Loading...
HomeMy WebLinkAboutAtlas Allied Inc; 2009-08-24; PWS09-28ENG/3 DOC # 201 0-021 7632 .r(t Record~ng requested by ) ) I llllllll Ill lllll Ill11 11111 11111 11111 1IIll IIIII IIIII Illll lllll Ill1 1111 lf CITY OF CARLSBAD ) APR 30, 2010 2.31 PM p\tp ) \ When recorded mall to ) OFFICIAL RECORDS SAN DIEGO COUNTY RECORDER'S OFFICE ) DAVID L BUTLER COUNTY RECORDER City Clerk ) FEES 0 00 C~ty of Carlsbad ) PAGES: 1 1200 Carlsbad V~llage Dr ) Carlsbad, CA 92008 I IHIII 11111 UIII 1111 IIIIIIIIII 11111 UIII UIII IIIII UIII IIIII 11111 IIIII IIIII UII 1111 Space above this line for Recorder's Use NOTICE OF COMPLETION Notice is hereby given that: 1. The undersigned is owner of the interest or estate stated below in the property hereinafter described. 2. The full name of the undersigned is Carlsbad Municipal Water District (CMWD), a municipal corporation. 3. The full address of the undersigned is 1200 Carlsbad Village Drive, Carlsbad, California 92008. 4. The nature of the title of the undersigned is: In fee. 5. A work or improvement on the property hereinafter described was completed on March 19, 2010. 6. The name of the contractor for such work of improvement is Atlas-Allied, Inc. 7. The property on which the work of improvement was completed is in the City of Carlsbad. County of San Diego, State of California, and is described as Project No. 5201 1, Industrial Park Recycled Water Service Lines. CARLSBAD MUNICIPAL WATER DISTRICT ?/- &-GLENN PRM Public Works Director VERIFICATION OF SECRETARY I, the undersigned, say: I am the Secretary of the Carlsbad Municipal Water District. 1200 Carlsbad Village Drive, Carlsbad. California. 92009. The Executive Board of said District on April 27 , 2010, accepted the above described work as completed and ordered that a Notice of Completion be filed. I declare under penalty of perjury that the foregoing is true and correct. Executed on Auril 27 , 2010. at Carlsbad. California. CARLSBAD MUNICIPAL WATER DISTRICT Karen R. Kundtz, Assistant Secretary CARLSBAD MUNICIPAL WATER DISTRICT San Diego County California CONTRACT DOCUMENTS, GENERAL PROVISIONS, AND SUPPLEMENTAL PROVISIONS FOR INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 BID NO. PWS09-28ENG Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 1 of 139 Pages TABLE OF CONTENTS Item Page Notice Inviting Bids 8 Contractor's Proposal 12 Bid Security Form 20 Bidder's Bond to Accompany Proposal 21 Guide for Completing the "Designation Of Subcontractors" Form 23 Designation of Subcontractor and Amount of Subcontractor's Bid Items 25 Bidder's Statement of Technical Ability and Experience 26 Bidder's Certificate of Insurance for General Liability, Employers' Liability, Automotive Liability and Workers'Compensation 27 Bidder's Statement Re Debarment 28 Bidder's Disclosure of Discipline Record 29 Non-Collusion Affidavit to Be Executed by Bidder and Submitted with Bid 31 Contract Public Works 32 Labor and Materials Bond 38 Faithful Performance/Warranty Bond 40 Optional Escrow Agreement for Surety Deposits in Lieu of Retention 42 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 2 of 139 Pages GENERAL PROVISIONS Section 1 Terms, Definitions Abbreviations and Symbols 1-1 Terms 45 1-2 Definitions 46 1-3 Abbreviations 50 1-4 Units of Measure 53 1-5 Symbols 54 Section 2 Scope and Control of The Work 2-1 Award and Execution of Contract 54 2-2 Assignment 54 2-3 Subcontracts 54 2-4 Contract Bonds 55 2-5 Plans and Specifications 56 2-6 Workto be Done 60 2-7 Subsurface Data 60 2-8 Right-of-Way 60 2-9 Surveying 60 2-10 Authority of Board and Engineer 63 2-11 Inspection 64 Section 3 Changes in Work 3-1 Changes Requested by the Contractor 64 3-2 Changes Initiated by the Agency 64 3-3 Extra Work 66 3-4 Changed Conditions 68 3-5 Disputed Work 69 Section 4 Control of Materials 4-1 Materials and Workmanship 72 4-2 Materials Transportation, Handling and Storage 76 Section 5 Utilities 5-1 Location ; 77 5-2 Protection 77 5-3 Removal 78 5-4 Relocation 78 5-5 Delays 78 5-6 Cooperation 79 Section 6 Prosecution, Progress and Acceptance of the Work 6-1 Construction Schedule and Commencement of Work 79 6-2 Prosecution of Work 82 6-3 Suspension ofWork 83 6-4 Default by Contractor 83 6-5 Termination of Contract 84 6-6 Delays and Extensions of Time 84 6-7 Time of Completion 85 6-8 Completion, Acceptance, and Warranty 86 6-9 Liquidated Damages 86 6-10 Use of Improvement During Construction 87 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 3 of 139 Pages Section 7 Responsibilities of the Contractor 7-1 Contractor's Equipment and Facilities 87 7-2 Labor 87 7-3 Liability Insurance 88 7-4 Workers' Compensation Insurance 88 7-5 Permits 88 7-6 The Contractor's Representative 88 7-7 Cooperation and Collateral Work 89 7-8 Project Site Maintenance 89 7-9 Protection and Restoration of Existing Improvements 91 7-10 Public Convenience and Safety 91 7-11 Patent Fees or Royalties 98 7-12 Advertising 98 7-13 Laws to be Observed 98 7-14 Antitrust Claims 99 Section 8 Facilities for Agency Personnel 8-1 General 99 Section 9 Measurement and Payment 9-1 Measurement of Quantities for Unit Price Work 99 9-2 Lump Sum Work 99 9-3 Payment 100 9-4 Bid Items 103 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 4 of 139 Pages SUPPLEMENTAL PROVISIONS TO PART 2, 3 AND 6 OF THE SSPWC Part 2 Construction Materials Section 200 Rock Materials 200-1 Rock Products 104 200-2 Untreated Base Materials 104 Section 201 Concrete, Mortar and Related Materials 201-1 Portland Cement Concrete 106 201-3 Expansion Joint Filler and Joint Sealants 108 Section 203 Bituminous Materials 203-6 Asphalt Concrete 109 203-11 Asphalt Rubber Hot Mix (ARHM) Wet Process 110 203-13 Asphalt Pavement Crack Sealants 110 Section 204 Lumber and Treatment with Preservatives 204-1 Lumberand Plywood 112 Section 206 Miscellaneous Metal Items 206-7 Traffic Signs 112 206-8 Light Gage Steel Tubing and Connectors 115 206-9 Portable Changeable Message Sign 116 Section 207 Pipe 207-2 Reinforced Concrete Pipe 117 207-9 Iron Pipe and Fittings 117 207-10 Steel Pipe 117 207-25 Underground Utility Marking Tape .- 118 Section 209 Signals, Lighting and Electrical Systems 209-1 General 119 Section 210 Paint and Protective Coatings 210-1 Paint 120 210-3 Galvanizing 120 Section 213 Engineering Fabrics 213-2 Geotextiles 121 213-3 Erosion Control Specialties 121 Section 214 Pavement Markers 214-5 Reflective Pavement Markers 122 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 5 of 139 Pages Part 3 Construction Methods Section 301 Treated Soil, Subgrade Preparation and Placement of Base Materials 301-1 Subgrade Preparation 123 Section 302 Roadway Surfacing 302-1 Oiled Roadways and Shoulders 123 302-2 Chip Seal 123 302-3 Asphalt-Rubber Chip Seal or Interlayer 124 302-4 Emulsion-Aggregate Slurry 124 302-5 Asphalt Concrete Pavement 126 302-11 Asphalt Pavement Repairs and Remediation 127 Section 303 Concrete and Masonry Construction. 303-1 Concrete Structures 129 303-2 Air-Placed Concrete 129 303-5 Concrete Curbs, Walks, Gutters, Cross Gutters, Alley Intersections, Access Ramps, And Driveways 129 303-6 Stamped Concrete 130 Section 304 Metal Fabrication and Construction 304-3 Chain Link Fence 130 Section 306 Underground Conduit Construction 306-1 Open Trench Operations 130 306-5 Abandonment of Conduits and Structures 134 Section 310 Painting 310-5 Painting Various Surfaces 134 310-7 Permanent Signing 135 Section 312 Pavement Marker Placement and Removal 312-1 Placement 135 Section 313 Temporary Traffic Control Devices 313-1 Temporary Traffic Pavement Markers 136 313-2 Temporary Traffic Signing 136 313-3 Temporary Railing (Type K) and Crash Cushions 137 313-4 Measurement and Payment : 138 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 6 of 139 Pages Parts Modified Asphalt, Pavement and Processes 600-3 Rubberized Emulsion-Aggregate Slurry Appendix A Door Hanger "Example" Appendix B Carlsbad Municipal Water District Standard Drawings W-2 Typical Trench Section W-3 1 Typical Water Service Connections W-4 2 Typical Water Service Connections W-8 Outlets or AC or PVC Main W-9 Outlets on D.I. or Steel Main W-10 Dielectric Connection to Steel Main W-13 Valve Box Assembly W-14 Tapped Connection to Steel Main W-15 Concrete Trust Blocks W-16 Gate Valve Installation W-17 Butterfly & Plug Valve Installation W-18 Thrust Anchor for Water Main W-19 Thrust Block Bearing Areas W-25 Zinc Anode & Connectors for 1" & 2" Water Service 139 oRevised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 7 of 139 Pages CARLSBAD MUNICIPAL WATER DISTRICT, CALIFORNIA NOTICE INVITING BIDS UNTIL 2:00 PM ON JUNE 30, 2009, the Carlsbad Municipal Water District (District) shall accept sealed bids, clearly marked as such, at the Faraday Center, 1635 Faraday Avenue, Carlsbad, CA 92008-7314, Attn: Purchasing Officer, by mail, delivery service or by deposit in the Bid Box located in the first floor lobby, at which time they will be opened and read, for performing the work as follows: Installation of Recycled Water Service Lines. INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 BID NO. PWS09-28ENG INSTRUCTIONS TO BIDDERS AND BID REQUIREMENTS This bid and the terms of the Contract Documents and General Provisions constitute an irrevocable offer that shall remain valid and in full force for a period of 90 days and such additional time as may be mutually agreed upon by the Carlsbad Municipal Water District and the Bidder. No bid will be received unless it is made on a proposal form furnished by the Purchasing Department. Each bid must be accompanied by security in a form and amount required by law. The bidder's security of the second and third next lowest responsive bidders may be withheld until the Contract has been fully executed. The security submitted by all other unsuccessful bidders shall be returned to them, or deemed void, within ten (10) days after the Contract is awarded. Pursuant to the provisions of law (Public Contract Code section 10263), appropriate securities may be substituted for any obligation required by this notice or for any monies withheld by the District to ensure performance under this Contract. Section 10263 of the Public Contract Code requires monies or securities to be deposited with the District or a state or federally chartered bank in California as the escrow agent. The escrow agent shall maintain insurance to cover negligent acts and omissions of the agent in connection with the handling of retentions under this section in an amount not less than $100,000 per contract. The Carlsbad Municipal Water District may disqualify a contractor or subcontractor from participating in bidding when a contractor or subcontractor has been debarred by the Carlsbad Municipal Water District or another jurisdiction in the State of California as an irresponsible bidder. The work shall be performed in strict conformity with the plans, provisions, and specifications as approved by the City Council of the City of Carlsbad on file with the Engineering Department. The specifications for the work include City of Carlsbad Specifications and the Stan- dard Specifications for Public Works Construction, Parts 2 & 3, current edition at time of bid opening and the supplements thereto as published by the "Greenbook" Committee of Public Works Standards, Inc., all hereinafter designated "SSPWC", as amended. Specification Reference is hereby made to the plans and specifications for full particulars and description of the work. The General Provisions (Part 1) to the SSPWC do not apply. The Carlsbad Municipal Water District encourages the participation of minority and women-owned businesses. The Carlsbad Municipal Water District encourages all bidders, suppliers, manufacturers, fabricators and contractors to utilize recycled and recyclable materials when available, appropriate and approved by the Engineer. Revised 5/01/08 Contract No. 501 1 1 (Industrial Park RW Service Lines Page 8 of 139 Pages BID DOCUMENTS The bid documents comprise the following documents which must be completed and properly executed including notarization, where indicated. 1. Contractor's Proposal 2. Bidder's Bond 3. Non-Collusion Affidavit 4. Designation of Subcontractor and Amount of Subcontractor's Bid 5. Bidder's Statement of Technical Ability and Experience 6. Acknowledgement of Addendum(a) 7. Certificate of Insurance. The riders covering the City, its officials, employees and volunteers may be omitted at the time of bid submittal but shall be provided by the Bidder prior to award of this contract. 8. Bidder's Statement Re Debarment 9. Bidder's Disclosure Of Discipline Record 10. Escrow Agreement for Security Deposits -(optional, must be completed if the Bidder wishes to use the Escrow Agreement for Security) ENGINEER'S ESTIMATE: All bids will be compared on the basis of the Engineer's Estimate. The estimated quantities are approximate and serve solely as a basis for the comparison of bids. The Engineer's Estimate is $200.000. TIME OF COMPLETION: The contractor shall complete the Work within the time set in the contract as defined in the General Provisions Section 6-7. SPECIALTY CONTRACTORS: ACCEPTABLE LICENSE TYPES Except as provided herein a bid submitted to the District by a Contractor who is not licensed as a contractor pursuant to the Business and Professions Code shall be considered nonresponsive and shall be rejected by the District. In all contracts where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder to be licensed in accordance with California law. Where federal funds are involved the contractor shall be properly licensed at the time the contract is awarded. In all other cases the contractor shall state their license number, expiration date and classification in the proposal, under penalty of perjury. This invitation to bid does not involve federal funds. The following classifications are acceptable for this contract: A: General Engineering ESCROW AGREEMENT If the Contractor intends to utilize the escrow agreement included in the contract documents in lieu of the usual 10% retention from each payment, these documents must be completed and submitted with the signed contract. The escrow agreement may not be substituted at a later date. OBTAINING PLANS AND SPECIFICATIONS Sets of plans, various supplemental provisions, and Contract documents may be obtained at the Cashier's Counter of the Faraday Center located at 1635 Faraday Avenue, Carlsbad, California 92008-7314, for a non-refundable fee of $40 per set. If plans and specifications are to be mailed, the cost for postage should be added. INTENT OF PLANS AND SPECIFICATIONS Any prospective bidder who is in doubt as to the intended meaning of any part of the drawings, specifications or other contract documents, or finds discrepancies in or omissions from the drawings and specifications may submit to the Engineer a written request for clarification or correction. Any response will be made only by a written addendum duly issued by the Engineer a copy of which will Revised 5/01/08 Contract No. 50111 (Industrial Park RW Service Lines Page 9 of 139 Pages be mailed or delivered to each person receiving a set of the contract documents. No oral response will be made to such inquiry. Prior to the award of the contract, no addition to, modification of or interpretation of any provision in the contract documents will be given by any agent, employee or contractor of the Carlsbad Municipal Water District except as hereinbefore specified. No bidder may rely on directions given by any agent, employee or contractor of the Carlsbad Municipal Water District except as hereinbefore specified. REJECTION OF BIDS The Carlsbad Municipal Water District reserves the right to reject any or all bids and to waive any minor irregularity or informality in such bids. PREVAILING WAGE TO BE PAID The general prevailing rate of wages for each craft or type of worker needed to execute the Contract shall be those as determined by the Director of Industrial Relations pursuant to the sections 1770, 1773, and 1773.1 of the Labor Code. Pursuant to section 1773.2 of the Labor Code, a current copy of applicable wage rates is on file in the Office of the City Engineer. The Contractor to whom the Contract is awarded shall not pay less than the said specified prevailing rates of wages to all workers employed by him or her in the execution of the Contract. The Prime Contractor shall be responsible for insuring compliance with provisions of section 1777.5 of the Labor Code and section 4100 et seq. of the Public Contracts Code, "Subletting and Subcontracting Fair Practices Act." The City Engineer is the District's "duly authorized officer" for the purposes of section 4107 and 4107.5. The provisions of Part 7, Chapter 1, of the Labor Code commencing with section 1720 shall apply to the Contract for work. PRE BID MEETING A pre-bid meeting and tour of the project site will not be held. UNIT PRICES AND COMPUTATION OF BIDS All bids are to be computed on the basis of the given estimated quantities of work, as indicated in this proposal, times the unit price as submitted by the bidder. In case of a discrepancy between words and figures, the words shall prevail. In case of an error in the extension of a unit price, the corrected extension shall be calculated and the bids will be computed as indicated above and compared on the basis of the corrected totals. All prices must be in ink or typewritten. Changes or corrections may be crossed out and typed or written in with ink and must be initialed in ink by a person authorized to sign for the Contractor. ADDENDUMS Bidders are advised to verify the issuance of all addenda and receipt thereof one day prior to bidding. Submission of bids without acknowledgment of addenda may be cause of rejection of bid. BOND AND INSURANCE REQUIREMENTS The Contractor shall provide bonds to secure faithful performance and warranty of the work in an amount equal to one hundred percent (100%) of the Contract price on this project. The Contractor shall provide bonds to secure payment of laborers and materials suppliers, in an amount equal to one hundred percent (100%) of the total amount payable by the terms of the contract. These bonds shall be kept in full force and effect during the course of this project, and shall extend in full force and effect and be retained by the District until they are released as stated in the General Provisions section of this contract. All bonds are to be placed with a surety insurance carrier admitted and authorized to transact the business of insurance in California and whose assets exceed their m¥ Revised 5/01/08 Contract No. 50111 (Industrial Park RW Service Lines Page 10 of 139 Pages liabilities in an amount equal to or in excess of the amount of the bond. The bonds are to be accompanied by the following documents: 1) An original, or a certified copy, of the unrevoked appointment, power of attorney, by laws, or other instrument entitling or authorizing the person who executed the bond to do so. 2) A certified copy of the certificate of authority of the insurer issued by the insurance commissioner. If the bid is accepted, the District may require copies of the insurer's most recent annual statement and quarterly statement filed with the Department of Insurance pursuant to Article 10 (commencing with section 900) of Chapter 1 of Part 2 of Division 1 of the Insurance Code, within 10 calendar days of the insurer's receipt of a request to submit the statements. Insurance is to be placed with insurers that: 1) Have a rating in the most recent Best's Key Rating Guide of at least A-:VII 2) Are admitted and authorized to transact the business of insurance in the State of California by the Insurance Commissioner. Auto policies offered to meet the specification of this contract must: 1) Meet the conditions stated above for all insurance companies. 2) Cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. Workers' compensation insurance required under this contract must be offered by a company meeting the above standards with the exception that the Best's rating condition is waived. The District does accept policies issued by the State Compensation Fund meeting the requirement for workers' compensation insurance. The Contractor shall be required to maintain insurance as specified in the Contract. Any additional cost of said insurance shall be included in the bid price. The award of the contract by the District is contingent upon the Contractor submitting the required bonds and insurance, as described in the contract, within twenty days of bid opening. If the Contractor fails to comply with these requirements, the District may award the contract to the second or third lowest bidder and the bid security of the lowest bidder may be forfeited. BUSINESS LICENSE The prime contractor and all subcontractors are required to have and maintain a valid City of Carlsbad Business License for the duration of the contract. Approved by the Board of Directors of the Carlsbad Municipal Water District, California, by Resolution No. 1351, adopted on the 5th day of May, 2009. May 14. 2009 Rhonda Heather Date Deputy City Clerk Publish Date: May 21, 2009 Revised 5/01/08 Contract No. 50111 (Industrial Park RW Service Lines Page 11 of 139 Pages CARLSBAD MUNICIPAL WATER DISTRICT INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 CONTRACTOR'S Board of Directors Carlsbad Municipal Water District 1200 Carlsbad Village Drive Carlsbad, California 92008 The undersigned declares he/she has carefully examined the location of the work, read the Notice Inviting Bids, examined the Plans, Specifications, General Provisions, Contract Documents, and addenda thereto, and hereby proposes to furnish all labor, materials, equipment, transportation, and services required to do all the work to complete Contract No. 52011 in accordance with the Plans, sjecjfig§tiin§, 9f ntr§! Pr9vi§i9n§, Qgntrapt ppcumfnt§, §nsl i^er^a thereto ^ thsrt he/§hf will take in full payment therefore the following unit prices for each item complete, to wit: Item Na A-1 A-2 A-3 Description Mobilization, demobilization, and preparatory work at a stipulated lump sum of Six Thousand Dollars (Stipulated Amount DO NOT CHANGE) Perform exploratory excavations for underground utilities at Sixteen Thousand Dollars (Price in Words) Sheeting, shoring, bracing for the protection of trench and workers in excavations at Two Thousand Dollars (Price in Words) SCHEDULE "A" Approximate Quantity And Unit LS $ Unit Price (Figures) 6.000.00 Total Amount (Figures) $ 6.000.00 LS $ 16.000.00 $ 16.000.00 LS $ 2.000.00 $ 2.000.00 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 -19 of 139 Item No. Description Approximate Quantity And Unit Unit Price (Figures) Total Amount (Figures) A-4 Construction 1-inch RW service (No. 1, Sheet 5) and all related work at Five Thousand Dollars (Price in Words) A-5 Construction two 2-inch RW service (No. 2&3, Sheet 6) perCMWDStd. Dwg.W4 including 2-inch PVC RW main, hot top connection and all related work at Twenty Thousand Dollars (Price in Words) A-6 Construction two 1-inch RW services (No. 4 & 5, Sheet 7) per eMWD Std. Dwg. W3 including 4-inch PVC RW main, hot top connection with 4-inch gate valve and all related work at Thirty Five Thousand Dollars (Price in Words) A-7 Construction 2-inch RW services (No. 6, Sheet 8) per CMWD Std. Dwg. W4 and and all related work at Six Thousand Dollars (Price in Words) A-8 Construction 2-inch RW services (No. 7, Sheet 9) per CMWD Std. Dwg. W4 and all related work at Six Thousand Dollars (Price in Words) LS $5.000.00 $ 5.000.00 LS $ 20,000.00 $ 20.000.00 LS $ 35.000.00 $ 35.000.00 LS $ 6.000.00 $ 6.0QO.OQ LS $ 6,000.00 $ 6.000.00 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12-19 of 139 Item No, Description Approximate Quantity And Unit Unit Price (Figures) Total Amount (Figures) A-9 Construction 2-inch RW services (No. 8, Sheet 10) per CMWD Std. Dwg. W4 and all related work at §ix ThQfcisjnd Bellam (Price in Words) A-10 Construction 2-inch RW services (No. 9, Sheet 11) per CMWD Std. Dwg. W4 and all related wprk at Seven Thousand Dollars (Price in Words) A-11 Construction two 2-inch RW serving (N0. 19 im Sheet 12) per CMWD Std. Dwg. W4 including microtunnei under median and all related work at Eight Teen Thousand Dollars (Price in Words) A-12 Construction two 2-inch RW services (No. 11 & 12, Sheet 13) per CMWD Std. Dwg. W4 and all related work at Twelve Thousand Dollars (Price in Words) LS $ 6.000.00 $ 6.000.00 LS $ 7.000.00 $ 7,000.00 LS $ 18,000.00 $ 18.000.00 LS $ 12.000.00 $12.000.00 A-13 Construction 2-inch RW services (No. 13, Sheet 14) per CMWD Std. Dwg. W4 and all related work at Six Thousand Dollars (Price in Words) LS $ 6.000.00 $ 6.000.00 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 - 19 of 139 Item No. Description Approximate Quantity And Unit Unit Price (Figures) Total Amount (Figures) A-14 Construction 2-inch RW LS S 12.000.00 services (No. 14 & 15, Sheet 15) per CMWD Std. Dwg. W4 and remove two existing 2" IR service laterals and all related work at Twelve Thousand Dollars (Price in Words) A-15 Provide all necessary and LS $ 2,500.00 required traffic control to perform construction in Bid Items A-1 through A-14 at Two Thousand Five Hundred Dollars (Price in Words) $ 12.000.00 $ 2.500.00 A-16 All other work to be done to LS $ N/A $ N/A complete the project but not specifically listed in Bid Item A-1 through A-15 at N/A (Price in Words) Total amount of bid in words for Schedule "A": One Hundred Fifty Nine Thousand and Five Hundred Dollars & Zero Cents. Total amount of bid in numbers for Schedule "A": $ 159,500.00 The basis of award will be the sum of Schedule "A". Price(s) given above are firm for 90 days after date of bid opening. Addendum(a) No(s). 1 has/have been received and is/are included in this proposal. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 -19 of 139 The Undersigned has carefully cheeked all ef the abeve figures and understands that the District will not be responsible for any error or omission on the part of the Undersigned in preparing this bid. The Undersigned agrees that in case of default in executing the required Contract with necessary bonds and insurance policies within twenty (20) days from the date of award of Contract by the Board of Directors of the Carlsbad Municipal Water District, the District may administratively authorize award ef the contract to the second QF third lowest bidder and the bid security ef the fewest bidder may be forfeited. The Undersigned bidder declares, under penalty of perjury, that the undersigned is licensed to do business or act in the capacity of a contractor within the State of California, validly licensed under license number 437235 , classification A.B.C34,C36,C42 which expires on 4/30/2011 , and that this statement is true and correct and has the legal effect of an affidavit. A bid submitted to the District by a Contractor who is not licensed as a contractor pursuant to the Business and Professions Code shall be considered nonresponsive and shall be rejected by the District § 7028.15(e). In all contracts where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder to be licensed in accordance with California law. However, at the time the contract is awarded, the contractor shall be properly licensed. The Undersigned bidder hereby represents as follows: 1. That no Board member, officer agent, or employee of the City of Carlsbad is personally interested, directly or indirectly, in this Contract, or the cornpf nsatipn to- be pgid hereunder; that no representation, oral or in writing, of the Board of Directors, its officers, agents, or employees has inducted him/her to enter into this Contract, excepting only those contained in this form of Contract and the papers made a part hereof by its terms; and 2. That this bid is made without connection with any person, firm, or corporation making a bid for the same work, and is in all respects fair and without collusion or fraud. Accompanying this proposal is Bid Bond (Cash, Certified Check, Bond or Cashier's Check) for ten percent (10%) of the amount bid. The Undersigned is aware of the provisions of section 3700 of the Labor Code which requires every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and agrees to comply with such provisions before commencing the performance of the work of this Contract and continue to comply until the contract is complete. The Undersigned is aware of the provisions of the Labor Code, Part 7, Chapter 1, Article 2, relative to the general prevailing rate of wages for each craft or type of worker needed to execute the Contract and agrees to comply with its provisions. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 - 19 of 139 Check a License or Home Improvement Salesperson (HIS) Registration - Contractors Stat... Page 1 of 1 Department of Consumer Affairs *- Contractors State License Board Contractor's License Detail - License # 437235 £J_1 DISCLAIMER: A license status check provides information taken from the CSLB license database. Before relying on this information, you should be aware of the following limitations. » CSLB complaint disclosure is restricted by law (B&P 7124.6). If this entity is subject to public complaint disclosure, a link for complaint disclosure will appear below. Click on the link or button to obtain complaint and/or legal action information. s> Per B&P 7071,17, only construction related civil judgments reported to the CSLB are disclosed. ••» Arbitrations are not listed unless the contractor fails to comply with the terms of the arbitration. ••» Due to workload, there may be relevant information that has not yet been entered onto the Board's license database. License Number: Business Information: Entity: Issue Date: Expire Date: License Status: Classifications: Bonding: Workers' Compensation: 437235 Extract Date: 06/30/2009 ATLAS-ALLIED INC 1210 N LAS BRISAS ANAHEIM, CA 92806 Business Phone Number: (314) 630-3633 Corporation 04/07/1983 04/30/2011 This license is current and active. All Information below should be reviewed. CLASS DESCRIPTION A GENERAL ENGINEERING CONTRACTOR B GENERAL BUILDING CONTRACTOR C34 PIPELINE C36 PLUMBING C42 SANITATION SYSTEM CONTRACTOR'S BOND This license filed Contractor's Bond number 6481400 in the amount of $12,500 with the bonding company FIRST NATIONAL INSURANCE COMPANY OF AMERICA. Effective Date: 03/22/2008 Contractor's Bonding History BOND OF QUALIFYING INDIVIDUAL 1. The Responsible Managing Officer (RMO) GEORGE LOUIS SICILIAN! certified that he/she owns 10 percent or more of the voting stock/equity of the corporation. A bond of qualifying individual is not required. Effective Date: 04/05/1984 This license has workers compensation insurance with the EVERESI.NATIONAL INSURANCE COMPANY Policy Number: 7600000261081 Effective Date: 11/01/2008 Expire Date: 11/01/2009 Workers' Compensation History Conditions of Use | Privacy Policy Copyright © 2009 State of California https://www2.cslb.ca.gov/OnlineServices/CheckLicense/LicenseDetail.asp 6/30/2009 IF A SOLE OWNER OR SOLE CONTRACTOR SIGN HERE: *"""' (1) Name under which business is conducted N/A(2) Signature (given and surname) of proprietor (3) Place of Business (Street andTTumber)"™ City and State (4) Zip Code : Telephone No. (5) E-Mail IF A PARTNERSHIP. SIGN HERE: N/A (1) Name under which business is conducted (2) Signature (given and surname and character of partner) (Note: Signature must be made by a general partner) (3) Place of Business (Street and Number) City and State (4) Zip Code Telephone No. (5) E-Mail Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 -19 of 139 IF A CORPORATION. SIGN HERE: (1) Name under which business is conducted Atlas-Allied. Inc. (2). (Signature} Corp. Secertary (Title) Impress Corporate Seal here (3) Incorporated under the laws of the State of California (4) Place of Business 1210 N. Las Brisas (Street and Number) City and State Ananeim. CA (5) Zip Code 92806 Telephone No. 714-630-3633 (6) E-Mail eva@atlas-aHied.com NOTARIAL ACKNOWLEDGMENT OF EXECUTION BY ALL SIGNATORIES MUST BE ATTACHED Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 - 19 of 139 ACKNOWLEDGMENT State of California County of Orange On June 29. 2009 before me, Nile Sensabauqh. Notary Public personally appeared Catherine Sturgeon l who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that she executed the same in her authorized capacity, and that by her signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. f WITNESS my hand and official seal. NILE SENSABAUGH ^'Sorange County Signature ' _ (Seal) Nile Sensabaugh, Notary Public List below Rames of president, vice president, secretary and assistant secretary, if a eorperation; if a partnership, list names of all general partners, and managing partners: George L. Siciliani President Eva Siciliani Vice President Catherine Sturgeon Corp. Secertary Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12-19 of 139 BID SECURITY FORM (Check to Accompany Bid) INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 (NOTE: The following form shall be used if check accompanies bid.) Accompanying this proposal is a ""Certified *Cashiers check payable to the order of CARLSBAD MUNICIPAL WATER DISTRICT, in the sum of dollars ($ . ), this amount being ten percent (10%) of the total amount of the bid. The proceeds of this check shall become the property of the District, provided this proposal shall be accepted by the District through action of its legally constituted contracting authorities and the undersigned shall fail to execute a contract and furnish the required Performance, Warranty and Payment Bonds and proof of insurance coverage within the stipulated time; otherwise, the check shall be returned to the undersigned. The proceeds of this check shall also become the property of the District if the undersigned shall withdraw his or her bid within the period of fifteen (15) days after the date set for the opening thereof, unless otherwise required by law, and notwithstanding the award of the contract to another bidder. BIDDER *Delete the inapplicable word. (NOTE: If the Bidder desires to use a bond instead of check, the Bid Bond form on the following pages shall be executed-the sum of this bond shall be not less than ten percent (10%) of the total amount of the bid.) Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 20 of 139 Pages BIDDER'S BOND TO ACCOMPANY PROPOSAL INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 KNOW ALL PERSONS BY THESE PRESENTS:First National Insurance That we, Atlas-Allied, Inc. as Principal, and Company of America as Surety are held and firmly bound unto the Carlsbad Municipal Water District, California, in an amount as follows: (must be at least ten percent (10%) of the bid amount) Ten Percent * for which payment, well and truly made, we bind ourselves, our heirs, executors and administrators, successors or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH that if the proposal of the above- bounden Principal for: INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 in the City of Carlsbad, is accepted by the Board of Directors, and if the Principal shall duly enter into and execute a Contract including required bonds and insurance policies within twenty (20) days from the date of award of Contract by the Board of Directors of the Carlsbad Municipal Water District of the City of Carlsbad, being duly notified of said award, then this obligation shall become null and void; otherwise, it shall be and remain in full force and effect, and the amount specified herein shall be forfeited to the said District. * of the Total Amount of the Bid ($10%) Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 21 of 139 Pages In the event Principal executed this bond as an shall not exonerate the Surety from its obligations individual, it is agreed that the death of Principal under this bond. Executed by PRINCIPAL this. PRINCIPAL: Atlas-Allied, Inc. day of (namajpf Principal) Bv: (sign here) Eva Sicilian! (print name here) Vice President/Treasurer (Title and Organization of Signatory) By: (sign here) (print name here) (title and organization of signatory) Executed by SURETY this 26th day of June , 20 09 . SURETY: First National Insurance Company of America (name of Surety) 120 Vantis, 3rd Floor, Aliso Viejo, CA 92656 (address of Surety) 949-860-6612 rnef-ih-Fact) Adriana Valenzuela (printed name of Attorney-in-Fact) (Attach corporate resolution showing current power of attorney.) (Proper notarial acknowledgment of execution by PRINCIPAL and SURETY must be attached.) (President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under corporate seal empowering that officer to bind the corporation.) APPROVED AS TO FORM: RONALD R. BALL General Counsel . Deputy General Counsel oRevised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 22 of 139 Pages Company Profile Page 1 of2 CALIFORNIA DEPARTMENT OF IMSURfiNCE Company Profile Company Search Company Search Results CompanyInformation Old Company Names Agent for Service Reference Information NAIC Group List Lines of Business Financial Statements PDF's Annual Statements Quarterly Statements CA Supplements Company Complaint Company Performance & Comparison Data Company Enforcement Action Composite Complaints Studies Additional Info Find A Company Representative In Your Area View Financial Disclaimer COMPANY PROFILE Company Information FIRST NATIONAL INSURANCE COMPANY OF AMERICA 175 BERKELEY STREET BOSTON, MA 02116 617635769500 Old Company Names back to top Agent For Service KAREN HARRIS 2730 GATEWAY OAKS DRIVE SUITE 100 SACRAMENTO CA 95833 back to top Reference Information back to top NAIC Group List Effective Date NAIC #: California Company ID #: Date Authorized in California: License Status: Company Type: State of Domicile: 24724 0978-7 01/03/1929 UNLIMITED-NORMAL Property & Casualty WASHINGTON NAIC Group #: back to top 0111 LIBERTY MUT GRP Lines Of Business The company is authorized to transact business within these lines of insurance. For an explanation of any of these terms, please refer to the glossary. AIRCRAFT AUTOMOBILE BOILER AND MACHINERY BURGLARY COMMON CARRIER LIABILITY CREDIT FIRE http://interactive.web.insurance.ca.gov/companyprofile/companyprofile?event:=companyPr... 6/30/2009 Company Profile Page 2 of 2 LIABILITY MARINE MISCELLANEOUS PLATE GLASS SPRINKLER SURETY TEAM AND VEHICLE WORKERS' COMPENSATION back to top © 2008 California Department of Insurance http://interactive.web.insurance.ca.gov/companyprofile/companyprofile?event=companyPr... 6/30/2009 ACKNOWLEDGMENT State of California County of Orange On June 29. 2009 before me, Nile Sensabauah. Notary Public personally appeared Eva Siciliani who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that she executed the same in her authorized capacity, and that by her signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. HUE 8EMSAMU6M I CommJ«l«i # 1800M9 i WITNESS my hand and official seal. A Comm. Expires <lun 1.2012 j Signature sr/~^ (Seal) Nile Sensabaugh, Notary Public ACKNOWLEDGMENT State of California County of Orange On June 26, 2009 before me, Susan Ponsell, Notary Public (insert name and title of the officer) Adriana Valenzuelapersonally appeared who proved to me on the basis of satisfactory evidence to be the persorXs^Twhose name^is/are' subscribed to the within instrument and acknowledged to me thatheTshe/they executed the same in J«s7her/tbeifauthorized capacityj^S), and that by>fc7her/tbetf signature^s)-on the instrument the person(s)7orthe entity upon behalf of which the persor>(s^acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. A.A A WITNESS my hand and official seal. Signature SUSAN PONSELL N COMWI. # 1734814 ^ i) NOTARY PUBLIC - CALIFORNIA § ORANGE COUNTY -- My Commission Expires MlfCtl 27.20111^ 'v v v~v yvvvvwvvvvvvvv. (Seal) Liberty POWER OF ATTORNEY First National Insurance Company of America 1001 4th Avenue Suite 1700 Seattle, WA 98154 KNOW ALL BY THESE PRESENTS:No- 13201 That FIRST NATIONAL INSURANCE COMPANY OF AMERICA, a Washington corporation, does hereby appoint **»,»*»»**»*****LOURDES LANDA. MARK RQSSKOPF; ADRIANA VALENZUELA; Fullerton, CA*********** its true and lawful attomey(s)-in-fact, with full authority to execute on behalf of the company fidelity and surety bonds or undertakings and other documents of a similar character issued by the company in the course of its business, and to bind FIRST NATIONAL INSURANCE COMPANY OF AMERICA thereby as fully as if such instruments had been duly executed by its regularly elected officers at its home office. IN WITNESS WHEREOF, FIRST NATIONAL INSURANCE COMPANY OF AMERICA has executed and attested these presents this 21st day of March 2009 Dexter R. Legg, Secretary Timothy A. Mikolajewski, Vice President CERTIFICATE Extract from the By-Laws of FIRST NATIONAL INSURANCE COMPANY OF AMERICA: "Article V, Section 13. - FIDELITY AND SURETY BONDS ... the President, any Vice President, the Secretary, and any Assistant Vice President appointed for that purpose by the officer in charge of surety operations, shall each have authority to appoint individuals as attorneys-in-fact or under other appropriate titles with authority to execute on behalf of the company fidelity and surety bonds and other documents of similar character issued by the company in the course of its business... On any instrument making or evidencing such appointment, the signatures may be affixed by facsimile. On any instrument conferring such authority or on any bond or undertaking of the company, the seal, or a facsimile thereof, may be impressed or affixed or in any other manner reproduced; provided, however, that the seal shall not be necessary to the validity of any such instrument or undertaking." Extract from a Resolution of the Board of Directors of FIRST NATIONAL INSURANCE COMPANY OF AMERICA adopted July 28, 1 970. "On any certificate executed by the Secretary or an assistant secretary of the Company setting out, (i) The provisions of Article V, Section 1 3 of the By-Laws, and (ii) A copy of the power-of-attorney appointment, executed pursuant thereto, and (iii) Certifying that said power-of-attorney appointment is in full force and effect, the signature of the certifying officer may be by facsimile, and the seal of the Company may be a facsimile thereof." I, Dexter R. Legg , Secretary of FIRST NATIONAL INSURANCE COMPANY OF AMERICA, do hereby certify that the foregoing extracts of the By-Laws and of a Resolution of the Board of Directors of this corporation, and of a Power of Attorney issued pursuant thereto, are true and correct, and that both the By-Laws, the Resolution and the Power of Attorney are still in full force and effect. , IN WITNESS WHEREOF, I have hereunto set my hand and affixed the facsimile seal of said corporation 26 200Hthisday of S-1049/DF3/09 Dexter R. Legg, Secretary WEB PDF GUIDE FOR COMPLETING THi "PiilQNATIQN QF SUBCONTRACTORS" FQRM REFERENCES Prior to preparation of the following "Subcontractor Disclosure Form" Bidders are urged to review the definitions in section 1-2 of the General Provisions to this Contract, especially, "Bid", "Bidder", "Contract", "Contractor", "Contract Price", "Contract Unit Price", "Engineer", "Own Organization", "Subcontractor", and "Work". Bidders are further urged to review sections 2-3 SUBCONTRACTS of the General Provisions. CAUTIONS This form will be used by the Agency to determine the percentage of work that the Bidder proposes to perform. Bidders are cautioned that failure to provide complete and correct information may result in rejection of the bid as non-responsive. Any bid that proposes performance of more than 50 percent of the work by subcontractors or otherwise to be preformed by forces other than the Bidder's own organization will be rejected as non-responsive. Specialty items of work that may be so designated by the Engineer on the "Contractor's Proposal" are not included in computing the percentage of work proposed to be performed by the Bidder. INSTRUCTIONS The Bidder shall set forth the name and location of business of each and every subcontractor whom the Bidder proposes to perform work or labor or render service in or about the work or improvement, and every subcontractor licensed as a contractor by the State of California whom the Bidder proposes to specially fabricate and install any portion of the work or improvement according to detailed drawings contained in the plans and specifications in excess of one-half of one percent (0.5%) of the Bidder's total bid or, in the case of bids or offers for the construction of streets and highways, including bridges, in excess of one-half of one percent (0.5%) or ten thousand dollars ($10,000) whichever is greater. Said name(s) and location(s) of business of subcontractor(s) shall be set forth and included as an integral part of the bid offer. The Designation of Subcontractors form must be submitted as a part of the Bidder's sealed bid. Failure to provide complete and correct information may result in rejection of the bid as non- responsive. Suppliers of materials from sources outside the limits of work are not subcontractors. The value of materials and transport of materials from sources outside the limits of work, as shown en the plans, shall be assigned to the Contractor or the Subcontractor as the case may be, that the Bidder proposes as installer of said materials. The value of material incorporated in any Subcontractor- installed bid item that is supplied by the Bidder shall be included as a part of the work that the Bidder proposes to be performed by the Subcontractor installing said item. When a Subcontractor has a Carlsbad business license, the number must be entered on the proper form, if the Subcontractor does not have a valid business license, enter "NONE" in the appropriate space. When the Bidder proposes using a Subcontractor to construct or install less than 100 percent of a bid item, the Bidder shall attach an explanation sheet to the Designation of Subcontractor form. The explanation sheet §ha!l §tesrly amrim the Dtetrist ef thu §B§§ifis fi$s Ihit shpw the Bidder proposes to perform no less than fifty percent (50%) of the work with its own forces. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 23 of 139 Pages Determination of the subcontract amounts for purposes of award of the contract shall be determined by the Board of Directors in conformance with the provisions of the contract documents and the various supplemental provisions. The decision of the Board of Directors shall be final. Contractor is prohibited from performing any work on this project with a subcontractor who is ineligible to perform work on a public works project pursuant to Labor Code Sections 1771.1 or 1777.7. Bidders shall make any additional copies of the disclosure forms as may be necessary to provide the required information. The page number and total number of additional form pages shall be entered in the location provided on each type of form so duplicated. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Ones) Page 24 of 139 Pages DESIGNATION OF SUBCONTRACTOR AND AMOUNT OF SUBCONTRACTOR'S BID ITEMS (Te Aeeempany Proposal) INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 The Bidder certifies that it has used the sub-bid of the following listed subcontractors in preparing this bjgj for thf Vyprk and. thit thf lifted subjonfrictors will be used to perform the portions of the Work as designated in this list in accordance with applicable provisions of the specifications and section 4100 et seq. of the Public Contract Code, "Subletting and Subcontracting Fair Practices Act." The Bidder further certifies that no additional subcontractor will be allowed to perform any portion of the Work in excess of one-half of one percent (0.5%) of the Bidder's total bid, or in the case of bids or offers for construction of streets and highways, including bridges, in excess of one-half of one percent (0.5%) or ten thousand dollars ($10,000), whichever is greater, and that no changes in the subcontractors listed work will be made except HPQH the prior approval of the Agency SUBCONTRACTOR'S BID ITEMS Portion of Work A/C Paving Subcontractor Name and Location of Business Haitbrink Asphalt Paving 1548 Maple St. Corona , CA 92880 Subcontractor's License No. and Classification* . 517707 A&C-12 Amount of Work by Subcontractor in Dollars* $ 10.000.00 Page 1 of 1 pages of this Subcontractor Designation form Pursuant to section 4104 (a)(2}(A) California Public Contract Code, receipt of the information preceded by an asterisk may be submitted by the Bidder up to 24 hours after the deadline for submitting bids contained in the "Notice Inviting Bids." Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 25 of 139 Pages BIDDER'S STATEMENT OF TECHNICAL ABILITY AND EXPERIENCE (To Accompany Proposal) INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 The Bidder is required to state what work of a similar character to that included in the proposed Contract he/she has successfully performed and give references, with telephone numbers, which will enable the City to judge his/her responsibility, experience and skill. An attachment can be used. Date Contract Completed Name and Address of the Employer -' '•' ^.•••'•••-V'. -: -•• .. ".• ' •Name and Phone No. of Person to Contract Pl§§§6 £S§ Attafifcl Type of Work '" •- ' "" -•' 3 Amtunt of Contract Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 26 of 139 Pages Pipeline >M 7 GeneralRpina Engineering Descriptive Job List 2008 Project: Lampton Elementary School - Site Utilities-Prime Contractor Owner: Norwalk La Mirada Unified School District Address: 12820 Pioneer Blvd Norwalk, CA 90650 Contact: Isela Vazquez 562-868-0431 x2015 Fax 562-864-7541 Description: Site Utilities including gas, water & sewer. Install pipe, test backfill, patch, replace all site water with new copper system including dielectric fittings, chlorinate entire site water system. Replace all site gas with complete new gas system Dates: Completed 8/28/08 Amount: $332,650.00 Project: Fullerton College - Building 1400 Site Work / Utilities-Prime Contractor Owner: North Orange County Community College Address: 1830 WRomneya Drive Anaheim, CA 92801 Contact: C W Driver Builders Tanya Sundnes (714) 732-5770 Fax (714)446-0770 Description: Site utility improvements including storm drain, concrete and asphalt repairs Pates: Completed 6-1-09 Amount: $1,949,511.00 Project: Modification to Existing Pressure Relief Facilities Owner: West Orange County Water Board Address: 2000 Main Street Huntington Beach, CA 92648 Contact: City of Huntington Beach Duane Wentworth (714) 536-5517 Fax (714)374-1573 Description: Install new Pressure Relief System for 20" City Huntington Beach water supply line, including excavation, piping, welding and on site improvements. This water line is a critical supply line for the City Huntington Beach water system. Dates: Completed 5/12/08 Amount: $246,150.00 Project: New Water Meter Installation & Meter Exchange Program -Prime Contractor Owner: City of Westminster Address: 8200 Westminster Boulevard Westminster, CA 92683 Contact: Paul Kalix (714)719-0461 Fax (714)373-5328 Description: From Early 1990 Atlas-Allied has performed a city wide water meter replacement of approximately 14,000+ water meters on 3 different contracts Dates: 8/27/07 - Current Amount: $354,500.00 YTD Pipeline Plpin8 2008 Continued Project: Lancaster Layover Service Utility Enhancement-Prime Contractor Owner: Southern CA Regional Rail Authority Address: 700 S Flower Street, Suite 2600 Los Angeles, CA 90017 Contact: LIM & Nascimento Engineering Corp Francisco Villasenor (714)998-3841 Fax (71 4) 974-61 93 Description: Metrolink Lancaster Station installed water, sewer, and communications utilities for end of line train maintenance yard. All work done with no interruptions or down time to the metro link trains. Dates: Completed 4/9/08 Amount: $1,136,537.00 Project: Orange Coast College East / West Utility Upgrade-Prime Contractor Owner: Coast Community College District Address: 1370 Adams Avenue Costa Mesa, CA 92626 Contact: C.W. Driver Randy Rankin (714) 540-4974 Cell (714) 540-5721 Description: East/ West Utility Upgrade / Phase II- Installed 1,000 LF of storm drain pipe, 20 catch basins, 1,000 LF of sewer for East Side Campus Wide Upgrade Dates: Completed March 2008 Amount: $639,872.00 Project: Huntington / Bolsa Chica State Beach - Emergency Backflow Project Owner CA Department of Parks & Recreation Address: 3030 Avenida del Presidente San Clemente, CA 92672 Contact: Julie Tobin (949) 366-4888 Fax (949) 492-9437 Description: Installed (4) 6" RP emergency backflow devices at various locations in the city of Huntington Beach following Huntington Beach Water Department compliance on a critical path emergency basis Dates: Completed 5/1/08 Amount: $91,500.00 GeneralEngineering Descriptive Job List 2007 Project: Wellhead Treatment at Well #13 Owner: City of Paramount Address: 16400 Colorado Avenue Paramount, CA 90723 Contact: Bill Pagett P.E. (562) 220-2157 Fax (562) 220-2105 Description: Manganese removal of Well #13 in the City of Paramount. Installation of new filtering system (3each 10,000 gallon tanks, 2 each 8,000 gallon tanks, and 124,000 Ibs of media filtering material). Including 83,000 gallon bolted tank, 2 block buildings.new serge tank, new chemical feeder tanks (1,060 gal & 230 gal tanks),new So Gal Edison service, new Murphy Panel, new Filter Control Panel (FCP), new metering and valve system. Dates: Completed 4/10/07 Amount: $1,368,524.00 Project: Huntington Beach High School Utility Installation-Prime Contractor Owner: Huntington Beach Union High School Dist Address: 5832 Bolsa Avenue Huntington Beach, CA 92649 Contact: McCarthy Building Companies John Staff (949)851-8383 Fax (949) 756-6843 Description: Combined utility upgrades including 1,000 LF of Domestic Water, Fire Water, Irrigation, Electrical Conduit and Gas, plus surface repairs as needed Dates: Completed 8/24/07 Amount: $1,043,344.00 Project: Foothill High School Site Utility Infrastructure-Prime Contractor Owner: Tustin Unified School District Address: 300 South C Street Tustin, CA 92780 Contact: Douglas E Bamhart, Inc John Squillace (714)731-4687 Fax (714) 731-4691 Description: Installed 1,000 LF of 6" -10" Storm drain, 1,000 LF 8" Sewer, 800 LF 8" Fire water line, 600 LF 6" Domestic Water, 500 LF 3" Gas line at Foothill High School for the Site Utility Infrastructure Quad Upgrade Dates: Completed 8/31/07 Amount: $975,258.00 Project: Concordia University Sewer, Water, & Storm Drain Installation Owner: C W Driver, Inc. Address: 15615 Alton Parkway, Suite 150 Irvine, CA 92618 Contact: Chris Graber (949)261-5100 Fax (949) 261-5167 Description: Installed Underground Site water, sewer & storm drain (8" Water line 800' /18" Storm Drain 1,000' / 6" Sewer line 700') through out Concordia University in Irvine Dates: Completed 6/27/07 Amount: $885,729.00 2007 Continued Project: Replace Pressure Reguarting Station #36 Owner: City of Anaheim Address: 200 S Anaheim Blvd Anaheim, CA 92805-3820 Contact: Bob Palaeologus (714) 765-5176 X5711 Fax (714) 765-5225 Pressure Regulating Station #36 Description: Replacement of Pressure Regulating Station #36 Dates: Completed 3/1/07 Amount: $372,115.20 Project: Water Meter Installations Owner: City of Alhambra Address: 111 S. First Street Alhambra, CA 91801-3704 Contact: Phil Nichols (626) 570-5067 Fax (626) 570-5067 Description: From 2003-2007 Atlas-Allied has performed a city wide water meter replacement of approximately 4,000+ water meters for the City of Alhambra. Dates: 2003 - 2007 Amount: $194,325.00 ATLAS-ALLIED, INC. Pipeline Piping General Engineering REFERENCE SHEET 2006 Walsh-Dillon Construction 27761 Camino Santo Domingo San Juan Capistrano, CA 92675 Mike Dillon (949)661-0346 Fax(949) 661-0346 Water Improvements @ Ortega Hwy, San Juan Capistrano $73,000.00 Huntington Beach Union High School Dist 5832 Bolsa Avenue Huntington Beach, CA 92646 John Staff / McCarthy (949) 851-8383 Fax (714) 964-3408 Watertine @ Huntington Beach High School Completed 3/16/06 $221,155.36 S D Deacon 20201 S W Birch Street, Suite 100 Newport Beach, CA 92660 Mark Runyan (949) 222-9060 Fax (949) 222-0596 Water, Sewer, Storm Drain @ Stadium Promenade, Orange $307,012.93 Orange County Water District 18700 Ward Street Fountain Valley, CA 92708 Mark Butier, Jr. (ButierC.M. 714 832-7222) Fax (714) 832-7211 Warner Basin Dam, Anaheim Completed 9/27/06 $364,282.66 Pipeline Piping GeneralEngineering REFERENCE SHEET 2005 Anaheim Union High School District 501 Crescent Way Anaheim, CA 92803 Roger Fisher - (949) 250-1500 Ph Fax (949) 555-2708 Anaheim High School Modernization $99,70100 Anaheim Union High School District 501 Crescent Way Anaheim, CA 92803 Guillermo Aguilar - (949) 250-1500 Fax (949) 555-2708 South Junior High School Fire Water / Storm Drain Extensions $794,900.00 North Orange County Comm. College Dist. 1830 W. Romneya Drive Anaheim, CA 92801-1819 Mike Fistes - (714) 252-9440 Fax (714) 252-9445 Cypress College Water System Improvements $455,720.94 North Orange County Comm. College Dist. 1830 W. Romneya Drive Anaheim, CA 92801-1819 Harold Abeln (C W Driver 949 261-5100) Fax(949 261-5167 Fullerton College - FireWaterSystem&StormDrain Completed 4/25/06 $2,093,083.00 Norwalk - La Mirada Unified School Dist. 12820 Pioneer Boulevard Norwalk, CA 90650-2894 Dennis Teo - (562) 863-2833 Ph Fax 562) 863-2813 Interim Housing @ Arturo Sanchez Elementary School $586,350.00 Rancho California Water District 42135 Winchester Road Temecula, CA 92590 Hilda Bojorquez - (951) 296-6989 Fax (951) 296-6860 Recycled Water Meter Modification $43,350.00 El Rancho Unified School District 8910 E. Slauson Avenue Pico Rivera, CA 90660 Pedro Newbern - (626) 449-6787 Fax (626) 449-6477 Modulars: 8 Classrooms - 2 Restrooms At South Ranchito Elementary School $1,229,357.34 Orange County Water District 18700 Ward Street Fountain Valley, CA 92708 Mark Butier, Jr. (Butier C. M. 714 832-7222) Fax (714) 832-7211 Mini-Anaheim Inflow Improvement Completed 3/14/06 $709,989.85 PipelinePiping General Engineering REFERENCE SHEET 2004 Anaheim Union High School Dist. C/O G K K Works (JFK High School) 8281 Walker Street La Raima, CA 90620 Ed Sukchai (714) 220-2600 Fax (714) 220-0277 Fire Water Connection @ JFK High $109,096.00 CA Department of Mental Health Metropolitan State Hospital 11401 S Bloomfield Avenue Norwalk, CA 90650 Leroy Richards (562) 651-4396 Fax (562) 929-1054 Shut Off Valves / Water Valves $705,370.00 Fullerton Joint Union High School Dist. C/O Erickson - Hall Construction 1021 W Bastanchury Rd., #110 Fullerton, CA 92833 Dave Hall (714)738-4995 Fax (714) 738-5194 Water Improvements - 4 Sites $208,500.00 John Wayne Airport 3160 Airway Avenue Costa Mesa, CA 92626 Jeff Oviedo (949) 252-5275 Ph Fax (714) 979-9862 Flush Mount Fire Hydrants $1,097,034.00 Los Angeles County Dept. Public Works 900 S Fremont Avenue Alhambra, CA91803 Ambrose Ajelo (626) 458-7921 Fax (626) 458-7827 Pump Station - Manhattan Beach $759,585.00 Los Angeles County Dept. Public Works 900 S Fremont Avenue Alhambra, CA91803 JosePou (626)458-2191 Fax (626) 458-2197 Low Flow Diversion - Redondo Beach Completed 4/29/05 $398,203.87 Walsh-Dillon Construction Inc. 27761 Camino Santo Domingo San Juan Capistrano, CA 92675 Fire Hydrant / Storm Drain Improvements Michael Dillon (949) 661-0346 Fax(949) 661-0346 $758,807.00 Helix Water District 7811 University Avenue La Mesa, CA 91941 ArtFloto (619) 596-1329 Ph Fax (619) 596-1320 Transmission Main Valve Installation $252,367.00 BIDDER'S CERTIFICATE OF INSURANCE FOR GENERAL LIABILITY, EMPLOYERS' LIABILITY, AUTOMOTIVE LIABILITY AND WORKERS' COMPENSATION (To Accompany Proposal) INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 As a required part of the Bidder's proposal the Bidder must attach either of the following to this page. 1) Certificates of insurance showing conformance with the requirements herein for each of: TSC Comprehensive General Liability y(. Automobile Liability "$s Workers Compensation 2) Statement with an insurance carrier's notarized signature stating that the carrier can, and upon payment of fees and/or premiums by the Bidder, will issue to the Bidder Policies of insurance for Comprehensive General Liability, Automobile Liability, Workers Compensation and Employer's Liability in conformance with the requirements herein and Certificates of insurance to the Agency showing conformance with the requirements herein. All certificates of insurance and statements of willingness to issue insurance for auto policies offered to meet the specification of this contract must: 1) Meet the conditions stated in The Notice Inviting Bids and the General Provisions for this project for each insurance company that the Contractor proposes. 2) Cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 27 of 139 Pages Clients: 1256929 305ATLASINC ACQRD, CERTIFICATE OF LIABILITY INSURANCE PRODUCER BB&T Insurance Svcs of CA Inc 680 Langsdorf Drive #100 Box 34009 Vuilerton, CA 92834-9409 INSURED Atlas-Allied, Inc. 1210 North Las Brisas Anaheim, CA 92806 DATE (MM/DD/YY) 08/11/2009 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE INSURER A: National Union Fire Ins Co PA(AIG) INSURER B: Everest National Insurance Company INSURER c: Travelers Prop & Cas Co America INSURER D: INSURER E: COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. NSRLTR A A A B C TYPE OF INSURANCE GENERAL LIABILITY X COMMERCIALGENERALLIABILITY | CLAIMS MADE X OCCUR GEN'L AGGREGATE LIM IT APPLIES PER:n ! I PRCV I "1POLICY j X | JECT 1 1 LOG AUTOMOBILE LIABILITY X ANY AUTO ALL OWNED AUTOS SCHEDULED AUTOS X HIRED AUTOS X NON-OWNED AUTOS GARAGE LIABILITY ANY AUTO EXCESS LIABILITY X OCCUR | CLAIMS MADE DEDUCTIBLE X RETENTION $10,000 WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OTHER Equipment Rented/Leased POLICY NUMBER 4882778 4882384 BE01 5679240 7600000261081 QT6601593C196TIL08 POLICY EFFECTIVEDATE (MM/DD/YY) 11/01/08 11/01/08 11/01/08 11/01/08 11/01/08 POLICY EXPIRATIONDATE (MM/DD/YY) 11/01/09 11/01/09 11/01/09 11/01/09 11/01/09 LIMITS EACH OCCURRENCE FIRE DAMAGE (Any one fire) MED EXP (Any one person) PERSONAL & ADV INJURY GENERAL AGGREGATE PRODUCTS -COMP/OPAGG COMBINED SINGLE LIMIT (Ea accident) BODILY INJURY(Per person) BODILY INJURY (Per accident) PROPERTY DAMAGE (Per accident) AUTO ONLY • EA ACCIDENT OTHER TH/ AUTO ONL' w EAACC ': AGG EACH OCCURRENCE AGGREGATE X WC STATU- OTH-TORY LIMITS ER E.L. EACH ACCIDENT E.L. DISEASE - EA EMPLOYEE E.L.DISEASE - POLICY LIMIT $1,000,000 $50,000 $5,000 $1,000,000 $2,000,000 $2,000,000 $1,000,000 $ $ $ $ $ $ $4,000,000 $4,000,000 $ $ $ $1,000,000 $1,000,000 $1,000,000 Deductible $1,000 $275,000 Max per item DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/EXCLUSIONS ADDED BY ENDORSEMENT/SPECIAL PROVISIONS Re: Bid No. PWS09-28ENG, Project No. 52011 - Industrial Park Recycled Water Service Lines The City of Carlsbad, its officials, employees, volunteers, and the Carlsbad Municipal Water District, its agents, officers, and employees are named additional insured as respects general and auto liability, this insurance is primary and noncontributory with any other insurance of the additional insured, and waiver of (See Attached Descriptions) CERTIFICATE HOLDER ADDlTiONALlNSURED;lNSURERLETTER: CANCELLATION 1 0 Days for Non-Pavment City of Carlsbad Public Works Purchasing Dept. Attn: Kevin Davis 1635 Faraday Avenue Carlsbad, CA 92008 SHOULD ANYOF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUTFAILURE TODOSOSHALL A A IMPOSE NO OBLIGATION OR LI ABILITY OF ANY KIND UPON THE INSURER/ITS AGENTS OR REPRESENTATIVES. \| . |\ / / AUTHORIZED REPRESENTATIVE iflm^ \ \\\ S //V tttWWy ACORD 25-S (7/97) 1 of 3 #53941584/M2701991 GAGAB© ACORD CORPORATION 1988 IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ACORD25-8(7/97)2 of 3 #S3941584/M2701991 DESCRIPTIONS (Continued from Page 1) subrogation applies as respects general liability, auto liability, and workers' compensation, as required by written contract, per endorsements attached. -*•1 Day notice to insured of cancellation for non-payment of premium/non-reporting of payroll. No other .. dification to the cancellation section in this certificate will apply to the Workers' Compensation coverage.** AMS 25.3 (07/97) 3 of 3 #83941584/M2701991 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ENDORSEMENT # 11/1/08This endorsement, effective 12:01 A.M. forms a part of Policy No. 4882778 issued tO Atlas-Allied Inc by National Union Fire Ins Co of PA ADDITIONAL INSURED - WHERE REQUIRED UNDER CONTRACT OR AGREEMENT (Professional Services Exclusion) This endorsement modifies insurance provided under the following: COAAMERCIAL GENERAL LIABILITY COVERAGE FORM Section II - Who is an Insured, 1., is amended to add: f. Any person or organization to whom you become obligated to include as an additional insured under this policy, as a result of any contract or agreement you enter into, excluding contracts or agreements for professional services, which requires you to furnish insurance to that person or organization of the type provided by this policy, but only with respect to liability arising out of your operations or premises owned by or rented to you. However, the insurance provided will not exceed the lesser of: 1. The coverage and/or limits of this policy, or 2. The coverage and/or limits required by said contract or agreement. Authorized Representative 61714(9/01) ENDORSEMENT # This endorsement, effective 12:01 A.M. 11/1/08 forms a part of Policy No. 4882778 issued to Atlas-Allied Inc. by National Union Fire Ins. Co. of PA ADDITIONAL INSURED - PRIMARY INSURANCE This endorsement modifies insurance provided under the following: COMMERCIAL LIABILITY COVERAGE FORM Section IV, Commercial General Liability Conditions, paragraph 4., Other Insurance, subparagraph a. Primary Insurance, is amended by the addition of the following: However, coverage under this policy afforded to an additional insured will apply as primary insurance where required by contract, and any other insurance issued to such additional insured shall apply as excess and noncontributory insurance. Authorized Representative 74434(10/99) POLICY NUMBER: 4882778 COMMERCIAL GENERAL LIABILITY CG 24 04 10 93 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Person or Organization: As required by written contract (If no entry appears above, information required to complete this endorsement will be shown in the Declarations as applicable to this endorsement.) The TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US Condition (Section IV - COMMER- CIAL GENERAL LIABILITY CONDITIONS) is amended by the addition of the following: We waive any right of recovery we may have against the person or organization shown in the Schedule above because of payments we make for injury or damage arising out of your ongoing operations or "your work" done under a contract with that person or organization and included in the "products-completed operations hazard". This waiver applies only to the person or organization shown in the Schedule above. CG 24 04 10 93 Copyright, Insurance Services Office, Inc., 1992 Page 1 of 1 D ENDORSEMENT This endorsement, effective 12:01 A.M.11/1/08 forms a part of Policy No.4882384 issued to Atlas-Allied Inc by: National Union Fire Ins Co of PA THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - WHERE REQUIRED UNDER CONTRACT OR AGREEMENT This endorsement modifies insurance provided under the following; BUSINESS AUTO COVERAGE FORM Section II • Liability Coverage, A. - Coverage, 1, - Who Is An Insured, is amended to add: d. Any person or organization to whom you become obligated to include as an additional insured under this policy, as a result of any contract or agreement you enter into which requires you to furnish insurance to that person or organization of the type provided by this policy, but only with respect to liability arising out of your operations or premises owned by or rented to you. However, the insurance provided will not exceed the lesser of: 1. The coverage and/or limits of this policy, or 2. The coverage and/or limits required by said contract or agreement. 61713(12/94) EPRESENTATIVE THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ENDORSEMENT # This endorsement, effective 12:01 A.M. forms a part of Policy No. issued to Atlas-Allied Inc By National Union Fire Ins Co of PA WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US This endorsement modifies insurance provided under the /of/ow/ng: BUSINESS AUTO COVERAGE FORM Section IV - Business Auto Conditions, A. - Loss Conditions, 5. - Transfer of Rights of Recovery Against Others to Us, is amended to add: However, we will waive any right of recovery we have against any person or organization with whom you have entered into a contract or agreement because of payments we make under this Coverage Form arising out of an "accident" or "loss" if: (1) The "accident" or "loss" is due to operations undertaken in accordance with the contract existing between you and such person or organization; and (2) The contract or agreement was entered into prior to any "accident" or "loss". No waiver of the right of recovery will directly or indirectly apply to your employees or employees of the person or organization, and we reserve our rights or lien to be reimbursed from any recovered funds obtained by any injured employee. /AUTHORIZEtHWWESENTATIVE 62897 (6/95) WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 04 03 06 WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT CALIFORNIA We have the right to recover our payments from anyone liable for an Injury covered by this policy. We will not enforce our right against the person(s) or organization (s) named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the work described in the Schedule. The additional premium for this endorsement shall be 2% of the California Workers' Compensation premium otherwise due on such remuneration. SCHEDULE PERSON OR ORGANIZATION JOB DESCRIPTION ANY PERSON OR ORGANIZATION FOR WHOM THE NAMED INSURED HAS AGREED BY WRITTEN CONTRACT TO FURNISH THIS WAIVER BLANKET WAIVER OF SUBROGATION This endorsement changes the policy to which is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective 11/01/08 Policy No.7600000261081 Insured ATLAS-ALLIED, INC Insurance Company EVEREST NATIONAL INSURANCE COMPANY Countersigned by Endorsement No. 001 Premium $ INC BIDDER'S STATEMENT RE DEBARMENT (To Accompany Proposal) INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 1) Have you or any of your subcontractors ever been debarred as an irresponsible bidder by another jurisdiction in the State of California? yes XXX no 2) If yes, what was/were the name(s) of the agency(ies) and what was/were the period(s) of debarment(s)? Attach additional copies of this page to accommodate more than two debar- ments. party debarred party debarred agency agency period of debarment period of debarment BY CONTRACTOR: Atlas-Allied. Inc. (name of Contractor) By:_ /_ (sign hei Catherine Sturge orp. Secertarv (print name/title) Page J of J pages of thjs Re pebarment form Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 28 of 139 Pages BIDDER'S DISCLOSURE OF DISCIPLINE RECORD (To Accompany Proposal) INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 Contractors are required by law to be licensed and regulated by the Contractors' State License gsgncj which hi§ jyri§dj§tj§n 10 inygstigate complaints ggiinst contragtors if a complaint regarding 9 patent act or omission is filed within four years of the date of the alleged violation. A complaint regarding a latent act or omission pertaining to structural defects must be filed within 10 years of the date of the alleged violation. Any questions concerning a contractor may be referred to the Registrar, Contractors' State License board, P.O. Box 26000, Sacramento, California 95826. 1) Haye you ever had your contractor's license suspended or revoked by the California Contractors' State license Board two or more times within an eight year period? XXX yes no 2) Has the suspension or revocation of your contractor's license ever been stayed? XXX yes no 3) Have any subcontractors that you propose to perform any portion of the Work ever had their contractor's license suspended or revoked by the California Contractors' State license Board .two or more times within an eight year period? yes 4) Has the suspension or revocation of the license of any subcontractor's that you propose to perform any portion of the Work ever been stayed? XXX yes no 5) If the answer to either of 1. or 3. above is yes fully identify, in each and every case, the party disciplined, the date of and violation that the disciplinary action pertain to, describe the nature of the violation and the disciplinary action taken therefore. N/A (If needed attach additional sheets to provide full disclosure.) Page 1 of 1 pages of this Disclosure of Discipline form Revised 5/01/08 Contract No. 52011 {Industrial Parfc RW Service Lines) Page 29 of 139 Pages BIDDER'S DISCLOSURE OF DISCIPLINE RECORD (CONTINUED) (To Accompany Proposal) INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 6) If the answer to either of 2. or 4. above is yes fully identify, in each and every case, the party who's discipline was stayed, the date of the violation that the disciplinary action pertains to, describe the nature of the violation and the condition (if any) upon which the disciplinary action was stayed. (If needed attach additional sheets to provide full disclosure.) BY CONTRACTOR: Atlas-Allied, Inc. (name of Contractor) Catherin Stureon Cor Secertar (print name/title) Page J of _j pages pf this Qj§cjQ,§Hre sf Pi§siplin§ f<?rm Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 30 of 139 Pages NON-COLLUSION AFFIDAVIT TO BE EXECUTED BY BIDDER AND SUBMITTED WITH BID PUBLIC CONTRACT CODE SECTION 7106 INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 State of California ) )ss. County of Orange ) Catherine Struaeon , being first duly sworn, deposes (Name of Bidder) and says that he or she is Corp. Secretary (Title) of Atlas-Allied. Inc. (Name of Firm) the party making the foregoing bid that the bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation; that the bid is genuine and not collusive or sham; that the bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid, and has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or that anyone shall refrain from bidding; that the bidder has riot in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to fix any overhead, profit, or cost element of the bid price, or of that of any other bidder, or to secure any advantage against the public body awarding the contract of anyone interested in the proposed contract; that all statements contained in the bid are true; and, further, that the bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged inforrnatipn or data relative thereto, or paid, and will not pay, any fee to any corporation, partnership, company association, organization, bid depository, or to any member or agent thereof to effectuate a collusive or sham bid. I declare under penalty of perjury that the foregoing is true and correct and that this affidavit was executed on the 29 day of June , 20 09 . Subscribed and sworn to before me on the 29 day of June , 2009 . (NOTARY SEAL) Please See Attached Signature of Notary Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 31 of 139 Pages JURAT State of California County of Orange Subscribed and sworn to (or affirmed) before me on this 29th day of June. 2009. by Catherine Sturgeon proved to me on the basis of satisfactory evidence to be the person(s) who appeared before me. NILE SENSABAUGH * 1800039 Notify PuWlc . CtMfontti I Orang* County = Signature ' (Seal) Nile Sensabaugh, Notary Public of Carlsbad Public Works - Contract Administration June 12, 2009 ADDENDUM NO. 1 RE: INDUSTRIAL PARK RECYCLED WATER SERVICE LINES BID NO. PWS09-28ENG, CONTRACT NO. 52011 Please include the attached addendum in the Notice to Bidder/Request for Bids you have for the above project. This addendum-receipt acknowledged-must be attached to your Request for Bid when your bid is submitted. RHONDA HEATHER Associate Contract Administrator Attachment I ACKNOWLEDGE RECEIPT OF ADDENDUM NO. 1 Bidder's Signature 1635 Faraday Avenue • Carlsbad, CA 92008-7314 - (76O) 6O2-4677 • FAX (760) 6O2-8562 CARLSBAD MUNICIPAL WATER DISTRICT INDUSTRIAL PARK RECYCLED WATER SERVICE LINES Contract Nos. 52011 Addendum No. 1 From: David Ahles, Project Manager Phone: (760)602-2748 Fax: (760) 602-8562 No. of Pages: 1 (including this page) Date: June 10, 2009 Bid Opening Date: June 30, 2009 2:00 pm (No Change) A. CONTRACTOR'S PROPOSAL SCHEDULE "A", (Page 13 of 117), Change the following: Item A-11 Description shall be "Construction of two 2-inch RW services (No. 10 & 16, Sheet 12) per CMWD Std. Dwg. W4 including microtunnel under median and all related work at (Price in Words)". (A new bid schedule is attached to this addendum and must be submitted as part of the bid). B. DRAWINGS Location Map (Sheet 2 of 15), Add the following: Service line No. 16 added to the Location Map and List of service lines. (A new sheet 2 is attached to this addendum). C. DRAWINGS El Camino Real - Plan and Profile (Sheet 12 of 15), Add the following: Service line No. 16 added to Plan and Profile. (A new sheet 12 is attached to this addendum). Contract No. 52011 Page 1 of 1 Pages Addendum No. 1 CARLSBAD MUNICIPAL WATER DISTRICT INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 CONTRACTOR'S PROPOSAL Board of Directors Carlsbad Municipal Water District 1200 Carlsbad Village Drive Carlsbad, California 92008 The undersigned declares he/she has carefully examined the location of the work, read the Notice Inviting Bids, examined the Plans, Specifications, General Provisions, Contract Documents, and addenda thereto, and hereby proposes to furnish all labor, materials, equipment, transportation, and services required to do all the work to complete Contract No. 52011 in accordance with the Plans, Specifications, General Provisions, Contract Documents, and addenda thereto and that he/she will take in full payment therefore the following unit prices for each item complete, to wit: SCHEDULE"A" Approximate Item Quantity Unit Price Total Amount No. Description And Unit (Figures) (Figures) A-1 Mobilization, demobilization, LS $ 6.000.00 $ 6.000.00 and preparatory work at a stipulated lump sum of Six Thousand Dollars (Stipulated Amount DO NOT CHANGE) A-2 Perform exploratory LS $ $_ excavations for underground utilities at (Price in Words) A-3 Sheeting, shoring, bracing for LS $_ the protection of trench and workers in excavations at (Price in Words) Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 - 19 of 139 Item No. Description Approximate Quantity And Unit Unit Price (Figures) Total Amount (Figures) A-4 Construction 1 -inch RW service (No. 1, Sheet 5) and all related work at LS $ (Price in Words) A-5 Construction two 2-inch RW service (No. 2&3, Sheet 6) per CMWD Std. Dwg. W4 including 2-inch PVC RW main, hot top connection and all related work at LS $ (Price in Words) A-6 Construction two 1 -inch RW services (No. 4 & 5, Sheet 7) per CMWD Std. Dwg. W3 including 4-inch PVC RW main, hot top connection with 4-inch gate valve and all related work at LS (Price in Words) A-7 Construction 2-inch RW services (No. 6, Sheet 8) per CMWD Std. Dwg. W4 and and all related work at LS $ (Price in Words) A-8 Construction 2-inch RW services (No. 7, Sheet 9) per CMWD Std. Dwg. W4 and all related work at LS $$_ (Price in Words) oRevised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 - 19 of 139 Item No. Description Approximate Quantity And Unit Unit Price (Figures) Total Amount (Figures) A-9 Construction 2-inch RW services (No. 8, Sheet 10) per CMWD Std. Dwg. W4 and all related work at LS $ (Price in Words) A-10 Construction 2-inch RW services (No. 9, Sheet 11) per CMWD Std. Dwg. W4 and all related work at LS (Price in Words) A-11 Construction two 2-inch RW services (No. 10 & 16, Sheet 12) per CMWD Std. Dwg. W4 including microtunnel under median and all related work at LS $ (Price in Words) A-12 Construction two 2-inch RW services (No. 11 & 12, Sheet 13) per CMWD Std. Dwg. W4 and all related work at LS $$_ (Price in Words) A-13 Construction 2-inch RW services (No. 13, Sheet 14) per CMWD Std. Dwg. W4 and all related work at LS $ (Price in Words) 0Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 - 19 of 139 Item No.Description Approximate Quantity Unit Price And Unit (Figures) Total Amount (Figures) A-14 Construction 2-inch RW LS $_ services (No. 14 & 15, Sheet 15) per CMWD Std. Dwg. W4 and remove two existing 2" IR service laterals and all related work at $_ (Price in Words) A-15 Provide all necessary and LS $_ required traffic control to perform construction in Bid Items A-1 through A-14 at (Price in Words) A-16 All other work to be done to complete the project but not specifically listed in Bid Item A-1 through A-15 at LS $_ (Price in Words) Total amount of bid in words for Schedule "A": Total amount of bid in numbers for Schedule "A": $ The basis of award will be the sum of Schedule "A". Price(s) given above are firm for 90 days after date of bid opening. Addendum(a) No(s)._ proposal. has/have been received and is/are included in this Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 - 19 of 139 The Undersigned has carefully checked all of the above figures and understands that the District will not be responsible for any error or omission on the part of the Undersigned in preparing this bid. The Undersigned agrees that in case of default in executing the required Contract with necessary bonds and insurance policies within twenty (20) days from the date of award of Contract by the Board of Directors of the Carlsbad Municipal Water District, the District may administratively authorize award of the contract to the second or third lowest bidder and the bid security of the lowest bidder may be forfeited. The Undersigned bidder declares, under penalty of perjury, that the undersigned is licensed to do business or act in the capacity of a contractor within the State of California, validly licensed under license number , classification which expires on , and that this statement is true and correct and has the legal effect of an affidavit. A bid submitted to the District by a Contractor who is not licensed as a contractor pursuant to the Business and Professions Code shall be considered nonresponsive and shall be rejected by the District § 7028.15(e). In all contracts where federal funds are involved, no bid submitted shall be invalidated by the failure of the bidder to be licensed in accordance with California law. However, at the time the contract is awarded, the contractor shall be properly licensed. The Undersigned bidder hereby represents as follows: 1. That no Board member, officer agent, or employee of the City of Carlsbad is personally interested, directly or indirectly, in this Contract, or the compensation to be paid hereunder; that no representation, oral or in writing, of the Board of Directors, its officers, agents, or employees has inducted him/her to enter into this Contract, excepting only those contained in this form of Contract and the papers made a part hereof by its terms; and 2. That this bid is made without connection with any person, firm, or corporation making a bid for the same work, and is in all respects fair and without collusion or fraud. Accompanying this proposal is (Cash, Certified Check, Bond or Cashier's Check) for ten percent (10%) of the amount bid. The Undersigned is aware of the provisions of section 3700 of the Labor Code which requires every employer to be insured against liability for workers' compensation or to undertake self-insurance in accordance with the provisions of that code, and agrees to comply with such provisions before commencing the performance of the work of this Contract and continue to comply until the contract is complete. The Undersigned is aware of the provisions of the Labor Code, Part 7, Chapter 1, Article 2, relative to the general prevailing rate of wages for each craft or type of worker needed to execute the Contract and agrees to comply with its provisions. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 - 19 of 139 IF A SOLE OWNER OR SOLE CONTRACTOR SIGN HERE: (1) Name under which business is conducted (2) Signature (given and surname) of proprietor (3) Place of Business (Street and Number) City and State (4) Zip Code Telephone No. (5) E-Mail IF A PARTNERSHIP. SIGN HERE: (1) Name under which business is conducted. (2) Signature (given and surname and character of partner) (Note: Signature must be made by a general partner) (3) Place of Business (Street and Number) City and State (4) Zip Code Telephone No. (5) E-Mail A•K Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 - 19 of 139 IF A CORPORATION. SIGN HERE: (1) Name under which business is conducted (2), (Signature) (Title) Impress Corporate Seal here (3) Incorporated under the laws of the State of (4) Place of Business , (Street and Number) City and State (5) Zip Code Telephone No. (6) E-Mail NOTARIAL ACKNOWLEDGMENT OF EXECUTION BY ALL SIGNATORIES MUST BE ATTACHED m^ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12 - 19 of 139 List below names of president, vice president, secretary and assistant secretary, if a corporation; if a partnership, list names of all general partners, and managing partners: Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Addendum No. 1 Replaces Page 12-19 of 139 CONTRACT PUBLIC WORKS This agreement is made this ^ day of ttM^£yvL4J[ , 20 Of by and between the Carlsbad Municipal Water District of the Cit/of Carlsbad, California, a municipal corporation, (hereinafter called "District"), and Atlas Allied, Inc., whose principal place of business is 1210 N. Las Brisas Anaheim CA 92806 (hereinafter called "Contractor"). District and Contractor agree as follows: 1. Description of Work. Contractor shall perform all work specified in the Contract documents for: INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 (hereinafter called "project") 2. Provisions of Labor and Materials. Contractor shall provide all labor, materials, tools, equipment, and personnel to perform the work specified by the Contract Documents. 3. Contract Documents. The Contract Documents consist of this Contract, Notice Inviting Bids, Contractor's Proposal, Bidder's Bond, Non-Collusion Affidavit, Designation of Subcontractors, Technical Ability and Experience, Bidder's Statement Re Debarment, Escrow Agreement, Release Form, the Plans and Specifications, the General Provisions, addendum(s) to said Plans and Specifications and General Provisions, and all proper amendments and changes made thereto in accordance with this Contract or the Plans and Specifications, and all bonds for the project; all of which are incorporated herein by this reference. Contractor, her/his subcontractors, and materials suppliers shall provide and install the work as indicated, specified, and implied by the Contract Documents. Any items of work not indicated or specified, but which are essential to the completion of the work, shall be provided at the Contractor's expense to fulfill the intent of said documents. In all instances through the life of the Contract, the District will be the interpreter of the intent of the Contract Documents, and the District's decision relative to said intent will be final and binding. Failure of the Contractor to apprise subcontractors and materials suppliers of this condition of the Contract will not relieve responsibility of compliance. 4. Payment. For all compensation for Contractor's performance of work under this Contract, District shall make payment to the Contractor per section 9-3 PAYMENT of the General Provisions section of this contract. The Engineer will close the estimate of work completed for progress payments on the last working day of each month. The District shall withhold retention as required by Public Contract Code Section 9203. m¥ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 32 of 139 Pages 5. Independent Investigation. Contractor has made an independent investigation of the jobsite, the soil conditions at the jobsite, and all other conditions that might affect the progress of the work, and is aware of those conditions. The Contract price includes payment for all work that may be done by Contractor, whether anticipated or not, in order to overcome underground conditions. Any information that may have been furnished to Contractor by District about underground conditions or other job conditions is for Contractor's convenience only, and District does not warrant that the conditions are as thus indicated. Contractor is satisfied with all job conditions, including underground conditions and has not relied on information furnished by District. 6. Hazardous Waste or Other Unusual Conditions. If the contract involves digging trenches or other excavations that extend deeper than four feet below the surface Contractor shall promptly, and before the following conditions are disturbed, notify District, in writing, of any: A. Hazardous Waste. Material that Contractor believes may be material that is hazardous waste, as defined in section 25117 of the Health and Safety Code, that is required to be removed to a Class I, Class II, or Class III disposal site in accordance with provisions of existing law. B. Differing Conditions. Subsurface or latent physical conditions at the site differing from those indicated. C. Unknown Physical Conditions. Unknown physical conditions at the site of any unusual nature, different materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the contract. District shall promptly investigate the conditions, and if it finds that the conditions do materially so differ, or do involve hazardous waste, and cause a decrease or increase in contractor's costs of, or the time required for, performance of any part of the work shall issue a change order under the procedures described in this contract. In the event that a dispute arises between District and Contractor whether the conditions materially differ, or involve hazardous waste, or cause a decrease or increase in the contractor's cost of, or time required for, performance of any part of the work, contractor shall not be excused from any scheduled completion date provided for by the contract, but shall proceed with all work to be performed under the contract. Contractor shall retain any and all rights provided either by contract or by law which pertain to the resolution of disputes and protests between the contracting parties. 7. Immigration Reform and Control Act. Contractor certifies it is aware of the requirements of the Immigration Reform and Control Act of 1986 (8 USC sections 1101-1525) and has complied and will comply with these requirements, including, but not limited to, verifying the eligibility for employment of all agents, employees, subcontractors, and consultants that are included in this Contract. 8. Prevailing Wage. Pursuant to the California Labor Code, the director of the Department of Industrial Relations has determined the general prevailing rate of per diem wages in accordance with California Labor Code, section 1773 and a copy of a schedule of said general prevailing wage rates is on file in the office of the City Engineer, and is incorporated by reference herein. Pursuant to California Labor Code, section 1775, Contractor shall pay prevailing wages. Contractor shall post copies of all applicable prevailing wages on the job site. Revised 5/01/08 Contract No. 5201 1 (Industrial Park RW Service Lines)Page 33 of 139 Pages 9. Indemnification. Contractor shall assume the defense of, pay all expenses of defense, and indemnify and hold harmless the District, and its officers and employees, from all claims, loss, damage, injury and liability of every kind, nature and description, directly or indirectly arising from or in connection with the performance of the Contract or work; or from any failure or alleged failure of Contractor to comply with any applicable law, rules or regulations including those relating to safety and health; and from any and all claims, loss, damages, injury and liability, howsoever the same may be caused, resulting directly or indirectly from the nature of the work covered by the Contract, except for loss or damage caused by the sole or active negligence or willful misconduct of the District. The expenses of defense include all costs and expenses including attorneys' fees for litigation, arbitration, or other dispute resolution method. Contractor shall also defend and indemnify the District against any challenges to the award of the contract to Contractor, and Contractor will pay all costs, including defense costs for the District. Defense costs include the cost of separate counsel for District, if District requests separate counsel. Contractor shall also defend and indemnify the District against any challenges to the award of the contract to Contractor, arising in whole or in part from alleged inaccuracies or misrepresentation by the Contractor, whether intentional or otherwise, and Contractor will pay all costs, including defense costs for the District. Defense costs include the cost of separate counsel for District, if District requests separate counsel. 10. Insurance. Contractor shall procure and maintain for the duration of the contract insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his or her agents, representatives, employees or subcontractors. Said insurance shall meet the City of Carlsbad's policy for insurance as stated in City Council Policy # 70. (A) Coverages And Limits Contractor shall maintain the types of coverages and minimum limits indicted herein: a. Commercial General Liability Insurance: $1,000,000 combined single limit per occurrence for bodily injury and property damage. If the policy has an aggregate limit, a separate aggregate in the amounts specified shall be established for the risks for which the District or its agents, officers or employees are additional insured. b. Business Automobile Liability Insurance: $1,000,000 combined single limit per accident for bodily injury and property damage. In addition, the auto policy must cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. c. Workers' Compensation and Employers' Liability Insurance: Workers' compensation limits as required by the Labor Code of the State of California. Workers' compensation offered by the State Compensation Insurance Fund is acceptable to the District. (B) Additional Provisions: Contractor shall ensure that the policies of insurance required under this agreement with the exception of Workers' Compensation and Business Automobile Liability Insurance contain, or are endorsed to contain, the following provisions. a. The District, its officials, employees and volunteers are to be covered as additional insured as respects: liability arising out of activities performed by or on behalf of the Contractor; products and completed operations of the contractor; premises owned, leased, hired or borrowed by the contractor. The coverage shall contain no special limitations on the scope of protection afforded to the District, its officials, employees or volunteers. All additional insured endorsements must be evidenced using separate documents attached to the certificate of insurance; one for each company affording general liability, and employers' liability coverage. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 34 of 139 Pages b. The Contractor's insurance coverage shall be primary insurance as respects the District, its officials, employees and volunteers. Any insurance or self-insurance maintained by the District, its officials, employees or volunteers shall be in excess of the contractor's insurance and shall not contribute with it. c. Any failure to comply with reporting provisions of the policies shall not affect coverage provided to the District, its officials, employees or volunteers. d. Coverage shall state that the contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. (C) Notice Of Cancellation. Each insurance policy required by this agreement shall be endorsed to state that coverage shall not be nonrenewed, suspended, voided, canceled, or reduced in coverage or limits except after ten (10) days' prior written notice has been sent to the District by certified mail, return receipt requested. (D) Deductibles And Self-Insured Retention (S.I.R.) Levels. Any deductibles or self-insured retention levels must be declared to and approved by the District. At the option of the District, either: the insurer shall reduce or eliminate such deductibles or self-insured retention levels as respects the District, its officials and employees; or the contractor shall procure a bond guaranteeing payment of losses and related investigation, claim administration and defense expenses. (E) Waiver Of Subrogation. All policies of insurance required under this agreement shall contain a waiver of all rights of subrogation the insurer may have or may acquire against the District or any of its officials or employees. (F) Subcontractors. Contractor shall include all subcontractors as insured under its policies or shall furnish separate certificates and endorsements for each subcontractor. Coverages for subcontractors shall be subject to all of the requirements stated herein. (G) Acceptability Of Insurers. Insurance is to be placed with insurers that have a rating in Best's Key Rating Guide of at least A-:VII. Insurers must also be authorized to transact the business of insurance by the State of California Insurance Commissioner as admitted carriers as evidenced by a listing in the official publication of the Department of Insurance of the State of California and/or under the standards specified by City Council Policy # 70. (H) Verification Of Coverage. Contractor shall furnish the District with certificates of insurance and original endorsements affecting coverage required by this clause. The certificates and endorsements for each insurance policy are to be signed by a person authorized by that insurer to bind coverage on its behalf. The certificates and endorsements are to be in forms approved by the District and are to be received and approved by the District before the Contract is executed by the District. (I) Cost Of Insurance. The Cost of all insurance required under this agreement shall be included in the Contractor's bid. 11. Claims and Lawsuits. All claims by contractor for $375,000 or less shall be resolved in accordance with the provisions in the Public Contract Code, Division 2, Part 3, Chapter 1, Article 1.5 (commencing with section 20104) which are incorporated by reference. A copy of Article 1.5 is included in Section 3 of the General Provisions. The contractor shall initially submit all claims over $375,000 to the City using the informal dispute resolution process described in Public Contract Code subsections 20104.2(a), (c), (d). Notwithstanding the provisions of this section of the contract, all claims shall comply with the Government Tort Claim Act (section 900 et seq., of the California Government Code) for any claim or cause of action for money or damages prior to filing any lawsuit for breach of this agreement. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 35 of 139 Pages (A) Assertion of Claims. Contractor hereby agrees that any contract claim submitted to the District must be asserted as part of the contract process as set forth in this agreement and not in anticipation of litigation or in conjunction with litigation. (B) False Claims. Contractor acknowledges that if a false claim is submitted to the District, it may be considered fraud and the Contractor may be subject to criminal prosecution. (C) Government Code. Contractor acknowledges that California Government Code sections 12650 et seq., the False Claims Act, provides for civil penalties where a person knowingly submits a false claim to a public entity. These provisions include false claims made with deliberate ignorance of the false information or in reckless disregard of the truth or falsity of the information. (D) Penalty Recovery. If the Carlsbad Municipal Water District seeks to recover penalties pursuant to the False Claims Act, it is entitled to recover its litigation costs, including attorney's fees. (E) Debarment for False Claims. Contractor hereby acknowledges that the filing of a false claim may subject the Contractor to an administrative debarment proceeding wherein the Contractor may be prevented from further bidding on public contracts for a period of up to five years. (F) Carlsbad Municipal Code. The provisions of Carlsbad Municipal Code sections 3.32.025, 3.32.026, 3.32.027 and 3.32.028 pertaining to false claims are incorporated herein by reference. (G) Debarment from Other Jurisdictions. Contractor hereby acknowledges that debarment by another jurisdiction is grounds for the Board of Directors of the Carlsbad Municipal Water District of the City of Carlsbad to disqualify the Contractor or subcontractor from participating in future contract bidding. (H) Jurisdiction. Contractor agrees and hereby stipulates that the proper venue and jurisdiction for resolution of any disputes between the parties arising out of this agreement is San Diego County, California. I have read and understand all provisions of Section 11 above, 12. Maintenance of Records. Contractor shall maintain and make available at no cost to the District, upon request, records in accordance with sections 1776 and 1812 of Part 7, Chapter 1, Article 2, of the Labor Code. If the Contractor does not maintain the records at Contractor's principal place of business as specified above, Contractor shall so inform the District by certified letter accompanying the return of this Contract. Contractor shall notify the District by certified mail of any change of address of such records. 13. Labor Code Provisions. The provisions of Part 7, Chapter 1, commencing with section 1720 of the Labor Code are incorporated herein by reference. 14. Security. Securities in the form of cash, cashier's check, or certified check may be substituted for any monies withheld by the District to secure performance of this contract for any obligation established by this contract. Any other security that is mutually agreed to by the Contractor and the District may be substituted for monies withheld to ensure performance under this Contract. A•^ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 36 of 139 Pages 15. Unfair Business Practices. In entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or subcontractor offers and agrees to assign to the awarding body all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec. 15) or under the Cartwright Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or the subcontract. This assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment by the parties. 16. Provisions Required by Law Deemed Inserted. Each and every provision of law and clause required by law to be inserted in this Contract shall be deemed to be inserted herein and included herein, and if, through mistake or otherwise, any such provision is not inserted, or is not correctly inserted, then upon application of either party, the Contract shall forthwith be physically amended to make such insertion or correction. 17. Additional Provisions. Any additional provisions of this agreement are set forth in the "General Provisions" or "Supplemental Provisions" attached hereto and made a part hereof. NOTARIAL ACKNOWLEDGMENT OF EXECUTION BY ALL SIGNATORIES MUST BE ATTACHED (CORPORATE SEAL) CONTRACTOR: Atlas-Allied, Inc. (name of Contractor) CAR muni By: MUN/jfclPflL WATER^EflSTRICT, a the Stated California By:• Cxm. (sign here) Eva Sicilian! Vice President (print name and title) Catherine sturgeon Corporate Secretary (print name and title) President or vice-president and secretary or assistant secretary must sign for w«.Kw.«»«,«,,,,1,^., one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under the corporate seal empowering that officer to bind the corporation. APPROVED AS TO FORM: RONALD R. BALL General Counsel Deputy General Couns Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 37 of 139 Pages ACKNOWLEDGMENT State of California County of Orange On August 11, 2009 before me,Nile Sensabaugh. Notary Public Catherine Sturgeonpersonally appeared who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that she executed the same in her authorized capacity, and that by her signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature Nile Sensabaugh, Notary Public NILE SENSABAUGH * Commission * 1600039 K Notary Public • California I Orange County = My Comrn. Expires Jun 1.20121 (Seal) State of California County of Orange ACKNOWLEDGMENT On August 11 7009 _before me, _ Eva Siciliani Nile Sensabaugh. Notary Public personally appeared who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that she executed the same in her authorized capacity, and that by her signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. NILE SENSABAUGH* Conwrtaaion * 1800039 Notary PuWte. California f Oranga County 2 [Cornm. ExpireaJuni Signature Nile Sensabaugh, Notary Public (Seal) Bond Number: 6579575 Premium: INCLUDED LABOR AND MATERIALS BOND Board of Directors of the Carlsbad Municipal Water District located in the State of California, by Resolution No. 691, adopted August 4, 2009, has awarded to Atlas Allied, Inc. (hereinafter designated as the "Principal"), a Contract for: INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 in the City of Carlsbad, in strict conformity with the drawings and specifications, and other Contract Documents now on file in the Office of the Secretary of the Carlsbad Municipal Water District and all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond, providing that if Principal or any of their subcontractors shall fail to pay for any materials, provisions, provender or other supplies or teams used in, upon or about the performance of the work agreed to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same to the extent hereinafter set forth. NOW, THEREFORE, WE, ATLAS ALLIED, INC., as Principal, (hereinafter designated as the "Contractor"), and First National Insurance Company of America as Surety, are held firmly bound unto the Carlsbad Municipal Water District in the sum of One Hundred Fifty Nine Thousand Five Hundred Dollars ($159,500), said sum being an amount equal to: One hundred percent (100%) of the total amount payable under the terms of the contract by the Carlsbad Municipal Water District, and for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the Contractor or his/her subcontractors fail to pay for any materials, provisions, provender, supplies, or teams used in, upon, for, or about the performance of the work contracted to be done, or for any other work or labor thereon of any kind, consistent with California Civil Code section 3181, or for amounts due under the Unemployment Insurance Code with respect to the work or labor performed under this Contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Development Department from the wages of employees of the contractor and subcontractors pursuant to section 13020 of the Unemployment Insurance Code with respect to the work and labor, that the Surety will pay for the same, and, also, in case suit is brought upon the bond, reasonable attorney's fees, to be fixed by the court consistent with California Civil Code section 3248. This bond shall inure to the benefit of any of the persons named in California Civil Code section 3181, so as to give a right of action to those persons or their assigns in any suit brought upon the bond. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed hereunder or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications. A•^ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 38 of 139 Pages In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. Executed by CONTRACTOR this llth day of A"gust 2009 Executed by SURETY this. of August 11th day _,2009 CONTRACTOR: Atlas-Allied, Inc. (name of Contractor) By: C*n>v (sign here) SURETY: First National Insurance Company of America (name of Surety) 120 Vantis, 3rd Floor, Aliso Viejo, CA 92656 (address of Surety) Eva Siciliani (print name here) Vice President/Treasurer (title and organization of signatory) (949) 860-6611 (telepl By:l By:. mber orf Surety) Gatherine Sturgeon v fsignararfe of Atorr»%-in-Fact) Adriana Valenzuela (printed name of Attorney-in-Fact) (attach corporate resolution showing current power of attorney)(print name here) Corp Secretary (title and organization of signatory) (Proper notarial acknowledgment of execution by CONTRACTOR and SURETY must be attached.) (President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under corporate seal empowering that officer to bind the corporation.) APPROVED AS TO FORM: RONALD R. BALL General Counsel By: Deputy General Counsel Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 39 of 139 Pages ACKNOWLEDGMENT State of California County of Orange On August 11 9009 before me, Nile Sensabauqh. Notary Public personally appeared Eva Sicilian! , who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that she executed the same in her authorized capacity, and that by her signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. NILE SENSABAUGH > „____ Commission # 1800039 IWITNESS my hand and official seal. Il6*j3w Noury Public • California | v&&*W7 Orang* County * My Comm. Expires Jun 1,20121 Signature ^<>^ (Seal) Nile Sensabaugh, Notary Public ACKNOWLEDGMENT State of California County of Orange On August 11. 2009 before me,Nile Sensabaugh. Notary Public Catherine Sturgeonpersonally appeared who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that she executed the same in her authorized capacity, and that by her signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature Nile Sensabaugh, Notary Public NILE SENSABAUGH f CommiMion * 1800039 I I (Seal) ACKNOWLEDGMENT State of California County of Orange On August 11, 2009 before me, Susan Ponsell, Notary Public (insert name and title of the officer) Adriana Valenzuelapersonally appeared _ who proved to me on the basis of satisfactory evidence to be the personj^Twhose namejp} is/ate subscribed to the within instrument and acknowledged to me that>e/she/JU=t6y executed the same in Jjis/her/tbefr authorized capacity(ies^ and that byJa+sTher/Jbelf signature^sfon the instrument the entity upon behalf of which the persor>(«f acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature A A AA A A A A '. AAAAAAAAA, SUSAN PONSELL f- COMM. # 1734814 ^ NOTARY PUBLIC - CALIFORNIA p ORANGE COUNTY ->. My Commission Expires March 27.2011 k (Seal) Liberty Mutual, r>/~>\A;iroKOWtK OF ATTORNEY First National Insurance Company of America 1001 4th Avenue Suite 1700 KNOW ALL BY THESE PRESENTS:No- 132Q1 That FIRST NATIONAL INSURANCE COMPANY OF AMERICA, a Washington corporation, does hereby appoint **,*»***»*»****»LOURDES LANDA. MARK ROSSKOPF; ADRIANA VALENZUELA; Fullerton, CA*********** its true and lawful attorney(s)-in-fact, with full authority to execute on behalf of the company fidelity and surety bonds or undertakings and other documents of a similar character issued by the company in the course of its business, and to bind FIRST NATIONAL INSURANCE COMPANY OF AMERICA thereby as fully as if such instruments had been duly executed by its regularly elected officers at its home office. IN WITNESS WHEREOF, FIRST NATIONAL INSURANCE COMPANY OF AMERICA has executed and attested these presents this Dexter R. Legg, Secretary 21st day of March 2009 Timothy A. Mikolajewski, Vice President CERTIFICATE Extract from the By-Laws of FIRST NATIONAL INSURANCE COMPANY OF AMERICA: "Article V, Section 13. - FIDELITY AND SURETY BONDS ... the President, any Vice President, the Secretary, and any Assistant Vice President appointed for that purpose by the officer in charge of surety operations, shall each have authority to appoint individuals as attorneys-in-fact or under other appropriate titles with authority to execute on behalf of the company fidelity and surety bonds and other documents of similar character issued by the company in the course of its business... On any instrument making or evidencing such appointment, the signatures may be affixed by facsimile. On any instrument conferring such authority or on any bond or undertaking of the company, the seal, or a facsimile thereof, may be impressed or affixed or in any other manner reproduced; provided, however, that the seal shall not be necessary to the validity of any such instrument or undertaking." Extract from a Resolution of the Board of Directors of FIRST NATIONAL INSURANCE COMPANY OF AMERICA adopted July 28, 1970. "On any certificate executed by the Secretary or an assistant secretary of the Company setting out, (i) The provisions of Article V, Section 1 3 of the By-Laws, and (ii) A copy of the power-of-attorney appointment, executed pursuant thereto, and (iii) Certifying that said power-of-attorney appointment is in full force and effect, the signature of the certifying officer may be by facsimile, and the seal of the Company may be a facsimile thereof." I, Dexter R. Legg , Secretary of FIRST NATIONAL INSURANCE COMPANY OF AMERICA, do hereby certify that the foregoing extracts of the By-Laws and of a Resolution of the Board of Directors of this corporation, and of a Power of Attorney issued pursuant thereto, are true and correct, and that both the By-Laws, the Resolution and the Power of Attorney are still in full force and effect. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the facsimile seal of said corporation AUG 112009thisday of S-1049/DF3/09 Dexter R. Legg, Secretary WEB PDF Bond Number: 6579575 Premium: $2,297.00 FAITHFUL PERFORMANCE/WARRANTY BOND Board of Directors of the Carlsbad Municipal Water District located in the State of California, by Resolution No. 691, adopted August 4, 2009, has awarded to Atlas Allied, Inc. (hereinafter designated as the "Principal"), a Contract for: INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 in the City of Carlsbad, in strict conformity with the contract, the drawings and specifications, and other Contract Documents now on file in the Office of the Secretary of the Carlsbad Municipal Water District, all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond for the faithful performance and warranty of said Contract; NOW, THEREFORE, WE, ATLAS ALLIED, INC., as Principal, (hereinafter designated as the "Contractor"), and First National Insurance Company of America ^_ as Surety, are held firmly bound unto the Carlsbad Municipal Water District in the sum of One Hundred Fifty Nine Thousand Five Hundred Dollars ($159,500), said sum being an amount equal to: One hundred percent (100%) of the total amount payable under the terms of the contract by the Carlsbad Municipal Water District, and for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the above bounden Contractor, their heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions, and agreements in the Contract and any alteration thereof made as therein provided on their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the Carlsbad Municipal Water District, its officers, employees and agents, as therein stipulated, then this obligation shall become null and void; otherwise it shall remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by the District in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed there under or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 40 of 139 Pages In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. Executed by CONTRACTOR this llth day of August 20 °9 . CONTRACTOR: Atlas-Allied, Inc. By: (name of Contractor) UJU (sign here) Eva Siciliani (print name here) Vice President/Treasurer (Title and Organization of Signatory) By: Catherine Sturgeon (print name here) Corp Secretary (Title and Organization of signatory) Executed by SURETY this nth day of August , 20 09 SURETY: First National Insurance Company of America (name of Surety) 120 Vantis, 3rd Floor, Aliso Viejo, CA 92656 (address of Surety) (9^9) 860-6612 (telephone number of Surety) By: V (sigTTature of Attomey-irvFact) Adriana Valenzuela (printed name of Attorney-in-Fact) (Attach corporate resolution showing current power of attorney.) (Proper notarial acknowledgment of execution by CONTRACTOR and SURETY must be attached.) (President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under corporate seal empowering that officer to bind the corporation.) APPROVED AS TO FORM: RONALD R. BALL General Counsel Bv: Deputy General Counsel Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 41 of 139 Pages ACKNOWLEDGMENT State of California County of Orange On August 11, 2009 before me,Nile Sensabaugh. Notary Public Catherine Sturgeonpersonally appeared who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that she executed the same in her authorized capacity, and that by her signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature Nile Sensabaugh, Notary Public NILE SENSABAUGH Commission * 1600039 Notary Public - California | Orwioj County ~ My Comm. Expires Jun 1.2012^ (Seal) ACKNOWLEDGMENT State of California County of Orange On August 11. 2009 before me, Nile Sensabaugh, Notary Public personally appeared Eva Siciliani , who proved to me on the basis of satisfactory evidence to be the person whose name is subscribed to the within instrument and acknowledged to me that she executed the same in her authorized capacity, and that by her signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. INILE SENSABAUGH WITNESS my hand and official seal. l/g^ SS^^SSSL | Orange County £Comm. Expires Jim 1.2012 E Signature ^^-^ (Seal) Nile Sensabaugh, Notary Public ACKNOWLEDGMENT State of California County of Orange On August 11, 2009 before me, Susan Ponsell, Notary Public (insert name and title of the officer) Adriana Valenzuelapersonally appeared who proved to me on the basis of satisfactory evidence to be the persor>(sf whose name^sT is/are subscribed to the within instrument and acknowledged to me that JreTshe/the'y executed the same in JjtsTher/thjerf'authorized capacity(je€)7and that by bis/her/thelf signature^®) on the instrument the personj^Tor the entity upon behalf of which the person(stticted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature SUSAN PONSELL *• COMM. # 1734814 !p NOTARY PUBLIC -CALIFORNIA p ORANGE COUNTY ->• My Commission Expires March 27,2011 Y (Seal) Liberty POWEROF ATTORNEY First National Insurance Company of America 1001 4th Avenue Suite 1700 KNOW ALL BY THESE PRESENTS:No- 132Q1 That FIRST NATIONAL INSURANCE COMPANY OF AMERICA, a Washington corporation, does hereby appoint ***»*»*********»LOURDES LANDA. MARK ROSSKOPF; ADRIANA VALENZUELA; Fullerton, CA*********** its true and lawful attorney(s)-in-fact, with full authority to execute on behalf of the company fidelity and surety bonds or undertakings and other documents of a similar character issued by the company in the course of its business, and to bind FIRST NATIONAL INSURANCE COMPANY OF AMERICA thereby as fully as if such instruments had been duly executed by its regularly elected officers at its home office. IN WITNESS WHEREOF, FIRST NATIONAL INSURANCE COMPANY OF AMERICA has executed and attested these presents this Dexter R. Legg, Secretary 21st day of March 2009 Timothy A. Mikolajewski, Vice President CERTIFICATE Extract from the By-Laws of FIRST NATIONAL INSURANCE COMPANY OF AMERICA: "Article V, Section 13. - FIDELITY AND SURETY BONDS ... the President, any Vice President, the Secretary, and any Assistant Vice President appointed for that purpose by the officer in charge of surety operations, shall each have authority to appoint individuals as attorneys-in-fact or under other appropriate titles with authority to execute on behalf of the company fidelity and surety bonds and other documents of similar character issued by the company in the course of its business... On any instrument making or evidencing such appointment, the signatures may be affixed by facsimile. On any instrument conferring such authority or on any bond or undertaking of the company, the seal, or a facsimile thereof, may be impressed or affixed or in any other manner reproduced; provided, however, that the seal shall not be necessary to the validity of any such instrument or undertaking." Extract from a Resolution of the Board of Directors of FIRST NATIONAL INSURANCE COMPANY OF AMERICA adopted July 28, 1970. "On any certificate executed by the Secretary or an assistant secretary of the Company setting out, (i) The provisions of Article V, Section 1 3 of the By-Laws, and (ii) A copy of the power-of-attorney appointment, executed pursuant thereto, and (iii) Certifying that said power-of-attorney appointment is in full force and effect, the signature of the certifying officer may be by facsimile, and the seal of the Company may be a facsimile thereof." I, Dexter R. Legg , Secretary of FIRST NATIONAL INSURANCE COMPANY OF AMERICA, do hereby certify that the foregoing extracts of the By-Laws and of a Resolution of the Board of Directors of this corporation, and of a Power of Attorney issued pursuant thereto, are true and correct, and that both the By-Laws, the Resolution and the Power of Attorney are still in full force and effect. IN WITNESS WHEREOF, I have hereunto set my hand and affixed the facsimile seal of said corporation AUG 1 1 2009thisday of S-1049/DF3/09 Dexter R. Legg, Secretary WEB PDF Escrow #23300 OPTIONAL ESCROW AGREEMENT FOR SECURITY DEPOSITS IN LIEU OF RETENTION This Escrow Agreement is made and entered into by and between the Carlsbad Municipal Water District whose address is 5950 El Camino Real, Carlsbad, California, 92008, hereinafter called "District" and _ Atlas-Allied Inc _ whose address isl?lO N. Ifis Brisas Stnapfr. Anafryyifl] fft Q7prft _ hereinafter called "Contractor" and Union BankjM^* ^ _ whose address is 1980 Saturn St . Monterey Park, CA 91755 _ hereinafter called "Escrow Agent." For the consideration hereinafter set forth, the District, Contractor and Escrow Agent agree as follows: 1. Pursuant to sections 22300 and 10263 of the Public Contract Code of the State of California, the Contractor has the option to deposit securities with the Escrow Agent as a substitute for retention earnings required to be withheld by the District pursuant to the Construction Contract entered into between the City and Contractor for INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 in the amount of $159,500.00 _ dated 08/05/09 (hereinafter referred to as the "Contract"). Alternatively, on written request of the Contractor, the District shall make payments of the retention earnings directly to the Escrow Agent. When the Contractor deposits the securities as a substitute for Contract earnings, the Escrow Agent shall notify the District within 10 days of the deposit. The Escrow Agent shall maintain insurance to cover negligent acts and omissions of the Escrow Agent in connection with the handling of retentions under these sections in an amount not less than $100,000 per contract. The market value of the securities at the time of the substitution shall be a least equal to the cash amount then required to be withheld as retention under the terms of the contract between the District and Contractor. Securities shall be held in the name of the District and shall designate the Contractor as the beneficial owner. 2. The District shall make progress payments to the Contractor for such funds which otherwise would be withheld from progress payments pursuant to the Contract provisions, provided that the Escrow Agent holds securities in the form and amount specified above. 3. When the District makes payment of retentions earned directly to the Escrow Agent, the Escrow Agent shall hold them for the benefit of the Contractor until such time as the escrow created under this contract is terminated. The Contractor may direct the investment of the payments into securities. All terms and conditions of this agreement and the rights and responsibilities of the parties shall be equally applicable and binding when the District pays the Escrow Agent directly. 4. The Contractor shall be responsible for paying all fees for the expenses incurred by the Escrow Agent in administering the Escrow Account and all expenses of the District. These expenses and payment terms shall be determined by the District, Contractor and Escrow Agent. 5. The interest earned on the securities or the money market accounts held in escrow and all interest earned on that interest shall be for the sole account of Contractor and shall be subject to withdrawal by Contractor at any time and from time to time without notice to the District. Am¥ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 42 of 139 Pages 6. Contractor shall have the right to withdraw all or any part of the principal in the Escrow Account only by written notice to Escrow Agent accompanied by written authorization from District to the Escrow Agent that the District consents to the withdrawal of the amount sought to be withdrawn by Contractor. 7. The District shall have a right to draw upon the securities in the event of default by the Contractor. Upon seven days' written notice to the Escrow Agent from the District of the default, the Escrow Agent shall immediately convert the securities to cash and shall distribute the cash as instructed by the District. 8. Upon receipt of written notification from the City certifying that the Contract is final and complete and that the Contractor has complied with all requirements and procedures applicable to the Contract, the Escrow Agent shall release to Contractor all securities and interest on deposit less escrow fees and charges of the Escrow Account. The escrow shall be closed immediately upon disbursement of all moneys and securities on deposit and payments of fees and charges. 9. The Escrow Agent shall rely on the written notifications from the District and the Contractor pursuant to sections (1) to (8), inclusive, of this agreement and the District and Contractor shall hold Escrow Agent harmless from Escrow Agent's release, conversion and disbursement of the securities and interest as set forth above. 10. The names of the persons who are authorized to give written notices or to receive written notice on behalf of the District and on behalf of Contractor in connection with the foregoing, and exemplars of their respective signatures are as follows: For District:Title FINANCE DIRECTOR Name Signature For Contractor: Address 1635 Faraday Avenue. Carlsbad. CA 92008 Title Vice President Name Eva Siciliani Signature LjLrry Oltuj2ji-.- For Escrow Agent: Address 1210 N Las Brisas St Anaheim CA 92806 Title Assistant Vice President _ Name Ka Signatun Address 1990 Saturn St. Mnterev E£rk. CA 91755 At the time the Escrow Account is opened, the District and Contractor shall deliver to the Escrow Agent a fully executed counterpart of this Agreement. ORevised 5/01/08 Contract No. 52011 (Industrial Park RW Sen/ice Lines)Page 43 of 139 Pages IN WITNESS WHEREOF, the parties have executed this Agreement by their proper officers on the date first set forth above. For District:Title Name Signatun Address 1200 Carlsbad Village Drive. Carlsbad. CA 92008 For Contractor:Title Vice President Name Eva Sicilian! Signature Address 1210 N Las Brisas St Anaheim CA 92806 For Escrow Agent:Title Assistant Vice President Name Katrijia, McLean Signatun Address 1980 Saturn St. Mntecey Park. (A 91755 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 44 of 139 Pages GENERAL PROVISIONS FOR INDUSTRIAL PARK RECYCLED WATER SERVICE LINES CONTRACT NO. 52011 CARLSBAD MUNICIPAL WATER DISTRICT BIDDERS ARE ADVISED THAT THIS SECTION REPLACES PART 1, GENERAL PROVISIONS, OF THE STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION SECTION 1 - TERMS, DEFINITIONS ABBREVIATIONS AND SYMBOLS 1-1 TERMS - Unless otherwise stated, the words directed, required, permitted, ordered, instructed, designated, considered necessary, prescribed, approved, acceptable, satisfactory, or words of like meaning, refer to actions, expressions, and prerogatives of the Engineer. 1-1.1 Reference to Drawings. Where words "shown", "indicated", "detailed", "noted", "scheduled", or words of similar import are used, it shall be understood that reference is made to the plans accompanying these provisions, unless stated otherwise. 1-1.2 Directions. Where words "directed", "designated", "selected", or words of similar import are used, it shall be understood that the direction, designation or selection of the Engineer is intended, unless stated otherwise. The word "required" and words of similar import shall be understood to mean "as required to properly complete the work as required and as approved by the Engineer," unless stated otherwise. 1-1.3 Equals and Approvals. Where the words "equal", "approved equal", "equivalent", and such words of similar import are used, it shall be understood such words are followed by the expression "in the opinion of the Engineer", unless otherwise stated. Where the words "approved", "approval", "acceptance", or words of similar import are used, it shall be understood that the approval, acceptance, or similar import of the Engineer is intended. 1-1.4 Perform. The word "perform" shall be understood to mean that the Contractor, at its expense, shall perform all operations, labor, tools and equipment, and further, including the furnishing and installing of materials that are indicated, specified or required to mean that the Contractor, at its expense, shall furnish and install the work, complete in place and ready to use, including furnishing of necessary labor, materials, tools, equipment, and transportation. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 45 of 139 1-2 Definitions. The following words, or groups of words, shall be exclusively defined by the definitions assigned to them herein. Addendum - Written or graphic instrument issued prior to the opening of Bids which clarifies, corrects, or changes the bidding or Contract Documents. The term Addendum shall include bulletins and all other types of written notices issued to potential bidders prior to opening of Bids. Agency - the Carlsbad Municipal Water District. Agreement - See Contract. Assessment Act Contract - A Contract financed by special assessments authorized under a State Act or procedural ordinance of a City or County. Base - A layer of specified material of planned thickness placed immediately below the pavement or surfacing. Bid - The offer or proposal of the Bidder submitted on the prescribed form setting forth the prices for the Work. Bidder - Any individual, firm, partnership, corporation, or combination thereof, submitting a Bid for the Work, acting directly or through a duly authorized representative. Board - The officer or body constituting the awarding authority of the Agency, the Board of Directors of Carlsbad Municipal Water District. Bond - Bid, performance, and payment bond or other instrument of security. Cash Contract - A Contract financed by means other than special assessments. Change Order - A written order to the Contractor signed by the Agency directing an addition, deletion, or revision in the Work, or an adjustment in the Contract Price or the Contract time issued after the effective date of the Contract. A Change Order may or may not also be signed by the Contractor. Code - The terms Government Code, Labor Code, etc., refer to codes of the State of California. Construction Manager- the Project Inspector's immediate supervisor and first level of appeal for informal dispute resolution. Contract - The written agreement between the Agency and the Contractor covering the Work. Contract Documents - Including but not limited to; the Contract, any Addendum (which pertain to the contract documents), Notice Inviting Bids, Instructions to Bidders; Bid (including documentation accompanying the Bid and any post-bid documentation submitted prior to the Notice of Award) when attached as an exhibit to the Contract, the Bonds, the General Provisions, permits from other agencies, the Technical Specifications, the Supplemental Provisions, the Plans, Standard Plans, Standard Specifications, Reference Specifications, and all Modifications issued after the execution of the Contract. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 46 of 139 Contractor - The individual, partnership, corporation, joint venture, or other legal entity having a Contract with the Agency to perform the Work. In the case of work being done under permit issued by the Agency, the permittee shall be constructed to be the Contractor. The term "prime contractor" shall mean Contractor. Contract Price - The total amount of money for which the Contract is awarded. Contract Unit Price - The amount stated in the Bid for a single unit of an item of work. County Sealer - The Sealer of Weights and Measures of the county in which the Contract is let. Days - Days shall mean consecutive calendar's days unless otherwise specified. Deputy City Engineer, Construction Management & Inspection - The Construction Manager's immediate supervisor and second level of appeal for informal dispute resolution. Dispute Board - persons designated by the City Manager of the City of Carlsbad or Executive Manager of the Carlsbad Municipal Water District, to hear and advise the City Manager on claims submitted by the Contractor. The City Manager for the City of Carlsbad or the Executive Manager for the Carlsbad Municipal Water District is the last appeal level for informal dispute resolution. Electrolier - Street light assembly complete, including foundation, standard, luminaire arm, luminaire, etc. Engineer - the City Engineer of the City of Carlsbad or his/her approved representative. The Engineer is the third level of appeal for informal dispute resolution. Geotextile - Synthetic fiber used in civil engineering applications, serving the primary functions of separation and filtration. House Connection Sewer - A sewer, within a public street or right-of-way, proposed to connect any parcel, lot, or part of a lot with a mainline sewer. House Sewer - A sewer, wholly within private property, proposed to connect any building to a house connection sewer. Luminaire - The lamp housing including the optical and socket assemblies (and ballast if so specified). Luminaire Arm - The structural member, bracket, or mast arm, which, mounted on the standard, supports the luminaire. Minor Bid Item - a single contract item constituting less than 10 percent (10%) of the original Contract Price bid. Modification - Includes Change Orders and Supplemental Agreements. A Modification may only be used after the effective date of the Contract. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 47 of 139 Notice of Award - The written notice by the Agency to the successful Bidder stating that upon .—%, compliance by it with the required conditions, the Agency will execute the Contract. Notice to Proceed - A written notice given by the Agency to the Contractor fixing the date on which the Contract time will start. Own Organization -When used in Section 2-3.1 - Employees of the Contractor who are hired, directed, supervised and paid by the Contractor to accomplish the completion of the Work. Further, such employees have their employment taxes, State disability insurance payments, State and Federal income taxes paid and administered, as applicable, by the Contractor. When used in Section 2-3.1 "own organization" means construction equipment that the Contractor owns or leases and uses to accomplish the Work. Equipment that is owner operated or leased equipment with an operator is not part of the Contractor's Own Organization and will not be included for the purpose of compliance with Section 2-3.1. Person - Any individual, firm, association, partnership, corporation, trust, joint venture, or other legal entity. Plans - The drawings, profiles, cross sections, working drawings, and supplemental drawings, or reproductions thereof, approved by the Engineer, which show the location, character, dimensions, or details of the Work. Private Contract - Work subject to Agency inspection, control, and approval, involving private funds, not administered by the Agency. Project Inspector - the Engineer's designated representative for inspection, contract ' "** administration and first level for informal dispute resolution. s*-r Proposal - See Bid. Reference Specifications - Those bulletins, standards, rules, methods of analysis or test, codes, and specifications of other agencies, engineering societies, or industrial associations referred to in the Contract Documents. These refer to the latest edition, including amendments in effect and published at the time of advertising the project or issuing the permit, unless specifically referred to by edition, volume, or date. Roadway - The portion of a street reserved for vehicular use. Service Connection - Service connections are all or any portion of the conduit, cable, or duct, including meter, between a utility distribution line and an individual consumer. Sewer - Any conduit intended for the reception and transfer of sewage and fluid industrial waste. Specifications - General Provisions, Standard Specifications, Technical Specifications, Reference Specifications, Supplemental Provisions, and specifications in Supplemental Agreements between the Contractor and the Board. Standard - The shaft or pole used to support street lighting luminaire, traffic signal heads, mast arms, etc. -^^ ORevised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 48 of 139 Standard Plans - Details of standard structures, devices, or instructions referred to on the Plans or in Specifications by title or number. Standard Specifications - The Standard Specifications for Public Works Construction (SSPWC), the "Greenbook". State - State of California. Storm Drain - Any conduit and appurtenances intended for the reception and transfer of storm water. Street - Any road, highway, parkway, freeway, alley, walk, or way. Subbase - A layer of specified material of planned thickness between a base and the subgrade. Subcontractor - An individual, firm, or corporation having a direct contract with the Contractor or with any other Subcontractor for the performance of a part of the Work. Subgrade - For roadways, that portion of the roadbed on which pavement, surfacing, base, subbase, or a layer of other material is placed. For structures, the soil prepared to support a structure. Supervision - Supervision, where used to indicate supervision by the Engineer, shall mean the performance of obligations, and the exercise of rights, specifically imposed upon and granted to the Agency in becoming a party to the Contract. Except as specifically stated herein, supervision by the Agency shall not mean active and direct superintendence of details of the Work. Supplemental Agreement - A written amendment of the Contract Documents signed by both parties. Supplemental Provisions - Additions and revisions to the Standard Specifications setting forth conditions and requirements peculiar to the work. Surety - Any individual, firm, or corporation, bound with and for the Contractor for the acceptable performance, execution, and completion of the Work, and for the satisfaction of all obligations incurred. Tonne - Also referred to as "metric ton". Represents a unit of measure in the International System of Units equal to 1,000 kilograms. Utility - Tracks, overhead or underground wires, pipeline, conduits, ducts, or structures, sewers, or storm drains owned, operated, or maintained in or across a public right of way or private easement. Work - That which is proposed to be constructed or done under the Contract or permit, including the furnishing of all labor, materials, equipment, and services. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 49 of 139 1-3 ABBREVIATIONS 1-3.1 General. The abbreviation herein, together with others in general use, are applicable to these Standard Specifications and to project Plans or other Contract Documents. All abbreviations and symbols used on Plans for structural steel construction shall conform to those given by the "Manual of Steel Construction" published by the American Institute of Steel Construction, Inc. 1-3.2 Common Usage Abbreviation Word or Words ABAN Abandon ABAND Abandoned ABS Acrylonitrile - butadiene - styrene AC Asphalt Concrete ACP Asbestos cement pipe ACWS Asphalt concrete wearing surface ALT Alternate ARTS Apartment and Apartments AMER STD American Standard AWG American Wire Gage (nonferrous wire) BC Beginning of curve BCR Beginning of curb return BDRY Boundary BF Bottom of footing BLDG Building and Buildings BM Bench mark BVC Beginning of vertical curve B/W Back of wall C/C Center to center CAB Crushed aggregate base CAL/OSHA California Occupational Safety and Health Administration CalTrans California Department of Transportation CAP Corrugated aluminum pipe CB Catch Basin Cb Curb CBP Catch Basin Connection Pipe CBR California Bearing Ratio CCR California Code of Regulations CCTV Closed Circuit TV CES Carlsbad Engineering Standards CF Curb face CF Cubic foot C&G Curb and gutter CFR Code of Federal Regulations CFS Cubic Feet per Second CIP Cast iron pipe CIPP Cast-in place pipe CL Clearance, center line CLF Chain link fence CMB Crushed miscellaneous base CMC Cement mortar-coated CML Cement mortar-lined CMWD Carlsbad Municipal Water District CO Cleanout (Sewer) COL Column COMM Commercial CONC Concrete CONN Connection CONST Construct, Construction COORD Coordinate CSP Corrugated steel pipe CSD Carlsbad Standard Drawings CTB Cement treated base CV Check valve CY Cubic yard D Load of pipe dB Decibels DEL Double DF Douglas fir DIA Diameter DIP Ductile iron pipe DL Dead load DR Dimension Ratio DT Drain Tile DWG Drawing DWY Driveway DWY APPR Driveway approach E Electric EA Each EC End of curve ECR End of curb return EF Each face EG Edge of gutter EGL Energy grade line El Elevation ELC Electrolier lighting conduit ELT Extra long ton ENGR Engineer, Engineering EP Edge of pavement ESMT Easement ETB Emulsion-treated base EVC End of vertical curb EWA Encina Wastewater Authority EXC Excavation EXP JT Expansion joint EXST .' Existing F Fahrenheit F&C Frame and cover F&l Furnish and install FAB Fabricate FAS Flashing arrow sign Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 50 of 139 FD Floor drain FDN Foundation FED SPEC Federal Specification FG Finished grade FH Fire hydrant FL Flow line FS Finished surface FT-LB Foot-pound FTG Footing FW Face of wall G Gas GA Gauge GAL Gallon and Gallons GALV Galvanized GAR Garage and Garages GIF Galvanized iron pipe GL Ground line or grade line GM Gas meter GNV Ground Not Visible GP Guy pole GPM gallons per minute GR Grade GRTG Grating GSP Galvanized steel pipe H High or height HB Hose bib HC House connection HDWL Headwall HGL Hydraulic grade line HORIZ Horizontal HP Horsepower HPG High pressure gas HPS High pressure sodium (Light) HYDR Hydraulic IE Invert Elevation ID Inside diameter INCL Including INSP Inspection INV Invert IP Iron pipe JC Junction chamber JCT Junction JS Junction structure JT Joint L Length LAB Laboratory LAT Lateral LB Pound LD Local depression LF Linear foot LH Lamp hole LL Live load LOL Layout line LONG Longitudinal LP Lamp post LPS Low pressure sodium (Light) LS Lump sum LTS Lime treated soil LWD Leucadia Wastewater District MAINT Maintenance MAX Maximum MCR Middle of curb return MEAS Measure MH Manhole, maintenance hole MIL SPEC Military specification MISC Miscellaneous MOD Modified, modify MON Monument MSL ..Mean Sea Level (Reg. Standard Drawing M-12) MTBM Microtunneling Boring Machine MULT Multiple MUTCD Manual on Uniform Traffic Control Devices MVL Mercury vapor light NCTD North County Transit District NRCP Nonreinforced concrete pipe OBS Obsolete OC On center OD Outside diameter OE Outer edge OHE Overhead Electric OMWD Olivenhain Municipal Water District OPP Opposite ORIG Original PB Pull box PC Point of curvature PCC Portland cement concrete or point of compound curvature PCVC Point of compound vertical curve PE Polyethylene PI Point of intersection PL Property line PMB Processed miscellaneous base POC Point on curve POT Point on tangent PP Power pole PRC Point of reverse curve PRVC Point of reverse vertical curve PSI Pounds per square inch PT : Point of tangency PVC Polyvinyl chloride PVMT Pavement PVT R/W Private right-of-way Q Rate of flow in cubic feet per second QUAD Quadrangle, Quadrant R Radius R&O Rock and oil R/W Right-of-way RA Recycling agent RAC Recycled asphalt concrete RAP Reclaimed asphalt pavement RBAC Rubberized asphalt concrete RC Reinforced concrete RGB Reinforced concrete box RCE Registered civil engineer RCP Reinforced concrete pipe RCV Remote control valve REF Reference REINF Reinforced or reinforcement RES Reservoir RGE Registered geotechnical engineer ROW Right-of-Way RR Railroad RSE Registered structural engineer RTE Registered traffic engineer S Sewer or Slope, as applicable SCCP Steel cylinder concrete pipe SD Storm drain SDNR San Diego Northern Railway Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 51 of 139 SDR Standard thermoplastic pipe dimension ratio (ratio of pipe O.D. to minimum wall thickness) SDRSD San Diego Regional Standard Drawings SE Sand Equivalent SEC Section SF Square foot SFM Sewer Force Main SI International System of Units (Metric) SPEC Specifications SPPWC Standard Plans for Public Works Construction SSPWC Standard Specifications for Public Works Construction STHWY State highway STA Station STD Standard SIR Straight SIR GR Straight grade STRUG Structural/Structure SW Sidewalk SWD Sidewalk drain SY Square yard T Telephone TAN Tangent TC Top of curb TEL Telephone TF Top of footing TOPO Topography TR Tract TRANS Transition TS Traffic signal or transition structure TSC Traffic signal conduit TSS Traffic signal standard TW Top of wall TYP Typical UE Underground Electric USA Underground Service Alert VAR Varies, Variable VB Valve box VC Vertical curve VCP Vitrified clay pipe VERT Vertical VOL Volume VWD Vallecitos Water District W Water, Wider or Width, as applicable WATCH Work Area Traffic Control Handbook Wl Wrought iron WM Water meter WPJ Weakened plane joint XCONN Cross connection XSEC Cross section 1-3.3 Institutions. Abbreviation Word or Words AASHTO American Association of State Highway and Transportation Officials AISC American Institute of Steel Construction ANSI American National Standards Institute API American Petroleum Institute AREA American Railway Engineering Association ASTM American Society for Testing and Materials AWPA American Wood Preservers Association AWS American Welding Society AWWA American Water Works Association FHWA Federal Highway Administration GRI Geosynthetic Research Institute NEMA National Electrical Manufacturers Association NOAA National Oceanic and Atmospheric Administration (Dept. of Commerce) UL Underwriters' Laboratories Inc. USGS United States Geological Survey Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 52 of 139 1-4 UNITS OF MEASURE. 1-4.1 General. U.S. Standard Measures, also called U.S. Customary System, are the principal measurement system in these specifications. However, certain material specifications and test requirements contained herein use SI units specifically and conversions to U.S. Standard Measures may or may not have been included in these circumstances. When U.S. Standard Measures are not included in parenthesis, then the SI units shall control. S.I. units and U.S. Standard Measures in parenthesis may or may not be exactly equivalent. Reference is also made to ASTM E 380 for definitions of various units of the SI system and a more extensive set of conversion factors. 1 -4.2 Units of Measure and Their Abbreviations. U.S. Customary Unit (Equal To) SI Unit (Abbreviations) (Abbreviations) 1 mil (=0.001 in) 25.4 micrometer (^m) 1 inch (in) 25.4 millimeter (mm) 1 inch (in) 2.54 centimeter (cm) 1 foot (ft) ! 0.3048 meter (m) 1 yard (yd) 0.9144 meter (m) 1 mile (mi) 1.6093 kilometer (km) 1 square foot (fr) 0.0929 square meter (m) 1 square yard (yd) 0.8361 square meter (m ) 1 cubic foot (ft3). 0.0283 cubic meter (m) 1 cubic yard (yd ) 0.7646 cubic meter (m ) 1 acre 0.4047 hectare (ha) 1 U.S. gallon (gal) 3.7854 Liter (L) 1 fluid ounce (fl. oz.) 29.5735 millileter (mL) 1 pound mass (Ib) (avoirdupois) 0.4536 kilogram (kg) 1 ounce mass (oz) 0.02835 kilogram (kg) 1 Ton (=2000 Ib avoirdupois) 0.9072 Tonne (= 907 kg) 1 Poise 0.1 pascal' second (Pa s) 1 centistoke (cs) 1 square millimeters per second (mm /s) 1 pound force (Ibf) 4.4482 Newton (N) 1 pounds per square inch (psi) 6.8948 Kilopascal (kPa) 1 pound force per foot (Ibf/ft) 1.4594 Newton per meter (N/m) 1 foot-pound force (ft-lbf) 1.3558 Joules (J) 1 foot-pound force per second ([ft-lbf]/s) 1.3558 Watt (W) 1 part per million (ppm) 1 milligram/liter (mg/L) Temperature Units and Abbreviations Degree Fahrenheit (°F): Degree Celsius (°C): °F = (1.8 x °C) + 32 °C = (°F - 32)/1.8 SI Units (abbreviation) Commonly Used in Both Systems 1 Ampere (A) 1 Volt (V) 1 Candela (cd) 1 Lumen (Im) 1 second (s) Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 53 of 139 Common Metric Prefixes kilo(k) -. 103 centi(c) 10, milli(m) 10'3 micro (n) 10"^ nano(n) 10"®. pico (p) 10"12 1-5 SYMBOLS A Delta, the central angle or angle between tangents Z Angle % Percent Feet or minutes Inches or seconds1 Number / per or (between words)0 Degree PL Property line CL Centerline SL Survey line or station line SECTION 2 - SCOPE AND CONTROL OF WORK 2-1 AWARD AND EXECUTION OF CONTRACT. Award and execution of Contract will be as provided for in the Specifications, Instruction to Bidders, or Notice Inviting Bids. 2-2 ASSIGNMENT. No Contract or portion thereof may be assigned without consent of the Board, except that the Contractor may assign money due or which will accrue to it under the Contract. If given written notice, such assignment will be recognized by the Board to the extent permitted by law. Any assignment of money shall be subject to all proper withholdings in favor of the Agency and to all deductions provided for in the Contract. All money withheld, whether assigned or not, shall be subject to being used by the Agency for completion of the Work, should the Contractor be in default. 2-3 SUBCONTRACTS. 2-3.1 General. Each Bidder shall comply with the Chapter of the Public Contract Code including Sections 4100 through 4113. The following excerpts or summaries of some of the requirements of this Chapter are included below for information: The Bidder shall set forth in the Bid, as provided in 4104: "(a) The name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the work or improvements, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specially fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of 1 percent of the prime contractor's total bid, or, in the case of bids or offers for the construction of streets or highways, including bridges, in excess of one-half of 1 percent of the prime contractor's total bid or ten thousand dollars ($10,000), whichever is greater." m¥ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 54 of 139 "(b) The portion of the work which will be done by each such subcontractor under this act. The prime contractor shall list only one subcontractor for each such portion as is defined by the prime contractor in his bid." If the Contractor fails to specify a Subcontractor, or specifies more than one Subcontractor for the same portion of the work to be performed under the Contract (in excess of one-half of 1 percent of the Contractor's total Bid), the Contractor shall be qualified to perform that portion itself, and shall perform that portion itself, except as otherwise provided in the Code. As provided in Section 4107, no Contractor whose Bid is accepted shall substitute any person as Subcontractor in place of the Subcontractor listed in the original Bid, except for causes and by procedures established in Section 4107.5. This section provides procedures to correct a clerical error in the listing of a Subcontractor. Section 4110 provides that a Contractor violating any of the provisions of the Chapter violates the Contract and the Board may exercise the option either to cancel the Contract or assess the Contractor a penalty in an amount of not more than 10 percent of the subcontract involved, after a public hearing. Should the Contractor fail to adhere to the provisions requiring the Contractor to complete 50 percent of the contract price with its own organization, the Agency may at its sole discretion elect to cancel the contract or deduct an amount equal to 10 percent of the value of the work performed in excess of 50 percent of the contract price by other than the Contractor's own organization. The Board shall be the sole body for determination of a violation of these provisions. In any proceedings under this section, the prime contractor shall be entitled to a public hearing before the Board and shall be notified ten (10) days in advance of the time and location of said hearing. The determination of the Board shall be final. 2-3.2 Additional Responsibility. The Contractor shall give personal attention to the fulfillment of the Contract and shall keep the Work under its control. The Contractor shall perform, with its own organization, Contract work amounting to at least 50 percent of the Contract Price except that any designated "Specialty Items" may be performed by subcontract, and the amount of any such "Specialty Items" so performed may be deducted from the Contract Price before computing the amount required to be performed by the Contractor with its own organization. "Specialty Items" will be identified by the Agency in the Bid or Proposal. Where an entire item is subcontracted, the value of work subcontracted will be based on the Contract Unit Price. When a portion of an item is subcontracted, the value of work subcontracted will be based on the estimated percentage of the Contract Unit Price. This will be determined from information submitted by the Contractor, and subject to approval by the Engineer. Before the work of any Subcontractor is started, the Contractor shall submit to the Engineer for approval a written statement showing the work to be subcontracted giving the name and business of each Subcontractor and description and value of each portion of the work to be so subcontracted. 2-3.3 Status of Subcontractors. Subcontractors shall be considered employees of the Contractor, and the Contractor shall be responsible for their work. 2-4 CONTRACT BONDS. Before execution of the Contract, the Bidder shall file surety bonds with the Agency to be approved by the Board in the amounts and for the purposes noted below. Bonds issued by a surety, who is authorized to issue bonds in California, and whose bonding limitation shown in said circular is sufficient to provide bonds in the amount required by the Contract Revised 5/01/08 Contract No. 5201 1 (Industrial Park RW Service Lines) Page 55 of 1 39 shall be deemed to be approved unless specifically rejected by the Agency. Bonds from all other sureties shall be accompanied by all of the documents enumerated in Code of Civil Procedure 995.660 (a). The Bidder shall pay all bond premiums, costs, and incidentals. Each bond shall incorporate, by reference, the Contract and be signed by both the Bidder and Surety and the signature of the authorized agent of the Surety shall be notarized. The Contractor shall provide a faithful performance/warranty bond and payment bond (labor and materials bond) for this contract. The faithful performance/warranty bond shall be in a sum not less than one hundred percent of the total amount payable by the terms of this contract. The Contractor shall provide bonds to secure payment of laborers and materials suppliers in a sum not less than one hundred percent of the total amount payable by the terms of this contract. Both bonds shall extend in full force and effect and be retained by the Agency during this project until they are released according to the provisions of this section. The faithful performance/warranty bond will be reduced to 25 percent of the original amount 30 days after recordation of the Notice of Completion and will remain in full force and effect for the one year warranty period and until all warranty repairs are completed to the satisfaction of the Engineer. The bonds to secure payment of laborers and materials suppliers shall be released six months plus 30 days after recordation of the Notice of Completion if all claims have been paid. All bonds are to be placed with a surety insurance carrier admitted and authorized to transact the business of insurance in California and whose assets exceed their liabilities in an amount equal to or in excess of the amount of the bond. The bonds are to contain the following documents: 1) An original, or a certified copy, of the un-revoked appointment, power of attorney, by laws, or other instrument entitling or authorizing the person who executed the bond to do so. 2) A certified copy of the certificate of authority of the insurer issued by the insurance commissioner. If the bid is accepted, the Agency may require a financial statement of the assets and liabilities of the insurer at the end of the quarter calendar year prior to 30 days next preceding the date of the execution of the bond. The financial statement shall be made by an officer's certificate as defined in Section 173 of the Corporations Code. In the case of a foreign insurer, the financial statement may be verified by the oath of the principal officer or manager residing within the United States. Should any bond become insufficient, the Contractor shall renew the bond within 10 days after receiving notice from the Agency. Should any Surety at any time be unsatisfactory to the Board, notice will be given the Contractor to that effect. No further payments shall be deemed due or will be made under the contract until a new Surety shall qualify and be accepted by the Board. Changes in the Work or extensions of time, made pursuant to the Contract, shall in no way release the Contractor or Surety from its obligations. Notice of such changes or extensions shall be waived by the Surety. 2-5 PLANS AND SPECIFICATIONS. 2-5.1 General. The Contractor shall keep at the Work site a copy of the Plans and Specifications, to which the Engineer shall have access at all times. The specifications for the work include the General Provisions, project specifications, Carlsbad Engineering Standards (CES), Standard Specifications for Public Works Construction, (SSPWC), Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 56 of 139 Part 2 & 3, and the latest supplements thereto, current edition at the time of bid opening as published by the "Greenbook" Committee of Public Works Standards, Inc., hereinafter designated "SSPWC", as amended. The construction plans consist of one set of drawings. The set is designated as City of Carlsbad Drawing No. 405-7A and consists of 15 sheets. The standard drawings used for this project are the latest edition of the San Diego Area Regional Standard Drawings, as issued by the San Diego County Department of Public Works, hereinafter designated SDRSD, together with the most recent editions of the City of Carlsbad Engineering Standards and Carlsbad Standard Drawings, as issued by the City of Carlsbad and the Carlsbad Municipal Water District, hereinafter designated as CES and CSD, respectively. Copies of some of the pertinent standard drawings are enclosed as an appendix to these General Provisions. The Plans, Specifications, and other Contract Documents shall govern the Work. The Contract Documents are intended to be complementary and cooperative. Anything specified in the Specifications and not shown on the Plans, or shown on the Plans and not specified in the Specifications, shall be as though shown on or specified in both. The Plans shall be supplemented by such working drawings and shop drawings as are necessary to adequately control the Work. The Contractor shall ascertain the existence of any conditions affecting the cost of the Work through a reasonable examination of the Work site prior to submitting the Bid. Existing improvements visible at the Work site, for which no specific disposition is made on the Plans, but which interfere with the completion of the Work, shall be removed and disposed of by the Contractor. The Contractor shall, upon discovering any error or omission in the Plans or Specifications, immediately call it to the attention of the Engineer. 2-5.2 Precedence of Contract Documents. If there is a conflict between Contract Documents, the document highest in precedence shall control. The precedence shall be the most recent edition of the following documents listed in order of highest to lowest precedence: 1) Permits from other agencies as may be required by law. 2) Change orders, whichever occurs last. 3) Contract addenda, whichever occurs last. 4) Contract 5) Carlsbad General Provisions, Technical Specifications, and Supplemental Provisions. 6) Plans. 7) Standards plans. a) City of Carlsbad Standard Drawings. b) Carlsbad Municipal Water District Standard Drawings. c) City of Carlsbad modifications to the San Diego Area Regional Standard Drawings. d) San Diego Area Regional Standard Drawings. e) State of California Department of Transportation Standard Plans. 8) Standard Specifications for Public Works Construction, as amended. 9) Reference Specifications. 10) Manufacturer's Installation Recommendations Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 57 of 139 Detail drawings shall take precedence over general drawings. Change Orders, Supplemental Agreements and approved revisions to Plans and Specifications will take precedence over items 2) through 9) above. Detailed plans and plan views shall have precedence over general plans. 2-5.3 Submittals. 2-5.3.1 General. Submittals shall be provided, at the Contractor's expense, as required in 2-5.3.2, 2-5.3.3 and 2-5.3.4, when required by the Plans or Special Provisions, or when requested by the Engineer. Materials shall neither be furnished nor fabricated, nor shall any work for which submittals are required by performed, before the required submittals have been reviewed and accepted by the Engineer. Neither review nor acceptance of submittals by the Engineer shall relieve the Contractor from responsibility for errors, omissions, or deviations from the Contract Documents, unless such deviations were specifically called to the attention of the Engineer in the letter of transmittal. The Contractor shall be responsible for the correctness of the submittals. The Contractor shall allow a minimum of 20 working days for review of submittals unless otherwise specified in the Special Provisions. Each submittal shall be accompanied by a letter of transmittal. Each submittal shall be consecutively numbered. Resubmittals shall be labeled with the number of the original submittal followed by an ascending alphabetical designation (e.g. The label '4-C' would indicate the third instance that the fourth submittal had been given to the Engineer). Each sheet of each submittal shall be consecutively numbered. Each set of shop drawings and submittaJs shall be accompanied by a letter of transmittal on the Contractor's letterhead. The Letter of transmittal shall contain the following: 1) Project title and Agency contract number. 2) Number of complete sets. 3) Contractor's certification statement. 4) Specification section number(s) pertaining to material submitted for review. 5) Submittal number (Submittal numbers shall be consecutive including subsequent submittals for the same materials.) 6) Description of the contents of the submittal. 7) Identification of deviations from the contract documents. When submitted for the Engineer's review, Shop Drawings shall bear the Contractor's certification that the Contractor has reviewed, checked, and approved the Shop Drawings and that they are in conformance with the requirements of the Contract Documents. The Contractor shall subscribe to and shall place the following certification on all submittals: "I hereby certify that the (equipment, material) shown and marked in this submittal is that proposed to be incorporated into this Project, is in compliance with the Contract Documents, can be installed in the allocated spaces, and is submitted for approval." By: Title: Date: Company Name: Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 58 of 139 2-5.3.2 Working Drawings. Working drawings are drawings showing details not shown on the Plans which are required to be designed by the Contractor. Working drawings shall be of a size and scale to clearly show all necessary details. Six copies and one reproducible shall be submitted. If no revisions are required, three of the copies will be returned to the Contractor. If revisions are required, the Engineer will return one copy along with the reproducible for resubmission. Upon acceptance, the Engineer will return two of the copies to the Contractor and retain the remaining copies and the reproducible. Working drawings are required in the following sections: ____^_ TABLE 2-5.3.2 (A) 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 7-10.4.1 207-2.5 207-8.4 207-10.2.1 300-3.2 303-1.6.1 303-1.7.1 303-3.1 304-1.1.1 304-1.1.2 304-2.1 306-2.1 306-3.1 306-3.4 306-6 306-8 307-4.3 Safety Orders Joints Joints General Cofferdams General General General Shop Drawings Falsework Plans General General General Tunnel Supports Remodeling Existing Sewer Facilities Microtunneling Controller Cabinet Wiring Diagrams Trench Shoring Reinforced Concrete Pipe Vitrified Clay Pipe Fabricated Steel Pipe Structure Excavation & Backfill Falsework Placing Reinforcement Prestressed Concrete Construction Structural Steel Structural Steel Metal Hand Railings Jacking Operations Tunneling Operations Tunneling Operations Polyethylene Liner Installation Microtunneling Operations Traffic Signal Construction Working drawings listed above as Items 5, 6, 8, 9, 10, 12, 13, 14 and 16 shall be prepared by a Civil or Structural Engineer registered by the State of California. 2-5.3.3 Shop Drawings. Shop drawings are drawings showing details of manufactured or assembled products proposed to be incorporated into the Work. Shop drawings required shall be as specified in the Special Provisions. 2-5.3.4 Supporting Information. Supporting information is information required by the Specifications for the purposes of administration of the Contract, analysis for verification of conformance with the Specifications, the operation and maintenance of a manufactured product or system to be constructed as part of the Work, and other information as may be required by the Engineer. Six copies of the supporting information shall be submitted to the Engineer prior to the start of the Work unless otherwise specified in the Special Provisions or directed by the Engineer. Supporting information for systems shall be bound together and include all manufactured items for the system. If resubmittal is not required, three copies will be returned to the Contractor. Supporting information shall consist of the following and is required unless otherwise specified in the Special Provisions: Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 59 of 139 1) List of Subcontractors per 2-3.2. 2) List of Materials per 4-1.4. 3) Certifications per 4-1.5. 4) Construction Schedule per 6-1. 5) Confined Space Entry Program per 7-10.4.4. 6) Concrete mix designs per 201-1.1. Asphalt concrete mix designs per 203-6.1. Data, including, but not limited to, catalog sheets, manufacturer's brochures, technical bulletins, specifications, diagrams, product samples, and other information necessary to describe a system, product or item. This information is required for irrigation systems, street lighting systems, and traffic signals, and may also be required for any product, manufactured item, or system. 2-5.4 RECORD DRAWINGS. The Contractor shall provide and keep up-to-date a complete "as-built" record set of blue-line prints, which shall be corrected in red daily and show every change from the original drawings and specifications and the exact "as-built" locations, sizes and kinds of equipment, underground piping, valves, and all other work not visible at surface grade. Prints for this purpose may be obtained from the Agency at cost. This set of drawings shall be kept on the job and shall be used only as a record set and shall be delivered to the Engineer within ten (10) days of completion of the work. Payment for performing the work required by Section 2-5.4 shall be included in the various bid items and no additional payment will be made therefore. 2-6 WORK TO BE DONE. The Contractor shall perform all work necessary to complete the Contract in a satisfactory manner. Unless otherwise provided, the Contractor shall furnish all materials, equipment, tools, labor, and incidentals necessary to complete the Work. 2-7 SUBSURFACE DATA. All soil and test hole data, water table elevations, and soil analyses shown on the drawings or included in the Specifications apply only at the location of the test holes and to the depths indicated. Soil test reports for test holes which have been drilled are available for inspection at the office of the Engineer. Any additional subsurface exploration shall be done by Bidders or the Contractor at their own expense. The indicated elevation of the water table is that which existed on the date when test hole data was determined. It is the Contractor's responsibility to determine and allow for the elevation of groundwater at the date of project construction. A difference in elevation between groundwater shown in soil boring logs and groundwater actually encountered during construction will not be considered as a basis for extra work. 2-8 RIGHT-OF-WAY. Rights-of-way, easements, or rights-of-entry for the Work will be provided by the Agency. Unless otherwise provided, the Contractor shall make arrangements, pay for, and assume all responsibility for acquiring, using, and disposing of additional work areas and facilities temporarily required. The Contractor shall indemnify and hold the Agency harmless from all claims for damages caused by such actions. 2-9 SURVEYING. 2-9.1 Permanent Survey Markers. The Contractor shall not cover or disturb permanent survey monuments or benchmarks without the consent of the Engineer. Where the Engineer concurs, in writing, with the Contractor that protecting an existing monument in place is impractical, the Contractor shall employ a licensed land surveyor or a registered civil engineer authorized to practice land surveying within the State of California, hereinafter Surveyor, to establish the location of the monument before it is disturbed. The Contractor shall have the monument replaced by the Surveyor no later than thirty (30) days after construction at the site of the replacement is completed. The Surveyor shall file corner record(s) as required by §§ 8772 and 8773, et seq. of the California Business and Professions Code. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 60 of 139 '**"**"" When a change is made in the finished elevation of the pavement of any roadway in which a ^n*" permanent survey monument is located, the Contractor shall adjust the monument frame and cover to the new grade within 7 days of paving unless the Engineer shall approve otherwise. Monument frames and covers shall be protected during street sealing or painting projects or be cleaned to the satisfaction of the Engineer. 2-9.2 Survey Service. The Contractor shall hire and pay for the services of a Surveyor, hereinafter Surveyor to perform all work necessary for establishing control, construction staking, records research and all other surveying work necessary to construct the work, provide surveying services as required herein and provide surveying, drafting and other professional services required to satisfy the requirements of the Land Surveyors Act. Surveyor shall be resident on the site during all surveying operations and shall personally supervise and certify the surveying work. 2-9.2.1 Submittal of Surveying Data, All surveying data submittals shall conform to the requirements of Section 2-5.3.3, "Submittals", herein. The Contractor shall submit grade sheets to the Engineer before commencing work in the area affected by the grade sheets. The Contractor shall submit field notes for all surveying required herein to the Engineer within ten days of performing the survey. All surveying field notes, grade sheets and survey calculations shall be submitted in bound form on 215mm by 280 mm (81/2" by 11") paper. The field notes, calculations and supporting data shall be clear and complete. Supporting data shall include all maps, affidavits, plats, field notes from earlier surveys and all other evidence used by the Surveyor to determine the location of the monuments set. The field notes and calculations will be labeled with name of the Surveyor, the party chief, the field crewmembers and the author of the field notes or calculations. They shall be annotated with the date of observation or calculation, be numbered with consecutive '*"* page numbers and shall be readable without resort to any electronic aid, computer program or W documentation for any computer program. The field notes shall be prepared in conformance with the CALTRANS "Surveys Manual". The Contractor shall have a Record of Survey prepared by the Surveyor and file it in conformance with §§ 8700 - 8805 of the State of California Business and Professions Code when the Surveyor performs any surveying that such map is required under §§ 8762 of the State of California Business and Professions Code and whenever the Surveyor shall establish, set or construct any permanent survey monument. SDRS drawing M-10 type monuments, bolts, spikes, leaded tacks and nails (when set in concrete), iron pipes, reinforcing steel and all monuments and marks that are at, or accessory to, property corners and street centerlines are permanent survey monuments. The Record of Survey shall show all monuments set, control monuments used, the basis of bearings and all other data needed to determine the procedure of survey and the degree of accuracy attained by the field surveying including the unadjusted ratio of closure. The unadjusted ratio of closure shall not exceed 1 part in 40,000. The record of survey shall show the location and justification of location of all permanent monuments set and their relation to the street right-of-way. Record(s) of Survey(s) shall be submitted for the Engineer's review and approval before submittal to the County Surveyor and before submittal to the County Recorder. 2-9.2.2 Survey Requirements, Stakes shall be set at offsets approved by the Engineer at no greater intervals than specified in TABLE 2-9.2.2(A) as measured along the project stationing. Stakes shall be set to show the location and grade of future curbs adjacent to traffic signal locations where the curb is not being built as a part of this contract. Staking and marking shall be completed by the Surveyor and inspected and approved by the Engineer before the start of construction in the area marked. Centerline monument shall have the disk stamped with the date the monument was set and the registration number of the Surveyor. Habitat mitigation sites and other areas to be preserved that are shown on the plans shall be staked and flagged prior to the start of any other activities within the limits of the work. When curb and gutter does not exist and is not being installed as a part of the project the location of adjacent facilities being constructed as a part of the contract Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 61 of 139 the Contractor shall place stakes defining the horizontal and vertical location of such adjacent utility vaults, poles or other facilities that are being installed as parts of, or adjunct to, the project either by the Contractor and/or those noted on the plans as to be installed by others. TABLE 2-9.2.2(A) Survey Requirements for Construction Staking Feature Staked Street Centerline Asphalt Pavement Finish Course Drainage Structures, Pipes & similar Facilities®, ® Curb Miscellaneous ® Contour Grading ® Utilities ®, ® Pavement Markers® Stake Description ® SDRSM-10 Monument RP, paint on previous course RP + Marker Stake RP + Marker Stake RP + Marker Stake RP + Marker Stake RP Centerline or Parallel to Centerline Spacing®, ® <1000', Street Intersections, Begin and end of curves, only when shown on the plans < 25' or as per the intersection grid points shown on the plan whichever provides the denser information intervisible & < 25', beginning and end, BC & EC of facilities, Grade breaks, Alignment breaks, Junctions, Inlets & similar facilities, Risers & similar facilities (except plumbing), Skewed cut-off lines < 25', BC & EC, at %A, 1/2A & >/4A on curb returns & at beginning & end <50' ^ 50' on tangents & curves when R> 1000' & < 25' on curves when R < 1000" or where grade < 0.30% 200' on tangents, 50' on curves when R > 1000' & 25' on curves when R <, 1000'. For PCC surfaced streets lane cold joints will suffice Lateral Spacing <D, ® on street centerline edge of pavement, paving pass width, crown line & grade breaks as appropriate ( constant offset) along contour line as appropriate at pavement marker location(s) Setting Tolerance (Within) 0.02' Horizontal, also see Section 2-9.2.1 herein V Horizontal & V Vertical •V Horizontal & V Vertical V Horizontal & V Vertical 0.1 'Verticals Horizontal V Horizontal & V Vertical V4" Horizontal Staking for feature may be omitted when adjacent marker stakes reference the offset and elevation of those features and the accuracy requirements of the RP meet the requirements for the feature ® Reference points shall be sufficiently durable and set securely enough to survive with accuracy intact throughout the installation & inspection of the features or adjacent facilities for which they provide control. RP means reference point for the purposes of this table ® Perpendicular to centerline. ® Some features are not necessarily parallel to centerline but are referenced thereto © Multi-plane surfaced features shall be staked so as to provide line & grade information for each plane of the feature ® > means greater than, or equal to, the number following the symbol. < means less than, or equal to, the number fol- lowing the symbol. ® The cut datum for storm drainage & sanitary sewer pipes & similar structures shall be their invert. The cut datum for all other utilities shall be the top of their pipe or conduit. All guard stakes, line stakes and lath shall be flagged. Unless otherwise approved by the Engineer flagging, paint and marking cards shall be the color specified in TABLE 2-9.2.2(6) Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 62 of 139 TABLE 2-9.2.2(6) Survey Stake Color Code for Construction Staking Type of Stake Horizontal Control Vertical Control Clearing Grading Structure Drainage, Sewer, Curb Right-of-Way Miscellaneous Description Coordinated control points, control lines, control reference points, centertine, alignments, etc. Bench marks Limits of clearing Slope, intermediate slope, abutment fill, rough grade, contour grading, final grade, etc. Bridges, sound and retaining walls, box culverts, etc. Pipe culverts, junction boxes, drop inlets, headwalls, sewer lines, storm drains, slope protection, curbs, gutters, etc. Fences, R/ W lines, easements, property monuments, etc. Signs, railings, barriers, lighting, etc. Color* White/Red White/Orange Yellow/Black Yellow White Blue White/Yellow Orange ' Flagging and marking cards, if used. 2-9.2.3 Payment for Survey, Payment for work performed to satisfy the requirements of Sections 2- 9.1 through 2-9.2.2 shall be included in the actual bid items requiring the survey work and no additional payment will be made. Extension of unit prices for extra work shall include full compensation for attendant survey work and no additional payment will be made. Payment for the replacement of disturbed monuments and the filing of records of survey and/or corner records, including filing fees, shall be incidental to the work necessitating the disturbance of said monuments and no additional payment will be made. 2-9.3 Private Engineers. Surveying by private engineers on the Work shall conform to the quality and practice required by the Engineer. 2-9.4 Line and Grade. All work shall conform to the lines, elevations, and grades shown on the Plans. Three consecutive points set on the same slope shall be used together so that any variation from a straight grade can be detected. Any such variation shall be reported to the Engineer. In the absence of such report, the Contractor shall be responsible for any error in the grade of the finished work. Grades for underground conduits will be set at the surface of the ground. The Contractor shall transfer them to the bottom of the trench. 2-10 AUTHORITY OF BOARD AND ENGINEER. The Board has the final authority in all matters affecting the Work. Within the scope of the Contract, the Engineer has the authority to enforce compliance with the Plans and Specifications. The Contractor shall promptly comply with instructions from the Engineer or an authorized representative. The decision of the Engineer is final and binding on all questions relating to: quantities; acceptability of material, equipment, or work; execution, progress or sequence of work; and interpretation of the Plans, Specifications, or other drawings. This shall be precedent to any payment under the Contract, unless otherwise ordered by the Board. 2-10.1 Availability of Records, The Contractor shall, at no charge to the Agency, provide copies of all records in the Contractor's or subcontractor's possession pertaining to the work that the Engineer may request. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 63 of 139 2-10.2 Audit And Inspection, Contractor agrees to maintain and/or make available, to the Engineer, within San Diego County, accurate books and accounting records relative to all its activities and to contractually require all subcontractors to this Contract to do the same. The Engineer shall have the right to monitor, assess, and evaluate Contractor's and its subcontractors performance pursuant to this Agreement, said monitoring, assessments, and evaluations to include, but not be limited to, audits, inspection of premises, reports, contracts, subcontracts and interviews of Contractor's staff and the staff of all subcontractors to this contract. At any time during normal business hours and as often as the Engineer may deem necessary, upon reasonable advance notice, Contractor shall make available to the Engineer for examination, all of its, and all subcontractors to this contract, records with respect to all matters covered by this Contract and will permit the Engineer to audit, examine, copy and make excerpts or transcripts from such data and records, and to make audits of all invoices, materials, payrolls, records of personnel, and other data relating to all matters covered by this Contract. However, any such activities shall be carried out in a manner so as to not unreasonably interfere with Contractor's ongoing business operations. Contractor and all subcontractors to this contract shall maintain such data and records for as long as may be required by applicable laws and regulations. 2-11 INSPECTION. The Work is subject to inspection and approval by the Engineer. The Contractor shall notify the Engineer before noon of the working day before inspection is required. Work shall be done only in the presence of the Engineer, unless otherwise authorized. Any work done without proper inspection will be subject to rejection. The Engineer and any authorized representatives shall at all times have access to the Work during its construction at shops and yards as well as the project site. The Contractor shall provide every reasonable facility for ascertaining that the materials and workmanship are in accordance with these specifications. Inspection of the Work shall not relieve the Contractor of the obligation to fulfill all conditions of the Contract. SECTION 3 - CHANGES IN WORK 3-1 CHANGES REQUESTED BY THE CONTRACTOR. 3-1.1 General. Changes in the Plans and Specifications, requested in writing by the Contractor, which do not materially affect the Work and which are not detrimental to the Work or to the interests of the Agency, may be granted by the Engineer. Nothing herein shall be construed as granting a right to the Contractor to demand acceptance of such changes. 3-1.2 Payment for Changes Requested by the Contractor. If such changes are granted, they shall be made at a reduction in cost or no additional cost to the Agency. 3-2 CHANGES INITIATED BY THE AGENCY. 3-2.1 General. The Agency may change the Plans, Specifications, character of the work, or quantity of work provided the total arithmetic dollar value of all such changes, both additive and deductive, does not exceed 25 percent of the Contract Price. Should it become necessary to exceed this limitation, the change shall be by written Supplemental Agreement between the Contractor and Agency, unless both parties agree to proceed with the change by Change Order. Change Orders shall be in writing and state the dollar value of the change or established method of payment, any adjustment in contract time of completion, and when negotiated prices are involved, shall provide for the Contractor's signature indicating acceptance. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 64 of 139 3-2.2 Payment. 3-2.2.1 Contract Unit Prices. If a change is ordered in an item of work covered by a Contract Unit Price, and such change does not involve substantial change in character of the work from that shown on the Plans or specified in the Specifications, then an adjustment in payment will be made. This adjustment will be based upon the increase or decrease in quantity and the Contract Unit Price. If the actual quantity of an item of work covered by a Contract Unit Price and constructed in conformance with the Plans and Specifications varies from the Bid quantity by 50 percent or less, payment will be made at the Contract Unit Price. If the actual quantity of said item of work varies from the Bid quantity by more than 50 percent, payment will be made per Section 3-2.2.2 or 3-2.2.3 as appropriate. If a change is ordered in an item of work covered by a Contract Unit Price, and such change does involve a substantial change in the character of the work from that shown on the Plans or specified in the Specifications, an adjustment in payment will be made per Section 3-2.4. 3-2.2.2 Increases of More Than 50 Percent. Should the actual quantity of an item of work covered by a Contract Unit Price and constructed in conformance with the Plans and Specifications, exceed the Bid quantity by more than 50 percent, payment for the quantity in excess of 125 percent of the Bid quantity will be made on the basis of an adjustment in the Contract Unit Price mutually agreed to by the Contractor and the Agency, or at the option of the Engineer, on the basis of Extra Work per Section 3-3. The Extra Work per Section 3-3, basis of payment, shall not include fixed costs. Fixed costs shall be deemed to have been recovered by the Contractor through payment for 150 percent of the Bid quantity at the Contract Unit Price. 3-2.2.3 Decreases of More Than 50 Percent. Should the actual quantity of an item of work covered by a Contract Unit Price, and constructed in conformance with the Plans and Specifications, be less than 50 percent of the Bid quantity, an adjustment in payment will not be made unless so requested in writing by the Contractor. If the Contractor so requests, payment will be made on the basis of an adjustment in the Contract Unit Price mutually agreed to by the Contractor and the Agency, or at the option of the Engineer, on the basis of Extra Work per Section 3-3; however, in no case will payment be less than would be made for the actual quantity at the Contract Unit Price nor more than would be made for 50 percent of the Bid quantity at the Contract Unit Price. 3-2.3 Stipulated Unit Prices. Stipulated Unit Prices are unit prices established by the Agency in the Contract Documents as distinguished from Contract Unit Prices submitted by the Contractor. Stipulated Unit Prices may be used for the adjustment of Contract changes when so specified in the Special Provisions. 3-2.4 Agreed Prices. Agreed Prices are prices for new or unforeseen work, or adjustments in Contract Unit Prices per Section 3-2.2, established by mutual agreement between the Contractor and the Agency. If mutual agreement can not be reached, the Engineer may direct the Contractor to proceed on the basis of Extra Work in accordance per Section 3-3, except as otherwise specified in Sections 3-2.2.2 and 3-2.2.3. 3.2.4.1 Schedule of Values. Prior to construction, Contractor shall provide a schedule of values for all lump sum bid items that shall be used for the purpose of progress payments. The prices shall be valid for the purpose of change orders to the project. m¥ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 65 of 139 3.2.5 Eliminated Items. Should any Bid item be eliminated in its entirety, payment will be made to the Contractor for its actual costs incurred in connection with the eliminated item prior to notification in writing from the Engineer so stating its elimination. If material conforming to the Plans and Specifications is ordered by the Contractor for use in the eliminated item prior to the date of notification of elimination by the Engineer, and if the order for that material can not be canceled, payment will be made to the Contractor for the actual cost of the material. In this case, the material shall become the property of the Agency. Payment will be made to the Contractor for its actual costs for any further handling. If the material is returnable, the material shall be returned and payment will be made to the Contractor for the actual cost of charges made by the supplier for returning the material and for handling by the Contractor. Actual costs, as used herein, shall be computed on the basis of Extra Work per Section 3-3. 3-3 EXTRA WORK. 3-3.1 General. New or unforeseen work will be classified as "extra work" when the Engineer determines that it is not covered by Contract Unit Prices or stipulated unit prices. 3-3.2 Payment. 3-3.2.1 General. When the price for the extra work cannot be agreed upon, the Agency will pay for the extra work based on the accumulation of costs as provided herein. 3-3.2.2 Basis for Establishing Costs. (a) Labor. The costs of labor will be the actual cost for wages of workers performing the extra work at the time the extra work is done, plus employer payments of payroll taxes, workers compensation insurance, liability insurance, health and welfare, pension, vacation, apprenticeship funds, and other direct costs, resulting from Federal, State, or local laws, as well as assessments or benefits required by lawful collective bargaining agreements. The use of a labor classification which would increase the extra work cost will not be permitted unless the Contractor establishes the necessity for such additional costs. Labor costs for equipment operators and helpers shall be reported only when such costs are not included in the invoice for equipment rental. The labor cost for foremen shall be proportioned to all of their assigned work and only that applicable to extra work will be paid. Nondirect labor costs, including superintendence, shall be considered part of the markup of Section 3-3.2.3 (a). (b) Materials. The cost of materials reported shall be at invoice or lowest current price at which such materials are locally available and delivered to the job site in the quantities involved, plus sales tax, freight, and delivery. The Agency reserves the right to approve materials and sources of supply, or to supply materials to the Contractor if necessary for the progress of the Work. No markup shall be applied to any material provided by the Agency. (c) Tool and Equipment Rental. No payment will be made for the use of tools which have a replacement value of $200 or less. Regardless of ownership, the rates and right-of-way delay factors to be used in determining rental and delay costs shall be the edition of the, "Labor Surcharge and Equipment Rental Rates" Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 66 of 139 published by CALTRANS, current at the time of the actual use of the tool or equipment. The right-of- way delay factors therein shall be used as multipliers of the rental rates for determining the value of costs for delay to the Contractor and subcontractors, if any. The labor surcharge rates published therein are not a part of this contract. The rental rates paid shall include the cost of fuel, oil, lubrication, supplies, small tools, necessary attachments, repairs and maintenance of any kind, depreciation, storage, insurance, and all incidentals. Necessary loading and transportation costs for equipment used on the extra work shall be included. If equipment is used intermittently and, when not in use, could be returned to its rental source at less expense to the Agency than holding it at the Work site, it shall be returned, unless the Contractor elects to keep it at the Work site, at no expense to the Agency. All equipment shall be acceptable to the Engineer, in good working condition, and suitable for the purpose for which it is to be used. Manufacturer's ratings and approved modifications shall be used to classify equipment and it shall be powered by a unit of at least the minimum rating recommended by the manufacturer. The reported rental time for equipment already at the Work site shall be the duration of its use on the extra work. This time begins when equipment is first put into actual operation on the extra work, plus the time required to move it from its previous site and back, or to a closer site. (d) Other Items. The Agency may authorize other items which may be required on the extra work, including labor, services, material, and equipment. These items must be different in their nature from those required for the Work, and be of a type not ordinarily available from the Contractor or Subcontractors. Invoices covering all such items in detail shall be submitted with the request for payment. (e) Invoices. Vendors' invoices for material, equipment rental and other expenditures shall be submitted with the request for payment. If the request for payment is not substantiated by invoices or other documentation, the Agency may establish the cost of the item involved at the lowest price which was current at the time of the report. 3-3.2.3 Markup. (a) Work by Contractor. The following percentages shall be added to the Contractor's costs and shall constitute the markup for all overhead and profits: 1) Labor 20 2) Materials 15 3) Equipment Rental 15 4) Other Items and Expenditures .. 15 To the sum of the costs and markups provided for in this section, 1 percent shall be added as compensation for bonding. (b) Work by Subcontractor. When all or any part of the extra work is performed by a Subcontractor, the markup established in Section 3-3.2.3(a) shall be applied to the Subcontractor's actual cost of such work. A markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of $5,000 of the subcontracted portion of the extra work may be added by the Contractor. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 67 of 139 3-3.3 Daily Reports by Contractor. When the price for the extra work cannot be agreed upon, the Contractor shall submit a daily report to the Engineer on forms approved by the Agency. Included are applicable delivery tickets, listing all labor, materials, and equipment involved for that day, and other services and expenditures when authorized. Payment for extra work will not be made until such time that the Contractor submits completed daily reports and all supporting documents to the Engineer. Failure to submit the daily report by the close of the next working day may waive any rights for that day. An attempt shall be made to reconcile the report daily, and it shall be signed by the Engineer and the Contractor. In the event of disagreement, pertinent notes shall be entered by each party to explain points which cannot be resolved immediately. Each party shall retain a signed copy of the report. Reports by Subcontractors or others shall be submitted through the Contractor. The report shall: 1 . Show names of workers, classifications, and hours worked. 2. Describe and list quantities of materials used. 3. Show type of equipment, size, identification number, and hours of operation, including loading and transportation, if applicable. 4. Describe other services and expenditures in such detail as the Agency may require. 3-4 CHANGED CONDITIONS. The Contractor shall promptly notify the Engineer of the following Work site conditions (hereinafter called changed conditions), in writing, upon their discovery and before they are disturbed: 1. Subsurface or latent physical conditions differing materially from those represented in the Contract; 2. Unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character being performed; and 3. Material differing from that represented in the Contract which the Contractor believes may be hazardous waste, as defined in Section 25117 of the Health and Safety Code, that is re- quired to be removed to a Class I, Class II, or Class III disposal site in accordance with provisions of existing law. The Engineer will promptly investigate conditions which appear to be changed conditions. If the Engineer determines that conditions are changed conditions and they will materially affect performance time, the Contractor, upon submitting a written request, will be granted an extension of time subject to the provisions of 6-6. If the Engineer determines that the conditions do not justify an adjustment in compensation, the Contractor will be notified in writing. This notice will also advise the Contractor of its obligation to notify the Engineer in writing if the Contractor disagrees. The Contractor's failure to give notice of changed conditions promptly upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith. The Contractor shall not be entitled to the payment of any additional compensation for any act, or failure to act, by the Engineer, including failure or refusal to issue a change order, or for the Revised 5/01/08 Contract No. 5201 1 (Industrial Park RW Service Lines) Page 68 of 139 happening of any event, thing, occurrence, or other cause, unless the Contractor shall have first given the Engineer due written notice of potential claim as hereinafter specified. Compliance with this section shall not be required as a prerequisite to notice provisions in Section 6-7.3 Contract Time Accounting, nor to any claim that is based on differences in measurement or errors of computation as to contract quantities. The written notice of potential claim for changed conditions shall be submitted by the Contractor to the Engineer upon their discovery and prior to the time that the Contractor performs the work giving rise to the potential claim. The Contractor's failure to give written notice of potential claim for changed conditions to the agency upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith. The Contractor shall provide the District with a written document containing a description of the particular circumstances giving rise to the potential claim, the reasons for which the Contractor believes additional compensation may be due and nature of any and all costs involved within 20 working days of the date of service of the written notice of potential claim for changed conditions. Verbal notifications are disallowed. The potential claim shall include the following certification relative to the California False Claims Act, Government Code Sections 12650-12655. "The undersigned certifies that the above statements are made in full cognizance of the California False Claims Act, Government Code Sections 12650-12655. The undersigned further understands and agrees that this potential claim, unless resolved, must be restated as a claim in response to the City's proposed final estimate in order for it to be further considered." By: Title: Date: Company Name: The Contractor's estimate of costs may be updated when actual costs are known. The Contractor shall submit substantiation of its actual costs to the Engineer within 20 working days after the affected work is completed. Failure to do so shall be sufficient cause for denial of any claim subsequently filed on the basis of said notice of potential claim. It is the intention of this section that differences between the parties arising under and by virtue of the contract be brought to the attention of the Engineer at the earliest possible time in order that such matters be settled, if possible, or other appropriate action promptly taken. 3-5 DISPUTED WORK. The Contractor shall give the agency written notice of potential claim prior to commencing any disputed work. Failure to give said notice shall constitute a waiver of all claims in connection therewith. If the contractor and the agency are unable to reach agreement on disputed work, the Agency may direct the contractor to proceed with the work. Prior to proceeding with dispute resolution pursuant to Public Contract Code provisions specified hereinafter, the contractor shall attempt to resolve all disputes informally through the following dispute resolution chain of command: Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 69 of 139 1. Project Inspector 2. Construction Manager 3. Deputy City Engineer, Construction Management & Inspection 4. City Engineer 5. General Manager The Contractor shall submit a complete report within 20 working days after completion of the disputed work stating its position on the claim, the contractual basis for the claim, along with all documentation supporting the costs and all other evidentiary materials. At each level of claim or appeal of claim the District will, within 10 working days of receipt of said claim or appeal of claim, review the Contractor's report and respond with a position, request additional information or request that the Contractor meet and present its report. When additional information or a meeting is requested the District will provide its position within 10 working days of receipt of said additional information or Contractor's presentation of its report. The Contractor may appeal each level's position up to the General Manager after which the Contractor may proceed under the provisions of the Public Contract Code. The authority within the dispute resolution chain of command is limited to recommending a resolution to a claim to the General Manager. Actual approval of the claim is subject to the change order provisions in the contract. All claims by the contractor for $375,000 or less shall be resolved in accordance with the procedures in the Public Contract Code, Division 2, Part 3, Chapter 1, Article 1.5 (commencing with Section 20104) which is set forth below: ARTICLE 1.5 RESOLUTION OF CONSTRUCTION CLAIMS 20104. (a)(1) This article applies to all public works claims of three hundred seventy-five thousand dollars ($375,000) or less which arise between a contractor and a local agency. (2) This article shall not apply to any claims resulting from a contract between a contractor and a public agency when the public agency has elected to resolve any disputes pursuant to Article 7.1 (commencing with Section 10240) of Chapter 1 of Part 2. (b)(1) "Public work" has the same meaning as in Sections 3100 and 3106 of the Civil Code, except that "public work" does not include any work or improvement contracted for by the state or the Regents of the University of California. (2) "Claim" means a separate demand by the contractor for (A) a time extension, (B) payment of money or damages arising from work done by, or on behalf of, the contractor pursuant to the contract for a public work and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to, or (C) an amount the payment of which is disputed by the local agency. (c) The provisions of this article or a summary thereof shall be set forth in the plans or specifications for any work which may give rise to a claim under this article. (d) This article applies only to contracts entered into on or after January 1, 1991. 20104.2. For any claim subject to this article, the following requirements apply: (a) The claim shall be in writing and include the documents necessary to substantiate the claim. Claims must be filed on or before the date of final payment. Nothing in this subdivision is intended to extend the time limit or supersede notice requirements otherwise provided by contract for the filing of claims. (b)(1) For claims of less than fifty thousand dollars ($50,000), the local agency shall respond in writing to any written claim within 45 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 70 of 139 (2) If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of the local agency and the claimant. (3) The local agency's written response to the claim, as further documented, shall be submitted to the claimant within 15 days after receipt of the further documentation or within a period of time no greater than that taken by the claimant in producing the additional information, whichever is greater. (c)(1) For claims of over fifty thousand dollars ($50,000) and less than or equal to three hundred seventy-five thousand dollars ($375,000), the local agency shall respond in writing to all written claims within 60 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant. (2) If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of the local agency and the claimant. (3) The local agency's written response to the claim, as further documented, shall be submitted to the claimant within 30 days after receipt of the further documentation, or within a period of time no greater than that taken by the claimant in producing the additional information or requested documentation, whichever is greater. (d) If the claimant disputes the local agency's written response, or the local agency fails to respond within the time prescribed, the claimant may so notify the local agency, in writing, either within 15 days of receipt of the local agency's response or within 15 days of the local agency's failure to respond within the time prescribed, respectively, and demand an informal conference to meet and confer for settlement of the issues in dispute. Upon a demand, the local agency shall schedule a meet and confer conference within 30 days for settlement of the dispute. (e) Following the meet and confer conference, if the claim or any portion remains in dispute, the claimant may file a claim as provided in Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the claimant submits his or her written claim pursuant to subdivision (a) until the time that claim is denied as a result of the meet and confer process, including any period of time utilized by the meet and confer process. (f) This article does not apply to tort claims and nothing in this article is intended nor shall be construed to change the time periods for filing tort claims or actions specified by Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. 20104.4. The following procedures are established for all civil actions filed to resolve claims subject to this article: (a) Within 60 days, but no earlier than 30 days, following the filing or responsive pleadings, the court shall submit the matter to non-binding mediation unless waived by mutual stipulation of both parties. The mediation process shall provide for the selection within 15 days by both parties of a disinterested third person as mediator, shall be commenced within 30 days of the submittal, and shall be concluded within 15 days from the commencement of the mediation unless a time requirement is extended upon a good cause showing to the court or by stipulation of both parties. If the parties fail to select a mediator within the 15-day period, any party may petition the court to appoint the mediator. (b)(1) If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, notwithstanding Section 1141.11 of that code. The Civil Discovery Act of 1986 (Article 3 (commencing with Section 2016) of Chapter 3 of Title 3 of Part 4 of the Code of Civil procedure) shall apply to any proceeding brought under the subdivision consistent with the rules pertaining to judicial arbitration. (2) Notwithstanding any other provision of law, upon stipulation of the parties, arbitrators appointed for purposes of this article shall be experienced in construction law, and, upon stipulation of the Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 71 of 139 parties, mediators and arbitrators shall be paid necessary and reasonable hourly rates of pay not to exceed their customary rate, and such fees and expenses shall be paid equally by the parties, except in the case of arbitration where the arbitrator, for good cause, determines a different division. In no event shall these fees or expenses be paid by state or county funds. (3) In addition to Chapter 2.5 (commencing with Section 1141.10) Title 3 of Part 3 of the Code of Civil Procedure, any party who after receiving an arbitration award requests a trial de novo but does not obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, pay the attorney's fees of the other party arising out of the trial de novo. (c) The court may, upon request by any party, order any witnesses to participate in the mediation or arbitration process. 20104.6. (a) No local agency shall fail to pay money as to any portion of a claim which is undisputed except as otherwise provided in the contract. (b) In any suit filed under Section 20104.4, the local agency shall pay interest at the legal rate on any arbitration award or judgment. The interest shall begin to accrue on the date the suit is filed in a court of law. Although not to be construed as proceeding under extra work provisions, the Contractor shall keep and furnish records of disputed work in accordance with Section 3-3. SECTION 4 - CONTROL OF MATERIALS 4-1 MATERIALS AND WORKMANSHIP. 4-1.1. General. All materials, parts, and equipment furnished by the Contractor in the Work shall be new, high grade, and free from defects. Quality of work shall be in accordance with the generally accepted standards. Material and work quality shall be subject to the Engineer's approval. Materials and work quality not conforming to the requirements of the Specifications shall be considered defective and will be subject to rejection. Defective work or material, whether in place or not, shall be removed immediately from the site by the Contractor, at its expense, when so directed by the Engineer. If the Contractor fails to replace any defective or damaged work or material after reasonable notice, the Engineer may cause such work or materials to be replaced. The replacement expense will be deducted from the amount to be paid to the Contractor. Used or secondhand materials, parts, and equipment may be used only if permitted by the Specifications. 4-1.2 Protection of Work and Materials. The Contractor shall provide and maintain storage facilities and employ such measures as will preserve the specified quality and fitness of materials to be used in the Work. Stored materials shall be reasonably accessible for inspection. The Contractor shall also adequately protect new and existing work and all items of equipment for the duration of the Contract. The Contractor shall not, without the Agency's consent, assign, sell, mortgage, hypothecate, or remove equipment or materials which have been installed or delivered and which may be necessary for the completion of the Contract. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 72 of 139 4-1.3 Inspection Requirements. 4-1.3.1 General. Unless otherwise specified, inspection is required at the source for such typical materials and fabricated items as bituminous paving mixtures, structural concrete, metal fabrication, metal casting, welding, concrete pipe manufacture, protective coating application, and similar shop or plant operations. Steel pipe in sizes less than 18 inches and vitrified clay and cast iron pipe in all sizes are acceptable upon certification as to compliance with the Specifications, subject to sampling and testing by the Agency. Standard items of equipment such as electric motors, conveyors, elevators, plumbing fixtures, etc., are subject to inspection at the job site only. Special items of equipment such as designed electrical panel boards, large pumps, sewage plant equipment, etc., are subject to inspection at the source, normally only for performance testing. The Specifications may require inspection at the source for other items not typical of those listed in this section. The Contractor shall provide the Engineer free and safe access to any and all parts of work at any time. Such free and safe access shall include means of safe access and egress, ventilation, lighting, shoring, dewatering and all elements pertaining to the safety of persons as contained in the State of California, California Code of Regulations, Title 8, Industrial Relations, Chapter 4, Division of Industrial Safety, Subchapter 4, Construction Safety Orders and such other safety regulations as may apply. Contractor shall furnish Engineer with such information as may be necessary to keep the Engineer fully informed regarding progress and manner of work and character of materials. Inspection or testing of the whole or any portion of the work or materials incorporated in the work shall not relieve Contractor from any obligation to fulfill this Contract. 4-1.3.2 Inspection of Materials Not Locally Produced. When the Contractor intends to purchase materials, fabricated products, or equipment from sources located more than 50 miles outside the geographical limits of the Agency, an inspector or accredited testing laboratory (approved by the Engineer), shall be engaged by the Contractor at its expense, to inspect the materials, equipment or process. This approval shall be obtained before producing any material or equipment. The inspector or representative of the testing laboratory shall judge the materiajs by the requirements of the Plans and Specifications. The Contractor shall forward reports required by the Engineer. No material or equipment shall be shipped nor shall any processing, fabrication or treatment of such materials be done without proper inspection by the approved agent. Approval by said agent shall not relieve the Contractor of responsibility for complying with the Contract requirements. 4-1.3.3 Inspection by the Agency. The Agency will provide all inspection and testing laboratory services within 50 miles of the geographical limits of the Agency. For private contracts, all costs of inspection at the source, including salaries and mileage costs, shall be paid by the permittee. 4-1.4 Test of Material. Before incorporation in the Work, the Contractor shall submit samples of materials, as the Engineer may require, at no cost to the Agency. The Contractor, at its expense, shall deliver the materials for testing to the place and at the time designated by the Engineer. Unless otherwise provided, all initial testing will be performed under the direction of the Engineer, and at no expense to the Contractor. If the Contractor is to provide and pay for testing, it will be stated in the Specifications. For private contracts, the testing expense shall be borne by the permittee. The Contractor shall notify the Engineer in writing, at least 15 days in advance, of its intention to use materials for which tests are specified, to allow sufficient time to perform the tests. The notice shall name the proposed supplier and source of material. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 73 of 139 If the notice of intent to use is sent before the materials are available for testing or inspection, or is sent so far in advance that the materials on hand at the time will not last but will be replaced by a new lot prior to use on the Work, it will be the Contractor's responsibility to renotify the Engineer when samples which are representative may be obtained. Except as specified in these Provisions, the Agency will bear the cost of testing of locally produced materials and/or on-site workmanship where the results of such tests meet or exceed the requirements indicated in the Standard Specifications, Technical Specification, and any Supplemental Provisions. The cost of all other tests shall be borne by the Contractor. At the option of the Engineer, the source of supply of each of the materials shall be approved by the Engineer before the delivery is started. All materials proposed for use may be inspected or tested at any time during their preparation and use. If, after incorporating such materials into the Work, it is found that sources of supply that have been approved do not furnish a uniform product, or if the product from any source proves unacceptable at any time, the Contractor shall furnish approved material from other approved sources. If any product proves unacceptable after improper storage, handling or for any other reason it shall be rejected, not incorporated into the work and shall be removed from the project site all at the Contractor's expense. Compaction tests may be made by the Engineer and all costs for tests that meet or exceed the requirements of the specifications shall be borne by the Agency. Said tests may be made at any place along the work as deemed necessary by the Engineer. The costs of any retests made necessary by noncompliance with the specifications shall be borne by the Contractor. 4-1.5 Certification. The Engineer may waive materials testing requirements of the Specifications and accept the manufacturer's written certification that the materials to be supplied meet those requirements. Material test data may be required as part of the certification. 4-1.6 Trade Names or Equals. The Contractor may supply any of the materials specified or offer an equivalent. The Engineer shall determine whether the material offered is equivalent to that specified. Adequate time shall be allowed for the Engineer to make this determination. Whenever any particular material, process, or equipment is indicated by patent, proprietary or brand name, or by name of manufacturer, such wording is used for the purpose of facilitating its description and shall be deemed to be followed by the words or equal. A listing of materials is not intended to be comprehensive, or in order of preference. The Contractor may offer any material, process, or equipment considered to be equivalent to that indicated. The substantiation of offers shall be submitted as provided in the contract documents. The Contractor shall, at its expense, furnish data concerning items offered by it as equivalent to those specified. The Contractor shall have the material tested as required by the Engineer to determine that the quality, strength, physical, chemical, or other characteristics, including durability, finish, efficiency, dimensions, service, and suitability are such that the item will fulfill its intended function. Test methods shall be subject to the approval of the Engineer. Test results shall be reported promptly to the Engineer, who will evaluate the results and determine if the substitute item is equivalent. The Engineer's findings shall be final. Installation and use of a substitute item shall not be made until approved by the Engineer. If a substitute offered by the Contractor is not found to be equal to the specified material, the Contractor shall furnish and install the specified material. Revised 5/01/08 Contract No. 5201 1 (Industrial Park RW Service Lines) Page 74 of 1 39 The specified Contract completion time shall not be affected by any circumstance developing from the provisions of this section. The Contractor is responsible for the satisfactory performance of substituted items. If, in the sole opinion of the Engineer, the substitution is determined to be unsatisfactory in performance, appearance, durability, compatibility with associated items, availability of repair parts and suitability of application the Contractor shall remove the substituted item and replace it with the originally specified item at no cost to the Agency. 4-1.7 Weighing and Metering Equipment. All scales and metering equipment used for proportioning materials shall be inspected for accuracy and certified within the past 12 months by the State of California Bureau of Weights and Measures, by the County Director or Sealer of Weights and Measures, or by a scale mechanic registered with or licensed by the County. The accuracy of the work of a scale service agency, except as stated herein, shall meet the standards of the California Business and Professions Code and the California Code of Regulations pertaining to weighing devices. A certificate of compliance shall be presented, prior to operation, to the Engineer for approval and shall be renewed whenever required by the Engineer at no cost to the Agency. All scales shall be arranged so they may be read easily from the operator's platform or area. They shall indicate the true net weight without the application of any factor. The figures of the scales shall be clearly legible. Scales shall be accurate to within 1 percent when tested with the plant shut down. Weighing equipment shall be so insulated against vibration or moving of other operating equipment in the plant area that the error in weighing with the entire plant running will not exceed 2 percent for any setting nor 1.5 percent for any batch. 4-1.8 Calibration of Testing Equipment. Testing equipment, such as, but not limited to pressure gages, metering devices, hydraulic systems, force (load) measuring instruments, and strain- measuring devices shall be calibrated by a testing agency acceptable to the Engineer at intervals not to exceed 12 months and following repairs, modification, or relocation of the equipment. Calibration certificates shall be provided when requested by the Engineer. 4-1.9 Construction Materials Dispute Resolution (Soils, Rock Materials, Concrete, Mortar and Related Materials, Masonry Materials, Bituminous Materials, Rock Products, and Modified Asphalts). In the interest of safety and public value, whenever credible evidence arises to contradict the test values of materials, the Agency and the Contractor will initiate an immediate and cooperative investigation. Test values of materials are results of the materials' tests, as defined by these Specifications or by the special provisions, required to accept the Work. Credible evidence is process observations or test values gathered using industry accepted practices. A contradiction exists whenever test values or process observations of the same or similar materials are diverse enough such that the work acceptance or performance becomes suspect. The investigation shall allow access to all test results, procedures, and facilities relevant to the disputed work and consider all available information and, when necessary, gather new and additional information in an attempt to determine the validity, the cause, and if necessary, the remedy to the contradiction. If the cooperative investigation reaches any resolution mechanism acceptable to both the Agency and the Contractor, the contradiction shall be considered resolved and the cooperative investigation concluded. Whenever the cooperative investigation is unable to reach resolution, the investigation may then either conclude without resolution or continue by written notification of one party to the other requesting the implementation of a resolution process by committee. The continuance of the investigation shall be contingent upon recipient's agreement and acknowledged in writing within 3 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 75 of 139 calendar days after receiving a request. Without acknowledgement, the investigation shall conclude without resolution. The committee shall consist of three State of California Registered Civil Engineers. Within 7 calendar days after the written request notification, the Agency and the Contractor will each select one engineer. Within 14 calendar days of the written request notification, the two selected engineers will select a third engineer. The goal in selection of the third member is to complement the professional experience of the first two engineers. Should the two engineers fail to select the third engineer, the Agency and the Contractor shall each propose 2 engineers to be the third member within 21 calendar days after the written request notification. The first two engineers previously selected shall then select one of the four proposed engineers in a blind draw. The committee shall be a continuance of the cooperative investigation and will re-consider all available information and if necessary gather new and additional information to determine the validity, the cause, and if necessary, the remedy to the contradiction. The committee will focus upon the performance adequacy of the material(s) using standard engineering principles and practices and to ensure public value, the committee may provide engineering recommendations as necessary. Unless otherwise agreed, the committee will have 30 calendar days from its formation to complete their review and submit their findings. The final resolution of the committee shall be by majority opinion, in writing, stamped and signed. Should the final resolution not be unanimous, the dissenter may attach a written, stamped, and signed minority opinion. Once started, the resolution process by committee shall continue to full conclusion unless: 1. Within 7 days of the formation of the committee, the Agency and the Contractor reach an acceptable resolution mechanism; or 2. Within 14 days of the formation of the committee, the initiating party withdraws its written notification and agrees to bear all investigative related costs thus far incurred; or 3. At any point by the mutual agreement of the Agency and the Contractor. Unless otherwise agreed, the Contractor shall bear and maintain a record for all the investigative costs until resolution. Should the investigation discover assignable causes for the contradiction, the assignable party, the Agency or the Contractor, shall bear all costs associated with the investigation. Should assignable causes for the contradiction extended to both parties, the investigation will assign costs cooperatively with each party or when necessary, equally. Should the investigation substantiate a contradiction without assignable cause, the investiga- tion will assign costs cooperatively with each party or when necessary, equally. Should the investigation be unable to substantiate a contradiction, the initiator of the investigation shall bear all investigative costs. All claim notification requirements of the contract pertaining to the contradiction shall be suspended until the investigation is concluded. 4-2 MATERIALS TRANSPORTATION, HANDLING AND STORAGE. The Contractor shall order, purchase, transport, coordinate delivery, accept delivery, confirm the quantity and quality received, prepare storage area(s), store, handle, protect, move, relocate, remove and dispose excess of all materials used to accomplish the Work. Materials shall be delivered to the site of the work only during working hours, as defined in Section 6-7.2, and shall be accompanied by bills of lading that shall clearly state for each delivery: the name of the Contractor as consignee, the project name and number, address of delivery and name of consignor and a description of the material(s) shipped. Prior to storage of any materials which have been shipped to or by the Contractor to any location within the Agency's boundaries the Contractor shall provide the Engineer a copy of lease agreements for each property where such materials are stored. The lease agreement shall clearly state the term of the lease, the description of materials allowed to be stored and shall provide for the removal of the materials and restoration of the storage site within the time allowed for the Work. All such storage shall conform to all laws and ordinances that may pertain to the materials stored and to preparation of the storage site and the location of the site on which the Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 76 of 139 materials are stored. Loss, damage or deterioration of all stored materials shall be the Contractor's responsibility. Conformance to the requirements of this section, both within and outside the limits of work are a part of the Work. The Engineer shall have the right to verify the suitability of materials and their proper storage at any time during the Work. SECTION 5-UTILITIES 5-1 LOCATION. The Agency and affected utility companies have, by a search of known records, endeavored to locate and indicate on the Plans, all utilities which exist within the limits of the work. However, the accuracy and/or completeness of the nature, size and/or location of utilities indicated on the Plans is not guaranteed. Where underground main distribution conduits such as water, gas, sewer, electric power, telephone, or cable television are shown on the Plans, the Contractor shall assume that every property parcel will be served by a service connection for each type of utility. As provided in Section 4216 of the California Government Code, at least 2 working days prior to commencing any excavation, the Contractor shall contact the regional notification center (Underground Service Alert of Southern California) and obtain an inquiry identification number. The California Department of Transportation is not required by Section 4216 to become a member of the regional notification center. The Contractor shall contact it for location of its subsurface installations. The Contractor shall determine the location and depth of all utilities, including service connections, which have been marked by the respective owners and which may affect or be affected by its operations. If no pay item is provided in the Contract for this work, full compensation for such work shall be considered as included in the prices bid for other items of work. 5-2 PROTECTION. The Contractor shall not interrupt the service function or disturb the support of any utility without authority from the owner or order from the Agency. All valves, switches, vaults, and meters shall be maintained readily accessible for emergency shutoff. Where protection is required to ensure support of utilities located as shown on the Plans or in accordance with Section 5-1, the Contractor shall, unless otherwise provided, furnish and place the necessary protection at its expense. Upon learning of the existence and location of any utility omitted from or shown incorrectly on the Plans, the Contractor shall immediately notify the Engineer in writing. When authorized by the Engineer, support or protection of the utility will be paid for as provided in Section 3-2.2.3 or 3-3. The Contractor shall immediately notify the Engineer and the utility owner if any utility is disturbed or damaged. The Contractor shall bear the costs of repair or replacement of any utility damaged if located as noted in Section 5-1. When placing concrete around or contiguous to any non-metallic utility installation, the Contractor shall at its expense: 1. Furnish and install a 2 inch cushion of expansion joint material or other similar resilient material; or 2. Provide a sleeve or other opening which will result in a 2 inch minimum-clear annular space between the concrete and the utility; or Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 77 of 139 3. Provide other acceptable means to prevent embedment in or bonding to the concrete. /*8>fe^ Where concrete is used for backfill or for structures which would result in embedment, or partial %»« embedment, of a metallic utility installation; or where the coating, bedding or other cathodic protection system is exposed or damaged by the Contractor's operations, the Contractor shall notify the Engineer and arrange to secure the advice of the affected utility owner regarding the procedures required to maintain or restore the integrity of the system. 5-3 REMOVAL. Unless otherwise specified, the Contractor shall remove all interfering portions of utilities shown on the Plans or indicated in the Bid documents as "abandoned" or "to be abandoned in place". Before starting removal operations, the Contractor shall ascertain from the Agency whether the abandonment is complete, and the costs involved in the removal and disposal shall be included in the Bid for the items of work necessitating such removals. 5-4 RELOCATION. When feasible, the owners responsible for utilities within the area affected by the Work will complete their necessary installations, relocations, repairs, or replacements before commencement of work by the Contractor. When the Plans or Specifications indicate that a utility installation is to be relocated, altered, or constructed by others, the Agency will conduct all negotiations with the owners and work will be done at no cost to the Contractor, except for manhole frame and cover sets to be brought to grade. After award of the Contract, portions of utilities which are found to interfere with the Work will be relocated, altered or reconstructed by the owners, or the Engineer may order changes in the Work to avoid interference. Such changes will be paid for in accordance with Section 3-2. When the Plans or Specifications provide for the Contractor to alter, relocate, or reconstruct a utility, all costs for such work shall be included in the Bid for the items of work necessitating such work. ^•^ Temporary or permanent relocation or alteration of utilities requested by the Contractor for its ^j convenience shall be its responsibility and it shall make all arrangements and bear all costs. "**"** 5-5 DELAYS. The Contractor shall notify the Engineer of its construction schedule insofar as it affects the protection, removal, or relocation of utilities. Said notification shall be included as a part of the construction schedule required in Section 6-1. The Contractor shall notify the Engineer in writing of any subsequent changes in the construction schedule which will affect the time available for protection, removal, or relocation of utilities. The Contractor will not be entitled to damages or additional payment for delays attributable to utility relocations or alterations if correctly located, noted, and completed in accordance with Section 5-1. The Contractor may be given an extension of time for unforeseen delays attributable to unreasonably protracted interference by utilities in performing work correctly shown on the Plans. The Agency will assume responsibility for the timely removal, relocation, or protection of existing main or trunkline utility facilities within the area affected by the Work if such utilities are not identified in the Contract Documents. The Contractor will not be assessed liquidated damages for any delay caused by failure of Agency to provide for the timely removal, relocation, or protection of such existing facilities. If the Contractor sustains loss due to delays attributable to interferences, relocations, or alterations not covered by Section 5-1, which could not have been avoided by the judicious handling of forces, equipment, or plant, there shall be paid to the Contractor such amount as the Engineer may find to be fair and reasonable compensation for such part of the Contractor's actual loss as was unavoidable and the Contractor may be granted an extension of time. •**"%, Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 78 of 139 5-6 COOPERATION. When necessary, the Contractor shall so conduct its operations as to <•**"'"" permit access to the Work site and provide time for utility work to be accomplished during the s^ progress of the Work. SECTION 6 - PROSECUTION, PROGRESS, AND ACCEPTANCE OF THE WORK 6-1 CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK. Except as otherwise provided herein and unless otherwise prohibited by permits from other agencies as may be required by law the Contractor shall begin work within 14 calendar days after receipt of the "Notice to Proceed". 6-1.1 Pre-Construction Meeting. After, or upon, notification of contract award, the Engineer will set the time and location for the Preconstruction Meeting. Attendance of the Contractor's management personnel responsible for the management, administration, and execution of the project is mandatory for the meeting to be convened. Failure of the Contractor to have the Contractor's responsible project personnel attend the Preconstruction Meeting will be grounds for default by Contractor per Section 6-4. No separate payment will be made for the Contractor's attendance at the meeting. The notice to proceed will only be issued on or after the completion of the Preconstruction meeting. 6-1.1.1 Baseline Construction Schedule Submittal. The Contractor shall submit the Baseline Construction Schedule per the submittal requirements of Section 2-5.3. The submittal of the Baseline Construction Schedule shall include each item and element of Sections 6-1.2 through 6- 1.2.9 and shall be on hard (paper) copy and electronic media conforming to Section 6-1.3.3 Electronic Media. 6-1.2 Preparation and Review of the Baseline Construction Schedule. The Contractor shall prepare the Baseline Construction Schedule as a Critical Path Method (CPM) Schedule in the precedence diagram method (activity-on-node) format. The Baseline Construction Schedule shall depict a workable plan showing the sequence, duration, and interdependence of all activities required to represent the complete performance of all project work as well as periods where work is precluded. The Baseline Construction Schedule shall begin with the projected date of issuance of the notice to proceed and conclude with the date of final completion per the contract duration. The Baseline Construction Schedule shall include detail of all project phasing, staging, and sequencing, including all milestones necessary to define beginning and ending of each phase or stage. 6-1.2.1 Time-Scaled Network Diagram. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a complete time-scaled network diagram showing all of the activities, logic relationships, and milestones comprising the schedule. 6-1.2.2 Tabular Listing. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a tabular listing of all of the activities, showing for each activity the identification number, the description, the duration, the early start, the early finish, the late start, the late finish, the total float, and all predecessor and successor activities for the activity described. 6-1.2.3 Bar Chart. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a chart showing individual tasks and their durations arranged with the tasks on the vertical axis and duration on the horizontal axis. The bar chart shall use differing texture patterns or distinctive line types to show the critical path. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 79 of 139 6-1.2.4 Schedule Software. Not used 6-1.2.5 Schedule Activities. Except for submittal activities, activity durations shall not be shorter than 1 working day nor longer than 15 working days, unless specifically and individually allowed by the Engineer. 6-1.2.6 Float. Float or slack time within the schedule is available without charge or compensation to whatever party or contingency first exhausts it. 6-1.2.7 Restraints to Activities. Any submittals, utility interfaces, or any furnishing of Agency supplied materials, equipment, or services, which may impact any activity's construction shall be shown as a restraint to those activities. Time periods to accommodate the review and correction of submittals shall be included in the schedule. 6-1.2.8 Late Completion. A Baseline Construction Schedule showing a project duration longer than the specified contract duration will not be acceptable and will be grounds for determination of default by Contractor, per Section 6-4. 6-1.2.9 Early Completion. The Baseline Construction Schedule will show the Contractor's plan to support and maintain the project for the entire contractual time span of the project. Should the Contractor propose a project duration shorter than contract duration, a complete Baseline Construction Schedule must be submitted, reflecting the shorter duration, in complete accordance with all schedule requirements of Section 6-1. The Engineer may choose to accept the Contractor's proposal of a project duration shorter than the duration specified; provided the Agency is satisfied the shortened Baseline Construction Schedule is reasonable and the Agency and all other entities, public and private, which interface with the project are able to support the provisions of the shortened Baseline Construction Schedule. The Agency's acceptance of a shortened duration project will be confirmed through the execution of a contract change order revising the project duration and implementing all contractual requirements including liquidated damages in accordance with the revised duration. 6-1.2.10 Engineer's Review. The Construction Schedule is subject to the review of the Engineer. The Engineer's determination that the Baseline Construction Schedule proposed by the Contractor complies with the requirements of these supplemental provisions shall be a condition precedent to issuance of the Notice to Proceed by the Engineer. If the Engineer determines that the Construction Schedule does not meet the requirements of these specifications the Contractor shall correct the Construction Schedule to meet these specifications and resubmit it to the Engineer. Failure of the Contractor to obtain the Engineer's determination that the initial Construction Schedule proposed by the Contractor complies with the requirements of these supplemental provisions within thirty (30) working days after the date of the preconstruction meeting shall be grounds for termination of the contract per Section 6-4. Days used by the Engineer to review the initial Construction Schedule will not be included in the 30 working days. The Engineer will review and return to the Contractor, with any comments, the Baseline Construction Schedule within 15 working days of submittal. The Baseline Construction Schedule will be returned marked as per Sections 6-1.2.10.1 through 6-1.2.10.3. 6-1.2.10.1 "Accepted." The Contractor may proceed with the project work upon issuance of the Notice to Proceed, and will receive payment for the schedule in accordance with Section 6-1.8.1. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 80 of 139 6-1.2.10.2 "Accepted with Comments." The Contractor may proceed with the project work upon issuance of the Notice to Proceed. The Contractor must resubmit the schedule incorporating the comments prior to receipt of payment per Section 6-1.8.1. 6-1.2.10.3 "Not Accepted." The Contractor must resubmit the schedule incorporating the corrections and changes of the comments prior to receipt of payment per Section 6-1.8.1. The Notice to Proceed will not be issued by the Engineer if the changes of the comments are not submitted as required hereinbefore and marked "Accepted" or "Accepted with Comments" by the Engineer. The Contractor, at the sole option of the Engineer, may be considered as having defaulted the contract under the provisions of Section 6-4 DEFAULT BY CONTRACTOR if the changes of the comments are not submitted as required hereinbefore and marked "Accepted" by the Engineer. 6-1.3 Preparation of Schedule Updates and Revisions. The Contractor shall meet with the Engineer during the last week of each month to agree upon each activity's schedule status and shall submit monthly updates of the Baseline Construction Schedule confirming the agreements no later than the fifth working day of the following month. The monthly update will be submitted on hard (paper) copy and electronic media conforming to Section 6-1.3.3 Electronic Media per the submittal requirements of Section 2-5.3 and will include each item and element of Sections 6-1.2 through 6- 1.2.9 and 6-1.3.1 through 6-1.3.7. 6-1.3.1 Actual Activity Dates. The actual dates each activity was started and/or completed during the month. After first reporting an actual date, the Contractor shall not change that actual date in later updates without specific notification to the Engineer with the update. 6-1.3.2 Activity Percent Complete. For each activity underway at the end of the month, the Contractor shall report the percentage determined by the Engineer as complete for the activity. 6-1.3.3 Electronic Media. The schedule data disk shall be a CD-ROM, labeled with the project name and number, the Contractor's name and the date of preparation of the schedule data disk. The schedule data disk shall be readable by the software specified in Section 6-1.2.4 "Schedule Software" and shall be free of file locking, encryption or any other protocol that would impede full access of all data stored on it. 6-1.3.4 List of Changes. A list of all changes made to the activities or to the interconnecting logic, with an explanation for each change. 6-1.3.5 Change Orders. Each monthly update will include the addition of the network revisions reflecting the change orders approved in the previous month. The network revisions will be as agreed upon during the review and acceptance of the Contractor's change orders. 6-1.3.6 Bar Chart Each monthly update will include a chart showing individual tasks and their durations arranged with the tasks on the vertical axis and duration on the horizontal axis. The bar chart shall use differing texture patterns or distinctive line types to show the critical path. 6-1.4 Engineer's Review of Updated Construction Schedule. The Engineer will review and return the Updated Construction Schedule to the Contractor, with any comments, within 5 working days of submittal. The Updated Construction Schedule will be returned marked as per Sections 6- 1.4.1 through 6-1.4.3. Any Updated Construction Schedule marked "Accepted with Comments" or "Not Accepted" by the Engineer will be returned to the Contractor for correction. Upon resubmittal the Engineer will review and return the resubmitted Updated Construction Schedule to the Contractor, with any comments, within 5 working days. Failure of the Contractor to submit a monthly Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 81 of 139 updated construction schedule will invoke the same consequences as the Engineer returning a monthly updated construction schedule marked "Not Accepted". 6-1.4.1 "Accepted." The Contractor may proceed with the project work, and will receive payment for the schedule in accordance with Section 6-1.8.2. 6-1.4.2 "Accepted with Comments." The Contractor may proceed with the project work. The Contractor must resubmit the Updated Construction Schedule to the Engineer incorporating the corrections and changes noted in the Engineer's comments prior to receipt of payment per Section 6-1.8.2. 6-1.4.3 "Not Accepted." The Contractor must resubmit the Updated Construction Schedule to the Engineer incorporating the corrections and changes noted in the Engineer's comments prior to receipt of payment per Section 6-1.8.2. The Contractor, at the sole option of the Engineer, may be considered as having defaulted the contract under the provisions of Section 6-4 DEFAULT BY CONTRACTOR if the changes of the comments are not submitted and marked "Accepted" by the Engineer before the last day of the month in which the Updated Construction Schedule is due. If the Contractor fails to submit the corrected Updated Construction Schedule as required herein the Contractor may elect to proceed with the project at its own risk. Should the Contractor elect not to proceed with the project, any resulting delay, impact, or disruption to the project will be the Contractor's responsibility. 6-1.5 Late Completion or Milestone Dates. Should the Schedule Update indicate a completion or contractually required milestone date later than the properly adjusted contract or milestone duration, the Agency may withhold Liquidated Damages for the number of days late. Should a subsequent "Accepted" Schedule Update remove all or a portion of the delay, all or the allocated portion of the previously held Liquidated Damages shall be released in the monthly payment to the Contractor immediately following the "Accepted" schedule. 6-1.6 Interim Revisions. Should the actual or projected progress of the work become substantially different from that depicted in the Project Schedule, independently of and prior to the next monthly update, the Contractor will submit a revised Baseline Construction Schedule, with a list and explanation of each change made to the schedule. The Revised Construction Schedule will be submitted per the submittal requirements of Section 2-5.3 and per the schedule review and acceptance requirements of Section 6-1, including but not limited to the acceptance and payment provisions. As used in this section "substantially different" means a time variance greater than 5 percent of the number of days of duration for the project. 6-1.7 Final Schedule Update. Not used 6-1.8 Measurement and Payment of Construction Schedule. The Contractor's preparation, revision and maintenance of the Construction Schedule are incidental to the work and no separate payment will be made therefore. 6-2 PROSECUTION OF WORK. To minimize public inconvenience and possible hazard and to restore street and other work areas to their original condition and state of usefulness as soon as practicable, the Contractor shall diligently prosecute the Work to completion. If the Engineer determines that the Contractor is failing to prosecute the Work to the proper extent, the Contractor shall, upon orders from the Engineer, immediately take steps to remedy the situation. All costs of prosecuting the Work as described herein shall be included in the Contractor's Bid. Should the Contractor fail to take the necessary c«Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 82 of 139 steps to fully accomplish said purposes, after orders of the Engineer, the Engineer may suspend the work in whole or part, until the Contractor takes said steps. As soon as possible under the provisions of the Specifications, the Contractor shall backfill all excavations and restore to usefulness all improvements existing prior to the start of the Work. If Work is suspended through no fault of the Agency, all expenses and losses incurred by the Contractor during such suspensions shall be borne by the Contractor. If the Contractor fails to properly provide for public safety, traffic, and protection of the Work during periods of suspension, the Agency may elect to do so, and deduct the cost thereof from monies due the Contractor. Such actions will not relieve the Contractor from liability. 6-2.1 Order of Work. The work to be done shall consist of furnishing all labor, equipment and materials, and performing all operations necessary to complete the Project Work as shown on the Project Plans and as specified in the Specifications. The work includes The Industrial Park Recycled Water Service Lines Project will construct copper service lines for two (2) residential and thirteen (13) industrial sites from the Districts recycled water pipelines at the locations shown in Exhibit 1. The purpose of the project is to allow for the conversion of onsite irrigation systems from potable water to recycled water. This project will install three (3) new 1-inch recycled water service lines and twelve (12) new 2-inch recycled water service lines. 6-2.3 Project Meetings. The Engineer will establish the time and location of (weekly) Project Meetings. The Contractor's Representative shall attend each Project Meeting. The Project Representative shall be the individual determined under Section 7-6, "The Contractor's Representative". No separate payment for attendance of the Contractor, the Contractor's Representative or any other employee or subcontractor or subcontractor's employee at these meetings will be made. 6-3 SUSPENSION OF WORK. 6-3.1 General. The Work may be suspended in whole or in part when determined by the Engineer that the suspension is necessary in the interest of the Agency. The Contractor shall comply immediately with any written order of the Engineer. Such suspension shall be without liability to the Contractor on the part of the Agency except as otherwise specified in Section 6-6.3. 6-3.2 Archaeological and Paleontological Discoveries. If discovery is made of items of archaeological or paleontological interest, the Contractor shall immediately cease excavation in the area of discovery and shall not continue until ordered by the Engineer. When resumed, excavation operations within the area of discovery shall be as directed by the Engineer. Discoveries which may be encountered may include, but not be limited to, dwelling sites, stone implements or other artifacts, animal bones, human bones, and fossils. The Contractor shall be entitled to an extension of time and compensation in accordance with the provisions of Section 6-6. 6-4 DEFAULT BY CONTRACTOR. If the Contractor fails to begin delivery of material and equipment, to commence the Work within the time specified, to maintain the rate of delivery of material, to execute the Work in the manner and at such locations as specified, or fails to maintain the Work schedule which will insure the Agency's interest, or, if the Contractor is not carrying out the mW Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 83 of 139 intent of the Contract, the Agency may serve written notice upon the Contractor and the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. The Contract may be canceled by the Board without liability for damage, when in the Board's opinion the Contractor is not complying in good faith, has become insolvent, or has assigned or subcontracted any part of the Work without the Board's consent. In the event of such cancellation, the Contractor will be paid the actual amount due based on Contract Unit Prices or lump sums bid and the quantity of the Work completed at the time of cancellation, less damages caused to the Agency by acts of the Contractor. The Contractor, in having tendered a Bid, shall be deemed to have waived any and all claims for damages because of cancellation of Contract for any such reason. If the Agency declares the Contract canceled for any of the above reasons, written notice to that effect shall be served upon the Surety. The Surety shall, within five (5) days, assume control and perform the Work as successor to the Contractor. If the Surety assumes any part of the Work, it shall take the Contractor's place in all respects for that part, and shall be paid by the Agency for all work performed by it in accordance with the Contract. If the Surety assumes the entire Contract, all money due the Contractor at the time of its default shall be payable to the Surety as the Work progresses, subject to the terms of the Contract. If the Surety does not assume control and perform the Work within 5 days after receiving notice of cancellation, or fails to continue to comply, the Agency may exclude the Surety from the premises. The Agency may then take possession of all material and equipment and complete the Work by Agency forces, by letting the unfinished Work to another Contractor, or by a combination of such methods. In any event, the cost of completing the Work shall be charged against the Contractor and its Surety and may be deducted from any money due or becoming due from the Agency. If the sums due under the Contract are insufficient for completion, the Contractor or Surety shall pay to the Agency within 5 days after the completion, all costs in excess of the sums due. The provisions of this section shall be in addition to all other rights and remedies available to the Agency under law. 6-5 TERMINATION OF CONTRACT. The Board may terminate the Contract at its own discretion or when conditions encountered during the Work make it impossible or impracticable to proceed, or when the Agency is prevented from proceeding with the Contract by act of God, by law, or by official action of a public authority. 6-6 DELAYS AND EXTENSIONS OF TIME. 6-6.1 General. If delays are caused by unforeseen events beyond the control of the Contractor, such delays will entitle the Contractor to an extension of time as provided herein, but the Contractor will not be entitled to damages or additional payment due to such delays, except as provided in 6- 6.3. Such unforeseen events may include: war, government regulations, labor disputes, strikes, fires, floods, adverse weather or elements necessitating cessation of work, inability to obtain materials, labor or equipment, required extra work, or other specific events as may be further described in the Specifications. No extension of time will be granted for a delay caused by the Contractor's inability to obtain materials unless the Contractor furnishes to the Engineer documentary proof, the proof must be provided in a timely manner in accordance with the sequence of the Contractor's operations and the approved construction schedule. V Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 84 of 139 If delays beyond the Contractor's control are caused by events other than those mentioned above, the Engineer may deem an extension of time to be in the best interests of the Agency. The Contractor will not be entitled to damages or additional payment due to such delays, except as provided in Section 6-6.3. If delays beyond the Contractor's control are caused solely by action or inaction by the Agency, such delays will entitle the Contractor to an extension of time as provided in Section 6-6.2. 6-6.2 Extensions of Time. Extensions of time, when granted, will be based upon the effect of delays to the Work. They will not be granted for noncontrolling delays to minor portions of the Work unless it can be shown that such delays did or will delay the progress of the Work. 6-6.3 Payment for Delays to Contractor. The Contractor will be compensated for damages incurred due to delays for which the Agency is responsible. Such actual costs will be determined by the Engineer. The Agency will not be liable for damages which the Contractor could have avoided by any reasonable means, such as judicious handling offerees, equipment, or plant. The determination of what damages the Contractor could have avoided will be made by the Engineer. 6-6.4 Written Notice and Report. The Contractor shall provide written notice to the Engineer within two hours of the beginning of any period that the Contractor has placed any workers or equipment on standby for any reason that the Contractor has determined to be caused by the Agency or by any organization that the Agency may otherwise be obligated by. The Contractor shall provide continuing daily written notice to the Engineer, each working day, throughout the duration of such period of delay. The initial and continuing written notices shall include the classification of each workman and supervisor and the make and model of each piece of equipment placed on standby, the cumulative duration of the standby, the Contractor's opinion of the cause of the delay and a cogent explanation of why the Contractor could not avoid the delay by reasonable means. Should the Contractor fail to provide the notice(s) required by this section the Contractor agrees that no delay has occurred and that it will not submit any claim(s) therefore. 6-7 TIME OF COMPLETION. 6-7.1 General. The Contractor shall complete the Work within the time set forth in the Contract. The Contractor shall complete each portion of the Work within such time as set forth in the Contract for such portion. The time of completion of the Contract shall be expressed in working days. The Contractor shall diligently prosecute the work to completion within 60 working days after the starting date specified in the Notice to Proceed. 6-7.2 Working Day. A working day is any day within the period between the start of the Contract time as defined in Section 6-1 and the date provided for completion, or upon field acceptance by the Engineer for all work provided for in the Contract, whichever occurs first, other than: 1. Saturday, 2. Sunday, 3. any day designated as a holiday by the Agency, 4. any other day designated as a holiday in a Master Labor Agreement entered into by the Contractor or on behalf of the Contractor as an eligible member of a contractor association, 5. any day the Contractor is prevented from working at the beginning of the workday for cause as defined in Section 6-6.1, 6. any day the Contractor is prevented from working during the first 5 hours with at least 60 percent of the normal work force for cause as defined in Section 6-6.1. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 85 of 139 Unless otherwise approved in writing by the Engineer, the hours of work shall be between the hours of'7:00 a.m. and 4:00 p.m. on Mondays through Fridays, excluding Agency holidays. The Contractor shall obtain the written approval of the Engineer if the Contractor desires to work outside said hours or at any time during weekends and/or holidays. This written permission must be obtained at least 48 hours prior to such work The Engineer may approve work outside the hours and/or days stated herein when, in his/her sole opinion, such work conducted by the Contractor is beneficial to the best interests of the Agency. The Contractor shall pay the inspection costs of such work. 6-7.3 Contract Time Accounting. The Engineer will make a daily determination of each working day to be charged against the Contract time. These determinations will be discussed and the Contractor will be furnished a periodic statement showing allowable number of working days of Contract time, as adjusted, at the beginning of the reporting period. The statement will also indicate the number of working days charged during the reporting period and the number of working days of Contract time remaining. If the Contractor does not agree with the statement, it shall file a written protest within 15 days after receipt, setting forth the facts of the protest. Otherwise, the statement will be deemed to have been accepted. 6-8 COMPLETION, ACCEPTANCE, AND WARRANTY. The Work will be inspected by the Engineer for acceptance upon receipt of the Contractor's written assertion that the Work has been completed. The Engineer will not accept the Work or any portion of the Work before all of the Work is completed and all outstanding deficiencies that may exist are corrected by the Contractor and the Engineer is satisfied that all the materials and workmanship, and all other features of the Work, meet the requirements of all of the specifications for the Work. Use, temporary, interim or permanent, of all, or portions of, the Work does not constitute acceptance of the Work. If, in the Engineer's judgment, the Work has been completed and is ready for acceptance the Engineer will so certify to the Board. Upon such certification by the Engineer the Board may accept the completed Work. Upon the Board's acceptance of the Work the Engineer will cause a "Notice of Completion" to be filed in the office of the San Diego County Recorder. The date of recordation shall be the date of completion of the Work. All work shall be warranted for one (1) year after recordation of the "Notice of Completion" and any faulty work or materials discovered during the warranty period shall be repaired or replaced by the Contractor, at its expense. Twenty-five percent of the faithful performance bond shall be retained as a warranty bond for the one year warranty period. The Contractor shall replace or repair any such defective work in a manner satisfactory to the Engineer, after notice to do so from the Engineer, and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the Agency may perform this work and the Contractor's sureties shall be liable for the cost thereof. 6-9 LIQUIDATED DAMAGES. Failure of the Contractor to complete the Work within the time allowed will result in damages being sustained by the Agency. For each consecutive calendar day in excess of the time specified for completion of Work, as adjusted in accordance with Section 6-6, the Contractor shall pay the Agency, or have withheld monies due it, the sum of One Thousand Dollars ($1,000.00). Such sum is liquidated damages and shall not be construed as a penalty, and may be deducted from payments due the Contractor if such delay occurs. Execution of the Contract shall constitute agreement by the Agency and Contractor that One Thousand Dollars ($1,000.00) per day is the minimum value of costs and actual damages caused by the Contractor to complete the Work within the allotted time. Any progress payments made after the specified completion date shall not constitute a waiver of this paragraph or of any damages. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 86 of 139 6-10 USE OF IMPROVEMENT DURING CONSTRUCTION. The Agency reserves the right to take over and utilize all or part of any completed facility or appurtenance. The Contractor will be notified in writing in advance of such action. Such action by the Agency will relieve the Contractor of responsibility for injury or damage to said completed portions of the improvement resulting from use by public traffic or from the action of the elements or from any other cause, except Contractor operations or negligence. The Contractor will not be required to reclean such portions of the improvement before field acceptance, except for cleanup made necessary by its operations. Nothing in this section shall be construed as relieving the Contractor from full responsibility for correcting defective work or materials. In the event the Agency exercises its right to place into service and utilize all or part of any completed facility or appurtenance, the Agency will assume the responsibility and liability for injury to persons or property resulting from the utilization of the facility or appurtenance so placed into service, except for any such injury to persons or property caused by any willful or negligent act or omission by the Contractor, Subcontractor, their officers, employees, or agents. SECTION 7 - RESPONSIBILITIES OF THE CONTRACTOR 7-1 CONTRACTOR'S EQUIPMENT AND FACILITIES. The Contractor shall furnish and maintain in good condition all equipment and facilities as required for the proper execution and inspection of the Work. Such equipment and facilities shall meet all requirements of applicable ordinances and laws. 7-2 LABOR. 7-2.1 General. Only competent workers shall be employed on the Work. Any person employed who is found to be incompetent, intemperate, troublesome, disorderly, or otherwise objectionable, or who fails or refuses to perform work properly and acceptably, shall be immediately removed from the Work by the Contractor and not be reemployed on the Work. 7-2.2 Laws. The Contractor, its agents, and employees shall be bound by and comply with applicable provisions of the Labor Code and Federal, State, and local laws related to labor. The Contractor shall strictly adhere to the provisions of the Labor Code regarding minimum wages; the 8-hour day and 40-hour week; overtime; Saturday, Sunday, and holiday work; and nondiscrimination because of race, color, national origin, sex, or religion. The Contractor shall forfeit to the Agency the penalties prescribed in the Labor Code for violations. In accordance with the Labor Code, the Board has on file and will publish a schedule of prevailing wage rates for the types of work to be done under the Contract. The Contractor shall not pay less than these rates. Each worker shall be paid subsistence and travel as required by the collective bargaining agreement on file with the State of California Department of Industrial Relations. The Contractor's attention is directed to Section 1776 of the Labor Code which imposes responsibility upon the Contractor for the maintenance, certification, and availability for inspection of such records for all persons employed by the Contractor or Subcontractor in connection with the project. The Contractor shall agree through the Contract to comply with this Section and the remaining provisions of the Labor Code. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 87 of 139 7-3 LIABILITY INSURANCE. Insurance shall be required as specified in section 10 of the Public Works Contract. The cost of this insurance shall be included in the Contractor's Bid. 7-4 WORKERS' COMPENSATION INSURANCE. Before execution of the Contract by the Board, the Contractor shall file with the Engineer the following signed certification: "I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers' compen- sation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract." The Contractor shall also comply with Section 3800 of the Labor Code by securing, paying for, and maintaining in full force and effect for the duration of the contract, complete Workers' Compensation Insurance, and shall furnish a Certificate of Insurance to the Engineer before execution of the Contract. The Agency, its officers, or employees, will not be responsible for any claims in law or equity occasioned by failure of the Contractor to comply with this paragraph. All compensation insurance policies shall bear an endorsement or shall have attached a rider whereby it is provided that, in the event of expiration or proposed cancellation of such policies for any reason whatsoever, the Agency shall be notified by registered mail not less than 30 days before expiration or cancellation is effective. All insurance is to be placed with insurers that are admitted and authorized to conduct business in the state of California and are listed in the official publication of the Department of Insurance of the State of California. Policies issued by the State Compensation Fund meet the requirement for workers' compensation insurance. 7-5 PERMITS. Except as specified herein the Contractor will obtain, at no cost to the Contractor all City of Carlsbad encroachment, right-of-way, grading and building permits necessary to perform work for this contract on Agency property, streets, or other rights-of-way. Contractor shall not begin work until all permits incidental to the work are obtained. The Contractor shall obtain and pay for all permits for the disposal of all materials removed from the project. The cost of said permit(s) shall be included in the price bid for the appropriate bid item and no additional compensation will be allowed therefore. The Contractor shall obtain and pay for all costs incurred for permits necessitated by its operations such as, but not limited to, those permits required for night work, overload, blasting, and demolition. For private contracts, the Contractor shall obtain all permits incidental to the Work or made necessary by its operations, and pay all costs incurred by the permit requirements. The Contractor shall pay all business taxes or license fees that are required for the work. 7-5.1 Resource Agency Permits. Not used 7-6 THE CONTRACTOR'S REPRESENTATIVE. Before starting work, the Contractor shall designate in writing a representative who shall have complete authority to act for it. An alternative representative may be designated as well. The representative or alternate shall be present at the Work site whenever work is in progress or whenever actions of the elements necessitate its presence to take measures necessary to protect the Work, persons, or property. Any order or Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 88 of 139 communication given to this representative shall be deemed delivered to the Contractor. A joint venture shall designate only one representative and alternate. In the absence of the Contractor or its representative, instructions or directions may be given by the Engineer to the superintendent or person in charge of the specific work to which the order applies. Such order shall be complied with promptly and referred to the Contractor or its representative. In order to communicate with the Agency, the Contractor's representative, superintendent, or person in charge of specific work shall be able to speak, read, and write the English language. 7-7 COOPERATION AND COLLATERAL WORK. The Contractor shall be responsible for ascertaining the nature and extent of any simultaneous, collateral, and essential work by others. The Agency, its workers and contractors and others, shall have the right to operate within or adjacent to the Work site during the performance of such work. The Agency, the Contractor, and each of such workers, contractors and others, shall coordinate their operations and cooperate to minimize interference. The Contractor shall include in its Bid all costs involved as a result of coordinating its work with others, the Contractor will not be entitled to additional compensation from the Agency for damages resulting from such simultaneous, collateral, and essential work. If necessary to avoid or minimize such damage or delay, the Contractor shall redeploy its work force to other parts of the Work. Should the Contractor be delayed by the Agency, and such delay could not have been reasonably foreseen or prevented by the Contractor, the Engineer will determine the extent of the delay, the effect on the project, and any extension of time. 7-7.1 Coordination. The Contractor shall coordinate and cooperate with all the utility companies during the relocation or construction of their lines. The Contractor may be granted a time extension if, in the opinion of the Engineer, a delay is caused by the utility company. No additional compensation will be made to the Contractor for any such delay. 7-8 PROJECT SITE MAINTENANCE. 7-8.1 Cleanup and Dust Control. Throughout all phases of construction, including suspension of work, and until the final acceptance, the Contractor shall keep the site clean and free from rubbish and debris. The Contractor shall also abate dust nuisance by cleaning, sweeping and sprinkling with water, or other means as necessary. The use of water resulting in mud on public streets will not be permitted as a substitute for sweeping or other methods. When required by the Plans or Specifications, the Contractor shall furnish and operate a self-loading motor sweeper with spray nozzles at least once each working day for the purpose of keeping paved areas acceptably clean wherever construction, including restoration, is incomplete. Materials and equipment shall be removed from the site as soon as they are no longer necessary. Before the final inspection, the site shall be cleared of equipment, unused materials, and rubbish so as to present a satisfactory clean and neat appearance. All cleanup costs shall be included in the Contractor's Bid. Care shall be taken to prevent spillage on haul routes. Any such spillage shall be removed immediately and the area cleaned. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 89 of 139 Excess excavation material from catch basins or similar structures shall be removed from the site immediately. Sufficient material may remain for use as backfill if permitted by the Specifications. Forms and form lumber shall be removed from the site as soon as practicable after stripping. Failure of the Contractor to comply with the Engineer's cleanup orders may result in an order to suspend work until the condition is corrected. No additional compensation will be allowed as a result of such suspension. Cleanup and dust control required herein shall also be executed on weekends and other non-working days when needed to preserve the health safety or welfare of the public. The Contractor shall conduct effective cleanup and dust control throughout the duration of the Contract. The Engineer may require increased levels of cleanup and dust control that, in his/her sole discretion, are necessary to preserve the health, safety and welfare of the public. Cleanup and dust control shall be considered incidental to the items of work that they are associated with and no additional payment will be made therefore. 7-8.2 Air Pollution Control. The Contractor shall not discharge smoke, dust, or any other air contaminants into the atmosphere in such quantity as will violate the regulations of any legally constituted authority. 7-8.3 Vermin Control. At the time of acceptance, structures entirely constructed under the Contract shall be free of rodents, insects, vermin, and pests. Necessary extermination work shall be arranged and paid for by the Contractor as part of the Work within the Contract time, and shall be performed by a licensed exterminator in accordance with requirements of governing authorities. The Contractor shall be liable for injury to persons or property and responsible for the elimination of offensive odors resulting from extermination operations. 7-8.4 Sanitation. The Contractor shall provide and maintain enclosed toilets for the use of employees engaged in the Work. These accommodations shall be maintained in a neat and sanitary condition. They shall also comply with all applicable laws, ordinances, and regulations pertaining to public health and sanitation of dwellings and camps. Wastewater shall not be interrupted. Should the Contractor disrupt existing sewer facilities, sewage shall be conveyed in closed conduits and disposed of in a sanitary sewer system. Sewage shall not be permitted to flow in trenches or be covered by backfill. 7-8.5 Temporary Light, Power, and Water. The Contractor shall furnish, install, maintain, and remove all temporary light, power, and water at its own expense. These include piping, wiring, lamps, and other equipment necessary for the Work. The Contractor shall not draw water from any fire hydrant (except to extinguish a fire), without obtaining permission from the water agency concerned. The Contractor shall obtain a construction meter for water used for the construction, plant establishment, maintenance, cleanup, testing and all other work requiring water related to this contract. The Contractor shall contact the appropriate water agency for requirements. The Contractor shall pay all costs of temporary light, power and water including hookup, service, meter and any, and all, other charges, deposits and/or fees therefore. Said costs shall be considered incidental to the items of work that they are associated with and no additional payment will be made therefore. 7-8.6 Water Pollution Control. The Contractor shall exercise every reasonable precaution to protect channels, storm drains, and bodies of water from pollution. It shall conduct and schedule operations so as to minimize or avoid muddying and silting of said channels, drains, and waters. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 90 of 139 Water pollution control work shall consist of constructing those facilities which may be required to provide prevention, control, and abatement of water pollution. The Contractor shall comply with the California State Water Resources Control Board (SWRCB) Order Number 99-08-DWQ, National Pollutant Discharge Elimination System (NPDES) General Permit Number CAS000002, Waste Discharge Requirements (WDR's) for Discharges of Stormwater Runoff associated with Construction Activity (General Permit) and subsequent adopted modifications and with all requirements of the Storm Water Pollution Prevention and Monitoring Plans for this project in accordance with these regulations. The Notice of Intent (NOI) shall not be filed for the project. 7-8.7 Drainage Control. The Contractor shall maintain drainage within and through the work areas. Earth dams will not be permitted in paved areas. Temporary dams of sandbags, asphaltic concrete, or other acceptable material will be permitted when necessary. Such dams shall be removed from the site as soon as their use is no longer necessary. 7-8.8 Noise Control. All internal combustion engines used in the construction shall be equipped with mufflers in good repair when in use on the project with special attention to the City Noise Control Ordinance, Carlsbad Municipal Code Chapter 8.48. 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS. The Contractor shall be responsible for the protection of public and private property adjacent to the Work and shall exercise due caution to avoid damage to such property. The Contractor shall repair or replace all existing improvements within the right-of-way which are not designated for removal (e.g., curbs, sidewalks, driveways, fences, walls, signs, utility installations, pavement, structures, etc.) which are damaged or removed as a result of its operations. When a portion of a sprinkler system within the right-of-way must be removed, the remaining lines shall be capped. Repairs and replacements shall be at least equal to existing improvements and shall match them in finish and dimension. Maintenance of street and traffic signal systems that are damaged, temporarily removed or relocated shall be done in conformance with 307-1.5. Trees, lawns, and shrubbery that are not to be removed shall be protected from damage or injury. If damaged or removed due to Contractor's operations, they shall be restored or replaced in as nearly the original condition and location as is reasonably possible. Lawns shall be reseeded and covered with suitable mulch. The Contractor shall give reasonable notice to occupants or owners of adjacent property to permit them to salvage or relocate plants, trees, fences, sprinklers, and other improvements, within the right-of-way which are designated for removal and would be destroyed because of the Work. All costs to the Contractor for protecting, removing, and restoring existing improvements shall be included in the Bid. 7-10 PUBLIC CONVENIENCE AND SAFETY. 7-10.1 Traffic and Access. The Contractor's operations shall cause no unnecessary inconve- nience. The access rights of the public shall be considered at all times. Unless otherwise authorized, traffic shall be permitted to pass through the Work, or an approved detour shall be provided. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 91 of 139 Safe and adequate pedestrian and vehicular access shall be provided and maintained to: fire hydrants; commercial and industrial establishments; churches, schools and parking lots; service stations and motels; hospitals; police and fire stations; and establishments of similar nature. Access to these facilities shall be continuous and unobstructed unless otherwise approved by the Engineer. Safe and adequate pedestrian zones and public transportation stops, as well as pedestrian crossings of the Work at intervals not exceeding 90 m (300 feet), shall be maintained unless otherwise approved by the Engineer. Vehicular access to residential driveways shall be maintained to the property line except when necessary construction precludes such access for reasonable periods of time. If backfill has been completed to the extent that safe access may be provided, and the street is opened to local traffic, the Contractor shall immediately clear the street and driveways and provide and maintain access. The Contractor shall cooperate with the various parties involved in the delivery of mail and the collection and removal of trash and garbage to maintain existing schedules for these services. Grading operations, roadway excavation and fill construction shall be conducted by the Contractor in a manner to provide a reasonably satisfactory surface for traffic. When rough grading is completed, the roadbed surface shall be brought to a smooth, even condition satisfactory for traffic. Unless otherwise authorized, work shall be performed in only one-half the roadway at one time. One half shall be kept open and unobstructed until the opposite side is ready for use. If one-half a street only is being improved, the other half shall be conditioned and maintained as a detour. The Contractor shall schedule the work so as to prevent damage by all traffic, including but not limited to mail delivery. The Contractor shall not schedule work so as to conflict with trash pickup. The trash hauling schedule can be obtained by calling the City's contracted waste disposal company, Coast Waste Management at 929-9417. During overlay operations, the Contractors schedule for overlay application shall be designated to provide residents and business owners whose streets are to be overlaid sufficient paved parking within an 800 foot distance from their homes or businesses. Seventy-two hours prior to the start of any construction in the public right-of-way that affects vehicular traffic and/or parking or pedestrian routes, the Contractor shall give written notification of the impending disruption. For a full street closure, all residences and/or businesses on the affected street or alley shall be notified. For partial street closures, or curb, sidewalk and driveway repairs, the residences and/or businesses directly affected by the work shall be notified. The notification shall be hand delivered and shall state the date and time the work will begin and its anticipated duration. The notification shall list two telephone numbers that may be called to obtain additional information. One number shall be the Contractor's permanent office or field office and the other number shall be a 24-hour number answered by someone who is knowledgeable about the project. At least one of the phone numbers shall be in the (760) area code. An answering machine shall not be connected to either number. The notification shall also give a brief description of the work and simple instructions to the home or business owner on what they need to do to facilitate the construction. The Contractor shall submit the contents of the notification to the Engineer for approval. Notices shall not be distributed until approved by the Engineer. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 92 of 139 For residences, the notification shall be pre-cut in a manner that enables it to be affixed to a doorknob without adhesives. It shall be a minimum size of 3-1/2 inches by 8-1/2 inches and shall be '"«•»••' brightly colored with contrasting printing. The material shall be equivalent in strength and durability to 65 Ib. card stock. The printing on the notice shall be no smaller than 12 point. An example of such notice is provided in Appendix "A". In addition to the notifications, the contractor shall post no parking signs 48 hours in advance of the work being performed. The no parking signs shall state the date and time of parking restriction for a duration not to exceed the time necessary to complete the work at that location. Failure of the contractor to meet the posted date requires re-posting the no parking signs 48 hours in advance of the rescheduled work. If the work is delayed or rescheduled the no parking signs shall be removed and re-posted 48 hours in advance of the rescheduled work. The preparation, materials, printing and distribution of the notifications shall be included in the contract price bid for traffic control and the Contractor will not be entitled to any additional compensation for printing and distributing these notices. The contractor shall replace all street markings and striping damaged by construction activities. The Contractor shall include in its Bid all costs for the above requirements. 7-10.2 Storage of Equipment and Materials in Public Streets. Construction materials shall not be stored in streets, roads, or highways for more than 5 days after unloading. All materials or equipment not installed or used in construction within 5 days after unloading shall be stored elsewhere by the Contractor at its expense unless authorized additional storage time. Construction equipment shall not be stored at the Work site before its actual use on the Work nor for more than 5 days after it is no longer needed. Time necessary for repair or assembly of equipment may be authorized by the Engineer. Excavated material, except that which is to be used as backfill in the adjacent trench, shall not be stored in public streets unless otherwise permitted. After placing backfill, all excess material shall be removed immediately from the site. 7-10.3 Street Closures, Detours, Barricades. The Contractor shall comply with all applicable State, County, and City requirements for closure of streets. The Contractor shall provide barriers, guards, lights, signs, temporary bridges, flagpersons, and watchpersons. The Contractor shall be responsible for compliance with additional public safety requirements which may arise. The Contractor shall furnish and install signs and warning devices and promptly remove them upon completion of the Work. After obtaining the Engineers approval and at least 5 working days before closing, detouring, partially closing or reopening any street, alley or other public thoroughfare the Contractor shall notify the following: 1) The Engineer (760) 602-2720 2) Carlsbad Fire Department Dispatch (760) 931-2197 3) Carlsbad Police Department Dispatch (760) 931-2197 4) Carlsbad Traffic Signals Maintenance (extension 2937) (760) 438-2980 5) Carlsbad Traffic Signals Operations (760) 602-2752 6) North County Transit District (760)967-2828 7) Waste Management (760) 929-9400 The Contractor shall comply with their requirements. The Contractor shall obtain the Engineer's m¥ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 93 of 139 written approval prior to deviating from the requirements of 2) through, and including, 7) above. The Contractor shall obtain the written approval no less than five working days prior to placing any traffic control that affects bus stops. The Contractor shall secure approval, in advance, from authorities concerned for the use of any bridges proposed by it for public use. Temporary bridges shall be clearly posted as to load limit, with signs and posting conforming to current requirements covering "signs" as set forth in the Traffic Manual published by the California Department of Transportation. This manual shall also apply to the street closures, barricades, detours, lights, and other safety devices required. All costs involved shall be included in the Bid. Traffic controls shall be in accordance with the plans, The California Manual on Uniform Traffic Control Devices (FHWA MUTCD 2003 Revision 1, as amended for use in California) and these provisions. If any component in the traffic control system is damaged, displaced, or ceases to operate or function as specified, from any cause, during the progress of the work, the Contractor shall immediately repair said component to its original condition or replace said component and shall restore the component to its original location. In the event that the Contractor fails to install and/or maintain barricades or such other traffic signs, markings, delineation or devices as may be required herein, the Engineer may, at his/her sole option, install the traffic signs, markings, delineation or devices and charge the Contractor twenty dollars ($25.00) per day per traffic sign or device, or the actual cost of providing such traffic control facility, whichever is the greater. 7-10.3.1 Construction Area Signs and Control Devices. All construction traffic signs and control devices shall be maintained throughout the duration of work in good order and according to the approved traffic control plan. All construction area signs shall conform to the provisions of Section 206-7.2 et seq. All temporary reflective pavement markers shall conform to the provisions of Section 214-5.let seq. All temporary reflective channelizers shall conform to the provisions of Section 214- 5.2 et seq. All paint for temporary traffic striping, pavement marking, and curb marking shall conform to the provisions of Section 210-1.6 et seq. except that all temporary paint shall be rapid dry water borne conforming to Section 210-1.6 for materials and Section 310-5 et seq. For workmanship. Warning and advisory signs, lights and devices installed or placed to provide traffic control, direction and/or warning shall be furnished, installed and maintained by the Contractor. Warning and advisory signs, lights and devices shall be promptly removed by the Contractor when no longer required. Warning and advisory signs that remain in place overnight shall be stationary mounted signs. Stationary signs that warn of non-existent conditions shall be removed from the traveled way and from the view of motorists in the traveled way or shielded from the view of the traveling public during such periods that their message does not pertain to existing conditions. Care shall be used in performing excavation for signs in order to protect underground facilities. All excavation required to install stationary construction area signs shall be performed by hand methods without the use of power equipment. Warning and advisory signs that are used only during working hours may be portable signs. Portable signs shall be removed from the traveled way and shielded from the view of the traveling public during non-working hours. During the hours of darkness, as defined in Division 1, Section 280, of the California Vehicle Code, portable signs shall be illuminated or, at the option of the Contractor, shall be in conformance with the provisions in Section 206-7.2 et seq. If illuminated traffic cones rather than post-type delineators are used during the hours of darkness, they shall be affixed or covered with reflective cone sleeves as specified in CALTRANS "Standard Specifications", except the sleeves shall be 7" long. Personal vehicles of the Contractor's employees shall not be parked within the traveled way, including any Section closed to public traffic. Whenever the Contractor's vehicles or equipment are parked on the shoulder within 6' of a traffic lane, the shoulder area shall be closed with fluorescent traffic cones or portable delineators placed on a taper in advance of the parked vehicles or equipment and along the edge of the pavement at not less than €3•fr Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 94 of 139 25' intervals to a point not less than 25* past the last vehicle or piece of equipment. A minimum of nine (9) cones or portable delineators shall be used for the taper. A W20-1 (Road Work Ahead) or C24 (Shoulder Work Ahead) sign shall be mounted, as required herein, on a signpost or telescoping flag tree with flags. The signpost or flag tree shall be placed where directed by the Engineer. 7-10.3.2 Maintaining Traffic. During the entire construction, a minimum of one paved traffic lanes, not less than 14 feet wide, shall be open for use by public traffic in each direction of travel. 7-10.3.3 Traffic Control System for Lane Closure. A traffic control system consists of closing traffic lanes or pedestrian walkways in accordance with the details shown on the plans, California Manual on Uniform Traffic Control Devices (FHWA MUTCD 2003 Revision 1, as amended for use in California) and provisions under "Maintaining Traffic" elsewhere in these Provisions. The provisions in this section will not relieve the Contractor from its responsibility to provide such additional devices or take such measures as may be necessary to maintain public safety. When lanes are closed for only the duration of work periods, all components of the traffic control system, except portable delineators placed along open trenches or excavation adjacent to the traveled way, shall be removed from the traveled way and shoulder at the end work period. If the Contractor so elects, said components may be stored at selected central locations, approved by the Engineer, within the limits of the right-of-way. 7-10.3.4 Traffic Control for Permanent and Temporary Traffic Striping. During traffic stripe operations, traffic shall be controlled with lane closures, as provided for under 'Traffic Control System for Lane Closure" of these Supplemental Provisions or by use of an alternative traffic control plan proposed by the Contractor and approved by the Engineer. The Contractor shall not start traffic striping operations using an alternative plan until the Contractor has submitted its plan to the Engineer and has received the Engineer's written approval of said plan. 7-10.3.5 Temporary Pavement Delineation. Temporary pavement delineation shall be furnished, placed, maintained and removed in accordance with the minimum standards specified in the California Manual on Uniform Traffic Control Devices (FHWA MUTCD 2003 Revision 1, as amended for use in California published by CALTRANS. Whenever the work causes obliteration of pavement delineation, temporary or permanent pavement delineation shall be in place prior to opening the traveled way to public traffic. Lane line or centerline pavement delineation shall be provided at all times for traveled ways open to public traffic. All work necessary, including any required lines or marks, to establish the alignment of temporary pavement delineation shall be performed by the Contractor. When temporary pavement delineation is removed, all lines and marks used to establish the alignment of the temporary pavement delineation shall be removed by grinding. Surfaces to receive temporary pavement delineation shall be dry and free of dirt and loose material. Temporary pavement delineation shall not be applied over existing pavement delineation or other temporary pavement delineation. Temporary pavement delineation shall be maintained until superseded or replaced with permanent pavement delineation. Temporary pavement delineation shall be removed when, as determined by the Engineer, the temporary pavement delineation conflicts with the permanent pavement delineation or with a new traffic pattern for the area and is no longer required for the direction of public traffic. When temporary pavement delineation is required to be removed, all lines and marks used to establish the alignment of the temporary pavement delineation shall be removed. oRevised 5/01/08 Contract No. 52011 (Industrial Park RW Sen/ice Lines) Page 95 of 139 7-10.3.6 Preparation of New, or Modifications and Additions to Existing, Traffic Control Plan Sheets. No traffic control plans (TCP) or Traffic Control Staging plans (TCP) are included in the project plans, the Contractor shall have such new TCP prepared and submitted as a part of the Work for any and all construction activities that are located within the traveled way. The Contractor shall have TCP prepared and submitted as a part of the Work for any construction activities that are a part of this project that are not included in the project plans. The Contractor must submit the TCP for the Engineer's review in conformance with the requirements of Section 2-5.3, et seq. and obtain the Engineer's approval of the TCP prior to implementing them. The minimum 20-day review period specified in Section 2-5.3.1 for shop drawings and submittals shall pertain to each submittal of TCP, new, modified or added to, for the Engineer's review. New or revised TCP submittals shall include all TCP needed for the entire duration of the Work. Each phase of the TCP shall be shown in sufficient scale and detail to show the lane widths, transition lengths, curve radii, stationing of features affecting the traffic control plan and the methodology proposed to transition to the subsequent TCP phase. When the vertical alignment of the traveled surface differs from the finished pavement elevation vertical curves must also be shown. Such modifications, supplements and/or new design of TCP shall meet the requirements of the Engineer and the California Manual on Uniform Traffic Control Devices (FHWA MUTCD 2003 Revision 1, as amended for use in California as published by CALTRANS. Such modification, addition, supplement, and/or new design of TCP shall be prepared by a registered professional engineer appropriately registered in the State of California. The Engineer shall be the sole judge of the suitability and quality of any such modifications, supplements, and/or new designs to TCP. The Engineer may approve any such modifications, supplements, and/or new designs to the TCP when, in the Engineer's sole opinion, such modifications, supplements, and/or new designs to the TCP prepared by the registered professional engineer retained by the Contractor will be beneficial to the best interests of the Agency. Such modification, addition, supplement, and/or new design shall not be implemented and no work shall be commenced that is contingent on such approval until the changed TCP are approved by the Engineer. The preparation of such modification, addition, supplement, and/or new designs of TCP shall not presuppose their approval or obligate the Agency in any fashion. Submittal and review requirements for such modifications, supplements, and/or new designs to TCP shall conform to the requirements of Section 2-5.3 Shop Drawings and Submittals. 7-10.3.7 Payment The Contractor shall provide traffic control at the contract lump sum price bid. The contract lump sum price paid for "traffic control" shall include full compensation for furnishing all labor (including flagging costs), materials (including signs), tools, equipment and incidentals, and for doing all the work involved in preparation, reproduction and changing of traffic control plans, placing, applying traffic stripes and pavement markers with bituminous adhesive, removing, storing, maintaining, moving to new locations, replacing, and disposing of the components of the traffic control system as shown on the plans and approved additions and modifications, as specified in these supplemental provisions, and as directed by the Engineer. All expenses and time to prepare and review modifications, additions, supplements and/or new TCP designs shall be included in the lump sum bid for traffic control and no additional payment will be made therefore. Flagging costs will be paid for as a part of the Lump Sum Amount for 'Traffic Control." The cost of labor and material for portable concrete barriers will be paid for at the unit price bid. When there is no bid item the cost of labor and material for portable concrete barriers they will be paid as an incidental to the work being performed and no additional payment will be made therefore. Progress payments for "Traffic Control" will be based on the percentage of the improvement work completed. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 96 of 139 7-10.4 Safety. 7-10.4.1 Safety Orders. The Contractor shall have at the Work site, copies or suitable extracts of: Construction Safety Orders, Tunnel Safety Orders and General Industry Safety Orders issued by the State Division of Industrial Safety. The Contractor shall comply with provisions of these and all other applicable laws, ordinances, and regulations. Before excavating any trench 5 feet or more in depth, the Contractor shall submit a detailed plan to the Agency showing the design of shoring, bracing, sloping, or other provisions to be made for the workers' protection from the hazard of caving ground during the excavation of such trench. If the plan varies from the shoring system standards, the plan shall be prepared by a registered Civil Engineer. No excavation shall start until the Engineer has accepted the plan and the Contractor has obtained a permit from the State Division of Industrial Safety. A copy of the permit shall be submitted to the Engineer. Payment for performing all work necessary to provide safety measures shall be included in the prices bid for other items of work except where separate bid items for excavation safety are provided, or required by law. 7-10.4.2 Use of Explosives. Explosives may be used only when authorized in writing by the Engineer, or as otherwise stated in the Specifications. Explosives shall be handled, used, and stored in accordance with all applicable regulations. The Engineer's approval of the use of explosives shall not relieve the Contractor from liability for claims caused by blasting operations. 7-10.4.3 Special Hazardous Substances and Processes. Materials that contain hazardous substances or mixtures may be required on the Work. A Material Safety Data Sheet as described in Section 5194 of the California Code of Regulations shall be requested by the Contractor from the manufacturer of any hazardous products used. Material usage shall be accomplished with strict adherence to California Division of Industrial Safety requirements and all manufacturer warnings and application instructions listed on the Material Safety Data Sheet and on the product container label. The Contractor shall notify the Engineer if a specified product cannot be used under safe conditions. 7-10.4.4 Confined Spaces. (a) Confined Space Entry Program. The Contractor shall be responsible for implementing, administering and maintaining a confined space entry program (CSEP) in accordance with Sections 5156, 5157 and 5158, Title 8, CCR. Prior to starting the Work, the Contractor shall prepare and submit its comprehensive CSEP to the Engineer. The CSEP shall address all potential physical and environmental hazards and contain procedures for safe entry into confined spaces, including, but not limited to the following: 1. Training of personnel 2. Purging and cleaning the space of materials and residue 3. Potential isolation and control of energy and material inflow 4. Controlled access to the space 5. Atmospheric testing of the space Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 97 of 139 6. Ventilation of the space 7. Special hazards consideration 8. Personal protective equipment 9. Rescue plan provisions The Contractor's submittal shall include the names of its personnel, including subcontractor personnel, assigned to the project who will have CSEP responsibilities, their CSEP training, and their specific assignment and responsibility in carrying out the CSEP. (b) Permit-Required Confined Spaces. Entry into permit-required confined spaces as defined in Section 5157, Title 8, CCR may be required as a part of the Work. All manholes, tanks, vaults, pipelines, excavations, or other enclosed or partially enclosed spaces shall be considered permit- required confined spaces until the pre-entry procedures demonstrate otherwise. The Contractor shall implement a permit space program prior to performing any work in a permit-required confined space. A copy of the permit shall be available at all times for review by Contractor and Agency personnel at the Work site. (c) Payment. Payment for implementing, administering, and providing all equipment and personnel to perform the CSEP shall be included in the bid items for which the CSEP is required. 7-10.4.5 Safety and Protection of Workers and Public. The Contractor shall take all necessary precautions for the safety of employees on the work and shall comply with all applicable provisions of Federal, State and Municipal safety laws and building codes to prevent accidents or injury to persons on, about, or adjacent to the premises where the work is being performed. The Contractor shall erect and properly maintain at all times, as required by the conditions and progress of the work, all necessary safeguards for the protection of workers and public, and shall use danger signs warning against hazards created by such features of construction as protruding nails, hoists, well holes, and falling materials. 7-11 PATENT FEES OR ROYALTIES. The Contractor shall absorb in its Bid the patent fees or royalties on any patented article or process furnished or used in the Work. The Contractor shall indemnify and hold the Agency harmless from any legal action that may be brought for infringement of patents. 7-12 ADVERTISING. The names, addresses and specialties of Contractors, Subcontractors, architects, or engineers may be displayed on removable signs. The size and location shall be subject to the Engineer's approval. Commercial advertising matter shall not be attached to or painted on the surfaces of buildings, fences, canopies, or barricades. 7-13 LAWS TO BE OBSERVED. The Contractor shall keep fully informed of State and National laws and County and Municipal ordinances and regulations which in any manner affect those employed in the Work or the materials used in the Work or in any way affect the conduct of the Work. The Contractor shall at all times observe and comply with such laws, ordinances, and regulations. Municipal ordinances that affect this work include Chapter 11.06. Excavation and Grading. If this notice specifies locations or possible materials, such as borrow pits or gravel beds, for use in the proposed construction project which would be subject to Section 1601 or Section 1603 of the Fish and Game Code, the conditions established pursuant to Section 1601 et seq. of the Fish and Game Code shall become conditions of the contract. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 98 of 139 7-14 ANTITRUST CLAIMS. Section 7103.5 of the Public Contract Code provides: "In entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or subcontractor offers and agrees to assign to the awarding body all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec 15) or Cartwright Act (Chapter 2 [commencing with Section 16700] of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or subcontract. The assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment of the parties." SECTION 8 - FACILITIES FOR AGENCY PERSONNEL 8-1 GENERAL. Not used SECTION 9 - MEASUREMENT AND PAYMENT 9-1 MEASUREMENT OF QUANTITIES FOR UNIT PRICE WORK. 9-1.1 General. Unless otherwise specified, quantities of work shall be determined from measurements or dimensions in horizontal planes. However, linear quantities of pipe, piling, fencing and timber shall be considered as being the true length measured along longitudinal axis. Unless otherwise provided in Specifications, volumetric quantities shall be the product of the mean area of vertical or horizontal sections and the intervening horizontal or vertical dimension. The planimeter shall be considered an instrument of precision adapted to measurement of all areas. 9-1.2 Methods of Measurement. Materials and items of work which are to be paid for on basis of measurement shall be measured in accordance with methods stipulated in the particular sections involved. 9-1.3 Certified Weights. When payment is to be made on the basis of weight, the weighing shall be done on certified platform scales or, when approved by the Engineer, on a completely automated weighing and recording system. The Contractor shall furnish the Engineer with duplicate licensed weighmaster's certificates showing actual net weights. The Agency will accept the certificates as evidence of weights delivered. 9-1.4 Units of Measurement. The system of measure for this contract shall be the U.S. Standard Measures. 9-2 LUMP SUM WORK. Items for which quantities are indicated "Lump Sum", "L.S.", or "Job", shall be paid for at the price indicated in the Bid. Such payment shall be full compensation for the items of work and all work appurtenant thereto. When required by the Specifications or requested by the Engineer, the Contractor shall submit to the Engineer within 15 days after award of Contract, a detailed schedule in triplicate, to be used only as a basis for determining progress payments on a lump sum contract or designated lump sum bid item. This schedule shall equal the lump sum bid and shall be in such form and sufficiently detailed as to satisfy the Engineer that it correctly represents a reasonable apportionment of the lump sum. €3mW Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 99 of 139 9-3 PAYMENT 9-3.1 General. The quantities listed in the Bid schedule will not govern final payment. Payment to >••'' the Contractor will be made only for actual quantities of Contract items constructed in accordance with the Plans and Specifications. Upon completion of construction, if the actual quantities show either an increase or decrease from the quantities given in the Bid schedule, the Contract Unit Prices will prevail subject to the provisions of Section 3-2.2.1. The unit and lump sum prices to be paid shall be full compensation for the items of work and all appurtenant work, including furnishing all materials, labor, equipment, tools, and incidentals. Payment will not be made for materials wasted or disposed of in a manner not called for under the Contract. This includes rejected material not unloaded from vehicles, material rejected after it has been placed, and material placed outside of the Plan lines. No compensation will be allowed for disposing of rejected or excess material. Payment for work performed or materials furnished under an Assessment Act Contract will be made as provided in particular proceedings or legislative act under which such contract was awarded. Whenever any portion of the Work is performed by the Agency at the Contractor's request, the cost thereof shall be charged against the Contractor, and may be deducted from any amount due or becoming due from the Agency. Whenever immediate action is required to prevent injury, death, or property damage, and precautions which are the Contractor's responsibility have not been taken and are not reasonably expected to be taken, the Agency may, after reasonable attempt to notify the Contractor, cause such ^^, precautions to be taken and shall charge the cost thereof against the Contractor, or may deduct -*«•*»' such cost from any amount due or becoming due from the Agency. Agency action or inaction under such circumstances shall not be construed as relieving the Contractor or its Surety from liability. Payment shall not relieve the Contractor from its obligations under the Contract; nor shall such payment be construed to be acceptance of any of the Work. Payment shall not be construed as the transfer of ownership of any equipment or materials to the Agency. Responsibility of ownership shall remain with the Contractor who shall be obligated to store any fully or partially completed work or structure for which payment has been made; or replace any materials or equipment required to be provided under the Contract which may be damaged, lost, stolen or otherwise degraded in any way prior to acceptance of the Work, except as provided in Section 6-10. Guarantee periods shall not be affected by any payment but shall commence on the date of recordation of the "Notice of Completion." If, within the time fixed by law, a properly executed notice to stop payment is filed with the Agency, due to the Contractor's failure to pay for labor or materials used in the Work, all money due for such labor or materials will be withheld from payment to the Contractor in accordance with applicable laws. At the expiration of 35 days from the date of acceptance of the Work by the Board, or as prescribed by law, the amount deducted from the final estimate and retained by the Agency will be paid to the Contractor except such amounts as are required by law to be withheld by properly executed and filed notices to stop payment, or as may be authorized by the Contract to be further retained. ^ot Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 100 of 139 9-3.2 Partial and Final Payment. The Engineer will, after award of Contract, establish a closure date for the purpose of making monthly progress payments. The Contractor may request in writing that such monthly closure date be changed. The Engineer may approve such request when it is compatible with the Agency's payment procedure. Each month, the Engineer will make an approximate measurement of the work performed to the closure date as basis for making monthly progress payments. The estimated value will be based on contract unit prices, completed change order work and as provided for in Section 9-2 of these General Provisions. Progress payments shall be made no later than thirty (30) calendar days after the closure date. Five (5) working days following the closure date, the Engineer shall complete the detailed progress pay estimate and submit it to the Contractor for the Contractor's information. Should the Contractor assert that additional payment is due, the Contractor shall within ten (10) days of receipt of the progress estimate, submit a supplemental payment request to the Engineer with adequate justification supporting the amount of supplemental payment request. Upon receipt of the supplemental payment request, the Engineer shall, as soon as practicable after receipt, determine whether the supplemental payment request is a proper payment request. If the Engineer determines that the supplemental payment request is not proper, then the request shall be returned to the Contractor as soon as practicable, but not later than seven (7) days after receipt. The returned request shall be accompanied by a document setting forth in writing the reasons why the supplemental payment request was not proper. In conformance with Public Contract Code Section 20104.50, the City shall make payments within thirty (30) days after receipt of an undisputed and properly submitted supplemental payment request from the Contractor. If payment of the undisputed supplemental payment request is not made within thirty (30) days after receipt by the Engineer, then the City shall pay interest to the Contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure. From each progress estimate, 10 percent will be deducted and retained by the Agency, and the remainder less the amount of all previous payments will be paid. After 50 percent of the Work has been completed and if progress on the Work is satisfactory, the deduction to be made from remaining progress estimates and from the final estimate may be limited to $500 or 10 percent of the first half of total Contract amount, whichever is greater. No progress payment made to the Contractor or its sureties will constitute a waiver of the liquidated damages under 6-9. As provided in Section 22300 of the California Public Contract Code, the Contractor may substitute securities for any monies withheld by the Agency to ensure performance under the Contract. After final inspection, the Engineer will make a Final Payment Estimate and process a corresponding payment. This estimate will be in writing and shall be for the total amount owed the Contractor as determined by the Engineer and shall be itemized by the contract bid item and change order item with quantities and payment amounts and shall show all deductions made or to be made for prior payments and amounts to be deducted under provisions of the contract. All prior estimates and progress payments shall be subject to correction in the Final Payment Estimate. The Contractor shall have 30 calendar days from receipt of the Final Payment Estimate to make written statement disputing any bid item or change order item quantity or payment amount. The Contractor shall provide all documentation at the time of submitting the statement supporting its position. Should the Contractor fail to submit the statement and supporting documentation within the time specified, the Contractor acknowledges that full and final payment has been made for all contract bid items and change order items. €3mW Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 101 of 139 If the Contractor submits a written statement with documentation in the aforementioned time, the Engineer will review the disputed item within 30 calendar days and make any appropriate adjustments on the Final Payment. Remaining disputed quantities or amounts not approved by the Engineer will be subject to resolution as specified in Section 3-5, Disputed Work. The written statement filed by the Contractor shall be in sufficient detail to enable the Engineer to ascertain the basis and amount of said disputed items. The Engineer will consider the merits of the Contractor's claims. It will be the responsibility of the Contractor to furnish within a reasonable time such further information and details as may be required by the Engineer to determine the facts or contentions involved in its claims. Failure to submit such information and details will be sufficient cause for denying payment for the disputed items. 9-3.2.1 Payment for Claims. Except for those final payment items disputed in the written statement required in Section 9-3.2 all claims of any dollar amount shall be submitted in a written statement by the Contractor no later than the date of receipt of the final payment estimate. Those final payment items disputed in the written statement required in Section 9-3.2 shall be submitted no later than 30 days after receipt of the Final Payment estimate. No claim will be considered that was not included in this written statement, nor will any claim be allowed for which written notice or protest is required under any provision of this contract including Sections 3-4 Changed Conditions, 3-5 Disputed Work, 6-6.3 Payment for Delays to Contractor, 6-6.4 Written Notice and Report, or 6-7.3 Contract Time Accounting, unless the Contractor has complied with notice or protest requirements. The claims filed by the Contractor shall be in sufficient detail to enable the Engineer to ascertain the basis and amount of said claims. The Engineer will consider and determine the Contractor's claims and it will be the responsibility of the Contractor to furnish within a reasonable time such further information and details as may be required by the Engineer to determine the facts or contentions involved in its claims. Failure to submit such information and details will be sufficient cause for denying the claims. Payment for claims shall be processed within 30 calendar days of their resolution for those claims approved by the Engineer. The Contractor shall proceed with informal dispute resolution under Section 3-5, Disputed Work, for those claims remaining in dispute. 9-3.3 Delivered Materials. When provided for in the Specifications, and subject to the limitation and conditions therein, the cost of materials and equipment delivered but not incorporated into the Work will be included in the progress estimate. 9-3.3.1 Delivered Materials. The cost of materials and equipment delivered but not incorporated into the work will not be included in the progress estimate. 9-3.4 Mobilization. When a bid item is included in the Proposal form for mobilization and subject to the conditions and limitations in the Specifications, the costs of work in advance of construction operations and not directly attributable to any specific bid item will be included in the progress estimate. When no such bid item is provided, payment for such costs will be considered to be included in the other items of work. 9-3.4.1 Mobilization and Preparatory Work. Payment for mobilization and preparatory Work will be made at the stipulated lump-sum price bid therefore in the bid schedule and includes full compensation for furnishing all insurance, bonds, licenses, labor, materials, utilities, tools, equipment and incidentals, and for doing all the work involved in mobilization and preparatory work and operations, including, but not limited to, those necessary for the movement of personnel, equipment, supplies, and incidental to preparing to conduct work on and off the project site and other offsite facilities necessary for work on the project; for all other facilities, sureties, work and operations which must be performed or costs incurred prior to beginning work on various contract items on or off the project site, excepting those specifically paid for under separate sections of these specifications. Revised 5/01 /08 Contract No. 52011 (Industrial Park RW Service Lines) Page 102 of 139 The Contractor hereby agrees that the stipulated lump sum amount is sufficient for Mobilization and Preparatory Work, as described in this section, and that the Contractor shall have no right to additional compensation for Mobilization and Preparatory Work. Progress payments for Mobilization and Preparatory Work will be made as follows: i For the first progress payment (after the issuance of the Notice to Proceed), forty percent (40%) of the amount bid for Mobilization And Preparatory Work will be allowed. For the second progress payment, an additional sixty percent (60%) of the amount bid for mobilization and preparatory work will be allowed therefore. 9-4 BID ITEMS. Payment for each Bid Item shall be made at the quantity and type as listed in the Contractor's Proposal. All work shown or mentioned on the plans, in the Contract Documents, General Provisions, or Technical Provisions/Specifications shall be considered as included in the Bid Items. Contractor must protect existing utilities, improvements, landscaping, irrigation systems, and vegetation in place. If damaged during the work, Contractor is responsible to repair or replace any utilities, improvements, landscaping, irrigation systems, and vegetation at his expense. €5mW Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 103 of 139 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 2, CONSTRUCTION MATERIALS SECTION 200 - ROCK MATERIALS 200-1 ROCK PRODUCTS Add the following section: 200-1.2.2 Permeable Material. Permeable material shall consist of hard, durable, clean sand, gravel, or crushed stone, and shall be free from organic material, clay balls, or other deleterious substances. Class 1 and Class 2 permeable material shall have a Durability Index of not less than 40. Class 2 Permeable material shall have a Sand Equivalent value of not less than 75. Class 1 permeable material shall conform to the requirements in this section and Table 200-1.2.2(A). Class 2 permeable material shall conform to the requirements in this section and Table 200-1.2.2(6). When permeable material is required and the class or kind is not specified, Class 1 permeable material shall be used. The alternative gradings within Class 1 permeable material are identified by types. Unless otherwise shown on the plans the Contractor will be permitted to furnish and place any one of the types provided for this class. The percentage composition by mass of permeable material in place shall conform to the gradings in Tables 200-1.2.2(A) and 200-1.2.2(6). TABLE 200-1.2.2(A) CLASS 1 PERMEABLE MATERIAL Sieve Sizes 50-mm (2") 37.5-mm (1 V2") 19-mm (%") 12.5-mm (V2") 9.5-mm CV8") 4.75-mm (No. 4) 2.36-mm (No. 8) 75-um (no. 200) Percen Type A — — 100 95-100 70-100 0-55 0-10 0-3 tage Passing TypeB 100 95-100 50-100 — 15-55 0-25 0-5 0-3 TABLE 200-1.2.2(8) CLASS 2 PERMEABLE MATERIAL Sieve Sizes 25-mm(1") 19-mm CY4") 9.5-mm (*/„•) 4.75-mm (No. 4^ 2.36-mm (No. 8) 600-um (No. 30) 300-um (No. 50) 75-um (no. 200) Percentage Passing 100 90-100 40-100 25-40 18-33 5-15 0-7 0-3 200-2 UNTREATED BASE MATERIALS 200-2.1 General. Add the following: Aggregate base shall be Class 2 Aggregate 6ase per Caltrans Standard Specification, July 1999, Section 26: Aggregate Bases, Subsection 26-1.02A Class 2 Aggregate Base and as specified herein. 3 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 104 of 139 Add the following section: 200-2.7 Class 2 Aggregate Base. Aggregate for Class 2 aggregate base shall be free from organic matter and other deleterious substances, and shall be of such nature that it can be compacted readily under watering and rolling to form a firm, stable base. Aggregate may include material processed from reclaimed asphalt concrete, portland cement concrete, lean concrete base, cement treated base or a combination of any of these materials. Aggregate shall conform to the grading and quality requirements shown in the following tables. At the option of the Contractor, the grading for either the 11/2-inch maximum or 3/4 inch maximum shall be used, except that once a grading is selected it shall not be changed without the Engineer's written approval. AGGREGATE GRADING REQUIREMENTS Percentage Passing 11/2" Maximum 3/4" Maximum Operating Operating Sieve Sizes Range Range 2" 100 — 11/2" 90-100 — 1" — 100 3/4" 50-85 90-100 No. 4 25-45 35-60 No. 30 10-25 10-30 No. 200 2-9 2-9 QUALITY REQUIREMENTS Operating Tests Range Resistance (R-value) 78 Min. Sand Equivalent 25 Min. Durability Index 35 Min. The aggregate shall not be treated with lime, cement or other chemical material before the Durability Index test is performed. If the results of either or both the aggregate grading and Sand Equivalent tests do not meet the requirements specified for "Operating Range" but meet the "Contract Compliance" requirements, placement of the aggregate base may be continued for the remainder of that day. However, another day's work may not be started until tests, or other information, indicate to the satisfaction of the Engineer that the next material to be used in the work will comply with the requirements specified for "Operating Range." If the results of either or both the aggregate grading and Sand Equivalent tests do not meet the requirements specified for "Contract Compliance," the aggregate base which is represented by these tests shall be removed. However, if requested by the Contractor and approved by the Engineer, the aggregate base may remain in place and the Contractor shall pay to the City $2.25 per cubic yard for such aggregate base left in place. The City may deduct this amount from any moneys due, or that may become due, the Contractor under the contract. If both the aggregate grading and Sand Equivalent do not conform to the "Contract Compliance" requirements, only one adjustment shall apply- No single aggregate grading or Sand Equivalent test shall represent more than 500 cubic yards or one day's production, whichever is smaller. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 105 of 139 SECTION 201 - CONCRETE, MORTAR, AND RELATED MATERIALS 201-1 PORTLAND CEMENT CONCRETE TABLE 201-1.1.2(A) Modify as follows: TABLE 201-1.1.2(A)(3) PORTLAND CEMENT CONCRETE Type of Construction All Concrete Used Within the Right-of-Way Trench Backfill Slurry Street Light Foundations and Survey Monuments Traffic Signal Foundations Concreted-Rock Erosion Protection Concrete Class 330-C-23 (560-C-3250) (1) 115-E-3 (190-E-400) 330-C-23 (560-C-3250) 350-C-27 (590-C-3750) 310-C-17 (520-C-2500P) Maximum Slump mm (Inches) (2) 200 (8") 100 (4") 100 (4") per Table 300-1 1.3.1 (1) Except that concrete required to be of higher strength by Table 201-1.1.2(A) SSPWC shall be as per Table 201-1.1.2(A) SSPWC. (2) As per Table 201 -1.1.2(A) SSPWC. (3) Portions of Table 201-1.1.2(A) of the Standard Specifications for Public Works Construction not shown herein as changed are not affected by this table. 201-1.2 Materials. 201-1.2.4(a) Integral Colored Concrete. Add the following: Integral color shall consist of colored admixtures developed for use in ready mixed concrete. The product shall be made of the highest quality pigments, as well as other ingredients designed to enhance the color and improve the pigment dispersion, workability and finishing performance of the concrete. Integral color pigments shall meet or exceed ASTM-C-979. The coloring method shall be designed for concrete flatwork applications (salt finished, broom finishes, rotary finishes), as well as vertical surfaces, and other types of architectural concrete. Pigment shall be a permanent coloration, uniform throughout the concrete surface and interior, and shall be highly UV and fade resistant. Integral colored concrete shall be cured with QC Color Cure color matched to the concrete (see product information bulletin). Provide sample panel submittals of all colors to be used in the installation on identical surfaces for approval by Resident Engineer. Contractor shall provide a maintenance schedule for integral colored concrete. Admixture for all integral colored concrete paving in medians and other integral colored concrete shall be the following: Color: Color and Finish in accordance with the City of Carlsbad Landscape Manual. Curing: Scofield Colorcure Concrete Sealer (or approved equal). See Section 201 of these Supplemental Provisions for Concrete Curing Materials. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 106 of 139 Manufacturer: Scofield Chromix Admixtures for color-conditioned concrete, or approved equal L.M. Scofield Company 6533 Bandini Boulevard Los Angeles, CA 90040 1-800-800-9900 Admixture products and procedures for installation shall be in strict accordance with the manufacturer's specifications and recommendations, and those published by the American Concrete Institute (ACI) and the Portland Cement Association (PCA). 201-1.2.4 Chemical Admixtures, (e) Air-Entraining Admixtures. Substitute the following: The air content shall not deviate from the percentage specified or permitted by more than 1-1/2 percentage points. The air content of freshly mixed concrete will be determined by California Test Method No. 504. Add the following: 201-1.6 Finish: Random stone stamped pattern with heavy sandblast to match existing median paving. Add the following: 201 -1.7 Miscellaneous Concrete Finishing Products. 201-1.7.1 Water Base Penetrating Sealer for Integral Colored Concrete. (Scofield Colorcure Concrete Sealer or approved equal) Water base penetrating sealer shall be a sealer designed for the protection of imprinted and natural concrete. Water base penetrating sealer shall be a sealer designed for the protection of imprinted, colored and natural concrete, and other masonry surfaces to preserve the natural appearance of the masonry without darkening or adding gloss to the surface. It shall preserve the natural slip resistance of the concrete, etc. Sealer shall repel spills and soils, minimizing staining and maintenance. Seal shall leave no visible material on the surface and shall be absorbed and locked into the pores of the masonry, repelling liquids and soils but leaving the top surface natural in appearance. Install per manufacturer's directions. Seal shall be compatible with the surfaces and materials which it is applied. Concrete sealer shall conform to the following specifications: Color: Clear, non-yellowing Odor: Mild Flash Point: None (C.O.C. method) Specif icGrav.: 1.03 Density: 8.6 pounds per gallon Drying Time: 30 minutes to 60 minutes Cure Time: 24 to 48 hours VOC Content: None (0 g/l) excluding water Polymer Type: Proprietary Reactive Resin System Coverages (approximate): Smooth Concrete: 300 to 400 square feet per gallon Rough Concrete: 200 to 300 square feet per gallon Note: Coverages vary depending on porosity and condition of surface and method of application. Method of: Airless sprayer. Application A•^ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 107 of 139 Manufacturer: Scofield Chromix Admixtures for color-conditioned concrete, or approved equal L.M. Scofield Company 6533 Bandini Boulevard Los Angeles, CA 90040 1-800-800-9900 All materials shall be furnished, prepared, applied, cured, and stored according to the product manufacturer's direction. 201-1.2.4 Chemical Admixtures, (e) Air-entraining Admixtures. Substitute the following: The air content shall not deviate from the percentage specified or permitted by more than 1-1/2 percentage points. The air content of freshly mixed concrete will be determined by California Test Method No. 504. 201-3 EXPANSION JOINT FILLER AND JOINT SEALANTS. Add the following: 201-3.4 Type "A" Sealant (Two-Part Polyurethane Sealant). Add the following: All finished concrete surfaces shall have a Yz continuous expansion joint at locations indicated on the plans and notes and shall be located either parallel to perpendicular to the curb line. When not otherwise indicated, all expansion joints located adjacent to colored concrete shall be sealant Type "A" and colored to match the color of the concrete surface. Contractor shall provide joint sealants that have been produced and installed to establish and to maintain watertight and airtight continuous seals without causing staining or deterioration of joint substrates. Contractor shall submit product data from the manufacturer of each joint sealant product required, including instructions for joint preparation and joint sealer application. Contractor shall also submit samples for initial selection purposes in form of manufacturer's standard bead samples, consisting of strips of actual products showing full range of colors available, for each product exposed to view. Samples shall be submitted to Engineer. Submit complete schedule of type (and location where type is to be used) of each sealant. Contractor shall engage an experienced installer who has completed joint sealant applications similar in material, design and extent to that indicated for Project that have resulted in construction with a record of successful in-service performance. Provide joint sealants, joint fillers, and other related materials that are compatible with one another and with joint substrates under conditions of service and application, as demonstrated by sealant manufacturer based on testing and field experience. Provide color selections made by Engineer from manufacturer's full range of standard colors for products of type indicated. Sealant color parallel to curbline shall match color of Paving Treatment Type "A" as specified in Section 201-1.2.4(a) of these Special Provisions. Joint sealants shall be multi-component polyurethane sealant. Except as otherwise indicated, provide manufacturer's standard, non-modified, 2-or-more-part, polyurethane-based, elastomeric sealant; complying with either ASTM-C-920-87, Type M, Grade P, Class 25, or FS TT-S 0227E Class A, non-sag, Type II. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 108 of 139 Acceptable Products: "Sonneborn NPII"; Sonneborn Building Products Division; "Scofield Lithoseal Trafficalk 3-G", L.M. Scofield Company; or equivalent, as approved by the Engineer. Provide sealant backings of material and type that are nonstaining; are compatible with joint substrates, sealants, primers and other joint fillers; and are approved for applications indicated by sealant manufacturer based on field experience and laboratory testing. Plastic foam joint fillers shall be preformed, compressible, resilient, nonstaining, nonwaxing, nonextruding strips of flexible plastic foam either open-cell polyurethane foam or closed-cell polyethylene foam, subject to approval of sealant manufacturer, for cold-applied sealants only. Polystyrene foam is not acceptable. SECTION 203 - BITUMINOUS MATERIALS 203-6 ASPHALT CONCRETE. DELETE sections 203-6.2 and 203-6.3.2 and ADD the following: 203-6.1 General. Add the following: The Contractor shall submit a design mix report and verification data for review by the Engineer for each source of supply and type of mixture specified. The design mix report shall indicate the results of all testing requirements identified in sections 203-1.2 and 203-6.3 of the standard specifications for public works construction and these special provisions. 203-6.2 Materials. Add the following: Asphalt concrete shall be class C2-AR-4000 for surface course, and B-AR-4000 for base course. Asphalt concrete shall be class D2-AR-8000 for dikes and class E-AR-8000 ditches. 203-6.3.2 Composition and Grading. Add the following: Evaluation of asphalt concrete shall be determined from samples of asphalt concrete taken after completion of all processing (Wet Mix) or by core sample analysis of the in-place asphalt concrete or by direct central plant inspection that confirms the production of a particular mix design and verifies using samples of aggregate taken before the addition of asphalt and mineral filler (Bin). All samples shall be taken in accordance with Calif. Test 125. When Wet Mix or Core samples of asphalt concrete are to be used for evaluation, sufficient size samples shall be taken to ensure representative and adequate quantity of material for: 1. Asphalt Content and Gradation of Extraction using Calif. Test 382 or ASTM 2172, and Calif. Test 202. 2. Stability1 using: a. Stabilometer Value2 using Calif. Test 366 and shall be the average of three individual Stabilometer Values And/or b. Marshall Stability in accordance with the Asphalt Institute's MS-2 fabricated and tested for traffic volume and shall be the average of three specimens. Stability will be waived provided the extracted asphalt concrete is within +/-.5 of mix design and the extracted gradation complies with Table 203-6.3.2 (A). 2Use Marshall Stability when the deviation between individual Stabilometer Values are greater than +1-4. oRevised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 109 of 139 When using core sample analysis, the samples must be properly prepared to safeguard against influx of outside contaminates and so that the cut surfaces do not influence the test results. The amount of asphalt binder used in asphalt concrete placed in dikes, gutters, gutter flares, overside drains and aprons at the ends of drainage structures shall be increased one percent by mass of the aggregate over the amount of asphalt binder determined for use in asphalt concrete placed on the traveled way. 203-6.3.3 Acceptance. Wet Mix or Core sampled asphalt concrete will be considered in conformance with the mix design when the asphalt content is within +I-.5 of the design mix and the gradation conforms to the grading as shown in Table 203-6.3.2 (A). Deviations in gradation may be considered in conformance with the mix design provided the stability of the completed mix complies with the requirements for Stabilometer Value per Table 203-6.3.2 (A) Marshall Stability using Asphalt Institute MS-2. Plant inspected asphalt concrete will be considered in conformance with the mix design when visually inspected and the combined gradation of the Bin samples show conformance to the grading as shown in Table 203-6.3.2 (A). 203-6.6.2, Batch Plant Method, modify as follows: Third paragraph, last sentence, delete "and from the Engineer's field laboratory". Last paragraph, add after D 2172: "method A or B." 203-6.7 Asphalt Concrete Storage, add the following: Open graded asphalt concrete stored in excess of 2 hours, and any other asphalt concrete stored in excess of 18 hours, shall not be used in the work. 203-11 ASPHALT RUBBER HOT MIX (ARHM) WET PROCESS 203-11.3 Composition and Grading. Add the following: Asphalt Rubber Hot Mix shall be class ARHM-GG-C. Add the following section: 203-13 ASPHALT PAVEMENT CRACK SEALANTS 203-13.1 Elastomeric Sealant. Elastomeric sealant shall be a polyurethane material of a composition that will, within its stated shelf life, cure only in the presence of moisture. No elastomeric sealant shall be incorporated into any portion of the work that is beyond the shelf life recommended by its manufacturer. No elastomeric sealant shall be incorporated into any portion of the work that has been stored under conditions not recommended by its manufacturer. Sealant shall be suitable for use in both asphalt concrete and portland cement concrete. The cured sealant shall have the performance characteristics in Table 203-13(A). Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 110 of 139 TABLE 203-13.1 (A) ELASTOMERIC SEALANT CHARACTERISTICS Property Hardness (indentation) Tensile Strength Elongation Flex at -40°C Weathering Resistance Salt-Spray Resistance Dielectric Constant Measuring Standard (ASTM Designation) ASTM D 2240 Rex. Type A, Model 1700 ASTM D 41 2 Die C, ASTM D 41 2 Die C, 0.6 mm (25 mil) Free Film Bend (180°) ASTM D 822 Weatherometer 350 h ASTM B 117 28 days at 38°C ASTM D 150 Results 65-85 3.45 MPa, minimum 400%, minimum No cracks Slight chalking 3.45 MPa, minimum tensile; 400% minimum Elongation Less than 25% change Conditions 25°C @ 50% relative humidity pulled at 508 mm (20") per minute pulled at 508 mm (20") per minute over 13 mm (V2") Mandrel Cured 7 days at 25°C @ 50% relative humidity 5% NaCI, Die C, pulled at 508 mm (20") per minute over a temperature range of -30^C to 50-^C 203-13.2 Asphaltic Emulsion Sealant. Asphaltic emulsion sealant shall conform to the State of California Specification 8040-41A-15 and shall be used only for filling slots in asphalt concrete pavement. This material shall not be used in slots which exceed 16 mm (5/8") in width or where the slope causes the material to run from the slot. The material shall not be thinned in excess of the manufacturer's recommendations and shall not be placed when the air temperature is less than 7°C (45T). 203-13.3 Hot-Melt Rubberized Asphalt Sealant. Hot-melt rubberized asphalt shall be in solid form at room temperature and fluid at an application temperature of 190°C (375°F) to 205°C (400°F). Fumes from the material shall be non-toxic. Sealant shall be suitable for use in both asphalt concrete and portland cement concrete. Performance characteristics of the cured hot-melt rubberized asphalt shall be as per Table 203-13.3(A). TABLE 203-13.3(A) CURED HOT-MELT RUBBERIZED ASPHALT Property Cone Penetration Flow, 60°C Resilience Softening Point, Ductility, Flash Point, COC, °C Viscosity, Brookfield Thermosel, Measuring Standard (ASTM Designation) ASTM D 3407, Sec. 5 ASTM D 3407, Sec. 6 ,ASTM D 3407, Sec. 8 ASTM D 36 ASTM D 113 ASTM D 92 ASTM D 4402 Results 3.5 mm, max. 5 mm, max. 25%, min. 82 °C, min. 300 mm, min. 288 °C, min. 2.5-3.5 Pa-s Conditions 25°C, 150g, 5s 25°C 25°C, 50 mm/min No. 27 Spindle, 20 rpm, 190°C, Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 111 of 139 SECTION 204 - LUMBER AND TREATMENT WITH PRESERVATIVES 204-1 LUMBER AND PLYWOOD TABLE 204-1.2(A) add the following: TABLE 204-1.2(A) USES Headers for bituminous pavement up to 50 mm x 100mm (2"x4") Headers for bituminous pavement larger than 50 mm x 100 mm (2"x4") GRADES Construction grade Redwood or preservative treated construction grade Douglas Fir Number 1 grade Redwood, or preservative treated number 1 grade Douglas Fir SECTION 206 - MISCELLANEOUS METAL ITEMS Add the following section: 206-7 TRAFFIC SIGNS. Add the following section: 206-7.1 Permanent Traffic Signs. Permanent traffic signs shall consist of 10-gage and 12-gage cold-rolled steel perforated tubing. This includes all signs used for the direction, warning, and regulation of vehicle (including bicycle) and pedestrian traffic upon the completion of the Work unless otherwise shown on the plans. Add the following section: 206-7.1.1 General. Materials, legend, proportion, size, and fabrication of all signs used for the direction, warning, and regulation of vehicle (including bicycle) and pedestrian traffic shall conform to the requirements of "SPECIFICATIONS FOR REFLECTIVE SHEETING SIGNS, October 1993", Sheets 1 through 5 that accompany "SPECIFICATIONS FOR REFLECTIVE SHEETING SIGNS, October 1993" of dimensions and details, dated April 1987, and "OPAQUE COLOR CHART", dated February 1980, all published by the State of California, Department of Transportation, Division of Procurement Services, Office of Material Operations, 1900 Royal Oaks Drive, Sacramento, CA 95819 and as modified herein. Where the "SPECIFICATION FOR REFLECTIVE SHEETING SIGNS, October 1993" require the Contractor or supplier to notify the Department of Transportation or to certify compliance to said SPECIFICATIONS, to provide a quality control program or to allow testing, approval, observation of manufacturing or assembly operations by the State of California, Department of Transportation and/or its employees or officials, such rights shall be vested in the Engineer. Add the following section: 206-7.1.2 Sign Identification. Modify the "SPECIFICATIONS FOR REFLECTIVE SHEETING SIGNS, October 1993" as follows: Sign identification shall be as per "SPECIFICATIONS FOR REFLECTIVE SHEETING SIGNS, October 1993", except that the notation shall be "PROPERTY OF THE CITY OF CARLSBAD". Add the following section: 206-7.1.3 Drawings. Modify the "Specifications For Reflective Sheeting Signs, October 1993" as follows: Standard signs shall be as per the most recently approved "Approved Sign Specification Sheets" of the State of California, Department of Transportation. The date of approval shall be the date most closely preceding the date of manufacture of the sign(s) or the date of the "Notice to Proceed" of this contract, whichever is most recent.o Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 112 of 139 Add the following section: 206-7.1.4 Reflective Sheeting. Modify the "Specifications For Reflective Sheeting Signs, October 1993" as follows: All advisory signs, warning signs and all regulatory signs shall be fabricated with Type III encapsulated lens sheeting conforming to the requirements of this specification. Add the following section: 206-7.1.5 Substrate. Modify the "Specifications For Reflective Sheeting Signs, October 1993" as follows: All permanent traffic signs used for the direction, warning, and regulation of vehicle (including bicycle) and pedestrian traffic shall use aluminum substrate. Add the following section: 206-7.1.6 Mounting Traffic Signs. Traffic signs shall be installed on 10-gage or 12-gage cold- rolled steel perforated tubing posts as shown on San Diego Regional Standard drawing M-45 or, when the sign area exceeds the maximum area allowed for on that drawing, on multiple 10-gage or 12-gage cold-rolled steel perforated tubing posts. The number of posts shall be determined by the parameters in SDRS drawing M-45 or as approved by the Engineer. Traffic signs will be provided with back braces and mounting blocks as approved by the Engineer consisting of 10-gage or 12-gage cold-rolled steel perforated tubing when multiple posts are used. Add the following section: 206-7.1.6 Traffic Sign Posts. Posts shall be constructed of 10-gage or 12-gage cold-rolled steel perforated tubing posts as shown on San Diego Regional Standard drawing M-45. Add the following section: 206-7.2 Temporary Traffic Signs. Temporary traffic signs shall consist of all signs used for the direction, warning, and regulation of vehicle (including bicycle) and pedestrian traffic during the Contractor's performance of the Work. Temporary traffic signs include both stationary and portable signs. Add the following section: 206-7.2.1 General. Materials, legend, proportion, size, and fabrication of all temporary traffic signs used for the direction, warning, and regulation of vehicle (including bicycle) and pedestrian traffic shall conform to the requirements of "Specifications For Reflective Sheeting Signs, October 1993", Sheets 1 through 5 that accompany "Specifications For Reflective Sheeting Signs, October 1993" of dimensions and details, dated April 1987, and "OPAQUE COLOR CHART', dated February 1980, all published by the State of California, Department of Transportation, Division of Procurement Services, Office of Material Operations, 1900 Royal Oaks Drive, Sacramento, CA 95819 and as modified herein. Where The "Specification For Reflective Sheeting Signs, October 1993" require the Contractor or supplier to notify the Department of Transportation or to certify compliance to said "Specifications For Reflective Sheeting Signs, October 1993", to provide a quality control program or to allow testing, approval, observation of manufacturing or assembly operations by the State of California, Department of Transportation and/or its employees or officials, such rights shall be vested in the Engineer. Add the following section: 206-7.2.2 Drawings. Modify the "Specifications For Reflective Sheeting Signs, October 1993" as follows: Standard temporary traffic signs shall be as per the most recently approved "Approved Sign Specification Sheets" of the State of California, Department of Transportation. The date of approval shall be the date most closely preceding the date of manufacture of the sign(s) or the date of the "Notice to Proceed" of this contract, whichever is most recent. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 113 of 139 Add the following section: 206-7.2.3 Reflective Sheeting. Modify the "Specifications For Reflective Sheeting Signs, October 1993" as follows: All advisory signs, warning signs and all regulatory signs shall be fabricated with Type III encapsulated lens sheeting conforming to the requirements of this specification. Add the following section: 206-7.2.4 Substrate. Modify the "Specifications For Reflective Sheeting Signs, October 1993" as follows: Excepting only construction warning signs used at a single location during daylight hours for not more than five (5) consecutive days, all signs used for the direction, warning, and regulation of vehicle (including bicycle) and pedestrian traffic shall be stationary mounted and shall use aluminum substrate. Add the following section: 206-7.2.5 Stationary Mounted Temporary Traffic Signs. Stationary mounted temporary traffic signs shall be installed on 10-gage and 12-gage cold-rolled steel perforated tubing posts in the same manner shown on the State of California, Department of Transportation "Standard Plans" 1995 edition standard plans numbers RS1, RS2, RS3 and RS4 for installation of roadside signs, except as follows: a) Wood posts shall not be used. b) Back braces and blocks for sign panels will not be required. c) The height to the bottom of the sign panel above the edge of traveled way shall be at least 2.1 m (7'). d) Unless otherwise shown on the plans traffic sign posts shall conform in materials and installation to SDRS drawing M-45 and shall have one post provided for each 0.48 m2 (5ft2)of sign area, or the signs may be installed on existing lighting standards when approved by the Engineer. e) Sign panels mounted on temporary traffic sign posts shall conform to the requirements specified for aluminum signs in the "Specifications For Reflective Sheeting Signs, October 1993". Add the following section: 206-7.2.6 Temporary Traffic Sign Posts. Posts shall be 10-gage or 12-gage cold-rolled steel perforated tubing used for the support and stabilization of stationary mounted temporary signs. Post size and number of posts shall be as shown on the plans, except that when stationary mounted signs are installed and the type of sign installation is not shown on the plans, post size and the number of posts will be determined by the Engineer. Sign panels for stationary mounted signs shall consist of reflective sheeting applied to a sign substrate. Add the following section: 206-7.2.7 Portable Temporary Traffic Signs. Each portable temporary traffic sign shall consist of a base, standard or framework and a sign panel. The units shall be capable of being delivered to the site of use and placed in immediate operation. Sign panels for portable signs shall conform to the requirements of sign panels for stationary mounted signs in the "Specifications For Reflective Sheeting Signs, October 1993, or shall be cotton drill fabric, flexible industrial nylon fabric, or other approved fabric. Fabric signs shall not be used during the hours of darkness. Size, color, and legend requirements for portable signs shall be as described for stationary mounted sign panels in section 206-7.2 of these Supplemental Provisions. The height to the bottom of the sign panel above the edge of traveled way shall be at least 0.3-m (12"). All parts of the sign standard or framework shall be finished with 2 applications of orange enamel which will match the color of the sign panel background. Testing of paint will not be required. oRevised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 114 of 139 Add the following section: 206-8 LIGHT GAGE STEEL TUBING AND CONNECTORS. Add the following section: 206-8.1 General. This Section pertains to 10-gage and 12-gage cold-rolled steel perforated tubing used for the support and stabilization of signs. All shapes shall have a galvanized finish and shall be cold-roll-formed steel conforming to ASTM Designation A-446, Grade A. Galvanizing shall conform to ASTM A-525, Designation G-90. Galvanizing shall be performed after all forming and punching operations have been completed. Cold-rolled steel perforated tubing shall be perforated on all four faces with 11mm (7/16") holes on 25 mm (1") centers. Add the following section: 206-8.2 Tolerances. Wall thickness tolerance shall not exceed +0.28 mm, -0.13 mm (+0.011", -0.005"). Convexity and concavity measured in the center of the flat side shall not exceed a tolerance of +0.25 mm (+0.010") applied to the specific size determined at the corner. Straightness tolerance variation shall not exceed 1.6 mm in 1 m (1/16 " in 3'). Tolerance for corner radius is 4.0mm (5/32"), plus or minus 0.40 mm (1/64"). Weld flash on corner-welded square tubing shall permit 3.60 mm (9/64") radius gage to be placed in the corner. Using 10-gage or 12-gage square tube, consecutive size tubes shall telescope freely for 3.1m (10'). Tolerance on hole size is plus or minus 0.40 mm (1/64") on a size. Tolerance on hole spacing is plus or minus 3.2 mm in 6.1 m (1/8" in 20'). In addition, for the following specific sizes of light gage steel tubing, dimensional tolerances shall not exceed those listed in tables 206-8.2 (A) and 206-8.2(8). TABLE 206-8.2(A) LIGHT GAGE STEEL TUBING SIZE TOLERANCE Nominal Outside Dimensions mm (inches) 25x25 32x32 38x38 44x44 51x51 56x56 57x57 64x64 51 x76 (1x1) (1V4X174) (1V2X172) (1%x1%) (2x2) (23/16 x 2*/16) (2Y4x274) (2V2x272) (2x3) Outside Tolerance for All Sides at Corners mm (inches) 0.13 0.15 0.15 0.20 0.20 0.25 0.25 0.25 0.25 0.005 0.006 0.006 0.008 0.008 0.010 0.010 0.010 0.010 TABLE 206-8.2(6) LIGHT GAGE STEEL TUBING SQUARENESS OF SIDES AND TWIST Nominal Outside Dimension mm (Inches) 25x25 32x32 38x38 44x44 51x51 56x56 57x57 64x64 51x76 (1 x1) (1-1/4x1-1/4) (1-1/2x1-1/2) (1-3/4x1-3/4) (2x2) (2-3/16x2-3/16) (2-1/4x2-V4) (2-1/2x2-V2) (2x3) Squareness(1) mm (Inches) 0.15 0.18 0.20 0.25 0.30 0.36 0.36 0.38 0.46 0.006 0.007 0.009 0.010 0.012 0.014 1.014 0.015 0.018 Twist Permissible in 900 mm (3") mm(2) (lnches)(2) 1.3 1.3 1.3 1.6 1.6 1.6 1.6 1.9 1.9 0.050 0.050 0.050 0.062 0.062 0.062 0.062 0.075 0.075 Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 115 of 139 (n) Tubing may have its sides failing to be 90 degrees to each other by the tolerance listed. (Z) Twist is measured by holding down the edge of one end of a square tube on a surface plate with the bottom side of the tube parallel to the surface plate, and noting the height that either corner on the opposite end of the bottom side is above the surface plate. Add the following section: 206-8.3 Fasteners. Fasteners used to assemble cold-rolled steel perforated tubing shall be steel "pull-through" electrogalvanized rivets with 9.5 mm (3/8") diameter shank, 22 mm (7/8") diameter head, and a grip range of from 5 mm (0.200") to 0.90 mm (0.356"). The fasteners shall conform to ASTM B-633, Type III Add the following section: 206-9 PORTABLE CHANGEABLE MESSAGE SIGN Add the following section: 206-9.1 General. Each portable changeable message sign (PCMS) unit shall consist of a controller unit, a power supply, and a structural support system all mounted on a trailer. The PCMS unit shall be assembled to form a complete self-contained portable changeable message sign, which can be delivered to the site of the work and placed in immediate operation. The complete PCMS unit shall be capable of operating in an ambient air temperature range of -20°C (-4°F) to +70°C (158°F) and shall not be affected by unauthorized mobile radio transmissions. The trailer shall be equipped so that it can be leveled and plumbed. Full operation height shall be with the bottom of the sign at least 2.1 m (71) above the ground and the top no more than 4.4 m (14.5') above the ground. After initial placement, PCMS shall be moved from location to location as directed by the Engineer Add the following section: 206-9.2 Message Board. The message displayed on the PCMS shall be visible from a distance of 460 m (1500') and shall be legible from a distance of 230 m (750'), at noon on a cloudless day, by persons with vision corrected to 20/20. The sign panel shall be 3-line matrix and shall display not less than 7 characters per line. Sign messages to be displayed shall be as approved by the Engineer. The sign face shall be flat black and shall be protected from glare of the sun by a method which does not interfere with the clarity of the sign message. The sign shall be raised and lowered by means of a power driven lifting mechanism. The matrix sign shall be capable of complete alphanumeric selection. Lamp matrix type signs shall be equipped with an automatic dimming operational mode that automatically compensates for the influence of a temporary light source or other abnormal lighting conditions. The sign shall have manual dimming operation modes of 3 or more different lamp intensities. Matrix signs not utilizing lamps shall be either internally or externally illuminated at night. The controller shall be an all solid-state unit containing all the necessary circuitry for the storage of at least 5 pre-programmed messages. The controller shall be installed in a location allowing the operator to perform all functions from one position. A keyboard entry system shall be provided to allow an operator to generate an infinite number of additional messages over the pre-programmed stored messages. The keyboard shall be equipped with a security lockout feature to prevent unauthorized use of the controller. The controller shall contain a nonvolatile memory to hold the keyboard created messages in memory during periods when the power is not activated. The controller shall provide for a variable message display rate which allows the operator to match the information display to the speed of the approaching traffic. The flashing off time shall be operator adjustable within the control cabinet. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 116 of 139 Add the following section: 206-9.3 Operation and Maintenance. PCMS shall be furnished, placed, operated, and maintained at locations shown on the plans, specified herein, or designated by the Engineer. The PCMS will be diligently maintained and repaired by the Contractor throughout the project in accordance with the manufacturer's recommendations. When ownership is transferred to the City (at the end of the job), it must be demonstrated to be in good working condition, and meet the provisions of these specifications, including current registration. Add the following section: 206-9.4 Measurement and Payment. The contract unit price PCMS shall include full compensation for furnishing all labor, materials, tools, equipment and incidentals, and for doing all the work involved in furnishing, placing, operating, maintaining, repairing, replacing, transporting from location to location, and delivery of the signs to the City at the completion of the construction, in good working order, and as directed by the Engineer, and no other compensation will be made. SECTION 207 - PIPE 207-2 REINFORCED CONCRETE PIPE. 207-2.5 Joints. Add the following: When watertight joints are indicated on the plans they shall be of the rubber-gasketed type meeting the requirements of ASTM Standard Specification designations C 361-95 and C 443-94. Pipe designated in the plans as "pressure pipe" or with a 100-year hydraulic grade line at or above the soffit shall be bell and groove spigot joint with "O" rings conforming to ASTM C-443 and C-361 for the limits shown on the plans. 207-9 IRON PIPE AND FITTINGS 207-9.2.2 Pipe Joints Unless otherwise shown on the Plans, all joints shall be the push-on type joint. Joints and accessories shall conform to the requirements and dimensions specified in ANSI A21.11, AWWA C111. Rubber gasket material shall conform to 208-1.2 and AWWA C111 and ANSI A21.11-90. 207-9.2.3 Fittings. Add the following: Ductile iron pipe and fittings shall be manufactured in accordance with ANSI 21.50, AWWA C150 and ANSI 21.51, AWWA C151, and shall be of the size and thickness classes shown on the Plans. Unless otherwise specified, size 4-inches through 6-inches DIP shall be thickness Class 52, while size 8-inches and larger shall be thickness Class 50. 207-9.2.4 Lining and Coating. Replace with the following: Unless otherwise specified, all iron pipe and fittings shall be lined with double thickness, cement motor lining with cement conforming to ASTM C150 Type II, AWWA C104/A21.4.90 and outside coating of bituminous coating a minimum of 2 mils, thick in accordance with AWWA C151 or C100. 207-10 STEEL PIPE add the following: 207-10.1 General Fabricated Steel Pipe and Fittings shall conform in all respects to Carlsbad Municipal Water District Rules and Regulations for Construction of (Potable or Reclaimed) Water Mains, latest edition. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 117 of 139 207-10.1.2 Submittals. The Contractor shall furnish submittals in accordance with Section 2-5.3, Submittals Shop Drawings. Submittals are required for the following: Shop Drawings Manufacturer's tests Fabrication Details Protective Coatings Layout Drawings Mill Reports or Plant Test Reports Dimensional Checks Welding Procedures/Certification for Field Welding Shop Drawings shall be submitted and approved prior to manufacture of pipe. 207-10.1.3 Quality Assurance. Field welders shall be certified under Section IX, Part A of the ASME Boiler and Pressure Vessel Code or in accordance with AWWA C206, Section 3. Welders shall submit a copy of their certification to the District prior to performing any field welding. Certifications shall be dated within three (3) years of the job to be performed. The top of all pipe and specials shall be clearly identified by marking the top with "T.O.P." for easy identifications in the field. Plainly mark each length of pipe at the bell end to identify the proper location of the pipe item by reference to the layout schedule. 207-10.1.4 Protective Coatings and Linings. All steel pipe and fittings exposed within a vault or above ground shall be cement-mortar lined in accordance with AWWA C205 and C602 and painted in accordance with CMWD Approved Materials List. All steel pipe and fittings for underground service shall be cement-mortar lined, taped wrapped and cement-mortar coated in accordance with AWWA C205, C214 and C602 unless otherwise specified on the Drawings. Add the following section: 207-25 UNDERGROUND UTILITY MARKING TAPE. Add the following section: 207-25.1 Detectable Underground Utility Marking Tape: Detectable Underground Utility Marking Tape shall have a minimum 0.13 mm (0.005") overall thickness, with no less than a 35 gauge (AWG), 0.14 mm aluminum foil core. The foil must be visible from both sides. The layers shall be laminated together with the extrusion lamination process, not adhesives. No inks or printing shall extend to the edges of the tape. All printing shall be encased to avoid ink rub-off. Detectable Underground Utility Marking Tape shall conform to the properties listed in Tables 207-25(A) and 207-25 (B). TABLE 207-25.1 (A) DETECTABLE UNDERGROUND UTILITY MARKING TAPE PROPERTIES Property Thickness Tensile strength Elongation Printability Flexibility Inks Message repeat Foil Top layer Method ASTM D2103 ASTM D882 ASTM D882-88 ASTM D2578 ASTM D671-81 Manufacturing specifications Manufacturing specifications Manufacturing specifications Manufacturing specifications Value 01 14 mm (0.0056") 4500g/cm (25 Ibs/inch) (5,500 PSI) <50 percent at break >50 dynes/square centimeter Pliable hand Heat-set Mylex Every 500 mm(20") Dead soft/annealed Virgin PET Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 118 of 139 Property Bottom layer Adhesives Bond strength Colors Method Manufacturing specifications Manufacturing specifications Boiling H2O at 100 degrees Celsius APWA Code Value Virgin LDPE >30 percent, solid 1.5#/R Five hours without peel See Table 207-25.1 (B) TABLE 207-25.1(6) DETECTABLE UNDERGROUND UTILITY MARKING TAPE COLORS Color Red Yellow Orange Blue Green Brown Purple Utility Marked Electric power, distribution, transmission, and municipal electric systems. Gas and oil distribution and transmission, dangerous materials, product and steam. Telephone and telegraph systems, police and fire communications, and cable television. Water systems. Sanitary and storm sewer systems, nonpotable. Force mains. Reclaimed water lines. Add the following section: 207-25.2 Materials Approvals. Detectable Underground Utility Marking Tape shall meet the requirements of each of the following agency/association publications. A. Department of Transportation, Materials Transportation Bureau, Office of Pipeline Safety. USAS code for pressure piping B31.8, paragraph 192.321 (e). B. National Transportation Safety Board, Washington, DC, Special Study Prevention of Damage to Pipelines. Adopted June 7, 1974. Report NTSB-PSS-73-1. C. American Petroleum Institute (API). Recommended practice for marking buried liquid petroleum pipelines - APR RP 1109. D. General Services Administration, Washington, DC, Public Buildings Service Guide Specification for Mechanical and Electrical Equipment - PBS 4-1501, Amendment 2, Page 501-14, Paragraph 18, Subparagraph 18.1, Clause 18.1.1. E. Rural Electrification Authority (REA), U.S. Department of Agriculture, Washington, DC, National Electrical Safety Code for Underground Construction for remote and immediate hazards. SECTION 209 - ELECTRICAL COMPONENTS 209 ELECTRICAL COMPONENTS. Modify as follows: Section 209, "Signals, Lighting and Traffic Electrical Systems", herein, shall replace Section 209, "Electrical Components", of the SSPWC in all matters pertaining to the specifications for measurement, payment, warranty, and materials and methods of construction for all elements of street lighting and traffic signals. For electrical components provided and installed in systems not including street lighting and traffic signals section 209 SSPWC is unmodified except as specified in sections other than section 209, "Signals, Lighting and Electrical Systems", herein. For section 209, "Signals, Lighting and Traffic Electrical Systems", for all elements of street lighting and traffic signals both construction materials and construction methods have been combined into a single section. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 119 of 139 SECTION 210 - PAINT AND PROTECTIVE COATINGS 210-1 PAINT. 210-1.5 Paint Systems. Add the following to Table 210-1.5(A) TABLE 210-1.5 (A) Surface to be Painted Temporary Railing type (K) Pre-reatment / Surface Preparation Abrasive Blast Cleaning to a Roughened, Textured Appearance Primer None Finish Coats Two coats white Acrylic Emulsion Paint (1) (1) acrylic emulsion paint designed for use on exterior masonry. This paint shall comply in all respects to Federal Specification TT-P-19 (latest revision), Paint, Acrylic Emulsion, Exterior. This paint may be tinted by using "universal" or "all purpose" concentrates. 210-1.6 Paint for Traffic Striping, Pavement Marking, and Curb Marking. Modify as follows: Paint for traffic lane lines, turn pocket lines, edge lines, channelizing lines, bike lane lines, chevrons, and curbs shall be rapid dry water borne conforming to CALTRANS Specification No. PTWB-01. Paint for pavement legends, pavement symbols, pavement arrows, cross walks, parking stall markings and stop bars shall be alkyd thermoplastic conforming to CALTRANS Specification No. 8010-19A. Glass beads shall be applied to the surface of the rapid dry water borne paint and the molten thermoplastic material and shall conform to the requirements of CALTRANS Specification No. 8010-004 (Type II). CALTRANS Specifications for water borne paint, thermoplastic material and glass beads may be obtained from the CALTRANS Transportation Laboratory, P.O. Box 19128, Sacramento, CA 95819, telephone number (916) 227-7000. 210-3 GALVANIZING. Add the following section: 210-3.6 Galvanizing for Traffic Signal Facilities. The requirements of this section shall pertain only to the preparation and galvanizing of traffic signal facilities. Galvanizing of products fabricated from rolled, pressed and forged steel shapes, plates, bars and strip 3.2 mm (1/8") thick or thicker, shall conform to the specifications of ASTM Designation: A 123, except that complete seal welding of tightly contacting surfaces of these products prior to galvanizing is required only where seal welding is shown on the plans or specified in these special provisions. Except for pre-galvanized standard pipe, galvanizing of material 3.2 mm (1/8") thick or thicker shall be performed after fabrication into the largest practical sections. At the option of the Contractor, material thinner than 3.2 mm (1/8") shall be galvanized either before fabrication in conformance with the requirements of ASTM Designation: A 525M, Coating Designation Z600, or after fabrication in conformance with the requirements of ASTM Designation: A 123, except that the weight of zinc coating shall average not less than 365 g per square meter (1.2 oz. per ft2) of actual surface area with no individual specimen having a coating weight of less than 305 g per square meter (1.0 oz. per ft2). Galvanizing of standard pipe shall conform to the requirements of ASTM Designation: A 53. Galvanizing will not be required for stainless steel, monel metal and similar corrosion resistant parts. Fabrication shall include all operations such as shearing, cutting, punching, forming, drilling, milling, bending, welding and riveting. All welded areas shall be thoroughly cleaned prior to galvanizing to remove all slab or other material that would interfere with the adherence of the zinc. When it is Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 120 of 139 necessary to straighten any sections after galvanizing, the work shall be performed without damage to the zinc coating. Galvanizing of iron and steel hardware and nuts and bolts, when specified or shown on the plans, shall conform to the specifications of ASTM Designation: A 153, except whenever threaded studs, bolts, nuts, and washers are specified to conform to ASTM Designation: A 307, A 325, A 325M, A 449, A 563, A 563M, or F 436 and zinc coating is required, they shall be hot-dip zinc coated or mechanically zinc coated in accordance with the requirements of the ASTM Designations. Unless otherwise specified, galvanizing shall be performed after fabrication. Components of bolted assemblies shall be galvanized separately before assembly. Tapping of nuts or other internally threaded parts to be used with zinc coated bolts, anchor bars or studs shall be done after galvanizing and shall conform to the requirements for thread dimensions and overlapping allowances in ASTM Designation: A 563 or A 563M. When specified, painting of zinc coated surfaces shall be in accordance with the procedures in Section 210.1 "Paint". Galvanized surfaces that are abraded or damaged at any time after the application of the zinc coating shall be repaired by thoroughly wire brushing the damaged areas and removing all loose and cracked coating, after which the cleaned areas shall be painted with two applications of unthinned zinc-rich primer (organic vehicle type) conforming to the provisions in Section 210-3.5, "Repair of Damaged Zinc Coating." Aerosol cans shall not be used. SECTION 213 - ENGINEERING FABRICS 213-2 GEOTEXTILES. 213-2.1 General. Table 213-2.1 (A) Add the following: Geotextile types shall be used for the applications listed in Table 213-2.1 (A) GEOTEXTILE APPLICATIONS Application of Geotextile Separation of Soil and Street Structural Section Separation of Soil and Subsurface Aggregate Drain Reinforcement of Street Structural Section Remediation and Separation of Soil Reinforcement of Soil Drainage at the Interface of Soil Structures Drainage at the Interface of Soil and Structures Rock Slope Protection Fabric for Rock Sizes Below 225 kg(1/4Ton) Rock Slope Protection Fabric for Rock Sizes Including and Above 225 kq (!4 Ton) Plant Protection Covering Erosion Control Fence with 14 AWG - 150 mm x 150 mm (6"x6") Wire and 3 m (10') Post Spacing Erosion Control Fence with 1.8 m (61) Post Spacing and Fencing No Wire Type Designation 90WS 180N 200WS 270WS 270WS N/A N/A 180N 250N 90N 90WS 200WS Add the following section: 213-3 EROSION CONTROL SPECIALTIES. Add the following section: 213-3 Gravel bags. Gravel bags for the use of temporary erosion control shall be burlap type, filled with no less than 23kg (50 Ibs) of 19 mm (3/4") crushed rock and securely tied closed. Plastic bags are not acceptable. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 121 of 139 SECTION 214 PAVEMENT MARKERS 214-5 REFLECTIVE PAVEMENT MARKERS Add the following section: 214-5.1 Temporary Reflective Pavement Markers. Temporary pavement markers shown on the plans and required in the specifications shall be one of the types shown in Table 214-5.1(A), or equal thereto. TABLE 214-5.1 (A) TEMPORARY REFLECTIVE PAVEMENT MARKERS o Type TFPM Manufacturer of Distributor DAPCO Davidson Plastics Company, 18726 East Valley Highway, Kent, Washington 98032, Telephone (206) 251-8140. Add the following section: 214-5.2 Permanent Reflective Channelizer. Reflective Channelizer shall be new surface-mounted type and shall be furnished, placed, and maintained at the locations shown on the plans. Reflective Channelizer posts shall be orange in color. Reflective channelizers shall have affixed white reflective sheeting as specified in the special provisions. The reflective sheeting shall be 75 mm x 300 mm in size. The reflective sheeting shall be visible at 300 m at night under illumination of legal high beam headlights, by persons with vision of or corrected to 20/20. Reflective Channelizer shall be one of the types shown in Table 214-5.2(A), or equal thereto. TABLE 214-5.2(A) REFLECTIVE CHANNELIZER Type Safe-Hit SH236MA Carsonite "Super Duck" SDF-436 Repo 'The Replaceable Post" Manufacturer of Distributor Safe-Hit Corporation 1930 West Winton Avenue, Building Hayward, CA 94545 Telephone (415) 783-6550 #11 Carsonite International Corporation 2900 Lockheed Way Carson City, NV 89701 Telephone (702) 883-5104 Western Highway Products P.O. Box 7 Stanton, CA 90680 Telephone (800) 422-4420 The Contractor shall provide the Engineer with a Certificate of Compliance in accordance with the provisions of Section 2-5.3.3 "Submittals". Said certificate shall certify that the permanent reflective channelizers comply with the plans and specifications and conform to the prequalified design and material requirements approved by the engineer and were manufactured in accordance with the approved quality control program. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 122 of 139 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 3, CONSTRUCTION METHODS SECTION 301 - TREATED SOIL, SUBGRADE PREPARATION AND PLACEMENT OF BASE MATERIALS 301-1 SUBGRADE PREPARATION. 301-1.2 Preparation of Subgrade. Modify the second and third paragraphs as follows: Change each instance reading "150mm (6 inches)" to "300 mm (12")". 301-1.3 Relative Compaction. Delete the first paragraph and substitute the following: The Contractor shall compact the upper 300 mm (12") of subgrade beneath areas to be paved, have base or subbase material placed on them, or curb, gutter, curb and gutter, alley pavement, driveway or sidewalk constructed over them to no less than 95 percent maximum dry density as determined by ASTM test D-1557-91. 301-1.7 Payment. Modify the first paragraph as follows: Payment for subgrade preparation shall be included in the contract bid price for which the subgrade is prepared and shall include all labor, materials; including water, operations and equipment to scarify, adjust moisture, compact or recompact the subgrade, both in cut areas and in fill areas, and no further compensation will be allowed. SECTION 302 - ROADWAY SURFACING 302-1 OILED ROADWAYS AND SHOULDERS 302-1.1 General, add the following: The Contractor shall treat roadway or shoulder to be oiled with a post emergent herbicide applied to all vegetation within the limits of the area to be oiled. Herbicide shall be applied at least 2 (two) working days prior to oiling the roadway or shoulder. Allowance for the two day period shall be shown in the schedule required per section 6-1. 302-1.2. Measurement and Payment, add the following: Payment for oiled roadways and shoulders shall include post emergent herbicide treatment of the areas to be oiled. 302-2 CHIP SEAL 302-2.1 General, add the following: The Contractor shall treat all vegetation within the limits of the paved area to be chip sealed with a post emergent herbicide. Herbicide shall be applied at least 2 (two) working days prior to chip sealing the street. Allowance for the two day period shall be shown in the schedule required per section 6-1. 302-2.8. Measurement and Payment, add the following: Payment for chip seal shall include post emergent herbicide treatment of the areas to be chip sealed. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 123 of 139 302-3 ASPHALT-RUBBER CHIP SEAL OR INTERLAYER Add the following section: 302-3.1 General. The Contractor shall treat all vegetation within the limits of the paved area to receive asphalt-rubber chip seal treatment with a post emergent herbicide. Herbicide shall be applied at least 2 (two) working days prior to sealing of street. Allowance for the two day period shall be shown in the schedule required per section 6-1. Payment for asphalt-rubber chip seal treatment shall include post emergent herbicide treatment of the areas to receive asphalt-rubber chip seal treatment. 302-4 EMULSION-AGGREGATE SLURRY Add the following section: 302-4.3.4 Surface Preparation. As part of surface preparation prior to application of emul- sion-slurry seal the Contractor shall: 1. treat the area to receive emulsion-slurry seal with a post emergent herbicide. Herbicide shall be applied at least 2 (two) working days prior to sealing of street. Allowance for the two day period shall be shown in the schedule required per section 6-1. 2. remediate cracks, potholes, and large areas of alligator cracking. Remediation shall be accomplished by: a) Removal of existing asphalt pavement, base material and soil and replacement with full depth asphalt concrete in locations designated by the Engineer b) Crack cleaning and sealing of all cracks designated by the Engineer. 302-4.4 Public Convenience and Traffic Control. Add the following: The Contractor shall schedule the work so as to prevent damage by all traffic, including but not limited to, mail delivery. The Contractor shall not schedule work so as to conflict with trash pickup. The trash hauling schedule can be obtained by calling Coast Waste Management at (760) 929-9400. At least two weeks prior to work, Contractor shall send, by first class mail, notification letters to all property addresses on which sealing shall occur. Obtaining the appropriate addresses shall be the contractor's responsibility. Letters shall be as shown in bold type as follows, with the appropriate information specific to the work inserted at the locations indicated in the brackets and italicized. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 124 of 139 (Name of Contracted (Address of Contractor} """*""' (Contractor's License Number) (Date) As a part of the City of Carlsbad's ongoing program to maintain its streets, your street will be sealed with a mixture of asphalt and sand, beginning in two or three weeks. This process requires that your street be closed for one day starting at 7:00 a.m. and continuing until the Contractor removes the traffic control devices. You will be notified 72 hours in advance of the day your street will be closed by a brightly colored 3 Ya" x 8 Ya" card attached to your doorknob. You will also notice temporary no parking signs on your street with a specific no parking date written on it. A successful street maintenance program depends on your cooperation. Please do not drive, walk, play, skate or allow pets on the sealed street until it has dried. Furthermore, please do not wash your car or turn on any sprinklers while you are waiting for the seal to dry. If you don't plan to leave your home before 7:00 a.m. on the day your street will be sealed, and you need to use your vehicle later in the day, please park your car on an adjacent street in your neighborhood that is not signed as a no parking zone. When walking to and from your car, remember not to walk on the newly sealed street or you will have black residue on the bottom of your shoes. The residue will damage some surfaces, will mark all surfaces that you track it on and will be very difficult to remove. (Name of Contractor) is the Contractor that will be performing the resurfacing work for the City and you may call them at (24 hour per day attended telephone number in the 76O area code) for any questions you may have about the project. Sealing of your street will not occur on the day your trash is collected. On the day your street is sealed mail delivery may be delayed until the next day. You will not know the exact date your street will be closed until you receive the 3 Ya" x 8 Ya" card. If you have a moving company scheduled to come to your house within the next two weeks, please call and inform the Contractor of the date. If you have any concerns which are not addressed by the Contractor, please call the City's Engineering Inspection Department at 438-1161, extension 4323. They will assist you in resolving the concerns. The City of Carlsbad has some of the finest streets in the county due to the concern and cooperation of citizens like you. Your cooperation is greatly appreciated." Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 125 of 139 During sealing operations, the Contractors schedule for slurry seal application shall be designed to provide residents and business owners whose streets are to be sealed sufficient paved parking within an 800 foot distance from their homes or businesses. ff Seventy two hours prior to the start of any construction in the public right-of-way that affects vehicular traffic and/or parking or pedestrian routes, the Contractor shall give written notification of the impending disruption. For a full street closure, all residences and/or businesses on the affected street or alley shall be notified. For partial street closures, or curb, sidewalk and driveway repairs, the residences and/or businesses directly affected by the work shall be notified. The Contractor shall deliver the notification which shall state the date and time the work will begin and its anticipated duration. The notification shall list two telephone numbers that may be called to obtain additional information. One number shall be the Contractor's permanent office or field office and the other number shall be a 24 hour number answered by a representative of the Contractor who is knowledgeable about the project. At least one of the phone numbers shall be in the (760) area code. An answering machine shall not be connected to either number. The notification shall also give a brief description of the work and simple instructions to the home or business owner on what they need to do to facilitate the construction. The Contractor shall submit the contents of the notification to the Engineer for approval. Notices shall not be distributed until approved by the Engineer. For residences, the notification shall be pre-cut in a manner that enables it to be affixed to a doorknob without adhesives. It shall be a minimum size of 3-1/2 inches by 8-1/2 inches and shall be brightly colored with contrasting printing. The material shall be equivalent in strength and durability to 65 Ib. card stock. The printing on the notice shall be no smaller than 12 point. The precut notices shall be as shown on the example provided in Appendix "A", with the day of the week circled and appropriate information specific to the work inserted at the locations indicated in the italicized font. The preparation, materials, printing and distribution of the notifications shall be included in the contract price bid for traffic control and the Contractor will not be entitled to any additional compensation for printing and distributing these notices. 302-5 ASPHALT CONCRETE PAVEMENT. 302-5.1 General, add the following: The Contractor shall treat all vegetation within the limits of the paved area to receive asphalt concrete paving with a post emergent herbicide. Herbicide shall be applied at least 2 (two) working days prior to paving the area. Allowance for the two day period shall be shown in the schedule required per section 6-1. 302-5.2.2 Equipment add the following: The machine shall be capable of grinding Asphalt Concrete so that the finished surface shall not vary from true plane enough to permit a .01 foot thick shim .25 feet wide to pass under a 12 foot long straight edge when the straight edge is laid on the finished surface parallel to the centerline. The transverse slope of the finished surface shall be uniform to a degree such that a .02 foot shim .25 feet wide will not pass under 12 foot long straight edge when the straight edge is laid on the finished surface in a direction transverse to the centerline and extending from edge to edge of a traffic lane. 302-5.2.5 Pavement Transitions, add the following: The Contractor shall ramp the approaches and termini to all structures and vertical joints in the cold-milled area which are transverse to through traffic with temporary asphalt concrete pavement as specified in section 306-1.5.1. Ramps shall be constructed the same day as cold milling and removed the same day as permanent paving. Ramp dimensions and compaction shall be as approved by the Engineer. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 126 of 139 302-5.4 Tack Coat, add the following: The Contractor shall place a tack coat between the successive interfaces of existing pavement and new pavement when, in the opinion of the engineer, the Contractor has failed to maintain or prepare each existing or previously laid course of asphalt receiving the subsequent course of asphalt in a sufficiently clean state and the asphalt receiving the new pavement course is dirty enough to impair bonding between the next lift of asphalt. 302-5.5 Distribution and Spreading, modify as follows: After second sentence of sixth paragraph, add: The Contractor shall provide the spreading and finishing machine used to construct the asphalt concrete surface course with an automatic screed control for surface course paving. The automatic screed control shall be 9 m (30') minimum length. The paving machine shall be operated by an operator and two full-time screed men during all paving. Delete the second sentence of paragraph 7 and the subsequent subsections A. thru E. which reference windrow operations. Add the following sentence in place of the deleted sentence and subsequent subsections: The use of windrow operations shall not be allowed. 302-5.6.1 General, modify as follows: Second paragraph, Part (2), add: Pinched joint rolling procedures shall be required, and vibratory rollers shall be limited to breakdown, unless otherwise directed by the Engineer. modify as follows: After last paragraph, add: Unless directed otherwise by the Engineer, the initial breakdown rolling shall be followed by a pneumatic-tired roller as described in this section. 302-5.8 Manholes (and other structures), delete the first paragraph and replace with the following: When placing the ARHM overlay the Contractor shall pave over appurtenances in the roadway which includes sanitary and storm access covers, water valve boxes, air vents, sewer dead end boxes and survey monument boxes. Each appurtenance shall be treated or covered to prevent adhesion of the overlay. Each appurtenance shall be located immediately after the overlay is placed and shall be thoroughly cleaned of any and all construction debris which may have entered due to the Contractor's operation. The contractor shall adjust all CMWD water valve boxes per CMWD Standard Drawing No. W11 or CMWD Standard Drawing No. W13. All City of Carlsbad sanitary sewer access covers shall be adjusted per CMWD Drawing No. S1. All storm sewer access covers shall be adjusted per SDRSD D-10. Riser rings or extensions shall not be used for the adjustment of these appurtenances. Raising and adjusting to grade all appurtenances in the roadway shall be paid for at the contract unit price per each as shown in the Bid. Such price shall constitute full compensation for all labor, materials, and equipment necessary for completing the work as described in these specifications and plans. 302-5.9 Measurement and Payment, add the following: Payment for asphalt concrete shall be included in the lump sum price bid. No additional payment shall be made for any tack coat. Add the following section: 302-11 ASPHALT PAVEMENT REPAIRS AND REMEDIATION Add the following section. 302-11.1 General. Asphalt pavement Repairs and Remediation shall consist of the repair and restoration of existing asphalt pavement. Repair of asphalt pavement shall consist of the saw cutting, removal and disposal of existing asphalt pavement in conformance with section 300-1.3, compaction of existing subgrade in conformance with section 301-1, grading and compaction of base material in conformance with section 301-2, application of grade SS-1h emulsified asphalt and Revised 5/01/08 Contract No. 5201 1 (Industrial Park RW Service Lines) Page 127 of 139 the placement of asphalt concrete base and wearing courses as specified herein Add the following section. 302-11.2 Full Depth Asphalt Concrete Patch. Full depth asphalt concrete patch shall consist of removing asphalt concrete and/or aggregate base/subgrade to 300 mm (1') below existing asphalt surface and placing replacing the material so removed with asphalt concrete. The area shown on the plans or set forth in the bid item are for estimating purposes only, final quantity will be as measured in the field. The Engineer will designate and mark the final limits of the asphalt patch area by outlining the area to be patched. The Contractor shall cut such areas to straight lines in square or rectangular areas as marked. The area so cut shall have two of the sides at right angles to the direction of traffic. The excavated faces of the base/subgrade shall be straight and vertical. The Contractor shall compact the upper 300mm (11) of subgrade to 95% relative compaction. A tack coat of SS-1 h emulsified asphalt shall be applied uniformly to all asphalt to asphalt contact surfaces at a rate of 0.25 L/m2 to 0.45 L/m2 (0.05 to O.IOgallons per square yard) in accordance with subsection 302-5.4, SSPWC. The Contractor shall fill and compact areas designated to be removed with 300 mm (1.0') full depth asphalt concrete. Asphalt concrete for full depth asphalt concrete patch shall be B-AR-4000. The asphalt concrete so constructed shall have a finish surface and density conforming to subsection 302-5.6.2 SSPWC. Add the following section. 302-11.3 Crack Sealing The Contractor shall wash, blow out and thoroughly dry all cracks designated to be sealed before installing elastomeric sealant material. The Contractor shall dispose debris from crack cleaning outside the public way in accordance with Section 7-8.1, "Cleanup and Dust Control." The hot-melt rubberized asphalt shall be melted in a jacketed, double boiler type melting unit. Temperature of the heat transfer medium shall not exceed 245°C (475°F). Application of the hot-melt sealant shall be made with a pressure feed applicator or pour pot. Sealant shall be applied when the pavement surface temperature is greater than 4°C (40°F). Containers of hot-melt sealant shall be delivered to the job-site in unopened containers that are clearly marked with data showing the manufacturer's name, the product designation and the manufacturer's batch number and lot numbers. The level of the sealant shall be flush with the surface of the existing pavement. All excess sealant shall be removed from the crack with a minimum overlap onto adjacent pavement. Add the following section. 302-11.4. Measurement and Payment. Quantities of full depth asphalt concrete patch and crack sealing set forth in the bid item are for estimating purposes only, final quantity will be as designated and measured in the field. The Engineer will designate and mark the limits of the Full depth asphalt concrete patch and crack sealant application areas. Payment for emulsion-aggregate slurry treatments shall include post emergent herbicide treatment of the areas to receive for emulsion- aggregate slurry treatment. Full compensation for conforming to the requirements of constructing full depth asphalt concrete patch shall include but not be limited to: furnishing all labor, tools, equipment, and materials necessary for doing the work including, saw cutting and removing and disposing 300 mm (11) thick section of existing asphalt concrete, aggregate base/subbase and basement soil as designated by the engineer, placement of asphalt concrete, compaction of subbase and asphalt concrete, placement of SS-1h asphalt emulsion and all other work incidental to full depth asphalt concrete patch shall be considered as included in the contract unit price bid for full depth asphalt concrete patch and no additional compensation will be allowed therefore. Full compensation for conforming to the requirements of crack sealing shall include but not be limited to, furnishing all labor, materials, tools, equipment, and incidentals necessary to do the work. Crack cleaning, roadway clean up, application of sealant, removal of excess sealant and all other work incidental to crack sealing shall be considered as included in the contract unit price bid and no additional compensation will be allowed therefore. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 128 of 139 SECTION 303 CONCRETE AND MASONRY CONSTRUCTION 303-1 CONCRETE STRUCTURES 303-1.6.2 Falsework Design, add the following: The Contractor shall provide all temporary bracing necessary to withstand all imposed loads during erection, construction, and removal of any falsework. The Contractor shall provide falsework drawings and calculations prepared by a registered professional engineer, civil or structural, that show provisions for resolution of all loads that may be imposed upon the falsework. Such plans and calculations shall include: 1. Resolution of all live, dead, wind, construction and impact loads that may be imposed on the falsework. 2. Temporary bracing or methods to be used during each phase of erection and removal of the falsework. 3. Concrete placement sequence. 4. Erection and removal sequence. 5. Deflection values for the falsework that include recommended methods to compensate for falsework deflections, vertical alignment, and anticipated falsework deflection. Add the following section: 303-1.9.5 Surface Finish for Concrete Spillway. The Contractor shall provide a surface finish for concrete spillway to prevent the use of rollerblades, skateboards, and other rolling devices. Surface finish shall be a rough rake finish approved by the Engineer. 303-2 AIR-PLACED CONCRETE. 303-2.1.1 General, add the following: Modify Regional Standard Drawing D-75 as follows: replace stucco netting with 150mm x 150mm (6" x 6") by No. 10 by No. 10 welded wire mesh. Add the following section: 303-5 CONCRETE CURBS, WALKS, GUTTERS, CROSS GUTTERS, ALLEY INTERSECTIONS, ACCESS RAMPS, AND DRIVEWAYS. 303-5.5.2 Curb, add the following: The Contractor shall stamp the curb face with 75 mm (3") high block letters directly above the point that it is crossed by underground facilities with the marking specified in Table 303-5.5.2(A) TABLE 303-5.5.2(A) Curb Face Markings Type of underground facilities Water Service Lateral Sewer Service Lateral Irrigation Water Lateral or Sleeve Marking W S RW 303-5.9 Measurement and Payment, add the following: Curb and gutter, and curb, shall be considered as continuing across driveways and access ramps when constructed adjacent thereto. Neither curb and gutter nor curb will be paid for across the length of local depressions, except that which occurs in gutter transitions at each side of an inlet. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 129 of 139 303-6 STAMPED CONCRETE. 303-6.1 General. Add the following: Concrete shall be 560-C-3250 with 6"x6" - 10 guage wire mesh throughout. Add the following: 303-6.5 Medians- Use color application method "B" (integral color). Color shall be per Section 201-1.2.4(a). The pattern shall match the existing median condition adjacent to the prposed construction. Add the following: 303-6.6 Measurement and Payment. Payment for colored, stamped concrete paving shall be paid under the contract unit price bid per square foot for median concrete paving. Said payment shall include compensation for all excavation, grading, backfill, permeable material, forming, mesh, reinforcing steel, concrete, integral color, texture sealers, and other material necessary to construct the specific paving. SECTION 304 - METAL FABRICATION AND CONSTRUCTION 304-3 CHAIN LINK FENCE. Not used SECTION 306 - UNDERGROUND CONDUIT CONSTRUCTION 306-1 OPEN TRENCH OPERATIONS Add the following section: 306-1.1.7 Steel Plate Bridging - With a Non-Skid Surface. This section covers the use of steel plate bridging. The Contractor shall not employ the use or use steel plate bridging or trench plate that does not meet the requirements of this section both in application and circumstance of use. Add the following section: 306-1.1.7.1 Requirements for Use. Alternate construction methods that avoid the use of steel plate bridging shall be used by the Contractor unless otherwise approved by the Engineer. It is recognized that to accommodate excavation work, steel plate bridging may be necessary. All conditions for use of steel plate bridging set forth in the following requirements must be fulfilled as conditions of approval of the use of steel plate bridging. Consideration of steel plate bridging in the review process will take into account the following factors: 1. Traffic volume and composition. 2. Duration of use of the steel plate bridging. 3. Size of the proposed excavation. 4. Weather conditions. o A•^ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 130 of 139 The following formula shall be used to score the permitted use of steel plate bridging: PS = [ APT + EWL + DAYS + 10 X WEEKEND + 5 X NIGHTS + 20 X WEATHER + SPEED (kmh) + SLOPE X 100] X LANES 1000 8 PS = [ APT+EWL + DAYS + 10 X WEEKEND + 5 X NIGHTS + 20 X WEATHER + SPEED (mph) + SLOPE X 100] X LANES 1000 5 where: PS = plate score. ADT = average daily traffic as defined in the Federal Highway Administration (FHWA) Manual on Uniform Traffic Control Devices (MUTCD) 2003 Edition as amended by the MUTCD 2003 California Supplement. EWL = equivalent wheel loads as defined in the Federal Highway Administration (FHWA) Manual on Uniform Traffic Control Devices (MUTCD) 2003 Edition as amended by the MUTCD 2003 California Supplement. DAYS = total number of 24 hour periods during which the plates will be utilized at the site being considered. WEEKEND = total number of Saturdays, Sundays and holidays that the plates will be utilized at the site being considered. NIGHTS = total number of overnight periods that the plates will be in place, exclusive of Saturday, Sunday and holiday nights. WEATHER = total number of 24-hour periods that the plates will be utilized at the site being considered when the possibility of rain exceeds 40 percent. SPEED = the design speed in kilometers per hour or miles per hour, as applicable in the formulae above, of the street where the plates are to be installed. This number shall not be reduced for construction zone speed reductions. SLOPE = the quotient of the vertical differential divided by the horizontal distance. The vertical and horizontal dimensions shall be measured at the locations spanning a distance of 15 m (501) up and downstream of the position of the proposed steel plate bridging. LANES = the number of lanes where plates will be used. When the computed value of the plate score exceeds 50, steel plate bridging shall not be used unless, and at the sole discretion of the Engineer, the Engineer determines that no alternative method of construction is possible in lieu of using steel plate bridging or that other overriding considerations make the use of steel plate bridging acceptable. Alternatives considered to bridging shall include, but not be limited to, detouring traffic, construction detour routes, tunneling, boring and other methods of trenchless construction. Unless specifically noted in the provisions of the Engineer's approval, the use of steel plate bridging at each location so approved shall not exceed four (4) consecutive working days in any given week. Add the following section: 306-1.1.7.2 Additional Requirements. In all cases when the depth of the trench exceeds the width of the steel plate bridging resting on each side of the pavement adjacent to the trench, safety regulations require or the Engineer determines that shoring is necessary to protect the health or safety of workers or the public the Contractor shall install shoring conforming to Section 7-10.4.1 of the Standard Specifications. The trench shoring shall be designed and installed to support the steel plate bridging and traffic loads. All approvals for design, substitution of materials or methods shall be submitted by the Contractor in accordance with all provisions of section 2-5.3 Shop Drawings and Submittals. The Contractor shall backfill and resurface excavations in accordance with section 306-1.5. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines)Page 131 of 139 Add the following section: 306-1.1.7.3 Installation. When backfilling operations of an excavation in the traveled way, whether transverse or longitudinal cannot be properly completed within a work day, steel plate bridging with a non-skid surface and shoring may be required to preserve unobstructed traffic flow. In such cases, the following conditions shall apply: a) Steel plate bridging when the plate score exceeds 50 is not allowed except when, at the sole discretion of the Engineer, it is approved as specified hereinbefore. b) Steel plates used for bridging must extend a minimum of 610 mm (21) beyond the edges of the trench. c) Steel plate bridging shall be installed to operate with minimum noise. When the use of steel plate bridging and shoring is approved by the Engineer, the Contractor shall install using either Method (1) or (2) depending on the design speed of the portion of street where the steel plate bridging is proposed for use. Method 1 [For speeds more than 70 Km/hr (45 MPH)]: The pavement shall be cold planed to a depth equal to the thickness of the plate and to a width and length equal to the dimensions of the plate. The cold milling shall produce a flat surface that the plate shall rest on with no horizontal or vertical movement. Horizontal gaps between the unmilled pavement and the plate shall not exceed 25 mm (1") and shall be filled with elastomeric sealant material which may, at the contractor's option, be mixed with no more that 50%, by volume, of Type I aggregate conforming to the requirements of tables 203-5.2(6) and 203-5.3(A). Method 2 [For speeds 70 Km/hr (45 MPH) or less]: Approach plate(s) and ending plate (if longitudinal placement) shall be attached to the roadway and shall be secured against displacement by using two adjustable cleats that are no less than 50 mm (2") shorter than the width of the trench bolted to the underside of each plate and located within 150 mm (6") of the beginning and end of the trench for plates at the beginning and end of the trench, a minimum of two 300 mm long by 19 mm diameter (12" x %") steel bolts placed through the plate and driven into holes drilled 300 mm (12") into the pavement section, or other devices approved by the Engineer. Subsequent plates shall be butted to each other. Fine graded asphalt concrete shall be compacted to form ramps, maximum slope 8.5% with a minimum 300 mm (12") taper to cover all edges of the steel plates. When steel plates are removed, the dowel holes in the pavement section shall be completely filled with elastomeric sealant material. At the Contractor's option, the methods required for Method 1 may be used. If the Contractor so elects, all requirements of Method 1 shall be used. The Contractor shall maintain the steel plates, shoring, and asphalt concrete ramps and maintain and restore the street surface during and after their use. Add the following section: 306-1.1.7.4 Materials. The minimal thickness of steel plate bridging shall be as shown in Table 306-1.1.7.4(A) TABLE 306-1.1.7.4(A) REQUIRED PLATE THICKNESS FOR A GIVEN TRENCH WIDTH Maximum Trench Width li; 0.3m (10") 0.6m (23") 0.8m (31") 1.0m (41") 1.6m (63") Minimum Plate Thickness 13mm (V2") 19mm (°/4") 22mm (78") 25mm (1") 32 mm (1 1/4") the Engineer for review and approval in accordance with section 2-5.3. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 132 of 139 Steel plate bridging shall be steel plate designed to support the HS20-44 truck loading per CALTRANS Bridge Design Specifications Manual. The Contractor shall maintain a non-skid surface on the steel plate with no less than a coefficient of friction of 0.35 as determined by California Test Method 342. If a different test method is used, the Contractor may utilize standard test plates with known coefficients of friction available from the CALTRANS District 11 Materials Engineer to correlate skid resistance results to California Test Method 342. In addition to all other required construction signing, the Contractor shall install Rough Road (W33) sign with black lettering on an orange background in advance of steel plate bridging. Add the following section: 306-1.1.7.5 Measurement and Payment. Steel plate bridge materials including, but not limited to: steel plates, anchoring devices, cold milling, elastomeric sealant material, asphalt ramping and padding, signage, placing, installation, removal, relocation, preparation and processing of shop drawings and submittals to support the use of steel plate bridging and all other materials, labor, supervision, overhead of any type or description will be paid for as an incidental to the work that the bridging is installed to facilitate. No separate payment for steel plate bridging will be made. No extension to contract time will be allowed for, or because of, the use of steel plate bridging. 306-1.2.1 Bedding. All installation of, and bedding for recycled water, or potable water mains shall conform to Carlsbad Municipal Water District Rules and Regulations for the Construction of (Potable or Reclaimed) Water Mains, latest edition. 306-1.2.4 Field Jointing of Reinforced Concrete Pipe, add the following: The Contractor shall provide Gasket-type joints for reinforced concrete pipe (watertight joints) where indicated on plans. 306-1.3.1 General, add the following: The Contractor shall install detectable underground utility marking tape 230 mm x75 mm (9" x 3") above each or, in the case of bundled underground conduit of the same type, the upper underground conduit being installed by the open trench method. The type and color of detectable underground utility marking tape shall conform to the requirements of section 207-25 et seq. 306-1.3.4 Compaction Requirements, delete Section 306-1.3.4 and replace with the following: The Contractor shall densify trench backfill to a minimum of 90 percent relative compaction except that in the top 300 mm (12") of the street right-of-way, compaction shall be 95 percent. 306-1.5 Trench Resurfacing. 306-1.5.1 Temporary Resurfacing. Delete the fourth and fifth paragraphs and substitute the following: Temporary bituminous resurfacing materials which are placed by the Contractor are for its convenience and shall be at no cost to the Agency. Temporary bituminous resurfacing materials shall be used in lieu of permanent resurfacing only when approved by the Engineer. When temporary bituminous resurfacing materials are used in lieu of permanent resurfacing it shall be removed and replaced with permanent resurfacing within 7 days of placement. No additional payment will be made for temporary bituminous resurfacing materials. The price bid for the associated conduit or structure shall include full compensation for furnishing, placing, maintaining, removing, and disposing of such temporary resurfacing materials. 306-1.5.2 Permanent Resurfacing. Add the following: Except as provided in section 306-1.5.1, "Temporary Resurfacing," the Contractor shall perform permanent trench resurfacing within 24 hours after the completion of backfill and densification of backfill and aggregate base materials. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 133 of 139 306-1.6 Basis of Payment for Open Trench Installation, add the following: Payment for utilities undergrounding which includes the utility trench for CAW and SDG&E and conduit for SDG&E's ^^\ electric conversion shall be made on the basis of contract lump sum price for utilities ^r undergrounding and no other payments will be made. Cox Cable will supply and deliver conduits and fittings to be installed by the Contractor. Cox Cable will install enclosures. The Contractor will furnish and install 6.4 mm (%") nylon pull ropes in all conduit. 306-5 ABANDONMENT OF CONDUITS AND STRUCTURES. Add the following. Unless otherwise noted on plans, the Contractor shall remove all existing abandoned pipelines and conduits of any type, or use, and pipelines and conduits of any type, or use, that are abandoned during the course of the work and shall replace said pipelines and conduits with properly compacted soils. Payment for removal and disposal of abandoned utilities shall be included in the lump-sum bid for Clearing and Grubbing, and no additional payment will be made. SECTION 310 - PAINTING 310-5 PAINTING VARIOUS SURFACES. 310-5.6 Painting Traffic Striping, Pavement Markings and Curb Markings. Modify the fifth paragraph as follows: The Contractor shall furnish all equipment, materials, labor, and supervision necessary for painting traffic lanes, directional arrows, guidelines, curbs, parking lines, crosswalks, and other designated markings in accordance with the Plans, or for approved temporary detours essential for safe control of traffic through and around the construction site. The Contractor shall remove by wet grinding all existing or temporary traffic markings and lines that may confuse the public. When temporary detour striping or markings are no longer required, they shall be removed prior to painting the new traffic stripes or markings. 310-5.6.3 Equipment. Delete the ninth paragraph and substitute the following: The Contractor shall ^^ provide a wet grinding machine with sufficient capacity to completely remove all existing or temporary traffic striping or markings that conflict with the striping plan, or are contrary to the Traffic Manual, or that may be confusing to the public. The surface produced by grinding the existing or temporary traffic striping or markings on pavement shall not exceed variations from a uniform plane more than 3 mm (V8") in 3 m (10') when measured parallel to the centerline of the street or more than 6 mm (V4") in 3 m (10') when measured perpendicular to the centerline of the street. The use of any equipment that leaves ridges, indentations or other objectionable marks in the pavement shall be discontinued, and equipment capable of providing acceptable surface shall be furnished by the Contractor. This equipment shall meet all requirements of the air pollution control district having jurisdiction. 310-5.6.6 Preparation of Existing Surfaces. Modify the first paragraph as follows: The Contractor shall remove all existing markings and striping, either permanent or temporary, which are to be abandoned, obliterated or that conflict with the plans by wet grinding methods. Removal of striping by high velocity water jet may be permitted when there is neither potential of the water and detritus from the high velocity water jetting to damage vehicles or private property nor to flow from the street into any storm drain or water course and when approved by the Engineer. The Contractor shall vacuum all water and detritus resulting from high velocity water jet striping removal from the pavement immediately after the water jetting and shall not allow such materials to flow in the gutter, enter the storm drain system or to leave the pavement surface. Surface variation limitations for high velocity water jet striping removal shall be the same as for grinding. The Contractor shall not use dry or wet sandblasting in any areas. Alternate methods of paint removal require prior approval of the Engineer. Obliteration of traffic striping with black paint, light emulsion oil or any other masking method other than a minimum 30mm (0.10') thick asphalt concrete overlay is not permitted. 310-5.6.7 Layout, Alignment, and Spotting. Modify the first paragraph as follows: The Contractor •<•»• shall establish the necessary control points for all required pavement striping and markings by €5m¥ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 134 of 139 surveying methods. No layout of traffic striping shall be performed by the Contractor before establishment of the necessary control points. The Contractor shall establish all traffic striping between these points by string line or other method to provide striping that will vary less than 80mm per 100m (1/2 inch in 50 feet) from the specified alignment. The Contractor shall obliterate, straight stripes deviating more than 80mm per 100mm (1/2 inch in 50 feet) by wet grinding, and then correcting the markings. The Contractor shall lay out (cat track) immediately behind installation of surface course asphalt and as the work progresses. 310-5.6.8 Application of Paint. Modify the second paragraph as follows: The Contractor shall apply the first coat of paint immediately upon approval of striping layout by the Engineer. The Contractor shall paint the ends of each median nose yellow. Add the following to the eighth paragraph: The Contractor shall apply temporary traffic stripes in one coat. Temporary traffic stripes shall be maintained by the Contractor so that the stripes are clearly visible both day and night. 310-5.6.10 Measurement and Payment. Modify the first paragraph as follows: Final and temporary traffic striping, curb markings and pavement markings as shown on the plans and required by the specifications shall be included in the lump-sum price bid for temporary and final traffic striping, and no additional compensation will be allowed therefore. Reapplication of temporary stripes and markings shall be repainted at the Contractor's expense, and no additional compensation will be allowed therefore. The lump sum prices bid and shall include all labor, tools, equipment, materials, and incidentals for doing all work in installing the final and temporary traffic striping. Add the following Section: 310-7 PERMANENT SIGNING Add the following Section: 310-7.1 General. Add the following section: The Contractor shall provide and install all permanent traffic control signs at locations shown on plans and as specified herein. Add the following section: 310-7.2 Measurement And Payment. Permanent signing and appurtenances thereto shown on the plans or required in the specifications are a part of the lump-sum item for permanent signing and payment therefore shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals and for doing all the work involved in supplying and installing permanent signing and appurtenances, complete in place, as shown on the plans, as specified in the Standard Specification and these special provisions, and as directed by the Engineer. SECTION 312 - PAVEMENT MARKER PLACEMENT AND REMOVAL 312-1 PLACEMENT. Add the following to the third paragraph: 4) When being installed on asphalt concrete pavement sooner than 14 days after placement of the asphalt concrete pavement course on which the pavement markers are to be placed. Add the following section: 312-1.1 Reflective Channelizer Placement and Removal. The Contractor shall place and remove reflective channelizers the same as for pavement marker placement and removal. The Contractor shall place the channelizers uniformly, straight on tangent alignment and on a true arc on curved alignment to the same tolerances of position as for application of paint in section 310-5.6.8. The Contractor shall perform all layout work necessary to place the channelizers to the proper alignment. If the channelizers are displaced or fail to remain in an upright position, from any cause, the channelizers shall immediately be replaced or restored to their original location, by the Contractor. When reflective channelizers are removed the pavement surface shall be restored to the same color and surface finish as the adjacent pavement. m& Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 135 of 139 SECTION 313 - TEMPORARY TRAFFIC CONTROL DEVICES Add the following section: 313-1 TEMPORARY TRAFFIC PAVEMENT MARKERS. Add the following section: 313-1.1 General. The Contractor shall supply and install temporary traffic pavement markers, channelizers, signing, railing (type K), crash cushions and appurtenances at the locations shown on the plans and as required in the specifications, complete in place prior to opening the traveled way served by said final and temporary traffic pavement markers, signing, railing (type K) and appurtenances to public traffic. 313-1.2 Temporary Pavement Markers. Temporary reflective raised pavement markers shall be placed in accordance with the manufacturer's instructions. Temporary reflective raised pavement markers shall be cemented to the surfacing with the adhesive recommended by the manufacturer, except epoxy adhesive shall not be used to place temporary reflective raised pavement markers in areas where removal of the markers will be required. Pavement striping, legends and markers which conflict with any traffic pattern shall be removed by grinding as determined by the Engineer. The Contractor shall use temporary reflective raised pavement markers for temporary pavement marking, except when the temporary pavement markers are used to replace patterns of temporary traffic stripe that will be in place for less than 30 days. Reflective pavement markers used in place of the removable-type pavement markers shall conform to the section 312 "Pavement Marker Placement and Removal", except the 14-day waiting period before placing the pavement markers on new asphalt concrete surfacing as specified in section 312-1 "Placement", shall not apply; and epoxy adhesive shall not be used to place pavement markers in areas where removal of the markers will be required. Add the following section: 313-1.3 Channelizers. Channelizers shall be new surface-mounted type and shall be furnished, placed, and maintained at the locations shown on the plans. Channelizer posts shall be orange in color. Channelizers shall have affixed white reflective sheeting as specified in the special provisions. The reflective sheeting shall be 75 mm x 300 mm (3" x 12") in size. The reflective sheeting shall be visible at 300 m (1000') at night under illumination of legal high beam headlights, by persons with vision of or corrected to 20/20. The channelizer bases shall be cemented to the pavement in the same manner as provided for cementing pavement markers to pavement in section 312-1, "Placement." Channelizers shall be applied only on a clean, dry surface. Channelizers shall be placed on the alignment and location shown on the plans and as directed by the Engineer. The channelizers shall be placed uniformly, straight on tangent alignment and on a true arc on curved alignment. All layout work necessary to place the channelizers to the proper alignment shall be performed by the Contractor. If the channelizers are displaced or fail to remain in an upright position, from any cause, the channelizers shall immediately be replaced or restored to their original location, by the Contractor. The Contractor shall provide the Engineer with a Certificate of Compliance in accordance with the provisions of section 4-1.5, "Certification". Said certificate shall certify that the channelizers comply with the plans and specifications and conform to the prequalified design and material requirements approved by the Engineer and were manufactured in accordance with a quality control program approved by the Engineer. Add the following section: 313-2 TEMPORARY TRAFFIC SIGNING. Add the following section: 313-2.1 General. The Contractor shall provide and install all temporary traffic control signs, markers, markings, and delineators at locations shown on plans and specified herein. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 136 of 139 Add the following section: 313-2.2 Maintenance of Temporary Traffic Signs. If temporary traffic signs are displaced or overturned, from any cause, during the progress of the work, the Contractor shall immediately replace the signs in their original approved locations. The Contractor shall maintain all temporary traffic signs used in the Work in a clean, reflective and readable condition. The Contractor shall replace or restore graffiti marked temporary traffic signs and posts used in the Work within 18 hours of such marking being discovered during non-working hours or, when the marking is discovered during working hours, within 2 hours of such discovery of marking. Add the following section: 313-3 TEMPORARY RAILING (TYPE K) AND CRASH CUSHIONS. Add the following section: 313-3.1 Temporary Railing and Crash Cushions. Temporary railing (Type K) shall consist of interconnected new or undamaged used precast concrete barrier units as shown on the plans. Temporary sand-filled crash cushions shall consist of new or undamaged used temporary sand-filled crash cushions units as shown on the plans. 313-3.1.1 Appearance. Exposed surfaces of new and used units of Temporary railing (Type K) shall be freshly coated with a white color paint prior to their first use on the project. The paint shall conform to the provisions in sections 210-1.5 "Paint Systems" and 310 "Painting". Contractor shall be responsible for the removal and cleanup or painting over the graffiti from the K-Rails within 48 hours. The Contractor Shall replace or repaint units of Temporary railing (Type K) or shall remove graffiti, tire or vehicle marks, dirt or any and all materials such that said marks or discoloration mar the appearance of said units when ordered by the Engineer after the units are in place. Add the following section. 313-3.1.2 Manufacture of Temporary Railing. In addition to the requirements herein the temporary railing (Type K) shall be manufactured per CALTRANS Standard Drawing T3. Concrete used to manufacture Temporary railing (Type K) shall conform to the provisions in sections 201-1, "Portland Cement Concrete" and 303-1 "Concrete Structures"." Load tickets and a Certificate of Compliance will not be required. Reinforcing steel shall conform to the provisions sections 201-1, "Portland Cement Concrete" and 303-1 "Concrete Structures". Steel bars to receive bolts at ends of concrete panels shall conform to ASTM Designation: A 36/A 36M. The bolts shall conform to ASTM Designation: A 307. A round bar of the same diameter may be substituted for the end-connecting bolt shown on the plans. The bar shall conform to ASTM Designation: A 36/A 36M, shall have a minimum length of 660 mm and shall have a 75 mm (3") diameter by 9 mm (3/8") thick plate welded on the upper end with a 5-mm (3/i6n) fillet weld. The final surface finish of temporary railings (Type K) shall conform to the provisions in section 303-1.9.2 "Ordinary Surface Finish." Exposed surfaces of concrete elements shall be cured by the water method, the forms-in-place method, or the pigmented curing compound method. The pigmented curing compound shall be type 2 curing compound. Temporary railing (Type K) may have the Contractor's name or logo on each panel. The name or logo shall not be more than 100mm in height and shall be located not more than 300 mm above the bottom of the rail panel. Add the following section. 313-3.1.3 Installation of Temporary Railing. In addition to the requirements herein the temporary railing (Type K) shall be installed per CALTRANS Standard Drawing T3. Temporary railing (Type K) shall be set on firm, stable foundation. The foundation shall be graded to provide a uniform bearing throughout the entire length of the railing. Abutting ends of precast concrete units shall be placed and maintained in alignment without substantial offset to each other. The precast concrete units shall be positioned straight on tangent alignment and on a true arc on curved alignment Each rail unit placed within 3 m (10') of a traffic lane shall have a reflector installed on top of the rail as directed by the Engineer. Reflectors and adhesive will be furnished by the Contractor. A Type P marker panel conforming to the requirements of the Federal Highway Administration (FHWA) Revised 5/01/08 Contract No. 5201 1 (Industrial Park RW Service Lines) Page 137 of 139 Manual on Uniform Traffic Control Devices (MUTCD) 2003 Edition as amended by the MUTCD 2003 California Supplement shall also be installed at each end of railing installed adjacent to a two-lane, two-way highway and at the end facing traffic of railing installed adjacent to a one-way roadbed. If the railing is placed on a skew, the marker shall be installed at the end of the skew nearest the traveled way. Type P marker panels shall conform to the provisions of section 206-7.2, "Temporary Traffic Signs". Where shown on the plans, threaded rods or dowels shall be bonded in holes drilled in existing concrete. When temporary railings (Type K) are removed, any area where temporary excavation or embankment was used to accommodate the temporary railing shall be restored to its previous condition, or constructed to its planned condition. Add the following section: 313-3.2 Temporary Sand-Filled Crash Cushions. Temporary sand-filled crash cushion units shall be "Energite III" manufactured by Energy Absorption Systems, "Pitch Inertial Barrier System Modules" manufactured by Roadway Safety Service, or equal. Features required to determine equivalence of any other temporary sand-filled crash cushion units shall be approval of the system by CALTRANS and that the temporary sand-filled crash cushion units meet NCHRP 350 standards. Other features will be suitability to application, operational characteristics, durability and other such characteristics that the Engineer shall determine. Temporary sand-filled crash cushions (TSFCC) shall be of the type and array configurations shown on plans, and installed at every end of, or gap in, the temporary railing (Type K) whenever the closest point of approach of traffic, regardless of direction, is 4.6 m (15') or less to the end of the temporary railing (Type K) being considered. The TSFCC shall be installed per CALTRANS Standard Drawings T1 and T2 for approach speeds no less than the posted speed of the street prior to construction or 55 kilometers per hour (35 mph), whichever is the greater. The TSFCC array shall be appropriate to the application as shown on said standard drawings. A Type J and/or P marker panel conforming to the requirements of the Federal Highway Administration (FHWA) Manual on Uniform Traffic Control Devices (MUTCD) 2003 Edition as amended by the MUTCD 2003 California Supplement shall also be installed at each TSFCC array as shown in CALTRANS Standard Drawings T1 and T2. Particular care shall be taken to assure that crash cushions are installed with the soil supporting them and the adjacent soil leveled to match the elevation of the bottom of the temporary railing immediately adjacent to the crash cushion. All routes of approach to the TSCFF array shall be graded such that any vehicle diverging from the travelled way to strike the TSCFF will travel on a vertical alignment parallel to the segment of the travel lane that it departed from. Add the following section: 313-4 MEASUREMENT AND PAYMENT. Temporary traffic pavement markers, temporary channelizers, temporary signing, temporary railing (type K), temporary crash cushions and temporary appurtenances thereto shown on the plans or required in the specifications are a part of the lump-sum item for traffic control and payment therefore shall include full compensation for furnishing all labor, materials, tools, equipment, and incidentals and for doing all the work involved in applying, installing, maintaining, and removing temporary traffic pavement markers, channelizers, signing, railing (type K), crash cushions and appurtenances, complete in place, as shown on the plans, as specified in the Standard Specification and these special provisions, and as directed by the Engineer. Payment for temporary crash cushions, concrete barriers and the signs and reflectors marking them shall include the installation, grading for installation, grading for the approach path, maintenance, painting and re-painting, replacement of damaged units and removal and shall also be included in the lump-sum price bid for traffic control. Payment for installation and/or relocation of K- rails and crash cushions when not shown on the plans and requested by the Engineer shall be made per section 3-3, Extra Work, SSPWC. Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 138 of 139 SUPPLEMENTAL PROVISIONS TO STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION PART 6, MODIFIED ASPHALTS, PAVEMENTS AND PROCESSES 600-3 Rubberized Emulsion - Aggregate Slurry 600-3.2 Materials add the following: Aggregate for Rubberized Emulsion - Aggregate Slurry shall be Type I Slurry Aggregate. 600-3.4 Application of REAS add to the first paragraphs: No slurry shall be applied until the provisions of subsection 212-1.2.6, Herbicide Application, Section 302-11 Asphalt Concrete Pavement Crack Filling and Sealing, Section 312-3 Pavement Marker Removal have all been satisfied. The Contractor shall remove all existing markings, legends and striping, either permanent or temporary in those areas to be slurried. Removal of striping by high velocity water jet may be permitted when there is neither potential of the water and detritus from the high velocity water jetting to damage vehicles or private property nor to flow from the street into any storm drain or water course and when approved by the Engineer. The Contractor shall vacuum all water and detritus resulting from high velocity water jet striping removal from the pavement immediately after the water jetting and shall not allow such materials to flow in the gutter, enter the storm drain system or to leave the pavement surface. Surface variation limitations for high velocity water jet striping removal shall be the same as for grinding. The Contractor shall not use dry or wet sandblasting in any areas. All cracks and areas between existing curb and gutter and edge of pavement that contain weeds or plant growth of any kind shall be treated with herbicides. Herbicides shall be applied at least 2(two) working days prior to sealing of street. Allowance for the two day period shall be shown in the schedule required per section 6-1. Contractor shall remove any visible plant growth prior to placement of Herbicide. Full compensation for removal of striping and herbicide application shall include but not be limited to: furnishing all labor, tools, equipment, and materials necessary for doing the work and shall be considered as included in the contract unit price bid for Rubberized Emulsion Aggregate Slurry and no additional compensation will be allowed therefore. 600-3.6 Public Convenience and Traffic Control modify the first line with the following: Public Convenience and traffic control shall conform to 302-4.4.4. There shall be no stockpiling of material allowed on City right-of-way. •^ Revised 5/01/08 Contract No. 52011 (Industrial Park RW Service Lines) Page 139 of 139 APPENDIX "A" APPENDIX "A" CITY OF CARLSBAD ROAD WORK ABC CONTRACTORS OFFICE # (760)XXX-XXXX FIELD # (760)XXX-XXXX Dear resident: As a part of the City of Carlsbad's ongoing program to maintain its streets, your street will be resurfaced with asphalt concrete oyer the existing roadway surface. This construction will require the closing of your street to through traffic for one day. Your street, from XYZ St. to DEF Ave. will be closed to through traffic and resurfaced on: MON. TUE. WED. THU. FRI. DATE: XX/XX/XX from 7:OOA.M. to 5:00 P.M. If you don't plan to leave your home by 7:00 A.M. on the above date please park your car on an adjacent street in your neighborhood that will not be resurfaced. Streets scheduled for resurfacing can be determined by calling either the Contractor or the City of Carlsbad's Project Inspector. When walking to and from your car, remember not to walk on the newly overlaid street or you will have black residue on the bottom of your shoes. Please do not drive, walk on, walk pets, play, or skate on the newly overlaid asphalt. Also, please refrain from watering your lawns, washing cars, etc., approximately 6-8 hours after the asphalt is laid as running water will cause damage to the new surface. ABC is the Contractor that will be performing the resurfacing work for the city and you may call them at the above phone number if you have any questions regarding the project. Resurfacing of your street will not occur on the day your trash is collected. Mail delivery may be delayed if the postman cannot reach the mailbox that day. If you have a moving company scheduled for that day please call and inform the Contractor of the date. If you have any concerns which cannot be addressed by the Contractor, you may call the City's Project Inspector @ (xxx) xxx-xxxx. Thank you for your cooperation as we work to make a better City of Carlsbad. APPENDIX "B" TRENCH WIDTH AT TOP OF TRENCH VARIES TOP OF BACKFILL TO BE SAME AS ORIGINAL GROUND AND MATCH ADJACENT UNDISTURBED GROUND AXIMUM ALLOWABLE SLOPE OF EXCAVATION PER REQUIREMENTS OF CAL/OSHA CD BACKFILL TRENCH ZONE WITH NAT)VI TRENCH WIDTH IN PIPE ZONE NATIVE EARTH BACKFILL OR IMPORTED MATERIAL 90% RELATIVE COMPATION* (D8ACKFILL PIPE BASE AND PIP£ ZOUE WITH IMPORTED SAND 90% RELATIVE COMPATION 1— HAUNCHING LIMITED A PIPE DIAMETER 1" THROUGH 8" 10" THROUGH 16" 18" THROUGH 24" 27" THROUGH 36" MIN. 6" 8" 10° 12" MAX. 9" 12" 18" 24"*IN PAVED AREA. TRENCH ZONE SHALL BE COMPACTED TO 95% MIN. NO SCALE ITEM DESCRIPTION SPEC/DWG BEDDING AND BACKFILL MATERIAL SECT 02223 REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT TYPICAL TRENCH SECTION CITY ENGII DATE STANDARD DWG. NO.W-2 SIDEWALK CURB & GUTTER METER. BALL VALVE BY DISTRICT CONNECT TO OUTLET ASSY. NOTES: 1. CONTRACTOR SHALL ADJUST ANGLE VALVE & METER BOX TO F.G. AFTER SIDEWALK IS INSTALLED & APPROVED 2. DISTRICT WILL SET METER AND BALL VALVE 3. ALL COPPER JIONTS SHALL BE SILVER SOLDERED IN CONFORMANCE WITH SPECIFICATIONS. 4. TAP TO MAIN TO BE MINIMUM OF 24" FROM NEAREST COUPLING. FITTING. VALVE, BELL OR OTHER TAPS. 5. POSITON ANODE MIDWAY BETWEEN PIPELINE AND METER BOX. 6. INTERIOR OF METER BOX SHALL BE CLEAR OF DEBRIS TO DEPTH OF 12" AND CORP STOP FULLY EXPOSED DETAIL NON-CONTIGUOUS SIDEWALK & CURB ITEM DESCRIPTION SPEC/DWG COPPER. (TYPE 'K' . SOFT) OUTLET ON PVC PRESSURE PIPE OUTLET ON AC PIPE W-8 OUTLET ON CML&C STEEL PIPE W-9 OUTLET ON DUCTILE IRON PIPE W-9 1" ANGLE METER STOP METER BOX AND COVER (TRAFFIC AREA) 8 METER BOX AND COVER (NON-TRAFFIC AREA) 30 LB. ZINC ANODE WITH ANODE LEAD WIRE W-25 REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT I" WATER SERVICE CONNECTION FOR 5/8", 3/4" & I" METERS W-3 METER BY DISTRICT. SIDEWALK I o CD FLANGED I BALL VALVE BY DISTRICT. 1. DISTRICT WILL SET METER AND BALL VALVE 2. ALL COPPER JIONTS SHALL BE SILVER SOLDERED IN CONFORMANCE WITH SPECIFICATIONS. 3. TAP TO MAIN TO BE MINIMUM OF 18" FROM NEAREST COUPLING OF TAP. 4. POSITION ANODE MIDWAY BETWEEN PIPELINE AND METER BOX. 5. FOR NON-CONTIGUOUS SIDEWALK SEE DETAIL DRAWING W3. ITEM DESCRIPTION SPEC/DWG 2" COPPER SERVICE PIPE OUTLET ON PVC PRESSURE PIPE W-8 OUTLET ON ACP PIPE W-8 OUTLET ON CML&C STEEL PIPE W-9 OUTLET ON DUCTILE IRON PIPE W-9 2" ANGLE METER STOP METER BOX AND COVER (TRAFFIC AREA)(TRAFF (NON-8 METER BOX AND COVER TRAFFIC AREA) 2" C X C 90' ELL (SILVER SOLDERED! J0_50 LB. ZINC ANODE WITH ANODE LEAD WIRE W-25 REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT 2" WATER SERVICE CONNECTION FOR I I/2" & 2" METERS J^fcjQv/jr CITY ENGINE&DATE STANDARD DWG. NO. A.C. MAIN P.V.C. MAIN FOR WATER SERVICE CONNECTION ( TYP. ) ITEM DESCRIPTION SPEC/DWG DOUBLE BAND BRASS SERVICE SADDLE. BRONZE DOUBLE STRAP SERVICE SADDLE. CORP. STOP 1 WATER SERVICE.W-3 CORP. STOP 2 WATER SERVICE.W-4 CORP, STOP 1" AIR VACUUM VALVE ASSEMBLY.W-7 CORP. STOP 2" AIR VACUUM VALVE ASSEMBLY W-7 1 MANUAL AIR RELEASE ASSEMBLY W-5 8 2 BLOW-OFF MANUAL AIR RELEASE ASSEMBLY.W-5&6 2" MANUAL BLOW-OFF / AIR RELEASE ASSEMBLY.W-6&7 REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT OUTLETS ON A.C. OR P.V.C. MAIN FOR I INCH THRU 2 INCH ASSEMBLIES CITY ENGINR DATE STANDARD DWG. NO.W-8 D.I. MAIN STEEL MAIN FOR WATER SERVICE CONNECTION ( TYP. ) ITEM DESCRIPTION SPEC/DWG DOUBLE BAND BRASS SERVICE SADDLE. CORP. STOP 1 WATER SERVICE.W-3 CORP. STOP 2 WATER SERVICE.W-4 CORP. STOP 1 AIR VACUUM VALVE ASSEMBLY.W-7 CORP. STOP? AIR VACUUM VALVE ASSEMBLY.W-7 1" MANUAL AIR RELEASE ASSEMBLY.W-5 2 BLOW-OFF MANUAL AIR RELEASE ASSEMBLY. 2" BLOW-OFF / AIR RELEASE ASSEMBLY. W-6&7 8 W-6&7 NOT USED 10 3000 PSI FORGED STEEL COUPLING WELDED TO MAIN.W-14 11 INSULATING BUSHING. ( LEXAN OR DELRIN ).W-10 REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT OUTLETS ON D.I. OR STEEL MAIN FOR I INCH THRU 2 INCH ASSEMBLIES CITY El DATE STANDARD DWG. NO.W-9 ~ FIELD WELD -° ( TYPICAL ). —-O < XV X SECTION A-A HELD APPLIED CEMENT MORTAR ALL AROUND. SIZING TABLE COPPER TUBING 2" 1" VALVE OR CORP.STOP 2" 1" STEELCOUPLING 2 1/2 1 1/2" INSULATING BUSHING 2 1/2 x 2" 1 1/2" x 1" NOTES: 1. DIELECTRIC CONNECTIONS SHALL BE REQUIRED ON ALL AIR AND VACUUM VALVE ASSEMBLIES, MANUAL AIR RELEASE ASSEMBLIES, BLOW-OFF ASSEMBLIES AND WATER SERVICE ASSEMBLIES WHERE COPPER TUBING OR BRASSS PIPE CONNECTIONS ARE MADE TO STEEL MAINS. ITEM DESCRIPTION SPEC/DWG CL 3000 STEEL COUPLING - STEEL WELDED. SEE DRAWING NO W9 W-9 INSULATING BUSHING - NPT LEXAN OR DELRIN. 9 DIA. 10 GA. SADDLE. NOT USED 1" & 2 COPPER SERVICE PIPE ( TYPE "K" SOFT ). REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT DIELECTRIC CONNECTION TO STEEL MAIN BUfrT. CITY ENGIN!DATE STANDARD DWG. NO.W-IO B PLAN FINISH GRADE, j rAC PAVEMENT. CO <£ i SECTION A-A DOMESTIC WATER RISER SHALL NOI REST ON BONNET OF VALVE. (2" MIN. CLEARANCE). SECTION B-B RECLAIMED WATER NOTES: 1. IN NON-ROAD AREAS PUCE MARKER POST NEXT TO VALVE BOX ASSEMBLY AS DIRECTED BY THE ENGINEER. ( SEE DRAWING NO. 23 ). 2. ALL BURIED NUTS AND BOLTS SHALL BE WAX TAPE COATED PER SPEC. 09902 3. SEE DRAWING NO. 23 FOR GATE VALVE EXTENSION. 4. UPPER SIDE OF LID TO RECIEVE 2 COATS OF PAINT. SEE SPECIFICATIONS FOR PAINTING REQUIREMENTS, ( PAGE 4 ). ITEM DESCRIPTION SPEC/DWG_ VAL BOX & COVER WITH NON-SKID CM. COVER AND LIFT HOLE. MARKED "WATER' VAL. BOX & COVER FOR NORMALLY CLOSED VALVE. VAL BOX & COVER MARKED RECYCLED WATER . 8" C900 PVC OR ASPHALT COATED WELL CASING. CONCRETE COLLAR IDENTIFY CONIC. BY CLASS 560-C-3250 6 POLYETHYLENE :NCASEMENT REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT VALVE BOX ASSEMBLY CITY EN > 7/A/gfi DATE STANDARD DWG. NO.W-I3 A CEMENT MORTAR LINE IN SHOP. FIELD POINT MORTAR IF DRY CONNECTION IS MADE. CUT TO FIT PIPE. SECTION A-A 1 i i 00 11 f 1 1 11 1- —111 f1r~ i ;j fe /"' V |! 18" MIN. ON ARC L _TL i If Lr VALVE & PIPE.. PER PLAN. PLAN NOTES: 1. FLANGE PRESSURE CLASS & FACING SHALL BE SAME AS ADJACENT VALVE. 2. REINFORCING SADDLE THICKNESS TO BE SAME AS MAIN T(3/16" MINIMUM). 3. FULL BACKING PLATE IS REQUIRED ON 12" AND LARGER MAINS & MAINS EXCEEDING 150 P.S.I. ITEM DESCRIPTION SPECDWG S.O.W.O. FLANGE. FIELD WELD ( TYPICAL ). EXISTING STEEL PIPE. EXISTING STEEL PIPE I.D. 3/4" MIN. CEMENT MORTAR COAT IN FIELD. REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTR GT TAPPED CONNECTION TO STEEL MAIN aUFr- CITY ENGIN DATE STANDARD DWG. NO. , - 4 FITTING OR COUPLING.CAP. ]_. 39" (RIGID ^-ir 1 MAX. PIPE) ^ ^-, 1 REINFORCING STEEL DETAIL. ENDCAPBLOCK. A=111/4',221/2'( 45*,50',60*. I. r i" I '""l"|f ' If'Wfl • VERTICAL BEND. 111/4*,221/2*, 45',50',61T, TEE (TOP VIEW). — -Jllr - HORIZONTAL & VERTICAL BEND. NOTES: TEE (SIDE VIEW). 1. FITTINGS SHALL BE DUCTILE IRON FOR D.I.P. & P.V.C.; CAST IRON FOR A.C.P. (CEMENT LINED SHORT BODY). LENGTH INTO AND OUT OF ALL FITTINGS. 3. CONCRETE SHALL BE 6 SACK, (3250 P.S.I.). HYDROSTATIC TEST. ' WAX TAPE CQATED ^ 4. SEE DWG'S. NO. 17 & 18 FOR REDUCER, PLUG, & BUTTERRY VALVE THRUST BLOCKS. 5. ENGINEER TO PROVIDE CALCULATIONS FOR THRUST/ANCHOR BLOCK SIZE. BE ITEM DESCRIPTION SPEC/DWG CONCRETE THRUST BLOCK. (560-G-3250) POLYETHYLENE ENCASEMENT. NO. 4 REINFORCING STEEL. VALVE BOX ASSEMBLY. FL X RT OR "L X MJ GATE VALVE. REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT CONCRETE THRUST BLOCKS FOR NON-RESTRAINED JOINTS CITY EN DATE STANDARD DWG. NO. W"~I5 FINISHED SURFACE (TYP.) , NOTES: 1. SEE SPECIFICATIONS FOR BURIED FLANGE AND VALVE REQUIREMENTS. 2. SEE DRAWING N0.19 FOR THRUST BLOCK BEARING AREAS. 3. All BURIED NUTS AND BOLTS SHALL BE WAX TAPE COATED PER SECT. 09902. TRENCH ELEVATION PVC PIPE TRENCH REINFORCING STEEL DETAIL. TRENCH SECTION (TYPICAL) TRENCH ELEVATION STEEL PIPE ITEM DESCRIPTION SPEC/DWG GATE VALVE POLYETHYLENE ENCASEMENT NO. 4 REINFORCING STEEL CONCRETE THRUST/ANCHOR BLOCK. (3250 P.S.U 560-C-5250 W-19 VALVE BOX ASSEMBLY.W-15 REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT GATE VALVE INSTALLATION P.V.C., & STEEL PIPE. "dbtofr CITY ENGINEER DATE STANDARD DWG. NO. V\(-|6 LINE VALVE INSTALLATION BUTTERFLY OR PLUG VALVE. 16" MIN. NOTE: ALL BURIED NUTS AND BOLTS SHALL BE WAX TAPE COATED PER SPEC. 09902 TEE ASSEMBLY ITEM DESCRIPTION SPEC/DWG FOR A.C.P. - 3CT LONG FL X PJ WALL PIPE. FOR P.V.C. - 30" LONG FL X MJ WALL PIPE. NO. 4 REINFORCING STEEL 6 O.C. EACH WAY. CONCRETE THRUST BLOCK. (3250 P.S.I.) 560-C-5250 W-19 POLYETHYLENE ENCASEMENT FOR P.V.C. - FL X PJ ADAPTER. FOR P.V.C. FL X MJ ADAPTER. 8 CONCRETE SUPPORT. SANDBAGS. 10 BUTTERFLY OR PLUG VALVE REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT BUTTERFLY & PLUG VALVE INSTALLATION FOR P.V.C. CITY ENGIN 7//Q/DB DATE STANDARD DWG. NO.W-I7 Q_UJQ nr CJ> UJ £ = CO ITEM r 2 3 -lit CD- @_ (5) z2 ~n|gjiE f .•.' ^y "^ ' 8"]j!i TRENCH MIN.Ti!J WIDTH ^=iv ' t. '!'•*• '*':_:3ZHQo3£ r Hi /jj ^<Z.i:- >i_.- . . , ^ '• ''." -4^ •-:'''•>* ' • -V • ' •« •%.'•- ^ " ' T • -1 J"j.v * 4 .. -• ' ' * 4 c • -» - ^ " i" •'-^ .-- *-.J H, 1 j |j I <j- ^ • '•'.•f. • VARIABLE - SEE NOTE F~l2*~ MIN._ _ o ) 't; *J •«*. •'"*••^^JfeajJ-^Sv.. 1 1 | ^-=fc.Ti-='- >i— %rix- —*S* • 4 >•w*1 h ii. »H) R T M A 00 ^«j — " & § LUUJ T UJ CD*c Cxi* JOTES: EARING AREA SHALL BE THE DIFFERENCE ETWEEN THE BEARING AREAS REQUIRED FOR HRUST ANCHORAGE OF MAINS ON EACH SIDE OF EDUCER AS FOUND FROM STD. DWG, 19 PLUS HE AREA OF THE TRENCH OPENING. INIMUM DIMENSIONS SHOWN SHAa BE DHERED TO. DESCRIPTION POLYETHYLENE ENCASEMENT CONCRETE THRUST BLOCK NO. 4 BAR 9" ON CENTER (560-C-3250 CONCRETE). EACH WAY. REV. APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT ^ TURIJQT I\ nr\uo i r DFntlfKtL/LH \NCHORFORWATERMAIN CITY a :ER - 4 THRU 16 INCH. STAND/ SPEC/DWG W-19 t~T./ls*M>»vJ<4 7y^?£ WINEER ^ DATE \RDDWG.NO. VV~I8 Q} d}t — O O C OO CD CO (E oo> o o CD 40 30 20 10 0 r y 1 NOTES- /!-]2 «j* ' zff J ^ Jj E ' c * /ri* 27 ^ 'g * • "•e jr I x i f * Jr J ^ ^ f , f J . * f\ 1r Ji- ' ' i* • T ji '- ^ ^ 4 w **Jf, ^ 1'y1 ' y 1 f 9 { ,*j^ iv*^i • " ^ 1 1 Vf/]]/]i/Mr/>/// 'Sr^n•A/]r//I'\ i' L iJj ^* <• J Tlr/ •>0 V ' •^ ^f / 0 y ^ ^v ^ , r 'V J \s* i, y ^v^ >? ">f .c ix „. V V kA *• f J» '•^ ^ ^^ ^f s ^ ^J L ^ k ^ ^1 1 •kJ ^ <•J^. ^ x 1* ' riT Lrjr..>.„ jr.-.f, = cj_.-. * V j J i..jjj \^r / S j _ _c J . { / ^*} f '* f 'j n •** r 2 s£ j^ > *' 27 ' JTN , t ^ j AV il r \x. • " *" \*H^2 S \ 4/ r ^ k ^ j^ I* j 1 C j r K^ . . - L 22 *• » j , C fi- - . . a 7o5<-! 3Z*J 2 3n *SJ« i I r - u 3Cssi! .ilSS--1Z * IS? h * S J / i? I J _„>.„rj r j . _r ------- 2r * 7,*j 2j r c r3 ™ 7 j;^2 £ 2^ Z"* i__---SSj___p *• j c ^ ^ . ^^i^? .„3t I Zv "] x1 2> ., r1 T f* _ 'r?^- j S * S ^L^K^ 5 - 1 S . _ - . _. p:: , ^ ,. ' , t ^ / J t$ A ' ' . 'f 4 if 2 j ^r j™ r •p J y > yi r , / ^ 6 8 10 12 14 16 Pipe Diameter in Inches 1. BASED ON 225. PSI TEST PRESSURE AND BEARING VALUES OF DRY SOILS. 2. VALUES FROM CURVES ARE FOR TEES AND DEADENDS, .E. ; STRAIGHT LINE THRUST. FOR 90' BEND: 1.4 VALUE FROM CURVE. FOR 45' BEND: 0.8 VALUE FROM CURVE. FOR 22 1/2- BEND: 0.4 VALUE FROM CURVE. 3. FOR CONDITIONS NOT COVERED BY CURVES, SPECIAL THRUST WALLS. THRUST BLOCKS AND ANCHORS MUST BE CALCULATED AND APPROVED. REV.APPROVED DATE CARLSBAD MUNICIPAL WATER I THRUST BLOCK BEARING A DISTRICT „)l .t ^- i / *.-//_ nr.^ CITY ENGINEER * DATE"EAo STANDARD DWG. NO. W- Q ZINC ANODE ANODE LEAD ABOVE GRADE CONNECTION ABOVE GRADE CONNECTION NOTES: 1. RISER PIPE SHALL BE WIRE BRUSHED TO CLEAN BRIGHT METAL. 2. PIPE CLAMP SHALL BE LOCATED ON RISER PIPE. 3. WIRE INSULATION SHALL BE STRIPPED TO A MINIMUM LENGTH TO CONNECT WIRE TO PIPE CLAMP. PACKAGED BACKFILL COMPOSITION: 75% GYPSUM 20% BENTONITE 5% SODIUM SULFATE INGOT WEIGHT: 30 LBS. PKGD. WEIGHT: 70 LBS. APPROX. ITEM DESCRIPTION SPEC/DWG ANODE LEAD N0.12 AWG STRD. COPPER WIRE W/ THW INSULATION. HEAT SHRINKABLE SLEEVE. SILVER SOLDER CONNECTION. 1/4" DIAMETER GALVANIZED STEEL CORE. 2"X2"X30 ZINC ALLOY INGOT. CLOTH BAG. PACKAGED BACKFILL 8 BRASS OR COPPER RISER PIPE. BRASS OR COPPER PIPE CLAMP WITH SCREW TERMINAL. REV.APPROVED DATE CARLSBAD MUNICIPAL WATER DISTRICT ZINC ANODE AND CONNECTORS FOR I" AND 2" WATER SERVICE W-25