Loading...
HomeMy WebLinkAboutWhenToWork, LLC; 2024-08-30;WhenToWork, LLC 1TimeClockDrive SanAngelo,TX76904 sales@when2work.com ContractStartDate:08/30/24 CLIENT INFORMATION Purchased for: City of Carlsbad Contract Contact Name: Brent Gerber Bill to: Senior Management Analyst Contract Contact Email: brent.gerber@carlsbadca.gov Billing Address: 1635 Faraday Ave Carlsbad, CA 92008, USA Support Contact Name: Devin Castel Billing Contact Name: Brent Gerber Support Contact Email: Devin.Castel@carlsbadca.gov Billing Contact Email: renewals@carlsbadca.gov brent.gerber@carlsbadca.gov Support Contact Phone: 442.339.2065 Billing Contact Phone: Start day of week: BILLING TERMS INITIAL TERM & Extentions RENEWAL TERM PAYMENT TERM PAYMENT METHOD 36 Months NA NET 30 per annual invoice Check ITEM DESCRIPTION UPLIFTED TOTAL PRICE # OF LICENSES DISCOUNT ORDER TOTAL Year 1 W2W Initial $6,270 500 15% $5,330 Year 2 W2W Extension $6,270 500 15% $5,330 Year 3 W2W Extension $6,270 500 25% $4,703 SUBTOTAL $15,362 TAXES $0.00 GRAND TOTAL IN US$ $15,362 SPECIAL TERMS: NA Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 billine@when2work.com Page 1 of www.w2w.com SERVICE TERMS & CONDITIONS WhenToWork, LLC ("W2W"), a California limited liability company, will provide Client and its authorized Users access to the Services during the Initial Service Term in accordance with the complete terms and conditions (collectively the "Licensing Agreement") attached as , The initial term of this Agreement will be for one (1) year, with two (2) possible one (1) year extensions, amendments will be executed for the extensions if applicable. W2W reserves the right to modify the Licensing Agreement at W2W's sole discretion provided that changes shall not materially decrease the Services features and functionalities that Client has subscribed to during the then-current term. Should W2W make any modifications to the Licensing Agreement, W2W and the Client will complete an amendment to the Agreement acknowledging the changes and will post the amended terms on the applicable URL link and will update the "Last Updated Date" within such documents to notify Client of said changes. This Order Form is entered into as of the Contract Start Date contained herein (the "Effective Date") by and between WhenToWork, LLC and the entity named in the Bill To section herein (the "Client") and is subject to the Licensing Agreement. In the event of any conflict between the Order Form and the Terms and Conditions (as applicable), the terms of the Order Form shall control. Client shall pay all fees or charges in accordance with those outlined on the Order Form. Except for cases of W2W breach, all fees are committed and non-cancelable during the term of the agreement. The individuals executing this Agreement on behalf of each Party represent and warrant to the other Party that they are fully authorized and legally capable of executing this Agreement on behalf of such Party and that such execution is binding upon such Party. Accepted by: Client WhenToWork, LLC By: By: Name: Name: Title: Title: APPROVED AS TO FORM: CINDIE K. McMAHON, City Attorney BY: __________________________ Deputy City Attorney Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 Exhibit "A" By this reference the attached Addendum "A" will be in full force to this agreement. Maria Callander Whitney Leifeste Director of Information Technology Director of Legal Services billine@when2work.com Page 2 of www.w2w.com 1. ACCEPTANCE OF TERMS Welcome to WhenToWork.com. WhenToWork, LLC. ("W2W"), provides its online service and mobile apps ("Service") to you ("User"), subject to the following Terms of Service ("TOS"). Please read these Terms of Service carefully before using our Service. Your access to and use of the Service is conditioned upon your acceptance of and compliance with these TOS. By accessing or using the Service you agree to be bound by these TOS. If you disagree with any part of the TOS then you do not have permission to access the Service. These TOS apply to all individuals accessing the Service through your W2W account and you are responsible for ensuring all individuals accessing your account are aware of and comply with all TOS stated terms and conditions. 2. DESCRIPTION OF SERVICE W2W currently provides Users in the United States, Canada, and other European Union Countries with paid subscription access to online resources, including various online scheduling abilities, (the "Service"). Fees are based on the number of employees added into the W2W account and the duration paid, as more specifically described online at: http://WhenToWork.com/pricing.htm. Unless explicitly stated otherwise, any changes that augment or enhance the current Service, including the release of new W2W features shall be subject to this TOS. You understand and agree that use of the Service is at your sole risk and is provided "AS-IS" and "AS-AVAILABLE" and that W2W assumes no responsibility for the timeliness, deletion, mis-delivery or failure to store any user communications, data entry or personalization settings. Our Service allows you to post, link, store, share and otherwise make available certain information, text, graphics, or other material ("Content"). You are responsible for the Content that you post on or through the Service, including its legality, reliability, and appropriateness. By posting Content on or through the Service, You represent and warrant that: (i) the Content is yours (you own it) and/or you have the right to use it and the right to grant us the rights and license as provided in these Terms, and (ii) that the posting of your Content on or through the Service does not violate the privacy rights, publicity rights, copyrights, contract rights or any other rights of any person or entity. We reserve the right to terminate the account if any User is found to be infringing on a copyright. You retain any and all of your rights to any Content you submit, post or display on or through the Service and you are responsible for protecting those rights. We take no responsibility and assume no liability for Content you or any third-party posts on or through the Service. However, by posting Content using the Service you grant us the right and license to use, modify, perform, display, reproduce, and distribute such Content on and through the Service. W2W has the right but not the obligation to monitor and edit all Content provided by users. Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 billine@when2work.com EXHIBIT "A" WhenToWork, LLC Terms of Service Page 3 of European Union ("EU") and Non- www.w2w.com 3. YOUR REGISTRATION OBLIGATIONS In consideration of your use of the Service, you agree: (a) When you create a paid subscription with us, you guarantee that you are above the age of 18, and that the information you provide us is accurate, complete, and current at all times. Inaccurate, incomplete, or obsolete information may result in the immediate termination of your account on the Service. (b) When contacting W2W customer service you will be honest about your identity, name and company title and any information about your request. (c) While the person who initially creates the W2W account is the "Main Manager" (the one person who can add and edit other managers) W2W has the authority to change the Main Manager on the account at our discretion at any time. W2W adheres to strict Main Manager change guidelines to protect your account, and the data contained therein, from unauthorized access and modification. (d) When a W2W account is created to schedule employees of an organization, that organization is considered the owner of the account. Anyone who makes a payment is considered an agent for the owner and all rights to the account belong to the organization. 4. W2W PRIVACY POLICY Registration Data and certain other information about Users is subject to our Privacy Policy. For more information, see our full privacy policy at https://whentowork.com/privacy.htm. 5. USER ACCOUNT, PASSWORD AND SECURITY You will create a username and password upon completing the registration process. You are responsible for maintaining the confidentiality of that login information, and are fully responsible for all activities or actions that occur under your account and/or login. You agree to immediately notify W2W of any unauthorized use of logins on your account or any other breach of security. It is recommended that you sign out from your account at the end of each session, especially on a shared device. W2W cannot and will not be liable for any loss or damage arising from your failure to comply with this Section 5. 6. USER CONDUCT You understand that all information, data, text, messages or other materials ("Content"), whether publicly posted or privately transmitted, are the sole responsibility of the person from which such Content originated. This means that you, and not W2W, are entirely responsible for all Content that you upload, post, email, transmit or otherwise make available via the Service. W2W does not control the Content posted via the Service and, as such, does not guarantee the accuracy, integrity or quality of such Content. You understand that by using the Service, you may be exposed to Content that is offensive, indecent or objectionable. Under no circumstances will W2W be liable in any way for any Content, including, but not limited to, for any errors or omissions in any Content, or for any loss or damage of any kind incurred as a result of the use of any Content posted, emailed, transmitted or otherwise made available via the Service. Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 billine@when2work.com Page4of www.w2w.com You agree to not use the Service to: a. upload, post, email, transmit or otherwise make available any Content that is unlawful, harmful, threatening, abusive, harassing, tortious, defamatory, vulgar, obscene, libelous, invasive of another's privacy, hateful, or racially, ethnically or otherwise objectionable; b. impersonate any person or entity or falsely state or otherwise misrepresent your affiliation with a person or entity; c. forge headers or otherwise manipulate identifiers in order to disguise the origin of any Content transmitted through the Service; d. upload, post, email, transmit or otherwise make available any Content that you do not have a right to make available under any law or under contractual or fiduciary relationships (such as inside information, proprietary and confidential information learned or disclosed as part of employment relationships or under nondisclosure agreements); e. upload, post, email, transmit or otherwise make available any Content that infringes any patent, trademark, trade secret, copyright or other proprietary rights ("Rights") of any party; f. upload, post, email, transmit or otherwise make available any unsolicited or unauthorized advertising, promotional materials, "junk mail," "spam," "chain letters," "pyramid schemes," or any other form of solicitation; g. upload, post, email, transmit or otherwise make available any material that contains scripts or any other code, files or programs designed to interrupt, destroy or limit the functionality of any computer software or hardware or equipment; h. interfere with or disrupt the Service or servers or networks connected to the Service, or disobey any requirements, procedures, policies or regulations of networks connected to the Service; i. intentionally or unintentionally violate any applicable local, state, national or international law. You acknowledge and agree that W2W may preserve Content and may also disclose Content if required to do so by law or in the good faith belief that such preservation or disclosure is reasonably necessary to: (a) comply with legal process; (b) enforce the TOS; (c) respond to claims that any Content violates the rights of third- parties; or (d) protect the rights, property, or personal safety of W2W, its users and the public. You understand that the technical processing and transmission of the Service, including your Content, may involve (a) transmissions over various networks; and (b) changes to conform and adapt to technical requirements of connecting networks or devices. You agree to not use any automated system, extension or software that causes your browser to automatically reload our web pages without special prior permission from W2W. 7. SPECIAL ADMONITIONS FOR INTERNATIONAL USE Recognizing the global nature of the Internet, you agree to comply with all local rules regarding online conduct and acceptable Content. Specifically, you agree to comply with all applicable laws regarding the transmission of technical data imported or exported from the United States or the country in which you reside. 8. RESERVED 9. NO RESALE OF SERVICE You agree not to reproduce, duplicate, copy, sell, resell or exploit for any commercial purposes, any portion of the Service, use of the Service, or access to the Service. Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 billine@when2work.com Page 5 of www.w2w.com 10. GENERAL PRACTICES REGARDING USE AND STORAGE You acknowledge that W2W may establish general practices and limits concerning use of the Service, including without limitation the maximum number of days that messages, schedules or other uploaded Content will be retained by the Service, the maximum number of messages that may be sent from or received by an account on the Service, the maximum size of any message that may be sent from or received by an account on the Service, the maximum storage space that will be allotted on W2W's servers on your behalf, and the maximum number of times (and the maximum duration for which) you may access the Service in a given period of time. You agree that W2W has no responsibility or liability for the deletion or failure to store any messages and other communications or other Content maintained or transmitted by the Service. You acknowledge that W2W reserves the right to change these general practices and limits at any time, in its sole discretion, with or without notice. 11. MODIFICATIONS TO SERVICE W2W reserves the sole right at any time and from time to time to modify or discontinue, temporarily or permanently, the Service (or any part thereof) with written notice the TOS. You agree that W2W shall not be liable to you or to any third party for any modification, suspension or discontinuance of the Service . All modifications to the Service shall be made in writing through an amendment. W2W may temporarily or permanently discontinue Service at the expiration of the agreement term, but not before unless agreed to in writing. 12. TERMINATION W2W may terminate or suspend your account and bar access to the Service immediately, with prior notice for a breach of the TOS. If you wish to terminate your account, you may simply discontinue using the Service. All provisions of the TOS which by their nature should survive termination shall survive termination, including, without limitation, ownership provisions, warranty disclaimers, indemnity and limitations of liability. You agree that W2W shall not be liable to you or any third-party for any termination of your access to the Service. 13. LINKS The Service may provide links to websites or resources. Because W2W has no control over such sites and resources, you acknowledge and agree that W2W is not responsible for the availability of such external sites or resources, and does not endorse and is not responsible or liable for any content, advertising, products, or other materials on or available from such sites or resources. You further acknowledge and agree that W2W shall not be responsible or liable, directly or indirectly, for any damage or loss caused or alleged to be caused by or in connection with use of or reliance on any such Content, goods or services available on or through any such site or resource. Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 if there's a breach of if there's a breach of the TOS billine@when2work.com Page 6 of www.w2w.com 14. W2W'S PROPRIETARY RIGHTS You acknowledge and agree that the Service and any necessary software used in connection with the Service ("Software") contains proprietary information that is protected by applicable intellectual property and other laws. You further acknowledge and agree that Content presented to you through the Service and its original content (excluding Content provided by Users), features and functionality contain proprietary information and will remain the exclusive property of W2W and its licensors. The Service is protected by copyright, trademark, and other laws of both the United States and foreign countries. W2W grants Users a personal, non- transferable and non-exclusive right and license to use the Software; provided that you do not (and do not allow any third party to) copy, modify, distribute, create a derivative work of, reverse engineer, reverse assemble or otherwise attempt to discover any source code, lease, sell, assign, sublicense, grant a security interest in or otherwise transfer any right in the Software. You agree not to modify the Software in any manner or form, or to use modified versions of the Software, including (without limitation) for the purpose of obtaining unauthorized access to the Service. You agree not to access the Service by any means other than through the interface that is provided by W2W for use in accessing the Service. 15. DISCLAIMER OF WARRANTIES YOU EXPRESSLY UNDERSTAND AND AGREE THAT: a. YOUR USE OF THE SERVICE IS AT YOUR SOLE RISK. THE SERVICE IS PROVIDED ON AN "AS-IS" AND "AS-AVAILABLE" BASIS. W2W EXPRESSLY DISCLAIMS ALL WARRANTIES OF ANY KIND, WHETHER EXPRESS OR IMPLIED, INCLUDING, BUT NOT LIMITED TO THE IMPLIED WARRANTIES OF MERCHANTABILITY, AND FITNESS FOR A PARTICULAR PURPOSE. b. W2W MAKES NO WARRANTY THAT (i) THE SERVICE WILL MEET YOUR REQUIREMENTS, (ii) THE SERVICE WILL BE UNINTERRUPTED, TIMELY, SECURE, OR ERROR-FREE, BUT SHALL BE REASONABLY UNINTERRUPTED, TIMELY, SECURE, OR ERROR-FREE, (iii) THE RESULTS THAT MAY BE OBTAINED FROM THE USE OF THE SERVICE WILL BE ACCURATE OR RELIABLE, BUT SHALL BE REASONABLY ACCURATE AND RELIABLE, (iv) THE QUALITY OF ANY PRODUCTS, SERVICES, INFORMATION, OR OTHER MATERIAL PURCHASED OR OBTAINED BY YOU THROUGH THE SERVICE WILL MEET YOUR EXPECTATIONS, AND (v) ANY ERRORS IN THE SOFTWARE WILL BE CORRECTED. c. ANY MATERIAL DOWNLOADED OR OTHERWISE OBTAINED THROUGH THE USE OF THE SERVICE IS DONE AT YOUR OWN DISCRETION AND RISK AND THAT YOU WILL BE SOLELY RESPONSIBLE FOR ANY DAMAGE TO YOUR COMPUTER SYSTEM OR LOSS OF DATA THAT RESULTS FROM THE DOWNLOAD OF ANY SUCH MATERIAL. d. NO ADVICE OR INFORMATION, WHETHER ORAL OR WRITTEN, OBTAINED BY YOU FROM W2W OR THROUGH OR FROM THE SERVICE SHALL CREATE ANY WARRANTY NOT EXPRESSLY STATED IN THE TOS. 16. LIMITATION OF LIABILITY YOU EXPRESSLY UNDERSTAND AND AGREE THAT W2W AND ITS DIRECTORS, OFFICERS, EMPLOYEES, PARTNERS, AGENTS, SUPPLIERS OR AFFILIATES SHALL NOT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL OR EXEMPLARY DAMAGES, INCLUDING BUT NOT LIMITED TO, DAMAGES FOR LOSS OF PROFITS, GOODWILL, USE, DATA OR OTHER INTANGIBLE LOSSES (EVEN IF W2W HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES), RESULTING FROM: (i) THE USE OR THE INABILITY TO USE THE SERVICE; (ii) THE COST OF PROCUREMENT OF SUBSTITUTE GOODS AND SERVICES RESULTING FROM ANY GOODS, DATA, INFORMATION OR SERVICES PURCHASED OR OBTAINED OR MESSAGES RECEIVED OR TRANSACTIONS ENTERED INTO THROUGH OR FROM THE SERVICE; (iii) UNAUTHORIZED ACCESS TO, USE OR ALTERATION OF YOUR TRANSMISSIONS OR DATA; (iv) STATEMENTS OR CONDUCT OF ANY THIRD PARTY ON THE Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 billine@when2work.com Page 7 of www.w2w.com SERVICE; OR (v) ANY OTHER MATTER RELATING TO THE SERVICE. W2W EXPRESSLY UNDERSTANDS AND AGREES THAT CLIENT AND ITS DIRECTORS, OFFICERS, ELECTED AND APPOINTED OFFICIALS, EMPLOYEES, AGENTS, OR VOLUNTEERS SHALL NOT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL OR EXEMPLARY DAMAGES, INCLUDING BUT NOT LIMITED TO, DAMAGES FOR LOSS OF PROFITS, GOODWILL, USE, OR OTHER INTANGIBLE LOSSES (EVEN IF CLIENT HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES) RELATING TO THE SERVICE. 17. EXCLUSIONS AND LIMITATIONS SOME JURISDICTIONS DO NOT ALLOW THE EXCLUSION OF CERTAIN WARRANTIES OR THE LIMITATION OR EXCLUSION OF LIABILITY FOR INCIDENTAL OR CONSEQUENTIAL DAMAGES. ACCORDINGLY, SOME OF THE ABOVE LIMITATIONS OF SECTIONS 15 AND 16 MAY NOT APPLY TO YOU. 18. NOTICE Notices to you may be made via either email or regular mail. The Service may provide notices of changes to the TOS or other matters by displaying notices or links to notices on the manager homepage of the Service, but any applicable changes to the TOS must be made in writing through an amendment. 19. TRADEMARK INFORMATION WhenToWork.com, W2W.com, and any accompanying logos are registered trademarks of WhenToWork, LLC. You agree not to display or use in any manner, the WhenToWork, LLC. marks or trade dress without WhenToWork, LLC's prior permission. 20. GENERAL INFORMATION This TOS and referenced web pages constitute the entire agreement between you and W2W and govern your use of the Service, superseding any prior agreements between you and W2W. You also may be subject to additional terms and conditions that may apply when you use affiliate services, third party content, or third party software. The TOS and the relationship between you and W2W shall be governed by the laws of the State of California without regard to its conflict of law provisions. You and W2W agree to submit to the personal and exclusive jurisdiction of the courts located within San Diego County, California. The failure of W2W to exercise or enforce any right or provision of the TOS shall not constitute a waiver of such right or provision. If any provision of the TOS is found by a court of competent jurisdiction to be invalid, the parties nevertheless agree that the court should endeavor to give effect to the parties' intentions as reflected in the provision, and the other provisions of the TOS remain in full force and effect. You and W2W agree that regardless of any statute or law to the contrary, any claim or cause of action by either party arising out of or related to use of the Service or the TOS must be filed within one (1) year after such claim or cause of action arose or be forever barred. The section titles in the TOS are for convenience only and have no legal or contractual effect. Revised: April 17, 2024 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 billine@when2work.com Page 8 of www.w2w.com IT ADDENDUM TO AGREEMENT FORM the standard form agreement provided by the Contractor. Nevertheless, the parties agree that this addendum is a part of the form 1. Payment. Notwithstanding anything in the Con attached, the payments to be made by the City for all goods, services and other deliverables under this Agreement shall not exceed sixteen thousand three hundred three dollars ($16,303.00). 2. Independent Contractor. In its performance under this Agreement, the Contractor and the agents and employees of Contractor act and will act in an independent capacity and not as an agent or employee of the City. 3. Inapplicable Terms. Because the City cannot accept certain standard clauses that may appear in the Agreement as a matter of law and policy, the Contractor agrees that no provision described below which appears in the Agreement shall be of any force and effect against the City: a. Requiring the City to obtain or maintain any form of insurance. b. Renewing or extending the Agreement beyond its initial term or duration other than by mutual agreement of the parties. c. Requiring or stating that the terms of this online forms or agreements, shall prevail over the terms of this addendum in the event of conflict. d. Requiring the City to indemnify, defend, or hold the Contractor harmless against claims of any kind or nature. e. Requiring the application of laws other than California law in interpreting or enforcing the Agreement, including this addendum, or requiring or permitting litigation arising under the Agreement in the courts of any state other than California, nor any venue other than San Diego County. f. Requiring the City to pay liquidated damages, indirect, special, punitive, incidental or consequential damages, including without limitation lost profits, lost revenue, lost business opportunities, loss of data, interruption of business, regardless of the theory of liability, even if City has been advised of the possibility of such damages. g. Requiring the City to pay any type of contract termination fee. h. Limiting the liability of the Contractor for actual damage to City property or for personal injury. i. Disclaiming negligence in violation of public policy. j. Permitting unilateral modification of this Agreement by the Contractor or deeming the City to agree to a modification by means other than affirmatively signing a modification to the Agreement. k. Requiring the City to engage in binding arbitration. l. Obligating the City to pay court costs, costs of collection, or fees. m. Requiring the City to withhold information from the public contrary to the requirements of Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 ADDENDUM "A" CONTRACTOR'S The City of Carlsbad ("City") and When To Work, LLC ("Contractor") are using agreement ("Agreement"), and amends and modifies the Agreement as provided below: tractor's form to which this Addendum is Agreement, or the terms of the Contractor's attorneys' billine@when2work.com Page 9 of www.w2w.com the California Public Records Act (CA Government Code § 6250 et seq.) and the California Civil Discovery Act (California Code of Civil Procedure § 2016.010 et seq.). n. Requiring City to provide notice prior to disclosure of government records subject to California Public Records Act (CA Government Code § 6250 et seq.) and the California Civil Discovery Act (California Code of Civil Procedure § 2016.010 et seq.). o. Imposing interest on late payments or requiring interest to be paid on disputed amounts. p. eement by providing thirty (30) days written notice to Contractor; provided, however, City shall not be entitled to a refund of any prepaid fees. 4. Technology Terms and Conditions. In addition, the Agreement is hereby amended to include the following Information Technology Terms and Conditions: Sensitive Information. In instances where any agreement, purchase order, or Scope of Work Contractor shall provide an independently certified System and Organization Controls (SOC) 2 Type 2 Audit Report or a SOC Cybersecurity Report or equivalent certification for all parties to the Agreement and annual updates during the term of the Agreement. Data Location and Ownership. The Contractor shall provide its services to the City and its end users solely from data centers in the continental United States. Storage of City Data at rest shall be located solely in data centers in the United States. Contractor will notify the City of any plans to relocate its hosted services to another data center. Contractor shall not allow personnel or subcontractors to store City Data on portable devices, including personal computers, except for devises that are used and kept only at its U.S. data centers. The Contractor shall permit its personnel and subcontractors to access City Data remotely only as required to provide technical user support or other customer support. The City will own all right, title and interest in City Data that is related to the services provided by this Agreement. Data Protection. Contractor shall ensure there is no inappropriate or unauthorized use of City Data at any time. To this end, Contractor shall safeguard the confidentiality, integrity, and availability of City Data within its control using security technologies and techniques in action or inaction result in any situation that is less secure than the security Contractor provides for its own systems and data. Data Breach Responsibilities. This section only applies when there is a breach of City Data within the possession or control of Contractor. Contractor shall: (1) promptly notify City within 72 hours or sooner by telephone, unless shorter time is required by applicable law, if it confirms that there is or reasonably believes that there has been a data breach; (2) cooperate with the City as reasonably requested by the City to investigate and resolve the data breach and provide daily updates; (3) quarantine the data breach and ensure secure access to City Data; (4) promptly implement necessary remedial measures; and (5) document responsive actions taken related to the data breach. Background Checks. As permitted or required by law, the Contractor shall conduct criminal background checks and not utilize any staff, including subcontractors, to fulfill the obligations of the Agreement who have been convicted of any crime of dishonesty, Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 Limiting the City's ability to terminate the Agr a. is for the provision of Public Cloud Services where City's sensitive data may be exchanged, b. c. accordance with standard industry practices for such data. In no event may Contractor's d. e. billine@when2work.com Page 10of www.w2w.com including but not limited to criminal fraud, or otherwise convicted of any felony or any misdemeanor offense for which incarceration for up to 1 year is an authorized penalty. The information among the Contractor Information Technology Access. Contractor shall endeavor to make all electronic and information technology procured through this Agreement meet the applicable accessibility standards of Section 508 of the Rehabilitation Act of 1973 (29 U.S.C. 794d) as amended and is viewable at http://www.section508.gov. Further, the Contractor assures the City that the Contractor will strive to comply with the American with Disabilities Act of 1990 (42 US.C. 12101 et seq.), including implementing title II of the Americans with Disabilities Act to establish specific requirements, including the adoption of specific technical standards, for making accessible the services, programs, and activities offered by State and local government entities to the public through the web and mobile 2024 (89 FR 31320.). And in accordance with California Government Code Section 7405(b), the Contractor shall strive to respond to and resolve any complaint regarding accessibility that is brought to the attention of the Contractor. Patent, Copyright and Trade Secret Indemnity. To the fullest extent permitted by law, Contractor will indemnify, defend, and hold harmless the City, its officers, elected and appointed officials, employees, and volunteers from any and all third-party claims, costs (including without limitation reaso infringement or violation of any U.S. Intellectual Property Right by any product or service provided by this Agreement. With respect to claims arising from software manufactured by a third party and sold by Contractor as reseller, Contractor will pass through to the City such indemnity rights as it receives from such third party and will cooperate in its enforcement. i. or any par become, the subject of a claim for infringement of a third party intellectual property right, then Contractor shall, at its sole option and expense: (i) procure for City the right to use and access the infringing or potentially infringing item(s) of the replace or modify the Infringing Item with a non-infringing substitute otherwise materially complying with the functionality of the replaced system; or (iii) if neither of the foregoing is reasonably practicable, terminate the right to use and access the Infringing Item and refund a prorated amount of any amount already paid. Warranty. Contractor warrants that the appliable product and services (1) will substantially conform to the requirements of the Agreement; (2) will be free of material defects and will be performed with professional care and skill; (3) will be free, at the time of delivery, of harmful code (e.g., computer viruses, worms, trap doors, time bombs, disabling code, or any similar malicious mechanism designed to interfere with the intended operation of, or cause damage to, computers, data, or software; (4) will not infringe or violate any U.S. Intellectual Property Right; and (5) if software, perform in accordance with the software license and accompanying manuals and other printed documents. Further, to the extent Contractor is legally able to do so, Contractor warrants it will pass through any applicable third-party warranties to the City and will reasonably cooperate in enforcing them. Cyber Liability Insurance. At all times during the performance of work under this Agreement Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 f. g. h. i. Contractor shall promote and maintain an awareness of importance of securing the City's 's employee and agents. the Department of Justice's final rule revising the regulation applications {"apps") which becomes effective June 24, nable attorneys' fees), damages, and losses for Aside from Contractor's indemnification obligation, should the product or services t thereof become, or in Contractor's reasonable opinion be likely to service or product ("Infringing Item") free of any liability for infringement; or (ii) billine@when2work.com Page 11 of www.w2w.com and for sixty (60) months following the date of Agreement termination, the Contractor will carry and maintain, at its own expense, Cyber Liability insurance with limits of not less than $1,000,000 per occurrence or claim, and $2,000,000 aggregate. 5. ity for damages to Contractor for any cause whatsoever arising out of or relating to this Agreement, and regardless of the theory of liability shall be limited to the total fees paid or payable by City to Contractor for the twelve-month period immediately preceding the date the cause of action arose. The existence of more than one claim shall not expand such limit. This limitation will apply notwithstanding any failure of any essential purpose of any limited remedy. IN WITNESS WHEREOF, the parties have obtained all necessary approvals and have caused the Agreement and this addendum to the Agreement to be executed by their duly authorized representatives. CONTRACTOR CITY OF CARLSBAD By: By: (sign here) IT Director (print name/title) Attest: By: (sign here) SHERRY FREISINGER City Clerk (print name/title) APPROVED AS TO FORM: CINDIE K. McMAHON, City Attorney BY: _____________________________ Deputy City Attorney Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599DB456 City's Limitation on Liability. The City's liabil Whitney Leifeste Director of Legal Services By: for (sign here) SHERRY FREISINGER billine@when2work.com Page 12 of www.w2w.com INSURANCE REQUIREMENTS 1.0 INSURANCE Contractor will obtain and maintain for the duration of the Agreement and any and all amendments, insurance against claims for injuries to persons or damage to property which may arise out of or in connection with performance of the services employees or subcontractors. The insurance will be obtained from an insurance carrier admitted and authorized to do business in the State of California. The insurance carrier is required to have a current Best's Key Rating of not less than "A- non-admitted insurer listed by the National Association of Insurance Commissioners (NAIC) latest quarterly listings report. 1.1 Coverages and Limits. Contractor will maintain the types of coverages and minimum limits indicated below, unless Risk Manager or City Manager approves a lower amount. These minimum amounts of coverage will not constitute any limitations or cap on Contractor's indemnification obligations under this Agreement. City, its officers, agents and employees make no representation that the limits of the insurance specified to be carried by Contractor pursuant to this Agreement are adequate to protect Contractor. If Contractor believes that any required insurance coverage is inadequate, Contractor will obtain such additional insurance coverage, as Contractor deems adequate, at Contractor's sole expense. The full limits available to the named insured shall also be available and applicable to the City as an additional insured. 1.1.1 Commercial General Liability (CGL) Insurance basis, including personal & advertising injury, with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location or the general aggregate limit shall be twice the required occurrence limit. 1.1.2 Automobile Liability. If the use of an automobile is involved for Contractor's work for City, $2,000,000 combined single-limit per accident for bodily injury and property damage. 1.1.3 Workers' Compensation and Employer's Liability. Workers' Compensation limits as required by the California Labor Code. Workers' Compensation will not be required if Contractor has no employees and provides, to City's satisfaction, a declaration stating this. 1.1.4 Professional Liability. profession with limits of not less than $1,000,000 per claim. Coverage must be maintained for a period of five years following the date of completion of the work. 1.2 Additional Provisions. Contractor will ensure that the policies of insurance required under this Agreement contain, or are endorsed to contain, the following provisions: 1.2.1 The City will be named as an additional insured on Commercial General Liability which shall provide primary coverage to the City. 1.2.2 Contractor will obtain occurrence coverage, excluding Professional Liability, which will be written as claims-made coverage. Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 ADDENDUM "B" by Contractor or Contractor's agents, representatives, :VII"; OR with a surplus line insurer on the State of California's List of Approved Surplus Line Insurers (LASLI) with a rating in the latest Best's Key Rating Guide of at least "A:X"; OR an alien . Insurance written on an "occurrence" Errors and omissions liability appropriate to Contractor's billine@when2work.com Page 13of www.w2w.com 1.2.3 If Contractor maintains higher limits than the minimums shown above, the City requires and will be entitled to coverage for the higher limits maintained by Contractor. Any available insurance proceeds in excess of the specified minimum limits of insurance and coverage will be 1.2.4 This insurance will be in force during the life of the Agreement and any extensions of it and will not be canceled without thirty (30) days prior written notice to City sent by certified mail pursuant to the Notice provisions of this Agreement. 1.3 Providing Certificates of Insurance and Endorsements. Prior to City's execution of this Agreement, Contractor will furnish certificates of insurance and endorsements to City. 1.4 Failure to Maintain Coverage. If Contractor fails to maintain any of these insurance coverages, then City will have the option to declare Contractor in breach, or may purchase replacement insurance or pay the premiums that are due on existing policies in order to maintain the required coverages. Contractor is responsible for any payments made by City to obtain or maintain insurance and City may collect these payments from Contractor or deduct the amount paid from any sums due Contractor under this Agreement. 1.5 Submission of Insurance Policies. City reserves the right to require, at any time, complete and certified copies of any or all required insurance policies and endorsements. Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 available to the City." billine@when2work.com Page 14of www.w2w.com SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBRWVDADDLINSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THISCERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED?(Mandatory in NH) DESCRIPTION OF OPERATIONS belowIf yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIREDAUTOS ONLY Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 ~ ACORD® I ~ 9/16/2024 Higginbotham Insurance Agency, Inc. Morayma Gonzalez 817-336-1197 I 817-347-6981 500 W. 13th Street Fort Worth TX 76102 mgonzalez@higginbotham.com License#: 2081754 Hartford Fire Insurance Company 19682 TCPSOFT--01 Trumbull Insurance Comoanv 27120 TCP Hawker Holdings, TimeClock Plus, LLC, Aladtec LLC, Hartford Casualty Insurance Company 29424 Humanity.com LLC, TimeCo Systems LLC, WhenToWork LLC Indian Harbor Insurance Company 36940 1 Time Clock Drive Crum & Forster Specialty Insurance Company 44520 San Angelo TX 76904 Twin City Fire Insurance Company 29459 609963570 A X 46UUNAW9LX6 4/15/2024 4/15/2025 1,000,000 ~ □ [Kl 1,000,000 10,000 ~ ~ 1,000,000 2,000,000 ~ □ □ 2,000,000 B 46UENEL4585 4/15/2024 4/15/2025 1,000,000 ~ ~ ~ ~ ~ X X ~ ~ C X M 46XHUAW9P8R 4/15/2024 4/15/2025 5,000,000 ~ 5,000,000 IX I an nnn F 46WEAW9LWS 4/15/2024 4/15/2025 X I I I ~ 1,000,000 1,000,000 1,000,000 D Technology E & O/Cyber MTP9046254 01 4/15/2024 4/15/2025 limit $5,000,000 E EXCESS TECHNOLOGY E&O/CYBER EOL-241207 4/15/2024 4/15/2025 limit $5,000,000 The General Liability and Automobile Liability policy includes a blanket automatic additional insured endorsement that provides additional insured status to the certificate holder only when there is a written contract between the named insured and the certificate holder that requires such status. The General Liability, Automobile Liability and Workers' Compensation policy includes a blanket waiver of subrogation endorsement to the certificate holder only when there is a written contract between the named insured and the certificate holder that requires such status. The General Liability policy has a blanket Primary & Non-Contributory endorsement that affords that coverage to certificate holders when required by written contract. See Attached ... City of Carlsbad 1635 Faraday Avenue ~, Carlsbad, CA 92008 ~ ... ~ I ACORD 101 (2008/01) The ACORD name and logo are registered marks of ACORD © 2008 ACORD CORPORATION. All rights reserved. THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER:FORM TITLE: ADDITIONAL REMARKS ADDITIONAL REMARKS SCHEDULE Page of AGENCY CUSTOMER ID: LOC #: AGENCY CARRIER NAIC CODE POLICY NUMBER NAMED INSURED EFFECTIVE DATE: Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 TCPSOFT-01 Higginbotham Insurance Agency, Inc. TCP Hawker Holdings, TimeClock Plus, LLC, Aladtec LLC, Humanity.com LLC, TimeCo Systems LLC, WhenToWork LLC 1 Time Clock Drive I San Angelo TX 76904 25 CERTIFICATE OF LIABILITY INSURANCE Umbrella is follow-form. Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 Pol#46UUNAW9LX6 HARTFORD COMMERCIAL GENERAL LIABILITY COVERAGE FORM Various provisions in this policy restrict coverage. Read the entire policy carefully to determine rights, duties and what is and is not covered . Throughout this policy the words "you" and "your" refer to the Named Insured shown in the Declarations, and any other person or organization qualifying as a Named Insured under this policy. The words "we", "us" and "our" refer to the stock insurance company member of The Hartford providing this insurance. The word "insured" means any person or organization qualifying as such under Section II -Who Is An Insured. Other words and phrases that appear in quotation marks have special meaning. Refer to Section V -Definitions. SECTION I -COVERAGES COVERAGE A BODILY INJURY AND PROPERTY DAMAGE LIABILITY 1. Insuring Agreement a. We will pay those sums that the insured becomes legally obligated to pay as damages because of "bodily injury" or "property damage" to which this insurance applies. We will have the right and duty to defend the insured against any "suit" seeking those damages. However, we will have no duty to defend the insured against any "suit" seeking damages for "bodily injury" or "property damage" to which this insurance does not apply. We may, at our discretion, investigate any "occurrence" and settle any claim or "suit" that may result. But: (1) The amount we will pay for damages is limited as described in Section Ill -Limits Of Insurance; and (2) Our right and duty to defend ends when we have used up the applicable limit of insurance in the payment of judgments or settlements under Coverages A or B or medical expenses under Coverage C. No other obligation or liability to pay sums or perform acts or services is covered unless explicitly provided for under Supplementary Payments -Coverages A and B. b. This insurance applies to "bodily injury" and "property damage" only if: (1) The "bodily injury" or "property damage" is caused by an "occurrence" that takes place in the "coverage territory"; (2) The "bodily injury" or "property damage" occurs during the policy period; and (3) Prior to the policy period, no insured listed under Paragraph 1. of Section II -Who Is An Insured and no "employee" authorized by you to give or receive notice of an "occurrence" or claim, knew that the "bodily injury" or "property damage" had occurred, in whole or in part. If such a listed insured or authorized "employee" knew, prior to the policy period, that the "bodily injury" or "property damage" occurred, then any continuation, change or resumption of such "bodily injury" or "property damage" during or after the policy period will be deemed to have been known prior to the policy period. c. "Bodily injury" or "property damage" will be deemed to have been known to have occurred at the earliest time when any insured listed under Paragraph 1. of Section II -Who Is An Insured or any "employee" authorized by you to give or receive notice of an "occurrence" or claim: (1) Reports all, or any part, of the "bodily injury" or "property damage" to us or any other insurer; (2) Receives a written or verbal demand or claim for damages because of the "bodily injury" or "property damage"; or (3) Becomes aware by any other means that "bodily injury" or "property damage" has occurred or has begun to occur. d. Damages because of "bodily injury" include damages claimed by any person or organization for care, loss of services or death resulting at any time from the "bodily injury". e. Incidental Medical Malpractice And Good Samaritan Coverage "Bodily injury" arising out of the rendering of or failure to render the following health care services by any "employee" or "volunteer worker" shall be deemed to be caused by an "occurrence" for: Form HG 00 01 0916 Page 1 of 22 © 2016 The Hartford (Includes copyrighted material of Insurance Services Office, Inc. with its permission.) Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 (1) Professional health care services such as: (a) Medical, surgical, dental, laboratory, x-ray or nursing services or treatment, advice or instruction, or the related furnishing of food or beverages; (b) Any health or therapeutic service, treatment, advice or instruction; or (c) The furnishing or dispensing of drugs or medical, dental, or surgical supplies or appliances; or (2) First aid services, which include: (a) Cardiopulmonary resuscitation, whether performed manually or with a defibrillator; or (b) Services performed as a Good Samaritan. For the purpose of determining the limits of insurance, any act or omission together with all related acts or omissions in the furnishing of these services to any one person will be considered one "occurrence". However, this Incidental Medical Malpractice And Good Samaritan Coverage provision applies only if you are not engaged in the business or occupation of providing any of the services described in this provision. 2. Exclusions This insurance does not apply to: a. Expected Or Intended Injury "Bodily injury" or "property damage" expected or intended from the standpoint of the insured. This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property. b. Contractual Liability "Bodily injury" or "property damage" for which the insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages: (1) That the insured would have in the absence of the contract or agreement; or (2) Assumed in a contract or agreement that is an "insured contract", provided the "bodily injury" or "property damage" occurs subsequent to the execution of the contract or agreement. Solely for the purposes of liability assumed in an "insured contract", reasonable attorney fees and necessary litigation expenses incurred by or for a party other than an insured are deemed to be damages because of "bodily injury" or "property damage", provided: (a) Liability to such party for, or for the cost of, that party's defense has also been assumed in the same "insured contract"; and (b) Such attorney fees and litigation expenses are for defense of that party against a civil or alternative dispute resolution proceeding in which damages to which this insurance applies are alleged. c. Liquor Liability "Bodily injury" or "property damage" for which any insured may be held liable by reason of: (1) Causing or contributing to the intoxication of any person; (2) The furnishing of alcoholic beverages to a person under the legal drinking age or under the influence of alcohol; or (3) Any statute, ordinance or regulation relating to the sale, gift, distribution or use of alcoholic beverages. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in: (a) The supervision, hiring, employment, training or monitoring of others by that insured; or (b) Providing or failing to provide transportation with respect to any person that may be under the influence of alcohol; if the "occurrence" which caused the "bodily injury" or "property damage", involved that which is described in Paragraph (1), (2) or (3) above. However, this exclusion applies only if you are in the business of manufacturing, distributing, selling, serving or furnishing alcoholic beverages. For the purposes of this exclusion, permitting a person to bring alcoholic beverages on your premises, for consumption on your premises, whether or not a fee is charged or a license is required for such activity, is not by itself considered the business of selling, serving or furnishing alcoholic beverages. d. Workers' Compensation And Similar Laws Any obligation of the insured under a workers' compensation, disability benefits or unemployment compensation law or any similar law. Page 2 of 22 Form HG 00 01 0916 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 e. Employer's Liability "Bodily injury" to: (1) An "employee" of the insured arising out of and in the course of: (a) Employment by the insured; or (b) Performing duties related to the conduct of the insured's business; or (2) The spouse, child, parent, brother or sister of that "employee" as a consequence of Paragraph (1) above. This exclusion applies: (1) Whether the insured may be liable as an employer or in any other capacity; and (2) To any obligation to share damages with or repay someone else who must pay damages because of the injury. This exclusion does not apply to liability assumed by the insured under an "insured contract". f. Pollution (1) "Bodily injury" or "property damage" arising out of the actual, alleged or threatened discharge, dispersal, seepage, migration, release or escape of "pollutants": (a) At or from any premises, site or location which is or was at any time owned or occupied by, or rented or loaned to, any insured. However, this subparagraph does not apply to: (i) "Bodily injury" if sustained within a building and caused by smoke, fumes, vapor or soot produced by or originating from equipment that is used to heat, cool or dehumidify the building, or equipment that is used to heat water for personal use, by the building's occupants or their guests; (ii) "Bodily injury" or "property damage" for which you may be held liable, if you are a contractor and the owner or lessee of such premises, site or location has been added to your policy as an additional insured with respect to your ongoing operations performed for that additional insured at that premises, site or location and such premises, site or location is not and never was owned or occupied by, or rented or loaned to, any insured, other than that additional insured; or (iii) "Bodily injury" or "property damage" arising out of heat, smoke or fumes from a "hostile fire"; (b) At or from any premises, site or location which is or was at any time used by or for any insured or others for the handling, storage, disposal, processing or treatment of waste; (c) Which are or were at any time transported, handled, stored, treated, disposed of, or processed as waste by or for: (i) Any insured; or (ii) Any person or organization for whom you may be legally responsible; (d) At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the "pollutants" are brought on or to the premises, site or location in connection with such operations by such insured, contractor or subcontractor. However, this subparagraph does not apply to: (i) "Bodily injury" or "property damage" arising out of the escape of fuels, lubricants or other operating fluids which are needed to perform the normal electrical, hydraulic or mechanical functions necessary for the operation of "mobile equipment" or its parts, if such fuels, lubricants or other operating fluids escape from a vehicle part designed to hold, store or receive them. This exception does not apply if the "bodily injury" or "property damage" arises out of the intentional discharge, dispersal or release of the fuels, lubricants or other operating fluids, or if such fuels, lubricants or other operating fluids are brought on or to the premises, site or location with the intent that they be discharged, dispersed or released as part of the operations being performed by such insured, contractor or subcontractor; (ii) "Bodily injury" or "property damage" sustained within a building and caused by the release of gases, fumes or vapors from materials brought into that building in connection with operations being performed by you or on your behalf by a contractor or subcontractor; or (iii) "Bodily injury" or "property damage" arising out of heat, smoke or fumes from a "hostile fire"; or (e) At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the operations are to test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants". Form HG 00 01 0916 Page 3 of 22 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 (2) Any loss, cost or expense arising out of any: (a) Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants"; or (b) Claim or suit by or on behalf of a governmental authority for damages because of testing for, monitoring, cleaning up, removing, containing, treating, detoxifying or neutralizing, or in any way responding to, or assessing the effects of, "pollutants". However, this paragraph does not apply to liability for damages because of "property damage" that the insured would have in the absence of such request, demand, order or statutory or regulatory requirement, or such claim or "suit" by or on behalf of a governmental authority. g. Aircraft, Auto Or Watercraft "Bodily injury" or "property damage" arising out of the ownership, maintenance, use or entrustment to others of any aircraft, "auto" or watercraft owned or operated by or rented or loaned to any insured. Use includes operation and "loading or unloading". This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage" involved the ownership, maintenance, use or entrustment to others of any aircraft, "auto" or watercraft that is owned or operated by or rented or loaned to any insured. This exclusion does not apply to: (1) A watercraft while ashore on premises you own or rent; (2) A watercraft you do not own that is: (a) Less than 51 feet long; and (b) Not being used to carry persons for a charge; (3) Parking an "auto" on, or on the ways next to, premises you own or rent, provided the "auto" is not owned by or rented or loaned to you or the insured; (4) Liability assumed under any "insured contract" for the ownership, maintenance or use of aircraft or watercraft; (5) "Bodily injury" or "property damage" arising out of: (a) The operation of machinery or equipment that is attached to, or part of, a land vehicle that would qualify under the definition of "mobile equipment" if it were not subject to a compulsory or financial responsibility law or other motor vehicle insurance law where it is licensed or principally garaged; or (b) The operation of any of the machinery or equipment listed in Paragraph f.(2) or f.(3) of the definition of "mobile equipment"; or (6) An aircraft that is not owned by any insured and is hired, chartered or loaned with a paid crew. However, this exception does not apply if the insured has any other insurance for such "bodily injury" or "property damage", whether the other insurance is primary, excess, contingent or on any other basis. h. Mobile Equipment "Bodily injury" or "property damage" arising out of: (1) The transportation of "mobile equipment" by an "auto" owned or operated by or rented or loaned to any insured; or (2) The use of "mobile equipment" in, or while in practice for, or while being prepared for, any prearranged racing, speed, demolition, or stunting activity. i. War "Bodily injury" or "property damage", however caused, arising, directly or indirectly, out of: (1) War, including undeclared or civil war; (2) Warlike action by a military force, including action in hindering or defending against an actual or expected attack, by any government, sovereign or other authority using military personnel or other agents; or (3) Insurrection, rebellion, revolution, usurped power, or action taken by governmental authority in hindering or defending against any of these. j. Damage To Property "Property damage" to: (1) Property you own, rent, or occupy, including any costs or expenses incurred by you, or any other person, organization or entity, for repair, replacement, enhancement, restoration or maintenance of such property for any reason, including prevention of injury to a person or damage to another's property; Page 4 of 22 Form HG 00 01 09 16 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 (2) Premises you sell, give away or abandon, if the "property damage" arises out of any part of those premises; (3) Property loaned to you; (4) Personal property in the care, custody or control of the insured; (5) That particular part of real property on which you or any contractors or subcontractors working directly or indirectly on your behalf are performing operations, if the "property damage" arises out of those operations; or (6) That particular part of any property that must be restored, repaired or replaced because "your work" was incorrectly performed on it. Paragraphs (1), (3) and (4) of this exclusion do not apply to "property damage" (other than damage by fire) to premises, including the contents of such premises, rented to you for a period of seven or fewer consecutive days. A separate limit of insurance applies to Damage To Premises Rented To You as described in Section Ill -Limits Of Insurance. Paragraph (2) of this exclusion does not apply if the premises are "your work" and were never occupied, rented or held for rental by you. Paragraphs (3) and (4) of this exclusion do not apply to "property damage" arising from the use of elevators. Paragraphs (3), (4), (5) and (6) of this exclusion do not apply to liability assumed under a sidetrack agreement. Paragraphs (3) and (4) of this exclusion do not apply to "property damage" to borrowed equipment while not being used to perform operations at the job site. Paragraph (6) of this exclusion does not apply to "property damage" included in the "products-completed operations hazard". k. Damage To Your Product "Property damage" to "your product" arising out of it or any part of it. I. Damage To Your Work "Property damage" to "your work" arising out of it or any part of it and included in the "products-completed operations hazard". This exclusion does not apply if the damaged work or the work out of which the damage arises was performed on your behalf by a subcontractor. m. Damage To Impaired Property Or Property Not Physically Injured "Property damage" to "impaired property" or property that has not been physically injured, arising out of: (1) A defect, deficiency, inadequacy or dangerous condition in "your product" or "your work"; or (2) A delay or failure by you or anyone acting on your behalf to perform a contract or agreement in accordance with its terms. This exclusion does not apply to the loss of use of other property arising out of sudden and accidental physical injury to "your product" or "your work" after it has been put to its intended use. n. Recall Of Products, Work Or Impaired Property Damages claimed for any loss, cost or expense incurred by you or others for the loss of use, withdrawal, recall, inspection, repair, replacement, adjustment, removal or disposal of: (1) "Your product"; (2) "Your work"; or (3) "Impaired property"; if such product, work, or property is withdrawn or recalled from the market or from use by any person or organization because of a known or suspected defect, deficiency, inadequacy or dangerous condition in it. o. Personal And Advertising Injury "Bodily injury" arising out of "personal and advertising injury". p. Access or Disclosure Of Confidential Or Personal Information And Data-related Liability Damages arising out of: (1) Any access to or disclosure of any person's or organization's confidential or personal information, including patents, trade secrets, processing methods, customer lists, financial information, credit card information, health information or any other type of nonpublic information; or (2) The loss of, loss of use of, damage to, corruption of, inability to access, or inability to manipulate electronic data. Form HG 00 01 0916 Page 5 of 22 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 This exclusion applies even if damages are claimed for notification costs, credit monitoring expenses, forensic expenses, public relations expenses or any other loss, cost or expense incurred by you or others arising out of that which is described in Paragraph (1) or (2) above. However, unless Paragraph (1) above applies, this exclusion does not apply to damages because of "bodily injury". As used in this exclusion, electronic data means information, facts or programs stored as or on, created or used on, or transmitted to or from computer software, including systems and applications software, hard or floppy disks, CD-ROMS, tapes, drives, cells, data processing devices or any other media which are used with electronically controlled equipment. q. Employment-Related Practices "Bodily injury" to: (1) A person arising out of any "employment-related practices"; or (2) The spouse, child, parent, brother or sister of that person as a consequence of "bodily injury" to that person at whom any "employment-related practices" are directed. This exclusion applies: (1) Whether the injury-causing event described in the definition of "employment-related practices" occurs before employment, during employment or after employment of that person; (2) Whether the insured may be liable as an employer or in any other capacity; and (3) To any obligation to share damages with or repay someone else who must pay damages because of the injury. r. Asbestos (1) "Bodily injury" or "property damage" arising out of the "asbestos hazard". (2) Any damages, judgments, settlements, loss, costs or expenses that: (a) May be awarded or incurred by reason of any claim or suit alleging actual or threatened injury or damage of any nature or kind to persons or property which would not have occurred in whole or in part but for the "asbestos hazard"; (b) Arise out of any request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, encapsulate, contain, treat, detoxify or neutralize or in any way respond to or assess the effects of an "asbestos hazard"; or (c) Arise out of any claim or suit for damages because of testing for, monitoring, cleaning up, removing, encapsulating, containing, treating, detoxifying or neutralizing or in any way responding to or assessing the effects of an "asbestos hazard". s. Recording And Distribution Of Material Or Information In Violation Of Law "Bodily injury" or "property damage" arising directly or indirectly out of any action or omission that violates or is alleged to violate: (1) The Telephone Consumer Protection Act (TCPA), including any amendment of or addition to such law; (2) The CAN-SPAM Act of 2003, including any amendment of or addition to such law; (3) The Fair Credit Reporting Act (FCRA), and any amendment of or addition to such law, including the Fair and Accurate Credit Transaction Act (FACTA); or (4) Any federal, state or local statute, ordinance or regulation, other than the TCPA or CAN-SPAM Act of 2003 or FCRA and their amendments and additions, that addresses, prohibits or limits the printing, dissemination, disposal, collecting, recording, sending, transmitting, communicating or distribution of material or information. Damage To Premises Rented To You -Exception For Damage By Fire, Lightning Or Explosion Exclusions c. through h. and j. through n. do not apply to damage by fire, lightning or explosion to premises while rented to you or temporarily occupied by you with permission of the owner. A separate limit of insurance applies to this coverage as described in Section Ill -Limits Of Insurance. COVERAGE B PERSONAL AND ADVERTISING INJURY LIABILITY 1. Insuring Agreement a. We will pay those sums that the insured becomes legally obligated to pay as damages because of "personal and advertising injury" to which this insurance applies. We will have the right and duty to defend the insured against any "suit" seeking those damages. However, we will have no duty to defend the insured against any "suit" seeking damages for "personal and advertising injury" to which this insurance does not apply. We may, at our discretion, investigate any offense and settle any claim or "suit" that may result. But: Page 6 of 22 Form HG 00 01 0916 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 (1) The amount we will pay for damages is limited as described in Section Ill -Limits Of Insurance; and (2) Our right and duty to defend end when we have used up the applicable limit of insurance in the payment of judgments or settlements under Coverages A or B or medical expenses under Coverage C. No other obligation or liability to pay sums or perform acts or services is covered unless explicitly provided for under Supplementary Payments -Coverages A and B. b. This insurance applies to "personal and advertising injury" caused by an offense arising out of your business but only if the offense was committed in the "coverage territory" during the policy period. 2. Exclusions This insurance does not apply to: a. Knowing Violation Of Rights Of Another "Personal and advertising injury" arising out of an offense committed by, at the direction or with the consent or acquiescence of the insured with the expectation of inflicting "personal and advertising injury". b. Material Published With Knowledge Of Falsity "Personal and advertising injury" arising out of oral, written or electronic publication, in any manner, of material, if done by or at the direction of the insured with knowledge of its falsity. c. Material Published Prior To Policy Period "Personal and advertising injury" arising out of oral, written or electronic publication, in any manner, of material whose first publication took place before the beginning of the policy period. d. Criminal Acts "Personal and advertising injury" arising out of a criminal act committed by or at the direction of the insured. e. Contractual Liability "Personal and advertising injury" for which the insured has assumed liability in a contract or agreement. This exclusion does not apply to liability for damages that the insured would have in the absence of the contract or agreement. f. Breach Of Contract "Personal and advertising injury" arising out of a breach of contract, except an implied contract to use another's "advertising idea" in your "advertisement". g. Quality Or Performance Of Goods -Failure To Conform To Statements "Personal and advertising injury" arising out of the failure of goods, products or services to conform with any statement of quality or performance made in your "advertisement". h. Wrong Description Of Prices "Personal and advertising injury" arising out of the wrong description of the price of goods, products or services. i. Infringement Of Intellectual Property Rights (1) "Personal and advertising injury" arising out of any actual or alleged infringement or violation of any intellectual property rights such as copyright, patent, trademark, trade name, trade secret, trade dress, service mark or other designation of origin or authenticity; or (2) Any injury or damage alleged in any clam or "suit" that also alleges an infringement or violation of any intellectual property right, whether such allegation of infringement or violation is made by you or by any other party involved in the claim or "suit", regardless of whether this insurance would otherwise apply. However, this exclusion does not apply if the only allegation in the claim or "suit" involving any intellectual property right is limited to: (1) Infringement, in your "advertisement", of: (a) Copyright; (b) Slogan; or (c) Title of any literary or artistic work; or (2) Copying, in your "advertisement", a person's or organization's "advertising idea" or style of "advertisement". j. Insureds In Media And Internet Type Businesses "Personal and advertising injury" committed by an insured whose business is: (1) Advertising, broadcasting, publishing or telecasting; (2) Designing or determining content of web sites for others; or (3) An Internet search, access, content or service provider. Form HG 00 01 0916 Page 7 of 22 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 However, this exclusion does not apply to Paragraphs a., b. and c. of the definition of "personal and advertising injury" under the Definitions Section. For the purposes of this exclusion, the placing of frames, borders or links, or advertising, for you or others anywhere on the Internet, is not by itself, considered the business of advertising, broadcasting, publishing or telecasting. k. Electronic Chatrooms Or Bulletin Boards "Personal and advertising injury" arising out of an electronic chatroom or bulletin board the insured hosts, owns, or over which the insured exercises control. I. Unauthorized Use Of Another's Name Or Product "Personal and advertising injury" arising out of the unauthorized use of another's name or product in your e-mail address, domain name or metatags, or any other similar tactics to mislead another's potential customers. m. Pollution "Personal and advertising injury" arising out of the actual, alleged or threatened discharge, dispersal, seepage, migration, release or escape of "pollutants" at any time. n. Pollution-Related Any loss, cost or expense arising out of any: (1) Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants"; or (2) Claim or suit by or on behalf of a governmental authority for damages because of testing for, monitoring, cleaning up, removing, containing, treating, detoxifying or neutralizing, or in any way responding to, or assessing the effects of, "pollutants". o. War "Personal and advertising injury", however caused, arising, directly or indirectly, out of: (1) War, including undeclared or civil war; (2) Warlike action by a military force, including action in hindering or defending against an actual or expected attack, by any government, sovereign or other authority using military personnel or other agents; or (3) Insurrection, rebellion, revolution, usurped power, or action taken by governmental authority in hindering or defending against any of these. p. Internet Advertisements And Content Of Others "Personal and advertising injury" arising out of: (1) An "advertisement" for others on your web site; (2) Placing a link to a web site of others on your web site; (3) Content, including information, sounds, text, graphics, or images from a web site of others displayed within a frame or border on your web site; or (4) Computer code, software or programming used to enable: (a) Your web site; or (b) The presentation or functionality of an "advertisement" or other content on your web site. q. Right Of Privacy Created By Statute "Personal and advertising injury" arising out of the violation of a person's right of privacy created by any state or federal act. However, this exclusion does not apply to liability for damages that the insured would have in the absence of such state or federal act. r. Violation Of Anti-Trust law "Personal and advertising injury" arising out of a violation of any anti-trust law. s. Securities "Personal and advertising injury" arising out of the fluctuation in price or value of any stocks, bonds or other securities. t. Recording And Distribution Of Material Or Information In Violation Of Law "Personal and advertising injury" arising directly or indirectly out of any action or omission that violates or is alleged to violate: Page 8 of 22 Form HG 00 01 0916 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 (1) The Telephone Consumer Protection Act (TCPA), including any amendment of or addition to such law; (2) The CAN-SPAM Act of 2003, including any amendment of or addition to such law; (3) The Fair Credit Reporting Act (FCRA), and any amendment of or addition to such law, including the Fair and Accurate Credit Transaction Act (FACTA); or (4) Any federal, state or local statute, ordinance or regulation, other than the TCPA or CAN-SPAM Act of 2003 or FCRA and their amendments and additions, that addresses, prohibits or limits the printing, dissemination, disposal, collecting, recording, sending, transmitting, communicating or distribution of material or information. u. Employment-Related Practices "Personal and advertising injury" to: (1) A person arising out of any "employment-related practices"; or (2) The spouse, child, parent, brother or sister of that person as a consequence of "personal and advertising injury" to that person at whom any "employment-related practices" are directed. This exclusion applies: (1) Whether the injury-causing event described in the definition of "employment-related practices" occurs before employment, during employment or after employment of that person; (2) Whether the insured may be liable as an employer or in any other capacity; and (3) To any obligation to share damages with or repay someone else who must pay damages because of the injury. v. Asbestos (1) "Personal and advertising injury" arising out of the "asbestos hazard". (2) Any damages, judgments, settlements, loss, costs or expenses that: (a) May be awarded or incurred by reason of any claim or suit alleging actual or threatened injury or damage of any nature or kind to persons or property which would not have occurred in whole or in part but for the "asbestos hazard"; (b) Arise out of any request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, encapsulate, contain, treat, detoxify or neutralize or in any way respond to or assess the effects of an "asbestos hazard"; or (c) Arise out of any claim or suit for damages because of testing for, monitoring, cleaning up, removing, encapsulating, containing, treating, detoxifying or neutralizing or in any way responding to or assessing the effects of an "asbestos hazard". w. Access Or Disclosure Of Confidential Or Personal Information "Personal and advertising injury" arising out of any access to or disclosure of any person's or organization's confidential or personal information, including patents, trade secrets, processing methods, customer lists, financial information, credit card information, health information or any other type of nonpublic information. This exclusion applies even if damages are claimed for notification costs, credit monitoring expenses, forensic expenses, public relations expenses or any other loss, cost or expense incurred by you or others arising out of any access to or disclosure of any person's or organization's confidential or personal information. COVERAGE C MEDICAL PAYMENTS 1. Insuring Agreement a. We will pay medical expenses as described below for "bodily injury" caused by an accident: (1) On premises you own or rent; (2) On ways next to premises you own or rent; or (3) Because of your operations; provided that: (1) The accident takes place in the "coverage territory" and during the policy period; (2) The expenses are incurred and reported to us within three years of the date of the accident; and (3) The injured person submits to examination, at our expense, by physicians of our choice as often as we reasonably require. b. We will make these payments regardless of fault. These payments will not exceed the applicable limit of insurance. We will pay reasonable expenses for: (1) First aid administered at the time of an accident; (2) Necessary medical, surgical, X-ray and dental services, including prosthetic devices; and Form HG 00 01 0916 Page 9 of 22 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 (3) Necessary ambulance, hospital, professional nursing and funeral services. 2. Exclusions We will not pay expenses for "bodily injury": a. Any Insured To any insured, except "volunteer workers". b. Hired Person To a person hired to do work for or on behalf of any insured or a tenant of any insured. c. Injury On Normally Occupied Premises To a person injured on that part of premises you own or rent that the person normally occupies. d. Workers Compensation And Similar Laws To a person, whether or not an "employee" of any insured, if benefits for the "bodily injury" are payable or must be provided under a workers' compensation or disability benefits law or a similar law. e. Athletics Activities To a person injured while practicing, instructing or participating in any physical exercises or games, sports, or athletic contests. f. Products-Completed Operations Hazard Included within the "products-completed operations hazard". g. Coverage A Exclusions Excluded under Coverage A. SUPPLEMENTARY PAYMENTS -COVERAGES A AND B 1. We will pay, with respect to any claim we investigate or settle, or any "suit" against an insured we defend: a. All expenses we incur. b. Up to $1,000 for cost of bail bonds required because of accidents or traffic law violations arising out of the use of any vehicle to which the Bodily Injury Liability Coverage applies. We do not have to furnish these bonds. c. The cost of appeal bonds or bonds to release attachments, but only for bond amounts within the applicable limit of insurance. We do not have to furnish these bonds. d. All reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or "suit", including actual loss of earnings up to $500 a day because of time off from work. e. All court costs taxed against the insured in the "suit". However, such costs do not include attorneys' fees, attorneys' expenses, witness or expert fees, or any other expenses of a party taxed to the insured. f. Prejudgment interest awarded against the insured on that part of the judgment we pay. If we make an offer to pay the applicable limit of insurance, we will not pay any prejudgment interest based on that period of time after the offer. g. All interest on the full amount of any judgment that accrues after entry of the judgment and before we have paid, offered to pay, or deposited in court the part of the judgment that is within the applicable limit of insurance. These payments will not reduce the limits of insurance. 2. If we defend an insured against a "suit" and an indemnitee of the insured is also named as a party to the "suit", we will defend that indemnitee if all of the following conditions are met: a. The "suit" against the indemnitee seeks damages for which the insured has assumed the liability of the indemnitee in a contract or agreement that is an "insured contract"; b. This insurance applies to such liability assumed by the insured; c. The obligation to defend, or the cost of the defense of, that indemnitee, has also been assumed by the insured in the same "insured contract"; d. The allegations in the "suit" and the information we know about the "occurrence" are such that no conflict appears to exist between the interests of the insured and the interests of the indemnitee; e. The indemnitee and the insured ask us to conduct and control the defense of that indemnitee against such "suit" and agree that we can assign the same counsel to defend the insured and the indemnitee; and f. The indemnitee: (1) Agrees in writing to: (a) Cooperate with us in the investigation, settlement or defense of the "suit"; Page 10 of 22 Form HG 00 01 0916 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 (b) Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the "suit"; (c) Notify any other insurer whose coverage is available to the indemnitee; and (d) Cooperate with us with respect to coordinating other applicable insurance available to the indemnitee; and (2) Provides us with written authorization to: (a) Obtain records and other information related to the "suit"; and (b) Conduct and control the defense of the indemnitee in such "suit". So long as the above conditions are met, attorneys' fees incurred by us in the defense of that indemnitee, necessary litigation expenses incurred by us and necessary litigation expenses incurred by the indemnitee at our request will be paid as Supplementary Payments. Notwithstanding the provisions of Paragraph 2.b.(2) of Section I -Coverage A - Bodily Injury And Property Damage Liability, such payments will not be deemed to be damages for "bodily injury" and "property damage" and will not reduce the limits of insurance. Our obligation to defend an insured's indemnitee and to pay for attorneys' fees and necessary litigation expenses as Supplementary Payments ends when: a. We have used up the applicable limit of insurance in the payment of judgments or settlements; or b. The conditions set forth above, or the terms of the agreement described in Paragraph f. above, are no longer met. SECTION II -WHO IS AN INSURED 1. If you are designated in the Declarations as: a. An individual, you and your spouse are insureds, but only with respect to the conduct of a business of which you are the sole owner. b. A partnership or joint venture, you are an insured. Your members, your partners, and their spouses are also insureds, but only with respect to the conduct of your business. c. A limited liability company, you are an insured. Your members are also insureds, but only with respect to the conduct of your business. Your managers are insureds, but only with respect to their duties as your managers. d. An organization other than a partnership, joint venture or limited liability company, you are an insured. Your "executive officers" and directors are insureds, but only with respect to their duties as your officers or directors. Your stockholders are also insureds, but only with respect to their liability as stockholders. e. A trust, you are an insured. Your trustees are also insureds, but only with respect to their duties as trustees. 2. Each of the following is also an insured: a. Employees And Volunteer Workers Your "volunteer workers" only while performing duties related to the conduct of your business, or your "employees", other than either your "executive officers" (if you are an organization other than a partnership, joint venture or limited liability company) or your managers (if you are a limited liability company), but only for acts within the scope of their employment by you or while performing duties related to the conduct of your business. However, none of these "employees" or "volunteer workers" are insureds for: (1) "Bodily injury" or "personal and advertising injury": (a) To you, to your partners or members (if you are a partnership or joint venture), to your members (if you are a limited liability company), to a co-"employee" while in the course of his or her employment or performing duties related to the conduct of your business, or to your other "volunteer workers" while performing duties related to the conduct of your business; (b) To the spouse, child, parent, brother or sister of that co-"employee" or that "volunteer worker'' as a consequence of Paragraph (1)(a) above; (c) For which there is any obligation to share damages with or repay someone else who must pay damages because of the injury described in Paragraphs (1 )(a) or (1 )(b) above; or (d) Arising out of his or her providing or failing to provide professional health care services. If you are not in the business of providing professional health care services: (a) Subparagraphs (1)(a), (1)(b) and (1)(c) above do not apply to any "employee" or "volunteer worker'' providing first aid services; and (b) Subparagraph (1)(d) above does not apply to any nurse, emergency medical technician or paramedic employed by you to provide such services. (2) "Property damage" to property: (a) Owned, occupied or used by, Form HG 00 01 0916 Page 11 of 22 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 (b) Rented to, in the care, custody or control of, or over which physical control is being exercised for any purpose by you, any of your "employees", "volunteer workers", any partner or member (if you are a partnership or joint venture), or any member (if you are a limited liability company). b. Real Estate Manager Any person (other than your "employee" or "volunteer worker"), or any organization while acting as your real estate manager. c. Temporary Custodians Of Your Property Any person or organization having proper temporary custody of your property if you die, but only: (1) With respect to liability arising out of the maintenance or use of that property; and (2) Until your legal representative has been appointed. d. Legal Representative If You Die Your legal representative if you die, but only with respect to duties as such. That representative will have all your rights and duties under this Coverage Part. e. Unnamed Subsidiary Any subsidiary, and subsidiary thereof, of yours which is a legally incorporated entity of which you own a financial interest of more than 50% of the voting stock on the effective date of the Coverage Part. The insurance afforded herein for any subsidiary not named in this Coverage Part as a named insured does not apply to injury or damage with respect to which such insured is also a named insured under another policy or would be a named insured under such policy but for its termination or the exhaustion of its limits of insurance. 3. Newly Acquired Or Formed Organization Any organization you newly acquire or form, other than a partnership, joint venture or limited liability company, and over which you maintain financial interest of more than 50% of the voting stock, will qualify as a Named Insured if there is no other similar insurance available to that organization. However: a. Coverage under this provision is afforded only until the 180th day after you acquire or form the organization or the end of the policy period, whichever is earlier; b. Coverage A does not apply to "bodily injury" or "property damage" that occurred before you acquired or formed the organization; and c. Coverage B does not apply to "personal and advertising injury" arising out of an offense committed before you acquired or formed the organization. 4. Nonowned Watercraft With respect to watercraft you do not own that is less than 51 feet long and is not being used to carry persons for a charge, any person is an insured while operating such watercraft with your permission. Any other person or organization responsible for the conduct of such person is also an insured, but only with respect to liability arising out of the operation of the watercraft, and only if no other insurance of any kind is available to that person or organization for this liability. However, no person or organization is an insured with respect to: a. "Bodily injury" to a co-"employee" of the person operating the watercraft; or b. "Property damage" to property owned by, rented to, in the charge of or occupied by you or the employer of any person who is an insured under this provision. 5. Additional Insureds When Required By Written Contract, Written Agreement Or Permit The following person(s) or organization(s) are an additional insured when you have agreed, in a written contract, written agreement or because of a permit issued by a state or political subdivision, that such person or organization be added as an additional insured on your policy, provided the injury or damage occurs subsequent to the execution of the contract or agreement. A person or organization is an additional insured under this provision only for that period of time required by the contract or agreement. However, no such person or organization is an insured under this provision if such person or organization is included as an insured by an endorsement issued by us and made a part of this Coverage Part. a. Vendors Any person(s) or organization(s) (referred to below as vendor), but only with respect to "bodily injury" or "property damage" arising out of "your products" which are distributed or sold in the regular course of the vendor's business Page 12 of 22 Form HG 00 01 09 16 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 and only if this Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products-completed operations hazard". (1) The insurance afforded the vendor is subject to the following additional exclusions: This insurance does not apply to: (a) "Bodily injury" or "property damage" for which the vendor is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages that the vendor would have in the absence of the contract or agreement; (b) Any express warranty unauthorized by you; (c) Any physical or chemical change in the product made intentionally by the vendor; (d) Repackaging, except when unpacked solely for the purpose of inspection, demonstration, testing, or the substitution of parts under instructions from the manufacturer, and then repackaged in the original container; (e) Any failure to make such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products; (f) Demonstration, installation, servicing or repair operations, except such operations performed at the vendor's premises in connection with the sale of the product; (g) Products which, after distribution or sale by you, have been labeled or relabeled or used as a container, part or ingredient of any other thing or substance by or for the vendor; or (h) "Bodily injury" or "property damage" arising out of the sole negligence of the vendor for its own acts or omissions or those of its employees or anyone else acting on its behalf. However, this exclusion does not apply to: (i) The exceptions contained in Sub-paragraphs (d) or (f); or (ii) Such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products. (2) This insurance does not apply to any insured person or organization, from whom you have acquired such products, or any ingredient, part or container, entering into, accompanying or containing such products. b. Lessors Of Equipment (1) Any person(s) or organization(s) from whom you lease equipment; but only with respect to their liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your maintenance, operation or use of equipment leased to you by such person(s) or organization(s). (2) With respect to the insurance afforded to these additional insureds this insurance does not apply to any "occurrence" which takes place after the equipment lease expires. c. Lessors Of Land Or Premises Any person or organization from whom you lease land or premises, but only with respect to liability arising out of the ownership, maintenance or use of that part of the land or premises leased to you. With respect to the insurance afforded these additional insureds the following additional exclusions apply: This insurance does not apply to: 1. Any "occurrence" which takes place after you cease to lease that land; or 2. Structural alterations, new construction or demolition operations performed by or on behalf of such person or organization. d. Architects, Engineers Or Surveyors Any architect, engineer, or surveyor, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (1) In connection with your premises; or (2) In the performance of your ongoing operations performed by you or on your behalf. With respect to the insurance afforded these additional insureds, the following additional exclusion applies: This insurance does not apply to "bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of or the failure to render any professional services by or for you, including: 1. The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or Form HG 00 01 0916 Page 13 of 22 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 2. Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional services by or for you. e. Permits Issued By State Or Political Subdivisions Any state or political subdivision, but only with respect to operations performed by you or on your behalf for which the state or political subdivision has issued a permit. With respect to the insurance afforded these additional insureds, this insurance does not apply to: (1) "Bodily injury", "property damage" or "personal and advertising injury" arising out of operations performed for the state or municipality; or (2) "Bodily injury" or "property damage" included within the "products-completed operations hazard". f. Any Other Party Any other person or organization who is not an additional insured under Paragraphs a. through e. above, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (1) In the performance of your ongoing operations; (2) In connection with your premises owned by or rented to you; or (3) In connection with "your work" and included within the "products-completed operations hazard", but only if (a) The written contract or agreement requires you to provide such coverage to such additional insured; and (b) This Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products-completed operations hazard". However: (1) The insurance afforded to such additional insured only applies to the extent permitted by law; and (2) If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. With respect to the insurance afforded to these additional insureds, this insurance does not apply to: "Bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: (1) The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or (2) Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional services by or for you. The limits of insurance that apply to additional insureds is described in Section Ill -Limits Of Insurance. How this insurance applies when other insurance is available to the additional insured is described in the Other Insurance Condition in Section IV -Commercial General Liability Conditions. No person or organization is an insured with respect to the conduct of any current or past partnership, joint venture or limited liability company that is not shown as a Named Insured in the Declarations. SECTION Ill -LIMITS OF INSURANCE 1. The Most We Will Pay The Limits of Insurance shown in the Declarations and the rules below fix the most we will pay regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". 2. General Aggregate Limit The General Aggregate Limit is the most we will pay for the sum of: a. Medical expenses under Coverage C; Page 14 of 22 Form HG 00 01 0916 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 b. Damages under Coverage A, except damages because of "bodily injury" or "property damage" included in the "products-completed operations hazard"; and c. Damages under Coverage B. 3. Products-Completed Operations Aggregate Limit The Products-Completed Operations Aggregate Limit is the most we will pay under Coverage A for damages because of "bodily injury" and "property damage" included in the "products-completed operations hazard". 4. Personal And Advertising Injury Limit Subject to 2. above, the Personal and Advertising Injury Limit is the most we will pay under Coverage B for the sum of all damages because of all "personal and advertising injury" sustained by any one person or organization. 5. Each Occurrence Limit Subject to 2. or 3. above, whichever applies, the Each Occurrence Limit is the most we will pay for the sum of: a. Damages under Coverage A; and b. Medical expenses under Coverage C because of all "bodily injury" and "property damage" arising out of any one "occurrence". 6. Damage To Premises Rented To You Limit Subject to 5. above, the Damage To Premises Rented To You Limit is the most we will pay under Coverage A for damages because of "property damage" to any one premises, while rented to you, or in the case of damage by fire, lightning or explosion, while rented to you or temporarily occupied by you with permission of the owner. In the case of damage by fire, lightning or explosion, the Damage to Premises Rented To You Limit applies to all damage proximately caused by the same event, whether such damage results from fire, lightning or explosion or any combination of these. 7. Medical Expense Limit Subject to 5. above, the Medical Expense Limit is the most we will pay under Coverage C for all medical expenses because of "bodily injury" sustained by any one person. 8. How Limits Apply To Additional Insureds If you have agreed in a written contract or written agreement that another person or organization be added as an additional insured on your policy, the most we will pay on behalf of such additional insured is the lesser of: a. The limits of insurance specified in the written contract or written agreement; or b. The Limits of Insurance shown in the Declarations. Such amount shall be a part of and not in addition to Limits of Insurance shown in the Declarations and described in this Section. The Limits of Insurance of this Coverage Part apply separately to each consecutive annual period and to any remaining period of less than 12 months, starting with the beginning of the policy period shown in the Declarations, unless the policy period is extended after issuance for an additional period of less than 12 months. In that case, the additional period will be deemed part of the last preceding period for purposes of determining the Limits of Insurance. SECTION IV -COMMERCIAL GENERAL LIABILITY CONDITIONS 1. Bankruptcy Bankruptcy or insolvency of the insured or of the insured's estate will not relieve us of our obligations under this Coverage Part. 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit a. Notice Of Occurrence Or Offense You or any additional insured must see to it that we are notified as soon as practicable of an "occurrence" or an offense which may result in a claim. To the extent possible, notice should include: (1) How, when and where the "occurrence" or offense took place; (2) The names and addresses of any injured persons and witnesses; and (3) The nature and location of any injury or damage arising out of the "occurrence" or offense. b. Notice Of Claim If a claim is made or "suit" is brought against any insured, you or any additional insured must: (1) Immediately record the specifics of the claim or "suit" and the date received; and (2) Notify us as soon as practicable. Form HG 00 01 0916 Page 15 of 22 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 You or any additional insured must see to it that we receive written notice of the claim or "suit" as soon as practicable. c. Assistance And Cooperation Of The Insured You and any other involved insured must: (1) Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the claim or "suit"; (2) Authorize us to obtain records and other information; (3) Cooperate with us in the investigation or settlement of the claim or defense against the "suit"; and (4) Assist us, upon our request, in the enforcement of any right against any person or organization which may be liable to the insured because of injury or damage to which this insurance may also apply. d. Obligations At The Insureds Own Cost No insured will, except at that insured's own cost, voluntarily make a payment, assume any obligation, or incur any expense, other than for first aid, without our consent. e. Additional Insureds Other Insurance If we cover a claim or "suit" under this Coverage Part that may also be covered by other insurance available to an additional insured, such additional insured must submit such claim or "suit" to the other insurer for defense and indemnity. However, this provision does not apply to the extent that you have agreed in a written contract or written agreement that this insurance is primary and non-contributory with the additional insured's own insurance. f. Knowledge Of An Occurrence, Offense, Claim Or Suit Paragraphs a. and b. apply to you or to any additional insured only when such "occurrence", offense, claim or "suit" is known to: (1) You or any additional insured that is an individual; (2) Any partner, if you or the additional insured is a partnership; (3) Any manager, if you or the additional insured is a limited liability company; (4) Any "executive officer'' or insurance manager, if you or the additional insured is a corporation; (5) Any trustee, if you or the additional insured is a trust; or (6) Any elected or appointed official, if you or the additional insured is a political subdivision or public entity. This duty applies separately to you and any additional insured. 3. Legal Action Against Us No person or organization has a right under this Coverage Part: a. To join us as a party or otherwise bring us into a "suit" asking for damages from an insured; or b. To sue us on this Coverage Part unless all of its terms have been fully complied with. A person or organization may sue us to recover on an agreed settlement or on a final judgment against an insured; but we will not be liable for damages that are not payable under the terms of this Coverage Part or that are in excess of the applicable limit of insurance. An agreed settlement means a settlement and release of liability signed by us, the insured and the claimant or the claimant's legal representative. 4. Other Insurance If other valid and collectible insurance is available to the insured for a loss we cover under Coverages A or B of this Coverage Part, our obligations are limited as follows: a. Primary Insurance This insurance is primary except when b. below applies. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. b. Excesslnsurance This insurance is excess over any of the other insurance, whether primary, excess, contingent or on any other basis: (1) Your Work That is Fire, Extended Coverage, Builder's Risk, Installation Risk or similar coverage for "your work"; (2) Premises Rented To You That is fire, lightning or explosion insurance for premises rented to you or temporarily occupied by you with permission of the owner; Page 16 of 22 Form HG 00 01 0916 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 (3) Tenant Liability That is insurance purchased by you to cover your liability as a tenant for "property damage" to premises rented to you or temporarily occupied by you with permission of the owner; (4) Aircraft, Auto Or Watercraft If the loss arises out of the maintenance or use of aircraft, "autos" or watercraft to the extent not subject to Exclusion g. of Section I -Coverage A -Bodily Injury And Property Damage Liability; (5) Property Damage To Borrowed Equipment Or Use Of Elevators If the loss arises out of "property damage" to borrowed equipment or the use of elevators to the extent not subject to Exclusion j. of Section I -Coverage A -Bodily Injury And Property Damage Liability; (6) When You Are Added As An Additional Insured To Other Insurance Any other insurance available to you covering liability for damages arising out of the premises or operations, or products and completed operations, for which you have been added as an additional insured by that insurance; or (7) When You Add Others As An Additional Insured To This Insurance Any other insurance available to an additional insured. However, the following provisions apply to other insurance available to any person or organization who is an additional insured under this coverage part. (a) Primary Insurance When Required By Contract This insurance is primary if you have agreed in a written contract or written agreement that this insurance be primary. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. (b) Primary And Non-Contributory To Other Insurance When Required By Contract If you have agreed in a written contract, written agreement, or permit that this insurance is primary and non-contributory with the additional insured's own insurance, this insurance is primary and we will not seek contribution from that other insurance. Paragraphs (a) and (b) do not apply to other insurance to which the additional insured has been added as an additional insured. When this insurance is excess, we will have no duty under Coverages A or B to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers. When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of: (1) The total amount that all such other insurance would pay for the loss in the absence of this insurance; and (2) The total of all deductible and self-insured amounts under all that other insurance. We will share the remaining loss, if any, with any other insurance that is not described in this Excess Insurance provision and was not bought specifically to apply in excess of the Limits of Insurance shown in the Declarations of this Coverage Part. c. Method Of Sharing If all of the other insurance permits contribution by equal shares, we will follow this method also. Under this approach each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. 5. Premium Audit a. We will compute all premiums for this Coverage Part in accordance with our rules and rates. b. Premium shown in this Coverage Part as advance premium is a deposit premium only. At the close of each audit period we will compute the earned premium for that period and send notice to the first Named Insured. The due date for audit and retrospective premiums is the date shown as the due date on the bill. If the sum of the advance and audit premiums paid for the policy period is greater than the earned premium, we will return the excess to the first Named Insured. Form HG 00 01 0916 Page 17 of 22 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 c. The first Named Insured must keep records of the information we need for premium computation, and send us copies at such times as we may request. 6. Representations a. When You Accept This Policy By accepting this policy, you agree: (1) The statements in the Declarations are accurate and complete; (2) Those statements are based upon representations you made to us; and (3) We have issued this policy in reliance upon your representations. b. Unintentional Failure To Disclose Hazards If unintentionally you should fail to disclose all hazards relating to the conduct of your business that exist at the inception date of this Coverage Part, we shall not deny coverage under this Coverage Part because of such failure. 7. Separation Of Insureds Except with respect to the Limits of Insurance, and any rights or duties specifically assigned in this Coverage Part to the first Named Insured, this insurance applies: a. As if each Named Insured were the only Named Insured; and b. Separately to each insured against whom claim is made or "suit" is brought. 8. Transfer Of Rights Of Recovery Against Others To Us a. Transfer Of Rights Of Recovery If the insured has rights to recover all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, those rights are transferred to us. The insured must do nothing after loss to impair them. At our request, the insured will bring "suit" or transfer those rights to us and help us enforce them. b. Waiver Of Rights Of Recovery (Waiver Of Subrogation) If the insured has waived any rights of recovery against any person or organization for all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, we also waive that right, provided the insured waived their rights of recovery against such person or organization in a contract, agreement or permit that was executed prior to the injury or damage. 9. When We Do Not Renew If we decide not to renew this Coverage Part, we will mail or deliver to the first Named Insured shown in the Declarations written notice of the nonrenewal not less than 30 days before the expiration date. If notice is mailed, proof of mailing will be sufficient proof of notice. SECTION V -DEFINITIONS 1. "Advertisement" means the widespread public dissemination of information or images that has the purpose of inducing the sale of goods, products or services through : a. (1) Radio; (2) Television; (3) Billboard; (4) Magazine; (5) Newspaper; or b. Any other publication that is given widespread public distribution. However, "advertisement" does not include: a. The design, printed material, information or images contained in, on or upon the packaging or labeling of any goods or products; or b. An interactive conversation between or among persons through a computer network. 2. "Advertising idea" means any idea for an "advertisement". 3. "Asbestos hazard" means an exposure or threat of exposure to the actual or alleged properties of asbestos and includes the mere presence of asbestos in any form. 4. "Auto" means: a. A land motor vehicle, trailer or semitrailer designed for travel on public roads, including any attached machinery or equipment; or Page 18 of 22 Form HG 00 01 09 16 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 b. Any other land vehicle that is subject to a compulsory or financial responsibility law or other motor vehicle insurance law where it is licensed or principally garaged. However, "auto" does not include "mobile equipment". 5. "Bodily injury" means physical: a. Injury; b. Sickness; or c. Disease sustained by a person and, if arising out of the above, mental anguish or death at any time. 6. "Coverage territory" means: a. The United States of America (including its territories and possessions), Puerto Rico and Canada; b. International waters or airspace, but only if the injury or damage occurs in the course of travel or transportation between any places included in a. above; or c. All other parts of the world if the injury or damage arises out of: (1) Goods or products made or sold by you in the territory described in a. above; (2) The activities of a person whose home is in the territory described in a. above, but is away for a short time on your business; or (3) "Personal and advertising injury" offenses that take place through the Internet or similar electronic means of communication provided the insured's responsibility to pay damages is determined in the United States of America (including its territories and possessions), Puerto Rico or Canada, in a "suit" on the merits according to the substantive law in such territory or in a settlement we agree to. 7. "Employee" includes a "leased worker''. "Employee" does not include a "temporary worker". 8. "Employment-Related Practices" means: a. Refusal to employ that person; b. Termination of that person's employment; or c. Employment-related practices, policies, acts or omissions, such as coercion, demotion, evaluation, reassignment, discipline, defamation, harassment, humiliation, discrimination or malicious prosecution directed at that person. 9. "Executive officer" means a person holding any of the officer positions created by your charter, constitution, by-laws or any other similar governing document. 10. "Hostile fire" means one which becomes uncontrollable or breaks out from where it was intended to be. 11. "Impaired property" means tangible property, other than "your product" or "your work", that cannot be used or is less useful because: a. It incorporates "your product" or "your work" that is known or thought to be defective, deficient, inadequate or dangerous; or b. You have failed to fulfill the terms of a contract or agreement; if such property can be restored to use by the repair, replacement, adjustment or removal of "your product" or "your work", or your fulfilling the terms of the contract or agreement. 12. "Insured contract" means: a. A contract for a lease of premises. However, that portion of the contract for a lease of premises that indemnifies any person or organization for damage by fire, lightning or explosion to premises while rented to you or temporarily occupied by you with permission of the owner is subject to the Damage to Premises Rented To You Limit described in Section Ill -Limits of Insurance; b. A sidetrack agreement; c. Any easement or license agreement, including an easement or license agreement in connection with construction or demolition operations on or within 50 feet of a railroad; d. An obligation, as required by ordinance, to indemnify a municipality, except in connection with work for a municipality; e. An elevator maintenance agreement; f. That part of any other contract or agreement pertaining to your business (including an indemnification of a municipality in connection with work performed for a municipality) under which you assume the tort liability of another party to pay for "bodily injury" or "property damage" to a third person or organization, provided the "bodily Form HG 00 01 0916 Page 19 of 22 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 injury" or "property damage" is caused, in whole or in part, by you or by those acting on your behalf. Tort liability means a liability that would be imposed by law in the absence of any contract or agreement. Paragraph f. includes that part of any contract or agreement that indemnifies a railroad for "bodily injury" or "property damage" arising out of construction or demolition operations, within 50 feet of any railroad property and affecting any railroad bridge or trestle, tracks, road-beds, tunnel, underpass or crossing. However, Paragraph f. does not include that part of any contract or agreement: (1) That indemnifies an architect, engineer or surveyor for injury or damage arising out of: (a) Preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or (b) Giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage; or (2) Under which the insured, if an architect, engineer or surveyor, assumes liability for an injury or damage arising out of the insured's rendering or failure to render professional services, including those listed in (1) above and supervisory, inspection, architectural or engineering activities. 13. "Leased worker" means a person leased to you by a labor leasing firm under an agreement between you and the labor leasing firm, to perform duties related to the conduct of your business. "Leased worker'' does not include a "temporary worker''. 14. "Loading or unloading" means the handling of property: a. After it is moved from the place where it is accepted for movement into or onto an aircraft, watercraft or "auto"; b. While it is in or on an aircraft, watercraft or "auto"; or c. While it is being moved from an aircraft, watercraft or "auto" to the place where it is finally delivered; but "loading or unloading" does not include the movement of property by means of a mechanical device, other than a hand truck, that is not attached to the aircraft, watercraft or "auto". 15. "Mobile equipment" means any of the following types of land vehicles, including any attached machinery or equipment: a. Bulldozers, farm machinery, forklifts and other vehicles designed for use principally off public roads; b. Vehicles maintained for use solely on or next to premises you own or rent; c. Vehicles that travel on crawler treads; d. Vehicles, whether self-propelled or not, maintained primarily to provide mobility to permanently mounted: (1) Power cranes, shovels, loaders, diggers or drills; or (2) Road construction or resurfacing equipment such as graders, scrapers or rollers; e. Vehicles not described in a., b., c. or d. above that are not self-propelled and are maintained primarily to provide mobility to permanently attached equipment of the following types: (1) Air compressors, pumps and generators, including spraying, welding, building cleaning, geophysical exploration, lighting and well servicing equipment; or (2) Cherry pickers and similar devices used to raise or lower workers; f. Vehicles not described in a., b., c. or d. above maintained primarily for purposes other than the transportation of persons or cargo. However, self-propelled vehicles with the following types of permanently attached equipment are not "mobile equipment" but will be considered "autos": (1) Equipment designed primarily for: (a) Snow removal; (b) Road maintenance, but not construction or resurfacing; or (c) Street cleaning; (2) Cherry pickers and similar devices mounted on automobile or truck chassis and used to raise or lower workers; and (3) Air compressors, pumps and generators, including spraying, welding, building cleaning, geophysical exploration, lighting and well servicing equipment. However, "mobile equipment" does not include any land vehicle that is subject to a compulsory or financial responsibility law or other motor vehicle insurance law where it is licensed or principally garaged. Land vehicles subject to a compulsory or financial responsibility law or other motor vehicle insurance law are considered "autos". Page 20 of 22 Form HG 00 01 0916 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 16. "Occurrence" means an accident, including continuous or repeated exposure to substantially the same general harmful conditions. 17. "Personal and advertising injury" means injury, including consequential "bodily injury", arising out of one or more of the following offenses: a. False arrest, detention or imprisonment; b. Malicious prosecution; c. The wrongful eviction from, wrongful entry into, or invasion of the right of private occupancy of a room, dwelling or premises that a person or organization occupies, committed by or on behalf of its owner, landlord or lessor; d. Oral, written or electronic publication, in any manner, of material that slanders or libels a person or organization or disparages a person's or organization's goods, products or services; e. Oral, written or electronic publication, in any manner, of material that violates a person's right of privacy; f. Copying, in your "advertisement", a person's or organization's "advertising idea" or style of "advertisement"; or g. Infringement of copyright, slogan, or title of any literary or artistic work, in your "advertisement". 18. "Pollutants" mean any solid, liquid, gaseous or thermal irritant or contaminant, including smoke, vapor, soot, fumes, acids, alkalis, chemicals and waste. Waste includes materials to be recycled, reconditioned or reclaimed. 19. "Products-completed operations hazard": a. Includes all "bodily injury" and "property damage" occurring away from premises you own or rent and arising out of "your product" or "your work" except: (1) Products that are still in your physical possession; or (2) Work that has not yet been completed or abandoned. However, "your work" will be deemed completed at the earliest of the following times: (a) When all of the work called for in your contract has been completed. (b) When all of the work to be done at the job site has been completed if your contract calls for work at more than one job site. (c) When that part of the work done at a job site has been put to its intended use by any person or organization other than another contractor or subcontractor working on the same project. Work that may need service, maintenance, correction, repair or replacement, but which is otherwise complete, will be treated as completed. b. Does not include "bodily injury" or "property damage" arising out of: (1) The transportation of property, unless the injury or damage arises out of a condition in or on a vehicle not owned or operated by you, and that condition was created by the "loading or unloading" of that vehicle by any insured; (2) The existence of tools, uninstalled equipment or abandoned or unused materials; or (3) Products or operations for which the classification, listed in the Declarations or in a policy Schedule, states that products-completed operations are subject to the General Aggregate Limit. 20. "Property damage" means: a. Physical injury to tangible property, including all resulting loss of use of that property. All such loss of use shall be deemed to occur at the time of the physical injury that caused it; or b. Loss of use of tangible property that is not physically injured. All such loss of use shall be deemed to occur at the time of the "occurrence" that caused it. As used in this definition, computerized or electronically stored data, programs or software are not tangible property. Electronic data means information, facts or programs: a. Stored as or on; b. Created or used on; or c. Transmitted to or from; computer software, including systems and applications software, hard or floppy disks, CD- ROMS, tapes, drives, cells, data processing devices or any other media which are used with electronically controlled equipment. 21. "Suit" means a civil proceeding in which damages because of "bodily injury", "property damage" or "personal and advertising injury" to which this insurance applies are alleged. "Suit" includes: a. An arbitration proceeding in which such damages are claimed and to which the insured must submit or does submit with our consent; or Form HG 00 01 0916 Page 21 of 22 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4843599D8456 b. Any other alternative dispute resolution proceeding in which such damages are claimed and to which the insured submits with our consent. 22. "Temporary worker" means a person who is furnished to you to substitute for a permanent "employee" on leave or to meet seasonal or short-term workload conditions. 23. "Volunteer worker" means a person who a. Is not your "employee"; b. Donates his or her work; c. Acts at the direction of and within the scope of duties determined by you; and d. Is not paid a fee, salary or other compensation by you or anyone else for their work performed for you. 24. "Your product": a. Means: (1) Any goods or products, other than real property, manufactured, sold, handled, distributed or disposed of by: (a) You; (b) Others trading under your name; or (c) A person or organization whose business or assets you have acquired; and (2) Containers (other than vehicles), materials, parts or equipment furnished in connection with such goods or products. b. Includes (1) Warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your product"; and (2) The providing of or failure to provide warnings or instructions. c. Does not include vending machines or other property rented to or located for the use of others but not sold. 25. "Your work": a. Means: (1) Work or operations performed by you or on your behalf; and (2) Materials, parts or equipment furnished in connection with such work or operations. b. Includes (1) Warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your work", and (2) The providing of or failure to provide warnings or instructions. Page 22 of 22 Form HG 00 01 0916 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 .l-'OHl"4() U ..t.N ..t.L4~~~ COMMERCIAL AUTOMOBILE HA 991612 21 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. COMMERCIAL AUTOMOBILE BROAD FORM ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM To the extent that the provisions of this endorsement provide broader benefits to the "insured" than other provisions of the Coverage Form, the provisions of this endorsement apply. 1. BROAD FORM INSURED Paragraph .1. -WHO IS AN INSURED -of Section II -Liability Coverage is amended to add the following: d. Subsidiaries and Newly Acquired or Formed Organizations The Named Insured shown in the Declarations is amended to include: ( 1) Any legal business entity other than a partnership or joint venture, formed as a subsidiary in which you have an ownership interest of more than 50% on the effective date of the Coverage Form. However, the Named Insured does not include any subsidiary that is an "insured" under any other automobile policy or would be an "insured" under such a policy but for its termination or the exhaustion of its Limit of Insurance. (2) Any organization that is acquired or formed by you and over which you maintain majority ownership. However, the Named Insured does not include any newly formed or acquired organization: (a) That is a partnership or joint venture, (b) That is an "insured" under any other policy, (c) That has exhausted its Limit of Insurance under any other policy, or (d) 180 days or more after its acquisition or formation by you, unless you have given us notice of the acquisition or formation. Coverage does not apply to "bodily injury" or "property damage" that results from an "accident" that occurred before you formed or acquired the organization. Form HA 99 16 12 21 e. Employees as Insureds (1). Any "employee" of yours while using a covered "auto" you don't own, hire or borrow in your business or your personal affairs. f. Lessors as Insureds (1). The lessor of a covered "auto" while the "auto" is leased to you under a written agreement if: (a) The agreement requires you to provide direct primary insurance for the lessor and (b) The "auto" is leased without a driver. Such a leased "auto" will be considered a covered "auto" you own and not a covered "auto" you hire. g. Additional Insured if Required by Contract (1) When you have agreed, in a written contract or written agreement, that a person or organization be added as an additional insured on your business auto policy, such person or organization is an "insured", but only to the extent such person or organization is liable for "bodily injury" or "property damage" caused by the conduct of an "insured" under paragraphs a. or b. of Who Is An Insured with regard to the ownership, maintenance or use of a covered "auto." The insurance afforded to any such additional insured applies only if the "bodily injury" or "property damage" occurs: (a) During the policy period , and (b) Subsequent to the execution of such written contract, and Page 1 of 5 © 2021, The Hartford (Includes copyrighted material of Insurance Services Office, Inc. with its permission.) Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 (c) Prior to the expiration of the period of time that the written contract requires such insurance be provided to the additional insured. (2) How Limits Apply If you have agreed in a written contract or written agreement that another person or organization be added as an additional insured on your policy, the most we will pay on behalf of such additional insured is the lesser of: (a) The limits of insurance specified in the written contract or written agreement; or (b) The Limits of Insurance shown in the Declarations. Such amount shall be a part of and not in addition to Limits of Insurance shown in the Declarations and described in this Section. (3) Additional Insureds Other Insurance If we cover a claim or "suit" under this Coverage Part that may also be covered by other insurance available to an additional insured, such additional insured must submit such claim or "suit" to the other insurer for defense and indemnity. However, this provision does not apply to the extent that you have agreed in a written contract or written agreement that this insurance is primary and non-contributory with the additional insured's own insurance. (4) Duties in The Event Of Accident, Claim, Suit or Loss If you have agreed in a written contract or written agreement that another person or organization be added as an additional insured on your policy, the additional insured shall be required to comply with the provisions in LOSS CONDITIONS 2. - DUTIES IN THE EVENT OF ACCIDENT, CLAIM , SUIT OR LOSS -OF SECTION IV -BUSINESS AUTO CONDITIONS, in the same manner as the Named Insured. 2. Primary and Non-Contributory if Required by Contract Only with respect to insurance provided to an additional insured in A.1.g . -Additional Insured If Required by Contract, the following provisions apply: (1) Primary Insurance When Required By Contract Page 2 of 5 This insurance is primary if you have agreed in a written contract or written agreement that this insurance be primary. If other insurance is also primary, we will share with all that other insurance by the method described in Other Insurance 5.d. (2) Primary And Non-Contributory To Other Insurance When Required By Contract If you have agreed in a written contract or written agreement that this insurance is primary and non-contributory with the additional insured's own insurance, this insurance is primary and we will not seek contribution from that other insurance. Paragraphs (1) and (2) do not apply to other insurance to which the additional insured has been added as an additional insured. When this insurance is excess, we will have no duty to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers. When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of: ( 1) The total amount that all such other insurance would pay for the loss in the absence of this insurance; and (2) The total of all deductible and self-insured amounts under all that other insurance. We will share the remaining loss, if any, by the method described in SECTION IV- Business Auto Conditions, B. General Conditions, Other Insurance 5.d. 3. AUTOS RENTED BY EMPLOYEES Any "auto" hired or rented by your "employee" on your behalf and at your direction will be considered an "auto" you hire. The SECTION IV-Business Auto Conditions, B. General Conditions, 5. OTHER INSURANCE Condition is amended by adding the following: e. If an "employee's" personal insurance also applies on an excess basis to a covered "auto" hired or rented by your "employee" on your behalf and at your direction, this insurance will be primary to the "employee's" personal insurance. Form HA 99 16 12 21 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 4. AMENDED FELLOW EMPLOYEE EXCLUSION EXCLUSION 5. -FELLOW EMPLOYEE -of SECTION II -LIABILITY COVERAGE does not apply if you have workers' compensation insurance in-force covering all of your "employees". Coverage is excess over any other collectible insurance. 5. HIRED AUTO PHYSICAL DAMAGE COVERAGE If hired "autos" are covered "autos" for Liability Coverage and if Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form for any "auto" you own, then the Physical Damage Coverages provided are extended to "autos" you hire or borrow, subject to the following limit. The most we will pay for "loss" to any hired "auto" is: (1) $100,000; (2) The actual cash value of the damaged or stolen property at the time of the "loss"; or (3) The cost of repairing or replacing the damaged or stolen property, whichever is smallest, minus a deductible. The deductible will be equal to the largest deductible applicable to any owned "auto" for that coverage. No deductible applies to "loss" caused by fire or lightning. Hired Auto Physical Damage coverage is excess over any other collectible insurance. Subject to the above limit, deductible and excess provisions, we will provide coverage equal to the broadest coverage applicable to any covered "auto" you own. We will also cover loss of use of the hired "auto" if it results from an "accident", you are legally liable and the lessor incurs an actual financial loss, subject to a maximum of $1000 per "accident". This extension of coverage does not apply to any "auto" you hire or borrow from any of your "employees", partners (if you are a partnership), members (if you are a limited liability company), or members of their households. 6. PHYSICAL DAMAGE ADDITIONAL TEMPORARY TRANSPORTATION EXPENSE COVERAGE Paragraph A.4.a. of SECTION Ill -PHYSICAL DAMAGE COVERAGE is amended to provide a limit of $50 per day and a maximum limit of $1,000. 7. LOAN/LEASE GAP COVERAGE Under SECTION Ill -PHYSICAL DAMAGE COVERAGE, in the event of a total "loss" to a covered "auto", we will pay your additional legal Form HA 99 16 12 21 obligation for any difference between the actual cash value of the "auto" at the time of the "loss" and the "outstanding balance" of the loan/lease. "Outstanding balance" means the amount you owe on the loan/lease at the time of "loss" less any amounts representing taxes; overdue payments; penalties, interest or charges resulting from overdue payments; additional mileage charges; excess wear and tear charges; lease termination fees; security deposits not returned by the lessor; costs for extended warranties, credit life Insurance, health, accident or disability insurance purchased with the loan or lease; and carry-over balances from previous loans or leases. 8. AIRBAG COVERAGE Under Paragraph B. EXCLUSIONS -of SECTION Ill -PHYSICAL DAMAGE COVERAGE, the following is added : The exclusion relating to mechanical breakdown does not apply to the accidental discharge of an airbag. 9. ELECTRONIC EQUIPMENT -BROADENED COVERAGE a. The exceptions to Paragraphs 8.4 EXCLUSIONS -of SECTION Ill -PHYSICAL DAMAGE COVERAGE are replaced by the following: Exclusions 4.c. and 4.d. do not apply to equipment designed to be operated solely by use of the power from the "auto's" electrical system that, at the time of "loss", is: ( 1) Permanently installed in or upon the covered "auto"; (2) Removable from a housing unit which is permanently installed in or upon the covered "auto"; (3) An integral part of the same unit housing any electronic equipment described in Paragraphs (1) and (2) above; or ( 4) Necessary for the normal operation of the covered "auto" or the monitoring of the covered "auto's" operating system. b. Section Ill , Physical Damage Coverage, Limit of Insurance, Paragraph C.2. is amended to add the following: $1,500 is the most we will pay for "loss" in any one "accident" to all electronic equipment (other than equipment designed solely for the reproduction of sound, and accessories used with such equipment) that reproduces, receives or transmits audio, visual or data signals which, at the time of "loss", is: Page 3 of 5 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 ( 1) Permanently installed in or upon the covered "auto" in a housing, opening or other location that is not normally used by the "auto" manufacturer for the installation of such equipment; (2) Removable from a permanently installed housing unit as described in Paragraph 2.a. above or is an integral part of that equipment; or (3) An integral part of such equipment. c. For each covered "auto", should loss be limited to electronic equipment only, our obligation to pay for, repair, return or replace damaged or stolen electronic equipment will be reduced by the applicable deductible shown in the Declarations, or $250, whichever deductible is less. 10. EXTRA EXPENSE -BROADENED COVERAGE Under Paragraph A. -COVERAGE -of SECTION Ill -PHYSICAL DAMAGE COVERAGE, we will pay for the expense of returning a stolen covered "auto" to you. 11. GLASS REPAIR-WAIVER OF DEDUCTIBLE Under Paragraph D. -DEDUCTIBLE -of SECTION Ill -PHYSICAL DAMAGE COVERAGE, the following is added: No deductible applies to glass damage if the glass is repaired rather than replaced . 12. TWO OR MORE DEDUCTIBLES Under Paragraph D. -DEDUCTIBLE -of SECTION Ill -PHYSICAL DAMAGE COVERAGE, the following is added: If another Hartford Financial Services Group, Inc. company policy or coverage form that is not an automobile policy or coverage form applies to the same "accident", the following applies: ( 1) If the deductible under this Business Auto Coverage Form is the smaller (or smallest) deductible, it will be waived; (2) If the deductible under this Business Auto Coverage Form is not the smaller ( or smallest) deductible, it will be reduced by the amount of the smaller (or smallest) deductible. 13. AMENDED DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS The requirement in LOSS CONDITIONS 2.a. - DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS -of SECTION IV -BUSINESS AUTO CONDITIONS that you must notify us of an "accident" applies only when the "accident" is known to: (1) You, if you are an individual; Page 4 of 5 (2) A partner, if you are a partnership; (3) A member, if you are a limited liability company; or (4) An executive officer or insurance manager, if you are a corporation. 14. UNINTENTIONAL FAILURE TO DISCLOSE HAZARDS If you unintentionally fail to disclose any hazards existing at the inception date of your policy, we will not deny coverage under this Coverage Form because of such failure. 15. HIRED AUTO -COVERAGE TERRITORY SECTION IV, BUSINESS AUTO CONDITIONS, PARAGRAPH B. GENERAL CONDITIONS, 7. - POLICY PERIOD, COVERAGE TERRITORY -is added to include the following: (6) For short-term hired "autos", the coverage territory with respect to Liability Coverage is anywhere in the world provided that if the "insured's" responsibility to pay damages for "bodily injury" or "property damage" is determined in a "suit," the "suit" is brought in the United States of America, the territories and possessions of the United States of America, Puerto Rico or Canada or in a settlement we agree to . 16. WAIVER OF SUBROGATION Paragraph 5. TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US -of SECTION IV -BUSINESS AUTO CONDITIONS A. Loss Conditions is amended by adding the following: We waive any right of recovery we may have against any person or organization with whom you have a written contract that requires such waiver because of payments we make for damages under this Coverage Form. 17. RESULTANT MENTAL ANGUISH COVERAGE The definition of "bodily injury" in SECTION V- DEFINITIONS, C. is replaced by the following: "Bodily injury" means bodily injury, sickness or disease sustained by any person , including mental anguish or death resulting from any of these. 18. EXTENDED CANCELLATION CONDITION Paragraph 2. of the COMMON POLICY CONDITIONS -CANCELLATION -applies except as follows: If we cancel for any reason other than nonpayment of premium, we will mail or deliver to the first Named Insured written notice of cancellation at least 60 days before the effective date of cancellation. Form HA 99 16 12 21 Docusign Envelope ID: D90F02A9-DBC5-4F3E-9EFF-4B43599DB456 19. HYBRID, ELECTRIC, OR NATURAL GAS VEHICLE PAYMENT COVERAGE In the event of a total loss to a "non-hybrid" auto for which Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form, then such Physical Damage Coverages are amended as follows: a. If the auto is replaced with a "hybrid" auto or an auto powered solely by electricity or natural gas, we will pay an additional 10%, to a maximum of $2,500 , of the "non-hybrid" auto's actual cash value or replacement cost, whichever is less, b. The auto must be replaced and a copy of a bill of sale or new lease agreement received by us within 60 calendar days of the date of "loss," c. Regardless of the number of autos deemed a total loss, the most we will pay under this Hybrid, Electric, or Natural Gas Vehicle Payment Coverage provision for any one "loss" is $10,000. For the purposes of the coverage provision, a. A "non-hybrid" auto is defined as an auto that uses only an internal combustion engine to move the auto but does not include autos powered solely by electricity or natural gas. Form HA 99 16 12 21 b. A "hybrid" auto is defined as an auto with an internal combustion engine and one or more electric motors; and that uses the internal combustion engine and one or more electric motors to move the auto, or the internal combustion engine to charge one or more electric motors, which move the auto. 20. VEHICLE WRAP COVERAGE In the event of a total loss to an "auto" for which Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form, then such Physical Damage Coverages are amended to add the following: In addition to the actual cash value of the "auto", we will pay up to $1,000 for vinyl vehicle wraps which are displayed on the covered "auto" at the time of total loss. Regardless of the number of autos deemed a total loss, the most we will pay under this Vehicle Wrap Coverage provision for any one "loss" is $5,000. For purposes of this coverage provision, signs or other graphics painted or magnetically affixed to the vehicle are not considered vehicle wraps. Page 5 of 5