Loading...
HomeMy WebLinkAboutSpacesaver Intermountain; 2023-03-20; PWM23-2014PDCARLSBAD POLICE DEPARTMENT MOBILE SHELVING INSTALLATION PROJECT City Attorney Approved 8/2/2022 CITY OF CARLSBAD MINOR PUBLIC WORKS CONTRACT CARLSBAD POLICE DEPARTMENT MOBILE SHELVING INSTALLATION PROJECT This agreement is made on the ______________ day of _________________________, 2023, by the City of Carlsbad, California, a municipal corporation, (hereinafter called "City"), and Spacesaver Intermountain, a limited liability corporation whose principal place of business is 8969 Kenamar Drive, Ste 101, San Diego, CA 92121 (hereinafter called "Contractor"). City and Contractor agree as follows: DESCRIPTION OF WORK. Contractor shall perform all work specified in the Contract documents for the project described by these Contract Documents (hereinafter called "Project"). PROVISIONS OF LABOR AND MATERIALS. Contractor shall provide all labor, materials, tools, equipment, and personnel to perform the work specified by the Contract Documents unless excepted elsewhere in this Contract. CONTRACT DOCUMENTS. The Contract Documents consist of this Contract, exhibits to this Contract, Contractor's Proposal, the Plans and Specifications, the General Provisions, addendum(s) to said Plans and Specifications, and all proper amendments and changes made thereto in accordance with this Contract or the Plans and Specifications, all of which are incorporated herein by this reference. When in conflict, this Contract will supersede terms and conditions in the Contractor’s proposal. LABOR. Contractor will employ only skilled workers and abide by all State laws and City of Carlsbad Ordinances governing labor. GUARANTEE. Contractor guarantees all labor and materials furnished and agrees to complete the Project in accordance with directions and subject to inspection approval and acceptance by: Paula Crewse (City Project Manager). PAYMENT. The City shall withhold retention as required by Public Contract Code Section 9203. WAGE RATES. The general prevailing rate of wages for each craft or type of worker needed to execute the Contract shall be those as determined by the Director of Industrial Relations pursuant to Sections 1770, 1773 and 1773.1 of the Labor Code. Pursuant to Section 1773.2 of the Labor Code, a current copy of the applicable wage rates is on file in the Office of the City Engineer. Contractor shall not pay less than the said specified prevailing rates of wages to all workers employed by him or her in execution of the Contract. Contractor shall be responsible for insuring compliance with provisions of section 1777.5 of the Labor Code and section 4100 et seq. of the Public Contracts Code, "Subletting and Subcontracting Fair Practices Act." The City Engineer is the City's "duly authorized officer" for the purposes of section 4107 and 4107.5. The provisions of Part 7, Chapter 1, of the Labor Code commencing with section 1720 shall apply to the Contract for work. A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, unless currently registered and qualified to perform public work pursuant to Section 1725.5. This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations. Contractor and any subcontractors shall comply with Section 1776 of the California Labor Code, which generally requires keeping accurate payroll records, verifying and certifying payroll records, and making them available for inspection. Contractor shall require any subcontractors to comply with Section 1776. PWM23-2014PD 1 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 20th March DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 PWM23-2014PD FALSE CLAIMS. Contractor hereby agrees that any contract claim submitted to the City must be asserted as part of the contract process as set forth in this agreement and not in anticipation of litigation or in conjunction with litigation. Contractor acknowledges that California Government Code sections 12650 et seq., the False Claims Act, provides for civil penalties where a person knowingly submits a false claim to a public entity. These provisions include false claims made with deliberate ignorance of the false information or in reckless disregard of the truth or falsity of the information. The provisions of Carlsbad Municipal Code sections 3.32.025, 3.32.026, 3.32.027 and 3.32.028 pertaining to false claims are incorporated herein by reference. Contractor hereby acknowledges that the filing of a false claim may subject the Contractor to an administrative debarment proceeding wherein the contractor may be prevented from further bidding on public contracts for a period of up to five years and that debarment by another jurisdiction is grounds for the City of Carlsbad to disqualify the Contractgr. or suq~ontractor from participating in contract bidding. Signature: ' 1',~N/?' ~a,,,Lc-:1 Print Name: Rnssell Rawberry -Caotral!er REQUIRED INSURANCE. The successful contractor shall provide to the City of Carlsbad, a Certification of Commercial General Liability and Property Damage Insurance and a Certificate of Workers' Compensation Insurance indicating coverage in a form approved by the California Insurance Commission. The certificates shall indicate coverage during the period of the contract and must be furnished to the City prior to the start of work. The minimum limits of liability insurance are to be placed with California admitted insurers that have a current Best's Key Rating of not less than "A-:VI!"; OR with a surplus line insurer on the State of California's List of Approved Surplus Line Insurers (LASLI) with a rating in the latest Best's Key Rating Guide of at least "A:X"; OR an alien non-admitted insurer listed by the National Association of Insurance Commissioners (NAIC) latest quarterly listings report. Commercial General Liability Insurance of Injuries including accidental death, to any one person in an amount not less than ........ $1,000,000 Subject to the same limit for each person on account of one accident in an amount not less than ....... $1,000,000 Property damage insurance in an amount of not less than ........ $1,000,000 Automobile Liability Insurance in the amount of $1,000,000 combined single limit per accident for bodily injury and property damage. In addition, the auto policy must cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non- scheduled. The automobile insurance certificate must state the coverage is for "any auto" and cannot be limited in any manner. The above policies shall have non-cancellation clauses providing that thirty (30) days written notice shall be given to the City prior to such cancellation. The policies shall name the City of Carlsbad as an additional insured. The full limits available to the named insured shall also be available and applicable to the City as an additional insured. WORKERS' COMPENSATION AND EMPLOYER'S LIABILITY. Workers' Compensation limits as required by the California Labor Code. Workers' Compensation will not be required if Contractor has no employees and provides, to City's satisfaction, a declaration stating this. BUSINESS LICENSE. The Contractor and all subcontractors are required to have and maintain a valid City of Carlsbad Business License for the duration of the contract. CARLSBAD POLICE DEPARTMENT MOBILE SHELVING INSTALLATION PROJECT 2 of 23 City Attorney Approved 8/2/2022 CARLSBAD POLICE DEPARTMENT MOBILE SHELVING INSTALLATION PROJECT City Attorney Approved 8/2/2022 INDEMNITY. The Contractor shall assume the defense of, pay all expenses of defense, and indemnify and hold harmless the City, and its officers and employees, from all claims, loss, damage, injury and liability of every kind, nature and description, directly or indirectly arising from or in connection with the performance of the Contract or work; or from any failure or alleged failure of Contractor to comply with any applicable law, rules or regulations including those related to safety and health; and from any and all claims, loss, damages, injury and liability, howsoever the same may be caused, resulting directly or indirectly from the nature of the work covered by the Contract, except for loss or damage caused by the sole or active negligence or willful misconduct of the City. The expenses of defense include all costs and expenses including attorneys’ fees for litigation, arbitration, or other dispute resolution method. JURISDICTION. The Contractor agrees and hereby stipulates that the proper venue and jurisdiction for resolution of any disputes between the parties arising out of this agreement is San Diego County, California. Start Work: Contractor agrees to start within 5 working days after receipt of Notice to Proceed. Completion: Contractor agrees to complete work within 60 working days after receipt of Notice to Proceed. // // // // // // // // // // // // // PWM23-2014PD 3 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 CARLSBAD POLICE DEPARTMENT MOBILE SHELVING INSTALLATION PROJECT City Attorney Approved 8/2/2022 CONTRACTOR’S INFORMATION. Spacesaver Intermountain, a limited liability corporation 8969 Kenamar Drive, Suite 101 (Name of Contractor) 981328 (Street Address) San Diego, CA 92121 (Contractor’s license number) C-61 / D34 - PREFABRICATED EQUIPMENT/ Exp. 02/28/2023 (City/State/Zip) (844) 800-6014 (License Class. and Exp. Date) 1000010315/ 6/30/2025 (Telephone No.) jmynuk@SpacesaverIM.com (DIR registration number and Exp. Date) (Email) AUTHORITY. The individuals executing this Agreement and the instruments referenced in it on behalf of Contractor each represent and warrant that they have the legal power, right and actual authority to bind Contractor to the terms and conditions of this Agreement. CONTRACTOR SPACESAVER INTERMOUNTAIN, a limited liability corporation CITY OF CARLSBAD, a municipal corporation of the State of California By: By: (sign here) Paz Gomez, Deputy City Manager, Public Works, as Authorized by the City Manager (print name/title) By: (sign here) (print name/title) If required by City, proper notarial acknowledgment of execution by Contractor must be attached. If a corporation, Agreement must be signed by one corporate officer from each of the following two groups: Group A Group B Chairman, President, or Vice-President Secretary, Assistant Secretary, CFO or Assistant Treasurer Otherwise, the corporation must attach a resolution certified by the secretary or assistant secretary under corporate seal empowering the officer(s) signing to bind the corporation. APPROVED AS TO FORM: CINDIE K. McMAHON, City Attorney BY: _____________________________ City Attorney PWM23-2014PD 4 of 23 Russell Rowberry - Controller DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 CARLSBAD POLICE DEPARTMENT MOBILE SHELVING INSTALLATION PROJECT City Attorney Approved 8/2/2022 EXHIBIT A LISTING OF SUBCONTRACTORS BY GENERAL CONTRACTOR Set forth below is the full name and location of the place of business of each sub-contractor whom the Contractor proposes to subcontract portions of the Project in excess of one-half of one percent of the total bid, and the portion of the Project which will be done by each sub-contractor for each subcontract. NOTE: The Contractor understands that if it fails to specify a sub-contractor for any portion of the Project to be performed under the contract in excess of one-half of one percent of the bid, the contractor shall be deemed to have agreed to perform such portion, and that the Contractor shall not be permitted to sublet or subcontract that portion of the work, except in cases of public emergency or necessity, and then only after a finding, reduced in writing as a public record of the Awarding Authority, setting forth the facts constituting the emergency or necessity in accordance with the provisions of the Subletting and Subcontracting Fair Practices Act (Section 4100 et seq. of the California Public Contract Code). If no subcontractors are to be employed on the project, enter the word "NONE." SUBCONTRACTORS Type of Work to be Subcontracted Business Name and Address DIR Registration No. License No., Classification & Expiration Date % of Total Contract Total % Subcontracted: _______________ The Contractor must perform no less than 50% of the work with its own forces. PWM23-2014PD 5 of 23 INSTALLATION RH OFFICE 651 ANITA ST 2010000447261016945 C61/D34 20 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 CARLSBAD POLICE DEPARTMENT MOBILE SHELVING INSTALLATION PROJECT City Attorney Approved 8/2/2022 EXHIBIT B Contractor will provide all the materials and labor necessary to install mobile shelving, property box and bike racking system as specified below in job quote 114542 and attached drawings at the Carlsbad Police Department located at 2560 Orion Way., Carlsbad, Ca 92010. QUOTATION: REF. 114542 ITEM NO. UNIT DESCRIPTION PRICE 1. LS 1. Narcotics Room Mobile Shelving Spacesaver high density mobile storage systems and shelving below as per drawings dated 10/26/22. Quantity (1) single sided static shelving unit, 18" D x 60"L x 79 1/4" H Quantity (1) single sided static shelving unit, 10" D x 60"L x 79 1/4" H (6) shelf openings Quantity (1) double sided mobile shelving unit, 36" D x 60"L x 79 1/4" H (6) shelf openings per side Color: Cottonwood Shelving, Lapis Blue End Paneling *Estimated total bankers box storage estimated at 96 total boxes, as shown on drawings dated 10/26/22. *Bankers box measured at 10.5”H x 13”W x 16.5”L *Above includes complete rail, ramp, and sub-floor system. *Control heads (1) to be mechanical assist handles, no safety stop mechanisms included 2. Property Box Qty (1) Property box as shown in drawing dated 7/22/22. Dimensions: 48”H (from slope), 36”H (from front) x 24”W x 24”D. *Included 4” base as shown in drawing dated 7/22/22. *Includes programmable digilock. *Color selected: "Safety Yellow" 3. Bike Racking System Qty (1) Vertical, No Scratch, Floor Mount Bike Racks as shown in drawing dated 3-28- 22.*Estimated to hold (50) total bikes *Bike racks to be secured to floor. $27,169.61 2. LS Freight and Handling $11,352.29 3. LS Installation 1. Bi-File Shelving Installation Complete disassembly, relocation, and reassembly of existing storage shelving units by Spacesaver certified installers, as shown in drawing dated 9/27/22. 2. VCT Flooring for Narcotics Room Includes product, installation. Color selection: Cirque White *To be installed between phase 1 and phase 2 of HDMS subfloor system. **Please note: over time, VCT tile has a tendency to crack and chip when installed over wood subfloors due to the minor flexing of the wood over time. Spacesaver Intermountain is not responsible for any cracks or chipping that may occur in the future.** **Installation is an estimate based on the following assumptions (any variable not being met may increase the installation price): 1.Installation area must be free and clear of all other trades 2.Access to loading dock 3.Access to freight elevator 4.Standard installation schedule (not compressed) 5.Reasonable push from loading dock to elevator and/or installation area 6.Regular hour installation (Monday through Friday 8 am to 5 pm) 7.Single handling of product $14,155.85 TOTAL* *Includes taxes, fees, expenses, and all other costs. 54,783.39 PWM23-2014PD 6 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 Spacesaver Corporation 1450 Janesville Avenue Fort Atkinson, Wisconsin 53538-2798 USA PH: 920-563-6362 FAX: 920-563-2702 www.spacesaver.com Rev level: Date Printed:10/28/2022 Last Saved:10/28/2022 Drawn by:Amar U. Salesperson:MYNUK, JOE Project Name:CarlsBad Police Department Project #:114452 Scale 1/2" = 1' Rendering PWM23-2014PD 7 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 j ® Spacesaver S t o r a g e S o I v e d• Spacesaver Corporation 1450 Janesville Avenue Fort Atkinson, Wisconsin 53538-2798 USA PH: 920-563-6362 FAX: 920-563-2702 www.spacesaver.com Rev level: Date Printed:10/28/2022 Last Saved:10/28/2022 Drawn by:Amar U. Salesperson:MYNUK, JOE Project Name:CarlsBad Police Department Project #:114452 Scale 1:40 Se i s m i c B A T Se i s m i c B A T U 1 U 2 F B U 3 10'3 3/16" 4'2" 10'6 3/4" 0'10 1/2" 60" 34 9/16" Red noted dimensions are critical dimensions. Please abide by critical dimensions. Spacesaver Intermountain is not responsible for deviations from critical dimensions noted. 32 " Asile 12'8" 5'5 7/8" Plan View 3'1 1/2"18 9/16" PWM23-2014PD 8 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 l j ® Spacesaver S t o r a g e S o I v e d• Spacesaver Corporation 1450 Janesville Avenue Fort Atkinson, Wisconsin 53538-2798 USA PH: 920-563-6362 FAX: 920-563-2702 www.spacesaver.com Rev level: Date Printed:10/28/2022 Last Saved:10/28/2022 Drawn by:Amar U. Salesperson:MYNUK, JOE Project Name:CarlsBad Police Department Project #:114452 Scale 1:45 U 1 H86 3/16" 79 1/4" x 60" x 18" U 2-F H86 3/16" 79 1/4" x 60" x 34" U 3 H86 3/16" 79 1/4" x 60" x 10" 10 3/4" 6 15/16" 10 3/4" 24 Boxes 16 3/4" 79 1/4"79 1/4" 96 Boxes 10 3/4" 24 Boxes 86 3/16" 6 15/16" 10 3/4" Filing Capacity Include Existing Items not assigned to a Position Actual LFI Nominal LFI Actual LFF Nominal LFF 1,392" 1,440" 116'0" 120'0" Elevations 16 3/4" 86 3/16" 10 3/4" 10 3/4" 10 3/4" 10 3/4" 10 3/4" 10 3/4" PWM23-2014PD 9 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 "'""'""'""'""'""'""'""'""' '"''"''"''"''"''"''"''"'' .. , .... , .... , .... , .... , .... , .... , .... .... , .... , .... , .... , .... , .... , .... , .. ............................................................ '"''"''"''"''"''"''"''"'' .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. .... , .... , .... , .... , .... , .... , .... , .. ............................................................ , .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. .... , .... , .... , .... , .... , .... , .... , .. ............................................................ , .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. ,, .. .... , .... , .... , .... , .... , .... , .... j ® Spacesaver S t o r a g e S o I v e d• I~~] 1~=~] 1~=~] 1~=~] !~~~~~] 'l===-1] " / / ~ " Project #: 114405 Drawn by: Amar U. Date Printed: 09/27/2022 Scale 1:30 Rev level: Project Name: Carlsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2022 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Corporation is expressly prohibited by law. CO P Y R I G H T © 2 0 2 2 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D U 4 U 4 U 4 U 3 7'10 1/2" Red noted dimensions are critical dimensions. Please abide by critical dimensions. Spacesaver Intermountain is not responsible for deviations from critical dimensions noted. 13" 7'7 5/8" 47" 1 1/2"42"48" 13" Plan View 13" PWM23-2014PD 10 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 1111 SPACESAVER INTERMOUNTAIN LLC 249 South 400 Eost (801) 363-5882 main Solt Lake City, UT 84111 (801) 359-4326 fox www.SpacesaverlM.com Project #: 114405 Drawn by: Amar U. Date Printed: 09/27/2022 Scale 1:40 Rev level: Project Name: Carlsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2022 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Corporation is expressly prohibited by law. CO P Y R I G H T © 2 0 2 2 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D Filing Capacity Include Existing Items not assigned to a Position Actual LFI Nominal LFI Actual LFF Nominal LFF 5,540" 5,892" 461'8" 491'0" U 6 H85 1/4" 85 1/4" x 42" x 12" U 7 H90 1/8" 85 1/4" x 36" x 12" U 9 H90 1/8" 85 1/4" x 30" x 12" U 5 H90 1/8" 85 1/4" x 36" x 16" U 8 H90 1/8" 85 1/4" x 30" x 16" 85 1/4" 12 3/4" Elevations 2 3/4" 12 3/4" 12 3/4" 12 3/4" 14 1/4" 12 3/4" PWM23-2014PD 11 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 1111 SPACESAVER INTERMOUNTAIN LLC 249 South 400 Eost (801) 363-5882 main Solt Lake City, UT 84111 (801) 359-4326 fox www.SpacesaverlM.com Project #: 114405 Drawn by: Amar U. Date Printed: 09/27/2022 Scale 1:30 Rev level: Project Name: Carlsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2022 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Corporation is expressly prohibited by law. CO P Y R I G H T © 2 0 2 2 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D Filing Capacity Include Existing Items not assigned to a Position Actual LFI Nominal LFI Actual LFF Nominal LFF 5,540" 5,892" 461'8" 491'0" U 3 H90 1/8" 85 1/4" x 48" x 13" U 4 H90 1/8" 85 1/4" x 42" x 13" 12 3/4" 90 1/8" Elevations 4 7/8" 14 1/4" 12 3/4" 12 3/4" 14 1/4" 85 1/4" 12 3/4" PWM23-2014PD 12 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 1111 SPACESAVER INTERMOUNTAIN LLC 249 South 400 Eost Salt Lake City, UT 84111 (801) 363-5882 main (801) 359-4326 fax www.SpacesaverlM.com Project #: 114405 Drawn by: Amar U. Date Printed: 09/27/2022 Scale 3/8" = 1' Rev level: Project Name: Carlsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2022 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Corporation is expressly prohibited by law. CO P Y R I G H T © 2 0 2 2 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D U 2 H90 1/8" 85 1/4" x 30" x 12" U 1 H90 1/8" 85 1/4" x 30" x 12" 4 7/8" Elevations 11 1/4" 11 1/4" 85 1/4" 11 1/4" 11 1/4" 11 1/4" 90 1/8" 11 1/4" Filing Capacity Include Existing Items not assigned to a Position Actual LFI Nominal LFI Actual LFF Nominal LFF 5,540" 5,892" 461'8" 491'0" 11 1/4" PWM23-2014PD 13 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 1111 SPACESAVER INTERMOUNTAIN LLC 249 South 400 Eost (801) 363-5882 main Solt Lake City, UT 84111 (801) 359-4326 fox www.SpacesaverlM.com Project #: 109560 Drawn by: M.Egbert Date Printed: 03/28/2022 Scale 1:50 Rev level: Project Name: Calrsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2021 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Intermountain LLC is expressly prohibited by law. CO P Y R I G H T © 2 0 2 1 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D Concept Image PWM23-2014PD 14 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 1111 SPACESAVER INTERMOUNTAIN LLC 249 South 400 Eost (801) 363-5882 main Solt Lake City, UT 84111 (801) 359-4326 fox www.SpacesaverlM.com Project #: 109560 Drawn by: M.Egbert Date Printed: 03/28/2022 Scale 1:50 Rev level: Project Name: Calrsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2021 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Intermountain LLC is expressly prohibited by law. CO P Y R I G H T © 2 0 2 1 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D Concept Images PWM23-2014PD 15 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 1111 SPACESAVER INTERMOUNTAIN LLC 249 South 400 Eost (801) 363-5882 main Solt Lake City, UT 84111 (801) 359-4326 fox www.SpacesaverlM.com Project #: 109560 Drawn by: M.Egbert Date Printed: 03/28/2022 Scale 1:50 Rev level: Project Name: Calrsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2021 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Intermountain LLC is expressly prohibited by law. CO P Y R I G H T © 2 0 2 1 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D Concept Elevations PWM23-2014PD 16 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 BASE EXTENSION(S) 1111 SPACESAVER INTERMOUNTAIN LLC 249 South 400 East (801) 363-5882 main Salt Lake City, UT 84111 (801) 359-4326 fax www.SpacesaverlM.com Project #: 109560 Drawn by: M.Egbert Date Printed: 03/28/2022 Scale 1:65 Rev level: Project Name: Calrsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2021 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Intermountain LLC is expressly prohibited by law. CO P Y R I G H T © 2 0 2 1 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D 14'10" 29'1" 6'10 3/8" 4'2 1/8" 32'9" 2'9 1/2" 24'5 3/8"4'1 5/8" 90 Bikes 4'7 1/8" PWM23-2014PD 17 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 1111 (~{fM~SAVER 249South400 E LJNTAIN LLC Salt L k as! a e City, UT 84111 (801) 363-5882 . (801) 359-4326 ;r101n wwwS ax . pacesaverlM.com Project #: 109560 Drawn by: M.Egbert Date Printed: 03/28/2022 Scale 1:45 Rev level: Project Name: Calrsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2021 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Intermountain LLC is expressly prohibited by law. CO P Y R I G H T © 2 0 2 1 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D 79" 84"84" 451 2" 84" 341 2" 12" 661 2" 551 2" 84" Elevations PWM23-2014PD 18 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 1111 SPACESAVER INTERMOUNTAIN LLC 249 South 400 Eost (801) 363-5882 main Solt Lake City, UT 84111 (801) 359-4326 fox www.SpacesaverlM.com Project #: 109933 Drawn by: M.Egbert Date Printed: 07/22/2022 Scale 3/8" = 1' Rev level: Project Name: Carlsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2022 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Corporation is expressly prohibited by law. CO P Y R I G H T © 2 0 2 2 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D Concept Rendering PWM23-2014PD 19 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 Saf,ety Yellow 1111 SPACESAVER INTERMOUNTAIN LLC 249 South 400 Eost (801) 363-5882 main Solt Lake City, UT 84111 (801) 359-4326 fox www.SpacesaverlM.com Project #: 109933 Drawn by: M.Egbert Date Printed: 07/22/2022 Scale 1:20 Rev level: Project Name: Carlsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2022 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Corporation is expressly prohibited by law. CO P Y R I G H T © 2 0 2 2 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D DU 1 ST ERELSTEREL DU 1 48"24" 24" 0'8" 4" 36" 56.90 lbs. Total PWM23-2014PD 20 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 □ D 1111 SPACESAVER INTERMOUNTAIN LLC 249 South 400 Eost (801) 363-5882 main Solt Lake City, UT 84111 (801) 359-4326 fox www.SpacesaverlM.com Project #: 109933 Drawn by: M.Egbert Date Printed: 07/22/2022 Scale 1:20 Rev level: Project Name: Carlsbad PD APPROVAL This drawing Approved By: Dated Copyright © 2022 Spacesaver Corporation. This material is proprietary and confidential, and the disclosure reproduction by photography, film, blueprint or otherwise or incorporation into any information retrieval system without first receiving written approval from Spacesaver Corporation is expressly prohibited by law. CO P Y R I G H T © 2 0 2 2 S P A C E S A V E R C O R P O R A T I O N . A L L R I G H T S R E S E R V E D PWM23-2014PD 21 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 I -~Levelers " -Anchors INSTALLING LOCKERS BASES I ~~_____.,ID Turn Locker base over, bottom side up. / ::::,::::::::::,""'com~, ~ lhe Lock01 0 K' g_~~ ~~ Set bases into installation location making sure to keep the flat surface to the front. Use a 114• socket to tum the level- ers to level all bases to the high spot in the floor. We recommend starting at the high- est point and working out from there. Anchor all basses in each corner with appropriate anchor to match site conditions .. Ill SPACESAVER INTERMOUNTAIN LLC 249 South 400 Eost Salt Lake City, UT 84111 (801) 363-5882 main (801) 359-4326 fax www.SpacesaverlM.com ~ ~0 Back of base has hems where the pieces are welded together ~ ,=~=~~, (§)~ I a ._____L Place Lockers onto bases and attach with the provided Tee screws. _[ J DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 EXHIBITC PWM23-2014PD Bond No. SUR0077281 LABOR AND MATERIALS BOND WHEREAS, the City Council of the City of Carlsbad, State of California, has awarded to Spacesaver lntermountain, a limited liability corporation (hereinafter designated as the "Principal"), a Contract for: CARLSBAD POLICE DEPARTMENT MOBILE SHELVING INSTALLATION PROJECT in the City of Carlsbad, in strict conformity with the drawings and specifications, and other Contract Documents now on file in the Office of the City Clerk of the City of Carlsbad and all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond, providing that if Principal or any of its subcontractors shall fail to pay for any materials, provisions, provender or other supplies or teams used in, upon or about the performance of the work agreed to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same to the extent hereinafter set forth. NOW, THEREFORE, WE, SPACESAVER INTERMOUNTAIN, a limited liability corporation , as Principal, (hereinafter designated as the "Contractor"), and ARGONAUT INSURANCE COMPANY ______________ as Surety, are held firmly bound unto the City of Carlsbad in the sum of EIEIY-EO\JR THOllSAND SEVEN HIINDRED EIGHTY-THREE DOI I ARS AND THIRTY-NINE CENTS ($ 54 783.39 ), said sum being an amount equal to: One hundred percent (100%) of the total amount payable under the terms of the Contract by the City of Carlsbad, and for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the Contractor or his/her subcontractors fail to pay for any materials, provisions, provender, supplies, or teams used in, upon, for, or about the performance of the work contracted to be done, or for any other work or labor thereon of any kind, consistent with California Civil Code section 9100, or for amounts due under the Unemployment Insurance Code with respect to the work or labor performed under this Contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of the contractor and subcontractors pursuant to section 13020 of the Unemployment Insurance Code with respect to the work and labor, that the Surety will pay for the same, and, also, in case suit is brought upon the bond, reasonable attorney's fees, to be fixed by the court consistent with California Civil Code section 9554. This bond shall inure to the benefit of any of the persons named in California Civil Code section 9100, so as to give a right of action to those persons or their assigns in any suit brought upon the bond. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed hereunder or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications. CARLSBAD POLICE DEPARTMENT MOBILE SHELVING INSTALLATION PROJECT 22 of 23 City Attorney Approved 8/2/2022 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 PWM23-2014PD In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. SIGNED AND SEALED, this _l_S_th ____ day of December SPACESAVER INTERMOUNTAIN, _a_li_m_it_e_d _lia_b_il_ity_co_r_po_r_at_io_n ____ (SEAL) By ~~ (Signature) ARGONAUT INSURANCE COMPANY ____________ (SEAL) (Surety) Roxanne Jensen, Attorney-in-Ea t (Signature) (SEAL AND NOTARIAL ACKNOWLEDGEMENT OF SURETY -ATTACH ATTORNEY-IN-FACT CERTIFICATE) APPROVED AS TO FORM : CINDIE K. McMAHON City Attorney By: City Attorney CARLSBAD POLICE DEPARTMENT MOBILE SHELVING INSTALLATION PROJECT City Attorney Approved 8/2/2022 23 of 23 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 STATE OF WISCONSIN ) ) SS: COUNTY OF BROWN ) On this 15th day of December, 2022 before me, a Notary Public within and for said County and State, personally appeared Roxanne Jensen known to me to be the Attorney-in-Fact of Argonaut Insurance Company the corporation described in and which executed the within the foregoing instrument and known to me to be the person who executed the said instrument in behalf of said corporation and she duly acknowledged to me that such corporation executed the same. Kell Cod Notary Public: Bro 1sconsm Commission Expires: 3/10/2026 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 Argonaut Insurance Company Deliveries Only: 225 W. Washington, 24th Floor Chicago, IL 60606 United States Postal Service: P.O. Box 469011, San Antonio, TX 78246 POWER OF ATTORNEY KNOW ALL l\1EN BY THESE PRESENTS: That the Argonaut Insurance Company, a Corporation duly organized and existing under the laws of the State of Illinois and having its principal office in the County of Cook, Illinois does hereby nominate, constitute and appoint: Brian Krause, Trudy Szalewski Kelly Cody Roxanne Jensen Their true and lawful agent(s) and attomey(s)-in-fact, each in their separate capacity if more than one is named above, to make, execute, seal and deliver for and on its behalf as surety, and as its act and deed any and all bonds, contracts, agreements of indemnity and other undertakings in suretyship provided, however, that the penal sum of any one such instrument executed hereunder shall not exceed the sum of: $97,550,000.00 This Power of Attorney is granted and is signed and sealed under and by the authority of the following Resolution adopted by the Board of Directors of Argonaut Insurance Company: "RESOLVED, That the President, Senior Vice President, Vice President, Assistant Vice Presiden~ Secretary, Treasurer and each of them hereby is authorized to execute powers of attorney, and such authority can be executed by use of facsimile signature, which may be attested or acknowledged by any officer or attorney, of the Company, qualifying the attorney or attorneys named in the given power of attorney, to execute in behalfof, and acknowledge as the act and deed of the Argonaut Insurance Company, all bond undertakings and contracts ofsuretyship, and to affix the corporate seal thereto." IN WITNESS WHEREOF, Argonaut Insurance Company has caused its official seal to be hereunto affixed and these presents to be signed by its duly authorized officer on the 19th day of November, 2021. Argonaut Insurance Company ,·,\,itiii;;,,,~ ✓.,.,, sURAN. '1, • -/~:~t~~aii;;t~~;,~-J\ ~ ~ :~: ·.o~ /~ C.. ·f 0 =.'SEALi.~§1 .: e>: :>= by: "-'l:·. 1948 ... <:: -:. 00• 11(/N0\7 ••• 'r .:. STATE OF TEXAS •• , ........... ,,• GaryE. Grose, President '~,,, * ,,,,"', COUNTY OF HARRIS SS: . ''!·'"!!!'~' On this 19th day of November, 2021 A.D., before me, a Notary Public of the State of Texas, in and for the County of Harris, duly commissioned and qualified, came THE ABOVE OFFICER OF THE COMPANY, to me personally known to be the individual and officer described in, and who executed the preceding instrument, and he acknowledged the execution of same, and being by me duly sworn, deposed and said that he is the officer of the said Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and the said Corporate Seal and his signature as officer were duly affixed and subscribed to the said instrument by the authority and direction of the said corporation, and that Resolution adopted by the Board of Directors of said Company, referred to in the preceding instrument is now in force. IN TESTIMONY WHEREOF, I have hereunto set my hand, and affixed my Official Seal at the County of Harris, the day and year first above written. KATHLEEN M MEEKS NOTARY PUBLIC STATE OF TEXAS MY COMM. EXP, 07/15125 NOTARY ID 557902--6 (Notary Public) I, the undersigned Officer of the Argonaut Insurance Company, Illinois Corporation, do hereby certify that the original POWER OF ATTORNEY of which the foregoing is a full, true and correct copy is still in full force and effect and has not been revoked. IN WITNESS WHEREOF, I have hereunto set my hand, and aff1Xed the Seal of said Company, on the / )th day of ilivef'v\ tJo r Austin W. King , Secretary IF YOU HA VE QUESTIONS ON AUTHENTICITY OF THIS DOCUMENT CALL (833) 820 -9137. DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 Document A312 ™ -2010 Perlormance Bond Bond No. SUR0077281 CONTRACTOR: (Name, legal status and address) SPACESAVER INTERMOUNTAIN, LLC. 8969 Kenamar Drive, Ste 101 San Diego, CA 92121 OWNER: (Name, legal status and address) CITY OF CARLSBAD 2560 Orion Way Carlsbad, CA 92010 CONSTRUCTION CONTRACT Date: December 15, 2022 SURETY: (Name, legal status and principal place of business) ARGONAUT INSURANCE COMPANY P.O. Box 469011 San Antonio, TX 78246 Amount: Fiftv Four Thousand Seven Hundred Eighty Three and 39/100 Dollars ($ M ,783.39) Description: (Name and location) Carlsbad Police Department, Mobile Shelving Installation Project, Carlsbad, California. BOND Date: December 15, 2022 (Not earlier than Construction Contract Date) Fifty Four Thousand Seven Hundred Eighty Three and 39/100 Dollars Amount:($ 54,783.39) Modifications to this Bond: l[I None □ See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) SPACESAVER INTERMOUNTAIN, LLC ARGONAUT INSURANCE COMPANY Signatur~~~L Signature: Name "'----:--, -~ .,,:;,J Name Roxanne Jensen, Attorney-j -act . --~J~ i\~~~ and Title: ,,!!:. t:? ~ and Title: (Any additional si;t,:;{ures appear on the last page of this Performance Bond.) (FOR INFORMATION ONLY -Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: AON RISK SERVICES CENTRAL, INC. (Architect, Engineer or other party.) 10700 West Research Drive Milwaukee, WI 53226 (414) 271-6420 AIA Document A312™ -2010. The American Institute of Architects. This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, into one form. This is not a single combined Performance and Payment Bond. 1 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor perfonns the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's perfonnance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3 .1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with tl1e tenns of the Constmction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3 .1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, tl1e Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by tl1e Owner and a contractor selected with the Owner's concurrence, to be secured with perfonnance and payment bonds executed by a qualified surety equivalent to the bonds issued on tl1e Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of tl1e Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perfonn and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under tl1e circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after tl1e amount is determined, make payment to tl1e Owner; or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 witl1 reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from tl1e Owner to tl1e Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. AIA Document A312™ -2010. The American Institute of Architects. 2 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. lf the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of tl1e Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or othenvise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under tl1e Construction Contract or to perform and complete or comply witll the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. AIA Document A312™ -2010. The American Institute of Architects. 3 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 § 16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: Signature: Name and Title: , Address: (Corporate Seal) Company: Signature: Name and Title: , Attorney-in-Fact Address: AIA Document A312™ -2010. The American Institute of Architects. (Corporate Seal) 4 ANY PROPRIETOR/PARTNER/EXECUTIVEOFFICER/MEMBER EXCLUDED? INSR ADDL SUBRLTRINSD WVD PRODUCER CONTACTNAME: FAXPHONE(A/C, No):(A/C, No, Ext): E-MAILADDRESS: INSURER A : INSURED INSURER B : INSURER C : INSURER D : INSURER E : INSURER F : POLICY NUMBER POLICY EFF POLICY EXPTYPE OF INSURANCE LIMITS(MM/DD/YYYY) (MM/DD/YYYY) AUTOMOBILE LIABILITY UMBRELLA LIAB EXCESS LIAB WORKERS COMPENSATION AND EMPLOYERS' LIABILITY DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) AUTHORIZED REPRESENTATIVE EACH OCCURRENCE $ DAMAGE TO RENTEDCLAIMS-MADE OCCUR $PREMISES (Ea occurrence) MED EXP (Any one person) $ PERSONAL & ADV INJURY $ GEN'L AGGREGATE LIMIT APPLIES PER:GENERAL AGGREGATE $ PRO-POLICY LOC PRODUCTS - COMP/OP AGGJECT OTHER:$ COMBINED SINGLE LIMIT $(Ea accident) ANY AUTO BODILY INJURY (Per person) $OWNED SCHEDULED BODILY INJURY (Per accident) $AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $AUTOS ONLY AUTOS ONLY (Per accident) $ OCCUR EACH OCCURRENCE CLAIMS-MADE AGGREGATE $ DED RETENTION $ PER OTH-STATUTE ER E.L. EACH ACCIDENT E.L. DISEASE - EA EMPLOYEE $If yes, describe under E.L. DISEASE - POLICY LIMITDESCRIPTION OF OPERATIONS below INSURER(S) AFFORDING COVERAGE NAIC # COMMERCIAL GENERAL LIABILITY Y / N N / A (Mandatory in NH) SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIODINDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THISCERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). COVERAGES CERTIFICATE NUMBER:REVISION NUMBER: CERTIFICATE HOLDER CANCELLATION © 1988-2015 ACORD CORPORATION. All rights reserved.ACORD 25 (2016/03) CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) $ $ $ $ $ The ACORD name and logo are registered marks of ACORD 1/20/2023 (801) 325-5000 (801) 532-2804 20281 Spacesaver Intermountain LLC c/o Henriksen Butler Design Group 249 South 400 East Salt Lake City, UT 84111 20303 40517 A 1,000,000 36054513 TPA 9/1/2022 9/1/2023 1,000,000 Completed Operations 10,000 1,000,000 2,000,000 2,000,000 COMBINED TOTAL 10,000,000 1,000,000B 73605042 9/1/2022 9/1/2023 8,000,000A 78188906 9/1/2022 9/1/2023 8,000,000 0 C 2211730 9/1/2022 9/1/2023 1,000,000 Y 1,000,000 1,000,000 City of Carlsbad, its officers, officials, employees, agets and volunteers are Additional Insured on General Liability with respect to the work performed by the Named Insured as required per written contract. Waiver of subrogation applies to Workers Compensation. 30 day notice of cancellation except 10 days notice of cancellation for non-payment of premium applies for General Liability. City of Carlsbad /CMWD c/o EXIGIS Insurance Compliance Services PO Box 947 Murrieta, CA 92564 HENRBUT-01 RTUELLER Diversified Insurance Group 136 E South Temple Suite 2300 Salt Lake City, UT 84111 Federal Insurance Company Great Northern Insurance Company WCF National Insurance Company X X X X X X X X X X DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 ACORD" I ~ I ~ □ □ ~ ~ ~ □ □ ~ ~ ~ ~ ~ ~ ~ ~ H I I I I I □ I DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 Liability Insurance Endorsement Policy Period Effective Date Policy Number Insured Name of Company Date Issued SEPTEMBER 1, 2022 TO SEPTEMBER 1, 2023 SEPTEMBER 1, 2022 3605-45-13 TPA HB INTERMOUNTAIN HOLDINGS LLC FEDERAL INSURANCE COMPANY SEPTEMBER 8, 2022 This Endorsement applies to the following forms: GENERAL LIABILITY Who Is An Insured Additional Insured - Scheduled Person Or Organization Liability Insurance Form 80-02-2367 (Rev. 5-07) Under Who Is An Insured, the following provision is added. Persons or organizations shown in the Schedule are insureds; but they are insureds only if you are obligated pursuant to a contract or agreement to provide them with such insurance as is afforded by this policy. However, the person or organization is an insured only: • if and then only to the extent the person or organization is described in the Schedule; • to the extent such contract or agreement requires the person or organization to be afforded status as an insured; • for activities that did not occur, in whole or in part, before the execution of the contract or agreement; and • with respect to damages, loss, cost or expense for injury or damage to which this insurance applies. No person or organization is an insured under this provision: • that is more specifically identified under any other provision of the Who Is An Insured section (regardless of any limitation applicable thereto). • with respect to any assumption of liability (of another person or organization) by them in a contract or agreement. This limitation does not apply to the liability for damages, loss, cost or expense for injury or damage, to which this insurance applies, that the person or organization would have in the absence of such contract or agreement. Additional Insured -Scheduled Person Or Organization continued Endorsement Page 1 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 Liability Endorsement (continued) Conditions Other Insurance - Primary, Noncontributory Insurance -Scheduled Person Or Organization Liability Insurance Form 80-02-2367 (Rev. 5-07) Under Conditions, the following provision is added to the condition titled Other fusurance. If you are obligated, pursuant to a contract or agreement, to provide the person or organization shown in the Schedule with primary insurance such as is afforded by this policy, then in such case this insurance is primary and we will not seek contribution from insurance available to such person or organization. Schedule Persons or organizations that you are obligated, pursuant to a contract or agreement, to provide with such insurance as is afforded by this policy. All other terms and conditions remain unchanged. Authorized Representative Additional Insured -Scheduled Person Or Organization last page Endorsement Page 2 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 Policy Conditions Endorsement Policy Period Effective Date Policy Number Insured Name of Company Date Issued SEPTEMBER 1, 2022 TO SEPTEMBER 1, 2023 SEPTEMBER 1, 2022 3605-45-13 TPA HB INTERMOUNTAIN HOLDINGS LLC FEDERAL INSURANCE COMPANY SEPTEMBER 8, 2022 This Endorsement applies to the following forms: COMMON POLICY CONDITIONS Conditions Notice Of Cancellation To Scheduled Persons Or Organizations When We Cancel Policy Conditions Form 80-02-9779 (Ed. 3-11) Under Conditions, the following condition is added. When we cancel this policy for any reason, other than non-payment of premium, we will notify person(s) or organization(s) shown in the Schedule at least 30 days in advance of the cancellation date. Any failure by us to notify such person(s) or organization(s) will not: • impose any liability or obligation of any kind upon us; or • invalidate such cancellation. Schedule Person(s) or Organization(s): PER SCHEDULE CONTAINED IN UW FILE Person(s) or Organization(s): WELLS FARGO EQUIPMENT FINANCE INC ATTN:INSURANCEDEPARTMENT Address: POBOX35702 BILLINGS, MT 59107 Notice Of cancellation To Scheduled Persons Or Organizations (Except Non-Payment Of Premium) Endorsement continued Page 1 DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 Conditions (continued) Policy Conditions Form 80-02-9779 (Ed. 3-11) All other terms and conditions remain unchanged. Authorized Representative Notice Of cancellation To Scheduled Persons Or Organizations (Except Non-Payment Of Premium) Endorsement last page Page2 WC 00 03 13 (Ed. 4-84) © Copyright 1983–2006 National Council on Compensation Insurance, Inc. All Rights Reserved. WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 00 03 13 (Ed. 4-84) Policy No.2211730 This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. Insured HENRIKSEN BUTLER DESIGN GROUP LLC Endorsement No. Premium Endorsement Effective 09/01/2022 249 S 400 E Salt Lake City, UT 84111 WCF National Insurance CompanyInsurance Company Countersigned by WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule 1. Waiver Type Blanket A blanket waiver of subrogation is granted for all projects and contracts for the below named insured and its subsidiaries for all jobs requiring such a waiver in writing in all states excluding Texas listed under section 3A of your information page. DocuSign Envelope ID: 72CA3B0C-000D-40B5-99B6-E2ACD410AF45 R