 mm x 100 mm (2"x4") Headers for bituminous pavement larger than 50 mm x 100 mm (2"x4") Construction grade Redwood or preservative treated construction grade Douglas Fir Number 1 grade Redwood, or preservative treated number 1 grade Douglas Fir or b. Marshall Stabilityl in accordance with the Asphalt Institute's MS-2 fabricated and tested for traffic volume and shall be the average of three specimens. lOnly use Marshall Stability when the deviation between individual Hveem Stabilometer Values are greater than +/-5. When using core sample analysis, the samples must be properly prepared to safeguard against influx of outside contaminates and so that the cut surfaces do not influence the test results. 203-6.8 Asphalt Concrete Storage. Add the following: Open graded or Gap graded asphalt concrete stored in excess of 2 hours, and any other asphalt concrete stored in excess of 10 hours, shall not be used in the work. 203-11 ASPHALT RUBBER HOT MIX (ARHM) WET PROCESS 203-11.3 Composition and Grading. Add the following: Asphalt Rubber Hot Mix shall be Gap Graded class ARHM-GG-C. SECTION 204 - LUMBER AND TREATMENT WITH PRESERVATIVES 204-1 LUMBER AND PLYWOOD TABLE 204-1.2(A) ADD THE FOLLOWING: TABLE 204-1.2(A) SECTION 206 - MISCELLANEOUS METAL ITEMS Add the following section: 206-7 TRAFFIC SIGNS. 206-7.1 Roadside Signs. This work shall consist of furnishing and installing roadside signs in accordance with details shown on the plans, the California Sign Specifications and these special provisions. Permanent and temporary signs shall be free from blemishes that may affect the serviceability and detract from the general sign color and appearance when viewing during daytime and nighttime from a distance of 25 feet. The face of each finished sign shall be uniform, flat, smooth, and free of defects, scratches, wrinkles, gel, hard spots, streaks, extrusion marks, and air bubbles. The front, back and edges of the sign panels shall be free of router chatter marks, burns, sharp edges, loose rivets, delaminated skins, excessive adhesive overspray, and aluminum marks. 206-7.1.2 Sign Identification. The following notation shall be placed on the lower right side of the back of each sign where the notation shall not be blocked by the sign post or frame: 11,11e fag, Revised 6/15/17 Contract No. 6335 Page 123 of 176 A.PROPERTY OF THE CITY OF CARLSBAD, B.Name of the sign manufacturer, C.Month and year of fabrication, D.Type of retroreflective sheeting, and E.Manufacturer's identification and lot number of retroreflective sheeting. The above notation shall be applied directly to the aluminum sign panels in 1/4-inch upper case letters and numerals by die-stamp and applied by similar method to the fiberglass reinforced plastic signs. Painting, screening, or engraving of the notation will not be allowed. The notation shall be applied without damaging the finish of the sign. 206-7.1.3 Drawings. Standard signs shall be as per the most recently approved California Sign Specifications. The date of approval shall be the date most closely preceding the date of manufacture of the sign(s) or the date of the "Notice to Proceed" of this contract, whichever is most recent. 206-7.1.4 Reflective Sheeting. All advisory signs, warning signs and all regulatory signs shall be fabricated with Type IV prismatic sheeting (High Intensity Prismatic or equivalent) or Type IX prismatic cube lens sheeting (Diamond Grade VIP or equivalent) in accordance to ASTM Designation D4956 and conforming to the requirements of these special provisions. 206-7.1.6 Sign Panel. Sign panels shall be fabricated from sheet aluminum in accordance with ASTM Designation B209. Sheet aluminum shall be pretreated in accordance to ASTM Designation B449. The surface of sheet aluminum shall be cleaned, deoxidized, and coated with a light and tightly adherent chromate conversion coating free of powdery residue. The conversion coating shall be Class 2 with a mass between 10 milligrams per square foot. Following the cleaning and coating process, the sheet aluminum shall be protected from exposure to grease, oils, dust, and contaminants. Sheet aluminum shall be free of buckles, warps, dents, cockles, burrs, and defects resulting from fabrication. 206-7.1.6 Mounting Traffic Signs. Traffic signs shall be installed on 10-gage or 12-gage cold- rolled steel perforated tubing posts as shown on San Diego Regional Standard drawing M-45 or, when the sign area exceeds the maximum area allowed for on that drawing, on multiple 10-gage or 12-gage cold-rolled steel perforated tubing posts. The number of posts shall be determined by the parameters in SDRS drawing M-45 or as approved by the Engineer. Traffic signs will be provided with back braces and mounting blocks as approved by the Engineer consisting of 10-gage or 12-gage cold-rolled steel perforated tubing when multiple posts are used. 206-7.1.6 Traffic Sign Posts. Posts shall be constructed of 10-gage or 12-gage cold-rolled steel perforated tubing posts as shown on San Diego Regional Standard drawing M-45. 206-7.2 Temporary Traffic Signs. Temporary traffic signs shall consist of all signs used for the direction, warning, and regulation of vehicle (including bicycle) and pedestrian traffic during the Contractor's performance of the Work. Temporary traffic signs include both stationary and portable signs. 206-7.2.1 General. This work shall consist of furnishing and installing temporary signs in accordance with details shown on the plans, the California Sign Specifications and these special provisions. Permanent and temporary signs shall be free from blemishes that may affect the serviceability and detract from the general sign color and appearance when viewing during tat —r- Revised 6/15/17 Contract No. 6335 Page 124 of 176 daytime and nighttime from a distance of 25 feet. The face of each finished sign shall be uniform, flat, smooth, and free of defects, scratches, wrinkles, gel, hard spots, streaks, extrusion marks, and air bubbles. The front, back and edges of the sign panels shall be free of router chatter marks, burns, sharp edges, loose rivets, delaminated skins, excessive adhesive overspray, and aluminum marks. 206-7.2.2 Drawings. Standard signs shall be as per the most recently approved California Sign Specifications. The date of approval shall be the date most closely preceding the date of manufacture of the sign(s) or the date of the "Notice to Proceed" of this contract, whichever is most recent. 206-7.2.3 Reflective Sheeting. All advisory signs, warning signs and all regulatory signs shall be fabricated with Type IV prismatic sheeting (High Intensity Prismatic or equivalent) or Type IX prismatic cube lens sheeting (Diamond Grade VIP or equivalent) in accordance to ASTM Designation D4956 and conforming to the requirements of these special provisions. 206-7.2.4 Sign Panel. Sign panels shall be fabricated from sheet aluminum in accordance with ASTM Designation B209. Sheet aluminum shall be pretreated in accordance to ASTM Designation B449. The surface of sheet aluminum shall be cleaned, deoxidized, and coated with a light and tightly adherent chromate conversion coating free of powdery residue. The conversion coating shall be Class 2 with a mass between 10 milligrams per square foot. Following the cleaning and coating process, the sheet aluminum shall be protected from exposure to grease, oils, dust, and contaminants. Sheet aluminum shall be free of buckles, warps, dents, cockles, burrs, and defects resulting from fabrication. 206-7.2.5 Stationary Mounted Temporary Traffic Signs. Stationary mounted temporary traffic signs shall be installed on 10-gage and 12-gage cold-rolled steel perforated tubing posts in the same manner shown on the State of California, Department of Transportation Standard Plans RS1, RS2, RS3 and RS4 for installation of roadside signs, except as follows: a)Wood posts shall not be used. b)Back braces and blocks for sign panels will not be required. c)The height to the bottom of the sign panel above the edge of traveled way shall be at least 2.1 m (7'). d)Unless otherwise shown on the plans traffic sign posts shall conform in materials and installation to SDRS drawing M-45 and shall have one post provided for each 0.46 m2 (5 ft2)of sign area, or the signs may be installed on existing lighting standards when approved by the Engineer. e)Sign panels mounted on temporary traffic sign posts shall conform to the requirements of these special provisions. 206-7.2.6 Temporary Traffic Sign Posts. Posts shall be 10-gage or 12-gage cold-rolled steel perforated tubing used for the support and stabilization of stationary mounted temporary signs. Post size and number of posts shall be as shown on the plans, except that when stationary mounted signs are installed and the type of sign installation is not shown on the plans, post size and the number of posts will be determined by the Engineer. Sign panels for stationary mounted signs shall consist of reflective sheeting applied to a sign substrate. 206-7.2.7 Portable Temporary Traffic Signs. Each portable temporary traffic sign shall consist of a base, standard or framework and a sign panel. The units shall be capable of being delivered to the site of use and placed in immediate operation. Sign panels for portable signs shall conform 41* Revised 6/15/17 Contract No. 6335 Page 125 of 176 to the requirements of these special provisions, or shall be cotton drill fabric, flexible industrial nylon fabric, or other approved fabric. Fabric signs shall not be used during the hours of darkness. Size, color, and legend requirements for portable signs shall be as described for stationary mounted sign panels in section 206-7.2 of these special provisions. The height to the bottom of the sign panel above the edge of traveled way shall be at least 0.3-m (12"). All parts of the sign standard or framework shall be finished with 2 applications of orange enamel which will match the color of the sign panel background. Testing of paint will not be required. Add the following section: 206-8 LIGHT GAGE STEEL TUBING AND CONNECTORS. Add the following section: 206-8.1 General. This Section pertains to 10-gage and 12-gage cold-rolled steel perforated tubing used for the support and stabilization of signs. All shapes shall have a galvanized finish and shall be cold-roll-formed steel conforming to ASTM Designation A-446, Grade A. Galvanizing shall conform to ASTM A-525, Designation G-90. Galvanizing shall be performed after all forming and punching operations have been completed. Cold-rolled steel perforated tubing shall be perforated on all four faces with 11mm (7/16") holes on 25 mm (1") centers. Add the following section: 206-8.2 Tolerances. Wall thickness tolerance shall not exceed +0.28 mm, -0.13 mm (+0.011", -0.005"). Convexity and concavity measured in the center of the flat side shall not exceed a tolerance of +0.25 mm (+0.010") applied to the specific size determined at the corner. Straightness tolerance variation shall not exceed 1.6 mm in 1 m (1/16" in 3'). Tolerance for corner radius is 4.0mm (5/32"), plus or minus 0.40 mm (1/64"). Weld flash on corner-welded square tubing shall permit 3.60 mm (9/64") radius gage to be placed in the corner. Using 10-gage or 12-gage square tube, consecutive size tubes shall telescope freely for 3.1m (10'). Tolerance on hole size is plus or minus 0.40 mm (1/64") on a size. Tolerance on hole spacing is plus or minus 3.2 mm in 6.1 m (1/8" in 20'). In addition, for the following specific sizes of light gage steel tubing, dimensional tolerances shall not exceed those listed in tables 206-8.2 (A) and 206-8.2(B). TABLE 206-8.2(A) LIGHT GAGE STEEL TUBING SIZE TOLERANCE Nominal Outside Dimensions mm (inches) Outside Tolerance for All Sides at Corners mm (inches) 25 x 25 (1 x 1) 0.13 0.005 32 x 32 (11/4 x 11/4) 0.15 0.006 38 x 38 (11/2 x 11/2) 0.15 0.006 44 x 44 (13/4 x 13/4) 0.20 0.008 51 x 51 (2 x 2) 0.20 0.008 56 x 56 (23/16 x 23/16) 0.25 0.010 57 x 57 (21/4 x 21/4) 0.25 0.010 64 x 64 (21/2 x 21/2) 0.25 0.010 51 x 76 (2 x 3) 0.25 0.010 Inf Revised 6/15/17 Contract No. 6335 Page 126 of 176 TABLE 206-8.2(B) LIGHT GAGE STEEL TUBING SQUARENESS OF SIDES AND TWIST Nominal Outside Dimension 1111-11 (Inches) Squarenesso) mm (Inches) Twist Permissible in 900 mm (3") mm(2) (Inches)2) 25 x 25 (1 x 1) 0.15 0.006 1.3 0.050 32 x 32 (1-1/4 x 1-1/4) 0.18 0.007 1.3 0.050 38 x 38 (1-1/2 x 1-1/2) 0.20 0.009 1.3 0.050 44 x 44 (1-3/4 x 1-3/4) 0.25 0.010 1.6 0.062 51 x 51 (2 x 2) 0.30 0.012 1.6 0.062 56 x 56 (2-3/16 x 2-3/16) 0.36 0.014 1.6 0.062 57 x 57 (2-1/4 x 2-1/4) 0.36 1.014 1.6 0.062 64 x 64 (2-1/2 x 2-1/2) 0.38 0.015 1.9 0.075 51 x 76 (2 x 3) 0.46 0.018 1.9 0.075 (1)Tubing may have its sides failing to be 90 degrees to each other by the tolerance listed. (2)Twist is measured by holding down the edge of one end of a square tube on a surface plate with the bottom side of the tube parallel to the surface plate and noting the height that either corner on the opposite end of the bottom side is above the surface plate. Add the following section: 206-8.3 Fasteners. Fasteners used to assemble cold-rolled steel perforated tubing shall be steel "pull-through" electrogalvanized rivets with 9.5 mm (3/8") diameter shank, 22 mm (7/8") diameter head, and a grip range of from 5 mm (0.200") to 0.90 mm (0.356"). The fasteners shall conform to ASTM B-633, Type III Add the following section: 206-9 PORTABLE CHANGEABLE MESSAGE SIGN Add the following section: 206-9.1 General. Each portable changeable message sign (PCMS) unit shall consist of a controller unit, a power supply, and a structural support system all mounted on a trailer. The PCMS unit shall be assembled to form a complete self-contained portable changeable message sign, which can be delivered to the site of the work and placed in immediate operation. The complete PCMS unit shall be capable of operating in an ambient air temperature range of -20°C (-4°F) to +70°C (158°F) and shall not be affected by unauthorized mobile radio transmissions. The trailer shall be equipped so that it can be leveled and plumbed. Full operation height shall be with the bottom of the sign at least 2.1 m (7') above the ground and the top no more than 4.4 m (14.5') above the ground. After initial placement, PCMS shall be moved from location to location as directed by the Engineer. Add the following section: 206-9.2 Message Board. The message displayed on the PCMS shall be visible from a distance of 460 m (1500') and shall be legible from a distance of 230 m (750'), at noon on a cloudless day, by persons with vision corrected to 20/20. The sign panel shall be 3-line matrix and shall display not less than 7 characters per line. Sign messages to be displayed shall be as approved by the Engineer. The sign face shall be flat black and shall be protected from glare of the sun by a method which does not interfere with the clarity of the sign message. The sign shall be raised and lowered by means of a power driven lifting mechanism. The matrix sign shall be capable of complete alphanumeric selection. tA... Revised 6/15/17 Contract No. 6335 Page 127 of 176 Lamp matrix type signs shall be equipped with an automatic dimming operational mode that automatically compensates for the influence of a temporary light source or other abnormal lighting conditions. The sign shall have manual dimming operation modes of 3 or more different lamp intensities. Matrix signs not utilizing lamps shall be either internally or externally illuminated at night. The controller shall be an all solid-state unit containing all the necessary circuitry for the storage of at least 5 pre-programmed messages. The controller shall be installed in a location allowing the operator to perform all functions from one position. A keyboard entry system shall be provided to allow an operator to generate an infinite number of additional messages over the pre- programmed stored messages. The keyboard shall be equipped with a security lockout feature to prevent unauthorized use of the controller. The controller shall contain a nonvolatile memory to hold the keyboard created messages in memory during periods when the power is not activated. The controller shall provide for a variable message display rate which allows the operator to match the information display to the speed of the approaching traffic. The flashing off time shall be operator adjustable within the control cabinet. Add the following section: 206-9.3 Operation and Maintenance. PCMS shall be furnished, placed, operated, and maintained at locations shown on the plans, specified herein, or designated by the Engineer. The PCMS will be diligently maintained and repaired by the Contractor throughout the project in accordance with the manufacturer's recommendations. When ownership is transferred to the City (at the end of the job), it must be demonstrated to be in good working condition, and meet the provisions of these specifications, including current registration. Add the following section: 206-9.4 Measurement and Payment. The contract unit price PCMS shall include full compensation for furnishing all labor, materials, tools, equipment and incidentals, and for doing all the work involved in furnishing, placing, operating, maintaining, repairing, replacing, transporting from location to location, and delivery of the signs to the City at the completion of the construction, in good working order, and as directed by the Engineer, and no other compensation will be made. 206-10 STEEL GRATINGS 206-10.1 General. Steel grating shall meet the requirements of DIN 19580 and be certified ADA compliant and slip-resistant. Grate shall be Load Class A and withstand a design load up to or exceeding 3,372 lbs per foot (15 kn). Grates slots shall be 1/2" or less on gratings in walkways and elongated slots must be placed longitudinally so that they are perpendicular to the dominant direction of travel. Steel grating shall be galvanized steel and all bolts and fasteners shall be stainless steel. Contractor shall submit product cutsheet for approval prior to ordering of material. Revised 6/15/17 Contract No. 6335 Page 128 of 176 SECTION 207 - PIPE 207-2 REINFORCED CONCRETE PIPE. 207-2.5 Joints. Add the following: When watertight joints are indicated on the plans they shall be of the rubber-gasketed type meeting the requirements of ASTM Standard Specification designations C 361-95 and C 443-94. Pipe designated in the plans as "pressure pipe" or with a 100-year hydraulic grade line at or above the soffit shall be bell and groove spigot joint with "0" rings conforming to ASTM C-443 and C- 361 for the limits shown on the plans. 207-9 IRON PIPE AND FITTINGS 207-9.2.2 Pipe Joints Unless otherwise shown on the Plans, all joints shall be the push-on type joint. Joints and accessories shall conform to the requirements and dimensions specified in ANSI A21.11, AWWA C111. Rubber gasket material shall conform to 208-1.2 and AWWA C111 and ANSI A21.11-90. 207-9.2.3 Fittings. Add the following: Ductile iron pipe and fittings shall be manufactured in accordance with ANSI 21.50, AWWA 0150 and ANSI 21.51, AVVVVA C151, and shall be of the size and thickness classes shown on the Plans. Unless otherwise specified, size 4-inches through 6-inches DIP shall be thickness Class 52, while size 8-inches and larger shall be thickness Class 50. 207-9.2.4 Lining and Coating. Replace with the following: Unless otherwise specified, all iron pipe and fittings shall be lined with double thickness, cement motor lining with cement conforming to ASTM C150 Type II, AWWA C104/A21.4.90 and outside coating of bituminous coating a minimum of 2 mils, thick in accordance with AWWA C151 or C100. 207-10 STEEL PIPE Add the following: 207-10.1 General Fabricated Steel Pipe and Fittings shall conform in all respects to Carlsbad Municipal Water District Rules and Regulations for Construction of (Potable or Reclaimed) Water Mains, latest edition. 207-10.1.2 Submittals. The Contractor shall furnish submittals in accordance with Section 2-5.3, Submittals Shop Drawings. Submittals are required for the following: Shop Drawings Layout Drawings Manufacturer's tests Mill Reports or Plant Test Reports Fabrication Details Dimensional Checks Protective Coatings Welding Procedures/Certification for Field Welding Shop Drawings shall be submitted and approved prior to manufacture of pipe. 207-10.1.3 Quality Assurance. Field welders shall be certified under Section IX, Part A of the ASME Boiler and Pressure Vessel Code or in accordance with AWWA 0206, Section 3. Welders shall submit a copy of their certification to the District prior to performing any field welding. Certifications shall be dated within three (3) years of the job to be performed. Revised 6/15/17 Contract No. 6335 Page 129 of 176 The top of all pipe and specials shall be clearly identified by marking the top with "T.O.P." for easy identifications in the field. Plainly mark each length of pipe at the bell end to identify the proper location of the pipe item by reference to the layout schedule. 207-10.1.4 Protective Coatings and Linings. All steel pipe and fittings exposed within a vault or above ground shall be cement-mortar lined in accordance with AVVWA 0205 and 0602 and painted in accordance with CMWD Approved Materials List. All steel pipe and fittings for underground service shall be cement-mortar lined, taped wrapped and cement-mortar coated in accordance with AVVWA C205, C214 and C602 unless otherwise specified on the Drawings. Add the following section: 207-26 UNDERGROUND UTILITY MARKING TAPE. Add the following section: 207-25.1 Detectable Underground Utility Marking Tape: Detectable Underground Utility Marking Tape shall have a minimum 0.13 mm (0.005") overall thickness, with no less than a 35 gauge (AWG), 0.14 mm aluminum foil core. The foil must be visible from both sides. The layers shall be laminated together with the extrusion lamination process, not adhesives. No inks or printing shall extend to the edges of the tape. All printing shall be encased to avoid ink rub-off. Detectable Underground Utility Marking Tape shall conform to the properties listed in Tables 207- 25(A) and 207-25 (B). TABLE 207-25.1(A) DETECTABLE UNDERGROUND UTILITY MARKING TAPE PROPERTIES Property Method Value Thickness ASTM D2103 0114 mm (0.0056") Tensile strength ASTM D882 4500g/cm (25 lbs/inch) (5,500 PSI) Elongation ASTM D882-88 <50 percent at break Printability ASTM D2578 >50 dynes/square centimeter Flexibility ASTM D671-81 Pliable hand Inks Manufacturing specifications Heat-set Mylex Message repeat Manufacturing specifications Every 500 mm(20") Foil Manufacturing specifications Dead soft/annealed Top layer Manufacturing specifications Virgin PET Bottom layer Manufacturing specifications Virgin LDPE Adhesives Manufacturing specifications >30 percent, solid 1.5#/R Bond strength Boiling H20 at 100 degrees Celsius Five hours without peel Colors APWA Code See Table 207-25.1 (B) ar. U.- Revised 6/15/17 Contract No. 6335 Page 130 of 176 TABLE 207-25.1(B) DETECTABLE UNDERGROUND UTILITY MARKING TAPE COLORS Color Utility Marked Red Electric power, distribution, transmission, and municipal electric systems. Yellow Gas and oil distribution and transmission, dangerous materials, product and steam. Orange Telephone and telegraph systems, police and fire communications, and cable television. Blue Water systems. Green Sanitary and storm sewer systems, non potable. Brown Force mains. Purple Reclaimed water lines. Add the following section: 207-25.2 Materials Approvals. Detectable Underground Utility Marking Tape shall meet the requirements of each of the following agency/association publications. A.Department of Transportation, Materials Transportation Bureau, Office of Pipeline Safety. USAS code for pressure piping B31.8, paragraph 192.321(e). B.National Transportation Safety Board, Washington, DC, Special Study Prevention of Damage to Pipelines. Adopted June 7, 1974. Report NTSB-PSS-73-1. C.American Petroleum Institute (API). Recommended practice for marking buried liquid petroleum pipelines - APR RP 1109. D.General Services Administration, Washington, DC, Public Buildings Service Guide Specification for Mechanical and Electrical Equipment - PBS 4-1501, Amendment 2, Page 501-14, Paragraph 18, Subparagraph 18.1, Clause 18.1.1. E.Rural Electrification Authority (REA), U.S. Department of Agriculture, Washington, DC, National Electrical Safety Code for Underground Construction for remote and immediate hazards. SECTION 209 - ELECTRICAL COMPONENTS 209 ELECTRICAL COMPONENTS. Modify as follows: Section 86, "Signals, Lighting and Electrical Systems", of the Ca!trans Standard Specifications replaces Section 209, "Electrical Components", and Section 307, "Street Lighting and Traffic Signals", of the SSPWC, in all matters pertaining to the specifications for measurement, payment, warranty, materials and methods of construction of street lighting and traffic signals. Section 86 of the Caltrans Standard Specifications is unmodified excepted as specified herein. For electrical components provided and installed in systems NOT including street lighting and traffic signals, Section 209 SSPWC is unmodified except as specified in sections other than Section 209, herein. t Revised 6/15/17 Contract No. 6335 Page 131 of 176 SECTION 86 - SIGNALS, LIGHTING AND TRAFFIC ELECTRICAL SYSTEMS 86-2 MATERIALS AND INSTALLATION Replace Section 86-2.02 with the following: 86-2.02 Removing and Replacing Improvements. In addition to the requirements of sections 7-9, "Protection and Restoration of Existing Improvements" and 306-1.5, "Trench Resurfacino", improvements such as sidewalks, curbs, gutters, portland cement concrete and asphalt concrete pavement, underlying material, lawns and plants, and any other improvements removed, broken or damaged by the Contractor's operations, shall be replaced or reconstructed with the same kind of material as found on the work or with materials of equal quality. The new work shall be left in a serviceable condition. Whenever a part of a square or slab of existing concrete sidewalk, curb, gutter, or driveway is broken or damaged, the entire square, section or slab shall be removed and the concrete reconstructed as above specified. The outline of all areas to be removed in portland cement concrete sidewalks and driveways and in pavements shall be cut to a minimum depth of 0.17 foot (2") with an abrasive type saw prior to removing the sidewalk, driveways and pavement material. Cuts shall be neat and true along score lines, with no shatter outside the removal area. 86-2.05 Conduit. To the City Supplement, add the following: All conduit shall be two inches (2") minimum schedule 80 PVC unless otherwise shown on plans. Replace Section 86-2.05B with the following: 86-2.05B Use. Exposed conduit installed on a painted structure shall be painted the same color as the structure. Unless otherwise indicated, the minimum metric trade size of conduit shall be: 1.From an electrolier to the adjacent pull box shall be Size 41 (11/2" dia). 2.From a pedestrian push button post to the adjacent pull box shall be Size 27 (1" dia). 3.From a signal standard to the adjacent pull box shall be Size 53 (2" dia). 4.From a controller cabinet to the adjacent pull box shall be Size 78 (3" dia). 5.For detector runs shall be Size 78 (3" dia). 6.Not otherwise specified shall be Size 78 (3" dia). Add the following: 86-2.08 Conductors. Signal cable shall be used for all new traffic signal installations. Individual conductors shall not be used. Add the following: 86-2.09B Installation. All conductors shall be pulled directly from the spool into the conduit and shall not be dragged on the ground as to cause damage to the conductors. 86-3 CONTROLLER ASSEMBLIES 86-3.01 Controller AssemblyTraffic signal controllers shall be Trafficware 2070 LX with SCOUT controller software and shall conform with the latest edition of Standard Specifications, State of California, Departmoi.', of Transportation," Section 86, and "Thaffic agna: Specifications," State of California. Controller assemblies shall be on the current State of Revised 6/15/17 Contract No. 6335 Page 132 of 176 California Qualified Products List (QPL). Traffic Signal Control Equipment Specifications shall have precedence over Caltrans Standard Specifications. Add the following: 86-3.04A Cabinet Construction. Controller cabinets shall be fabricated from aluminum sheet and shall be McCain 352i ATC or approved equal. Controller cabinets shall have full size front and back two doors equipped with a Best Company lock core and lock. Key and lock core shall be unique to the City of Carlsbad. No other manufacturers shall be accepted. Cabinet shall meet the following requirements: Dimensions: 6TH x 24"W x 30" Material: 5052-H32 aluminum, 0.125" thick Finish: Anodized Mounting: Base mounted including four (4) 3/4" x 16" anchor bolts Ventilation: Thermostatically controlled 100 CFM fans (2) Louvered air intake in door, pleated fiber Cabinet shall include the following features: •One (1) Field output termination file •Two (2) Field input termination file •EDI auxiliary display unit or approved equal •Flashable and programmable channels •Hermetically sealed high-density FIR featuring an LED indicator •Interior LED cabinet lights (2), front and back •Model 2202 dual flasher/switch pack combination •Continuously welded exterior •Police Panel Pickleswitch 86-3.0413 Layer 2 Ethernet Switch Contractor shall coordinate with City to determine switch make and model prior to ordering of material. The Layer 2 Ethernet switch shall meet the following specifications: 1.Layer 2 switch shall provide 8 Ethernet 10/100 ports and 2 dual-purpose fiber uplinks. 2.Layer 2 switch shall include two 1000Base SFP ports. 3.Layer 2 switch shall include SFP transceivers. 4.SFP transceiver shall support 1000BASE-TX SMF, 1300nm wavelength, and reach 10km over single-mode fiber. SFP transceiver shall be compatible with Layer 3 switch transceivers. 5.SFP transceiver shall NOT void warranty of approved switch. 6.Layer 2 switch shall include power supply and din rail or 19" mounting kit. 7.Layer 2 switch shall operate within a temperature range of -40 to 167°F. 8.Layer 2 switch shall be supplied with a field hardened power supply unit. 86-3.04D Conflict Monitor Unit The CMU shall be EDI CMUip-2212-HV or approved equal. 86-3.04E Accessible Pedestrian Signal (APS) Pedestrian Pushbutton System The APS control module shall be Polara EZ COMM Navigator 2-wire System or approved equal. The pushbutton assembly housing shall be yellow. 40), —I- Revised 6/15/17 Contract No. 6335 Page 133 of 176 86-3.04F Cellular Modem Contractor shall coordinate with City for type of modem prior to ordering of material. The cell modem shall be Cradlepoint 4G LTE or approved equal. Add the following section: 86-3.05F Document Tray. Controller cabinets shall have a pull-out type document tray. 86-4 TRAFFIC SIGNAL FACES AND FITTINGS Replace Section 86-4.06 with the following: 86-4.06 Pedestrian Signal Faces. Message symbols for pedestrian signal faces shall be white WALKING PERSON, Portland orange UPRAISED HAND and COUNTDOWN DIGITS. Pedestrian signal faces shall conform to definitions and practices described in "Pedestrian Traffic Control Signal Indications" published in the Equipment and Materials Standards of the institute of Transportation Engineers, (referred to in this document as "PTCSI") and in the Applicable Sections of Manual on Uniform Traffic Control Devices (MUTCD) latest edition, Section 4E. Add the following section: 86-4.06A Physical and Mechanical Requirements. Add the following section: 86-4.06A(1) General. Modules shall not require special tools for installation and shall fit into existing pedestrian signal housings built for the PTCSI sizes stated in Section 1 of the "walking person" and "hand" icon pedestrian signal indication Standard without modification to the housing. Installation of a retrofit replacement module into an existing pedestrian signal housing shall only require the removal of the existing optical unit components, i.e., lens, lamp module, gaskets, and reflector; shall be weather tight and fit securely in the housing; and shall connect directly to existing electrical wiring. Add the following section: 86-4.06A(2) The Module under Physical and Mechanical Requirements. a.The LED module shall have a visual appearance similar to that of an incandescent lamp (ie: Smooth and non-pixilated). b.The module lens shall not be a replaceable part. Screwed on lenses are not allowed. Only modules with internal mask shall be utilized. No external silk-screen shall be permitted. c.The dividers inside the module that make up the icons and digits shall be black so as to eliminate sun phantom effect. When not illuminated with the sun shining into .the module, the WALKING PERSON and UPRAISED HAND and COUNTDOWN DIGITS shall not be readily visible. d.The countdown digits of the pedestrian signal module shall be located adjacent to the associated UPRAISED HAND (symbolizing DON'T WALK). When displaying a number "1" for both digits, the number "1" shall use the two segments furthest to the right. The digits shall remain on during the entire count down cycle. Flashing digits are not allowed. e.The display of the number of remaining seconds shall begin only at the beginning of the pedestrian change interval. After the countdown displays zero, the display shall remain dark until the beginning of the next countdown. f.The walking person, hand icons and countdown digits (16"x18" size only) shall_ be incanaescent looking. I ne configurations of the walking person icon, hand icon- and numbers icons are illustrated in Figures 1, 2 (per PTCSI Part 2 Specification) and Figure 3 respectively. t at Revised 6/15/17 Contract No. 6335 Page 134 of 176 Hu Figure 1 Figure 2 Figure 3 Dimensions for Figures 1, 2 and 3 For each nominal message bearing surface (module) size, use the corresponding minimum H (height) and W (width) measurements: Module Size Icon Height Icon Width Countdow n Height Countdow n Width Countdown Segment Width 406 x 457 mm (16 x 18 in) 297 mm 11 in 178 mm 7 in 229 mm 9 in 178 mm 7 in 17.78 mm 0.7 in Note: The units shall not have any external attachments, dip switches, toggle switches or options that will allow the mode to be changed from counting the clearance cycle, to the full walk/don't walk cycle or any other modification to the icons or digits. Add the following section: 86-4.06A(3) Environmental Requirements. a.All exposed components of a module shall be suitable for prolonged exposure to the environment, without appreciable degradation that would interfere with function or appearance. As a minimum, selected materials shall be rated for service for a period of a minimum of 60 months in a south-facing installation. b.The module shall be rated for use in the ambient operating temperature range, measured at the exposed rear of the module, of -40°C to +74°C. (-40°F to +165°F). c.A module shall be protected against dust and moisture intrusion, including rain and blowing rain. Shall be sealed and meet MIL-STD-810F Procedure I, Rain & Blowing Rain specifications. d.The module lens shall not crack, craze or yellow due to solar UV irradiation typical for a south-facing Arizona Desert installation after a minimum of 60 months in service. Add the following section: 86-4.06A(4) Construction. a. To prevent water seepage between the back cover and the electrical wires, or between the copper and insulation of the wires, the electrical wires shall not penetrate the LED module housing. te4, Revised 6/15/17 Contract No. 6335 Page 135 of 176 b.The module shall be a single, self-contained device, not requiring on-site assembly for installation into an existing pedestrian signal housing. The power supply shall be designed to fit and mount inside the pedestrian signal module. c.The assembly and manufacturing process for the module shall be designed to assure all internal LED and electronic components are adequately supported to withstand mechanical shock and vibration from high winds and other sources. Add the following section: 86-4.06A(5) Materials. a.Materials used for the lens and LED module construction shall conform to ASTM specifications where applicable. b.Enclosures containing the power supply and electronic components of the LED module shall be made of UL94 flame retardant materials. The lens of the LED module is excluded from this requirement. c.The front window shall be a transparent polycarbonate material with internal masking to prevent the icons and digits from being visible when not in operation. External masking or silk-screen technology shall not be permitted. When not illuminated, the Walking Person, Hand and Countdown Digits shall not be readily visible. Add the following section: 86-4.06A(6) Module Identification. a.Each module shall be identified on the backside with the manufacturer's name, model, serial number and operating characteristics of each symbol. The operating characteristics identified shall include the nominal operating voltage and stabilized power consumption, in watts and Volt-Amperes. b.Modules conforming to this specification (WALKING PERSON, UPRAISED HAND only), may have the following statement on an attached label: "Manufactured in Conformance with the ITE Pedestrian Traffic Control Signal Indications - Part 2: Light Emitting Diode (LED) Pedestrian Signal Modules". Add the following section: 86-4.06B Photometric Requirements. Add the following section: 86-4.06B(1) Luminance, Uniformity and Distribution. a. For a minimum period of eo months, the maintained minimum luminance values for the modules under the operating conditions defined in Sections 2.3.1 and 4.2.1, when measured normal to the plane of the icon surface, shall not be less than: •Walking person: 2,200 cd/m2; •Hand: 1,400 cd/m2. •Countdown digits: 1,400 cd/m2; The luminance of the emitting surface, measured at angles from the normal of the surface, may decrease linearly to a value of 50% of the values listed above at an angle of 15 degrees. The light output requirements in this specification apply to pedestrian signal heads without any visors, hooded or louvered (egg-crate). b. The LED module shall ;!dve -d visual appedi luesiiiiiiat t) that of an incandescent Lin ip (i.e., smooth and non-pixilated). Av. r• Revised 6/15/17 Contract No. 6335 Page 136 of 176 c.Maximum permissible luminance: When operated within the temperature range specified in Section 2.3.2, the actual luminance for a module shall not exceed three times the required peak value of the minimum maintained luminance. d.Luminance uniformity: The uniformity of the signal output across the emitting section of the module lens (i.e. the hand, person or countdown icon) shall not exceed a ratio of 5 to 1 between the maximum and minimum luminance values (cd/m2). Add the following section: 86-4.0613(2) Chromaticity. a. The standard colors for the LED Pedestrian Signal Module shall be White for the walking person and Portland Orange for the hand icon and the countdown digits. The colors for these icons shall conform to the following color regions, based on the 1931 CIE chromaticity diagram: Walking Person —White: Blue boundary: 1st Green boundary: 2nd Green boundary: Yellow boundary: 1st Purple boundary: 2nd Purple boundary: x = 0.280. 0.280 s x< 0.400 y = 0.7917-x + 0.0983. 0.400 s x < 0.450 y = 0.4600.x + 0.2310. x= 0.450 0.450 sx< 0.400 y = 0.4600.x + 0.1810. 0.400 s x < 0.280 = 0.7917.x + 0.0483. White Point x y 1 0.280 0.320 2 0.400 0.415 3 0.450 0.438 4 0.450 0.388 5 0.400 0.365 6 0.280 0.270 Hand and Countdown Digits—Portland Orange: Yellow boundary: y = 0.390 White boundary: 0.600 s x S 0.659 y = 0.990 — x Red boundary: y= 0.331. Revised 6/15/17 Contract No. 6335 Page 137 of 176 Portland Orange Point X Y 1 0.609 0.390 2 0.600 0.390 3 0.659 0.331 4 0.669 0.331 b. Color Uniformity: AY 0.04 Walking Person—White: 11(AX 2 )+ ( where ix and Ay are the differences in the chromaticity coordinates of the measured colors to the coordinates of the average color, using the CIE 1931 Chromaticity Diagram and a 2 degree Standard Observer. Hand and Countdown Digits—Portland Orange: The dominant wavelength for any individual color measurement of a portion of the emitting surface of a module shall be within ±3nm of the dominant wavelength for the average color measurement of the emitting surface as a whole. Add the following section: 86-4.06C Electrical. Add the following section: 86-4.06C(1) General. All wiring and terminal blocks shall meet the requirements of Section 13.02 of the VTCSH Standard. Maximum of three secured, color coded, 1 meter (39 in) long 600 V, 16 AWG minimum, jacketed wires, conforming to the National Electrical Code, rated for service at +105°C, are to be provided for electrical connection. The conductors shall be color coded with orange for the hand, blue for the walking person and white as the common lead. Add the following section: 86-4.06C(2) Voltage. a.LED modules shall operate from a 60 + 3 Hertz ac line power over a voltage range from 80 to 135 VAC RMS. b.Nominal operating voltage for all measurements shall be 120 + 3 VAC RMS. c.Fluctuations in line voltage over the range of 80 to 135 VAC RMS shall not affect luminous intensity by more than + 10 °/0. d.Catastrophic failure of one LED light source in Man & Hand icons shall not result in the loss of more than the light from that one LED. e.To prevent the appearance of flicker, the module circuitry shall drive the LEDs at frequencies greater than 100 Hz when modulated, or at DC, over the voltage range specified in Section 4.2.1. f.Low Voltage Turn Off: There should be no illumination of the module when the applied voltage is less than 35 VAC RMS. To test for this condition, each icon must first be fully illuminated at the nominal operating voltage. The applied voltage shall then be reduced to the point where there is no illumination. This point must be greater than 35 VAC RMS. g.Turn-ON and Turn-OFF Time: A module shall reach 90% of full illumination (turn-ON) within 75 msec of the application of the nominal operating voltaae. The signal shall cease emitting visible illumination (turn-OFF) within 75 msec of the removal of the nominal operating voltage. 4r. tat , —T- Revised 6/15/17 Contract No. 6335 Page 138 of 176 h.Default Condition: For abnormal conditions when nominal voltage is applied to the unit across the two-phase wires (rather than being applied to the phase wire and the neutral wire) the pedestrian signal unit shall default to the hand symbol. i.Icon Power Supplies: LED pedestrian countdown modules shall have two separate power supplies for powering the Walking Person and Upraised Hand icons. The circuitry shall be unrelated to power the LED Walking Person icon and the LED Upraised Hand icon, in order to virtually eliminate the risk of displaying the wrong icon Add the following section: 86-4.06C(3) Transient Voltage Protection. The on-board circuitry of a module shall include voltage surge protection: •To withstand high-repetition noise transients and low-repetition high-energy transients as specified in NEMA Standard TS-2 2003; Section 2.1.8 •Section 8.2 IEC 1000-4-5 & Section 6.1.2 ANSI/IEEE C62.41.2-2002, 3kV, 2 ohm •Section 8.0 IEC 1000-4-12 & Section 6.1.1 ANSI/IEEE C62.41.2-2002, 6kV, 30 ohm Add the following section: 86-4.06C(4) Electronic Noise. The LED signal and associated on-board circuitry shall meet the requirements of the Federal Communications Commission (FCC) Title 47, Subpart B, Section 15 regulations concerning the emission of electronic noise by Class A digital devices. Add the following section: 86-4.06C(5) Power Factor (PF) and AC Harmonics. a.The modules shall provide a power factor of 0.90 or greater when operated at nominal operating voltage, and 25°C (77°F). b.Total harmonic distortion induced into an AC power line by the module, operated at nominal operating voltage, and at 25°C (77°F) shall not exceed 20%. Add the following section: 86-4.06C(6) Controller assembly Compatibility. a.The current draw shall be sufficient to ensure compatibility and proper triggering and operation of load current switches and conflict monitors in signal controller units. b.Off State Voltage Decay: When the module is switched from the On state to the Off state the terminal voltage shall decay to a value less than 10 VAC RMS in less than 100 milliseconds when driven by a maximum allowed load switch leakage current of 10 milliamps peak (7.1 milliamps AC) Add the following section: 86-4.06C(7) Constant Current Drive. The countdown digits shall be driven by constant current to improve LED efficiency and lifespan. Add the following section: 86-4.06C(8) Power Consumption. Maximum power consumption requirements for the modules are as follows: 25°C "Hand" 11.0 Watts "Walking Person" 8.0 Watts "Count-Down Display" 6.0 Watts (when display shows "88") ar. r- Revised 6/15/17 Contract No. 6335 Page 139 of 176 Add the following section: 86-4.06D Module Functions. Add the following section: 86-4.06D(1) Cycle. The module shall operate in one mode: Clearance Cycle Countdown Mode Only. The module shall start counting when the flashing "Don't Walk" turns on and will countdown to "0" and turn off when the steady "Don't Walk" signal turns on. The module shall not have user accessible switches or controls for the purpose of modifying the cycle, icons or digits. Add the following section: 86-4.06D(2) Learning Cycle. At power on, the module enters a single automatic learning cycle. During the automatic learning cycle, the countdown display shall remain dark. Add the following section: 86-4.06D(3) Cycle Modification. The unit shall re-program itself if it detects any increase or decrease of Pedestrian Timing. The digits shall go blank once a change is detected and then take one complete pedestrian cycle (with no counter during this cycle) to adjust its buffer timer. Add the following section: 86-4.06D(4) Recycling. The module shall allow for consecutive cycles without displaying the steady Hand icon ("Don't Walk"). Add the following section: 86-4.06D(6) Pre-Emption. The module shall recognize preemption events and temporarily modify the crossing cycle accordingly. •If the controller preempts during the walking man, the countdown shall follow the controller's directions and shall adjust from walking man to flashing hand. It shall start to count down during the flashing hand. •If the controller preempts during the flashing hand, the countdown shall continue to count down without interruption. The next cycle, following the preemption event, shall use the correct, initially programmed values. This specification is worded such that the flashing "don't walk" time is not modified. Add the following section: 86-4.06D(6) "Don't Walk" Steady. If the controller output displays Don't Walk steady condition or if both the hand /person go dark and the unit has not arrived to zero, the unit suspends any timing and the digits shall go dark. Add the following section: 86-4.06D(7) Power Outage. The digits will go dark for one pedestrian cycle after loss of power of more than 2.0 seconds. Add the following section: 86-4.06D(8) Digit Operation. The digits shall remain continuously lit during the clearance cycle and shall not flash in conjunction with the Hand/Don't Walk icon. Add the following section: 86-4.06E Quality Assurance. 4ts, t at, Revised 6/15/17 Contract No 6335 Page 140 of 176 Add the following section: 86-4.06E(1) General. Unless otherwise specified all of the test will be conducted at an ambient temperature of 25°C and at the nominal operating voltage of 120 VAC RMS. a.The modules shall be manufactured in accordance with a vendor quality assurance (QA) program. b.QA process and test result documentation shall be kept on file for a minimum period of seven years Add the following section: 86-4.06E(2) Conformance. The module designs not satisfying design qualification testing and the production quality assurance testing performance requirements shall not be labeled, advertised, or sold as conforming to this specification. Add the following section: 86-4.06E(3) Production Tests & Inspections. All lamps manufactured shall be affixed with an Intertek ETL Verified label (or other 3 rd Party "Nationally Recognized Testing Laboratory/NRTL") to demonstrate compliance to Section 6.3 (Production Tests & Inspections) of the latest ITE PTCSI Pedestrian specification, dated March 19, 2004. a.All new LED modules tendered for sale shall undergo the following Production Test and Inspection prior to shipment. Failure of a module to meet requirements of these Production Test and Inspection shall be cause for rejection. Test results shall be maintained for a period of 5 years following the production of the last production unit. b.All LED modules shall be tested for maintained minimum luminous intensity. A single point measurement with a correlation to the intensity requirements referred to in Section 3.0 may be used. The LED module shall be operated at nominal operating voltage and at an ambient temperature of 25°C (77°F). c.All LED modules shall be tested for power factor per the requirements of Section 4.6.1. A commercially available power factor meter may be used to perform this measurement. d.All LED modules shall be measured for current flow in Amperes. The measured current values shall be compared against those resulting from design qualification measurements in Section 5.4.6.1. Measured current values in excess of 120% of the design qualification current values shall be cause for rejection. e.All LED modules shall be visually inspected for any exterior physical damage or assembly anomalies. Add the following section: 86-4.06E(4) Design Qualification Testing. a.Design Qualification testing shall be performed on new module designs, and when a major design change has been implemented on an existing design. b.High Temperature High Humidity (HTHH): 1000 hours at +60°C (+140°F), 90% Relative Humidity with cycling starting at 30 down to 0. This will ensure that each symbol is properly tested. c.Unless otherwise specified, all of the tests shall be conducted on the same set of randomly selected modules, hereafter called the sample set, at an ambient temperature of 25°C and at the nominal operating voltage of 120 VAC RMS. d.Testing shall be performed once every 5 years or when the module design or LED technology has been changed. The module manufacturer shall retain test data for a minimum period of 7 years and for a period of at least 5 years beyond the last date of manufacture of that model type. t at, Revised 6/15/17 Contract No. 6335 Page 141 of 176 e.Conditioning: The module shall be energized for a minimum of 24 hours in an ambient temperature of +60°C (+140°F), 0% Relative Humidity with cycling starting at 99 down to 0. This will ensure that each symbol is properly conditioned. f.Mechanical Vibration: Mechanical vibration testing shall be performed per MIL-STD-883, Test Method 2007. g.Temperature Cycling: Temperature cycling shall be performed per MIL-STD-883, Test method 1010. The temperature range shall include the full ambient operating temperature range specified in Section 2.3.2. h.Moisture Resistance: Moisture resistance testing shall be performed per MIL-STD-810F, Test Method 506.4, Procedure I, Rain and Blowing Rain. The test shall be conducted on stand-alone modules, without a protective housing. The modules shall be vertically oriented, such that the lens is directed towards the wind source when at a zero rotation angle. The modules shall be energized throughout the test. The water shall be at 25° ± 5°C (77° ± 9°F). The wind velocity shall be 80 km/hr (50 mph). Add the following section: 86-4.06E(5) Warranty. Manufacturers will provide the following warranty provisions. Replacement or repair of an LED signal module that fails to function as intended due to workmanship or material defects within the first 5 years (60 months) from the date of delivery. 86-4.07 LED Blank-Out Sign. Blank-Out signs shall be manufactured by McCain or be a City approved equal meeting the following requirements: Standard Features •Conforms to applicable MUTCD standards •LED's mounted on modular PCB's •LED strings with no more than 4 LED's per string, are staggered to maintain symbol integrity if an LED fails •Non-glare, high-impact, gray acrylic window •Automatic dimming adjusts to ambient light level • Can withstand temperatures ranging from -37° C to 74° C and humidity from 0 to 95% (non-condensing) •7" sun visor •Screened weep holes •Reliable FR4 PCB's, black solder mask, conformal coated Assemblies •Modular message circuii boards (with LED's) •Solid state power supply •LED interface board (dimmer) •Photocell •Control relay •Field connection terminal block Housing: Material: Access: LED Type / Colors: Sign Viewing Angle: Power Supply: 5052-H32 marine-grade aluminum, 0.125" thick; Finish: Black powder coat (custom colors available) Front, hinged door with padlock hasp Red: 630 nm A and amber: 591 nm A, high intensity, AlInGaPII White: x.--0.,;1, y=0.31, high intensity, InGaN Red & white LED's: 23°, amber LED's: 30° Solid state, 95 - 125 VAC input, 12-15 VDC output, >95% power factor 11' —1- Revised 6/15/17 Contract No. 6335 Page 142 of 176 Power Consumption: 35 W - 105 W (varies per message) Ventilation: Ventilation louvers provided on back of housing, includes washable filter 86-5 DETECTORS Add the following section: 86-5.01B Emergency Vehicle Pre-Emption Detector System. Each emergency vehicle pre-emption detector system shall be Opticom and shall conform to the details shown on the plans and these special provisions and shall consist of an optical emitter assembly or assemblies located on the appropriate vehicle and an optical detector/discriminator assembly or assemblies located at the traffic signal. Each system shall permit detection of Class II emergency vehicles. Class II emergency vehicles shall be capable of being detected at any range up to 2,500 feet from the optical detector. Add the following section: 86-5.01B(1) Optical Emitter Assembly. Each optical emitter assembly shall be Opticom and shall consist of an emitter unit, an emitter control unit and connecting cables and shall conform to the following: Each optical emitter assembly, including lamp, shall be designed to operate over an ambient temperature range of -34°C to 74°C at both modulation frequencies and to operate continuously at the higher frequency for a minimum of 3,000 hours at 25°C ambient before failure of lamp or any other component. Each emitter unit shall be controlled by a single, maintained-contact switch on the respective emitter control unit. The switch shall be capable of being positioned in a readily accessible location to the vehicle driver. The control unit shall contain a pilot light to indicate that the emitter power circuit is energized and shall be capable of generating only Class II modulating code. Functional Requirements. Each emitter unit shall transmit optical energy in one direction only. The signal from each emitter unit shall be capable of being detected at a distance of 2,500 feet when used with a standard optical detection/discriminator assembly. The modulation frequency for Class II signal emitters shall be 14.035 Hz ± 0.003 Hz. The standard optical detection/discriminator assembly to be used in conducting the range tests shall be available from the manufacturer of the system. A certified performance report shall be furnished by the contractor with each assembly. The emitter unit shall be configured with a grating to provide precise directionality control. Electrical Requirements. Each optical emitter assembly shall be capable of providing full light output with input voltages between 10 and 16 volts DC. An optical emitter assembly shall not be damaged by input voltages up to 7.5 volts DC about the supply voltage. The optical emitter assembly shall not generate voltage transient, on the input supply, which exceeds the supply voltage by more than 4 volts. Each optical emitter assembly shall not consume more than 100 watts at 17.5 volts DC and shall have a power input circuit breaker rated at 10 to 12 amperes, 12 volts DC. The design and circuitry of each emitter unit shall permit its use on vehicles with either negative or positive ground without disassembly or rewiring of the unit. WS' ta w* --1- Revised 6/15/17 Contract No. 6335 Page 143 of 176 Mechanical Requirements. Each emitter unit shall be housed in a weatherproof, corrosion- resistant housing. The housing shall be provided with facilities to permit mounting on various types of vehicles and shall have provision for proper alignment of the emitter unit and for locking of the emitter unit into proper alignment. Each emitter control unit shall be provided with appurtenant hardware to permit its mounting in or on an emergency vehicle or mass transit vehicle. Where required for certain emergency vehicles, the emitter control unit and all exposed controls shall be weatherproof. Each emitter shall include a multi-purpose port compliant with the SAE J1708 communication standard to enable unit configuration to be set into the emitter and read from the emitter. Add the following section: 86-5.01E3(2) Optical Detection/Discriminator Assembly. Optical detection/discriminator assembly shall consist of one or more optical detectors, connecting cable and a discriminator module and conform to the following: Each such assembly, when used with standard emitters, shall have a range of up to 2,500 feet for Class II signals. Standard emitters for Class II signals shall be available from the manufacturer of the system. Range measurements shall be taken with all range adjustments on the discriminator module set to "maximum". Add the following section: 86-5.016(3) Optical Detector. Each optical detector shall be a waterproof unit capable of receiving optical energy from one or two separately aimable directions. The horizontal angle between the two directions shall be variable from 5 degrees to 180 degrees. The reception angle for each photocell assembly shall be a maximum of 8 degrees in all directions about the aiming axis of the assembly. Measurements of reception angle will be taken at a range of 2,500 feet for a Class ll emitter. All internal circuitry shall be solid state and electrical power shall be provided by the associated discriminator module. Each optical detector shall be contained in a housing, which shall include one or two rotatable photocell assemblies, an electronic assembly and a base. The base shall have an opening to permit its mounting on a mast arm. Each optical detector shall weigh no more than 2.5 pounds and shall present a maximum wind load area of 36 square inches. The housing shall be provided with weep holes to permit drainage of condensed moisture. Each optical detector shall be installed, wired and aimed as specified by the manufacturer. Add the following section: 86-5.016(4) Optical Detector Cable. Optical detector cable shall meet the requirements of IPCEA-S-61-402/NEMA WC 5, Section 7.4, 600 volt control cable, 75°C, Type B and the following: The cable shall contain three conductors, each of which shall be AWG #20 (7x28) stranded, tinned copper with low-density polyethylene insulation. Minimum average insulation thickness shall be 25 mils. The insulation of individual conductors shall be color coded as follows: Yellow Detector Signal #1 Blue Detector Signal #2 Orange Power (+) I, ' Revised 6/15/17 Contract No. 6335 Page 144 of 176 Bare (Drain) - Common or Ground The shield shall be either tinned copper braid or aluminized polyester film with a nominal 20 percent overlap. Where the film is used, a AWG #20 (7x28) standard, tinned, bare drain wire shall be place between the insulated conductors and the shield and in contact with the conductive surface of the shield. The jacket shall be black polyvinyl chloride with a minimum rating of 600 volts and 80°C and a minimum average thickness of 45 mils. The jacket shall be marked as required by IPCEA/NEMA. The finished outside diameter of the cable shall not exceed 0.3 inches. The capacitance of the optical detector cable, as measured between any conductor and the other conductors and the shield, shall not exceed 14.3 microfarads per 1000 feet. The characteristic impedance of the optical detector cable shall be 0.6 ohms per 1000 feet. Add the following section: 86-5.01E3(5) Discriminator Module. Each discriminator module shall be Opticom 764 and shall be designed to be compatible and usable with Model 2070 controller unit and to be mounted in the input file of a Model 332 controller cabinet, and shall conform to the requirements of Chapter 1 of the State of California, Department of Transportation, "Traffic Signal Control Equipment Specifications", dated January 1989, and to all addenda thereto current at the time of project advertisement. Each discriminator module shall be capable of operating one or two channels and shall be capable of: 1 Receiving Class II signals at a range of up to 2,500 feet. 2.Decoding the signal on the basis of frequency at 14.035 Hz ± 0.003 Hz for Class II signals. 3.Establishing the validity of received signals on the basis of frequency and length of time received. A signal shall be considered valid only when received for more than 0.50 seconds. No combination of Class I signals shall be recognized as a Class II signal regardless of the number of signals being received, up to a maximum of ten signals. Once a valid signal has been recognized, its effect shall be held by the module in the event of temporary loss of the signal for a period adjustable from 4.5 seconds to 11 seconds in at least 2 steps at 5 ± 0.5 seconds and 10 ± 0.5 seconds. 4.Providing an output for each channel that will result in "lovst or grounded condition of the appropriate input of a Model 170 controller unit. For Class II signals the output shall be steady. Each discriminator module shall be powered from 115 volt (95 volts AC to 135 volts AC), 60 Hz mains and will contain an internal, regulated power supply that supports up to twelve optical detectors. Electric power, one detector input for each channel and one output for each channel, shall terminate at the printed circuit board edge connector pins listed below. Board edge connector pin assignments shall be as follows: Revised 6/15/17 Contract No. 6335 Page 145 of 176 Function Ground Channel A primary detector input Detector 24 VDC power output Channel A output, collector (+) Channel A output, emitter (-) Channel B primary detector input Detector ground Earth ground AC - (in) AC + (in) Function Not used Detector 24 VDC power output Not used Not used Not used Detector ground Channel B output collector (+) Channel B output emitter (-) Not used Not used Pins V X Pins A Two auxiliary inputs for each channel shall enter each module through the front panel connector. Pin assignment for the connector shall be as follows: Pins Function 13 Auxiliary detector 2 input, Channel A 14 Auxiliary detector 1 input, Channel B 15 Auxiliary detector 2 input, Channel B 28 Auxiliary detector 1 input, Channel A Each channel output shall be an optically isolated NPN open collector transistor capable of sinking 50 milliamperes at 30 volts and shall be compatible with Model 170 controller unit inputs. Each discriminator module shall be provided with means of preventing transients received by the detector from affecting the Model 170 controller assembly. Each discriminator module shall have a single connector board, shall be capable of being inserted into the input file of a Model 332 cabinet and shall occupy one slot width of the input file. The front panel of each module shall have a handle to facilitate withdrawal and the following controls and indicators for each channel: 1.A Command (High) and Advantage (Low) solid-state LED indicator for each channel to display active calls. 2.A test switch for each channel to test proper operation of Command or Advantage priority. 3.A single confirmation light control output for each channel. These outputs shall be user configurable through software for a variety of confirmation light sequences. The front panel shall be provided with a single circular, bayonet-captured, multi-pin connector for two auxiliary detector inputs for each channel. Connector shall be a mechanical configuration equivalent to a D-Shell 44-Pin front panel. Wiring for a Model 332 cabinet shall conform to the following: Slots 12 and 13 of the input file "J" shall be wired to accept a two-channel module. Field wiring for the primary detectors, except 24-volt DC power, shall terminate on either terminal board TB-9 in the controller cabinet or on the rear of input file "J", depending on cabinet configuration. Where TB-9 is used, position assignments shall be as follows: 10)' fa4: Revised 6/15/17 Contract No. 6335 Page 146 of 176 Position Assignment 4 Channel A detector input, 1st module (Slot J-12) 5 Channel B detector input, 1st module (Slot J-12) 7 Channel A detector input, 2nd module (Slot J-13) 8 Channel B detector input, 2nd module (Slot J-13) The 24 volt cabinet DC power shall be available at Position 1 of terminal board TB-1 in the controller cabinet. All field wiring for the auxiliary detectors shall terminate on terminal board TB-0 in the controller cabinet. Position assignments are as follows: Position Assignment 7 +24\/DC from (J-13E) 8 Detector ground from (J-13K) 9 Channel A auxiliary detector input 1 10 Channel A auxiliary detector input 2 11 Channel B auxiliary detector input 1 12 Channel B auxiliary detector input 2 The contractor shall demonstrate that all of the components of the system will perform satisfactorily as a system. Satisfactory performance shall be determined using the following test procedure: 1.Each system to be used for testing shall consist of an optical emitter assembly, an optical detector, at least 200 feet of optical detector cable and a discriminator module. 2.The discriminator modules shall be installed in the proper input file slot of Model 332 controller cabinet. The controller cabinet, together with a Model 170 controller unit with the appropriate operating program, a Model 210 monitor unit and 120 volt AC power, will be available as shown on the plans and as indicated elsewhere in these special provisions. 3.One test shall be conducted using a Class ll signal emitter and a distance of 2,500 feet between the emitter and the detector. All range adjustments on the module shall be set to "Maximum" for each test. 4.Each test shall be conducted for a period of one hour, during which the emitter shall be operated for 30 cycles, each consisting of a one minute "on" interval and a one minute "off' interval. During the total test period: (A) the emitter signal shall cause the proper response from the Model 170 controller unit during each "on" interval and (B) there shall be no improper operation of either the Model 170 controller unit or the monitor during each "off" interval. 86-5.01B(6) GridSmart Video Detection System. Video detection system shall be a Gridsmart System manufactured by GridSmart or approved equal. The system shall include all necessary components to run the system including but not limited to: • GS-3-CBL 84" Cable Bracket • GS-3-CAT5 Burial Grade CAT5E Cable • GS-3-CBP Controller Breakout Panel • GS-3-GS2 GridSmart GS2 Processor • GS-3-RMB Rack Mount Bracket • GS-2-TS1-OPT GS2 Processor TS1 Module • GS-3-PFM+ Performance Plus Module • GS-3-SMK SmartMount Bell Camera • GS-3-TS1 TS1 Interface Cable to 4, Revised 6/15/17 Contract No. 6335 Page 147 of 176 The contact documents show the location of the Gridsmart Bell Camera for quantity takeoff purposed only. The contractor shall coordinate with the manufacturer's representative to determine the best installation location of the Bell Camera for a fully functioning system. All system components shall be installed and configured per manufacturers specifications. 86-6 LIGHTING Replace Section 86-6.02 with the following: 86-6.02 Luminaires for Safety Lighting. Luminaires for safety lighting on traffic signal standards shall be 1,600 lumen (120 watt). Safety lighting luminaires shall be General Electric catalog number ERL2-0-16-C3-40-D-GRAY-LY or approved equal. Add the following: 86-6.07 Photoelectric Controls. Type IV photoelectric control shall be used unless otherwise shown on the plans or required by these special provisions and shall be installed in a receptacle integral with the luminaire. ADD Section 209-6: 209-6 Measurement and Payment Payment for Signals, Lighting and Traffic Electrical Systems shall be made at the contract lump sum for Traffic Signal Improvements and no other payments will be made. SECTION 210 - PAINT AND PROTECTIVE COATINGS 210-1 PAINT. 210-1.5 Paint Systems. Add the following to Table 210-1.5(A) TABLE 210-1.5(Al Surface to be Painted Pre-Treatment / Surface Preparation Primer Finish Coats Temporary Railing type (K) Abrasive Blast Cleaning to a Roughened, Textured _Aspfp_T.nce None Two coats white Acrylic Emulsion Paint (1) (1) acrylic emulsion paint designed for use on exterior masonry. This paint shall comply in all respects to Federal Specification TT-P- 19 (latest revision), Paint, Acrylic Emulsion, Exterior. This paint may be tinted by using "universal" or "all purpose" concentrates. 210-1.6 Paint for Traffic Striping, Pavement Marking, and Curb Marking. Modify as follows: Paint for traffic lane lines, turn pocket lines, edge lines, channelizing lines, bike lane lines, chevrons, and curbs shall be rapid dry water borne conforming to CALTRANS Specification No. PTWB-01. Paint for pavement legends, pavement symbols, pavement arrows, cross walks, parking stall markings and stop bars shall be alkyd thermoplastic conforming to CALTRANS Specification No. 8010-19A. Glass beads shall be applied to the surface of the rapid dry water borne paint and the molten thermoplastic material and shall conform to the requirements of CALTRANS Specification No. 8010-004 (Type II). CALTRANS Specifications for water borne paint, thermoplastic material and glass beads may be obtained from the CALTRANS Transportation Laboratory, P.O. Box 19128, Sacramento, CA 95819, telephone number (9161 227-7000. 11, —1— Revised 6/15/17 Contract No. 6335 Page 148 of 176 210-3 GALVANIZING. Add the following section: 210-3.6 Galvanizing for Traffic Signal Facilities. The requirements of this section shall pertain only to the preparation and galvanizing of traffic signal facilities. Galvanizing of products fabricated from rolled, pressed and forged steel shapes, plates, bars and strip 3.2 mm (1/8") thick or thicker, shall conform to the specifications of ASTM Designation: A 123, except that complete seal welding of tightly contacting surfaces of these products prior to galvanizing is required only where seal welding is shown on the plans or specified in these special provisions. Except for pre-galvanized standard pipe, galvanizing of material 3.2 mm (1/8") thick or thicker shall be performed after fabrication into the largest practical sections. At the option of the Contractor, material thinner than 3.2 mm (1/8") shall be galvanized either before fabrication in conformance with the requirements of ASTM Designation: A 525M, Coating Designation Z600, or after fabrication in conformance with the requirements of ASTM Designation: A 123, except that the weight of zinc coating shall average not less than 365 g per square meter (1.2 oz. per ft2) of actual surface area with no individual specimen having a coating weight of less than 305 g per square meter (1.0 oz. per ft2). Galvanizing of standard pipe shall conform to the requirements of ASTM Designation: A 53. Galvanizing will not be required for stainless steel, monel metal and similar corrosion resistant parts. Fabrication shall include all operations such as shearing, cutting, punching, forming, drilling, milling, bending, welding and riveting. All welded areas shall be thoroughly cleaned prior to galvanizing to remove all slab or other material that would interfere with the adherence of the zinc. When it is necessary to straighten any sections after galvanizing, the work shall be performed without damage to the zinc coating. Galvanizing of iron and steel hardware and nuts and bolts, when specified or shown on the plans, shall conform to the specifications of ASTM Designation: A 153, except whenever threaded studs, bolts, nuts, and washers are specified to conform to ASTM Designation: A 307, A 325, A 325M, A 449, A 563, A 563M, or F 436 and zinc coating is required, they shall be hot-dip zinc coated or mechanically zinc coated in accordance with the requirements of the ASTM Designations. Unless otherwise specified, galvanizing shall be performed after fabrication. Components of bolted assemblies shall be galvanized separately before assembly. Tapping of nuts or other internally threaded parts to be used with zinc coated bolts, anchor bars or studs shall be done after galvanizing and shall conform to the requirements for thread dimensions and overlapping allowances in ASTM Designation: A 563 or A 563M. When specified, painting of zinc coated surfaces shall be in accordance with the procedures in Section 210.1 "Paint". Galvanized surfaces that are abraded or damaged at any time after the application of the zinc coating shall be repaired by thoroughly wire brushing the damaged areas and removing all loose and cracked coating, after which the cleaned areas shall be painted with two applications of unthinned zinc-rich primer (organic vehicle type) conforming to the provisions in Section 210-3.5, "Repair of Damaged Zinc Coating." Aerosol cans shall not be used. •11, to 42 —1- Revised 6/15/17 Contract No. 6335 Page 149 of 176 SECTION 212 - LANDSCAPE AND IRRIGATION MATERIALS Add Section 212-4 the following: 212-4 HYDRANTS 212-4.1 General. Fire hydrant assembly shall be per Carlsbad Municipal Water District (CMWD) approved materials list for use on construction of potable and recycled water facilities. Fire Hydrant installation shall conform to City of Carlsbad Engineering Standards Volume 3 Chapter 6 Section 15139 "Fire Hydrants," and CMWD Standard Drawing No. W-12. Trenching shall be per CMWD Standard Drawing W-2. Backfill and resurface shall be per City of Carlsbad Supplement Standard No. GS- 24 and GS-28. 212-4.2 Existing Water Line Removal Removal or existing water lines shall conform to City of Carlsbad Engineering Standards Volume 3 Chapter 6 Section 15000 Part 3.11. Backfill and resurface shall be per City of Carlsbad Supplement Standard No. GS-24 and GS-28. SECTION 213 - ENGINEERING FABRICS 213-2 GEOTEXTILES. 213-2.1 General. Add the following: Geotextile types shall be used for the applications listed in Table 213-2.1(A) TABLE 213-2.1(A) GEOTEXTILE APPLICATIONS Application of Geotextile Type Designation Separation of Soil and Street Structural Section 9OWS Separation of Soil and Subsurface Aggregate Drain 180N Reinforcement of Street Structural Section 200WS Remediation and Separation of Soil 270WS Reinforcement of Soil 270WS Drainage at the Interface of Soil Structures N/A Drainage at the Interface of Soil and Structures N/A Rock Slope Protection Fabric for Rock Sizes Below 225 kg (1/4 Ton) 180N Rock Slope Protection Fabric for Rock Sizes Including and Above 225 kg (1/4 Ton) 250N Plant Protection Covering 90N Erosion Control Fence with 14 AWG - 150 mm x 150 mm (6"x6") Wire and 3 m (10') Post Spacing 9OWS Erosion Control Fence with 1.8 m (6') Post Spacing and No Wire Fencing 200WS Add the following section: 213-3 EROSION CONTROL SPECIALTIES. 02"10 4 Revised 6/15/17 Contract No. 6335 Page 150 of 176 Add the following section: 213-3 Gravel bags. Gravel bags for the use of temporary erosion control shall be burlap type, filled with no less than 23kg (50 lbs) of 19 mm (3/4") crushed rock and securely tied closed. Plastic bags are not acceptable. SECTION 214 PAVEMENT MARKERS 214-5 REFLECTIVE PAVEMENT MARKERS Add the following section: 214-5.1 Temporary Reflective Pavement Markers. Temporary pavement markers shown on the plans and required in the specifications shall be one of the types shown in Table 214-5.1(A), or equal thereto. TABLE 214-5.1(A) TEMPORARY REFLECTIVE PAVEMENT MARKERS Type Manufacturer of Distributor TOM- Temporary Overlay Davidson Traffic Control Products, 3110 70th Avenue East, Markers Tacoma, WA 98424, (877) 335-4638 Add the following section: 214-5.2 Permanent Reflective Channelizer. Reflective Channelizer shall be new surface- mounted type and shall be furnished, placed, and maintained at the locations shown on the plans. Reflective channelizer posts shall be orange in color. Reflective channelizers shall have affixed white reflective sheeting as specified in the special provisions. The reflective sheeting shall be 75 mm x 300 mm in size. The reflective sheeting shall be visible at 300 m at night under illumination of legal high beam headlights, by persons with vision of or corrected to 20/20. Reflective channelizer shall be one of the types shown in Table 214-5.2(A), or equal thereto. TABLE 214-5.2(A) REFLECTIVE CHANNELIZER Type Manufacturer of Distributor Safe-Hit SH336SMA Safe-Hit, A Division of Energy Absorption Systems, Inc. 35 East Wacker Drive, Suite 1100 Chicago, IL 60602 (800) 537-8958 Carsonite "Super Duck" SDR3036 Carsonite Composites, LLC 605 Bob Gifford Boulevard Early Branch, SC 29916 (800) 648-7916 Repo "The Replaceable Post" Western Highway Products 10680 Fern Avenue Stanton, CA 90680 (800) 854-3360 43* Revised 6/15/17 Contract No. 6335 Page 151 of 176 The Contractor shall provide the Engineer with a Certificate of Compliance in accordance with the provisions of Section 2-5.3.3 "Submittals". Said certificate shall certify that the permanent reflective channelizers comply with the plans and specifications and conform to the prequalified design and material requirements approved by the engineer and were manufactured in accordance with the approved quality control program. SECTION 215 - FENCING Add the following section: 216-1 ENVIRONMENTAL FENCING Add the following section: 216-1.1 Materials. Environmental fence shall be minimum 4'-3" high, orange colored plastic construction fencing installed prior to performing any work. Environmental fence shall be constructed of non-toxic, non-conductive polyethylene capable of withstanding temperatures from —58F degrees to 194F degrees. Color shall be non-fading. Posts shall be 6'-6" long, shall be spaced no more than 10'-0" apart and buried portion shall be no less than 2'-6" deep. Used materials may be installed providing the used materials are good, sound, and are suitable for the purpose intended, as determined by the Engineer. Materials may be commercial quality providing the dimensions and sizes of the materials are equal to, or greater than, the dimensions and sizes specified herein. Posts shall be either metal or wood at the Contractor's option. Galvanizing and painting of steel items will not be required. Treating wood with wood preservatives will not be required. Concrete footings for metal posts will not be required. 4fSei t Revised 6/15/17 Contract No. 6335 Page 152 of 176 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 3, CONSTRUCTION METHODS SECTION 300 - EARTHWORK 300-1 CLEARING AND GRUBBING. 300-1.1 General. add the following to the third paragraph: During surface clearing operations, the Contractor shall not cover or bury any plant growth or other objectionable materials. If the Contractor cannot successfully separate the plant growth from the surface soil and advertently or inadvertently mixes organic or other objectionable materials with the soil, the soil so contaminated shall be removed from the site by the Contractor. All costs, if any, associated with removing the soil mixed with organic or other objectionable materials and importing soil to replace said contaminated soil shall be borne by the Contractor and no additional payment therefore shall be made to the Contractor. 300-1.3 Removal and Disposal of Materials, add the following: Also included in clearing and grubbing shall be removal and disposal of existing street poles and lights, metal guard rail, fences, asphalt concrete and aggregate base, concrete curb and gutter, concrete sidewalk, existing gate, existing headwalls, rip-rap, traffic signs, and other existing features which interfere with the work. Whether or not such items are shown on the plans they shall be removed as a part of clearing and grubbing. Existing underground pipes and conduits that are shown on the plans and designated to be removed shall be removed by the Contractor as a part of clearing and grubbing. 300-1.4 Payment. Modify as follows: Payment for clearing and grubbing shall be made at the contract lump sum price for clearing and grubbing within the project limits and at stockpile locations and no other payments will be made. Unless otherwise noted on plans, the Contractor shall remove all existing abandoned pipelines and conduits of any type, or use, and pipelines and conduits of any type, or use, that are abandoned during the course of the work and shall replace said pipelines and conduits with properly compacted soils. Payment for removal and disposal of abandoned utilities shall be included in the lump-sum bid for Clearing and Grubbing, and no additional payment will be made. 300-5 BORROW EXCAVATION. Add the following section: 3Cf.)-5.2.1 Imported Borrow Properties. The Contractor shall provide imported borrow that is clean well graded soil consisting of material conforming to all of the requirements in Table 300-5.2.1(A) and the following requirements. Rock included in the top 1 m (3') of imported borrow shall be particles of less than 75 mm (3"). Rock included below the top 1 m (3') of imported borrow shall be particles of less than 150 mm (6"). 41‘ 31:41 —1- Revised 6/15/17 Contract No. 6335 Page 153 of 176 TABLE 300-5.2.1(A) IMPORTED BORROW PROPERTIES Tests Test Method No. Requirements R-Value Calif. 301 40 Min. Expansion Index UBC Standard 18-2 10 Max. Plasticity Index ASTM D 424 4 Max. Sieve Analysis ASTM D 422 Percent Passing 75µ (No. 200) 15 Max. 300-9 GEOTEXTILES FOR EROSION CONTROL. Modify as follows: 300-9 GEOTEXTILES FOR EROSION CONTROL AND WATER POLLUTION CONTROL. Add the following section: 300-9.2 General. The Contractor shall provide erosion control and water pollution control conforming to the requirements shown on the plans, as specified herein, and as elsewhere required by the Contract Documents. Erosion control and water pollution control shall include the work specified herein, and such additional measures, as may be directed by the Engineer, to meet Best Management Practices, as defined herein, and to properly control erosion and storm water damage of the limits of work and construction impacts upon areas receiving drainage flows from within the limits of work. Add the following section: 300-9.2.1 Grading Controls. The Contractor shall protect all areas that have been graded and/or cleared and grubbed as well as areas that have not been graded and/or cleared and grubbed within the limits of work from erosion. The Contractor shall provide temporary earth berms, gravel bags, silt fences, stabilized construction entrances and similar measures, coordinated with its construction procedures, as necessary and as shown on the plans to control on site and off site erosion during the construction period. The Contractor will be required to protect areas which have been cleared and grubbed prior to excavation or embankment operations, and which are subject to runoff during the duration of the contract. The criteria used to determine the appropriate erosion control measures shall be the "Best Management Practices", hereinafter BMP, defined and described in the, "Stormwater Best Management Practices Handbook, Construction", January 2009 edition as published by the California Stormwater Quality Association. The Contractor shall maintain a copy of the "Stormwater Best Management Practices Handbook, Construction", January 2009 edition on the project site and shall conduct its operations in conformity to said Handbook. Temporary erosion control measures provided by the Contractor shall include, but not be limited to, the following: a)Embankment areas, while being brought up to grade and during periods of completion prior to final roadbed construction, shall be graded so as to direct runoff into impoundment areas within the limits of work where such runoff shall have pollutants removed by BMP methods. b)The Contractor shall provide protection by BMP measures to eliminate erosion and the siltation of downstream facilities and adjacent areas. These measures shall include, but shall not be limited to: temporary down drains, either in the form of pipes or paved ditches with protected ouffall berms; graded berms around areas to eliminate erosion of embankment slopes by surface runoff; confined ponding areas to desilt runoff; and to desilt runoff. C) Excavation areas, while being brought to grade, shall be protected from erosion and the resulting siltation of downstream facilities and adjacent areas by the use of BMP measures. t.4.1 —I- Revised 6/15/17 Contract No. 6335 Page 154 of 176 These measures shall include, but shall not be limited to, methods shown on the plans and described herein. Add the following section: 300-9.2.2 Payment. Full compensation for performing erosion control and water pollution control, conforming to the operational requirements herein, of the BMP and conforming to the requirements of the Federal Water Pollution Control Act, including the latest amendments thereto, which is not a part of the planned permanent work or included as a separate bid item shall be considered as included in the contract price bid for unclassified excavation, and no additional compensation will be allowed therefore. 300-13 STORM WATER POLLUTION PREVENTION PLAN Add the following section: 300-13.1 Storm Water Pollution Prevention Plan. As part of the storm water pollution prevention work, the Contractor shall prepare and submit Storm Water Pollution Prevention Plan, hereafter referred to as the "SWPPP,". The SWPPP shall conform to the requirements of the "Greenbook" Standard Specifications for Public Works Construction, the requirements in the California Storm Water Quality Association, Stormwater Best Management Practice Handbook, Construction ("Handbook"), the requirements of the Permit, the requirements in the plans and these supplemental provisions. 300-13.1.1 SWPPP Document Within 15 calendar days after the execution of the contract, the Contractor shall submit 3 copies of the SWPPP to the Engineer, in accordance with Section 2-5.3.3 of these Special Provisions. Contractor will be provided the digital format for SWPPP to complete required sections. If revisions are required, as determined by the Engineer, the Contractor shall revise and resubmit the SWPPP within 15 days of receipt of the Engineer's comments and shall allow 5 days for the Engineer to review the revisions. Upon the Engineer's acceptance of the SWPPP, 3 additional copies of the SWPPP, incorporating the required changes, shall be submitted to the Engineer. In order to allow construction activities to proceed, the Engineer may conditionally approve the SWPPP while minor revisions are being completed. The objectives of the SWPPP shall be to identify pollution sources that may adversely affect the quality of storm water discharges associated with the project and to identify, construct, implement and maintain storm water pollution prevention measures, hereafter referred to as control measures, to reduce to the extent feasible pollutants in storm water discharges from the construction site both during and after construction is completed under this contract. The SWPPP shall incorporate control measures in the following categories: 1.Soil stabilization practices; 2.Sediment control practices; 3.Wind erosion control practices; and 4.Non-storm water management and waste management and disposal control practices. Specific objectives and minimum requirements for each category of control measures are contained in the Handbook. The Contractor shall designate a Water Pollution Control Manager who will have the responsibilities outlined in the SWPPP. —1- Revised 6/15/17 Contract No. 6335 Page 155 of 176 The SWPPP shall include, but not be limited to, the following items as described in the SWPPP: 1.Source Identification; 2.Erosion and Sediment Controls; 3.Non-Storm Water Management; 4.Waste Management and Disposal; 5.Maintenance, Inspection and Repair; 6.Training; 7.List of Contractors and Subcontractors; 8.Post-Construction Storm Water Management; 9.Preparer; 10.Copy of the local permit; 11.BMP Consideration Checklist; 12.SWPPP Checklist; 13.Schedule of Values; and 14.Storm Water Pollution Prevention Drawings. The Contractor shall amend the SWPPP, graphically and in narrative form, whenever there is a change in construction activities or operations which may affect the discharge of significant quantities of pollutants to surface waters, ground waters, municipal storm drain systems, or when deemed necessary by the Engineer. The SWPPP shall also be amended if it is in violation of any condition of the Permit or has not effectively achieved the objective of reducing pollutants in storm water discharges. Amendments shall show additional control measures or revised operations, including those in areas not shown in the initially accepted SWPPP, which are required on the project to control water pollution effectively. Amendments to the SWPPP shall be submitted for review and acceptance by the Engineer in the same manner specified for the initially accepted SWPPP. Accepted amendments shall be dated and logged in the SWPPP. Upon acceptance of the amendment, the Contractor shall implement the additional control measures or revised operations. The Contractor shall keep a copy of the accepted SWPPP and accepted amendments at the project site. The SWPPP shall be made available upon request of a representative of the Regional Water Quality Control Board, State Water Resources Control Board, U.S. Environmental Protection Agency or local storm water management agency. Requests by the public shall be directed to the Engineer. By June 15 of each year, the Contractor shall submit an annual certification to the Engineer stating compliance with the requirements governing the Permit. If the project is in non-compliance at any time, the Contractor shall make a written report to the Engineer within 15 days of identification of non-compliance. Add the following section: 300-13-1.2 Availability of SWPPP template. A site-specific draft document intended for use as a template for the required SWPPP document will be made available for use at the Contractor's option, at no cost to the Contractor. The document is available for review in Appendix B. The Contractor shall review the template and modify it as necessary to reflect the Contractor's operations. Add the following section: 300-13.1.3 Payment. Preparation, implementation and management of SWPPP shall be considered incidental to the items of work and no additional payment will be made therefore. —1- Revised 6/15/17 Contract No. 6335 Page 156 of 176 Add the following section: 300-13.1.4 SWPPP Implementation. Upon acceptance of the SWPPP, the Contractor shall be responsible throughout the duration of the project for installing, constructing, inspecting and maintaining the control measures included in the SWPPP and any amendments thereto and for removing and disposing of temporary control measures. Unless otherwise directed by the Engineer or specified in these supplemental provisions, the Contractor's responsibility for SWPPP implementation shall continue throughout any temporary suspension of work ordered in accordance with Section 6-3, "Suspension of Work". Requirements for installation, construction, inspection, maintenance, removal and disposal of control measures are specified in the "Handbook" and these supplemental provisions. Soil stabilization practices and sediment control measures, including minimum requirements, shall be provided throughout the winter season, defined as between October 1 and April 30. Implementation of soil stabilization practices and sediment control measures for soil-disturbed areas of the project site shall be completed, except as provided for below, no later than 20 days prior to the beginning of the winter season or upon start of applicable construction activities for projects which begin either during or within 20 days of the winter season. The Contractor shall implement, year-round and throughout the duration of the project, control measures included in the SWPPP for sediment tracking, wind erosion, non-storm water management and waste management and disposal. The Engineer may order the suspension of construction operations, at the Contractor's cost, which create water pollution if the Contractor fails to conform to the requirements of this section as determined by the Engineer. Add the following section: 300-13.1.5 Maintenance. To ensure the proper implementation and functioning of control measures, the Contractor shall regularly inspect and maintain the construction site for the control measures identified in the SWPPP. The Contractor shall identify corrective actions and time frames to address any damaged measures or reinitiate any measures that have been discontinued. The construction site inspection checklist provided in the "Handbook" shall be used to ensure that the necessary measures are being properly implemented, and to ensure that the control measures are functioning adequately. The Contractor shall submit one copy of each site inspection record to the Engineer, within two days of the inspection. During the winter season, inspections of the construction site shall be conducted by the Contractor to identify deficient measures, as follows: 1.When the five-day rain probability forecast exceeds forty percent (40%). 2.After any precipitation which causes runoff capable of carrying sediment from the construction site; 3.At 24 hour intervals during extended precipitation events; and 4.Routinely, at a minimum of once every week. If the Contractor or the Engineer identifies a deficiency in the deployment or functioning of an identified control measure, the deficiency shall be corrected by the Contractor immediately, or by a later date and time if requested by the Contractor and accepted by the Engineer in writing, but Revised 6/15/17 Contract No. 6335 Page 157 of 176 not later than the onset of subsequent precipitation events. The correction of deficiencies shall be at no additional cost to the City. SECTION 301 - TREATED SOIL, SUBGRADE PREPARATION AND PLACEMENT OF BASE MATERIALS 301-1 SUBGRADE PREPARATION. 301-1.2 Preparation of Subgrade. Modify the second and third paragraphs as follows: Change each instance reading "150mm (6 inches)" to "300 mm (12")". 301-1.3 Relative Compaction. Delete the first paragraph and substitute the following: The Contractor shall compact the upper 300 mm (12") of subgrade beneath areas to be paved, have base or subbase material placed on them, or curb, gutter, curb and gutter, alley pavement, driveway or sidewalk constructed over them to no less than 95 percent maximum dry density as determined by ASTM test D-1557-91. 301-1.7 Payment. Modify the first paragraph as follows: Payment for subgrade preparation shall be included in the contract bid price for which the subgrade is prepared and shall include all labor, materials; including water, operations and equipment to scarify, adjust moisture, compact or recompact the subgrade, both in cut areas and in fill areas, and no further compensation will be allowed. SECTION 302 - ROADWAY SURFACING Add the following: The Contractor shall be responsible for tree trimming along the curb line as noted in Section 300-1 Clearing and Grubbing — so as to provide a clear travel way during the construction of the roadway resurfacing. The Contractor shall treat all vegetation within the limits of the paved area to be surfaced with a post emergent herbicide. Herbicide shall be applied at least 2 (two) working days prior to surfacing the street. Allowance for the two day period shall be shown in the schedule required per section 6-1. Payment for pavement surfacing shall include tree trimming and post emergent herbicide treatment of the areas to be surfaced and no extra payment will be made therefore. Public Convenience and Traffic Control. The Contractor shall schedule the work so as to prevent damage by all traffic. The Contractor shall not schedule work so as to conflict with trash pickup. The trash hauling schedule can be obtained by calling Coast Waste Management at (760) 929-9400. At least two weeks prior to work, Contractor shall send, by first class mail, notification letters to all property addresses within 500' of the work. Obtaining the appropriate addresses shall be the contractor's responsibility. Letters shall be as shown in bold type as follows, with the appropriate information specific to the work inserted at the locations indicated in the brackets and italicized. 41.31' —1- Revised 6/15/17 Contract No 6335 Page 158 of 176 (Name of Contractor) (Address of Contractor) (Contractor's License Number) (Date) As a part of the City of Carlsbad's ongoing program to maintain its streets, your street will be (insert type of resurfacing), beginning in two or three weeks. This process requires that your street be closed for (X hours) starting at 7:00 a.m. and continuing until the Contractor removes the traffic control devices. You will be notified 72 hours in advance of the day your street will be closed by a brightly colored 3 1/2" x 8 1/2" card attached to your doorknob. You will also notice temporary no parking signs on your street with a specific no parking date written on it. A successful street maintenance program depends on your cooperation. Please do not drive, walk, play, skate or allow pets on the street until it is opened by the Contractor. Furthermore, please do not wash your car or turn on any sprinklers while you are waiting. If you don't plan to leave your home before 7:00 a.m. on the day your street will be surfaced, and you need to use your vehicle later in the day, please park your car on an adjacent street in your neighborhood that is not signed as a no parking zone. When walking to and from your car, remember not to walk on the newly surfaced street or you may have black residue on the bottom of your shoes. The residue may damage some surfaces, may mark surfaces that you track it on, and may be very difficult to remove. (Name of Contractor) is the Contractor that will be performing the resurfacing work for the City and you may call them at (24 hour per day attended telephone number in the 760 area code) for any questions you may have about the project. On the day your street is surfaced mail delivery may be delayed until the next day. You will not know the exact date your street will be closed until you receive the 3 1/2" x 8 1/2" card. If you have a moving company scheduled to come to your house within the next two weeks, please call and inform the Contractor of the date. If you have any concerns which are not addressed by the Contractor, please call the City's Engineering Inspection Department at 602-2780„ They will assist you in resolving the concerns. The City of Carlsbad has some of the finest streets in the county due to the concern and cooperation of citizens like you. Your cooperation is greatly appreciated." ArN UT- Revised 6/15/17 Contract No. 6335 Page 159 of 176 During operations, the Contractor's schedule for resurfacing shall be designed to provide residents and business owners sufficient paved parking within an 800 foot distance from their homes or businesses. Seventy-two hours prior to the start of any construction in the public right-of-way that affects vehicular traffic and/or parking or pedestrian routes, the Contractor shall give written notification of the impending disruption. For a full street closure, all residences and/or businesses on the affected street or alley shall be notified. For partial street closures, or curb, sidewalk and driveway repairs, the residences and/or businesses directly affected by the work shall be notified. The Contractor shall deliver the notification which shall state the date and time the work will begin and its anticipated duration. The notification shall list two telephone numbers that may be called to obtain additional information. One number shall be the Contractor's permanent office or field office and the other number shall be a 24 hour number answered by a representative of the Contractor who is knowledgeable about the project. At least one of the phone numbers shall be in the (760) area code. An answering machine shall not be connected to either number. The notification shall also give a brief description of the work and simple instructions to the home or business owner on what they need to do to facilitate the construction. The Contractor shall submit the contents of the notification to the Engineer for approval. Notices shall not be distributed until approved by the Engineer. For door hangers, the notification shall be pre-cut in a manner that enables it to be affixed to a doorknob without adhesives. It shall be a minimum size of 3-1/2 inches by 8-1/2 inches and shall be brightly colored with contrasting printing. The material shall be equivalent in strength and durability to 65 lb. card stock. The printing on the notice shall be no smaller than 12 point. The precut notices shall be as shown on the example provided in Appendix "A", with the day of the week circled and appropriate information specific to the work inserted at the locations indicated in the italicized font. The preparation, materials, printing and distribution of the notifications shall be included in the contract price bid for Traffic Control and the Contractor will not be entitled to any additional compensation for printing and distributing these notices. 302-5 ASPHALT CONCRETE PAVEMENT. Add the following: 302-5.2 Pavement Transitions. The Contractor shall ramp the approaches and termini to all structures and vertical joints in the cold-milled area which are transverse to through traffic with temporary asphalt concrete pavement as specified in section 306-1.5.1. Ramps shall be constructed the same day as cold milling and removed the same day as permanent paving. Ramp dimensions and compaction shall be as approved by the Engineer. 302-5.5 Distribution and Spreading. Modify as follows: After second sentence of sixth paragraph, add: The Contractor shall provide the spreading and finishing machine used to construct the asphalt concrete surface course with an automatic screed control for surface course paving. The automatic screed control shall be 9 m (30') minimum length. The paving machine shall be operated by an operator and two full-time screed men during all paving. The Contractor shall provide an on-site backup paving during all paving operations. The use of windrow operations shall not be allowed. toil Revised 6/15/17 Contract No. 6335 Page 160 of 176 302-5.6.1 General. Modify as follows: Second paragraph, Part (2), add: Pinched joint rolling procedures shall be required, and vibratory rollers shall be limited to breakdown, unless otherwise directed by the Engineer. Modify as follows: After last paragraph, add: Unless directed otherwise by the Engineer, the initial breakdown rolling shall be followed by a pneumatic-tired roller as described in this section. 302-5.8 Manholes (and other structures). delete the first paragraph and replace with the following: When placing the overlay the Contractor shall pave over appurtenances in the roadway which includes sanitary and storm access covers, water valve boxes, air vents, sewer dead end boxes and survey monument boxes. Each appurtenance shall be treated or covered to prevent adhesion of the overlay. Each appurtenance shall be located immediately after the overlay is placed and shall be thoroughly cleaned of any and all construction debris which may have entered due to the Contractor's operation. The contractor shall adjust all CMWD water valve boxes per CMWD Standard Drawing No. W11 or CMWD Standard Drawing No. W13. All City of Carlsbad sanitary sewer access covers shall be adjusted per CMWD Drawing No. S1. All storm sewer access covers shall be adjusted per SDRSD D-10. Riser rings or extensions shall not be used for the adjustment of these appurtenances. Raising and adjusting to grade all appurtenances in the roadway shall be paid for at the contract unit price per each as shown in the Bid. Such price shall constitute full compensation for all labor, materials, and equipment necessary for completing the work as described in these specifications and plans. 302-5.9 Measurement and Payment. Add the following: Payment for asphalt concrete shall be at the unit price bid per ton. No additional payment shall be made for any tack coat or sand blotter. Add the following section: 302-11 ASPHALT PAVEMENT REPAIRS AND REMEDIATION Add the following section. 302-11.1 General. Asphalt pavement Repairs and Remediation shall consist of the repair and restoration of existing asphalt pavement. Repair of asphalt pavement shall consist of the saw cutting, removal and disposal of existing asphalt pavement in conformance with section 300-1.3, compaction of existing subgrade in conformance with section 301-1, grading and compaction of base material in conformance with section 301-2, application of grade SS-1h emulsified asphalt and the placement of asphalt concrete base and wearing courses as specified herein Add the following section. 302-11.2 Full Depth Asphalt Concrete Patch. Full depth asphalt concrete patch shall consist of removing asphalt concrete and/or aggregate base/subgrade to 300 mm (1') below existing asphalt surface and placing replacing the material so removed with asphalt concrete. The area shown on the plans or set forth in the bid item are for estimating purposes only, final quantity will be as measured in the field. The Engineer will designate and mark the final limits of the asphalt patch area by outlining the area to be patched. The Contractor shall cut such areas to straight lines in square or rectangular areas as marked. The area so cut shall have two of the sides at right angles to the direction of traffic. The excavated faces of the base/subgrade shall be straight and vertical. The Contractor shall compact the upper 300mm (1') of subgrade to 95% relative compaction. A tack coat of SS-1h emulsified asphalt shall be applied uniformly to all asphalt to asphalt contact surfaces at a rate of 0.25 Um2 to 0.45 Um2 (0.05 to 0.10gallons per square yard) in accordance 011, Revised 6/15/17 Contract No. 6335 Page 161 of 176 with subsection 302-5.4, SSPWC. The Contractor shall fill and compact areas designated to be removed with 300 mm (1.0') full depth asphalt concrete. Asphalt concrete for full depth asphalt concrete patch shall be B-AR-4000. The asphalt concrete so constructed shall have a finish surface and density conforming to subsection 302-5.6.2 SSPWC. Add the following section. 302-11.3 Crack Sealing. The Contractor shall wash, blow out and thoroughly dry all cracks designated to be sealed before installing hot poured rubber-asphalt joint sealant material. The sealant shall conform to the requirements of ASTM D1190. The Contractor shall dispose debris from crack cleaning outside the public way in accordance with Section 7-8.1, "Cleanup and Dust Control." The hot-melt rubberized asphalt shall be melted in a jacketed, double boiler type melting unit. Temperature of the heat transfer medium shall not exceed 245°C (475°F). Application of the hot-melt sealant shall be made with a pressure feed applicator or pour pot. Sealant shall be applied when the pavement surface temperature is greater than 4°C (40°F). Containers of hot- melt sealant shall be delivered to the job-site in unopened containers that are clearly marked with data showing the manufacturer's name, the product designation and the manufacturer's batch number and lot numbers. The level of the sealant shall be flush with the surface of the existing pavement. All excess sealant shall be removed from the crack with a minimum overlap onto adjacent pavement. Add the following section: 302-11.4. Measurement and Payment. Quantities of full depth asphalt concrete patch and crack sealing set forth in the bid item are for estimating purposes only, final quantity will be as designated and measured in the field. The Engineer will designate and mark the limits of the Full depth asphalt concrete patch and crack sealant application areas. Payment for resurfacing shall include post emergent herbicide treatment. Full compensation for conforming to the requirements of constructing full depth asphalt concrete patch shall include but not be limited to: furnishing all labor, tools, equipment, and materials necessary for doing the work including, saw cutting and removing and disposing 300 mm (1') thick section of existing asphalt concrete, aggregate base/subbase and basement soil as designated by the engineer, placement of asphalt concrete, compaction of subbase and asphalt concrete, placement of SS-1h asphalt emulsion and all other work incidental to full depth asphalt concrete patch shall be considered as included in the contract unit price bid for full depth asphalt concrete patch and no additional compensation will be allowed therefore. Full compensation for conforming to the requirements of crack sealing shall include but not be limited to, furnishing all labor, materials, tools, equipment, and incidentals necessary to do the work. Crack cleaning, roadway clean up, application of sealant, removal of excess sealant and all other work incidental to crack sealing shall be considered as included in the contract unit price bid and no additional compensation will be allowed therefore. SECTION 303 CONCRETE AND MASONRY CONSTRUCTION. 303-1 CONCRETE STRUCTURES 303-1.6.2 Falsework Design. Add the following: The Contractor shall provide all temporary bracing necessary to withstand all imposed loads during erection, construction, and removal of any falsework. The Contractor shall provide falsework drawings and calculations prepared by a registered professional engineer. riviI or Onintlirat that show provisions for resolution of all logris that may be imposed upon the talsework. Such plans and calculations shall include: •31' tat —T- Revised 6/15/17 Contract No. 6335 Page 162 of 176 1.Resolution of all live, dead, wind, construction and impact loads that may be imposed on the falsework. 2.Temporary bracing or methods to be used during each phase of erection and removal of the falsework. 3.Concrete placement sequence. 4.Erection and removal sequence. 5.Deflection values for the falsework that include recommended methods to compensate for falsework deflections, vertical alignment, and anticipated falsework deflection. Add the following section: 303-1.9.5 Surface Finish for Concrete Spillway. The Contractor shall provide a surface finish for concrete spillway to prevent the use of rollerblades, skateboards, and other rolling devices. Surface finish shall be a rough rake finish approved by the Engineer. 303-2 AIR-PLACED CONCRETE. 303-2.1.1 General. add the following: Modify Regional Standard Drawing D-75 as follows: replace stucco netting with 150mm x 150mm (6" x 6") by No. 10 by No. 10 welded wire mesh. Add the following section: 303-5 CONCRETE CURBS, WALKS, GUTTERS, CROSS GUTTERS, ALLEY INTERSECTIONS, ACCESS RAMPS AND DRIVEWAYS. 303-5.5.2 Curb. Add the following: The Contractor shall stamp the curb face with 75 mm (3") high block letters directly above the point that it is crossed by underground facilities with the marking specified in Table 303-5.5.2(A) TABLE 303-5.5.2(A) Curb Face Markings Type of underground facilities Marking Water Service Lateral Sewer Service Lateral Irrigation Water Lateral or Sleeve RW 303-5.9 Measurement and Payment. Add the following: Curb and gutter, and curb, shall be considered as continuing across driveways and access ramps when constructed adjacent thereto. Neither curb and gutter nor curb will be paid for across the length of local depressions, except that which occurs in gutter transitions at each side of an inlet. 303-5.10 Curb Ramp Construction 303-5.10 Installation. The curb ramp work will conform to the requirements of Section 303-5 of the Green Book as modified herein. The work will consist of the following: a) The Contractor shall be solely responsible for means and methods for laying out and verifying all proposed curb ramps' and appurtenances' grades, including all associated sidewalks, curbs, and gutter plates, in accordance with the standard drawings and as indicated in the construction documents. The final grades for all constructed curb ramps and appurtenances shall not exceed maximum grades indicated in the standard drawings and the construction documents. There shall be no construction tolerances allowed. Any 4111, ta w. Revised 6/15/17 Contract No. 6335 Page 163 of 176 curb ramps or appurtenances constructed in excess of maximum grades as indicated in the aforementioned documents shall be removed and replaced at the Contractor's sole expense. Removal or AC pavement disposal of existing concrete including curb and gutter or portion of spandrel as occurs, and sidewalk necessary to construct the ramp shall be made as straight edges and by the full depth saw cutting only. Removal limits shall be agreed to in writing prior to the saw cutting operation for each ramp location. b) The pedestrian ramps locations and types are shown on the plans. Details for saw cutting existing cross gutter spandrels and replacement of existing AC pavement are shown on the plans. 303-5.10.2 Payment. Payment for construction of curb ramps will be made at the contract unit price per each, and shall include full compensation for furnishing all labor, materials, tools, equipment and incidentals and for doing all work involved in providing and constructing the curb ramps including removal of and construction of curb, curb and gutter, cross gutter spandrel, alley apron, AC pavement and sidewalk, removal of existing ramps and sidewalk associated with ramp construction, and construction of curb, gutter and sidewalks in place, as necessary to achieve ADA compliant grades (regardless of replacement limits shown on plans), construction staking of curb ramps, removal and reconstruction of adjacent improvements including but not limited to private hardscape improvements and landscaping/irrigation improvements, repainting of new curb to match painting of existing curb, if any, prior to ramp construction, and joining work to tie proposed ramp into the adjacent existing PCC (doweling, epoxy, etc.) as shown on plans, complete in place as specified in the special provisions and as directed by the Engineer. The payment for curb ramps shall include the detectable warning strip. Payment for construction of curb ramps shall include full compensation for furnishing all labor, materials, tools, equipment, including but not limited to; saw cutting, removal & disposal of materials, compaction, adjacent asphalt paving and all related incidentals required to complete the work in place. Add the following section: 303-9 TRENCH DRAIN/CURB CHANNEL CONSTRUCTION 303-9.1 General. Trench Drain/ Curb channel work will conform to Section 303-5 of the Green Book and shall be constructed as shown in the plans. The trench drain shall be graded to achieve positive drainage and ensure no water collects within the trench drain area. Steel grating shall be ADA compliant and installed in accordance with manufacturer's recommendation and City Engineer's approval. 303-9.2 Payment. Payment for Trench Drain/Curb Channel construction in accordance with these specifications shall be at the contract unit price for Curb Channel and Metal Grate in the bid schedule. Payment shall include all labor, equipment, and material costs and no additional compensation will be made therefore. te4: Revised 6/15/17 Contract No 6335 Page 164 of 176 SECTION 306 - UNDERGROUND CONDUIT CONSTRUCTION 306-1 OPEN TRENCH OPERATIONS Add the following section: 306-1.1.7 Steel Plate Bridging - With a Non-Skid Surface. This section covers the use of steel plate bridging. The Contractor shall not employ the use or use steel plate bridging or trench plate that does not meet the requirements of this section both in application and circumstance of use. Add the following section: 306-1.1.7.1 Requirements for Use. Alternate construction methods that avoid the use of steel plate bridging shall be used by the Contractor unless otherwise approved by the Engineer. It is recognized that to accommodate excavation work, steel plate bridging may be necessary. All conditions for use of steel plate bridging set forth in the following requirements must be fulfilled as conditions of approval of the use of steel plate bridging. Consideration of steel plate bridging in the review process will take into account the following factors: 1.Traffic volume and composition. 2.Duration of use of the steel plate bridging. 3.Size of the proposed excavation. 4.Weather conditions. The following formula shall be used to score the permitted use of steel plate bridging: PS = [ ADT + EWL + DAYS + 10 X WEEKEND + 5X NIGHTS + 20 X WEATHER + SPEED (kmh) + SLOPE X 1001X LANES 1000 8 PS = [ADT 4 EWL + DAYS + 10 X WEEKEND + 5 X NIGHTS + 20 X WEATHER + SPEED (mph) + SLOPE X 1001X LANES 1000 5 where: PS ADT EWL plate score. average daily traffic as defined in the Federal Highway Administration (FHWA) Manual on Uniform Traffic Control Devices (MUTCD) latest edition as amended by the MUTCD latest edition of the California Supplement. equivalent wheel loads as defined in the Federal Highway Administration (FHWA) Manual on Uniform Traffic Control Devices (MUTCD) latest edition as amended by the MUTCD latest edition of the California Supplement. total number of 24 hour periods during which the plates will be utilized at the site being considered. = total number of Saturdays, Sundays and holidays that the plates will be utilized at the site being considered. = total number of overnight periods that the plates will be in place, exclusive of Saturday, Sunday and holiday nights. total number of 24-hour periods that the plates will be utilized at the site being considered when the possibility of rain exceeds 40 percent. the design speed in kilometers per hour or miles per hour, as applicable in the formulae above, of the street where the plates are to be installed. This number shall not be reduced for construction zone speed reductions. the quotient of the vertical differential divided by the horizontal distance. The vertical and horizontal dimensions shall be measured at the locations spanning DAYS WEEKEND NIGHTS WEATHER SPEED SLOPE 4,11' Revised 6/15/17 Contract No. 6335 Page 165 of 176 a distance of 15 m (50') up and downstream of the position of the proposed steel plate bridging. LANES = the number of lanes where plates will be used. When the computed value of the plate score exceeds 50, steel plate bridging shall not be used unless, and at the sole discretion of the Engineer, the Engineer determines that no alternative method of construction is possible in lieu of using steel plate bridging or that other overriding considerations make the use of steel plate bridging acceptable. Alternatives considered to bridging shall include, but not be limited to, detouring traffic, construction detour routes, tunneling, boring and other methods of trenchless construction. Unless specifically noted in the provisions of the Engineer's approval, the use of steel plate bridging at each location so approved shall not exceed four (4) consecutive working days in any given week. Add the following section: 306-1.1.7.2 Additional Requirements. In all cases when the depth of the trench exceeds the width of the steel plate bridging resting on each side of the pavement adjacent to the trench, safety regulations require or the Engineer determines that shoring is necessary to protect the health or safety of workers or the public the Contractor shall install shoring conforming to Section 7-10.4.1 of the Standard Specifications. The trench shoring shall be designed and installed to support the steel plate bridging and traffic loads. All approvals for design, substitution of materials or methods shall be submitted by the Contractor in accordance with all provisions of section 2- 5.3 Shop Drawings and Submittals. The Contractor shall backfill and resurface excavations in accordance with section 306-1.5. Add the following section: 306-1.1.7.3 Installation. When backfilling operations of an excavation in the traveled way, whether transverse or longitudinal cannot be properly completed within a work day, steel plate bridging with a non-skid surface and shoring may be required to preserve unobstructed traffic flow. In such cases, the following conditions shall apply: a)Steel plate bridging when the plate score exceeds 50 is not allowed except when, at the sole discretion of the Engineer, it is approved as specified hereinbefore. b)Steel plates used for bridging must extend a minimum of 610 mm (2') beyond the edges of the trench. c)Steel plate bridging shall be installed to operate with minimum noise. When the use of steel plate bridging and shoring is approved by the Engineer, the Contractor shall install using either Method (1) or (2) depending on the design speed of the portion of street where the steel plate bridging is proposed for use. Method 1 [For speeds more than 70 Km/hr (45 MPH)]: The pavement shall be cold planed to a depth equal to the thickness of the plate and to a width and length equal to the dimensions of the plate. The cold milling shall produce a flat surface that the plate shall rest on with no horizontal or vertical movement. Horizontal gaps between the unmilled pavement and the plate shall not exceed 25 mm (1") and shall be filled with elastomeric sealant material which may, at the contractor's option, be mixed with no more that 50%, by volume, of Type I aggregate conforming to the requirements of tables 203-5.2(B) and 203-5.3(A). Method 2 [For speeds 70 Km/hr (45 MPH) or less]: Approach plate(s) and ending plate (if longitudinal placement) shall be attached to the roadway and shall be secured against displacement by using two adiustable cleats that are no less than 50 mm (2") shorter than the width of the trench bolted to the underside of each plate and located within 150 mm (6") of the beginning and end of the trench for plates at the beginning and end of the trench, a minimum of two 300 mm long by 19 mm diameter (12" x 3/4") steel bolts placed through the plate and driven TUiV Revised 6/15/17 Contract No 6335 Page 166 of 176 into holes drilled 300 mm (12") into the pavement section, or other devices approved by the Engineer. Subsequent plates shall be butted to each other. Fine graded asphalt concrete shall be compacted to form ramps, maximum slope 8.5% with a minimum 300 mm (12") taper to cover all edges of the steel plates. When steel plates are removed, the dowel holes in the pavement section shall be completely filled with elastomeric sealant material. At the Contractor's option, the methods required for Method 1 may be used. If the Contractor so elects, all requirements of Method 1 shall be used. The Contractor shall maintain the steel plates, shoring, and asphalt concrete ramps and maintain and restore the street surface during and after their use. Add the following section: 306-1.1.7.4 Materials. The minimal thickness of steel plate bridging shall be as shown in Table 306-1.1.7.4(A) TABLE 306-1.1.7.4(A) REQUIRED PLATE THICKNESS FOR A GIVEN TRENCH WIDTH Maximum Trench Width (1) Minimum Plate Thickness 0.3 m (10") 13 mm (1/2") 0.6 m (23") 19 mm (3/4") 0.8 m (31") 22 mm (7/8") 1.0 m (41") 25 mm (1") 1.6 m (63") 32 mm (1 1/4") (1) For spans greater than 1.6 m (5'), a structural design shall be prepared by a registered civil engineer and submitted to the Engineer for review and approval in accordance with section 2-5.3. Steel plate bridging shall be steel plate designed to support the HS20-44 truck loading per CALTRANS Bridge Design Specifications Manual. The Contractor shall maintain a non-skid surface on the steel plate with no less than a coefficient of friction of 0.35 as determined by California Test Method 342. If a different test method is used, the Contractor may utilize standard test plates with known coefficients of friction available from the CALTRANS District 11 Materials Engineer to correlate skid resistance results to California Test Method 342. In addition to all other required construction signing, the Contractor shall install Rough Road (W33) sign with black lettering on an orange background in advance of steel plate bridging. Add the following section: 306-1.1.7.6 Measurement and Payment. Steel plate bridge materials including, but not limited to: steel plates, anchoring devices, cold milling, elastomeric sealant material, asphalt ramping and padding, signage, placing, installation, removal, relocation, preparation and processing of shop drawings and submittals to support the use of steel plate bridging and all other materials, labor, supervision, overhead of any type or description will be paid for as an incidental to the work that the bridging is installed to facilitate. No separate payment for steel plate bridging will be made. No extension to contract time will be allowed for, or because of, the use of steel plate bridging. 306-1.2.1 Bedding. All installation of, and bedding for recycled water, or potable water mains shall conform to Carlsbad Municipal Water District Rules and Regulations for the Construction of (Potable or Reclaimed) Water Mains, latest edition. 306.1.2.2 Pipe Laying. Add the following: The contractor shall coordinate with SDG&E to determine electrical service location. The contractor shall furnish and install electrical pull box, electrical conduit, electrical conduit riser, and conductors per SDG&E requirements. 306-1.2.4 Field Jointing of Reinforced Concrete Pipe. Add the following: The Contractor shall provide Gasket-type joints for reinforced concrete pipe (watertight joints) where indicated on plans. 411111' twit Revised 6/15/17 Contract No. 6335 Page 167 of 176 306-1.3.1 General. Add the following: The Contractor shall install detectable underground utility marking tape 230 mm x75 mm (9" x 3") above each or, in the case of bundled underground conduit of the same type, the upper underground conduit being installed by the open trench method. The type and color of detectable underground utility marking tape shall conform to the requirements of section 207-25 et seq. 306-1.3.4 Compaction Requirements. Delete Section 306-1.3.4 and replace with the following: The Contractor shall densify trench backfill to a minimum of 90 percent relative compaction except that in the top 300 mm (12") of the street right-of-way, compaction shall be 95 percent. 306-1.5 Trench Resurfacing. 306-1.5.1 Temporary Resurfacing. Delete the fourth and fifth paragraphs and substitute the following: Temporary bituminous resurfacing materials which are placed by the Contractor are for its convenience and shall be at no cost to the Agency. Temporary bituminous resurfacing materials shall be used in lieu of permanent resurfacing only when approved by the Engineer. When temporary bituminous resurfacing materials are used in lieu of permanent resurfacing it shall be removed and replaced with permanent resurfacing within 7 days of placement. No additional payment will be made for temporary bituminous resurfacing materials. The price bid for the associated conduit or structure shall include full compensation for furnishing, placing, maintaining, removing, and disposing of such temporary resurfacing materials. 306-1.5.2 Permanent Resurfacing. Add the following: Except as provided in section 306-1.5.1, "Temporary Resurfacing," the Contractor shall perform permanent trench resurfacing within 24 hours after the completion of backfill and densification of backfill and aggregate base materials. 306-1.6 Basis of Payment for Open Trench Installation, add the following: Payment for utilities undergrounding which includes the utility trench for CATV and SDG&E and conduit for SDG&E's electric conversion shall be made on the basis of contract lump sum price for utilities undergrounding and no other payments will be made. Cox Cable will supply and deliver conduits and fittings to be installed by the Contractor. Cox Cable will install enclosures. The Contractor will furnish and install 6.4 mm (%") nylon pull ropes in all conduit. 306-5 ABANDONMENT OF CONDUITS AND STRUCTURES. Add the following: Unless otherwise noted on plans, the Contractor shall remove all existing abandoned pipelines and conduits of any type, or use, and pipelines and conduits of any type, or use, that are abandoned during the course of the work and shall replace said pipelines and conduits with properly compacted soils. Payment for removal and disposal of abandoned utilities shall be included in the lump-sum bid for Clearing and Grubbing, and no additional payment will be made. SECTION 307 - STREET LIGHTING AND TRAFFIC SIGNALS 307 STREET LIGHTING AND TRAFFIC SIGNALS. Modify as follows: Section 86, "Signals, Lighting and Electrical Systems", of the Caltrans Standard Specifications replaces Section 209, "Plectrica1 Components", and Section 1(-17, "Street I iChtinn lrlri Traffic Signals", of the SSPWC, in all matters pertaining to the specifications for measurement, payment, warranty, materials and methods of construction of street lighting and traffic signals. (ply IL" Revised 6/15/17 Contract No. 6335 Page 168 of 176 SECTION 310 - PAINTING 310-5 PAINTING VARIOUS SURFACES. 310-5.6 Painting Traffic Striping, Pavement Markings and Curb Markings. Modify the fifth paragraph as follows: The Contractor shall furnish all equipment, materials, labor, and supervision necessary for painting traffic lanes, directional arrows, guidelines, curbs, parking lines, crosswalks, and other designated markings in accordance with the Plans, or for approved temporary detours essential for safe control of traffic through and around the construction site. The Contractor shall remove by wet grinding all existing or temporary traffic markings and lines that may confuse the public. When temporary detour striping or markings are no longer required, they shall be removed prior to painting the new traffic stripes or markings. 310-5.6.3 Equipment. Delete the ninth paragraph and substitute the following: The Contractor shall provide a wet grinding machine with sufficient capacity to completely remove all existing or temporary traffic striping or markings that conflict with the striping plan, or are contrary to the Traffic Manual, or that may be confusing to the public. The surface produced by grinding the existing or temporary traffic striping or markings on pavement shall not exceed variations from a uniform plane more than 3 mm (10 in 3 m (10') when measured parallel to the centerline of the street or more than 6 mm (1/4") in 3 m (10') when measured perpendicular to the centerline of the street. The use of any equipment that leaves ridges, indentations or other objectionable marks in the pavement shall be discontinued, and equipment capable of providing acceptable surface shall be furnished by the Contractor. This equipment shall meet all requirements of the air pollution control district having jurisdiction. 310-5.6.6 Preparation of Existing Surfaces. Modify the first paragraph as follows: The Contractor shall remove all existing markings and striping, either permanent or temporary, which are to be abandoned, obliterated or that conflict with the plans by wet grinding methods. Removal of striping by high velocity water jet may be permitted when there is neither potential of the water and detritus from the high velocity water jetting to damage vehicles or private property nor to flow from the street into any storm drain or water course and when approved by the Engineer. The Contractor shall vacuum all water and detritus resulting from high velocity water jet striping removal from the pavement immediately after the water jetting and shall not allow such materials to flow in the gutter, enter the storm drain system or to leave the pavement surface. Surface variation limitations for high velocity water jet striping removal shall be the same as for grinding. The Contractor shall not use dry or wet sandblasting in any areas. Alternate methods of paint removal require prior approval of the Engineer. Obliteration of traffic striping with black paint, light emulsion oil or any other masking method other than a minimum 30mm (0.10') thick asphalt concrete overlay is not permitted. 310-5.6.7 Layout, Alignment, and Spotting. Modify the first paragraph as follows: The Contractor shall establish the necessary control points for all required pavement striping and markings by surveying methods. No layout of traffic striping shall be performed by the Contractor before establishment of the necessary control points. The Contractor shall establish all traffic striping between these points by string line or other method to provide striping that will vary less than 80mm per 100m (1/2 inch in 50 feet) from the specified alignment. The Contractor shall obliterate, straight stripes deviating more than 80mm per 100mm (1/ 2 inch in 50 feet) by wet 4.4 Revised 6/15/17 Contract No. 6335 Page 169 of 176 grinding, and then correcting the markings. The Contractor shall lay out (cat track) immediately behind installation of surface course asphalt and as the work progresses. 310-6.6.8 Application of Paint. Modify the second paragraph as follows: The Contractor shall apply the first coat of paint immediately upon approval of striping layout by the Engineer. The Contractor shall paint the ends of each median nose yellow. Add the following to the eighth paragraph: The Contractor shall apply temporary traffic stripes in one coat. Temporary traffic stripes shall be maintained by the Contractor so that the stripes are clearly visible both day and night. 310-5.6.10 Measurement and Payment. Final and temporary traffic striping, curb markings and pavement markings as shown on the plans and required by the specifications shall be included in the lump-sum price bid for temporary and final traffic striping, and no additional compensation will be allowed therefore. Reapplication of temporary stripes and markings shall be repainted at the Contractor's expense, and no additional compensation will be allowed, therefore. The lump sum prices bid and shall include all labor, tools, equipment, materials, and incidentals for doing all work in installing the final and temporary traffic striping. Add the following Section: 310-7 PERMANENT SIGNING Add the following Section: 310-7.1 General. Add the following section: The Contractor shall provide and install all permanent traffic control signs at locations shown on plans and as specified herein. Add the following section: 310-7.2 Measurement And Payment. Permanent signing and appurtenances thereto shown on the plans or required in the specifications are a part of the lump-sum item for permanent signing and payment therefore shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals and for doing all the work involved in supplying and installing permanent signing and appurtenances, complete in place, as shown on the plans, as specified in the Standard Specification and these special provisions, and as directed by the Engineer. SECTION 312 - PAVEMENT MARKER PLACEMENT AND REMOVAL 312-1 PLACEMENT. Add the following to the third paragraph: 4) When being installed on asphalt concrete pavement sooner than 14 days after placement of the asphalt concrete pavement course on which the pavement markers are to be placed. Add the following section: 312-1.1 Reflective Channelizer Placement and Removal. The Contractor shall place and remove reflective channelizers the same as for pavement marker placement and removal. The Contractor shall place the channelizers uniformly, straight on tangent alignment and on a true arc on curved alignment to the same tolerances of position as for application of paint in section 310- 5.6.8. The Contractor shall perform all layout work necessary to place the channelizers to the proper alignment. If the channelizers are displaced or fail to remain in an upright position, from qny r•qirs(4, the channelizers shqll immediately be replaced or restorer! fr the.ir oricirml lorsqtion, by the Contractor. When reflective channelizers are removed the pavement surface shall be restored to the same color and surface finish as the adjacent pavement. —r- Revised 6/15/17 Contract No. 6335 Page 170 of 176 SECTION 313 - TEMPORARY TRAFFIC CONTROL DEVICES Add the following section: 313-1 TEMPORARY TRAFFIC PAVEMENT MARKERS. Add the following section: 313-1.1 General. The Contractor shall supply and install temporary traffic pavement markers, channelizers, signing, railing (type K), crash cushions and appurtenances at the locations shown on the plans and as required in the specifications, complete in place prior to opening the traveled way served by said final and temporary traffic pavement markers, signing, railing (type K) and appurtenances to public traffic. 313-1.2 Temporary Pavement Markers. Temporary reflective raised pavement markers shall be placed in accordance with the manufacturer's instructions. Temporary reflective raised pavement markers shall be cemented to the surfacing with the adhesive recommended by the manufacturer, except epoxy adhesive shall not be used to place temporary reflective raised pavement markers in areas where removal of the markers will be required. Pavement striping, legends and markers which conflict with any traffic pattern shall be removed by grinding as determined by the Engineer. The Contractor shall use temporary reflective raised pavement markers for temporary pavement marking, except when the temporary pavement markers are used to replace patterns of temporary traffic stripe that will be in place for less than 30 days. Reflective pavement markers used in place of the removable-type pavement markers shall conform to the section 312 "Pavement Marker Placement and Removal", except the 14-day waiting period before placing the pavement markers on new asphalt concrete surfacing as specified in section 312-1 "Placement", shall not apply; and epoxy adhesive shall not be used to place pavement markers in areas where removal of the markers will be required. Add the following section: 313-1.3 Channelizers. Channelizers shall be new surface-mounted type and shall be furnished, placed, and maintained at the locations shown on the plans. Channelizer posts shall be orange in color. Channelizers shall have affixed white reflective sheeting as specified in the special provisions. The reflective sheeting shall be 75 mm x 300 mm (3" x 12") in size. The reflective sheeting shall be visible at 300 m (1000') at night under illumination of legal high beam headlights, by persons with vision of or corrected to 20/20. The channelizer bases shall be cemented to the pavement in the same manner as provided for cementing pavement markers to pavement in section 312-1, "Placement." Channelizers shall be applied only on a clean, dry surface. Channelizers shall be placed on the alignment and location shown on the plans and as directed by the Engineer. The channelizers shall be placed uniformly, straight on tangent alignment and on a true arc on curved alignment. All layout work necessary to place the channelizers to the proper alignment shall be performed by the Contractor. If the channelizers are displaced or fail to remain in an upright position, from any cause, the channelizers shall immediately be replaced or restored to their original location, by the Contractor. The Contractor shall provide the Engineer with a Certificate of Compliance in accordance with the provisions of section 4-1.5, "Certification". Said certificate shall certify that the channelizers comply with the plans and specifications and conform to the prequalified design and material requirements approved by the Engineer and were manufactured in accordance with a quality control program approved by the Engineer. OS' t Ur- Revised 6/15/17 Contract No. 6335 Page 171 of 176 Add the following section: 313-2 TEMPORARY TRAFFIC SIGNING. Add the following section: 313-2.1 General. The Contractor shall provide and install all temporary traffic control signs, markers, markings, and delineators at locations shown on plans and specified herein. Add the following section: 313-2.2 Maintenance of Temporary Traffic Signs. If temporary traffic signs are displaced or overturned, from any cause, during the progress of the work, the Contractor shall immediately replace the signs in their original approved locations. The Contractor shall maintain all temporary traffic signs used in the Work in a clean, reflective and readable condition. The Contractor shall replace or restore graffiti marked temporary traffic signs and posts used in the Work within 18 hours of such marking being discovered during non-working hours or, when the marking is discovered during working hours, within 2 hours of such discovery of marking. Add the following section: 313-3 TEMPORARY RAILING (TYPE K) AND CRASH CUSHIONS. Add the following section: 313-3.1 Temporary Railing and Crash Cushions. Temporary railing (Type K) shall consist of interconnected new or undamaged used precast concrete barrier units as shown on the plans. Temporary sand-filled crash cushions shall consist of new or undamaged used temporary sand- filled crash cushions units as shown on the plans. 313-3.1.1 Appearance. Exposed surfaces of new and used units of Temporary railing (Type K) shall be freshly coated with a white color paint prior to their first use on the project. The paint shall conform to the provisions in sections 210-1.5 "Paint Systems" and 310 "Painting". Contractor shall be responsible for the removal and cleanup or painting over the graffiti from the K-Rails within 48 hours. The Contractor Shall replace or repaint units of Temporary railing (Type K) or shall remove graffiti, tire or vehicle marks, dirt or any and all materials such that said marks or discoloration mar the appearance of said units when ordered by the Engineer after the units are in place. Add the following section. 313-3.1.2 Manufacture of Temporary Railing. In addition to the requirements herein the temporary railing (Type K) shall be manufactured per CALTRANS Standard Drawing T3. Concrete used to manufacture Temporary railing (Type K) shall conform to the provisions in sections 201-1, "Portland Cement Concrete" and 303-1 "Concrete Structures"." Load tickets and a Certificate of Compliance will not be required. Reinforcing steel shall conform to the provisions sections 201-1, "Portland Cement Concrete" and 303-1 "Concrete Structures". Steel bars to receive bolts at ends of concrete panels shall conform to ASTM Designation: A 36/A 36M. The bolts shall conform to ASTM Designation: A 307. A round bar of the same diameter may be substituted for the end-connecting bolt shown on the plans. The bar shall conform to ASTM Desig- nation: A 36/A 36M, shall have a minimum length of 660 mm and shall have a 75 mm (3") diameter by 9 mm (3/8") thick plate welded on the upper end with a 5-mm (3/16") fillet weld. The final surface finish of temporary railings (Type K) shall conform to the provisions in section 303-1.9.2 "Ordinary Surface Finish." Exposed surfaces of concrete elements shall be cured by the water method, the forms-in-place method, or the pigmented curing compound method. The pigmented curing compound shall be type 2 curing compound. Temporary railing (Type K) may have the Contractor's name or logo on each panel. The name or logo shall not be more than 100 mm in height and shall be located not more than 300 mm above the bottom of the rail panel. 411S, tar. —1- Revised 6/15/17 Contract No. 6335 Page 172 of 176 Add the following section. 313-3.1.3 Installation of Temporary Railing. In addition to the requirements herein the temporary railing (Type K) shall be installed per CALTRANS Standard Drawing T3. Temporary railing (Type K) shall be set on firm, stable foundation. The foundation shall be graded to provide a uniform bearing throughout the entire length of the railing. Abutting ends of precast concrete units shall be placed and maintained in alignment without substantial offset to each other. The precast concrete units shall be positioned straight on tangent alignment and on a true arc on curved alignment Each rail unit placed within 3 m (10') of a traffic lane shall have a reflector installed on top of the rail as directed by the Engineer. Reflectors and adhesive will be furnished by the Contractor. A Type P marker panel conforming to the requirements of the Federal Highway Administration (FHWA) Manual on Uniform Traffic Control Devices (MUTCD) latest edition as amended by the MUTCD latest edition of the California Supplement shall also be installed at each end of railing installed adjacent to a two-lane, two-way highway and at the end facing traffic of railing installed adjacent to a one-way roadbed. If the railing is placed on a skew, the marker shall be installed at the end of the skew nearest the traveled way. Type P marker panels shall conform to the provisions of section 206-7.2, "Temporary Traffic Signs". Where shown on the plans, threaded rods or dowels shall be bonded in holes drilled in existing concrete. When temporary railings (Type K) are removed, any area where temporary excavation or embankment was used to accommodate the temporary railing shall be restored to its previous condition or constructed to its planned condition. Add the following section: 313-3.2 Temporary Sand-Filled Crash Cushions. Temporary sand-filled crash cushion units shall be "Energite III" manufactured by Energy Absorption Systems, "Fitch Inertial Barrier System Modules" manufactured by Roadway Safety Service, or equal. Features required to determine equivalence of any other temporary sand-filled crash cushion units shall be approval of the system by CALTRANS and that the temporary sand-filled crash cushion units meet NCHRP 350 standards. Other features will be suitability to application, operational characteristics, durability and other such characteristics that the Engineer shall determine. Temporary sand-filled crash cushions (TSFCC) shall be of the type and array configurations shown on plans, and installed at every end of, or gap in, the temporary railing (Type K) whenever the closest point of approach of traffic, regardless of direction, is 4.6 m (15') or less to the end of the temporary railing (Type K) being considered. The TSFCC shall be installed per CALTRANS Standard Drawings T1 and T2 for approach speeds no less than the posted speed of the street prior to construction or 55 kilometers per hour (35 mph), whichever is the greater. The TSFCC array shall be appropriate to the application as shown on said standard drawings. A Type J and/or P marker panel conforming to the requirements of the Federal Highway Administration (FHWA) Manual on Uniform Traffic Control Devices (MUTCD) latest edition as amended by the MUTCD latest edition of the California Supplement shall also be installed at each TSFCC array as shown in CALTRANS Standard Drawings T1 and T2. Particular care shall be taken to assure that crash cushions are installed with the soil supporting them and the adjacent soil leveled to match the elevation of the bottom of the temporary railing immediately adjacent to the crash cushion. All routes of approach to the TSCFF array shall be graded such that any vehicle diverging from the travelled way to strike the TSCFF will travel on a vertical alignment parallel to the segment of the travel lane that it departed from. Add the following section: 313-4 MEASUREMENT AND PAYMENT. Temporary traffic pavement markers, temporary channelizers, temporary signing, temporary railing (type K), temporary crash cushions and temporary appurtenances thereto shown on the plans or required in the specifications are a part 41k, Revised 6/15/17 Contract No. 6335 Page 173 of 176 of the lump-sum item for traffic control and payment therefore shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals and for doing all the work involved in applying, installing, maintaining, and removing temporary traffic pavement markers, channelizers, signing, railing (type K), crash cushions and appurtenances, complete in place, as shown on the plans, as specified in the Standard Specification and these special provisions, and as directed by the Engineer. Payment for temporary crash cushions, concrete barriers and the signs and reflectors marking them shall include the installation, grading for installation, grading for the approach path, maintenance, painting and re-painting, replacement of damaged units and removal and shall also be included in the lump-sum price bid for traffic control. Payment for installation and/or relocation of K-rails and crash cushions when not shown on the plans and requested by the Engineer shall be made per section 3-3, Extra Work, SSPWC. /‘' Revised 6/15/17 Contract No. 6335 Page 174 of 176 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 6, MODIFIED ASPHALTS, PAVEMENTS AND PROCESSES 600-3 RUBBERIZED EMULSION - AGGREGATE SLURRY. 600-3.2 Materials add the following: Aggregate for Rubberized Emulsion - Aggregate Slurry shall be Type I Slurry Aggregate. 600-3.4 Application of REAS Add to the first paragraphs: No slurry shall be applied until the provisions of subsection 212-1.2.6, Herbicide Application, Section 302-11 Asphalt Concrete Pavement Crack Filling and Sealing, Section 312-3 Pavement Marker Removal have all been satisfied. The Contractor shall remove all existing markings, legends and striping, either permanent or temporary in those areas to be slurried. Removal of striping by high velocity water jet may be permitted when there is neither potential of the water and detritus from the high velocity water jetting to damage vehicles or private property nor to flow from the street into any storm drain or water course and when approved by the Engineer. The Contractor shall vacuum all water and detritus resulting from high velocity water jet striping removal from the pavement immediately after the water jetting and shall not allow such materials to flow in the gutter, enter the storm drain system or to leave the pavement surface. Surface variation limitations for high velocity water jet striping removal shall be the same as for grinding. The Contractor shall not use dry or wet sandblasting in any areas. All cracks and areas between existing curb and gutter and edge of pavement that contain weeds or plant growth of any kind shall be treated with herbicides. Herbicides shall be applied at least 2(two) working days prior to sealing of street. Allowance for the two day period shall be shown in the schedule required per section 6-1. Contractor shall remove any visible plant growth prior to placement of Herbicide. Full compensation for removal of striping and herbicide application shall include but not be limited to: furnishing all labor, tools, equipment, and materials necessary for doing the work and shall be considered as included in the contract unit price bid for Rubberized Emulsion Aggregate Slurry and no additional compensation will be allowed therefore. 600-3.6 Public Convenience and Traffic Control Modify the first line with the following: Public Convenience and traffic control shall conform to 302-4.4.4. There shall be no stockpiling of material allowed on City right-of-way. 111, t olv Revised 6/15/17 Contract No. 6335 Page 175 of 176 CITY OF CARLSBAD ROAD WORK ABC CONTRACTORS OFFICE # (760)XXX-XXXX FIELD # (760)XXX0000C Dear resident: As a part of the City of Carlsbad's ongoing program to maintain its streets, your street will be resurfaced with asphalt concrete over the existing roadway surface. This construction will require the closing of your street to.through traffic for one day. Your street, from XYZ St. to DEF Ave. will be closed to through traffic and resurfaced on: MON. TUE. WED. THU. FRI. DATE: XX/XX/XX from 7:00A.M. to 5:00 P.M. If you don't plan to leave your home by 7:00 A.M. on the above date please park your car on an adjacent street in your neighborhood that will not be resurfaced. Streets scheduled for resurfacing can be determined by calling either the Contractor or the City of Carlsbad's Project Inspector. When walking to and from your car, remember not to walk on the newly overlaid street or you will have black residue on the bottom of your shoes. Please do not drive, walk on, walk pets, play, or skate on the newly overlaid asphalt. Also, please refrain from watering your lawns, washing cars, etc., approximately 6-8 hours after the asphalt is laid as running water will cause damage to the new surface. ABC is the Contractor that will be performing the resurfacing work for the city and you may call them at the above phone number if you have any questions regarding the project. Resurfacing of your street will not occur on the day your trash is collected. Mail delivery may be delayed if the postman cannot reach the mailbox that day. If you have a moving company scheduled for that day please call and inform the Contractor of the date. If you have any concerns which cannot be addressed by the Contractor, you may call the City's Project Inspector @ (xxx) xxx-xxxx. Thank you for your cooperation as we work to make a better City of Carlsbad. APPENDIX "A" t all- Revised 6/15/17 Contract No. 6335 Page 176 of 176