HomeMy WebLinkAbout2022-12-06; City Council; Resolution 2022-270RESOLUTION NO. 2022-270
A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF CARLSBAD,
CALIFORNIA, AUTHORIZING THE CITY MANAGER TO EXECUTE A
SUPPLEMENTAL TERMS AND CONDITIONS AGREEMENT WITH EC AMERICA,
INC. FOR IMPLEMENTATION, LICENSING AND SUBSCRIPTION SERVICES FOR
PROCORE PROJECT MANAGEMENT PRO SOFTWARE IN AN AMOUNT NOT TO
EXCEED $119,687.95 FOR THE INITIAL TERM AND AUTHORIZING THE CITY
MANAGER TO EXECUTE EXTENSIONS AND AMENDMENTS OVER $100,000
ANNUALLY, IF APPROPRIATE, FOR A TOTAL ESTIMATED AGREEMENT
AMOUNT OF $566,080 PLUS A $10,000 CONTINGENCY FOR UNEXPECTED
IMPLEMENTATION COSTS
WHEREAS, the City Council of the City of Carlsbad, California has determined that the most
effective way to operate and support the City of Carlsbad's project management requirements is with
Procore Project Management Pro Software; and
WHEREAS, the City of Carlsbad currently does not have a project management solution in place
and Procore Project Management Pro Software will be the solution chosen from a citywide
requirement gathering process; and
WHEREAS, EC America, Inc. provides implementation, licensing and subscription services for
Procore Project Management Pro Software under the California Multiple Award Schedules (CMAS)
Agreement CMAS No. 3-18-70-1448C contract; and
WHEREAS, under Carlsbad Municipal Code 3.28.100 -Cooperative Purchasing, the Purchasing
Officer has the authority to join with other public agencies for the purchase of goods or services when
it is in the best interest of the city; and
WHEREAS, in order for the City of Carlsbad to use Procore Project Management Pro Software
EC America will provide implementation, licensing and subscription services for the PM solution; and
WHEREAS, the city manager will have the authority to execute the supplemental terms and
conditions agreement with EC America for implementation, licensing and subscription services of
Proco re Project Management Pro Software and, if appropriate, to execute extensions and amendments
to the agreement over $100,000 annually for four one-year terms, for a total estimated agreement
amount of $566,080 plus a $10,000 contingency; and
WHEREAS, EC America will provide implementation, licensing and subscription services of
Procore Project Management Pro Software; and
WHEREAS, funding is available in the Strategic Digital Transformation Investment Program
{SDTIP) to fund this project and initial services; and
WHEREAS, if the EC America agreement is extended for Years 2 through 5 the Information
Technology Department's Annual Operating Budget will need to be increased starting in Fiscal Year
2023-24 for the annual on-going licensing and subscription cost.
NOW, THEREFORE, BE IT RESOLVED by the City Council of the City of Carlsbad, California, as
follows:
1.
2.
That the above recitations are true and correct.
That the supplemental terms and conditions agreement for implementation, licensing
and subscription services of Procore Project Management Pro Software with EC America
(Attachment A) is approved and the city manager is authorized to execute all required
documents on behalf of the city including possible extension and amendments over
$100,000 for four one-year terms, if appropriate, for a total estimated agreement
amount of $566,080 plus a $10,000 contingency.
3.That the total for the implementation, licensing and subscription services with EC
America, Inc. shall not exceed $119,687.95 for the initial term ending one year from the
date the agreement is signed.
4.That the funding for the agreement is budgeted in the fiscal year 2022-23 SDTIP Project
Portfolio Management Tool and Consulting.
5.That the extension of the agreement for Years 2 through 5 for the annual licensing and
subscription services are subject to the approval of corresponding increases to the
Information Technology Department's Annual Operating Budget.
PASSED, APPROVED AND ADOPTED at a Regular Meeting of the City Council of the City of
Carlsbad on the 6th day of December, 2022, by the following vote, to wit:
AYES:
NAYS:
ABSENT:
Blackburn, Bhat-Patel, Acosta, Norby.
None.
Hall.
fv
for
MATT HALL, Mayor
FAVIOLA MEDINA, City Clerk Services Manager
{SEAL)
l
DocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C78232724 Attachment A
SUPPLEMENTAL TERMS & CONDITIONS to the CALIFORNIA MULTIPLE AWARD SCHEDULE (CMAS) CONTRACT #3-18-70-1448C
These Supplemental Terms and Conditions to the CMAS Contract #3-18-70-1448C, ("Agreement") dated as of thisll-1'--'day of t>(..(.wbf,y2022 is between EC America, Inc., having its
principal office and place of business at 8444 Westpark Drive, Ste. 200, McLean, VA 22102, ("Contractor") and CITY OF CARLSBAD, a municipal corporation ("City"). The City is undertaking certain activities related to acquiring Information Technology Products, Solutions and Services and
the City desires to engage the Contractor to provide work in connection with such undertakings of the City.
RECITALS
A.City requires information technology goods and professional services of aninformation technology firm that is experienced in information technology solutions.
B.Contractor has the necessary experience in providing professional services andadvice related to information technology solutions.
C.Contractor has submitted a proposal to City and has affirmed its willingness and abilityto perform such work.
D.Contractor was awarded the attached CMAS #3-18-70-1448C, signed and dated bythe State of California, pursuant to a competitive solicitation process (CMAS Contract). The CMAS Contract has been in effect since October 3, 2018.
Now, therefore, in consideration recitals and the mutual covenants contained herein, the City and Contractor agree as follows:
Unless expressly amended and/or superseded, the terms and conditions of this Agreement shall include, and expressly incorporate, all the terms and conditions of the CMAS Contract.
The parties agree that, to the extent the terms in this Agreement contradict or are in any way inconsistent with any term in the CMAS Contract, the terms in this Agreement shall prevail.
The following terms of the CMAS Contract are specifically modified solely for the purposes of this Agreement:
1.scopE OF WORKCity retains Contractor to perform, and Contractor agrees to render those services that are defined in attached Exhibit "A," Scope of Work (Services), , which is incorporated by this reference in accordance with this Agreement's terms and conditions. To the extent any of the terms in any exhibit or attachment to this Agreement conflict, in whole or part, with the terms of this Agreement, the terms of this Agreement shall prevail.
2.STANDARD OF PERFORMANCEWhile performing the Services, Contractor will exercise the reasonable professional care and skill
customarily exercised by reputable members of Contractor's profession practicing in the
DocuSign Envelope ID: 655A9EA1-DD18-408F-BE56-459C78232724
Metropolitan Southern California Area, and will use reasonable diligence and best judgment while exercising its professional skill and expertise.
3.TERMThe term of this Agreement will be effective for a period of one (1) year from the date first above written.The City Manager may amend the Agreement to extend it for four (4) additional one (1) year periodsor parts thereof. Extensions will be based upon a satisfactory review of Contractor's performance, Cityneeds, and appropriation of funds by the City Council.
4.JIME IS OF THE ESSENCETime is of the essence for each and every provision of this Agreement.
s.COMPENSATIONThe total fee payable for the Services to be performed during the initial Agreement term will be onehundred nineteen thousand six hundred eighty-seven dollars and ninety-five cents ($119,687.95).
No other compensation for the Services will be allowed except for items covered by subsequent
amendments to this Agreement. Fees for subsequent renewal terms will be based on Contractor'sthen-current pricing and the City's estimated number of projects annually and approved by both
parties.
s.STATUS OF CONTRACTORContractor will perform the Services in Contractor's own way as an independent contractor and inpursuit of Contractor's independent calling, and not as an employee of City. Contractor will be under
control of City only as to the result to be accomplished, but will consult with City as necessary. The
persons used by Contractor to provide services under this Agreement will not be considered
employees of City for any purposes.
The payment made to Contractor pursuant to the Agreement will be the full and complete
compensation to which Contractor is entitled. City will not make any federal or state tax withholdings on behalf of Contractor or its agents, employees or subcontractors. City will not be required to pay any workers' compensation insurance or unemployment contributions on behalf of Contractor or its
employees or subcontractors. Contractor agrees to indemnify City within thirty (30) days for any tax,
retirement contribution, social security, overtime payment, unemployment payment or workers' compensation payment which City may be required to make on behalf of Contractor or any agent, employee, or subcontractor of Contractor for work done under this Agreement. At the City's election,
City may deduct the indemnification amount from any balance owing to Contractor.
1.SUBCONTRACTINGAll Services performed under this Agreement will be performed by Contractor or its authorizedsubcontractors who have been identified to City and approved by City in advance, such approval not
to be unreasonably withheld. Notwithstanding any delegation of Services, Contractor will remain
primarily responsible for the performance of the Services. Nothing contained in this Agreement will
create any contractual relationship between any subcontractor of Contractor and City. Contractor
will be responsible for payment of subcontractors. Contractor will bind every subcontractor and every
subcontractor of a subcontractor by the terms of this Agreement applicable to Contractor's work
unless specifically noted to the contrary in the subcontract and approved in writing by City.
DocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
a.OTHER CONTRACTORSThe City reserves the right to employ other Contractors in connection with the Services.
9.INDEMNIFICATIONContractor agrees to provide indemnification to the City under the same terms and conditions specified in the CMAS Contract's General Provisions -Information Technology, including Paragraph 7, "Compliance with Statutes and Regulations"; Paragraph 26, "Limitation of Liability"; Paragraph 27, "Contractor's Liability for Injury to Persons or Damage to Property"; Paragraph 28, "Indemnification"; and Paragraph 43, "Patent, Copyright and Trade Secret Indemnity" as well as the CMAS Contract's State Model Cloud Computer Services Special Provisions, including Paragraph 7, "Compliance with Statutes and Regulations"; Paragraph 20 "Limitation of Liability"; Paragraph 21, "Indemnification"; and Paragraph 34, "Patent, Copyright and Trade Secret Indemnity." Exhibit "B". Any references to the State in these paragraphs shall be construed to be the City and any reference to State Department of General Services or State Department of Technology officers and employees shall be construed to be the City Manager or a designee.
The parties expressly agree that any payment, attorney's fee, costs or expense City incurs or makes to or on behalf of an injured employee under the City's self-administered workers' compensation is included as a loss, expense or cost for the purposes of this section, and that this section will survive the expiration or early termination of this Agreement
10.NOTICESThe name of the persons who are authorized to give written notice or to receive written notice on behalf of City and on behalf of Contractor under this Agreement.
For City
Name
Title
Maria Callander
IT Director
Department IT
City of Carlsbad
Address 1635 Faraday Ave
Carlsbad, CA 92008
Phone No. 442.339.2454
For Contractor
Name Tyler Waldrep
Title Sales Operations Manager
Address 8444 Westpark Drive, Suite 200
McLean, VA 22102
Phone No. 770-625-7632
Email tyler.waldrep@immixgroup.com
Each party will notify the other immediately of any changes of address that would require any notice or delivery to be directed to another address.
11.CONFLICT Of INTERESTContractor shall file a Conflict of Interest Statement with the City Clerk in accordance with the requirements of the City of Carlsbad Conflict of Interest Code. The Contractor shall report investments or interests in all categories.
Yes DNo 1:81
12.GENERAL COMPLIANCE WITH LAWSContractor will keep fully informed of federal, state and local laws and ordinances and regulations
DocuSign Envelope ID: 655A9EA1-DD18-408F-BE56-459C78232724
which in any manner affect those employed by Contractor, or in any way affect the performance of
the Services by Contractor. Contractor will at all times observe and comply with these laws,
ordinances, and regulations and will be responsible for the compliance of Contractor's services with
all applicable laws, ordinances and regulations.
Contractor will be aware of the requirements of the Immigration Reform and Control Act of 1986 and will comply with those requirements, including, but not limited to, verifying the eligibility for
employment of all agents, employees, subcontractors and consultants whose services are required
by this Agreement.
13.DISCRIMINATION AND HARASSMENT PROHIBITED
Contractor will comply with all applicable local, state and federal laws and regulations prohibiting
discrimination, harassment, retaliation or other unlawful employment practice.
14.TERMINATIONRESERVED.
15.COVENANTS AGAINST CONTINGENT FEESContractor warrants that Contractor has not employed or retained any company or person, other
than a bona fide employee working for Contractor, to solicit or secure this Agreement, and that
Contractor has not paid or agreed to pay any company or person, other than a bona fide employee,any fee, commission, percentage, brokerage fee, gift, or any other consideration contingent upon, or
resulting from, the award or making of this Agreement. For breach or violation of this warranty, City
will have the right to annul this Agreement without liability, or, in its discretion, to deduct from the
Agreement price or consideration, or otherwise recover, the full amount of the fee, commission,
percentage, brokerage fees, gift, or contingent fee.
1s. CLAIMS AND LAWSUITS By signing this Agreement, Contractor agrees that any Agreement claim submitted to City must be
asserted as part of the Agreement process as set forth in this Agreement and not in anticipation of
litigation or in conjunction with litigation. Contractor acknowledges that if a false claim is submitted to City, it may be considered fraud and Contractor may be subject to criminal prosecution. Contractor
acknowledges that California Government Code sections 12650 et seq., the False Claims Act
applies to this Agreement and, provides for civil penalties where a person knowingly submits a false claim to a public entity. These provisions include false claims made with deliberate ignorance of the
false information or in reckless disregard of the truth or falsity of information. If City seeks to recover penalties pursuant to the False Claims Act, it is entitled to recover its litigation costs, including
attorney's fees. Contractor acknowledges that the filing of a false claim may subject Contractor to
an administrative debarment proceeding as the result of which Contractor may be prevented to act as a Contractor on any public work or improvement for a period of up to five (5) years. Contractor
acknowledges debarment by another jurisdiction is grounds for City to terminate this Agreement.
11.JURISDICTION AND VENUEAny action at law or in equity brought by either of the parties for the purpose of enforcing a right or
rights provided for by this Agreement will be tried in a court of competent jurisdiction in the Countyof San Diego, State of California, and the parties waive all provisions of law providing for a change
of venue in these proceedings to any other county.
DocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
1 s. SUCCESSORS AND ASSIGNS It is mutua lly understood and agreed that this Agreement will be binding upon City and Contracto r and
their respect ive successors. Neither this Agreement nor any part of it nor any monies due or to
become due under it may be assigned by Contractor without the prio r consent of City, which shall
not be unreasonab ly withheld.
19.INSURANCE
Contractor will obtain and maintain for the duration of the Agreement and any and all amendments,
insurance against claims for injuries to persons or damage to property which may arise out of or in
connection with performance of the services by Contractor or Contractor's agents, representatives,
employees or subcontractors. The insurance will be obtained from an insurance carrie r admitted and
authorized to do business in the State of California. The insurance carrier is required to have a current
Best's Key Rating of not less than "A-:VII"; OR with a surplus line insurer on the State of California's
List of Approved Surplus Line Insurers (LASLI) with a rating in the latest Best's Key Rating Guide of
at least "A:X"; OR an alien non-adm itted insurer listed by the National Association of Insurance
Commissioners (NAIC) latest quarterly listings report.
•Coverage and Limits.
Contractor will maintain the types of coverage and minimum limits indicated below, unless the Risk
Manager or City Manager approves a lower amount. These minimum amounts of coverage will not
constitute any limitations or cap on Contractor's indemnification obligations under this Agreement.
City, its officers, agents and employees make no representation that the limits of the insurance
specified to be carried by Contractor pursuant to this Agreement are adequate to protect Contractor.
If Contractor believes that any required insurance coverage is inadequate, Contractor will obtain
such additional insurance coverage, as Contractor deems adequate, at Contractor's sole expense.
The full limits available to the named insured shall also be available and applicable to the City as an
additional insured.
•Commercial General Liability (CGL) Insurance. Insurance written on an "occurrence" basis,
including personal & advertising injury, with limits no less than $1,000,000 per occurrence. If a
general aggregate limit applies, either the general aggregate limit shall apply separately to this
project/location or the general aggregate limit shall be twice the required occurrence limit.
•Automobile Liability. (if the use of an automobile is involved for Contractor's work for City).
$1,000,000 combined single-limit per accident for bodily injury and property damage.
•Workers' Compensation and Employer's Liability. Workers' Compensation limits as required by
the California Labor Code. Workers' Compensation will not be required if Contractor has no
employees and provides, to City's satisfaction, a declaration stating this.
•Professional Liability. Errors and omissions liability appropriate to Contractor's profession with
limits of not less than $1,000,000 per claim. Coverage must be maintained for a period of five
years following the date of completion of the work.
• Additional Provisions. Contractor will ensure that the policies of insurance required under this
Agreement contain, or are endorsed to contain, the following provisions:
DocuSign Envelope ID: 655A9EA1-DD18-408F-BE56-459C7B232724
•The City will be named as an additional insured on Commercial General Liability which shall
provide primary coverage to the City.
•Contractor will obtain occurrence coverage, excluding Professional Liability, which will be
written as claims-made coverage.
•This insurance will be in force during the life of the Agreement and any extensions of it and
will not be canceled without thirty (30) days prior written notice to City sent by certified mail
pursuant to the Notice provisions of this Agreement.
Providing Certificates of Insurance and Endorsements. Prior to City's execution of this Agreement,
Contractor will furnish certificates of insurance and endorsements to City.
Failure to Maintain Coverage. If Contractor fails to maintain any of these insurance coverages, then City will have the option to declare Contractor in breach, or may purchase replacement insurance or
pay the premiums that are due on existing policies in order to maintain the required coverages.
Contractor is responsible for any payments made by City to obtain or maintain insurance and City may collect these payments from Contractor or deduct the amount paid from any sums due
Contractor under this Agreement.
Submission of Insurance Policies. City reserves the right to require, at any time, complete and certified copies of any or all required insurance policies and endorsements.
20.BUSINESS LICENSEContractor will obtain and maintain a City of Carlsbad Business License for the term of theAgreement, as may be amended from time-to-time.
21.ENTIRE AGREEMENTThis Agreement, together with any other written document referred to or contemplated by it, alongwith the purchase order for this Agreement and its provisions, embody the entire Agreement and
understanding between the parties relating to the subject matter of it. In case of conflict, the terms of
the Agreement supersede the purchase order. Neither this Agreement nor any of its provisions maybe amended, modified, waived or discharged except in a writing signed by both parties.
Ill
Ill
Ill
Ill
Ill
Ill
Ill
DocuSign Envelope ID: 655A9EA1-DD18-408F-BE56-459C78232724
22.AUTHORITYThe individuals executing this Agreement and the instruments referenced in it on behalf ofContractor each represent and warrant that they have the legal power, right and actual authority tobind Contractor to the terms and conditions of this Agreement
IN WITNESS HEREOF, THE PARTIES HERETO HAVE CAUSED THIS SUPPLEMENT TO THE CMAS CONTRACT TO BE EXECUTED AND INSTITUTED ON THE DATE FIRST ABOVE WRITTEN.
CONTRACTOR
By: tAA\cU'.'11. ffu (sign here)
Tamara Ells VP
(print name/title)
By:
� f11i tKf %gn here)
Jeffrey Ellinport
CIT. 0 CARLSBAD, a municipal
co orati n of the State of California
By:
City Manager
ATTEST:
J6t0 f FAVIOLA MEDINA
VP Lega 1 corp. sec _City Clerk Services Manager ---------------(print name/title)
APPROVED AS TO FORM:
Cindie McMahon, City Attorney
BY: {jv.,J_,i� k.. �"
City Attorney
EXHIBIT “A” - SCOPE OF WORK
•Quote Number: QUO-1333721-Q2V4C9
•Contracting vehicle: CMAS Contract
•Term length: 12 months
•ACV Cap (MM): $40M
•Project Cap: 80
•List of Services Included:
o Unlimited customer support, unlimited user licensing, unlimited storage in the cloud,dedicated implementation manager
•Total Cost to City: $119,687.95
Item Part
Number
Contract Trans
Type Product Description Qty Price Extended
Price
1 1410-6 3-18-70-1448C SUB Project Management Pro: provides Project Overview, Documentation, and Communication Management tools, including Directory, Reports, Documents, Drawings, Photos, RFIs, Specifications, Submittals, and Punchlist. Pricing is maximum price for ACV from $25M -** TRUSTED PRODUCT **
1 $42,716.04 $42,716.04
2 1480-6 3-18-70-1448C SUB Quality & Safety: provides Quality & Safety tools, including Incidents, Inspections, and Observations. Pricing is maximum price for ACV from $25M - $50M.** TRUSTED PRODUCT **
1 $13,509.32 $13,509.32
3 1430-6 3-18-70-1448C SUB Project Financials: provides Financial Management tools, including Direct Costs, Change Events, Commitments, Change Orders, Prime Contract, and Budget. Pricing is maximum price for ACV from $25M - $50M.** TRUSTED PRODUCT **
1 $17,859.82 $17,859.82
4 1600-6 3-18-70-1448C SUB Invoice Management: provides invoice management tools, including Owner and Subcontractor invoices. Pricing is maximum price for ACV from $25M - $50M.** TRUSTED PRODUCT **
1 $5,197.06 $5,197.06
5 1660-03 3-18-70-1448C SUB Procore Analytics Single Daily: export Procore product data into a hosted SQL database and apply Analytics tools on 100+ ready made reports and dashboard to derive insights. Pricing is maximum price for ACV from $25M - $50M.** TRUSTED PRODUCT **
1 $8,163.63 $8,163.63
6 PRO-2800 3-18-70-1448C XAAS Custom Statements of Work: One hour of custom bundle of services based on business needs. May include any of the above service types. If additional services not listed are needed, these requests will be evaluated on a case by case basis for feasibility. M**
TRUSTED PRODUCT **
156 $206.68 $32.242.08
SUBSCRIPTION
$87,445.87
SERVICES $32,242.08
Grand Total
$119,687.95
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5
QuickStart 4
Services Included:
Implementation Manager Services. Up to 35 hours of Implementation Manager Services for 16 weeks, ensuring a consistent point of contact to drive implementation success metrics throughout the implementation. Includes weekly scheduled consultations and project administration.
Onsite Training. Up to 2 days of onsite training, up to 8 hours per day, to increase adoption and accelerate time value.
Consulting Services. 15 hours of additional 1:1 virtual Consulting services to assist with strategic business planning, education, deep product training, Procore rollout, and best practices for additional users.
Custom Solutions. 25 hours with Contractor Custom Solution experts to design and
implement custom forms, custom workflows, and custom tools.
Add-On Services. Services in addition to those included in this service package, such as an extension of Implementation Manager services beyond (16) weeks, additional Consulting Services and Customer solutionhours, or Training and Integration Services, are available uponrequest for a fee and are not included in this scope.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 1 OF 61
1. DEFINITIONS: Unless otherwise specified in the Statement of Work the following terms shall be given the meaning shown, unless context requires otherwise.
a) "Acceptance Tests" means those tests performed during the Performance Period which are
intended to determine compliance of Equipment and Software with the specifications and all other Attachments incorporated herein by reference and to determine the reliability of the Equipment. b) "Application Program" means a computer program which is intended to be executed for the purpose of performing useful work for the user of the information being processed. Application
programs are developed or otherwise acquired by the user of the Hardware/Software system, but they may be supplied by the Contractor. c) "Attachment" means a mechanical, electrical, or electronic interconnection to the Contractor- supplied Machine or System of Equipment, manufactured by other than the original Equipment manufacturer, that is not connected by the Contractor.
d) “Business entity” means any individual, business, partnership, joint venture, corporation, S- corporation, limited liability company, sole proprietorship, joint stock company, consortium, or other private legal entity recognized by statute. e) “Buyer” means the State’s authorized contracting official. f) “Commercial Hardware” means Hardware developed or regularly used that: (i) has been
sold, leased, or licensed to the general public; (ii) has been offered for sale, lease, or license to the general public; (iii) has not been offered, sold, leased, or licensed to the public but will be available for commercial sale, lease, or license in time to satisfy the delivery requirements of this Contract; or (iv) satisfies criterion expressed in (i), (ii), or (iii) above and would require only minor modifications to meet the requirements of this Contract.
g) “Commercial Software” means Software developed or regularly used that: (i) has been sold, leased, or licensed to the general public; (ii) has been offered for sale, lease, or license to the general public; (iii) has not been offered, sold, leased, or licensed to the public but will be available for commercial sale, lease, or license in time to satisfy the delivery requirements of this Contract; or (iv) satisfies a criterion expressed in (i), (ii), or (iii) above and would require
only minor modifications to meet the requirements of this Contract. h) “Contract” means this Contract or agreement (including any purchase order), by whatever name known or in whatever format used. i) “Custom Software” means Software that does not meet the definition of Commercial Software.
j) “Contractor” means the Business Entity with whom the State enters into this Contract. Contractor shall be synonymous with “supplier”, “vendor” or other similar term. k) "Data Processing Subsystem" means a complement of Contractor-furnished individual Machines, including the necessary controlling elements (or the functional equivalent), Operating Software and Software, if any, which are acquired to operate as an integrated
group, and which are interconnected entirely by Contractor- supplied power and/or signal cables; e.g., direct access controller and drives, a cluster of terminals with their controller, etc. l) "Data Processing System (System)" means the total complement of Contractor-furnished Machines, including one or more central processors (or instruction processors), Operating Software which are acquired to operate as an integrated group.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 18 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 2 OF 61
m) “Deliverables” means Goods, Software, Information Technology, telecommunications technology, Hardware, and other items (e.g. reports) to be delivered pursuant to this Contract, including any such items furnished incident to the provision of services. n) "Designated CPU(s)" means for each product, if applicable, the central processing unit of the
computers or the server unit, including any associated peripheral units. If no specific “Designated CPU(s)” are specified on the Contract, the term shall mean any and all CPUs located at the site specified therein. o) "Documentation" means manuals and other printed materials necessary or useful to the State in its use or maintenance of the Equipment or Software provided hereunder. Manuals
and other printed materials customized for the State hereunder constitute Work Product if such materials are required by the Statement of Work. p) "Equipment" is an all-inclusive term which refers either to individual Machines or to a complete Data Processing System or subsystem, including its Hardware and Operating Software (if any).
q) "Equipment Failure" is a malfunction in the Equipment, excluding all external factors, which prevents the accomplishment of the Equipment’s intended function(s). If microcode or Operating Software residing in the Equipment is necessary for the proper operation of the Equipment, a failure of such microcode or Operating Software which prevents the accomplishment of the Equipment’s intended functions shall be deemed to be an Equipment
Failure. r) "Facility Readiness Date" means the date specified in the Statement of Work by which the State must have the site prepared and available for Equipment delivery and installation. s) “Goods” means all types of tangible personal property, including but not limited to materials, supplies, and Equipment (including computer and telecommunications Equipment).
t) "Hardware" usually refers to computer Equipment and is contrasted with Software. See also Equipment. u) "Installation Date" means the date specified in the Statement of Work by which the Contractor must have the ordered Equipment ready (certified) for use by the State. v) "Information Technology" includes, but is not limited to, all electronic technology systems
and services, automated information handling, System design and analysis, conversion of data, computer programming, information storage and retrieval, telecommunications which include voice, video, and data communications, requisite System controls, simulation, electronic commerce, and all related interactions between people and Machines. w) "Machine" means an individual unit of a Data Processing System or subsystem, separately
identified by a type and/or model number, comprised of but not limited to mechanical, electro- mechanical, and electronic parts, microcode, and special features installed thereon and including any necessary Software, e.g., central processing unit, memory module, tape unit, card reader, etc. x) "Machine Alteration" means any change to a Contractor-supplied Machine which is not made
by the Contractor, and which results in the Machine deviating from its physical, mechanical, electrical, or electronic (including microcode) design, whether or not additional devices or parts are employed in making such change. y) "Maintenance Diagnostic Routines" means the diagnostic programs customarily used by the Contractor to test Equipment for proper functioning and reliability.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 19 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 3 OF 61
z) “Manufacturing Materials” means parts, tools, dies, jigs, fixtures, plans, drawings, and information produced or acquired, or rights acquired, specifically to fulfill obligations set forth herein. aa)"Mean Time Between Failure (MTBF)” means the average expected or observed time
between consecutive failures in a System or component. bb)"Mean Time to Repair (MTTR)" means the average expected or observed time required to repair a System or component and return it to normal operation. cc) "Operating Software" means those routines, whether or not identified as Program Products, that reside in the Equipment and are required for the Equipment to perform its intended
function(s), and which interface the operator, other Contractor-supplied programs, and user programs to the Equipment. dd)"Operational Use Time" means for performance measurement purposes, that time during which Equipment is in actual operation by the State. For maintenance Operational Use Time purposes, that time during which Equipment is in actual operation and is not synonymous with
power on time. ee)"Period of Maintenance Coverage" means the period of time, as selected by the State, during which maintenance services are provided by the Contractor for a fixed monthly charge, as opposed to an hourly charge for services rendered. The Period of Maintenance Coverage consists of the Principal Period of Maintenance and any additional hours of coverage per day,
and/or increased coverage for weekends and holidays. ff) "Preventive Maintenance" means that maintenance, performed on a scheduled basis by the Contractor, which is designed to keep the Equipment in proper operating condition. gg)"Principal Period of Maintenance" means any nine consecutive hours per day (usually between the hours of 7:00 a.m. and 6:00 p.m.) as selected by the State, including an official
meal period not to exceed one hour, Monday through Friday, excluding holidays observed at the installation. hh)"Programming Aids" means Contractor- supplied programs and routines executable on the Contractor’s Equipment which assists a programmer in the development of applications including language processors, sorts, communications modules, data base management
systems, and utility routines, (tape-to-disk routines, disk-to-print routines, etc.). ii) "Program Product" means programs, routines, subroutines, and related items which are proprietary to the Contractor and which are licensed to the State for its use, usually on the basis of separately stated charges and appropriate contractual provisions. jj) "Remedial Maintenance" means that maintenance performed by the Contractor which results
from Equipment (including Operating Software) failure, and which is performed as required, i.e., on an unscheduled basis. kk) "Software" means an all-inclusive term which refers to any computer programs, routines, or subroutines supplied by the Contractor, including Operating Software, Programming Aids, Application Programs, and Program Products.
ll) "Software Failure” means a malfunction in the Contractor-supplied Software, other than Operating Software, which prevents the accomplishment of work, even though the Equipment (including its Operating Software) may still be capable of operating properly. For Operating Software failure, see definition of Equipment Failure.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 20 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 4 OF 61
mm) "State” means the government of the State of California, its employees and authorized representatives, including without limitation any department, agency, or other unit of the government of the State of California. nn)"System" means the complete collection of Hardware, Software and services as described in
this Contract, integrated and functioning together, and performing in accordance with this Contract. oo)“U.S. Intellectual Property Rights” means intellectual property rights enforceable in the United States of America, including without limitation rights in trade secrets, copyrights, and U.S. patents.
2. CONTRACT FORMATION: If this Contract results from a Letter of Offer, then Contractor’s offer is deemed a firm offer and this Contract document is the State's acceptance of that offer.
3. COMPLETE INTEGRATION:
This Contract, including any documents incorporated herein by express reference, is intended to
be a complete integration and there are no prior or contemporaneous different or additional agreements pertaining to the subject matter of the Contract.
4. SEVERABILITY: The Contractor and the State agree that if any provision of this Contract is found to be illegal or unenforceable, such term or provision shall be deemed stricken and the remainder of the Contract
shall remain in full force and effect. Either party having knowledge of such term or provision shall promptly inform the other of the presumed non-applicability of such provision.
5. INDEPENDENT CONTRACTOR: Contractor and the agents and employees of Contractor, in the performance of this Contract, shall act in an independent capacity and not as officers or employees or agents of the State.
6. APPLICABLE LAW: This Contract shall be governed by and shall be interpreted in accordance with the laws of the State of California; venue of any action brought with regard to this Contract shall be in Sacramento County, Sacramento, California. The United Nations Convention on Contracts for the International Sale of Goods shall not apply to this Contract.
7. COMPLIANCE WITH STATUTES AND REGULATIONS: a) The State and the Contractor warrants and certifies that in the performance of this Contract, it will comply with all applicable statutes, rules, regulations and orders of the United States and the State of California. The Contractor agrees to indemnify the State against any loss, cost, damage or liability by reason of the Contractor’s violation of this provision.
b) The State will notify Contractor of any such claim in writing and tender the defense thereof within a reasonable time; and
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 21 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 5 OF 61
c) The Contractor will have sole control of the defense of any action on such claim and all negotiations for its settlement or compromise; provided that (i) when substantial principles of government or public law are involved, when litigation might create precedent affecting future State operations or liability, or when involvement of the State is otherwise mandated by law,
the State may participate in such action at its own expense with respect to attorneys’ fees and costs (but not liability); (ii) where a settlement would impose liability on the State, affect principles of California government or public law, or impact the authority of the State, the Department of General Services will have the right to approve or disapprove any settlement or compromise, which approval will not unreasonably be withheld or delayed; and (iii) the State
will reasonably cooperate in the defense and in any related settlement negotiations. d) If this Contract is in excess of $554,000, it is subject to the requirements of the World Trade Organization (WTO) Government Procurement Agreement (GPA). e) To the extent that this Contract falls within the scope of Government Code Section 11135, Contractor hereby agrees to respond to and resolve any complaint brought to its attention,
regarding accessibility of its products or services.
8. CONTRACTOR’S POWER AND AUTHORITY: The Contractor warrants that it has full power and authority to grant the rights herein granted and will hold the State harmless from and against any loss, cost, liability, and expense (including
reasonable attorney fees) arising out of any breach of this warranty.
Further, Contractor avers that it will not enter into any arrangement with any third party which might abridge any rights of the State under this Contract.
a) The State will notify Contractor of any such claim in writing and tender the defense thereof within a reasonable time; and
b) The Contractor will have sole control of the defense of any action on such claim and all
negotiations for its settlement or compromise; provided that (i) when substantial principles of government or public law are involved, when litigation might create precedent affecting future State operations or liability, or when involvement of the State is otherwise mandated by law, the State may participate in such action at its own expense with respect to attorneys’ fees and
costs (but not liability); (ii) where a settlement would impose liability on the State, affect
principles of California government or public law, or impact the authority of the State, the Department of General Services will have the right to approve or disapprove any settlement or compromise, which approval will not unreasonably be withheld or delayed; and (iii) the State will reasonably cooperate in the defense and in any related settlement negotiations.
9. CMAS - ASSIGNMENT:
a) This Contract shall not be assignable by the Contractor in whole or in part without the written consent of the State. The State’s consent shall not be unreasonably withheld or delayed. For the purpose of this paragraph, State will not unreasonably prohibit Contractor from freely assigning its right to payment, provided that Contractor remains responsible for its obligations hereunder.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 22 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 OF 61
b)Should the State desire financing of the assets provided hereunder through the Golden StateFinancial Marketplace, the Contractor agrees to assign to a State-designated lender its right toreceive payment from the State for the assets in exchange for payment by the lender of thecash purchase price for the assets. Upon notice to do so from the State-designated lender at
any time prior to payment by the State for the assets, the Contractor will execute and deliver tothe State-designated lender an assignment agreement and any additional documentsnecessary for the State selected financing plan. The State-designated lender will pay theContractor according to the terms of the Contractor’s invoice upon acceptance of the assets bythe State.
10. WAIVER OF RIGHTS:Any action or inaction by the State or the failure of the State on any occasion, to enforce any rightor provision of the Contract, shall not be construed to be a waiver by the State of its rightshereunder and shall not prevent the State from enforcing such provision or right on any future
occasion. The rights and remedies of the State herein are cumulative and are in addition to any
other rights or remedies that the State may have at law or in equity.
11. CMAS - ORDER OF PRECEDENCE:In the event of any inconsistency between the articles, attachments, specifications or provisionswhich constitute this Contract, the following order of precedence shall apply:
a)These General Provisions – Information Technology (In the instances provided herein where
the paragraph begins: “Unless otherwise specified in the Statement of Work” provisionsspecified in the Statement of Work replacing these paragraphs shall take precedence over theparagraph referenced in these General Provisions);b)Contract form, i.e., Purchase Order STD 65, FiSCal contract/order, and any amendments
thereto;
c)Other Special Provisions;d)Federal GSA (or other multiple award contract) terms and conditions;e)Statement of work, including any specifications incorporated by reference herein; andf)All other attachments incorporated in the Contract by reference.
12. PACKING AND SHIPMENT:
a)All Goods are to be packed in suitable containers for protection in shipment and storage, andin accordance with applicable specifications. Each container of a multiple container shipmentshall be identified to:i.show the number of the container and the total number of containers in the shipment; andii.the number of the container in which the packing sheet has been enclosed.
b)All shipments by Contractor or its subcontractors must include packing sheets identifying: theState’s Contract number; item number; quantity and unit of measure; part number anddescription of the Goods shipped; and appropriate evidence of inspection, if required. Goodsfor different Contracts shall be listed on separate packing sheets.c)Shipments must be made as specified in this Contract, as it may be amended, or otherwise
directed in writing by the State’s Transportation Management Unit within the Department ofGeneral Services, Procurement Division.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Page 23 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 7 OF 61
13. TRANSPORTATION COSTS AND OTHER FEES OR EXPENSES: No charge for delivery, drayage, express, parcel post, packing, cartage, insurance, license fees, permits, cost of bonds, or for any other purpose will be paid by the State unless expressly included and itemized in the Contract.
a) The Contractor must strictly follow Contract requirements regarding Free on Board (F.O.B.), freight terms and routing instructions. The State may permit use of an alternate carrier at no additional cost to the State with advance written authorization of the Buyer. b) If “prepay and add” is selected, supporting freight bills are required when over $50, unless an exact freight charge is approved by the Transportation Management Unit within the
Department of General Services Procurement Division and a waiver is granted. c) On "F.O.B. Shipping Point" transactions, should any shipments under the Contract be received by the State in a damaged condition and any related freight loss and damage claims filed against the carrier or carriers be wholly or partially declined by the carrier or carriers with the inference that damage was the result of the act of the shipper such as inadequate packaging
or loading or some inherent defect in the Equipment and/or material, Contractor, on request of the State, shall at Contractor's own expense assist the State in establishing carrier liability by supplying evidence that the Equipment and/or material was properly constructed, manufactured, packaged, and secured to withstand normal transportation conditions. 14. DELIVERY:
The Contractor shall strictly adhere to the delivery and completion schedules specified in this Contract. Time, if stated as a number of days, shall mean calendar days unless otherwise specified. The quantities specified herein are the only quantities required. If the Contractor delivers in excess of the quantities specified herein, the State shall not be required to make any
payment for the excess Deliverables and may return them to Contractor at Contractor’s expense
or utilize any other rights available to the State at law or in equity.
15. SUBSTITUTIONS: Substitution of Deliverables may not be tendered without advance written consent of the Buyer. Contractor shall not use any specification in lieu of those contained in the Contract without written
consent of the Buyer.
16. INSPECTION, ACCEPTANCE AND REJECTION: Unless otherwise specified in the Statement of Work:
a) When acquiring Commercial Hardware or Commercial Software, the State shall rely on Contractor’s existing quality assurance system as a substitute for State inspection and testing. For all other acquisitions, Contractor and its subcontractors will provide and maintain a quality
assurance system acceptable to the State covering Deliverables and services under this Contract and will tender to the State only those Deliverables that have been inspected and found to conform to this Contract’s requirements. The Contractor will keep records evidencing inspections and their result, and will make these records available to the State during Contract performance and for three years after final payment. The Contractor shall permit the State to
review procedures, practices, processes, and related documents to determine the acceptability of Contractor’s quality assurance System or other similar business practices related to performance of the Contract.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 24 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 8 OF 61
b) All Deliverables may be subject to inspection and test by the State or its authorized representatives. c) The Contractor and its subcontractors shall provide all reasonable facilities for the safety and convenience of inspectors at no additional cost to the State. The Contractor shall furnish to
inspectors all information and data as may be reasonably required to perform their inspection. d) Subject to subsection 16 (a) above, all Deliverables may be subject to final inspection, test and acceptance by the State at destination, notwithstanding any payment or inspection at source. e) The State shall give written notice of rejection of Deliverables delivered or services performed hereunder within a reasonable time after receipt of such Deliverables or performance of such
services. Such notice of rejection will state the respects in which the Deliverables do not substantially conform to their specifications. If the State does not provide such notice of rejection within 15 days of delivery for purchases of Commercial Hardware or Commercial Software or 30 days of delivery for all other purchases, such Deliverables and services will be deemed to have been accepted. Acceptance by the State will be final and irreversible, except
as it relates to latent defects, fraud, and gross mistakes amounting to fraud. Acceptance shall not be construed to waive any warranty rights that the State might have at law or by express reservation in this Contract with respect to any nonconformity.
17. SAMPLES: a) Samples of items may be required by the State for inspection and specification testing and
must be furnished free of expense to the State. The samples furnished must be identical in all respects to the products offered and/or specified in the Contract. b) Samples, if not destroyed by tests, may, upon request made at the time the sample is furnished, be returned at Contractor’s expense.
18. CMAS - WARRANTY:
The following warranty language is in addition to the warranty language provided in the federal GSA Multiple Award Schedule or other base Contract used to establish this CMAS Contract. When there is a conflict between the language, the following warranty language overrides.
a) Unless otherwise specified in the Statement of Work, the warranties in this subsection a) begin
upon delivery of the goods or services in question and end 1 year thereafter. The Contractor
warrants that (i) Deliverables and services furnished hereunder will substantially conform to the requirements of this Contract (including without limitation all descriptions, specifications, and drawings identified in the Statement of Work), and (ii) the Deliverables will be free from material defects in materials and workmanship. Where the parties have agreed to design
specifications (such as a Detailed Design Document) and incorporated the same or equivalent
in the Statement of Work directly or by reference, the Contractor will warrant that its Deliverables provide all material functionality required thereby. In addition to the other warranties set forth herein, where the Contract calls for delivery of Commercial Software, the Contractor warrants that such Software will perform in accordance with its license and
accompanying Documentation. The State’s approval of designs or specifications furnished by
Contractor shall not relieve the Contractor of its obligations under this warranty.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 25 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 9 OF 61
b) The Contractor warrants that Deliverables furnished hereunder (i) will be free, at the time of delivery, of harmful code (i.e. computer viruses, worms, trap doors, time bombs, disabling code, or any similar malicious mechanism designed to interfere with the intended operation of, or cause damage to, computers, data, or Software); and (ii) will not infringe or violate any U.S.
Intellectual Property Right. Without limiting the generality of the foregoing, if the State believes that harmful code may be present in any Commercial Software delivered hereunder, the Contractor will, upon the State’s request, provide a new or clean install of the Software. c) Unless otherwise specified in the Statement of Work: i. The Contractor does not warrant that any Software provided hereunder is error-free or that
it will run without immaterial interruption. ii. The Contractor does not warrant and will have no responsibility for a claim to the extent that it arises directly from (A) a modification made by the State, unless such modification is approved or directed by the Contractor, (B) use of Software in combination with or on products other than as specified by Contractor, or (C) misuse by the State.
iii. Where the Contractor resells Commercial Hardware or Commercial Software it purchased from a third party, Contractor, to the extent it is legally able to do so, will pass through an such third-party warranties to the State and will reasonably cooperate in enforcing them. Such warranty pass- through will not relieve the Contractor from Contractor’s warranty obligations set forth above.
d) All warranties, including special warranties specified elsewhere herein, shall inure to the State, its successors, assigns, customer agencies, and governmental users of the Deliverables or services. e) Except as may be specifically provided in the Statement of Work or elsewhere in this Contract, for any breach of the warranties provided in this Section, the State’s exclusive remedy and
Contractor’s sole obligation will be limited to: i. re-performance, repair, or replacement of the nonconforming Deliverable (including without limitation an infringing Deliverable) or service; or ii. should the State in its sole discretion consent, refund of all amounts paid by the State for the nonconforming Deliverable or service and payment to the State of any additional
amounts necessary to equal the State’s Cost to Cover. “Cost to Cover” means the cost, properly mitigated, of procuring Deliverables or services of equivalent capability, function, and performance. The payment obligation in subsection e)(ii) above will not exceed the limits on Contractor’s liability set forth in the Section entitled “Limitation of Liability.” f) EXCEPT FOR THE EXPRESS WARRANTIES SPECIFIED IN THIS SECTION,
CONTRACTOR MAKES NO WARRANTIES EITHER EXPRESS OR IMPLIED, INCLUDING WITHOUT LIMITATION ANY IMPLIED WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE.
19. SAFETY AND ACCIDENT PREVENTION:
In performing work under this Contract on State premises, the Contractor shall conform to any
specific safety requirements contained in the Contract or as required by law or regulation. The Contractor shall take any additional precautions as the State may reasonably require for safety and accident prevention purposes. Any violation of such rules and requirements, unless promptly corrected, shall be grounds for termination of this Contract in accordance with the default
provisions hereof.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 26 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 10 OF 61
20. INSURANCE:The Contractor shall maintain all commercial general liability insurance, workers’ compensationinsurance and any other insurance required under the Contract. The Contractor shall furnishinsurance certificate(s) evidencing required insurance coverage acceptable to the State, including
endorsements showing the State as an “additional insured” if required under Contract. Anyrequired endorsements requested by the State must be separately provided; merely referring tosuch coverage on the certificate(s) is insufficient for this purpose. When performing work on stateowned or controlled property, Contractor shall provide a waiver of subrogation in favor of the Statefor its workers’ compensation policy.
21. TERMINATION FOR NON- APPROPRIATION OF FUNDS:a)If the term of this Contract extends into fiscal years subsequent to that in which it is approved,such continuation of the Contract is contingent on the appropriation of funds for such purposeby the Legislature. If funds to effect such continued payment are not appropriated, the
Contractor agrees to take back any affected Deliverables furnished under this Contract,
terminate any services supplied to the State under this Contract, and relieve the State of anyfurther obligation therefor.b)The State agrees that if it appears likely that subsection a) above will be invoked, the Stateand Contractor shall agree to take all reasonable steps to prioritize work and Deliverables and
minimize the incurrence of costs prior to the expiration of funding for this Contract.
c)THE STATE AGREES THAT IF PARAGRAPH a) ABOVE IS INVOKED, COMMERCIALHARDWARE AND SOFTWARE THAT HAS NOT BEEN PAID FOR, SHALL BE RETURNEDTO THE CONTRACTOR IN SUBSTANTIALLY THE SAME CONDITION IN WHICHDELIVERED TO THE STATE, SUBJECT TO NORMAL WEAR AND TEAR. THE STATE
FURTHER AGREES TO PAY FOR PACKING, CRATING, TRANSPORTATION TO
CONTRACTOR’S NEAREST FACILITY AND FOR REIMBURSEMENT TO THECONTRACTOR FOR EXPENSES INCURRED FOR THEIR ASSISTANCE IN SUCHPACKING AND CRATING.
22. TERMINATION FOR THE CONVENIENCE OF THE STATE:
a)The State may terminate performance of work under this Contract for its convenience in whole
or, from time to time, in part, if the Department of General Services, Deputy DirectorProcurement Division, or designee, determines that a termination is in the State’s interest. TheDepartment of General Services, Deputy Director, Procurement Division, or designee, shallterminate by delivering to the Contractor a Notice of Termination specifying the extent of
termination and the effective date thereof.
b)After receipt of a Notice of Termination, and except as directed by the State, the Contractorshall immediately proceed with the following obligations, as applicable, regardless of any delayin determining or adjusting any amounts due under this clause. The Contractor shall:i.Stop work as specified in the Notice of Termination.
ii.Place no further subcontracts for materials, services, or facilities, except as necessary to
complete the continuing portion of the Contract.iii.Terminate all subcontracts to the extent they relate to the work terminated.iv.Settle all outstanding liabilities and termination settlement proposals arising from thetermination of subcontracts;
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 27 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 11 OF 61
c) After termination, the Contractor shall submit a final termination settlement proposal to the State in the form and with the information prescribed by the State. The Contractor shall submit the proposal promptly, but no later than 90 days after the effective date of termination, unless a different time is provided in the Statement of Work or in the Notice of Termination.
d) The Contractor and the State may agree upon the whole or any part of the amount to be paid as requested under subsection (c) above. e) Unless otherwise set forth in the Statement of Work, if the Contractor and the State fail to agree on the amount to be paid because of the termination for convenience, the State will pay the Contractor the following amounts; provided that in no event will total payments exceed the
amount payable to the Contractor if the Contract had been fully performed: i. The Contract price for Deliverables or services accepted or retained by the State and not previously paid for, adjusted for any savings on freight and other charges; and ii. The total of: A) The reasonable costs incurred in the performance of the work terminated, including
initial costs and preparatory expenses allocable thereto, but excluding any cost attributable to Deliverables or services paid or to be paid; B) The reasonable cost of settling and paying termination settlement proposals under terminated subcontracts that are properly chargeable to the terminated portion of the Contract; and
C) Reasonable storage, transportation, demobilization, unamortized overhead and capital costs, and other costs reasonably incurred by the Contractor in winding down and terminating its work. f) The Contractor will use generally accepted accounting principles, or accounting principles otherwise agreed to in writing by the parties, and sound business practices in determining all
costs claimed, agreed to, or determined under this clause.
23. TERMINATION FOR DEFAULT: a) The State may, subject to the clause titled “Force Majeure” and to subsection d) below, by written notice of default to the Contractor, terminate this Contract in whole or in part if the
Contractor fails to:
i. Deliver the Deliverables or perform the services within the time specified in the Contract or any amendment thereto; ii. Make progress, so that the lack of progress endangers performance of this Contract; or iii. Perform any of the other provisions of this Contract.
b) The State’s right to terminate this Contract under subsection a) above, may be exercised only
if the failure constitutes a material breach of this Contract and if the Contractor does not cure such failure within the time frame stated in the State’s cure notice, which in no event will be less than 15 days, unless the Statement of Work calls for a different period. c) If the State terminates this Contract in whole or in part pursuant to this Section, it may acquire,
under terms and in the manner the Buyer considers appropriate, Deliverables or services
similar to those terminated, and the Contractor will be liable to the State for any excess costs for those Deliverables and services, including without limitation costs third party vendors charge for Manufacturing Materials (but subject to the clause entitled “Limitation of Liability”). However, the Contractor shall continue the work not terminated.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 28 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 12 OF 61
d) If the Contract is terminated for default, the State may require the Contractor to transfer title, or in the case of licensed Software, license, and deliver to the State, as directed by the Buyer, any: i. completed Deliverables,
ii. partially completed Deliverables, and, iii. subject to provisions of subsection e) below, Manufacturing Materials related to the terminated portion of this Contract. Nothing in this subsection d) will be construed to grant the State rights to Deliverables that it would not have received had this Contract been fully performed. Upon direction of the Buyer, the Contractor shall also protect and preserve
property in its possession in which the State has an interest. e) The State shall pay Contract price for completed Deliverables delivered and accepted and items the State requires the Contractor to transfer under section (d) above. Unless the Statement of Work calls for different procedures or requires no- charge delivery of materials, the Contractor and Buyer shall attempt to agree on the amount of payment for Manufacturing
Materials and other materials delivered and accepted by the State for the protection and preservation of the property; provided that where the Contractor has billed the State for any such materials, no additional charge will apply. Failure to agree will constitute a dispute under the Disputes clause. The State may withhold from these amounts any sum it determines to be necessary to protect the State against loss because of outstanding liens or claims of former
lien holders. f) If, after termination, it is determined by a final decision that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the State. g) Both parties, State and Contractor, upon any termination for default, have a duty to mitigate
the damages suffered by it. h) The rights and remedies of the State in this clause are in addition to any other rights and remedies provided by law or under this Contract, and are subject to the clause titled “Limitation of Liability.” 24. FORCE MAJEURE:
Except for defaults of subcontractors at any tier, the Contractor shall not be liable for any excess costs if the failure to perform the Contract arises from causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include, but are not limited to:
a) Acts of God or of the public enemy, and
b) Acts of the federal or State government in either its sovereign or contractual capacity.
If the failure to perform is caused by the default of a subcontractor at any tier, and if the cause of the default is beyond the control of both the Contractor and subcontractor, and without the fault or negligence of either, the Contractor shall not be liable for any excess costs for failure to perform.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 29 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 13 OF 61
25. RIGHTS AND REMEDIES OF STATE FOR DEFAULT: a) In the event any Deliverables furnished or services provided by the Contractor in the performance of the Contract should fail to conform to the requirements herein, or to the sample submitted by the Contractor, the State may reject the same, and it shall become the duty of the
Contractor to reclaim and remove the item promptly or to correct the performance of services, without expense to the State, and immediately replace all such rejected items with others conforming to the Contract. b) In addition to any other rights and remedies the State may have, the State may require the Contractor, at Contractor’s expense, to ship Deliverables via air freight or expedited routing to
avoid or minimize actual or potential delay if the delay is the fault of the Contractor. c) In the event of the termination of the Contract, either in whole or in part, by reason of default or breach by the Contractor, any loss or damage sustained by the State in procuring any items which the Contractor agreed to supply shall be borne and paid for by the Contractor (but subject to the clause entitled “Limitation of Liability”).
d) The State reserves the right to offset the reasonable cost of all damages caused to the State against any outstanding invoices or amounts owed to Contractor or to make a claim against the Contractor therefore.
26. LIMITATION OF LIABILITY: a) Except as may be otherwise approved by the Department of General Services Deputy
Director, Procurement Division or their designee, Contractor’s liability for damages to the State for any cause whatsoever, and regardless of the form of action, whether in Contract or in tort, shall be limited to the Purchase Price. For purposes of this subsection a), “Purchase Price” will mean the aggregate Contract price; except that, with respect to a Contract under which
multiple purchase orders will be issued (e.g., a Master Agreement or Multiple Award Schedule
Contract), “Purchase Price” will mean the total price of the purchase order for the Deliverable(s) or service(s) that gave rise to the loss, such that Contractor will have a separate limitation of liability for each purchase order. b) The foregoing limitation of liability shall not apply (i) to any liability under the General
Provisions entitled “Compliance with Statutes and Regulations”; (ii) to liability under the
General Provisions entitled “Patent, Copyright, and Trade Secret Indemnity” or to any other liability (including without limitation indemnification obligations) for infringement of third party intellectual property rights; (iii) to claims arising under provisions herein calling for indemnification for third party claims against the State for death, bodily injury to persons or
damage to real or tangible personal property caused by Contractor’s negligence or willful
misconduct; or (iv) to costs or attorney’s fees that the State becomes entitled to recover as a prevailing party in any action. c) The State’s liability for damages for any cause whatsoever, and regardless of the form of action, whether in Contract or in tort, shall be limited to the Purchase Price, as that term is
defined in subsection a) above. Nothing herein shall be construed to waive or limit the State’s
sovereign immunity or any other immunity from suit provided by law.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 30 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 14 OF 61
d) In no event will either the Contractor or the State be liable for consequential, incidental, indirect, special, or punitive damages, even if notification has been given as to the possibility of such damages, except (i) to the extent that Contractor’s liability for such damages is specifically set forth in the Statement of Work or (ii) to the extent that Contractor’s liability for
such damages arises out of subsection b)(i), b)(ii), or b)(iv) above.
27. CONTRACTOR’S LIABILITY FOR INJURY TO PERSONS OR DAMAGE TO PROPERTY: a) The Contractor shall be liable for damages arising out of injury to the person and/or damage to the property of the State, employees of the State, persons designated by the State for training, or any other person(s) other than agents or employees of the Contractor, designated by the
State for any purpose, prior to, during, or subsequent to delivery, installation, acceptance, and use of the Deliverables either at the Contractor’s site or at the State’s place of business, provided that the injury or damage was caused by the fault or negligence of the Contractor. b) The Contractor shall not be liable for damages arising out of or caused by an alteration or an Attachment not made or installed by the Contractor, or for damage to alterations or
Attachments that may result from the normal operation and maintenance of the Deliverables provided by the Contractor during the Contract.
28. INDEMNIFICATION: The Contractor agrees to indemnify, defend and save harmless the State, its officers, agents and employees from any and all third party claims, costs (including without limitation reasonable
attorneys’ fees), and losses due to the injury or death of any individual, or the loss or damage to any real or tangible personal property, resulting from the willful misconduct or negligent acts or omissions of the Contractor or any of its affiliates, agents, subcontractors, employees, suppliers, or laborers furnishing or supplying work, services, materials, or supplies in connection with the performance of this Contract. Such defense and payment will be conditional upon the following:
a) The State will notify the Contractor of any such claim in writing and tender the defense thereof within a reasonable time; and b) The Contractor will have sole control of the defense of any action on such claim and all negotiations for its settlement or compromise; provided that (i) when substantial principles of government or public law are involved, when litigation might create precedent affecting future
State operations or liability, or when involvement of the State is otherwise mandated by law, the State may participate in such action at its own expense with respect to attorneys’ fees and costs (but not liability); (ii) where a settlement would impose liability on the State, affect principles of California government or public law, or impact the authority of the State, the Department of General Services will have the right to approve or disapprove any settlement or
compromise, which approval will not unreasonably be withheld or delayed; and (ii) the State will reasonably cooperate in the defense and in any related settlement negotiations.
29. INVOICES: Unless otherwise specified, invoices shall be sent to the address set forth herein. Invoices shall be
submitted in triplicate and shall include the Contract number; release order number (if applicable);
item number; unit price, extended item price and invoice total amount. State sales tax and/or use tax shall be itemized separately and added to each invoice as applicable.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 31 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 15 OF 61
30. REQUIRED PAYMENT DATE: Payment will be made in accordance with the provisions of the California Prompt Payment Act, Government Code Section 927 et. seq. Unless expressly exempted by statute, the Act requires State agencies to pay properly submitted, undisputed invoices not more than 45 days after (i) the
date of acceptance of Deliverables or performance of services; or (ii) receipt of an undisputed invoice, whichever is later.
31. TAXES: Unless otherwise required by law, the State of California is exempt from Federal excise taxes. The State will only pay for any State or local sales or use taxes on the services rendered or Goods
supplied to the State pursuant to this Contract.
32. NEWLY MANUFACTURED GOODS: All Goods furnished under this Contract shall be newly manufactured Goods or certified as new and warranted as new by the manufacturer; used or reconditioned Goods are prohibited, unless otherwise specified.
33. CONTRACT MODIFICATION: No amendment or variation of the terms of this Contract shall be valid unless made in writing, signed by the parties and approved as required. No oral understanding or agreement not incorporated in the Contract is binding on any of the parties. 34. CONFIDENTIALITY OF DATA:
All financial, statistical, personal, technical and other data and information relating to the State's operation which are designated confidential by the State and made available to the Contractor in order to carry out this Contract, or which become available to the Contractor in carrying out this Contract, shall be protected by the Contractor from unauthorized use and disclosure through the
observance of the same or more effective procedural requirements as are applicable to the State.
The identification of all such confidential data and information as well as the State's procedural requirements for protection of such data and information from unauthorized use and disclosure shall be provided by the State in writing to the Contractor. If the methods and procedures employed by the Contractor for the protection of the Contractor's data and information are deemed
by the State to be adequate for the protection of the State's confidential information, such methods
and procedures may be used, with the written consent of the State, to carry out the intent of this paragraph. The Contractor shall not be required under the provisions of this paragraph to keep confidential any data or information which is or becomes publicly available, is already rightfully in the Contractor's possession without obligation of confidentiality, is independently developed by the
Contractor outside the scope of this Contract, or is rightfully obtained from third parties.
35. NEWS RELEASES: Unless otherwise exempted, news releases, endorsements, advertising, and social media content pertaining to this Contract shall not be made without prior written approval of the Department of General Services.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 32 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 16 OF 61
36. DOCUMENTATION a) The Contractor agrees to provide to the State, at no charge, all Documentation as described within the Statement of Work, and updated versions thereof, which are necessary or useful to the State in its use of the Equipment or Software provided hereunder. The Contractor agrees
to provide additional Documentation at prices not in excess of charges made by the Contractor to its other customers for similar Documentation. b) If the Contractor is unable to perform maintenance or the State desires to perform its own maintenance on Equipment purchased under this Contract then upon written notice by the State the Contractor will provide at Contractor’s then current rates and fees adequate and
reasonable assistance including relevant Documentation to allow the State to maintain the Equipment based on Contractor’s methodology. The Contractor agrees that the State may reproduce such Documentation for its own use in maintaining the Equipment. If the Contractor is unable to perform maintenance, the Contractor agrees to license any other Contractor that the State may have hired to maintain the Equipment to use the above noted Documentation.
The State agrees to include the Contractor’s copyright notice on any such Documentation reproduced, in accordance with copyright instructions to be provided by the Contractor.
37. RIGHTS IN WORK PRODUCT: a) All inventions, discoveries, intellectual property, technical communications and records originated or prepared by the Contractor pursuant to this Contract including papers, reports,
charts, computer programs, and other Documentation or improvements thereto, and including Contractor’s administrative communications and records relating to this Contract (collectively, the “Work Product”), shall be Contractor’s exclusive property. The provisions of this subsection a) may be revised in a Statement of Work. b) Software and other materials developed or otherwise obtained by or for Contractor or its
affiliates independently of this Contract or applicable purchase order (“Pre- Existing Materials”) do not constitute Work Product. If the Contractor creates derivative works of Pre-Existing Materials, the elements of such derivative works created pursuant to this Contract constitute Work Product, but other elements do not. Nothing in this Section 37 will be construed to interfere with Contractor’s or its affiliates’ ownership of Pre-Existing Materials.
c) The State will have Government Purpose Rights to the Work Product as Deliverable or delivered to the State hereunder. “Government Purpose Rights” are the unlimited, irrevocable, worldwide, perpetual, royalty-free, non-exclusive rights and licenses to use, modify, reproduce, perform, release, display, create derivative works from, and disclose the Work Product. “Government Purpose Rights” also include the right to release or disclose the Work Product
outside the State for any State government purpose and to authorize recipients to use, modify, reproduce, perform, release, display, create derivative works from, and disclose the Work Product for any State government purpose. Such recipients of the Work Product may include, without limitation, State Contractors, California local governments, the U.S. federal government, and the State and local governments of other states. “Government Purpose
Rights” do not include any rights to use, modify, reproduce, perform, release, display, create derivative works from, or disclose the Work Product for any commercial purpose. d) The ideas, concepts, know-how, or techniques relating to data processing, developed during the course of this Contract by the Contractor or jointly by the Contractor and the State may be used by either party without obligation of notice or accounting.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 33 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 17 OF 61
e) This Contract shall not preclude the Contractor from developing materials outside this Contract that are competitive, irrespective of their similarity to materials which might be delivered to the State pursuant to this Contract. 38. SOFTWARE LICENSE:
Unless otherwise specified in the Statement of Work, the Contractor hereby grants to the State and the State accepts from the Contractor, subject to the terms and conditions of this Contract, a perpetual, irrevocable, royalty-free, non-exclusive, license to use the Software Products in this Contract (hereinafter referred to as “Software Products”).
a) The State may use the Software Products in the conduct of its own business, and any division
thereof b) The license granted above authorized the State to use the Software Products in machine- readable form on the Computer System located at the site(s) specified in the Statement of Work. Said Computer System and its associated units (collectively referred to as CPU) are as
designated in the Statement of Work. If the designated CPU is inoperative due to malfunction,
the license herein granted shall be temporarily extended to authorize the State to use the Software Products, in machined-readable form, on any other State CPU until the designated CPU is returned to operation. c) By prior written notice, the State may redesignate the CPU in which the Software Products are to be used provided that the redesignated CPU is substantially similar in size and scale at no
additional cost. The redesignation shall not be limited to the original site and will be effective upon the date specified in the notice of redesignation. d) Acceptance of Commercial Software (including third party Software) and Custom Software will be governed by the terms and conditions of this Contract.
39. PROTECTION OF PROPRIETARY SOFTWARE AND OTHER PROPRIETARY DATA:
The State agrees that all material appropriately marked or identified in writing as proprietary and furnished hereunder are provided for State’s exclusive use for the purposes of this Contract only. All such proprietary data shall remain the property of the Contractor. The State agrees to take all reasonable steps to insure that such proprietary data are not disclosed to others, without prior
written consent of the Contractor, subject to the California Public Records Act. The State will
insure, prior to disposing of any media, that any licensed materials contained thereon have been erased or otherwise destroyed. The State agrees that it will take appropriate action by instruction, agreement or otherwise with its employees or other persons permitted access to licensed software and other proprietary data to satisfy its obligations under this Contract with respect to use,
copying, modification, protection and security of proprietary software and other proprietary data.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 34 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 18 OF 61
40. RIGHT TO COPY OR MODIFY: a) Any Software Product provided by the Contractor in machine-readable form may be copied, in whole or in part, in printed or machine-readable form for use by the State with the designated CPU, to perform one-time benchmark tests, for archival or emergency restart purposes, to
replace a worn copy, to understand the contents of such machine-readable material, or to modify the Software Product as provided below; provided, however, that no more than the number of printed copies and machine-readable copies as specified in the Statement of Work will be in existence under this Contract at any time without prior consent of the Contractor. Such consent shall not be unreasonably withheld by the Contractor. The original, and any
copies of the Software Product, in whole or in part, which are made hereunder shall be the property of the Contractor. b) The State may modify any non-personal computer Software Product, in machine- readable form, for its own use and merge it into other program material. Any portion of the Software Product included in any merged program material shall be used only on the designated CPUs
and shall be subject to the terms and conditions of the Contract.
41. FUTURE RELEASES: Unless otherwise specifically provided in the Contract, or the Statement of Work, if improved versions, e.g., patches, bug fixes, updates or releases, of any Software Product are developed by
the contractor, and are made available to other licensees, they will be made available to the State
at no additional cost only if such are made available to other licensees at no additional cost. If the Contractor offers new versions or upgrades to the Software Product, they shall be made available to the State at the State’s option at a price not greater than the Contract price plus a price increase proportionate to the increase from the list price of the original version to that of the new
version, if any. If the Software Product has no list price, such price increase will be proportionate
to the increase in average price from the original to the new version, if any, as estimated by the Contractor in good faith.
42. ENCRYPTION/CPU ID AUTHORIZATION CODES: a) When Encryption/CPU Identification (ID) authorization codes are required to operate the Software Products, the Contractor will provide all codes to the State with delivery of the
Software. b) In case of an inoperative CPI, the Contractor will provide a temporary encryption/CPU ID authorization code to the State for use on a temporarily authorized CPU until the designated CPU is returned to operation. c) When changes in designated CPUs occur, the State will notify the Contractor via telephone
and/or facsimile/e-mail of such change. Upon receipt of such notice, the Contractor will issue via telephone and/or facsimile/e-mail to the State within 24 hours, a temporary encryption ID authorization code for use on the newly designated CPU until such time as permanent code is assigned.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 35 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 19 OF 61
43. PATENT, COPYRIGHT AND TRADE SECRET INDEMNITY: a) Contractor will indemnify, defend, and save harmless the State, its officers, agents, and employees, from any and all third-party claims, costs (including without limitation reasonable attorneys’ fees), and losses for infringement or violation of any U.S. Intellectual Property Right
by any product or service provided hereunder. With respect to claims arising from computer Hardware or Software manufactured by a third party and sold by Contractor as a reseller, Contractor will pass through to the State such indemnity rights as it receives from such third party (“Third Party Obligation”) and will cooperate in enforcing them; provided that if the third party manufacturer fails to honor the Third Party Obligation, Contractor will provide the State
with indemnity protection equal to that called for by the Third Party Obligation, but in no event greater than that called for in the first sentence of this Section. The provisions of the preceding sentence apply only to third party computer Hardware or Software sold as a distinct unit and accepted by the State. Unless a Third-Party Obligation provides otherwise, the defense and payment obligations set forth in this Section will be conditional upon the following:
i. The State will notify the Contractor of any such claim in writing and tender the defense thereof within a reasonable time; and ii. The Contractor will have sole control of the defense of any action on such claim and all negotiations for its settlement or compromise; provided that (a) when substantial principles of government or public law are involved, when litigation might create precedent affecting
future State operations or liability, or when involvement of the State is otherwise mandated by law, the State may participate in such action at its own expense with respect to attorneys’ fees and costs (but not liability); (b) where a settlement would impose liability on the State, affect principles of California government or public law, or impact the authority of the State, the Department of General Services will have the right to approve or disapprove
any settlement or compromise, which approval will not unreasonably be withheld or delayed; and (c) the State will reasonably cooperate in the defense and in any related settlement negotiations. b) Should the Deliverables, or the operation thereof, become, or in the Contractor's opinion are likely to become, the subject of a claim of infringement or violation of a U.S. Intellectual
Property Right, the State shall permit the Contractor at its option and expense either to procure for the State the right to continue using the Deliverables, or to replace or modify the same so that they become non-infringing. If none of these options can reasonably be taken, or if the use of such Deliverables by the State shall be prevented by injunction, the Contractor agrees to take back such Deliverables and make every reasonable effort to assist the State in procuring
substitute Deliverables. If, in the sole opinion of the State, the return of such infringing Deliverables makes the retention of other Deliverables acquired from the Contractor under this Contract impractical, the State shall then have the option of terminating such Contracts, or applicable portions thereof, without penalty or termination charge. The Contractor agrees to take back such Deliverables and refund any sums the State has paid Contractor less any
reasonable amount for use or damage. c) The Contractor shall have no liability to the State under any provision of this clause with respect to any claim of patent, copyright or trade secret infringement which is based upon: i. The combination or utilization of Deliverables furnished hereunder with Equipment, Software or devices not made or furnished by the Contractor; or,
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 36 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 20 OF 61
ii. The operation of Equipment furnished by the Contractor under the control of any Operating Software other than, or in addition to, the current version of Contractor-supplied Operating Software; or iii. The modification initiated by the State, or a third party at the State’s direction, of any
Deliverable furnished hereunder; or iv. The combination or utilization of Software furnished hereunder with non-Contractor supplied Software. d) The Contractor certifies that it has appropriate systems and controls in place to ensure that State funds will not be used in the performance of this Contract for the acquisition, operation or
maintenance of computer Software in violation of copyright laws.
44. DISPUTES: a) The parties shall deal in good faith and attempt to resolve potential disputes informally. If the dispute persists, the Contractor shall submit to the Department Director or designee a written
demand for a final decision regarding the disposition of any dispute between the parties arising
under, related to or involving this Contract. Contractor’s written demand shall be fully supported by factual information, and if such demand involves a cost adjustment to the Contract, Contractor shall include with the demand a written statement signed by an authorized person indicating that the demand is made in good faith, that the supporting data are accurate and complete and that
the amount requested accurately reflects the Contract adjustment for which Contractor believes
the State is liable. The contracting Department Director or designee shall have 30 days after receipt of Contractor’s written demand invoking this Section “Disputes” to render a written decision. If a written decision is not rendered within 30 days after receipt of contractor’s demand, it shall be deemed a decision adverse to the Contractor’s contention. If the Contractor is not
satisfied with the decision of the Department Director or designee, the Contractor may appeal the
decision, in writing, within 15 days of its issuance (or the expiration of the 30-day period in the event no decision is rendered by the contracting department), to the Department of General Services, Deputy Director, Procurement Division, who shall have 45 days to render a final decision. If the Contractor does not appeal the decision of the contracting Department Director or
designee, the decision shall be conclusive and binding regarding the dispute and the Contractor
shall be barred from commencing an action in court, or with the Victims Compensation Government Claims Board, for failure to exhaust Contractor’s administrative remedies. b) Pending the final resolution of any dispute arising under, related to or involving this Contract, Contractor agrees to diligently proceed with the performance of this Contract, including the
delivery of Goods or providing of services in accordance with the State’s instructions regarding
this Contract. Contractor’s failure to diligently proceed in accordance with the State’s instructions regarding this Contract shall be considered a material breach of this Contract. c) Any final decision of the State shall be expressly identified as such, shall be in writing, and shall be signed by the Deputy Director, Procurement Division if an appeal was made. If the Deputy
Director, Procurement Division fails to render a final decision within 45 days after receipt of
Contractor’s demand, it shall be deemed a final decision adverse to Contractor’s contentions. The State’s final decision shall be conclusive and binding regarding the dispute unless Contractor commences an action in a court of competent jurisdiction to contest such decision within 90 days following the date of the final decision or 1 year following the accrual of the cause of action,
whichever is later.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 37 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 21 OF 61
d) For disputes involving purchases made by the Department of General Services, Procurement Division, the Contractor shall submit to the Department Director or designee a written demand for a final decision, which shall be fully supported in the manner described in the subsection a above. The Department Director or designee shall have 30 days to render a final decision. If a
final decision is not rendered within 30 days after receipt of the Contractor’s demand, it shall be deemed a final decision adverse to the Contractor’s contention. The final decision shall be conclusive and binding regarding the dispute unless the Contractor commences an action in a court of competent jurisdiction to contest such decision within 90 days following the date of the final decision or 1 year following the accrual of the cause of action, whichever is later. The
dates of decision and appeal in this section may be modified by mutual consent, as applicable, excepting the time to commence an action in a court of competent jurisdiction.
45. STOP WORK: a) The State may, at any time, by written Stop Work Order to the Contractor, require the Contractor to stop all, or any part, of the work called for by this Contract for a period up to 45
days after the Stop Work Order is delivered to the Contractor, and for any further period to which the parties may agree. The Stop Work Order shall be specifically identified as such and shall indicate it is issued under this clause. Upon receipt of the Stop Work Order, the Contractor shall immediately comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the work covered by the Stop Work Order during the period
of work stoppage. Within a period of 45 days after a Stop Work Order is delivered to the Contractor, or within any extension of that period to which the parties shall have agreed, the State shall either: i. Cancel the Stop Work Order; or ii. Terminate the work covered by the Stop Work Order as provided for in the termination for
default or the termination for convenience clause of this Contract. b) If a Stop Work Order issued under this clause is canceled or the period of the Stop Work Order or any extension thereof expires, the Contractor shall resume work. The State shall make an equitable adjustment in the delivery schedule, the Contract price, or both, and the Contract shall be modified, in writing, accordingly, if:
i. The Stop Work Order results in an increase in the time required for, or in the Contractor’s cost properly allocable to the performance of any part of this Contract; and ii. The Contractor asserts its right to an equitable adjustment within 60 days after the end of the period of work stoppage; provided, that if the State decides the facts justify the action, the State may receive and act upon a proposal submitted at any time before final payment
under this Contract. c) If a Stop Work Order is not canceled and the work covered by the Stop Work Order is terminated in accordance with the provision entitled Termination for the Convenience of the State, the State shall allow reasonable costs resulting from the Stop Work Order in arriving at the termination settlement.
d) The State shall not be liable to the Contractor for loss of profits because of a Stop Work Order issued under this clause.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 38 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 22 OF 61
46. EXAMINATION AND AUDIT: Contractor agrees that the State, or its designated representative shall have the right to review and copy any records and supporting documentation pertaining to performance of this Contract. The Contractor agrees to maintain such records for possible audit for a minimum of three years
after final payment, unless a longer period of records retention is stipulated. The Contractor agrees to allow the auditor(s) access to such records during normal business hours and in such a manner so as to not interfere unreasonably with normal business activities and to allow interviews of any employees or others who might reasonably have information related to such records. Further, Contractor agrees to include a similar right of the State to audit records and interview staff
in any subcontract related to performance of this Contract. The State shall provide reasonable advance written notice of such audit(s) to the Contractor.
47. FOLLOW-ON CONTRACTS: a) If the Contractor or its affiliates provides Technical Consulting and Direction (as defined below), the Contractor and its affiliates:
i. will not be awarded a subsequent Contract to supply the service or system, or any significant component thereof, that is used for or in connection with any subject of such Technical Consulting and Direction; and ii. will not act as consultant to any person or entity that does receive a Contract described in subsection (i). This prohibition will continue for one year after termination of this Contract or
completion of the Technical Consulting and Direction, whichever comes later. b) “Technical Consulting and Direction” means services for which the Contractor received compensation from the State and includes: i. development of or assistance in the development of work statements, specifications, solicitations, or feasibility studies;
ii. development or design of test requirements; iii. evaluation of test data; iv. direction of or evaluation of another Contractor; v. provision of formal recommendations regarding the acquisition of Information Technology products or services; or
vi. provisions of formal recommendations regarding any of the above. For purposes of this Section, “affiliates” are employees, directors, partners, joint venture participants, parent corporations, subsidiaries, or any other entity controlled by, controlling, or under common control with the Contractor. Control exists when an entity owns or directs more than 50 percent of the outstanding shares or securities representing the right to vote for the election
of directors or other managing authority. c) To the extent permissible by law, the Director of the Department of General Services, or designee, may waive the restrictions set forth in this Section by written notice to the Contractor if the Director determines their application would not be in the State’s best interest. Except as prohibited by law, the restrictions of this Section will not apply:
i. to follow-on advice given by vendors of commercial off-the-shelf products, including Software and Hardware, on the operation, integration, repair, or maintenance of such products after sale; or
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 39 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 23 OF 61
ii. where the State has entered into a master agreement for Software or services and the scope of work at the time of Contract execution expressly calls for future recommendations among the Contractor’s own products. d) The restrictions set forth in this Section are in addition to conflict of interest restrictions
imposed on public Contractors by California law (“Conflict Laws”). In the event of any inconsistency, such Conflict Laws override the provisions of this Section, even if enacted after execution of this Contract.
48. PRIORITY HIRING CONSIDERATIONS:
If this Contract includes services in excess of $200,000, the Contractor shall give priority
consideration in filling vacancies in positions funded by the Contract to qualified recipients of aid under Welfare and Institutions Code Section 11200 in accordance with Public Contract Code (PCC) Section 10353.
49. COVENANT AGAINST GRATUITIES:
The Contractor warrants that no gratuities (in the form of entertainment, gifts, or otherwise) were
offered or given by the Contractor, or any agent or representative of the Contractor, to any officer or employee of the State with a view toward securing the Contract or securing favorable treatment with respect to any determinations concerning the performance of the Contract. For breach or violation of this warranty, the State shall have the right to terminate the Contract, either in whole or
in part, and any loss or damage sustained by the State in procuring on the open market any items
which Contractor agreed to supply shall be borne and paid for by the Contractor. The rights and remedies of the State provided in this clause shall not be exclusive and are in addition to any other rights and remedies provided by law or in equity.
50. NONDISCRIMINATION CLAUSE:
a) During the performance of this Contract, the Contractor and its subcontractors shall not
unlawfully discriminate, harass or allow harassment, against any employee or applicant for employment because of sex, sexual orientation, race, color, ancestry, religious creed, national origin, disability (including HIV and AIDS), medical condition (cancer), age, marital status, and denial of family care leave. The Contractor and subcontractors shall insure that the evaluation
and treatment of their employees and applicants for employment are free from such
discrimination and harassment. The Contractor and subcontractors shall comply with the provisions of the Fair Employment and Housing Act (Government Code, Section 12990 et seq.) and the applicable regulations promulgated thereunder (California Code of Regulations, Title 2, Section 7285.0 et seq.). The applicable regulations of the Fair Employment and
Housing Commission implementing Government Code Section 12990 (a-f), set forth in Chapter
5 of Division 4 of Title 2 of the California Code of Regulations are incorporated into this Contract by reference and made a part hereof as if set forth in full. The Contractor and its subcontractors shall give written notice of their obligations under this clause to labor organizations with which they have a collective bargaining or other agreement.
b) The Contractor shall include the nondiscrimination and compliance provisions of this clause in
all subcontracts to perform work under the Contract.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 40 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 24 OF 61
51. NATIONAL LABOR RELATIONS BOARD CERTIFICATION: The Contractor swears under penalty of perjury that no more than one final, unappealable finding of contempt of court by a federal court has been issued against the Contractor within the immediately preceding two-year period because of the Contractor’s failure to comply with an order
of the National Labor Relations Board. This provision is required by, and shall be construed in accordance with, PCC Section 10296.
52. ASSIGNMENT OF ANTITRUST ACTIONS: Pursuant to Government Code Sections 4552, 4553, and 4554, the following provisions are incorporated herein:
a) In submitting an offer to the State, the supplier offers and agrees that if the offer is accepted, it will assign to the State all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. 15) or under the Cartwright Act (Chapter 2, commencing with Section 16700, of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of Goods, material or other items, or services by the supplier for
sale to the State pursuant to the solicitation. Such assignment shall be made and become effective at the time the State tenders final payment to the supplier. b) If the State receives, either through judgment or settlement, a monetary recovery for a cause of action assigned under this chapter, the assignor shall be entitled to receive reimbursement for actual legal costs incurred and may, upon demand, recover from the State any portion of
the recovery, including treble damages, attributable to overcharges that were paid by the assignor but were not paid by the State as part of the offer price, less the expenses incurred in obtaining that portion of the recovery. c) Upon demand in writing by the assignor, the assignee shall, within one year from such demand, reassign the cause of action assigned under this part if the assignor has been or may
have been injured by the violation of law for which the cause of action arose and i. the assignee has not been injured thereby, or ii. the assignee declines to file a court action for the cause of action.
53. DRUG-FREE WORKPLACE CERTIFICATION:
The Contractor certifies under penalty of perjury under the laws of the State of California that the
Contractor will comply with the requirements of the Drug-Free Workplace Act of 1990 (Government Code Section 8350 et seq.) and will provide a drug-free workplace by taking the following actions:
a) Publish a statement notifying employees that unlawful manufacture, distribution, dispensation,
possession, or use of a controlled substance is prohibited and specifying actions to be taken
against employees for violations, as required by Government Code Section 8355(a). b) Establish a Drug-Free Awareness Program as required by Government Code Section 8355(b) to inform employees about all of the following: i. the dangers of drug abuse in the workplace;
ii. the person's or organization's policy of maintaining a drug-free workplace;
iii. any available counseling, rehabilitation, and employee assistance programs; and, iv. penalties that may be imposed upon employees for drug abuse violations.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 41 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 25 OF 61
c) Provide, as required by Government Code Section 8355(c), that every employee who works on the proposed or resulting Contract: i. will receive a copy of the company's drug-free policy statement; and, ii. will agree to abide by the terms of the company's statement as a condition of employment
on the Contract.
54. FOUR-DIGIT DATE COMPLIANCE: Contractor warrants that it will provide only Four-Digit Date Compliant (as defined below) Deliverables and/or services to the State. “Four Digit Date Compliant” Deliverables and services can accurately process, calculate, compare, and sequence date data, including without limitation
date data arising out of or relating to leap years and changes in centuries. This warranty and representation is subject to the warranty terms and conditions of this Contract and does not limit the generality of warranty obligations set forth elsewhere herein.
55. SWEATFREE CODE OF CONDUCT:
a) Contractor declares under penalty of perjury that no equipment, materials, or supplies
furnished to the State pursuant to the Contract have been produced in whole or in part by sweatshop labor, forced labor, convict labor, indentured labor under penal sanction, abusive forms of child labor or exploitation of children in sweatshop labor, or with the benefit of sweatshop labor, forced labor, convict labor, indentured labor under penal sanction, abusive
forms of child labor or exploitation of children in sweatshop labor. Contractor further declares
under penalty of perjury that they adhere to the Sweatfree Code of Conduct as set forth on the California Department of Industrial Relations website located at www.dir.ca.gov, and Public Contract Code Section 6108. b) Contractor agrees to cooperate fully in providing reasonable access to its records, documents,
agents or employees, or premises if reasonably required by authorized officials of the State,
the Department of Industrial Relations, or the Department of Justice to determine Contractor’s compliance with the requirements under paragraph (a).
56. RECYCLED CONTENT REQUIREMENTS: The Contractor shall certify in writing under penalty of perjury, the minimum, if not exact, percentage of postconsumer material as defined in the PCC Section 12200-12209, in products,
materials, goods, or supplies offered or sold to the State that fall under any of the statutory categories regardless of whether the product meets the requirements of Section 12209. The certification shall be provided by the contractor, even if the product or good contains no postconsumer recycled material, and even if the postconsumer content is unknown. With respect to printer or duplication cartridges that comply with the requirements of Section 12156(e), the
certification required by this subdivision shall specify that the cartridges so comply (PCC 12205 (b)(2)). A state agency contracting officer may waive the certification requirements if the percentage of postconsumer material in the products, materials, goods, or supplies can be verified in a written advertisement, including, but not limited to, a product label, a catalog, or a manufacturer or vendor Internet web site. Contractors are to use, to the maximum extent
economically feasible in the performance of the contract work, recycled content products (PCC 12203(d)).
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 42 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 26 OF 61
57. CHILD SUPPORT COMPLIANCE ACT: For any Contract in excess of $100,000, the Contractor acknowledges in accordance with PCC Section 7110, that:
a) The Contractor recognizes the importance of child and family support obligations and shall fully
comply with all applicable State and federal laws relating to child and family support enforcement, including, but not limited to, disclosure of information and compliance with earnings assignment orders, as provided in Chapter 8 (commencing with Section 5200) of Part 5 of Division 9 of the Family Code; and b) The Contractor, to the best of its knowledge is fully complying with the earnings assignment
orders of all employees and is providing the names of all new employees to the New Hire Registry maintained by the California Employment Development Department.
58. AMERICAN WITH DISABILITIES ACT: The Contractor assures the State that the Contractor complies with the Americans with Disabilities Act of 1990 (42 U.S.C. 12101 et seq.).
59. ELECTRONIC WASTE RECYCLING ACT OF 2003: The Contractor certifies that it complies with the applicable requirements of the Electronic Waste Recycling Act of 2003, Chapter 8.5, Part 3 of Division 30, commencing with Section 42460 of the Public Resources Code. The Contractor shall maintain documentation and provide reasonable access to its records and documents that evidence compliance.
60. USE TAX COLLECTION: In accordance with PCC Section 10295.1, the Contractor certifies that it complies with the requirements of Section 7101 of the Revenue and Taxation Code. Contractor further certifies that it will immediately advise the State of any change in its retailer’s seller’s permit or certification of registration or applicable affiliate’s seller’s permit or certificate of registration as described in
subdivision (a) of PCC Section 10295.1.
61. EXPATRIATE CORPORATIONS: Contractor hereby declares that it is not an expatriate corporation or subsidiary of an expatriate corporation within the meaning of PCC Sections 10286 and 10286.1, and is eligible to Contract
with the State.
62. DOMESTIC PARTNERS: For Contracts over $100,000 executed or amended after January 1, 2007, the Contractor certifies that the Contractor is in compliance with Public Contract Code Section 10295.3.
63. SMALL BUSINESS PARTICIPATION AND DVBE PARTICIPATION REPORTING
REQUIREMENTS:
a) If for this Contract the Contractor made a commitment to achieve small business participation, then the Department requires the Contractor upon completion of this Contract (or within such other time period as may be specified elsewhere in this Contract) to report to the actual percentage of small business participation that was achieved. (Govt. Code 14841.)
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 43 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 27 OF 61
b) If for this Contract the Contractor made a commitment to achieve disabled veteran business enterprise (DVBE) participation goal, then, pursuant to Mil. & Vets. Code 999.5(d), upon completion of this Contract, the Department requires the Contractor to certify using the Prime Contractor’s Certification – DVBE Subcontracting Report (STD 817), all of the following:
i. the total amount the prime Contractor received under the Contract; ii. the name, address, Contract number, and certification ID number of the DVBE(s) that participated in the performance of the Contract; iii. the amount and percentage of work the prime Contractor committed to provide to one or more DVBE(s) under the requirements of the Contract and the total payment each DVBE
received from the prime Contractor; iv. that all payments under the Contract have been made to the DVBE; and v. the actual percentage of DVBE participation that was achieved. Upon request, the prime Contractor shall provide proof of payment for the work.
If for this Contract the Contractor made a commitment to achieve the DVBE participation goal, the
Department will withhold $10,000 from the final payment, or the full final payment if less than $10,000, until the Contractor complies with the certification requirements above. A Contractor that fails to comply with the certification requirement shall, after written notice, be allowed to cure the defect.
Notwithstanding any other law, if, after at least 15 calendar days but not more than 30 calendar
days from the date of written notice, the prime contractor refuses to comply with the certification requirements, the Department shall permanently deduct $10,000 from the final payment, or the full payment if less than $10,000. (Mil. & Vets. Code 999.7)
A person or entity that knowingly provides false information shall be subject to a civil penalty for each violation. (Mil. & Vets. Code 999.5(d); Govt. Code 14841)
Contractor agrees to comply with the rules, regulations, ordinances, and statutes that apply to the DVBE program as defined in Section 999 of the Mil. & Vets. Code, including, but not limited to, the requirements of Section 999.5(d). (PCC 10230)
64. LOSS LEADER:
It is unlawful for any person engaged in business within this state to sell or use any article or
product as a “loss leader” as defined in Section 17030 of the Business and Professions Code. (PCC 12104.5(b).).
ADDITIONAL CMAS TERMS AND CONDITIONS
65. CMAS - CONTRACTOR’S LICENSE REQUIREMENTS:
Contracts that include installation or the wording “Furnish and Install” require at the time of
Contract award that Contractors possess a valid California State Contractor’s License. If subcontractors are used, they must also possess a valid California State Contractor’s License. All businesses which construct or alter any building, highway, road, parking facility, railroad, excavation, or other structure in California must be licensed by the California State License Board
(CSLB) if the total cost (labor and materials) of the project is $500 or more. Failure to be licensed
or to keep the license current and in good standing shall be grounds for Contract revocation.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 44 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 28 OF 61
66. CMAS - PUBLIC WORKS REQUIREMENTS (LABOR/INSTALLATION): a) Prior to the commencement of performance, the Contractor must obtain and provide to the State, a payment bond, on Standard Form 807, when the Contract involves a public works expenditure (labor/installation costs) in excess of $5,000. Such bond shall be in a sum not less
than 100 percent of the Contract price. b) In accordance with the provisions of Section 1773 of the California Labor Code, the Contractor shall, conform and stipulates to the general prevailing rate of wages, including employer benefits as defined in Section 1773.1 of the California Labor Code, applicable to the classes of labor to be used for public works such as at the delivery site for the assembly and installation
of the equipment or materials under the purchase order. Pursuant to Section 1770 of the California Labor Code, the Department of Industrial Relations has ascertained the general prevailing rate of wages in the county in which the work is to be done, to be as listed in the booklet entitled General Prevailing Wage Rates. The booklet is compiled monthly and copies of the same are available from the Department of Industrial Relations, Prevailing Wage Unit at
www.dir.ca.gov (select Statistics & Research) or (415) 703-4774. The booklet is required to be posted at the job site. c) The Contractor hereby certifies by signing this Contract that: i. Contractor has met or will comply with the standards of affirmative compliance with the Non-Discrimination Clause Requirements included herein;
ii. Contractor is aware of the provisions of Section 3700 of the Labor Code that require every employer to be insured against liability for workmen's compensation or to undertake self- insurance in accordance with the provisions of that Code, and Contractor will comply with such provisions before commencing the performance of the work of the purchase order. d) Laws to be Observed
i. Labor Pursuant to Section 1775 of the California Labor Code the Contractor shall, as a penalty to the State or Political subdivision on whose behalf the purchase order is made or awarded, forfeit not more than fifty dollars for each calendar day, or portions thereof, for each worker paid by him or subcontractor under him, less than the prevailing wage so stipulated; and in
addition, the Contractor further agrees to pay to each workman the difference between the actual amount paid for each calendar day, or portions thereof, and the stipulated prevailing wage rate for the same. This provision shall not apply to properly indentured apprentices. Pursuant to Sections 1810-1815 of the California Labor Code, inclusive, it is further agreed that the maximum hours a worker is to be employed is limited to eight hours a day and forty
hours a week and the Contractor shall forfeit, as a penalty to the State, twenty-five dollars for each worker employed in the execution of the purchase order for each calendar day during which a workman is required or permitted to labor more than eight hours in any calendar day or more than forty hours in any calendar week, in violation of California Labor
Code Sections 1810- 1815, inclusive.
ii. Worker's Compensation Insurance The Contractor will be required to secure the payment of compensation to its employees in accordance with the provisions of Labor Code Section 3700.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 45 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 29 OF 61
iii. Travel and Subsistence Payments Travel and subsistence payments shall be paid to each worker needed to execute the work, as such travel and subsistence payments are defined in the applicable collective bargaining agreements filed in accordance with Labor Code Section 1773.8.
iv. Apprentices Special attention is directed to Sections 1777.5, 1777.6, and 1777.7 of the California Labor Code and Title 8, California Administrative Code Section 200 et seq. Each Contractor and/or subcontractor must, prior to commencement of the public works Contract/purchase order, contact the Division of Apprenticeship Standards, 525 Golden Gate Avenue, San
Francisco, CA, or one of its branch offices to insure compliance and complete understanding of the law regarding apprentices and specifically the required ratio thereunder. Responsibility for compliance with this section lies with the prime Contractor. v. Payroll The Contractor shall keep an accurate payroll record showing the name, social security
account, and work classification specific and straight time and overtime hours worked by each employee. A certified copy of the employee’s payroll record shall be available for inspection as specified in Section 1776 of the California Labor Code.
67. CMAS - TERMINATION OF CMAS CONTRACT: a) The State may terminate this CMAS Contract at any time upon 30 days prior written notice.
b) If the Contractor's GSA Multiple Award Schedule is terminated within the term of the CMAS Contract, the CMAS Contract shall also be considered terminated on the same date. c) Prior to the expiration of this CMAS Contract, this Contract may be terminated for the convenience of both parties by mutual consent.
d) This provision shall not relieve the Contractor of the obligation to perform under any purchase
order or other similar ordering document executed prior to the termination becoming effective.
68. CMAS - CONTRACT AMOUNT: There is no guarantee of minimum purchase of Contractor's products or services by the State.
69. CMAS - DEBARMENT CERTIFICATION (FEDERALLY FUNDED CONTRACTS):
When Federal funds are being expended, the prospective recipient of Federal assistance funds is
required to certify to the Buyer, that neither it nor its principals are presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any Federal department or agency.
70. CMAS - PURCHASE ORDERS FUNDED IN WHOLE OR PART BY THE FEDERAL
GOVERNMENT:
All Contracts (including individual orders), except for State construction projects, which are funded in whole or in part by the federal government may be canceled with 30-day notice, and are subject to the following:
a) It is mutually understood between the parties that this Contract (order) may have been written
before ascertaining the availability of congressional appropriation of funds, for the mutual
benefit of both parties, in order to avoid program and fiscal delays which would occur if the Contract (order) were executed after that determination was made.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 46 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 30 OF 61
b) This Contract (order) is valid and enforceable only if sufficient funds are made available to the State by the United States Government for the fiscal year during which the order was generated for the purposes of this program. In addition, this Contract (order) is subject to any additional restrictions, limitations, or conditions enacted by the Congress or any statute
enacted by the Congress that may affect the provisions, terms or funding of this Contract (order) in any manner. c) It is mutually agreed that if the Congress does not appropriate sufficient funds for the program, this Contract (order) shall be amended to reflect any reduction in funds. The department has the option to void the Contract (order) under the 30-day cancellation clause or to amend the
Contract to reflect any reduction of funds.
71. CMAS - CONFLICT OF INTEREST: a) Current State Employees (Public Contract Code Section 10410): i. No officer or employee shall engage in any employment, activity or enterprise from which the officer or employee receives compensation or has a financial interest and which is
sponsored or funded by any State agency, unless the employment, activity or enterprise is required as a condition of regular State employment. ii. No officer or employee shall Contract on his or her own behalf as an independent Contractor with any State agency to provide Goods or services. b) Former State Employees (Public Contract Code Section 10411):
i. For the two-year period from the date he or she left State employment, no former State officer or employee may enter into a Contract in which he or she engaged in any of the negotiations, transactions, planning, arrangements or any part of the decision-making process relevant to the Contract while employed in any capacity by any State agency. ii. For the twelve-month period from the date he or she left State employment, no former State
officer or employee may enter into a Contract with any State agency if he or she was employed by that State agency in a policy-making position in the same general subject area as the proposed Contract within the twelve-month period prior to his or her leaving State service. 72. CMAS - SUBCONTRACTING REQUIREMENTS:
Any subcontractor that the CMAS supplier chooses to use in fulfilling the requirements of this Contract (order) and is expected to receive more than 10 percent of the value of the Contract/purchase order must also meet all Contractual requirements of the Contract (order).
73. CMAS - RENTAL AGREEMENTS:
The State does not agree to:
• Indemnify a Contractor;
• Assume responsibility for matters beyond its control;
• Agree to make payments in advance;
• Accept any other provision creating a contingent liability against the State; or
• Agree to obtain insurance to protect the Contractor.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 47 of 103
GSPD-401IT-CMAS
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) GENERAL PROVISIONS – INFORMATION TECHNOLOGY
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 31 OF 61
The State’s responsibility for repairs and liability for damage or loss is restricted to that made necessary by or resulting from the negligent act or omission of the State or its officers, employees, or agents.
If the Contractor maintains the equipment, the Contractor must keep the equipment in good
working order and make all necessary repairs and adjustments without qualification. The State may terminate for default or cease paying rent should the Contractor fail to maintain the equipment properly.
Personal property taxes are not generally reimbursed when leasing equipment (SAM 8736). 74. CMAS - LEASE (LEASE SMART):
If an agency desires to lease through Lease SMart, the Contractor agrees to sell to lessor the assets at the same price as they agree to sell to the State.
75. CMAS - PROGRESS PAYMENTS & RISK ASSESSMENT: In accordance with PCC 12112 agencies are required to withhold not less than 10 percent of the Contract price until final delivery and acceptance of the Goods or services, for any Contract that
provides for progress payments in a Contract for IT Goods or services to be manufactured or performed by a Contractor especially for the State and not suitable for sale to others in the ordinary course of the Contractor’s business.
Interim Risk Assessment guidelines and financial protection measures are detailed in PCC 12112 for agencies to use to determine their applicability to agency projects.
76. CMAS - QUARTERLY REPORTS: Contractors are required to submit quarterly business activity reports, as specified in this Contract, even when there is no activity. A separate report is required for each Contract, as differentiated by alpha suffix. 77. CMAS - CONTRACTOR EVALUATION:
In accordance with PCC 10367 and 10369, performance of the Contractor under orders issued against this Contract will be evaluated. The ordering agency shall complete a written evaluation, and if the Contractor did not satisfactorily perform the work specified, a copy of the evaluation will be sent to the DGS, Office of Legal Services.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 48 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 32 OF 61
THESE CLOUD COMPUTING – SOFTWARE AS A SERVICE GENERAL PROVISIONS ARE ONLY TO BE USED FOR SOFTWARE AS A SERVICE (SaaS), AS DEFINED BELOW, AND ANY ANCILLARY SERVICES. THE CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (SOFTWARE AS A SERVICE) ARE INCORPORATED BY REFERENCE UNLESS SPECIFICALLY MODIFIED AND ATTACHED HERETO. THIS CONTRACT SHALL BE ACCOMPANIED BY A STATEMENT OF WORK (SOW) AND SERVICE LEVEL AGREEMENT (SLA), IN ADDITION TO STANDARD EXHIBITS.
1. DEFINITIONS: Unless otherwise specified in the Statement of Work, the following terms shall be given the meaning shown, unless context requires otherwise.
a) “Application Program" means a computer program that is intended to be executed for the purpose of performing useful work for the user of the information being processed. Application Programs are developed or otherwise acquired by the User of the Hardware/Software system, but they may be supplied by the Contractor.
b) “Buyer” means the State’s authorized contracting official.
c) “Contract” means this Contract or agreement (including any purchase order), by whatever name known or in whatever format used. d) “Contractor” means the business entity with whom the State enters into this Contract. Contractor shall be synonymous with supplier, vendor, Reseller, Service Provider, or other similar term.
e) “Customer” means the State or an Eligible Public Entity using the Contractor’s or the Service Provider’s Services. f) “Deliverables” means the tangible products or works of authorship and other items (e.g. reports) to be delivered pursuant to this Contract, including any such items furnished that are incidental to the provision of Services.
g) "Documentation" means manuals and other published materials necessary or useful to the State in its use or maintenance of the products and Services provided hereunder and includes online materials, virtual help, and help desk where available. In addition, manuals and other published materials customized for the State hereunder constitute Work Product as defined below.
h) “Eligible Public Entity” means each of the non-State public entities authorized to purchase the Deliverables and Services offered hereunder. “Eligible Public Entity” includes the county, city, city and county, district, public authority, public agency, municipal corporation, or any other political subdivision or public corporation in the State. “Eligible Public Entity” also includes a federally-recognized tribal entity acting in its tribal governmental capacity.
i) “Goods” means all types of tangible personal property, including but not limited to materials, supplies, and equipment (including computer and telecommunications equipment). j) "Hardware" refers to computer equipment and is contrasted with Software.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 49 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 33 OF 61
k) “Information Technology” includes, but is not limited to, all electronic technology systems and services, automated information handling, system design and analysis, conversion of data, computer programming, information storage and retrieval, telecommunications which include voice, video, and data communications, requisite system controls, simulation, electronic
commerce, and all related interaction between people and machines. l) "Maintenance" includes: i) remedial maintenance performed by the Contractor which results from a Services failure and which is performed as required, i.e., on an unscheduled basis; and ii) the maintenance performed on a scheduled basis by the Contractor. m) “Reseller” means the agent(s) of the Service Provider or the business entity authorized by the
Service Provider to resell the Services or perform aspects of this Contract as specified herein including, but not limited to sales, fulfillment, invoicing, returns, and customer service. n) “Service Provider” means the Contractor, subcontractors, agents, Resellers, third parties and affiliates of the Contractor, the cloud service provider, or managed service provider who may
provide the Services agreed to under the Contract.
o) "Services" means the cloud computing services, including Software as a Service (but not Infrastructure as a Service or Platform as a Service), and any related services, offered to the State by the Contractor herein. p) "Software" means an all-inclusive term which refers to any computer programs, routines, or
subroutines supplied by the Contractor, including operating Software, Application Programs,
and enabling software (“Software Products”) that the State downloads to the State’s systems to facilitate use of the Service. q) “Software as a Service (SaaS)” is the capability provided to the Customer to use applications made available by the Service Provider running on a cloud infrastructure. The applications are accessible from various client devices through a thin client interface such as a web browser
(e.g., web-based email). The Customer does not manage or control the underlying cloud infrastructure including network, servers, operating systems, storage, or even individual application capabilities, with the possible exception of limited user-specific application configuration settings. r) "State" means the government of the State of California, its employees and authorized
representatives, including without limitation any department, agency, or other unit of the government of the State of California. s) “State Data” means all data owned by the State, and submitted to, processed by, or stored by the Service Provider under this Contract and includes, but is not limited to, all data that originated with the State or Users, all data provided by the State or Users, and data generated,
manipulated, produced, reported by or otherwise emanating from or by applications run by the State or Users on the Services. For clarity, State Data is synonymous with “Customer Data”, “Customer Content”, or similar terms, as used in various provisions of the service agreements and incorporated into the Contract and includes the following: i. “Non-Public Data” means data submitted to the Service Provider, other than Personal Data,
that is not subject to distribution to the public as public information. It is deemed to be sensitive and confidential by the State because it contains information that may be exempt by statute, regulation, or policy from access by the general public as public information. ii. “Personal Data” means Personal Information as defined by the California Information Practices Act (Civil Code sections 1798 et seq.) submitted to the Service Provider.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 50 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 34 OF 61
iii. “Public Information” means any information prepared, owned, used, or retained by the State and not specifically exempt from the disclosure requirements of the California Public Records Act (Government Code section 6250 et. seq.) or other applicable state or federal laws. For clarity, "Public Information” is also interchangeable with “Public Data”.
t) “Statement of Work” (or “SOW”) means a document provided by the State which defines the timeline, and specifies the objectives, Services, Deliverables and tasks that the Contractor is expected to perform, their responsibilities and expectations, indicating the type, level and quality of service that is expected, all of which form a contractual obligation upon the Contractor in providing Services to the State. The SOW includes detailed technical
requirements and pricing, with permitted modifications (“carve- outs”) to the SaaS General and Special Provisions. u) “User" means any authorized end user of the Services under this Contract and includes Customer’s employees, subcontractors, or any system utilized by the Customer to access the
Services, whose compliance with the terms of this Contract is the responsibility of the
Customer. v) “U.S. Intellectual Property Rights” means intellectual property rights enforceable in the United States of America, including without limitation rights in trade secrets, copyrights, and U.S. patents.
2. CONTRACT FORMATION:
a) If this Contract results from a sealed bid offered in response to a solicitation conducted pursuant to Chapters 2 (commencing with section 10290), 3 (commencing with section 12100), and 3.6 (commencing with section 12125) of Part 2 of Division 2 of the Public Contract Code (PCC), then Contractor's bid is a firm offer to the State which is accepted by the issuance of this Contract and no further action is required by either party.
b) If this Contract results from a solicitation other than described in paragraph a), above, the Contractor's quotation or proposal is deemed a firm offer and this Contract document is the State's acceptance of that offer. c) If this Contract resulted from a joint bid, it shall be deemed one indivisible Contract. Each such joint Contractor will be jointly and severally liable for the performance of the entire Contract.
The State assumes no responsibility or obligation for the division of orders or purchases among joint Contractors.
3. COMPLETE INTEGRATION: This Contract, including any documents incorporated herein by express reference, is intended to be a complete integration and there are no prior or contemporaneous different or additional
agreements pertaining to the subject matter of the Contract.
4. SEVERABILITY: The Contractor and the State agree that if any provision of this Contract is found to be illegal or unenforceable, such term or provision shall be deemed stricken and the remainder of the Contract shall remain in full force and effect. Either party having knowledge of such term or provision shall
promptly inform the other of the presumed non-applicability of such provision.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 51 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 35 OF 61
5. INDEPENDENT CONTRACTOR: Contractor and the agents and employees of the Contractor, in the performance of this Contract, shall act in an independent capacity and not as officers or employees or agents of the State.
6. APPLICABLE LAW:
This Contract shall be governed by and shall be interpreted in accordance with the laws of the State of California; venue of any action brought with regard to this Contract shall be in Sacramento County, Sacramento, California. The United Nations Convention on Contracts for the International Sale of Goods shall not apply to this Contract.
7. COMPLIANCE WITH STATUTES AND REGULATIONS:
a) The State and the Contractor warrant and certify that in the performance of this Contract, it will comply with all applicable statutes, rules, regulations and orders of the United States and the State of California, including the California Information Practices Act (Civil Code sections 1798 et seq.). The Contractor agrees to indemnify, defend, and save harmless the State against any
loss, cost, damage or liability by reason of the Contractor’s violation of this provision.
b) The State will notify the Contractor of any such claim in writing and tender the defense thereof within reasonable time. c) The Contractor will have sole control of the defense of any action on such claim and all negotiations for its settlement or compromise; provided that (i) when substantial principles of government or public law are involved, when litigation might create precedent affecting future
State operations or liability, or when involvement of the State is otherwise mandated by law, the State may participate in such action at its own expense with respect to attorneys’ fees and costs (but not liability); (ii) where a settlement would impose liability on the State, affect principles of California government or public law, or impact the authority of the State, the Department of General Services or the Department of Technology, as applicable, will have the
right to approve or disapprove any settlement or compromise, which approval will not unreasonably be withheld or delayed; and (iii) the State will reasonably cooperate in the defense and in any related settlement negotiations. d) If this Contract is in excess of $554,000, it is subject to the requirements of the World Trade Organization (WTO) Government Procurement Agreement (GPA).
e) To the extent that this Contract falls within the scope of Government Code section 7405, the Contractor will be responsible to respond to and resolve any complaint brought to its attention, regarding accessibility of its products or Services. The State shall designate an authorized representative who will be responsible for submission to Contractor of complaints received by the State regarding the accessibility of Contractor’s products and Services. Contractor shall be
responsible to review and respond to all complaints regarding accessibility brought to the attention of the State. The State and Contractor shall work together to determine a reasonable response and resolution of all complaints. The State acknowledges that Contractor can satisfy its duty to respond to and resolve complaints under this provision by taking action it deems appropriate under the circumstances, which may in some instances include no further action
beyond responding to the complaint.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 52 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 36 OF 61
8. CONTRACTOR’S POWER AND AUTHORITY: The Contractor warrants that it has full power and authority to grant the rights herein granted and will reimburse the State for any loss, cost, liability, and expense (including reasonable attorney fees) arising out of any breach of this warranty.
Further, the Contractor avers that it will not enter into any arrangement with any third party which might abridge any rights of the State under this Contract.
a) The State will notify the Contractor of any such claim in writing and tender the defense thereof within a reasonable time; and b) The Contractor will have sole control of the defense of any action on such claim and all
negotiations for its settlement or compromise; provided that (i) when substantial principles of government or public law are involved, when litigation might create precedent affecting future State operations or liability, or when involvement of the State is otherwise mandated by law, the State may participate in such action at its own expense with respect to attorneys’ fees and
costs (but not liability); (ii) where a settlement would impose liability on the State, affect
principles of California government or public law, or impact the authority of the State, the Department of General Services or the Department of Technology, as applicable, will have the right to approve or disapprove any settlement or compromise, which approval will not unreasonably be withheld or delayed; and (iii) the State will reasonably cooperate in the
defense and in any related settlement negotiations.
9. ASSIGNMENT: This Contract shall not be assignable by the Contractor in whole or in part without the written consent of the State. The State’s consent shall not be unreasonably withheld or delayed. For the purpose of this paragraph, the State will not unreasonably prohibit the Contractor from freely assigning its right to payment, provided that the Contractor remains responsible for its obligations
hereunder.
10. WAIVER OF RIGHTS: Any action or inaction by the State or the failure of the State on any occasion, to enforce any right or provision of the Contract, shall not be construed to be a waiver by the State of its rights hereunder and shall not prevent the State from enforcing such provision or right on any future
occasion. Except as specifically set forth in Section 13 (Warranty) below, the rights and remedies of the State herein are cumulative and are in addition to any other rights or remedies that the State may have at law or in equity.
11. ORDER OF PRECEDENCE: In the event of any inconsistency between the articles, attachments, specifications or provisions
which constitute this Contract, the following order of precedence shall apply:
a) These Cloud Computing - Software as a Service General Provisions (In the instances provided herein where the paragraph begins: “Unless otherwise specified in the Statement of Work” provisions specified in the Statement of Work replacing these paragraphs shall take precedence over the paragraph referenced in these General Provisions);
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 53 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 37 OF 61
b) Contract form, e.g., Purchase Order STD 65, Standard Agreement STD 213, FISCal generated Purchase Order, etc., and any amendments thereto; c) The Cloud Computing Special Provisions – Software as a Service (hereafter referred to as, the “SaaS Special Provisions”), which are incorporated by reference unless specifically modified
and attached hereto, and other Special Provisions; d) Statement of Work, including any specifications incorporated by reference herein; e) Cost worksheets; f) The Service Provider’s service agreement and attachments; and g) All other attachments incorporated in the Contract by reference.
12. INSPECTION, ACCEPTANCE AND REJECTION: Unless otherwise specified in the Statement of Work:
a) When acquiring SaaS, the State shall rely on Contractor’s existing quality assurance system as a substitute for State inspection and testing.
b) For all other acquisitions, Contractor and its subcontractors will provide and maintain a quality
assurance system acceptable to the State covering Deliverables and Services under this Contract and will tender to the State only those Deliverables and Services that have been inspected and found to conform to this Contract’s requirements. The Contractor will keep records evidencing inspections and their result, and will make these records available to the
State during Contract performance and for three years after final payment. The Contractor
shall permit the State to review procedures, practices, processes, and related documents to determine the acceptability of the Contractor’s quality assurance system or other similar business practices related to performance of the Contract. c) In the event any Goods or Deliverables furnished by the Contractor in the performance of the Contract should fail to conform to the requirements herein, the State may reject the same, and
it shall become the duty of the Contractor to reclaim and remove the item promptly without expense to the State.
13. WARRANTY: a) Limited Warranty for Services. Unless otherwise specified in the Statement of Work, Contractor warrants that Services furnished hereunder will substantially conform to the
requirements of this Contract (including without limitation all descriptions, specifications, and drawings identified in the Statement of Work), and: i. Services will be performed in accordance with the Contract; and ii. All customer support for Services will be performed with professional care and skill. b) Duration of Limited Warranty. The limited warranty will be for the duration of State’s use of the
Services, unless the underlying Service Provider’s warranty is shorter in duration, in which case the parties will specify the length of the applicable limited warranty in the Statement of Work. This limited warranty is subject to the following limitations: i. any implied warranties, guarantees, or conditions not able to be disclaimed as a matter of law last for one year from the start of the limited warranty;
ii. the limited warranty does not cover problems caused by the State’s accident, abuse or use in a manner inconsistent with this Contract or any applicable service agreement, or resulting from events beyond Contractor’s reasonable control;
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 54 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 38 OF 61
iii. the limited warranty does not apply to components of Software that the State may be permitted to redistribute; iv. the limited warranty does not apply to free, trial, pre-release, or beta Services; and v. the limited warranty does not apply to problems caused by the State’s failure to meet
minimum system requirements. c) Remedies for breach of Limited Warranty. Unless otherwise specified in the Statement of Work, if Contractor fails to meet any of the above limited warranties and the State notifies Contractor within the warranty period, then the State’s remedy and the Contractor’s obligation will be re-performance, repair, replacement, or refund of fees paid. In the event the Contractor
fails to re- perform, repair, replace, or refund fees paid for the products and/or Services as appropriate, the State may terminate the Contract. d) Warranty for Software Products. Any Software Products provided by the Service Provider shall be covered by the developer’s consumer warranty that will be passed to the Customer.
e) DISCLAIMER OF OTHER WARRANTIES. OTHER THAN THIS LIMITED WARRANTY,
CONTRACTOR PROVIDES NO OTHER EXPRESS OR IMPLIED WARRANTIES OR CONDITIONS. CONTRACTOR DISCLAIMS ANY IMPLIED REPRESENTATIONS, WARRANTIES, OR CONDITIONS, INCLUDING WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, SATISFACTORY QUALITY, OR TITLE. THESE
DISCLAIMERS WILL APPLY UNLESS APPLICABLE LAW DOES NOT PERMIT THEM.
f) Contractor shall ensure that the Service Provider shall apply anti-malware controls to the Services to help avoid malicious software gaining unauthorized access to State Data, including malicious software originating from public networks. Such controls shall at all times equal or exceed the controls consistent with the industry standards for such data, but in no event less than the controls that Contractor applies to its own internal corporate electronic data of like
character. g) Unless otherwise specified elsewhere in the Contract: i. The Contractor does not warrant that any Services provided hereunder is error-free or that it will run without immaterial interruption; and ii. The Contractor does not warrant and will have no responsibility for a claim to the extent
that it arises directly from: a. a modification made by the State, unless such modification is approved or directed by the Contractor, b. use of Services in combination with software or services other than as specified by the Contractor, or
c. misuse by the State. h) All warranties, including special warranties specified elsewhere herein, shall inure to the State, its successors, assigns, customer agencies, and governmental users of the Deliverables or Services.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 55 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 39 OF 61
14. SAFETY AND ACCIDENT PREVENTION: In performing work under this Contract on State premises, the Contractor shall conform to any specific safety requirements contained in the Contract or as required by law or regulation. The Contractor shall take any additional precautions as the State may reasonably require for safety
and accident prevention purposes. Any violation of such rules and requirements, unless promptly corrected, shall be grounds for termination of this Contract in accordance with the default provisions hereof.
15. TERMINATION FOR NON-APPROPRIATION OF FUNDS: a) If the term of this Contract extends into fiscal years subsequent to that in which it is approved,
such continuation of the Contract is contingent on the appropriation of funds for such purpose by the Legislature or the United States Congress, if applicable. If funds to effect such continued payment are not appropriated, the Contractor agrees to terminate any services supplied to the State under this Contract, and relieve the State of any further obligation
therefor.
b) The State agrees that if it appears likely that subsection a) above will be invoked, the State and Contractor shall agree to take all reasonable steps to prioritize work and minimize the incurrence of costs prior to the expiration of funding for this Contract.
16. TERMINATION FOR THE CONVENIENCE OF THE STATE: a) The State may terminate performance under this Contract for its convenience in whole or, from
time to time, in part, if the Department of General Services, Deputy Director Procurement Division, or designee, determines that a termination is in the State’s interest. The Department of General Services, Deputy Director, Procurement Division, or designee, or the Department of Technology, Deputy Director, Statewide Technology Procurement, or designee, as applicable, shall terminate by delivering to the Contractor a Notice of Termination specifying the extent of
termination and the effective date thereof, which shall be no less than 15 days from the Notice of Termination date. b) After receipt of a Notice of Termination, and except as directed by the State, the Contractor shall immediately stop work as specified in the Notice of Termination, regardless of any delay in determining or adjusting any amounts due under this clause.
c) After termination, the Contractor shall submit a final termination settlement proposal to the State in the form and with the information prescribed by the State except that in no instance shall the Contractor seek nor will the State pay for Services not utilized or costs not specified on an order for Services regardless of Contractors’ liability or costs for materials, equipment, Software, facilities, or subcontracts. The Contractor shall submit the proposal promptly, but no
later than 30 days after the effective date of termination, unless a different time is provided in the Statement of Work or in the Notice of Termination. d) The Contractor and the State may agree upon the whole or any part of the amount to be paid or refunded as requested under subsection (c) above;
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 56 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 40 OF 61
e) Unless otherwise set forth in the Statement of Work, if the Contractor and the State fail to agree on the amount to be paid because of the termination for convenience. i. The State will pay the Contractor the Contract price for Services accepted or utilized by the State; provided that in no event will total payments exceed the amount payable to the
Contractor if the Contract had been fully performed. f) The Contractor will use generally accepted accounting principles, or accounting principles otherwise agreed to in writing by the parties, and sound business practices in determining all costs claimed, agreed to, or determined under this clause.
17. TERMINATION FOR DEFAULT:
a) The State may, subject to the clause titled “18. Force Majeure”, by written notice of default to the Contractor, terminate this Contract in whole or in part if the Contractor fails to: i. Perform the Services within the time specified in the Contract or any amendment thereto; ii. Make progress, so that the lack of progress endangers performance of this Contract; or
iii. Perform any of the other provisions of this Contract.
b) The State’s right to terminate this Contract under subsection a) above, may be exercised only if the failure constitutes a material breach of this Contract and if the Contractor does not cure such failure within the time frame stated in the State’s cure notice, which in no event will be less than 30 days, unless otherwise provided.
c) Both parties, State and Contractor, upon any termination for default, have a duty to mitigate
the damages suffered by it. The State shall pay Contract price for completed and accepted Deliverables and Services. d) The rights and remedies of the State in this clause are in addition to any other rights and remedies provided by law or under this Contract and are subject to the clause titled “20. Limitation of Liability.”
18. FORCE MAJEURE: Except for defaults of subcontractors at any tier, and any Contractor responsibilities concerning disaster recovery and/or business continuity, the Contractor shall not be liable for any excess costs if the failure to perform the Contract arises from causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include, but are not limited to:
a) Acts of God or of the public enemy, and b) Acts of the federal or State government in either its sovereign or contractual capacity.
If the failure to perform is caused by the default of a subcontractor at any tier, and if the cause of the default is beyond the control of both the Contractor and subcontractor, and without the fault or negligence of either, the Contractor shall not be liable for any excess costs for failure to perform.
19. RIGHTS AND REMEDIES OF STATE FOR DEFAULT: a) In the event of the termination of the Contract, either in whole or in part, by reason of default or breach by the Contractor, any subsequent loss or damage sustained by the State in procuring any Deliverables or Services which the Contractor agreed to supply shall be borne and paid for by the Contractor (but subject to the clause entitled “Limitation of Liability”); and
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 57 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 41 OF 61
b) The State reserves the right to offset the reasonable cost of all damages caused to the State against any outstanding invoices or amounts owed to the Contractor or to make a claim against the Contractor therefore.
20. LIMITATION OF LIABILITY:
a) Except as may be otherwise approved by the Department of General Services Deputy Director, Procurement Division or their designee, or the Department of Technology, Deputy Director, Statewide Technology Procurement, or designee, as applicable, Contractor’s liability for damages to the State for any cause whatsoever, and regardless of the form of action, whether in Contract or in tort, shall be limited to the Purchase Price. For purposes of this
subsection a), “Purchase Price” will mean the aggregate Contract price; except that, with respect to a Contract under which multiple purchase orders will be issued (e.g., a Master Agreement or Multiple Award Schedule contract), “Purchase Price” will mean the total price of the purchase order for the Deliverable(s) or Service(s) that gave rise to the loss, such that the
Contractor will have a separate limitation of liability for each purchase order.
b) The foregoing limitation of liability shall not apply: i. to any liability under provisions herein entitled “Compliance with Statutes and Regulations”; ii. to liability under provisions herein entitled “Patent, Copyright, and Trade Secret Indemnity” or to any other liability (including without limitation indemnification obligations) for
infringement of third party intellectual property rights;
iii. to claims arising under provisions herein calling for indemnification for third party claims against the State for death, bodily injury to persons or damage to real or tangible personal property caused by the Contractor’s negligence or willful misconduct; iv. to costs or attorney’s fees that the State becomes entitled to recover as a prevailing party in any action; or
v. to direct costs of mitigation, remediation, and/or notification obligations set forth in the SaaS Special Provisions, resulting from any Data Breach as defined therein, and resulting from the Contractor’s failure to perform or negligent acts of its personnel. c) The State’s liability for damages for any cause whatsoever, and regardless of the form of action, whether in Contract or in tort, shall be limited to the Purchase Price, as that term is
defined in subsection a) above. Nothing herein shall be construed to waive or limit the State’s sovereign immunity or any other immunity from suit provided by law. d) IN NO EVENT WILL EITHER THE CONTRACTOR OR THE STATE BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, INDIRECT, SPECIAL, OR PUNITIVE DAMAGES, EVEN IF NOTIFICATION HAS BEEN GIVEN AS TO THE POSSIBILITY OF SUCH DAMAGES,
EXCEPT (I) TO THE EXTENT THAT THE CONTRACTOR’S LIABILITY FOR SUCH DAMAGES IS SPECIFICALLY SET FORTH IN THE STATEMENT OF WORK OR (II) TO THE EXTENT THAT THE CONTRACTOR’S LIABILITY FOR SUCH DAMAGES ARISES OUT OF SUBSECTION b)(i), b)(ii), OR b)(iv) ABOVE.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 58 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 42 OF 61
21. INDEMNIFICATION: The Contractor agrees to indemnify, defend and save harmless the State, its officers, agents and employees from any and all third party claims, costs (including without limitation reasonable attorneys’ fees), and losses due to the injury or death of any individual, or the loss or damage to
any real or tangible personal property, resulting from the willful misconduct or negligent acts or omissions of the Contractor or any of its affiliates, agents, subcontractors, employees, suppliers, or laborers furnishing or supplying work, Services, materials, or supplies in connection with the performance of this Contract. Such defense and payment will be conditional upon the following:
a) The State will notify the Contractor of any such claim in writing and tender the defense thereof
within a reasonable time; and b) The Contractor will have sole control of the defense of any action on such claim and all negotiations for its settlement or compromise; provided that i. when substantial principles of government or public law are involved, when litigation might
create precedent affecting future State operations or liability, or when involvement of the
State is otherwise mandated by law, the State may participate in such action at its own expense with respect to attorneys’ fees and costs (but not liability); ii. where a settlement would impose liability on the State, affect principles of California government or public law, or impact the authority of the State, the Department of General
Services or the Department of Technology, as applicable, will have the right to approve or
disapprove any settlement or compromise, which approval will not unreasonably be withheld or delayed; and iii. the State will reasonably cooperate in the defense and in any related settlement negotiations. 22. INVOICES:
Unless otherwise specified, invoices shall be sent to the address set forth herein. Invoices shall be submitted in triplicate and shall include the Contract number; release order number (if applicable); item number; unit price, extended item price and invoice total amount. State sales tax and/or use tax shall be itemized separately and added to each invoice as applicable.
23. REQUIRED PAYMENT DATE:
Payment will be made in accordance with the provisions of the California Prompt Payment Act, Government Code section 927 et. seq. Unless expressly exempted by statute, the Act requires State agencies to pay properly submitted, undisputed invoices not more than 45 days after:
a) the date of acceptance of Deliverables or performance of Services; or b) receipt of an undisputed invoice, whichever is later.
24. TAXES: Unless otherwise required by law:
a) the State of California is exempt from Federal excise taxes; and b) the State will only pay for any applicable State or local sales or use taxes on the services rendered or Goods supplied to the State pursuant to this Contract.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 59 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 43 OF 61
25. CONTRACT MODIFICATION: a) No amendment or variation of the terms of this Contract shall be valid unless made in writing, signed by the parties and approved as required. No oral understanding or agreement not incorporated in the Contract is binding on any of the parties.
b) Notwithstanding subsection a) above, service agreements may be modified by Contractor from time to time, but any such modifications will not degrade the functionality or security features of the SaaS. Service agreements shall be subject to section 11(f) Order of Precedence.
26. CONFIDENTIALITY OF DATA: a) All Customer Data made available to the Contractor in order to carry out this Contract, or which
become available to the Contractor in carrying out this Contract, shall be protected by the Contractor from unauthorized use and disclosure by use of the same or more effective confidentiality requirements as are applicable to the State. The identification of all such confidential data and information as well as the State's confidentiality requirements for
protection of such data and information from unauthorized use and disclosure shall be
provided by the State in writing to the Contractor. If the methods and procedures employed by the Contractor for the protection of the Contractor's data and information are deemed by the State to be adequate for the protection of the State's confidential information, such methods and procedures may be used, with the written consent of the State, to carry out the intent of
this paragraph. Any additional requirements to ensure confidentiality of data shall be set forth
in the SOW. The Contractor shall not be required under the provisions of this paragraph to keep confidential any data or information which is or becomes publicly available, is already rightfully in the Contractor's possession without obligation of confidentiality, is independently developed by the Contractor outside the scope of this Contract, or is rightfully obtained from
third parties. Contractor shall sign a security and confidentiality statement. Contractor is
responsible for all Contractor personnel assigned to this Contract and will have appropriate agreements in place to enable Contractor to meet its obligations hereunder. b) The parties acknowledge information transmitted by the State to the Contractor and/or Service Provider may inadvertently contain Federal Tax Information (FTI). The State will use all reasonable efforts to prevent the transmittal of FTI to Contractor and/or Service Provider under
this Contract. The State further acknowledges that the Contractor and/or Service Provider does not require any “access” to, or “receipt” or “storage” of FTI to perform the Services under the Contract. The Contractor and/or Service Provider further acknowledges that Contractor and/or Service Provider shall not knowingly access or permit access to such FTI, unless directed by the State. Access to FTI is out-of-scope of the Services. To the extent that
Contractor’s and/or Service Provider’s access to FTI is “incidental” to Contractor’s provision of Services, it is the parties’ view that such incidental exposure should not legally subject Contractor and/or Service Provider to the Internal Revenue Service (IRS) requirements set forth in IRS Publication 1075, section 11.2. If, however, the IRS ultimately takes a contrary position, and determines that Contractor, Service Provider and/or the State should have
nevertheless complied with the requirements of IRS Publication 1075, the parties will immediately commence an evaluation of the feasibility of continued performance under the Contract.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 60 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 44 OF 61
27. NEWS RELEASES: Unless otherwise exempted, news releases, endorsements, advertising, and social media content pertaining to this Contract shall not be made without prior written approval of the Department of General Services.
28. DOCUMENTATION: The Contractor agrees to provide to the State, at no charge, all Documentation as described within the Statement of Work, and updated versions thereof, which are necessary or useful to the State in its use of the equipment, Services, or Software provided hereunder. The Contractor agrees to provide additional Documentation at prices not in excess of charges made by the
Contractor to its other customers for similar Documentation.
29. RIGHTS IN WORK PRODUCT: a) All inventions, discoveries, intellectual property, technical communications and records originated or prepared by the Contractor pursuant to this Contract including papers, reports,
charts, customized software, and other Documentation or improvements thereto, and including
the Contractor’s administrative communications and records relating to this Contract (collectively, the “Work Product”), shall be the Contractor’s exclusive property. The provisions of this subsection “a)” may be revised in a Statement of Work. b) Software, other components of SaaS, and materials developed or otherwise obtained by or for the Contractor or its affiliates independently of this Contract or applicable purchase order
(“Pre-Existing Materials”) do not constitute Work Product. If the Contractor creates derivative works of Pre-Existing Materials, the elements of such derivative works created pursuant to this Contract constitute Work Product, but other elements do not. Nothing in this Section 29 will be construed to interfere with the Contractor’s or its affiliates’ ownership of Pre- Existing Materials. c) The State will have Government Purpose Rights to the Work Product as Deliverable or
delivered to the State hereunder. “Government Purpose Rights” are the unlimited, irrevocable, worldwide, perpetual, royalty-free, non-exclusive rights and licenses to use, modify, reproduce, perform, release, display, create derivative works from, and disclose the Work Product. “Government Purpose Rights” also include the right to release or disclose the Work Product outside the State for any State government purpose and to authorize recipients to use, modify,
reproduce, perform, release, display, create derivative works from, and disclose the Work Product for any State government purpose. Such recipients of the Work Product may include, without limitation, State contractors, California local governments, the U.S. federal government, and the state and local governments of other states. “Government Purpose Rights” do not include any rights to use, modify, reproduce, perform, release, display, create
derivative works from, or disclose the Work Product for any commercial purpose. This subsection and the rights thereunder may be modified as required for federally funded SaaS pursuant to federal law or regulations, including, but not limited to, 7 CFR 277.18 and 45 CFR 95.617.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 61 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 45 OF 61
d) The ideas, concepts, know-how, or techniques relating to data processing, developed during the course of this Contract by the Contractor or jointly by the Contractor and the State, may be used by either party without obligation of notice or accounting. e) This Contract shall not preclude the Contractor from developing materials outside this Contract
that are competitive, irrespective of their similarity to materials which might be delivered to the State pursuant to this Contract.
30. SOFTWARE LICENSE: A Service may require the use of Software Products to facilitate use of the Service. Unless otherwise specified in the Statement of Work, the Contractor hereby grants to the State and the
State accepts from the Contractor, subject to the terms and conditions of this Contract, a royalty- free, non-exclusive license to use the Software Products in this Contract. The State may use the Software Products only in connection with use of the Service and according to any licensing terms if specified in a Statement of Work or otherwise in the Contract. Acceptance of Software (including
third party Software) will be governed by the terms and conditions of this Contract.
31. PROTECTION OF PROPRIETARY SOFTWARE AND OTHER PROPRIETARY DATA: a) The State agrees that all material appropriately marked or identified in writing as proprietary and furnished hereunder by the Contractor are provided for the State’s exclusive use for the purposes of this Contract only. All such proprietary data shall remain the property of the
Contractor. The State agrees to take all reasonable steps to ensure that such proprietary data
are not disclosed to others, without prior written consent of the Contractor, subject to the California Public Records Act, or other lawful process (e.g., in response to a subpoena); b) The State will ensure, prior to disposing of any media, that any licensed materials contained thereon have been erased or otherwise destroyed; and c) The State agrees that it will take appropriate action by instruction, agreement or otherwise with
its employees or other persons permitted access to proprietary data to satisfy its obligations in this Contract with respect to use, copying, modification, protection and security of proprietary materials and data, subject to the California Public Records Act and other applicable law.
32. FUTURE RELEASES: Unless otherwise specifically provided in the Statement of Work, if improved versions (e.g.,
patches, bug fixes, updates or releases) or upgrades of any SaaS versions or Software Product are developed by the Contractor, and are made available to other customers, they will be made available to the State at no additional cost only if such are made available to other customers at no additional cost.
33. ENCRYPTION AND AUTHORIZATION KEYS:
Upon initiation of Service, Contractor will provide all encryption and authorization keys required by the State to operate or access the Software Products or Services.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 62 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 46 OF 61
34. PATENT, COPYRIGHT AND TRADE SECRET INDEMNITY: a) Contractor will indemnify, defend, and save harmless the State, its officers, agents, and employees, from any and all third party claims, costs (including without limitation reasonable attorneys’ fees), and losses for infringement or violation of any U.S. Intellectual Property Right
by any product or service provided hereunder. With respect to claims arising from Software manufactured by a third party and sold by Contractor as a reseller, Contractor will pass through to the State such indemnity rights as it receives from such third party (“Third Party Obligation”) and will cooperate in enforcing them; provided that if the third party manufacturer fails to honor the Third Party Obligation, Contractor will provide the State with indemnity
protection equal to that called for by the Third Party Obligation, but in no event greater than that called for in the first sentence of this Section). Unless a Third Party Obligation provides otherwise, the defense and payment obligations set forth in this Section will be conditional upon the following:
i. The State will notify the Contractor of any such claim in writing and tender the defense
thereof within a reasonable time; and ii. The Contractor will have sole control of the defense of any action on such claim and all negotiations for its settlement or compromise; provided that when substantial principles of government or public law are involved, when litigation might create precedent affecting
future State operations or liability, or when involvement of the State is otherwise mandated
by law, the State may participate in such action at its own expense with respect to attorneys’ fees and costs (but not liability); (b) where a settlement would impose liability on the State, affect principles of California government or public law, or impact the authority of the State, the Department of General Services or the Department of Technology, as
applicable, will have the right to approve or disapprove any settlement or compromise,
which approval will not unreasonably be withheld or delayed; and (c) the State will reasonably cooperate in the defense and in any related settlement negotiations. b) Should the Software Products or Services, or the operation thereof, become, or in the Contractor's opinion are likely to become, the subject of a claim of infringement or violation of a U.S. Intellectual Property Right, the State shall, subject to prior approval, permit the
Contractor, at its option and expense, either to procure for the State the right to continue using the Services, or to replace or modify the same so that they become non-infringing. If none of these options can reasonably be taken, or if the use of such Services by the State shall be prevented by injunction, the State shall then have the option of terminating this Contract, or applicable portions thereof, without penalty or termination charge and the Contractor shall
refund any sums the State has paid the Contractor less any reasonable amount for use or damage. c) The Contractor shall have no liability to the State under any provision of this clause with respect to any claim of patent, copyright or trade secret infringement which is based upon: i. The combination or utilization of Deliverables furnished hereunder with Goods or Software
not made or furnished by the Contractor; or ii. The combination or utilization of Software or Services not made or furnished by the Contractor, and introduced into the States computing environment; or iii. The modification initiated by the State, or a third party at the State’s direction, of any Software or Service furnished hereunder; or
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 63 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 47 OF 61
iv. The combination or utilization of Software furnished hereunder with non- Contractor supplied Software. d) The Contractor certifies that it has appropriate systems and controls in place to ensure that State funds will not be used in the performance of this Contract for the acquisition, operation or
maintenance of Software in violation of any U.S. Intellectual Property laws.
35. DISPUTES: a) The parties shall deal in good faith and attempt to resolve potential disputes informally. If the dispute persists, the Contractor shall submit to the contracting Department Director or designee a written demand for a final decision regarding the disposition of any dispute
between the parties arising under, related to or involving this Contract. Contractor’s written demand shall be fully supported by factual information, and if such demand involves a cost adjustment to the Contract, the Contractor shall include with the demand a written statement signed by an authorized person indicating that the demand is made in good faith, that the
supporting data are accurate and complete and that the amount requested accurately reflects
the Contract adjustment for which Contractor believes the State is liable. The contracting Department Director or designee shall have 30 days after receipt of Contractor’s written demand invoking this Section “Disputes” to render a written final decision. If a written decision is not rendered within 30 days after receipt of the Contractor’s demand, it shall be deemed a
final decision adverse to the Contractor’s contention.
b) Pending the final resolution of any dispute arising under, related to or involving this Contract, Contractor agrees to diligently proceed with the performance of this Contract, including the delivery of Goods or providing of Services in accordance with the State’s instructions regarding this Contract. Contractor’s failure to diligently proceed in accordance with the State’s instructions regarding this Contract shall be considered a material breach of this Contract.
c) Any final decision of the State shall be expressly identified as such, shall be in writing, and shall be signed by the contracting Department Director, or designee. The State’s final decision shall be conclusive and binding regarding the dispute unless the Contractor commences an action in a court of competent jurisdiction to contest such decision within 90 days following the date of the final decision or 1 year following the accrual of the cause of action, whichever is
later. d) For disputes involving purchases made by the Department of General Services, Procurement Division, the Contractor shall submit to the Department Director or designee a written demand for a final decision, which shall be fully supported in the manner described in subsection a) above. The Department Director or designee shall have 30 days to render a final decision. If a
final decision is not rendered within 30 days after receipt of the Contractor’s demand, it shall be deemed a final decision adverse to the Contractor’s contention. The final decision shall be conclusive and binding regarding the dispute unless the Contractor commences an action in a court of competent jurisdiction to contest such decision within 90 days following the date of the final decision or 1 year following the accrual of the cause of action, whichever is later.
e) The dates of decision in this section may be modified by mutual consent, as applicable, excepting the time to commence an action in a court of competent jurisdiction.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 64 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 48 OF 61
36. STOP WORK: a) The State may, at any time, by written Stop Work Order to the Contractor, require the Contractor to stop all, or any part, of the called for by this Contract in the Statement of Work for a period up to 45 days after the Stop Work Order is delivered to the Contractor, and for any
further period to which the parties may agree. The Stop Work Order shall be specifically identified as such and shall indicate it is issued under this clause. Upon receipt of the Stop Work Order, the Contractor shall immediately comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the work covered by the Stop Work Order during the period of work stoppage. Within a period of 45 days after a Stop Work Order
is delivered to the Contractor, or within any extension of that period to which the parties shall have agreed, the State shall either: i. Cancel the Stop Work Order; or ii. Terminate the work covered by the Stop Work Order as provided for in the Termination for
Default or the Termination for Convenience clause of this Contract.
b) If a Stop Work Order issued under this clause is canceled or the period of the Stop Work Order or any extension thereof expires, the Contractor shall resume work. The State shall make an equitable adjustment in the delivery schedule, the Contract price, or both, and the Contract shall be modified, in writing, accordingly, if:
i. The Stop Work Order results in an increase in the time required for, or in the Contractor’s
cost properly allocable to the performance of any part of this Contract; and ii. The Contractor asserts its right to an equitable adjustment within 60 days after the end of the period of work stoppage; provided, that if the State decides the facts justify the action, the State may receive and act upon a proposal submitted at any time before final payment under this Contract.
c) If a Stop Work Order is not canceled and the work covered by the Stop Work Order is terminated in accordance with the provision entitled Termination for the Convenience of the State, the State shall allow reasonable costs resulting from the Stop Work Order in arriving at the termination settlement. d) The State shall not be liable to the Contractor for loss of profits because of a Stop Work Order
issued under this clause.
37. EXAMINATION AND AUDIT: The Contractor agrees that the State or its designated representative shall have the right to review and copy any records and supporting documentation directly pertaining to performance of this Contract. The Contractor agrees to maintain such records for possible audit for a minimum of
three years after final payment, unless a longer period of records retention is stipulated. The Contractor agrees to allow the auditor(s) access to such records during normal business hours and in such a manner so as to not interfere unreasonably with normal business activities and to allow interviews of any employees or others who might reasonably have information related to such records. Further, the Contractor agrees to include a similar right of the State to audit records
and interview staff in any subcontract related to performance of this Contract. The State shall provide reasonable advance written notice of such audit(s) to the Contractor.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 65 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 49 OF 61
38. FOLLOW-ON CONTRACTS: a) If the Contractor or its affiliates provides Technical Consulting and Direction (as defined below), the Contractor and its affiliates: i. will not be awarded a subsequent Contract to supply the service or system, or any
significant component thereof, that is used for or in connection with any subject of such Technical Consulting and Direction; and ii. will not act as consultant to any person or entity that does receive a Contract described in subsection (i). This prohibition will continue for one year after termination of this Contract or completion of the Technical Consulting and Direction, whichever comes later.
b) “Technical Consulting and Direction” means services for which the Contractor received compensation from the State and includes: i. development of or assistance in the development of work statements, specifications, solicitations, feasibility studies, or project approval documentation;
ii. development or design of test requirements;
iii. evaluation of test data; iv. direction of or evaluation of another Contractor; v. provision of formal recommendations regarding the acquisition of Information Technology products or services; or
vi. provisions of formal recommendations regarding any of the above. For purposes of this
Section, “affiliates” are employees, directors, partners, joint venture participants, parent corporations, subsidiaries, or any other entity controlled by, controlling, or under common control with the Contractor. Control exists when an entity owns or directs more than 50 percent of the outstanding shares or securities representing the right to vote for the election of directors or other managing authority.
c) To the extent permissible by law, the Director of the Department of General Services, or designee, may waive the restrictions set forth in this Section by written notice to the Contractor if the Director determines their application would not be in the State’s best interest. Except as prohibited by law, the restrictions of this Section will not apply: i. to follow-on advice given by vendors of commercial off-the-shelf products, including
Software and Hardware, on the operation, integration, repair, or maintenance of such products after sale; or ii. where the State has entered into a master agreement for Software or services and the scope of work at the time of Contract execution expressly calls for future recommendations among the Contractor’s own products.
d) The restrictions set forth in this Section are in addition to conflict of interest restrictions imposed on public contractors by California law (“Conflict Laws”). In the event of any inconsistency, such Conflict Laws override the provisions of this Section, even if enacted after execution of this Contract.
39. PRIORITY HIRING CONSIDERATIONS:
If this Contract includes services in excess of $200,000, the Contractor shall give priority consideration in filling vacancies in positions funded by the Contract to qualified recipients of aid under Welfare and Institutions Code section 11200 in accordance with PCC section 10353.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 66 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 50 OF 61
40. COVENANT AGAINST GRATUITIES: The Contractor warrants that no gratuities (in the form of entertainment, gifts, or otherwise) were offered or given by the Contractor, or any agent or representative of the Contractor, to any officer or employee of the State with a view toward securing the Contract or securing favorable treatment
with respect to any determinations concerning the performance of the Contract. For breach or violation of this warranty, the State shall have the right to terminate the Contract, either in whole or in part and any loss or damaged sustained by the State in procuring on the open market any items which the Contractor agreed to supply shall be borne and paid for by the Contractor. The rights and remedies of the State provided in this clause shall not be exclusive and are in addition to any
other rights and remedies provided in law or equity.
41. NONDISCRIMINATION CLAUSE: a) During the performance of this Contract, the Contractor and its subcontractors shall not unlawfully discriminate, harass or allow harassment, against any employee or applicant for
employment because of sex, sexual orientation, race, color, ancestry, religious creed, national
origin, disability (including HIV and AIDS), medical condition (cancer), age, marital status, and denial of family care leave. The Contractor and subcontractors shall ensure that the evaluation and treatment of their employees and applicants for employment are free from such discrimination and harassment. The Contractor and subcontractors shall comply with the
provisions of the Fair Employment and Housing Act (Government Code, section 12990 et seq.)
and the applicable regulations promulgated thereunder (California Code of Regulations, Title 2, section 7285.0 et seq.). The applicable regulations of the Fair Employment and Housing Commission implementing Government Code section 12990 (a-f), set forth in Chapter 5 of Division 4 of Title 2 of the California Code of Regulations are incorporated into this Contract by
reference and made a part hereof as if set forth in full. The Contractor and its subcontractors
shall give written notice of their obligations under this clause to labor organizations with which they have a collective bargaining or other agreement; and b) The Contractor shall include the nondiscrimination and compliance provisions of this clause in all subcontracts to perform work under the Contract.
42. NATIONAL LABOR RELATIONS BOARD CERTIFICATION:
The Contractor swears under penalty of perjury that no more than one final, unappealable finding of contempt of court by a federal court has been issued against the Contractor within the immediately preceding two-year period because of the Contractor’s failure to comply with an order of the National Labor Relations Board. This provision is required by, and shall be construed in accordance with, PCC section 10296.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 67 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 51 OF 61
43. ASSIGNMENT OF ANTITRUST ACTIONS: Pursuant to Government Code sections 4552, 4553, and 4554, the following provisions are incorporated herein:
a) In submitting a bid to the State, the supplier offers and agrees that if the bid is accepted, it will
assign to the State all rights, title, and interest in and to all causes of action it may have under section 4 of the Clayton Act (15 U.S.C. 15) or under the Cartwright Act (Chapter 2, commencing with section 16700, of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of Goods, material or other items, or services by the supplier for sale to the State pursuant to the solicitation. Such assignment shall be made and become
effective at the time the State tender’s final payment to the supplier; b) If the State receives, either through judgment or settlement, a monetary recovery for a cause of action assigned under this chapter, the assignor shall be entitled to receive reimbursement for actual legal costs incurred and may, upon demand, recover from the State any portion of
the recovery, including treble damages, attributable to overcharges that were paid by the
assignor but were not paid by the State as part of the bid price, less the expenses incurred in obtaining that portion of the recovery; and c) Upon demand in writing by the assignor, the assignee shall, within one year from such demand, reassign the cause of action assigned under this part if the assignor has been or may
have been injured by the violation of law for which the cause of action arose and:
i. the assignee has not been injured thereby, or ii. the assignee declines to file a court action for the cause of action.
44. DRUG-FREE WORKPLACE CERTIFICATION: The Contractor certifies under penalty of perjury under the laws of the State of California that the Contractor will comply with the requirements of the Drug-Free Workplace Act of 1990
(Government Code section 8350 et seq.) and will provide a drug-free workplace by taking the following actions:
a) Publish a statement notifying employees that unlawful manufacture, distribution, dispensation, possession, or use of a controlled substance is prohibited and specifying actions to be taken against employees for violations, as required by Government Code section 8355(a);
b) Establish a Drug-Free Awareness Program as required by Government Code section 8355(b) to inform employees about all of the following: i. the dangers of drug abuse in the workplace; ii. the person's or organization's policy of maintaining a drug-free workplace; iii. any available counseling, rehabilitation and employee assistance programs; and,
iv. penalties that may be imposed upon employees for drug abuse violations. c) Provide, as required by Government Code section 8355(c), that every employee who works on the proposed or resulting Contract: i. will receive a copy of the company's drug-free policy statement; and ii. will agree to abide by the terms of the company's statement as a condition of employment
on the Contract.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 68 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 52 OF 61
45. FOUR-DIGIT DATE COMPLIANCE: Contractor warrants that it will provide only Four-Digit Date Compliant (as defined below) Deliverables and Services to the State. “Four-Digit Date Compliant” Deliverables and Services can accurately process, calculate, compare, and sequence date data, including without limitation date
data arising out of or relating to leap years and changes in centuries. This warranty and representation is subject to the warranty terms and conditions of this Contract and does not limit the generality of warranty obligations set forth elsewhere herein.
46. SWEATFREE CODE OF CONDUCT: a) Contractor declares under penalty of perjury that no equipment, materials, or supplies
furnished to the State pursuant to the Contract have been produced in whole or in part by sweatshop labor, forced labor, convict labor, indentured labor under penal sanction, abusive forms of child labor or exploitation of children in sweatshop labor, or with the benefit of sweatshop labor, forced labor, convict labor, indentured labor under penal sanction, abusive
forms of child labor or exploitation of children in sweatshop labor. The Contractor further
declares under penalty of perjury that they adhere to the Sweat free Code of Conduct as set forth on the California Department of Industrial Relations website located at www.dir.ca.gov, and Public Contract Code section 6108; and b) The Contractor agrees to cooperate fully in providing reasonable access to its records, documents, agents or employees, or premises if reasonably required by authorized officials of
the State, the Department of Industrial Relations, or the Department of Justice to determine the Contractor’s compliance with the requirements under paragraph (a).
47. RECYCLED CONTENT REQUIREMENTS: The Contractor shall certify in writing under penalty of perjury, the minimum, if not exact, percentage of post-consumer material (as defined in the PCC section 12200-12209), in products,
materials, goods, or supplies offered or sold to the State that fall under any of the statutory categories regardless of whether the product meets the requirements of Section 12209. The certification shall be provided by the contractor, even if the product or good contains no post- consumer recycled material, and even if the post-consumer content is unknown. With respect to printer or duplication cartridges that comply with the requirements of section 12156(e), the
certification required by this subdivision shall specify that the cartridges so comply (PCC 12205 (b)(2)). A state agency contracting officer may waive the certification requirements if the percentage of post-consumer material in the products, materials, goods, or supplies can be verified in a written advertisement, including, but not limited to, a product label, a catalog, or a manufacturer or vendor Internet web site. Contractors are to use, to the maximum extent
economically feasible in the performance of the contract work, recycled content products (PCC 12203(d)).
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Dec. 6, 2022 Item #5 Page 69 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 53 OF 61
48. CHILD SUPPORT COMPLIANCE ACT: For any Contract in excess of $100,000, the Contractor acknowledges in accordance with PCC section 7110, that:
a) The Contractor recognizes the importance of child and family support obligations and shall fully
b) comply with all applicable State and federal laws relating to child and family support enforcement, including, but not limited to, disclosure of information and compliance with earnings assignment orders, as provided in Chapter 8 (commencing with section 5200) of Part 5 of Division 9 of the Family Code; and c) The Contractor, to the best of its knowledge is fully complying with the earnings assignment
orders of all employees and is providing the names of all new employees to the New Hire Registry maintained by the California Employment Development Department.
49. AMERICANS WITH DISABILITIES ACT AND PUBLIC WEBSITE ACCESSIBILITY a) The Contractor assures the State that the Contractor complies with the Americans with
Disabilities Act of 1990 (42 U.S.C. 12101 et seq.). The State is responsible for ensuring that
public websites are accessible to both the general public and that internal electronic and Information Technology systems are accessible by state employees, including persons with disabilities. Contractor shall assist the State in meeting its responsibilities. b) In accordance with Cal. Gov. Code section 7405(b), the Contractor shall have an ongoing obligation to promptly respond to and resolve any complaint regarding accessibility of its
electronic and Information Technology products and Services that is brought to the attention of the Contractor, pursuant to Section 7(e) above.
50. ELECTRONIC WASTE RECYCLING ACT OF 2003: The Contractor certifies that it complies with the applicable requirements of the Electronic Waste Recycling Act of 2003, Chapter 8.5, Part 3 of Division 30, commencing with section 42460 of the
Public Resources Code. The Contractor shall maintain documentation and provide reasonable access to its records and documents that evidence compliance.
51. USE TAX COLLECTION: In accordance with PCC section 10295.1, the Contractor certifies that it complies with the requirements of section 7101 of the Revenue and Taxation Code. Contractor further certifies that
it will immediately advise the State of any change in its retailer’s seller’s permit or certification of registration or applicable affiliate’s seller’s permit or certificate of registration as described in subdivision (a) of PCC section 10295.1.
52. EXPATRIATE CORPORATIONS: Contractor hereby declares that it is not an expatriate corporation or subsidiary of an expatriate
corporation within the meaning of PCC sections 10286 and 10286.1, and is eligible to contract with the State.
53. DOMESTIC PARTNERS: For contracts over $100,000 executed or amended after January 1, 2007, the Contractor certifies that the Contractor is in compliance with Public Contract Code section 10295.3.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 70 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS)
STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Software as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 54 OF 61
54. SMALL BUSINESS PARTICIPATION AND DVBE PARTICIPATION REPORTING REQUIREMENTS: a) If for this Contract the Contractor made a commitment to achieve small business participation, then the Contractor must within 60 days of receiving final payment under this Contract (or
within such other time period as may be specified elsewhere in this Contract) report to the awarding department the actual percentage of small business participation that was achieved. (Govt. Code§ 14841.); and b) If for this Contract the Contractor made a commitment to achieve disabled veteran business enterprise (DVBE) participation, then Contractor must within 60 days of receiving final payment
under this Contract (or within such other time period as may be specified elsewhere in this Contract) certify in a report to the awarding department: (1) the total amount the prime Contractor received under the Contract; (2) the name and address of the DVBE(s) that participated in the performance of the Contract; (3) the amount each DVBE received from the
prime Contractor; (4) that all payments under the Contract have been made to the DVBE; and
(5) the actual percentage of DVBE participation that was achieved. A person or entity that knowingly provides false information shall be subject to a civil penalty for each violation. (Mil. & Vets. Code § 999.5(d); Govt. Code § 14841.)
55. LOSS LEADER: It is unlawful for any person engaged in business within this state to sell or use any article or
product as a “loss leader” as defined in section 17030 of the Business and Professions Code. (PCC 12104.5(b).).
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 71 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Infrastructure as a Service and Platform as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 55 OF 61
THESE SPECIAL PROVISIONS ARE ONLY TO BE USED FOR INFRASTRUCTURE AS A SERVICE (IaaS) AND PLATFORM AS A SERVICE (PaaS), AS DEFINED BELOW. THESE SPECIAL PROVISIONS ARE TO BE ATTACHED TO THE GENERAL PROVISIONS – INFORMATION TECHNOLOGY AND ACCOMPANIED BY, AT MINIMUM, A STATEMENT OF WORK (SOW) AND SERVICE LEVEL AGREEMENT (SLA). STATE AGENCIES MUST FIRST:
A. CLASSIFY THEIR DATA PURSUANT TO THE CALIFORNIA STATE ADMINISTRATIVE MANUAL (SAM) 5305.5;
B. CONSIDER THE FACTORS TO BE TAKEN INTO ACCOUNT WHEN SELECTING A PARTICULAR TECHNOLOGICAL APPROACH, IN ACCORDANCE WITH SAM 4981.1, 4983 AND 4983.1 AND THEN;
C. MODIFY THESE SPECIAL PROVISIONS THROUGH THE SOW AND/OR SLA TO MEET THE NEEDS OF EACH ACQUISITION. 1. DEFINITIONS:
a) “Authorized Persons” means the Service Provider’s employees, Contractors, subcontractors or other agents who need to access the State’s Data to enable the Service Provider to perform the services required. b) “Data Breach” means the unauthorized access that results in the use, disclosure, destruction, modification, loss or theft of the State’s unencrypted Personal Data or Non-Public Data.
c) “Individually Identifiable Health Information” means Information that is a subset of health information, including demographic information collected from an individual, and (1) is created or received by a health care provider, health plan, employer or health care clearinghouse; and (2) relates to the past, present or future physical or mental health or condition of an individual; the provision of health care to an individual; or the past, present or future payment for the provision
of health care to an individual; and (a) that identifies the individual; or (b) with respect to which there is a reasonable basis to believe the information can be used to identify the individual. d) “Infrastructure-as-a-Service” (IaaS) means the capability provided to the consumer is to provision processing, storage, networks and other fundamental computing resources where the consumer is able to deploy and run arbitrary software, which can include operating systems and
applications. The consumer does not manage or control the underlying cloud infrastructure but has control over operating systems, storage, deployed application; and possibly limited control of select networking components (e.g., host firewalls). e) “Non-Public Data” means data submitted to the Service Provider’s IaaS or PaaS Service, other than Personal Data, that is not subject to distribution to the public as public information. It
is deemed to be sensitive and confidential by the State because it contains information that is exempt by statute, regulation or policy from access by the general public as public information. f) “Personal Data” means data submitted to the Service Provider’s IaaS or PaaS Service that includes information relating to a person that identifies the person by name and has any of the
following personally identifiable information (PII): government-issued identification numbers
(e.g., Social Security, driver’s license, passport); financial account information, including account number, credit or debit card numbers; or protected health information (PHI) relating to a person.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 72 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Infrastructure as a Service and Platform as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 56 OF 61
g) “Platform-as-a-Service” (PaaS) means the capability provided to the consumer to deploy onto the cloud infrastructure consumer- created or -acquired applications created using programming languages and tools supported by the provider. This capability does not necessarily preclude the use of compatible programming languages, libraries, services and
tools from other sources. The consumer does not manage or control the underlying cloud infrastructure, including network, servers, operating systems or storage, but has control over the deployed applications and possibly application hosting environment configurations. h) “Protected Health Information” (PHI) means Individually Identifiable Health Information transmitted by electronic media, maintained in electronic media, or transmitted or maintained in
any other form or medium. PHI excludes education records covered by the Family Educational Rights and Privacy Act (FERPA) as amended, 20 U.S.C. 1232g, records described at 20 U.S.C. 1232g(a)(4)(B)(iv) and employment records held by a covered entity in its role as employer.
i) “Security Incident” means the potentially unauthorized access to Personal Data or Non-
Public Data the Service Provider believes could reasonably result in the use, disclosure or theft of the State’s unencrypted Personal Data or Non-Public Data within the possession or control of the Service Provider. A Security Incident may or may not turn into a Data Breach. j) “Service Level Agreement” (SLA) means a written agreement between both the State and
the Service Provider that is subject to the terms and conditions in this document that unless
otherwise agreed to includes (1) the technical service level performance promises, (i.e. metrics for performance and intervals for measure), (2) description of service quality, (3) identification of roles and responsibilities, (4) security responsibilities and notice requirements, how disputes are discovered and addressed, and (6) any remedies for performance failures.
k) “Service Provider” means the Contractor, subcontractors, agents, resellers, third parties and
affiliates who are providing the services agreed to under the Contract. l) “State Data” means all data created or in any way originating with the State, and all data that is the output of computer processing of or other electronic manipulation of any data that was created by or in any way originated with the State, whether such data or output is stored on the State’s hardware, the Service Provider’s hardware or exists in any system owned, maintained
or otherwise controlled by the State or by the Service Provider. m) “State Identified Contact” means the person or persons designated in writing by the State to receive Security Incident or Data Breach notification. n) “Statement of Work” (SOW) means a written statement in a Contract that describes the State’s service needs and expectations.
2. DATA OWNERSHIP: The State will own all right, title and interest in State Data that is related to the services provided by this Contract. The Service Provider shall not access State user accounts or State Data, except in the course of data center operations, (2) in response to service or technical issues, (3) as required by the express terms of this Contract, (4) at the State’s written request or (5) as required
by law.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 73 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Infrastructure as a Service and Platform as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 57 OF 61
3. DATA PROTECTION: Protection of personal privacy and data shall be an integral part of the business activities of the Service Provider to ensure there is no inappropriate or unauthorized use of State information at any time. To this end, the Service Provider shall safeguard the confidentiality, integrity and
availability of State information within its control and comply with the following conditions:
a) In addition to the Compliance with Statues and Regulations provisions set forth in the General Provisions – Information Technology, the Service Provider shall comply as required with: i. The California Information Practices Act (Civil Code Sections 1798 et seq). ii. NIST Special Publication 800-53 Revision 4 or its successor.
iii. Privacy provisions of the Federal Privacy Act of 1974. b) All State Data obtained by the Service Provider within its control in the performance of this Contract shall become and remain the property of the State. c) Unless otherwise set forth in the SOW and/or SLA, Personal Data and Non-Public Data shall
be encrypted at rest, in use, and in transit with controlled access. The SOW and/or SLA will
specify which party is responsible for encryption and access control of the State Data for the service model under Contract. If the SOW and/or SLA and the Contract are silent, then the State is responsible for encryption and access control. d) Unless otherwise set forth in the SOW and/or SLA, it is the State’s responsibility to identify
data it deems as Non-Public Data to the Service Provider. The level of protection and
encryption for all Non-Public Data shall be identified and made a part of this Contract. e) At no time shall any Personal Data and Non-Public Data or processes — which either belong to or are intended for the use of State or its officers, agents or employees — be copied, disclosed or retained by the Service Provider or any party related to the Service Provider for subsequent use in any transaction without the express written consent of the State except as
permitted in Section 2 above. f) (For PaaS Only) Encryption of Data at Rest: The Service Provider shall ensure hard drive encryption consistent with validated cryptography standards as referenced in FIPS 140-2, Security Requirements for Cryptographic Modules for all Personal Data and Non-Public Data, unless the Service Provider presents a justifiable position approved by the State that Personal
Data and Non-Public Data must be stored on a Service Provider portable device in order to accomplish work as defined in the SOW and/or SLA.
4. DATA LOCATION: The Service Provider shall provide its services to the State and its end users solely from data centers in the continental United States. Storage of State Data at rest shall be located solely in
data centers in the continental United States. The Service Provider shall not allow its personnel or contractors to store State Data on portable devices, including personal computers, except for devices that are used and kept only at its U.S. data centers. The Service Provider shall permit its personnel and contractors to access State Data remotely only as required to provide technical user support or other customer support. The Service Provider may provide technical user support
or other customer support on a 24/7 basis using a Follow the Sun model, unless otherwise prohibited in this Contract.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 74 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Infrastructure as a Service and Platform as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 58 OF 61
5. SECURITY INCIDENT OR DATA BREACH NOTIFICATION: The Service Provider shall inform the State of any Security Incident or Data Breach related to State Data within the possession or control of the Service Provider and related to the service provided under this Contract.
a) Security Incident Reporting Requirements: Unless otherwise set forth in the SOW and/or SLA, the Service Provider shall promptly report a Security Incident related to its service under the Contract to the appropriate State Identified Contact as defined in the SOW and/or SLA. b) Breach Reporting Requirements: If the Service Provider has actual knowledge of a confirmed Data Breach that affects the security of any State Data that is subject to applicable Data
Breach notification law, the Service Provider shall (1) promptly notify the appropriate State Identified Contact within 24 hours or sooner, unless otherwise required by applicable law, and (2) take commercially reasonable measures to address the Data Breach in a timely manner. c) (For PaaS Only) Incident Response: The Service Provider may need to communicate with
outside parties regarding a Security Incident, which may include contacting law enforcement,
fielding media inquiries and seeking external expertise as mutually agreed upon, defined by law or contained in the contract. Discussing Security Incidents with the State should be handled on an urgent as- needed basis, as part of Service Provider communication and mitigation processes as mutually agreed, defined by law or contained in the Contract.
6. DATA BREACH RESPONSIBILITIES:
This section only applies when a Data Breach occurs with respect to Personal Data and/or Non- Public Data within the possession or control of a Service Provider and related to service provided under this Contract.
a) The Service Provider, unless otherwise set forth in in the SOW and/or SLA, shall promptly notify the appropriate State Identified Contact within 24 hours or sooner by telephone, unless
shorter time is required by applicable law, if it confirms that there is or reasonably believes that there has been a Data Breach. The Service Provider shall (1) cooperate with the State as reasonably requested by the State to investigate and resolve the Data Breach; (2) promptly implement necessary remedial measures, if necessary; and (3) document responsive actions taken related to the Data Breach, including any post-incident review of events and actions
taken to make changes in business practices in providing the services, if necessary. b) Service Provider will provide daily updates, or more frequently if required by the State, regarding findings and actions performed by Service Provider to the State Identified Contact until the Data Breach has been effectively resolved to the State’s satisfaction. c) Service Provider shall quarantine the Data Breach, ensure secure access to Data, and repair
IaaS and/or PaaS as needed in accordance with the SOW and/or SLA. Failure to do so may result in the State exercising its options for assessing damages or other remedies under this Contract.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 75 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Infrastructure as a Service and Platform as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 59 OF 61
d) Unless otherwise set forth in the SOW and/or SLA, if a Data Breach is a direct result of the Service Provider’s breach of its Contract obligation to encrypt Personal Data and/or Non-Public Data or otherwise prevent its release, the Service Provider shall bear the costs associated with (1) the investigation and resolution of the Data Breach; (2) notifications to individuals,
regulators or others required by State law; (3) a credit monitoring service required by State (or Federal) law; (4) a website or a toll-free number and call center for affected individuals required by State law; and (5) complete all corrective actions as reasonably determined by the Service Provider based on root cause; all [(1) through (5)] subject to this Contract’s Limitation of Liability provision as set forth in the General Provisions – Information Technology.
7. NOTIFICATION OF LEGAL REQUESTS: Unless otherwise required by law, the Service Provider shall contact the State upon receipt of any electronic discovery, litigation holds, discovery searches and expert testimonies related to the State’s Data under this Contract, or which in any way might reasonably require access to State’s
Data. The Service Provider shall not respond to subpoenas, service of process and other legal
requests related to the State without first notifying the State, unless prohibited by law from providing such notice. Unless otherwise required by law, Service Provider agrees to provide its intended responses to the State with adequate time for the State to review, revise and, if necessary, seek a protective order in a court of competent jurisdiction. Service Provider shall not
respond to legal requests directed at the State unless authorized in writing to do so by the State.
8. DATA PRESERVATION AND RETRIEVAL: a) For 90 days prior to the expiration date of this Contract, or upon notice of termination of this Contract, Service Provider shall assist the State in extracting and/or transitioning all State Data in the format determined by the State (“Transition Period”). b) The Transition Period may be modified in the SOW and/or SLA or as agreed upon in writing by
the parties in a Contract amendment. c) During the Transition Period, IaaS and/or PaaS and State Data access shall continue to be made available to the State without alteration. d) Service Provider agrees to compensate the State for damages or losses the State incurs as a result of Service Provider’s failure to comply with this section in accordance with the “Limitation
of Liability” provision set forth in the General Provisions - Information Technology. e) The State at its option, may purchase additional transition services as agreed upon in the SOW and/or SLA. f) During any period of suspension, the Service Provider shall not take any action to intentionally erase any State Data.
g) The Service Provider will impose no additional fees for access and retrieval of State Data by the State during the Transition Period. h) After termination of the Contract and the prescribed retention period, the Service Provider shall securely dispose of all State Data in all forms. State Data shall be permanently deleted and shall not be recoverable, according to NIST-approved methods. Certificates of destruction shall
be provided to the State.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 76 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Infrastructure as a Service and Platform as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 60 OF 61
9.BACKGROUND CHECKS:As permitted or required by law, the Service Provider shall conduct criminal background checksand not utilize any staff, including subcontractors, to fulfill the obligations of the Contract who havebeen convicted of any crime of dishonesty, including but not limited to criminal fraud, or otherwise
convicted of any felony or any misdemeanor offense for which incarceration for up to 1 year is anauthorized penalty. The Service Provider shall promote and maintain an awareness of theimportance of securing the State’s information among the Service Provider’s employees andagents.
10. ACCESS TO SECURITY LOGS AND REPORTS:
a)(For IaaS Only) Upon request, the Service Provider shall provide reports to the State directlyrelated to the infrastructure the Service Provider controls upon which the State accountresides. Unless otherwise agreed to in the SLA, the Service Provider shall provide the State ahistory of all Application Program Interface (API) calls for the State account that includes the
identity of the API caller, the time of the API call, the source IP address of the API caller, the
request parameters and the response elements returned by the Service Provider. The reportwill be sufficient to enable the State to perform security analysis, resource change tracking andcompliance auditing.b)(For PaaS Only) Upon request, the Service Provider shall provide reports to the State in aformat as specified in the SOW and/or SLA and agreed to by both the Service Provider and the
State. Reports will include latency statistics, user access, user access IP address, user accesshistory and security logs for all State files related to this Contract.c)The Service Provider and the State recognize that security responsibilities are shared. TheService Provider is responsible for providing a secure infrastructure. The State is responsiblefor its secure guest operating system, firewalls and other logs captured within the guest
operating system. Specific shared responsibilities are identified within the SOW and/or SLA.
11. CONTRACT AUDIT:The Service Provider shall allow the State to audit conformance to the Contract terms. The Statemay perform this audit or Contract with a third party at its discretion and at the State’s expense.
12. DATA CENTER AUDIT:
The Service Provider shall undergo an annual Statement on Standards for AttestationEngagements (SSAE) No. 16 Service Organization Control (SOC) 2 Type II audit of its datacenters, or its successor at its own expense. The Service Provider shall provide a redactedversion of the audit report and Contractor’s plan to correct any negative findings upon request.The Service Provider may remove its proprietary information from the redacted version.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 77 of 103
CALIFORNIA MULTIPLE AWARD SCHEDULES (CMAS) STATE MODEL CLOUD COMPUTING SERVICES SPECIAL PROVISIONS (Infrastructure as a Service and Platform as a Service)
REVISED AND EFFECTIVE JANUARY 20, 2022 PAGE 61 OF 61
13. CHANGE CONTROL AND ADVANCE NOTICE:The Service Provider shall give advance notice (as agreed to by the parties and included in theSOW and/or SLA) to the State of any upgrades (e.g., major upgrades, minor upgrades, systemchanges) that is expected to materially and negatively impact service availability and performance,
as well as any planned downtime for such upgrades. A major upgrade is a replacement ofhardware, software or firmware ware with a newer or better version in order to bring the system upto date or to improve its characteristics. It usually includes a new version number. Service Providermay change the features and functionality of the services, without degrading them, to makeimprovements, address security requirements and comply with changes in law.
14. SECURITY PROCESSES:The Service Provider shall disclose its non-proprietary security processes and technical limitationsto the State such that adequate protection and flexibility can be attained between the State and theService Provider. The State and the Service Provider shall understand each other’s roles and
responsibilities, which shall be set forth in the SOW and/or SLA.
15. IMPORT AND EXPORT OF DATA:The State shall have the ability to import or export data in whole or in part at its discretion withoutinterference from the Service Provider. This includes the ability for the State to import or export datato or from other Service Providers.
16. RESPONSIBILITIES AND UPTIME GUARANTEE:
The Service Provider shall be responsible for the acquisition and operation of all hardware,software and network support related to the services being provided. The technical andprofessional activities required for establishing, managing and maintaining the environment are theresponsibility of the Service Provider. The system shall be available 24/7/365 (with agreed- uponmaintenance downtime), and shall provide service to customers as defined in the SOW and/or SLA.
17. RIGHT TO REMOVE INDIVIDUALS:The State shall have the right at any time to require the Service Provider remove from interactionwith State any Service Provider representative who the State believes is detrimental to its workingrelationship with the Service Provider. The State shall provide the Service Provider with notice of itsdetermination, and the reasons it requests the removal. The Service Provider shall not assign the
person to any aspect of the Contract or future work orders without the State’s consent.
18. BUSINESS CONTINUITY AND DISASTER RECOVERY:The Service Provider shall provide a business continuity and disaster recovery plan and shallensure that it achieves the State’s Recovery Time Objective (RTO), as agreed to by the parties andset forth in the SOW and/or SLA.
19. WEB SERVICES:(For PaaS Only) The Service Provider shall use Web services exclusively to interface with StateData in near real time when possible, or as mutually agreed in the SOW and/or SLA.
DocuSign Envelope ID: B8F7F946-29BB-4390-9B30-8AE38D35A96FDocuSign Envelope ID: 655A9EA1-DD18-4D8F-BE56-459C7B232724
Item #5 Page 78 of 103