The URL can be used to link to this page

Home My WebLink AboutTW Associates dba MISCOwater; 2019-07-24; PWS19-822UTIL-.. RECORDED REQUESTED BY CITY OF CARLSBAD DOC# 2020-0195215 111111111111 lllll 111111111111111111111111111111 IIIII IIIII IIIII IIII IIII Apr 17, 2020 08:52 AM OFFICIAL RECORDS Ernest J. Dronen burg, Jr., AND WHEN RECORDED PLEASE MAIL TO: SAN DIEGO COUNTY RECORDER FEES $0.00 (SB2 Atkins $0 00) City Clerk City of Carlsbad 1200 Carlsbad Village Drive Carlsbad, California 92008 PAGES 2 Space above this line for Recorder's use. PARCEL NO: NOTICE OF COMPLETION Notice is hereby given that: 1. The undersigned is owner of the interest or estate stated below in the property hereinafter described. 2. The full names of the undersigned are City of Carlsbad, a municipal corporation. 3. The full address of the undersigned is 1200 Carlsbad Village Drive, Carlsbad, California 92008. 4. The nature of the title of the undersigned is: In fee. 5. A work or improvement on the property hereinafter described was completed on Jan. 28, 2020. 6. The name of the contractor for such work or improvement is TW Associates dba MISCOwater. 7. The property on which said work or improvement was completed is in the City of Carlsbad, County of San Diego, State of California, and is described as follows: Project No. 3840-14, Project Name North Batiquitos Lift Station Hydropneumatic Surge Tank Replacement, Contract No. PWS19-822UTIL. 8. The street address of said property is 7382 Gabbiano Lane, in the City of Carlsbad. CITY OF CARLSBAD ~ Y ---: Geoff P/Jlnoe 1 A~1. ~ Scott Chadwick, City ManagJr li ·~ /VJ an ()o,t/ VERIFICATION OF CITY CLERK J I, the undersigned, say: I am the City Clerk of the City of Carlsbad, 120 Carlsbad Village Drive, Carlsbad, California, 92008; the City Manager of said City on ~ 20 d0 , accepted the above described work as completed and ordered tha a Notice of Completion be filed. I declare under penalty of perjury that the foregoing is true and correct. Executed on 4 J ~ i , 20 ;/() at Carlsbad, California. CITY OF CARLSBAD~ £~2~, 7" BARBARA ENGLESON .7 City Clerk 1-lecior Gorne21 Ptp~fj c,!;J Cleo/ Q:\Public Works\PW Common\00_PW Formally Approved DocumentslNOCs and APls\MISKO WATERINOC_NBLS Tank Replacement (MISKO) Biskup.doc -· CITY OF CARLSBAD ACCEPTANCE OF PUBLIC IMPROVEMENTS COMPLETION OF PUBLIC IMPROVEMENTS TW Associates dba MISCOwater has completed the contract work required for Project No. 3840-14; North Batiquitos Lift Station Hydropneumatic Surge Tank Replacement. City forces have inspected the work and found it to be satisfactory. The work consisted of: IMPROVEMENTS CITY: Hydropneumatics Surge Tank Replacement for the North Batiguitos Lift Station VALUE $151,814 CERTIFICATION OF COMPLETION OF IMPROVEMENTS Mark Bis Date/ I CITY MANAGER'S ACCEPTANCE OF PUBLIC IMPROVEMENTS The construction of the above described contract is deemed complete and hereby accepted. The City Clerk is hereby authorized to record the Notice of Completion and release the bonds in accordance with State Law and City Ordinances. The City of Carlsbad is hereby directed to commence maintaining the above described improvements. 0..1 ~ Y, L , GtoH \-Scott Chadwick, City Manager 1 Pafnge 1 A~1. Cifj Date f'J', tu) q j(, { APPROVED AS TO FORM: CELIA BREWER, City Attorney By)QQ,g_ ~ Deputy City Attorney Q \Public Works\PW Common\00_PW Formally Approved Documents\NOCs and APls\MISKO WATERIAPI_NBLS Tank Replacement (MISKO) Biskup.doc PWS19-822UTIL CONTRACT PUBLIC WORKS This agreement is made this d Lf t/1 day of __,.,_..._._.......,~o;:--------:----' 2019, by and between the City of Carlsbad, California, a municipal tion, (hereinafter called "City"), and TW Associates dba MISCOwater, a California corporation, whose principal place of business is 27101 Burbank, Suite B, Foothill Ranch, CA 92610 (hereinafter called "Contractor"). City and Contractor agree as follows: 1. Description of Work. Contractor shall perform all work specified in the Contract docu- ments for: NORTH BATIQUITOS LIFT STATION HYDROPNEUMATIC SURGE TANK REPLACEMENT CONTRACT NO. 3840-14 (hereinafter called "project") 2. Provisions of Labor and Materials. Contractor shall provide all labor, materials, tools, equipment, and personnel to perform the work specified by the Contract Documents. 3. Contract Documents. The Contract Documents consist of this Contract, Notice Inviting Bids, Contractor's Proposal, Bidder's Bond, Noncollusion Declaration, Designation of Subcontrac- tors, Technical Ability and Experience, Bidder's Statement Re Debarment, Escrow Agreement, Release Form, the Plans and Specifications, the General Provisions, addendum(s) to said Plans and Specifications and General Provisions, and all proper amendments and changes made thereto in accordance with this Contract or the Plans and Specifications, and all bonds for the project; all of which are incorporated herein by this reference. Contractor, her/his subcontractors, and materials suppliers shall provide and install the work as indicated, specified, and implied by the Contract Documents. Any items of work not indicated or specified, but which are essential to the completion of the work, shall be provided at the Contrac- tor's expense to fulfill the intent of said documents. In all instances through the life of the Contract, the City will be the interpreter of the intent of the Contract Documents, and the City's decision relative to said intent will be final and binding. Failure of the Contractor to apprise subcontractors and materials suppliers of this condition of the Contract will not relieve responsibility of compli- ance. 4. Payment. For all compensation for Contractor's performance of work under this Contract, City shall make payment to the Contractor per section 9-3 PAYMENT of the General Provisions section of this contract. The Engineer will close the estimate of work completed for progress pay- ments on the last working day of each month. The City shall withhold retention as required by Public Contract Code Section 9203. 5. Independent Investigation. Contractor has made an independent investigation of the jobsite, the soil conditions at the jobsite, and all other conditions that might affect the progress of the work and is aware of those conditions. The Contract price includes payment for all work that may be done by Contractor, whether anticipated or not, in order to overcome underground condi- tions. Any information that may have been furnished to Contractor by City about underground conditions or other job conditions is for Contractor's convenience only, and City does not warrant ft ~, Revised 6/12/18 Contract No. 3840-14 Page 1 of 73 PWS 19-822UTIL that the conditions are as thus indicated. Contractor is satisfied with all job conditions, including underground conditions and has not relied on information furnished by City. 6. Hazardous Waste or Other Unusual Conditions. If the contract involves digging trenches or other excavations that extend deeper than four feet below the surface Contractor shall promptly, and before the following conditions are disturbed, notify City, in writing, of any: A. Hazardous Waste. Material that Contractor believes may be material that is hazardous waste, as defined in section 25117 of the Health and Safety Code, that is required to be removed to a Class I, Class II, or Class Ill disposal site in accordance with provisions of existing law. B. Differing Conditions. Subsurface or latent physical conditions at the site differing from those indicated. C. Unknown Physical Conditions. Unknown physical conditions at the site of any unusual nature, different materially from those ordinarily encountered and generally recognized as inher- ent in work of the character provided for in the contract. City shall promptly investigate the conditions, and if it finds that the conditions do materially so differ, or do involve hazardous waste, and cause a decrease or increase in contractor's costs of, or the time required for, performance of any part of the work shall issue a change order under the procedures described in this contract. In the event that a dispute arises between City and Contractor whether the conditions materially differ, or involve hazardous waste, or cause a decrease or increase in the contractor's cost of, or time required for, performance of any part of the work, contractor shall not be excused from any scheduled completion date provided for by the contract, but shall proceed with all work to be performed under the contract. Contractor shall retain any and all rights provided either by contract or by law which pertain to the resolution of disputes and protests between the contracting parties. 7. Immigration Reform and Control Act. Contractor certifies it is aware of the require- ments of the Immigration Reform and Control Act of 1986 (8 USC sections 1101-1525) and has complied and will comply with these requirements, including, but not limited to, verifying the eligi- bility for employment of all agents, employees, subcontractors, and consultants that are included in this Contract. 8. Prevailing Wage. Pursuant to the California Labor Code, the director of the Department of Industrial Relations has determined the general prevailing rate of per diem wages in accordance with California Labor Code, section 1773 and a copy of a schedule of said general prevailing wage rates is on file in the office of the City Engineer and is incorporated by reference herein. Pursuant to California Labor Code, section 1775, Contractor shall pay prevailing wages. Contractor shall post copies of all applicable prevailing wages on the job site. Contractor shall comply with Cali- fornia Labor Code, section 1776, which generally requires keeping accurate payroll records, ver- ifying and certifying payroll records, and making them available for inspection. Contractor shall require all subcontractors to comply with Section 1776. 9. Indemnification. Contractor shall assume the defense of, pay all expenses of defense, and indemnify and hold harmless the City, and its officers and employees, from all claims, loss, damage, injury and liability of every kind, nature and description, directly or indirectly arising from or in connection with the performance of the Contract or work; or from any failure or alleged failure of Contractor to comply with any applicable law, rules or regulations including those relating to ft {.I Revised 6/12/18 Contract No. 3840-14 Page 2 of 73 PWS19-822UTIL safety and health; and from any and all claims, loss, damages, injury and liability, howsoever the same may be caused, resulting directly or indirectly from the nature of the work covered by the Contract, except for loss or damage caused by the sole or active negligence or willful misconduct of the City. The expenses of defense include all costs and expenses including attorneys' fees for litigation, arbitration, or other dispute resolution method. Contractor shall also defend and indemnify the City against any challenges to the award of the contract to Contractor, and Contractor will pay all costs, including defense costs for the City. De- fense costs include the cost of separate counsel for City, if City requests separate counsel. Contractor shall also defend and indemnify the City against any challenges to the award of the contract to Contractor, arising in whole or in part from alleged inaccuracies or misrepresentation by the Contractor, whether intentional or otherwise, and Contractor will pay all costs, including defense costs for the City. Defense costs include the cost of separate counsel for City, if City requests separate counsel. 10. Insurance. Contractor shall procure and maintain for the duration of the contract insurance against claims for injuries to persons or damage to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his or her agents, representatives, employees or subcontractors. Said insurance shall meet the City's policy for insurance as stated in City Council Policy # 70. {A) Coverages and Limits Contractor shall maintain the types of coverages and minimum limits indicted herein: a. Commercial General Liability {CGL) Insurance: Insurance written on an "occurrence" ba- sis, including products-completed operations, personal & advertising injury, with limits no less than $2,000,000 per occurrence. If a general aggregate limit applies, either the general aggregate limit shall apply separately to this project/location or the general aggregate limit shall be twice the required occurrence limit. b. Business Automobile Liability Insurance: $2,000,000 combined single limit per accident for bodily injury and property damage. In addition, the auto policy must cover any vehicle used in the performance of the contract, used onsite or offsite, whether owned, non-owned or hired, and whether scheduled or non-scheduled. c. Workers' Compensation and Employers' Liability Insurance: Workers' compensation limits as required by the Labor Code of the State of California and Employers' Liability limits of $1,000,000 per incident. Workers' compensation offered by the State Compensation Insurance Fund is acceptable to the City. {B) Additional Provisions: Contractor shall ensure that the policies of insurance required under this agreement with the exception of Workers' Compensation and Business Automobile Liability Insurance contain, or are endorsed to contain, the following provisions. a. The City, its officials, employees and volunteers are to be covered as additional insured as respects: liability arising out of activities performed by or on behalf of the Contractor; products and completed operations of the contractor; premises owned, leased, hired or borrowed by the contractor. The coverage shall contain no special limitations on the scope of protection afforded to the City, its officials, employees or volunteers. All additional insured endorsements must be evidenced using separate documents attached to the certificate of insurance; one for each com- pany affording general liability, and employers' liability coverage. ft Q Revised 6/12/18 Contract No. 3840-14 Page 3 of 73 PWS19-822UTIL b. The Contractor's insurance coverage shall be primary insurance as respects the City, its officials, employees and volunteers. Any insurance or self-insurance maintained by the City, its officials, employees or volunteers shall be in excess of the contractor's insurance and shall not contribute with it. c. Any failure to comply with reporting provisions of the policies shall not affect coverage pro- vided to the City, its officials, employees or volunteers. d. Coverage shall state that the contractor's insurance shall apply separately to each insured against whom claim is made or suit is brought, except with respect to the limits of the insurer's liability. (C) Notice of Cancellation. Each insurance policy required by this agreement shall be endorsed to state that coverage shall not be nonrenewed, suspended, voided, canceled, or reduced in cov- erage or limits except after ten ( 10) days' prior written notice has been sent to the City by certified mail, return receipt requested. (D) Deductibles and Self-Insured Retention (S.I.R.) Levels. Any deductibles or self-insured retention levels must be declared to and approved by the City. At the option of the City, either: the insurer shall reduce or eliminate such deductibles or self-insured retention levels as respects the City, its officials and employees; or the contractor shall procure a bond guaranteeing payment of losses and related investigation, claim administration and defense expenses. (E) Waiver of Subrogation. All policies of insurance required under this agreement shall contain a waiver of all rights of subrogation the insurer may have or may acquire against the City or any of its officials or employees. (F) Subcontractors. Contractor shall include all subcontractors as insured under its policies or shall furnish separate certificates and endorsements for each subcontractor. Coverages for sub- contractors shall be subject to all of the requirements stated herein. (G) Acceptability of Insurers. Insurance is to be placed with insurers that have a rating in Best's Key Rating Guide of at least A-:VII. Insurers must also be authorized to transact the business of insurance by the State of California Insurance Commissioner as admitted carriers as evidenced by a listing in the official publication of the Department of Insurance of the State of California and/or under the standards specified by City Council Policy# 70. (H) Verification of Coverage. Contractor shall furnish the City with certificates of insurance and original endorsements affecting coverage required by this clause. The certificates and endorse- ments for each insurance policy are to be signed by a person authorized by that insurer to bind coverage on its behalf. The certificates and endorsements are to be in forms approved by the City and are to be received and approved by the City before the Contract is executed by the City. (I) Cost of Insurance. The Cost of all insurance required under this agreement shall be included in the Contractor's bid. 11. Claims and Lawsuits. All claims by Contractor shall be resolved in accordance with Public Contract Code section 9204, which is incorporated by reference. A copy of Section 9204 is in- cluded in Section 3 of the General Provisions. In addition, all claims by Contractor for $375,000 or less shall be resolved in accordance with the provisions in the Public Contract Code, Division 2, Part 3, Chapter 1, Article 1.5 (commencing with section 20104) which are incorporated by ref- erence. A copy of Article 1.5 is included in Section 3 of the General Provisions. In the event of a ~ ~ Revised 6/12/18 Contract No. 3840-14 Page 4 of 73 PWS 19-822UTIL conflict between Section 9204 and Article 1.5, Section 9204 shall apply. Notwithstanding the pro- visions of this section of the contract, all claims shall comply with the Government Tort Claim Act (section 900 et seq., of the California Government Code) for any claim or cause of action for money or damages prior to filing any lawsuit for breach of this agreement. (A) Assertion of Claims. Contractor hereby agrees that any contract claim submitted to the City must be asserted as part of the contract process as set forth in this agreement and not in antici- pation of litigation or in conjunction with litigation. (B) False Claims. Contractor acknowledges that if a false claim is submitted to the City, it may be considered fraud and the Contractor may be subject to criminal prosecution. (C) Government Code. Contractor acknowledges that California Government Code sections 12650 et seq., the False Claims Act, provides for civil penalties where a person knowingly submits a false claim to a public entity. These provisions include false claims made with deliberate igno- rance of the false information or in reckless disregard of the truth or falsity of the information. (D) Penalty Recovery. If the City of Carlsbad seeks to recover penalties pursuant to the False Claims Act, it is entitled to recover its litigation costs, including attorney's fees. (E) Debarment for False Claims. Contractor hereby acknowledges that the filing of a false claim may subject the Contractor to an administrative debarment proceeding wherein the Contractor may be prevented from further bidding on public contracts for a period of up to five years. (F) Carlsbad Municipal Code. The provisions of Carlsbad Municipal Code sections 3.32.025, 3.32.026, 3.32.027 and 3.32.028 pertaining to false claims are incorporated herein by reference. (G) Debarment from Other Jurisdictions. Contractor hereby acknowledges that debarment by another jurisdiction is grounds for the City of Carlsbad to disqualify the Contractor or subcontractor from participating in future contract bidding. (H) Jurisdiction. Contractor agrees and hereby stipulates that the proper venue and jurisdiction for resolution of any disputes between the parties arising out of this agreement is San Diego County, California. I have read and understand all provisions of Section 11 above. ~ init CivI init 12. Maintenance of Records. Contractor shall maintain and make available at no cost to the City, upon request, records in accordance with sections 1776 and 1812 of Part 7, Chapter 1, Article 2, of the Labor Code. If the Contractor does not maintain the records at Contractor's prin- cipal place of business as specified above, Contractor shall so inform the City by certified letter accompanying the return of this Contract. Contractor shall notify the City by certified mail of any change of address of such records. 13. Labor Code Provisions. The provisions of Part 7, Chapter 1, commencing with section 1720 of the Labor Code are incorporated herein by reference. 14. Security. Securities in the form of cash, cashier's check, or certified check may be substi- tuted for any monies withheld by the City to secure performance of this contract for any obligation established by this contract. Any other security that is mutually agreed to by the Contractor and the City may be substituted for monies withheld to ensure performance under this Contract. ft Q Revised 6/12/18 Contract No. 3840-14 Page 5 of 73 PWS 19-822UTIL 15. Unfair Business Practices. In entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or sub- contractor offers and agrees to assign to the awarding body all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec. 15) or under the Cartwright Act (Chapter 2 (commencing with Section 16700) of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursu- ant to the public works contract or the subcontract. This assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment by the parties. 16. Provisions Required by Law Deemed Inserted. Each and every provision of law and clause required by law to be inserted in this Contract shall be deemed to be inserted herein and included herein, and if, through mistake or otherwise, any such provision is not inserted, or is not correctly inserted, then upon application of either party, the Contract shall forthwith be physically amended to make such insertion or correction. 17. Additional Provisions. Any additional provisions of this agreement are set forth in the "General Provisions" or "Supplemental Provisions" attached hereto and made a part hereof. NOTARIAL ACKNOWLEDGMENT OF EXECUTION BY ALL SIGNATORIES MUST BE ATTACHED (CORPORATE SEAL) ARLSBAD a municipal corporation of C lifomia President or vice-president and secretary or assistant secretary must sign for corporations. If only one officer signs, the corporation must attach a resolution certified by the secretary or assistant secretary under the corporate seal empowering that officer to bind the corporation. APPROVED AS TO FORM: CELIA A. BREWER City Attorney By: ft \.J Revised 6/12/18 Contract No. 3840-14 Page 6 of 73 PWS19-822UTIL EXHIBIT A JOB QUOTATION ITEM UNIT QTY DESCRIPTION PRICE NO. 1 Each 1 Provide Hydropneumatic Surge Tank and Air Compressor per attached: $131,070 Appendix A -General Provisions Appendix B -Section 01010 Scope of Work; Appendix C -Drawing 306-6 Annotated Revisions Appendix D -Existino Suroe Tank Documents 2 Lump 1 Remove Existing Surge Protection System Equipment and Sum Install New Hydropneumatic Surge Tank System per at-$20,744 tached: Appendix A -General Provisions Appendix B -Section 01010 Scope of Work; Appendix C -Drawing 306-6 Annotated Revisions Aooendix D -Existino Suroe Tank Documents TOTAL* $151,814 *Includes taxes, fees, expenses and all other costs ~ Q Revised 6/12/18 Contract No. 3840-14 Page 7 of 73 PWS 19-822UTIL EXHIBIT B LISTING OF SUBCONTRACTORS BY GENERAL CONTRACTOR NORTH BATIQUITOS LIFT STATION HYDROPNEUMATIC SURGE TANK REPLACEMENT CONTRACT NO. 3840-14 Set forth below is the full name and location of the place of business of each sub-contractor whom the Contractor proposes to subcontract portions of the Project in excess of one-half of one percent of the total bid, and the portion of the Project which will be done by each sub-contractor for each subcontract. NOTE: The Contractor understands that if it fails to specify a sub-contractor for any portion of the Project to be performed under the contract in excess of one-half of one percent of the bid, the contractor shall be deemed to have agreed to perform such portion, and that the Contractor shall not be permitted to sublet or subcontract that portion of the work, except in cases of public emergency or necessity, and then only after a finding, reduced in writing as a public record of the Awarding Authority, setting forth the facts constituting the emergency or necessity in accordance with the provisions of the Subletting and Subcontracting Fair Practices Act (Section 4100 et seq. of the California Public Contract Code). If no subcontractors are to be employed on the project, enter the word "NONE." SUBCONTRACTORS Subcontractor Name Phone No. DIR Subcontractor's Amount of Portion of and and Email Registration License No. and Work by Work Subcontractor Location of Business Address No. Classification in Dollars* :.L,.s,A(.. '-"3f\r.,,,,;Sc,..J 5v C:r:,;..ic~~ 7H-4Ilf -'1l'f(.,, f O<X,c(:. 7 3 1<, 7G:i03ss-, 'A,,,. /8~5"00 Page __ of __ pages of this Subcontractor Designation form Total % Subcontracted: __ 9 ____ _ The Contractor must perform no less than fifty percent (50%) of the work with its own forces. ft ~, Revised 6/12/18 Contract No. 3840-14 Page 8 of 73 EXHIBIT C Bond #070207596 Premium: Incl. in Performance Bond PWS 19-822UTI L LABOR AND MATERIALS BOND WHEREAS, the City of Carlsbad, State of California, has awarded to TW Associates dba MIS- COwater (hereinafter designated as the "Principal") a Contract for: NORTH BATIQUITOS LIFT STATION HYDROPNEUMATIC SURGE TANK REPLACEMENT CONTRACT NO. 3840-14 in the City of Carlsbad, in strict conformity with the drawings and specifications, and other Contract Documents now on file in the Office of the City Clerk of the City of Carlsbad and all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond, providing that if Principal or any of their subcontractors shall fail to pay for any materials, provisions, provender or other supplies or teams used in, upon or about the performance of the work agreed to be done, or for any work or labor done thereon of any kind, the Surety on this bond will pay the same to the extent hereinafter set forth. NOW, THEREFORE, WE, TW Associates dba MISCOwater, as Principal, (hereinafter designated as the "Contractor"), and Liberty Mutual Insurance Company as Surety, are held firmly bound unto the City of Carlsbad in the sum of one hundred fifty-one eight hundred fourteen Dollars ($151,814), said sum being an amount equal to: One hundred percent ( 100%) of the total amount payable under the terms of the contract by the City of Carls- bad, and for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the Contractor or his/her subcontrac- tors fail to pay for any materials, provisions, provender, supplies, or teams used in, upon, for, or about the performance of the work contracted to be done, or for any other work or labor thereon of any kind, consistent with California Civil Code section 9100, or for amounts due under the Unemployment Insurance Code with respect to the work or labor performed under this Contract, or for any amounts required to be deducted, withheld, and paid over to the Employment Develop- ment Department from the wages of employees of the contractor and subcontractors pursuant to section 13020 of the Unemployment Insurance Code with respect to the work and labor, that the Surety will pay for the same, and, also, in case suit is brought upon the bond, reasonable attor- ney's fees, to be fixed by the court consistent with California Civil Code section 9554. This bond shall inure to the benefit of any of the persons named in California Civil Code section 9100, so as to give a right of action to those persons or their assigns in any suit brought upon the bond. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed hereunder or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications. ,, •+;' Revised 6/12/18 Contract No. 3840-14 Page 9 of 73 PWS19-822UTIL In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. SIGNED AND SEALED, this _..:..;1 s=t ____ day of __ -=Ju=ly,,__ _______ , 20__1L TW Associates, DBA MISCOwater (SEAL) Liberty Mutual Insurance Company (SEAL) (Surety) (Principal) ~,~~~ (Signature) By 'r/J,~~ (Sir,ature) Erin Bautista, Attorney-in-Fact (SEAL AND NOTARIAL ACKNOWLEDGEMENT OF SURETY -ATTACH ATTORNEY-IN-FACT CERTIFICATE) APPROVED AS TO FORM: CELIA A. BREWER City Attorney By: ,, •+;' Revised 6/12/18 Contract No. 3840-14 Page 10 of 73 ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Santa Clara On July 1, 2019 before me, Jean L. Neu, Notary Public (insert name and title of the officer) personally appeared _E_r_in_B_a_u_t_is_ta ______________________ _ who proved to me on the basis of satisfactory evidence to be the person~) whose name(g) is/m:& subscribed to the within instrument and acknowledged to me that llm/she/~y executed the same in fflS/herbUwt,rnuthorized capacity~, and that by m!J/her/~ir signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signatur~L (Seal) THIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON RED BACKGROUND. This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated. Certificate No. 8018403 Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint. Bryan D. Martin; Erin Bautista; Angelina A. Campana; Jean L. Neu; Debra Ann Perry all of the city of San Mateo , state of CA each individually if there be more than one named, its true and lawful attorney-in-fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 22nd day of February ~ STATE OF PENNSYLVANIA COUNTY OF MONTGOMERY ss By: The Ohio Casualty Insurance Company Liberty Mutual Insurance Company West 1\merican Insurance Company /J //'' I// /;7_?' £C~ / (~;,~: --------- David M. Carey./\ssistant Secretary On this 22nd day of February , 2018 . before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company, The Ohio Casualty Company. and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. IN WITNESS WHEREOF. I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written. :'/:: "'"' COMMONWEALTH OF PENNSYLVANIA Not;:-ina! Snal Teres.1 P;iste:!a, Notary Putihc Upper Merion Twp , Montoomery County My Comrn1ss,on Expires March 2R, 2021 ~ 1-t'SY\..\I~°' V Oi,4Fr{ p,J'?>V Mcmt;er P,~nnsy!vr~rim Ass,1u,1t1on ul NrJtcme!> By: ~~ !lut;µ Teresa Pastella, Notary Public This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: ARTICLE IV -OFFICERS -Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President. and subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys-in-fact, subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney-in-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE XIII -Execution of Contracts -SECTION 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal. acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys-in-fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation -The President of the Company. acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attorneys-in- tact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization -By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Renee C Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company. Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this .,..- day of U i{, ,20J.j_ 93 of 250 LMS_ 12873_022017 «I -0 1/) 1/) G) C: 1/): :::I .c C: «I C: -o ~I- >,(/) a,W EE 0 :t::o <(C'") 0~ ... "O G) C: ~ «I OE a. «I .!!?o .c:O ..... _en 0 C: >, G) ... G) :a~ ·---G) ~.c G) 0 .c: ..,. ..,N 00 EN'' ... ' •-M -oo C: I 00 C.,T"" o<-9 I-,.... EXHIBIT D Bond #070207596 Premium: $2,277.00 PWS19-822UTIL FAITHFUL PERFORMANCE/WARRANTY BOND WHEREAS, the City Council of the City of Carlsbad, State of California, has awarded to TW Associates dba MISCOwater (hereinafter designated as the "Principal") a Contract for: NORTH BATIQUITOS LIFT STATION HYDROPNEUMATIC SURGE TANK REPLACEMENT CONTRACT NO. 3840-14 in the City of Carlsbad, in strict conformity with the contract, the drawings and specifications, and other Contract Documents now on file in the Office of the City Clerk of the City of Carlsbad, all of which are incorporated herein by this reference. WHEREAS, Principal has executed or is about to execute said Contract and the terms thereof require the furnishing of a bond for the faithful performance and warranty of said Contract; NOW, THEREFORE, WE, TW Associates dba MISCOwater, as Principal, (hereinafter designated as the "Contractor"), and Liberty Mutual Insurance Company as Surety, are held firmly bound unto the City of Carlsbad in the sum of one hundred fifty-one eight hundred fourteen Dollars ($151,814), said sum being an amount equal to: One hundred percent (100%) of the total amount payable under the terms of the contract by the City of Carls- bad, and for which payment well and truly to be made we bind ourselves, our heirs, executors and administrators, successors, or assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION IS SUCH that if the above bounden Contractor, their heirs, executors, administrators, successors or assigns, shall in all things stand to and abide by, and well and truly keep and perform the covenants, conditions, and agreements in the Contract and any alteration thereof made as therein provided on their part, to be kept and performed at the time and in the manner therein specified, and in all respects according to their true intent and meaning, and shall indemnify and save harmless the City of Carlsbad, its officers, employees and agents, as therein stipulated, then this obligation shall become null and void; otherwise it shall remain in full force and effect. As a part of the obligation secured hereby and in addition to the face amount specified therefore, there shall be included costs and reasonable expenses and fees, including reasonable attorney's fees, incurred by the City in successfully enforcing such obligation, all to be taxed as costs and included in any judgment rendered. Surety stipulates and agrees that no change, extension of time, alteration or addition to the terms of the Contract, or to the work to be performed there under or the specifications accompanying the same shall affect its obligations on this bond, and it does hereby waive notice of any change, extension of time, alterations or addition to the terms of the contract or to the work or to the specifications . . , \.;, Revised 6/15/17 Contract No. 3840-14 Page 11 of 73 PWS19-822UTIL In the event that Contractor is an individual, it is agreed that the death of any such Contractor shall not exonerate the Surety from its obligations under this bond. SIGNED AND SEALED, this ---"-1=st"------day of ___ J_ul..._y _______ , 20.1§L_ TW Associates, DBA MISCOwater (SEAL) Liberty Mutual Insurance Company (SEAL) (Surety) (Principal) ByL~µ By~~ (Signature) Erin Bautista, Attorney-in-Fact (SEAL AND NOTARIAL ACKNOWLEDGEMENT OF SURETY -ATTACH ATTORNEY-IN-FACT CERTIFICATE) APPROVED AS TO FORM: CELIA A. BREWER City Attorney fl By c_ 1/ Deputy City Attorney ,, •+' Revised 6/15/17 Contract No. 3840-14 Page 12 of 73 '' ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of Santa Clara On July 1, 2019 before me, Jean L. Neu, Notary Public (insert name and title of the officer) personally appeared _E_r_in_B_a_u_t_is_ta ______________________ _ who proved to me on the basis of satisfactory evidence to be the person~) whose name(s) is/~ subscribed to the within instrument and acknowledged to me that l!J5/she/tb'ey executed the same in ~her~authorized capacity~~. and that by limr/her/Mreir signature(5) on the instrument the person(5), or the entity upon behalf of which the person(5) acted, executed the instrument. I certify under PENAL TY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signatur~--;--+---_;,_L __ ,,. 1 _____ _ (Seal) \"3A ♦. •· ..••••••••• i ~ &Ji~ JEAN L. NEU ·1 ;{r' · \~~ Notary Public -California z \~• t_f;,.~ Santa Clara County ! • ~~-¥._:.(;; Commission# 2230024 ,; ~ My Comm. Expires Mar 1, 2022 ,. (/) (I) (I) -C: ... ~ i5 ~ e Cl u (I) 02 ... !U (I)> i::-~ ~ ~ "C ~-;;; .2 e (1)0 0~ C: !U ~ ... THIS POWER OF ATTORNEY IS NOT VALID UNLESS IT IS PRINTED ON RED BACKGROUND. This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated. Certificate No. 8018404 Liberty Mutual Insurance Company The Ohio Casualty Insurance Company West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company Is a corporation duly organized under the laws of the State of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the "Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint. Bryan D. Martin; Erin Bautista; Angelina A. Campana; Jean L. Neu; Debra Ann Perry all of the city of San Mateo . state of CA each individually if there be more than one named, its true and lawful attorney-in-fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizances and other surety obligations. in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 22nd day of February . ~- STATE OF PENNSYLVANIA COUNTY OF MONTGOMERY ss By: The Ohio Casualty Insurance Company Liberty Mutual Insurance Company West •\merican Insurance Company ,1£:✓~;0.:;, --··----- David M. Carey.,.,Assistant Secretary On this 22nd day of February , 2018 . before me personally appeared David M Carey. who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company, The Ohio Casualty Company, and West American Insurance Company. and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. IN WITNESS WHEREOF. I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written. ~ ~~ COMMONWEALTH OF PENNSYLVANIA Nntana! SHai Tcn~sa Pastt~;1a. Notary Putil1c Upper Menon Twp., !'vfontqornery County My C0mrniss1on Exp,ms March 28, 2021 ~ i"~\)i►' ~ 0,::4Av ~V M0rntJ01. Pf:nnsylvania Ass()Cfc'lfton ut N(Jtanc~ By: .fiu~ U!k Teresa Pastella, Notary Public This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company. Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: (1)-Cl II) ~ e ARTICLE IV -OFFICERS -Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject t:: ~ to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, O .!: acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys-in-fact, subject to the limitations set forth in their respective E Cl) powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so ...... 0 <U executed. such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney-in-fact under .._ :::_ the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority :'S! .... Ri g ARTICLE XIII -Execution of Contracts -SECTION 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, ;; e and subject to such limitations as the chairman or the president may prescribe. shall appoint such attorneys-in-fact. as may be necessary to act in behalf of the Company to make, execute, o :5 seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attorneys-in-fact subject to the limitations set forth in their Z u respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation -The President of the Company. acting pursuant to the Bylaws of the Company. authorizes David M. Carey, Assistant Secretary to appoint such attorneys-in- f act as may be necessary to act on behalf of the Company to make, execute. seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Authorization -By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I. Renee C. Llewellyn, the undersigned. Assistant Secretary, The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company do hereby certify that the original power of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF. I have hereunto set my hand and affixed the seals of said Companies this / ~ f day of -..J Ct.. , , 20~. 94 of 250 LMS_ 12873_022017 RI "C (/) (/) (I) C: (/) ::, .0 C: !U C: -0 !U t-u C/'J ~w EE 0 t:o <(M 0~ ... "C (I) C: S:: RI oe a. !U .!!lo .c:o ~c;; 0 C: ~~ :a~ =(I) ~ .0 (1)0 .c: -.t .,N E °r .:: ~ 'E°r 00 u..-o<9 I-.... ACORD® CERTIFICATE OF LIABILITY INSURANCE I DATE (MMIDDNYYY) ~ 6/28/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER ~2~i~cT Dawn Steohens-Wriaht Wood Gutmann & Bogart r.~~N,;n c-"· 714-505-7000 I FAX 15901 Red Hill Ave., Suite 100 iAJc Nol: 714-573-1770 Tustin CA 92780 ~~D'M~ss: dawnln"lwnbib.com INSURERISI AFFORDING COVERAGE NAIC# INSURER A: HARTFORD FIRE IN CO 19682 INSURED INSURER B: Llovds of London 29424 T.W. Associates dba MISCOWater INSURER c : HARTFORD ACCID & IND CO 22357 27101 Burbank Suite B INSURER D: TWIN CITY FIRE INS CO CO 29459 Foothill Ranch CA 92610 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER· 1935321594 REVISION NUMBER· THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR ,:~M%~, l~~~J%~\ LTR 1 .. onn lun,n POLICY NUMBER LIMITS A X COMMERCIAL GENERAL LIABILITY 72UUOIZ6496 41112019 4/1/2020 EACH OCCURRENCE $1,000,000 ~ □ CLAIMS-MADE 0 OCCUR ~~~~~~J9E~~J~,;lence\ $300,000 ~ MED EXP (Any one person) $10,000 PERSONAL & ADV INJURY $1,000,000 ~ GEN'L AGGREGATE LIMIT APPLIES PER GENERAL AGGREGATE $2,000,000 Pl □PRO-DLoc POLICY JECT PRODUCTS -COMP/OP AGG $2,000,000 OTHER $ C AUTOMOBILE LIABILITY 72UUQIZ6496 4/112019 4/1/2020 fE~~~~~~llNGLE LIMIT $ 1000000 ~ X ANY AUTO BODIL y INJURY (Per person) $ ~ ALL OWNED ~ SCHEDULED AUTOS AUTOS BODIL y INJURY (Per accident) $ ~ ~ X X NON-OWNED ;p~~~~~le~t~AMAGE $ HIRED AUTOS AUTOS ~ ~ $ B UMBRELLA LIAB HOCCUR 72RHQYC9878 4/112019 4/1/2020 EACH OCCURRENCE $10,000,000 ~ X EXCESS LIAB CLAIMS-MADE AGGREGATE $10,000,000 / DED I I RETENTION$ $ D WORKERS COMPENSATION 72\NECAC9MAS 4/112019 4/1/2020 X I ~ffTuTE I I OTH- AND EMPLOYERS" LIABILITY YIN ER ANY PROPRIETOR/PARTNER/EXECUTIVE □ NIA E.L. EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? (Mandatory In NH) E.L. DISEASE -EA EMPLOYEE $1,000,000 ~lst~ri~r~ 'gfoPERATIONS below E.L. DISEASE -POLICY LIMIT $1,000,000 A Contractors's Equip 72UUOIZ6496 4/112019 4/1/2020 BPP $332,100 B Professional Liability ANE174530218 7/1312018 7/1312019 Aggregate $2,000,000 Prof Retro Date 7-13-16 SIR $50,000 / DESCRIPTION OF OPERATIONS/ LOCATIONS/ VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached If more space Is required) RE: 7382 Gabbiano Ln Carlsbad CA 92008; The City, its officials, employees and volunteers are named as additional insured on the General Liability per attached HG0001 0916 and on the Auto Liability per attached HA9916 0312 as required by written contract subject to the terms and conditions of the policy. Primary and Non-Contributory applies on the General Liability per attached HG0001 0916 Waiver of Subrogation applies to the General Liability per attached HG0001 0916 Waiver of Subrogation applies to the Workers' Compensation per attached WC 040306 Waiver of Subrogation applies to the Auto per attached HA9916 0312 CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of Carlsbad 1635 Faraday Ave AUTHORIZED REPRESENTATIVE Carlsbad CA 92008 ~~ I ACORD 25 (2014/01) / © 1988-2014 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD ✓ Policy Number: 72UUQIZ6496 COMMERCIAL AUTOMOBILE HA 99 16 0312 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. COMMERCIAL AUTOMOBILE BROAD FORM ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM To the extent that the provisions of this endorsement provide broader benefits to the "insured" than other provisions of the Coverage Form, the provisions of this endorsement apply. 1. BROAD FORM INSURED A. Subsidiaries and Newly Acquired or Formed Organizations The Named Insured shown in the Declarations is amended to include: (1) Any legal business entity other than a partnership or joint venture, formed as a subsidiary in which you have an ownership interest of more than 50% on the effective date of the Coverage Form. However, the Named Insured does not include any subsidiary that is an "insured" under any other automobile policy or would be an "insured" under such a policy but for its termination or the exhaustion of its Limit of Insurance. (2) Any organization that is acquired or formed by you and over which you maintain majority ownership. However, the Named Insured does not include any newly formed or acquired organization: (a) That is a partnership or joint venture, (b) That is an "insured" under any other policy, (c) That has exhausted its Limit of Insurance under any other policy, or (d) 180 days or more after its acquisition or formation by you, unless you have given us notice of the acquisition or formation. Coverage does not apply to "bodily injury" or "property damage" that results from an "accident" that occurred before you formed or acquired the organization. B. Employees as Insureds Paragraph A.1. -WHO IS AN INSURED -of SECTION II -LIABILITY COVERAGE is amended to add: d. Any "employee" of yours while using a covered "auto" you don't own, hire or borrow in your business or your personal affairs. C. Lessors as Insureds Paragraph A.1. -WHO IS AN INSURED -of Section 11 -Liability Coverage is amended to add: e. The lessor of a covered "auto" while the "auto" is leased to you under a written agreement if: (1) The agreement requires you to provide direct primary insurance for the lessor and (2) The "auto" is leased without a driver. Such a leased "auto" will be considered a covered "auto" you own and not a covered "auto" you hire. D. Additional Insured if Required by Contract (1) Paragraph A.1. -WHO IS AN INSURED -of Section II -Liability Coverage is amended to add: f. When you have agreed, in a written contract or written agreement, that a person or organization be added as an additional insured on your business auto policy, such person or organization is an "insured", but only to the extent such person or organization is liable for "bodily injury" or "property damage" caused by the conduct of an "insured" under paragraphs a. or b. of Who Is An Insured with regard to the ownership, maintenance or use of a covered "auto." Form HA 99 16 03 12 © 2011, The Hartford (Includes copyrighted material of ISO Properties, Inc., with its permission.) Page 1 of 5 The insurance afforded to any such additional insured applies only if the "bodily injury" or "property damage" occurs: (1) During the policy period, and (2) Subsequent to the execution of such written contract, and (3) Prior to the expiration of the period of time that the written contract requires such insurance be provided to the additional insured. (2) How Limits Apply If you have agreed in a written contract or written agreement that another person or organization be added as an additional insured on your policy, the most we will pay on behalf of such additional insured is the lesser of: (a) The limits of insurance specified in the written contract or written agreement; or (b) The Limits of Insurance shown in the Declarations. Such amount shall be a part of and not in addition to Limits of Insurance shown in the Declarations and described in this Section. (3) Additional Insureds Other Insurance If we cover a claim or "suit" under this Coverage Part that may also be covered by other insurance available to an additional insured, such additional insured must submit such claim or "suit" to the other insurer for defense and indemnity. However, this provision does not apply to the extent that you have agreed in a written contract or written agreement that this insurance is primary and non- contributory with the additional insured's own insurance. (4) Duties in The Event Of Accident, Claim, Suit or Loss If you have agreed in a written contract or written agreement that another person or organization be added as an additional insured on your policy, the additional insured shall be required to comply with the provisions in LOSS CONDITIONS 2. -DUTIES IN THE EVENT OF ACCIDENT, CLAIM , SUIT OR LOSS -OF SECTION IV - BUSINESS AUTO CONDITIONS, in the same manner as the Named Insured. E. Primary and Non-Contributory if Required by Contract Only with respect to insurance provided to an additional insured in 1.D. -Additional Insured If Required by Contract, the following provisions apply: (3) Primary Insurance When Required By Contract This insurance is primary if you have agreed in a written contract or written agreement that this insurance be primary. If other insurance is also primary, we will share with all that other insurance by the method described in Other Insurance 5.d. (4) Primary And Non-Contributory To Other Insurance When Required By Contract If you have agreed in a written contract or written agreement that this insurance is primary and non-contributory with the additional insured's own insurance, this insurance is primary and we will not seek contribution from that other insurance. Paragraphs (3) and (4) do not apply to other insurance to which the additional insured has been added as an additional insured. When this insurance is excess, we will have no duty to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers. When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of: (1) The total amount that all such other insurance would pay for the loss in the absence of this insurance; and (2) The total of all deductible and self-insured amounts under all that other insurance. We will share the remaining loss, if any, by the method described in Other Insurance 5.d. 2. AUTOS RENTED BY EMPLOYEES Any "auto" hired or rented by your "employee" on your behalf and at your direction will be considered an "auto" you hire. The OTHER INSURANCE Condition is amended by adding the following: Form HA 9916 0312 © 2011, The Hartford (Includes copyrighted material of ISO Properties, Inc., with its permission.) Page 2 of 5 If an "employee's" personal insurance also applies on an excess basis to a covered "auto" hired or rented by your "employee" on your behalf and at your direction, this insurance will be primary to the "employee's" personal insurance. 3. AMENDED FELLOW EMPLOYEE EXCLUSION EXCLUSION 5. -FELLOW EMPLOYEE -of SECTION II -LIABILITY COVERAGE does not apply if you have workers' compensation insurance in-force covering all of your "employees". Coverage is excess over any other collectible insurance. 4. HIRED AUTO PHYSICAL DAMAGE COVERAGE If hired "autos" are covered "autos" for Liability Coverage and if Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form for any "auto" you own, then the Physical Damage Coverages provided are extended to "autos" you hire or borrow, subject to the following limit. The most we will pay for "loss" to any hired "auto" is: (1) $100,000; (2) The actual cash value of the damaged or stolen property at the time of the "loss"; or (3) The cost of repairing or replacing the damaged or stolen property, whichever is smallest, minus a deductible. The deductible will be equal to the largest deductible applicable to any owned "auto" for that coverage. No deductible applies to "loss" caused by fire or lightning. Hired Auto Physical Damage coverage is excess over any other collectible insurance. Subject to the above limit, deductible and excess provisions, we will provide coverage equal to the broadest coverage applicable to any covered "auto" you own. We will also cover loss of use of the hired "auto" if it results from an "accident", you are legally liable and the lessor incurs an actual financial loss, subject to a maximum of $1000 per "accident". This extension of coverage does not apply to any "auto" you hire or borrow from any of your "employees", partners (if you are a partnership), members (if you are a limited liability company), or members of their households. 5. PHYSICAL DAMAGE ADDITIONAL TEMPORARY TRANSPORTATION EXPENSE COVERAGE Paragraph A.4.a. of SECTION Ill -PHYSICAL DAMAGE COVERAGE is amended to provide a limit of $50 per day and a maximum limit of $1,000. 6. LOAN/LEASE GAP COVERAGE Under SECTION Ill -PHYSICAL DAMAGE COVERAGE, in the event of a total "loss" to a covered "auto", we will pay your additional legal obligation for any difference between the actual cash value of the "auto" at the time of the "loss" and the "outstanding balance" of the loan/lease. "Outstanding balance" means the amount you owe on the loan/lease at the time of "loss" less any amounts representing taxes; overdue payments; penalties, interest or charges resulting from overdue payments; additional mileage charges; excess wear and tear charges; lease termination fees; security deposits not returned by the lessor; costs for extended warranties, credit life Insurance, health, accident or disability insurance purchased with the loan or lease; and carry-over balances from previous loans or leases. 7. AIRBAG COVERAGE Under Paragraph B. EXCLUSIONS -of SECTION Ill PHYSICAL DAMAGE COVERAGE, the following is added: The exclusion relating to mechanical breakdown does not apply to the accidental discharge of an airbag. 8. ELECTRONIC EQUIPMENT -BROADENED COVERAGE a. The exceptions to Paragraphs 8.4 - EXCLUSIONS -of SECTION Ill -PHYSICAL DAMAGE COVERAGE are replaced by the following: Exclusions 4.c. and 4.d. do not apply to equipment designed to be operated solely by use of the power from the "auto's" electrical system that, at the time of "loss", is: (1) Permanently installed in or upon the covered "auto"; (2) Removable from a housing unit which is permanently installed in or upon the covered "auto"; (3) An integral part of the same unit housing any electronic equipment described in Paragraphs (1) and (2) above; or Form HA 99 16 03 12 © 2011, The Hartford (Includes copyrighted material of ISO Properties, Inc., with its permission.) Page 3 of 5 (4) Necessary for the normal operation of the covered "auto" or the monitoring of the covered "auto's" operating system. b.Section Ill -Version CA 00 01 03 10 of the Business Auto Coverage Form, Physical Damage Coverage, Limit of Insurance, Paragraph C.2 and Version CA 00 01 10 01 of the Business Auto Coverage Form, Physical Damage Coverage, Limit of Insurance, Paragraph C are each amended to add the following: $1,500 is the most we will pay for "loss" in any one "accident" to all electronic equipment (other than equipment designed solely for the reproduction of sound, and accessories used with such equipment) that reproduces, receives or transmits audio, visual or data signals which, at the time of "loss", is: (1) Permanently installed in or upon the covered "auto" in a housing, opening or other location that is not normally used by the "auto" manufacturer for the installation of such equipment; (2) Removable from a permanently installed housing unit as described in Paragraph 2.a. above or is an integral part of that equipment; or (3) An integral part of such equipment. c. For each covered "auto", should loss be limited to electronic equipment only, our obligation to pay for, repair, return or replace damaged or stolen electronic equipment will be reduced by the applicable deductible shown in the Declarations, or $250, whichever deductible is less. 9. EXTRA EXPENSE BROADENED COVERAGE Under Paragraph A. -COVERAGE -of SECTION Ill -PHYSICAL DAMAGE COVERAGE, we will pay for the expense of returning a stolen covered "auto" to you. 10. GLASS REPAIR-WAIVER OF DEDUCTIBLE Under Paragraph D. -DEDUCTIBLE -of SECTION Ill -PHYSICAL DAMAGE COVERAGE, the following is added: No deductible applies to glass damage if the glass is repaired rather than replaced. 11. TWO OR MORE DEDUCTIBLES Under Paragraph D. -DEDUCTIBLE -of SECTION Ill -PHYSICAL DAMAGE COVERAGE, the following is added: If another Hartford Financial Services Group, Inc. company policy or coverage form that is not an automobile policy or coverage form applies to the same "accident", the following applies: (1) If the deductible under this Business Auto Coverage Form is the smaller (or smallest) deductible, it will be waived; (2) If the deductible under this Business Auto Coverage Form is not the smaller ( or smallest) deductible, it will be reduced by the amount of the smaller (or smallest) deductible. 12. AMENDED DUTIES IN THE EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS The requirement in LOSS CONDITIONS 2.a. - DUTIES IN THE EVENT OF ACCIDENT.CLAIM, SUIT OR LOSS -of SECTION IV -BUSINESS AUTO CONDITIONS that you must notify us of an "accident" applies only when the "accident" is known to: (1) You, if you are an individual; (2) A partner, if you are a partnership; (3) A member, if you are a limited liability company; or (4) An executive officer or insurance manager, if you are a corporation. 13. UNINTENTIONAL FAILURE TO DISCLOSE HAZARDS If you unintentionally fail to disclose any hazards existing at the inception date of your policy, we will not deny coverage under this Coverage Form because of such failure. 14. HIRED AUTO -COVERAGE TERRITORY Paragraph e. of GENERAL CONDITIONS 7. - POLICY PERIOD, COVERAGE TERRITORY - of SECTION IV BUSINESS AUTO CONDITIONS is replaced by the following: e. For short-term hired "autos", the coverage territory with respect to Liability Coverage is anywhere in the world provided that if the "insured's" responsibility to pay damages for "bodily injury" or "property damage" is determined in a "suit," the "suit" is brought in the United States of America, the territories and possessions of the United States of America, Puerto Rico or Canada or in a settlement we agree to. 15. WAIVER OF SUBROGATION TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US -of SECTION IV - BUSINESS AUTO CONDITIONS is amended by adding the following: Form HA 99 16 0312 © 2011, The Hartford (Includes copyrighted material of ISO Properties, Inc., with its permission.) Page 4 of 5 We waive any right of recovery we may have against any person or organization with whom you have a written contract that requires such waiver because of payments we make for damages under this Coverage Form. 16. RESULT ANT MENTAL ANGUISH COVERAGE The definition of "bodily injury" in SECTION V- DEFINITIONS is replaced by the following: "Bodily injury" means bodily injury, sickness or disease sustained by any person, including mental anguish or death resulting from any of these. 17. EXTENDED CANCELLATION CONDITION Paragraph 2. of the COMMON POLICY CONDITIONS -CANCELLATION -applies except as follows: If we cancel for any reason other than nonpayment of premium, we will mail or deliver to the first Named Insured written notice of cancellation at least 60 days before the effective date of cancellation. 18. HYBRID, ELECTRIC, OR NATURAL GAS VEHICLE PAYMENT COVERAGE In the event of a total loss to a "non-hybrid" auto for which Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form, then such Physical Damage Coverages are amended as follows: a. If the auto is replaced with a "hybrid" auto or an auto powered solely by electricity or natural gas, we will pay an additional 10%, to a maximum of $2,500, of the "non-hybrid" auto's actual cash value or replacement cost, whichever is less, b. The auto must be replaced and a copy of a bill of sale or new lease agreement received by us within 60 calendar days of the date of "loss," c. Regardless of the number of autos deemed a total loss, the most we will pay under this Hybrid, Electric, or Natural Gas Vehicle Payment Coverage provision for any one "loss" is $10,000. For the purposes of the coverage provision, a.A "non-hybrid" auto is defined as an auto that uses only an internal combustion engine to move the auto but does not include autos powered solely by electricity or natural gas. b.A "hybrid" auto is defined as an auto with an internal combustion engine and one or more electric motors; and that uses the internal combustion engine and one or more electric motors to move the auto, or the internal combustion engine to charge one or more electric motors, which move the auto. 19. VEHICLE WRAP COVERAGE In the event of a total loss to an "auto" for which Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this Coverage Form, then such Physical Damage Coverages are amended to add the following: In addition to the actual cash value of the "auto", we will pay up to $1,000 for vinyl vehicle wraps which are displayed on the covered "auto" at the time of total loss. Regardless of the number of autos deemed a total loss, the most we will pay under this Vehicle Wrap Coverage provision for any one "loss" is $5,000. For purposes of this coverage provision, signs or other graphics painted or magnetically affixed to the vehicle are not considered vehicle wraps. Form HA 99 16 0312 © 2011, The Hartford (Includes copyrighted material of ISO Properties, Inc., with its permission.) Page 5 of 5 Policy Number: 72UUQIZ6496 / SECTION II -WHO IS AN INSURED 1. If you are designated in the Declarations as: a. An individual, you and your spouse are insureds, but only with respect to the conduct of a business of which you are the sole owner. b. A partnership or joint venture, you are an insured. Your members, your partners, and their spouses are also insureds, but only with respect to the conduct of your business. c. A limited liability company, you are an insured. Your members are also insureds, but only with respect to the conduct of your business. Your managers are insureds, but only with respect to their duties as your managers. d. An organization other than a partnership, joint venture or limited liability company, you are an insured. Your "executive officers" and directors are insureds, but only with respect to their duties as your officers or directors. Your stockholders are also insureds, but only with respect to their liability as stockholders. e. A trust, you are an insured. Your trustees are also insureds, but only with respect to their duties as trustees. 2. Each of the following is also an insured: a. Employees And Volunteer Workers Your "volunteer workers" only while performing duties related to the conduct of your business, or your "employees", other than either your "executive officers" (if you are an organization other than a partnership, joint venture or limited liability company) or your managers (if you are a limited liability company), but only for acts within the scope of their employment by you or while performing duties related to the conduct of your business. However, none of these "employees" or "volunteer workers" are insureds for: (1) "Bodily injury" or "personal and advertising injury": (a) To you, to your partners or members (if you are a partnership or joint venture), to your members (if you are a limited liability company), to a co-"employee" while in the course of his or her employment or performing duties related to the conduct of your business, or to your other "volunteer workers" while performing duties related to the conduct of your business; (b) To the spouse, child, parent, brother or sister of that co-"employee" or that HG 00 01 0916 "volunteer worker" as a consequence of Paragraph (1 )(a) above; (c) For which there is any obligation to share damages with or repay someone else who must pay damages because of the injury described in Paragraphs (1 )(a) or (1 )(b) above; or (d) Arising out of his or her providing or failing to provide professional health care services. If you are not in the business of providing professional health care services: (a) Subparagraphs (1)(a), (1)(b) and (1)(c) above do not apply to any "employee" or "volunteer worker" providing first aid services; and (b) Subparagraph (1)(d) above does not apply to any nurse, emergency medical technician or paramedic employed by you to provide such services. (2) "Property damage" to property: (a) Owned, occupied or used by, (b) Rented to, in the care, custody or control of, or over which physical control is being exercised for any purpose by you, any of your "employees", "volunteer workers", any partner or member (if you are a partnership or joint venture), or any member (if you are a limited liability company). b. Real Estate Manager Any person (other than your "employee" or "volunteer worker"), or any organization while acting as your real estate manager. c. Temporary Custodians Of Your Property Any person or organization having proper temporary custody of your property if you die, but only: (1) With respect to liability arising out of the maintenance or use of that property; and (2) Until your legal representative has been appointed. d. Legal Representative If You Die Your legal representative if you die, but only with respect to duties as such. That representative will have all your rights and duties under this Coverage Part. e. Unnamed Subsidiary Any subsidiary, and subsidiary thereof, of yours which is a legally incorporated entity of which you own a financial interest of more than 50% of the voting stock on the effective date of the Coverage Part. Page 11 of 21 Policy Number: 72UUQIZ6496 The insurance afforded herein for any subsidiary not named in this Coverage Part as a named insured does not apply to injury or damage with respect to which such insured is also a named insured under another policy or would be a named insured under such policy but for its termination or the exhaustion of its limits of insurance. 3. Newly Acquired Or Formed Organization Any organization you newly acquire or form, other than a partnership, joint venture or limited liability company, and over which you maintain financial interest of more than 50% of the voting stock, will qualify as a Named Insured if there is no other similar insurance available to that organization. However: a. Coverage under this provision is afforded only until the 180th day after you acquire or form the organization or the end of the policy period, whichever is earlier; b. Coverage A does not apply to "bodily injury" or "property damage" that occurred before you acquired or formed the organization; and c. Coverage B does not apply to "personal and advertising injury" arising out of an offense committed before you acquired or formed the organization. 4. Nonowned Watercraft Vs. With respect to watercraft you do not own that is less than 51 feet long and is not being used to carry persons for a charge, any person is an insured while operating such watercraft with your permission. Any other person or organization responsible for the conduct of such person is also an insured, but only with respect to liability arising out of the operation of the watercraft, and only if no other insurance of any kind is available to that person or organization for this liability. However, no person or organization is an insured with respect to: a. "Bodily injury" to a co-"employee" of the person operating the watercraft; or b. "Property damage" to property owned by, rented to, in the charge of or occupied by you or the employer of any person who is an insured under this provision. Additional Insureds When Required By Written Contract, Written Agreement Or Permit The following person(s) or organization(s) are an additional insured when you have agreed, in a written contract, written agreement or because of a permit issued by a state or political subdivision, that such person or organization be added as an additional insured on your policy, provided the injury or damage occurs subsequent to the execution of the contract or agreement. Page 12 of 21 A person or organization is an additional insured under this provision only for that period of time required by the contract or agreement. However, no such person or organization is an insured under this provision if such person or organization is included as an insured by an endorsement issued by us and made a part of this Coverage Part. a. Vendors Any person(s) or organization(s) (referred to below as vendor), but only with respect to "bodily injury" or "property damage" arising out of "your products" which are distributed or sold in the regular course of the vendor's business and only if this Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products-completed operations hazard". (1) The insurance afforded the vendor is subject to the following additional exclusions: This insurance does not apply to: (a) "Bodily injury" or "property damage" for which the vendor is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages that the vendor would have in the absence of the contract or agreement; (b) Any express warranty unauthorized by you; (c) Any physical or chemical change in the product made intentionally by the vendor; (d) Repackaging, except when unpacked solely for the purpose of inspection, demonstration, testing, or the substitution of parts under instructions from the manufacturer, and then repackaged in the original container; (e) Any failure to make such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products; (f) Demonstration, installation, servicing or repair operations, except such operations performed at the vendor's premises in connection with the sale of the product; (g) Products which, after distribution or sale by you, have been labeled or relabeled or used as a container, part or ingredient of any other thing or substance by or for the vendor; or HG 00 01 0916 Policy Number: 72UUQIZ6496 (h) "Bodily injury" or "property damage" arising out of the sole negligence of the vendor for its own acts or omissions or those of its employees or anyone else acting on its behalf. However, this exclusion does not apply to: (i) The exceptions contained in Sub- paragraphs (d) or (f); or (ii) Such inspections, adjustments, tests or servicing as the vendor has agreed to make or normally undertakes to make in the usual course of business, in connection with the distribution or sale of the products. (2) This insurance does not apply to any insured person or organization, from whom you have acquired such products, or any ingredient, part or container, entering into, accompanying or containing such products. b. Lessors Of Equipment (1) Any person(s) or organization(s) from whom you lease equipment; but only with respect to their liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your maintenance, operation or use of equipment leased to you by such person(s) or organization(s). (2) With respect to the insurance afforded to these additional insureds this insurance does not apply to any "occurrence" which takes place after the equipment lease expires. c. Lessors Of Land Or Premises Any person or organization from whom you lease land or premises, but only with respect to liability arising out of the ownership, maintenance or use of that part of the land or premises leased to you. With respect to the insurance afforded these additional insureds the following additional exclusions apply: This insurance does not apply to: 1. Any "occurrence" which takes place after you cease to lease that land; or 2. Structural alterations, new construction or demolition operations performed by or on behalf of such person or organization. d. Architects, Engineers Or Surveyors Any architect, engineer, or surveyor, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or HG 00 01 0916 omissions of those acting on your behalf: (1) In connection with your premises; or (2) In the performance of your ongoing operations performed by you or on your behalf. With respect to the insurance afforded these additional insureds, the following additional exclusion applies: This insurance does not apply to "bodily injury", "property damage" or "personal ~nd advertising injury" arising out of the rendering of or the failure to render any professional services by or for you, including: 1. The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or 2. Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional services by or for you. e. Permits Issued By State Or Political Subdivisions Any state or political subdivision, but only with respect to operations performed by you ~r. on your behalf for which the state or poht,cal subdivision has issued a permit. With respect to the insurance afforded these additional insureds, this insurance does not apply to: (1) "Bodily injury", "property damage" or "personal and advertising injury" arising out of operations performed for the state or municipality; or (2) "Bodily injury" or "property damage" included within the "products-completed operations hazard". f. Any Other Party Any other person or organization who is not an additional insured under Paragraphs a. through e. above, but only with respect to liability for "bodily injury", "property damag~" or "personal and advertising injury" caused, m whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (1) In the performance of your ongoing operations; Page 13 of 21 Policy Number: 72UUQIZ6496 (2) In connection with your premises owned by or rented to you; or (3) In connection with "your work" and included within the "products-completed operations hazard", but only if (a) The written contract or agreement requires you to provide such coverage to such additional insured; and (b) This Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products- completed operations hazard". However: (1) The insurance afforded to such additional insured only applies to the extent permitted by law; and (2) If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. With respect to the insurance afforded to these additional insureds, this insurance does not apply to: "Bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: (1) The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or (2) Supervisory, inspection, architectural or engineering activities. This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury" or "property damage", or the offense which caused the "personal and advertising injury", involved the rendering of or the failure to render any professional services by or for you. The limits of insurance that apply to additional insureds is described in Section Ill -Limits Of Insurance. How this insurance applies when other insurance is available to the additional insured is described in the Other Insurance Condition in Section IV - Commercial General Liability Conditions. Page 14 of 21 No person or organization is an insured with respect to the conduct of any current or past partnership, joint venture or limited liability company that is not shown as a Named Insured in the Declarations. SECTION Ill -LIMITS OF INSURANCE 1. The Most We Will Pay The Limits of Insurance shown in the Declarations and the rules below fix the most we will pay regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". 2. General Aggregate Limit The General Aggregate Limit is the most we will pay for the sum of: a. Medical expenses under Coverage C; b. Damages under Coverage A, except damages because of "bodily injury" or "property damage" included in the "products- completed operations hazard"; and c. Damages under Coverage B. 3. Products-Completed Operations Aggregate Limit The Products-Completed Operations Aggregate Limit is the most we will pay under Coverage A for damages because of "bodily injury" and "property damage" included in the "products- completed operations hazard". 4. Personal And Advertising Injury Limit Subject to 2. above, the Personal and Advertising Injury Limit is the most we will pay under Coverage B for the sum of all damages because of all "personal and advertising injury" sustained by any one person or organization. 5. Each Occurrence Limit Subject to 2. or 3. above, whichever applies, the Each Occurrence Limit is the most we will pay for the sum of: a. Damages under Coverage A; and b. Medical expenses under Coverage C because of all "bodily injury" and "property damage" arising out of any one "occurrence". 6. Damage To Premises Rented To You Limit Subject to 5. above, the Damage To Premises Rented To You Limit is the most we will pay under Coverage A for damages because of "property damage" to any one premises, while rented to you, or in the case of damage by fire, lightning or explosion, while rented to you or temporarily occupied by you with permission of the owner. HG 00 01 0916 Policy Number: 72UUQIZ6496 In the case of damage by fire, lightning or explosion, the Damage to Premises Rented To You Limit applies to all damage proximately caused by the same event, whether such damage results from fire, lightning or explosion or any combination of these. 7. Medical Expense Limit Subject to 5. above, the Medical Expense Limit is the most we will pay under Coverage C for all medical expenses because of "bodily injury" sustained by any one person. 8. How Limits Apply To Additional Insureds If you have agreed in a written contract or written agreement that another person or organization be added as an additional insured on your policy, the most we will pay on behalf of such additional insured is the lesser of: a. The limits of insurance specified in the written contract or written agreement; or b. The Limits of Insurance shown in the Declarations. Such amount shall be a part of and not in addition to Limits of Insurance shown in the Declarations and described in this Section. The Limits of Insurance of this Coverage Part apply separately to each consecutive annual period and to any remaining period of less than 12 months, starting with the beginning of the policy period shown in the Declarations, unless the policy period is extended after issuance for an additional period of less than 12 months. In that case, the additional period will be deemed part of the last preceding period for purposes of determining the Limits of Insurance. SECTION IV COMMERCIAL GENERAL LIABILITY CONDITIONS 1. Bankruptcy Bankruptcy or insolvency of the insured or of the insured's estate will not relieve us of our obligations under this Coverage Part. 2. Duties In The Event Of Occurrence, Offense, Claim Or Suit a. Notice Of Occurrence Or Offense You or any additional insured must see to it that we are notified as soon as practicable of an "occurrence" or an offense which may result in a claim. To the extent possible, notice should include: (1) How, when and where the "occurrence" or offense took place; (2) The names and addresses of any injured persons and witnesses; and (3) The nature and location of any injury or damage arising out of the "occurrence" or offense. HG 00 01 0916 b. Notice Of Claim If a claim is made or "suit" is brought against any insured, you or any additional insured must: (1) Immediately record the specifics of the claim or "suit" and the date received; and (2) Notify us as soon as practicable. You or any additional insured must see to it that we receive written notice of the claim or "suit" as soon as practicable. c. Assistance And Cooperation Of The Insured You and any other involved insured must: (1) Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the claim or "suit"; (2) Authorize us to obtain records and other information; (3) Cooperate with us in the investigation or settlement of the claim or defense against the "suit"; and (4) Assist us, upon our request, in the enforcement of any right against any person or organization which may be liable to the insured because of injury or damage to which this insurance may also apply. d. Obligations At The Insureds Own Cost No insured will, except at that insured's own cost, voluntarily make a payment, assume any obligation, or incur any expense, other than for first aid, without our consent. e. Additional Insureds Other Insurance If we cover a claim or "suit" under this Coverage Part that may also be covered by other insurance available to an additional insured, such additional insured must submit such claim or "suit" to the other insurer for defense and indemnity. However, this provision does not apply to the extent that you have agreed in a written contract or written agreement that this insurance is primary and non-contributory with the additional insured's own insurance. f. Knowledge Of An Occurrence, Offense, Claim Or Suit Paragraphs a. and b. apply to you or to any additional insured only when such "occurrence", offense, claim or "suit" is known to: (1) You or any additional insured that is an individual; (2) Any partner, if you or the additional insured is a partnership; Page 15 of 21 Policy Number: 72UUQIZ6496 (3) Any manager, if you or the additional insured is a limited liability company; (4) Any "executive officer" or insurance manager, if you or the additional insured is a corporation; (5) Any trustee, if you or the additional insured is a trust; or (6) Any elected or appointed official, if you or the additional insured is a political subdivision or public entity. This duty applies separately to you and any additional insured. 3. Legal Action Against Us No person or organization has a right under this Coverage Part: a. To join us as a party or otherwise bring us into a "suit" asking for damages from an insured; or b. To sue us on this Coverage Part unless all of its terms have been fully complied with. A person or organization may sue us to recover on an agreed settlement or on a final judgment against an insured; but we will not be liable for damages that are not payable under the terms of this Coverage Part or that are in excess of the applicable limit of insurance. An agreed settlement means a settlement and release of liability signed by us, the insured and the claimant or the claimant's legal representative. 4. Other Insurance If other valid and collectible insurance is available to the insured for a loss we cover under Coverages A or B of this Coverage Part, our obligations are limited as follows: a. Primary Insurance This insurance is primary except when b. below applies. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. b. Excess Insurance This insurance is excess over any of the other insurance, whether primary, excess, contingent or on any other basis: (1) Your Work That is Fire, Extended Coverage, Builder's Risk, Installation Risk or similar coverage for "your work"; (2) Premises Rented To You That is fire, lightning or explosion insurance for premises rented to you or temporarily occupied by you with permission of the owner; Page 16 of 21 (3) Tenant Liability That is insurance purchased by you to cover your liability as a tenant for "property damage" to premises rented to you or temporarily occupied by you with permission of the owner; (4) Aircraft, Auto Or Watercraft If the loss arises out of the maintenance or use of aircraft, "autos" or watercraft to the extent not subject to Exclusion g. of Section I -Coverage A -Bodily Injury And Property Damage Liability; (5) Property Damage To Borrowed Equipment Or Use Of Elevators If the loss arises out of "property damage" to borrowed equipment or the use of elevators to the extent not subject to Exclusion j. of Section I -Coverage A - Bodily Injury And Property Damage Liability; (6) When You Are Added As An Additional Insured To Other Insurance Any other insurance available to you covering liability for damages arising out of the premises or operations, or products and completed operations, for which you have been added as an additional insured by that insurance; or (7) When You Add Others As An Additional Insured To This Insurance Any other insurance available to an additional insured. However, the following provisions apply to other insurance available to any person or organization who is an additional insured under this coverage part. (a) Primary Insurance When Required By Contract This insurance is primary if you have agreed in a written contract or written agreement that this insurance be primary. If other insurance is also primary, we will share with all that other insurance by the method described in c. below. (b) Primary And Non-Contributory To Other Insurance When Required By Contract If you have agreed in a written contract, written agreement, or permit that this insurance is primary and non- contributory with the additional insured's own insurance, this insurance is primary and we will not seek contribution from that other insurance. HG 00 01 0916 Policy Number: 72UUQIZ6496 Paragraphs (a) and (b) do not apply to other insurance to which the additional insured has been added as an additional insured. When this insurance is excess, we will have no duty under Coverages A or B to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers. When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of: (1) The total amount that all such other insurance would pay for the loss in the absence of this insurance; and (2) The total of all deductible and self-insured amounts under all that other insurance. We will share the remaining loss, if any, with any other insurance that is not described in this Excess Insurance provision and was not bought specifically to apply in excess of the Limits of Insurance shown in the Declarations of this Coverage Part. c. Method Of Sharing If all of the other insurance permits contribution by equal shares, we will follow this method also. Under this approach each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. 5. Premium Audit a. We will compute all premiums for this Coverage Part in accordance with our rules and rates. b. Premium shown in this Coverage Part as advance premium is a deposit premium only. At the close of each audit period we will compute the earned premium for that period and send notice to the first Named Insured. The due date for audit and retrospective premiums is the date shown as the due date on the bill. If the sum of the advance and audit premiums paid for the policy period is greater than the earned premium, we will return the excess to the first Named Insured. c. The first Named Insured must keep records of the information we need for premium HG 00 01 0916 computation, and send us copies at such times as we may request. 6. Representations a. When You Accept This Policy By accepting this policy, you agree: (1) The statements in the Declarations are accurate and complete; (2) Those statements are based upon representations you made to us; and (3) We have issued this policy in reliance upon your representations. b. Unintentional Failure To Disclose Hazards If unintentionally you should fail to disclose all hazards relating to the conduct of your business that exist at the inception date of this Coverage Part, we shall not deny coverage under this Coverage Part because of such failure. 7. Separation Of Insureds Except with respect to the Limits of Insurance, and any rights or duties specifically assigned in this Coverage Part to the first Named Insured, this insurance applies: a. As if each Named Insured were the only Named Insured; and b. Separately to each insured against whom claim is made or "suit" is brought. 8. Transfer Of Rights Of Recovery Against Others To Us a. Transfer Of Rights Of Recovery If the insured has rights to recover all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, those rights are transferred to us. The insured must do nothing after loss to impair them. At our request, the insured will bring "suit" or transfer those rights to us and help us enforce them. b. Waiver Of Rights Of Recovery (Waiver Of Subrogation) If the insured has waived any rights of recovery against any person or organization for all or part of any payment, including Supplementary Payments, we have made under this Coverage Part, we also waive that right, provided the insured waived their rights of recovery against such person or organization in a contract, agreement or permit that was executed prior to the injury or damage. 9. When We Do Not Renew If we decide not to renew this Coverage Part, we will mail or deliver to the first Named Insured shown in the Declarations written notice of the Page 17 of 21 • THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT· CALIFORNIA / Policy Number: 72WECAC9MAS Endorsement Number: Effective Date: 4/1/2019 Effective hour is the same as stated on the Information Page of the policy. Named Insured and Address: T.W. ASSOCIATES dba MISCOwater 27101 BURBANK STE B FOOTHILL RANCH CA 92610 We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the work described in the Schedule. The additional premium for this endorsement shall be 2 % of the California workers' compensation premium otherwise due on such remuneration. SCHEDULE Person or Organization Job Description Any person or organization from whom you are required by written contract or agreement to obtain ttiis waiver of rights from us Form WC 0403 06 (1) Printed in U.S.A. Process Date: 01/29/18 Policy Expiration Date: 4/1/2020 $33(1',;$ *(1(5$/3529,6,216 APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 1 of 63 GENERAL PROVISIONS FOR NORTH BATIQUITOS LIFT STATION HYDROPNEUMATIC SURGE TANK REPLACEMENT CONTRACT NO. 3840-14 CITY OF CARLSBAD BIDDERS ARE ADVISED THAT THIS SECTION REPLACES PART 1, GENERAL PROVISIONS, OF THE STANDARD SPECIFICATIONS FOR PUBLIC WORKS CONSTRUCTION SECTION 1 -- TERMS, DEFINITIONS, ABBREVIATIONS, AND SYMBOLS 1-1 TERMS – Unless otherwise stated, the words directed, required, permitted, ordered, instructed, designated, considered necessary, prescribed, approved, acceptable, satisfactory, or words of like meaning, refer to actions, expressions, and prerogatives of the Engineer. 1-1.1 Reference to Drawings. Where words "shown”, "indicated”, "detailed”, "noted”, "scheduled”, or words of similar import are used, it shall be understood that reference is made to the plans accompanying these provisions, unless stated otherwise. 1-1.2 Directions. Where words "directed”, "designated”, "selected”, or words of similar import are used, it shall be understood that the direction, designation or selection of the Engineer is intended, unless stated otherwise. The word “required”, and words of similar import shall be understood to mean "as required to properly complete the work as required and as approved by the Engineer," unless stated otherwise. 1-1.3 Equals and Approvals. Where the words "equal”, "approved equal”, "equivalent”, and such words of similar import are used, it shall be understood such words are followed by the expression "in the opinion of the Engineer”, unless otherwise stated. Where the words "approved”, "approval”, "acceptance”, or words of similar import are used, it shall be understood that the approval, acceptance, or similar import of the Engineer is intended. 1-1.4 Perform. The word "perform" shall be understood to mean that the Contractor, at its expense, shall perform all operations, labor, tools and equipment, and further, including the furnishing and installing of materials that are indicated, specified or required to mean that the Contractor, at its expense, shall furnish and install the work, complete in place and ready to use, including furnishing of necessary labor, materials, tools, equipment, and transportation. 1-2 Definitions. The following words, or groups of words, shall be exclusively defined by the definitions assigned to them herein. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 2 of 63 Addendum – Written or graphic instrument issued prior to the opening of Bids which clarifies, corrects, or changes the bidding or Contract Documents. The term Addendum shall include bulletins and all other types of written notices issued to potential bidders prior to opening of Bids. Agency – The City of Carlsbad, California. Agreement – See Contract. Assessment Act Contract – A Contract financed by special assessments authorized under a State Act or procedural ordinance of a City or County. Base – A layer of specified material of planned thickness placed immediately below the pavement or surfacing. Bid – The offer or proposal of the Bidder submitted on the prescribed form setting forth the prices for the Work. Bidder – Any individual, firm, partnership, corporation, or combination thereof, submitting a Bid for the Work, acting directly or through a duly authorized representative. Board – The officer or body constituting the awarding authority of the Agency, which is the City Council for the City of Carlsbad or the Board of Directors of Carlsbad Municipal Water District. Bond – Bid, performance, and payment bond or other instrument of security. City Council – the City Council of the City of Carlsbad. City Manager – the City Manager of the City of Carlsbad or his/her approved representative. Cash Contract – A Contract financed by means other than special assessments. Change Order – A written order to the Contractor signed by the Agency directing an addition, deletion, or revision in the Work, or an adjustment in the Contract Price or the Contract time issued after the effective date of the Contract. A Change Order may or may not also be signed by the Contractor. Code – The terms Government Code, Labor Code, etc., refer to codes of the State of California. Construction Manager– the Project Inspector’s immediate supervisor and first level of appeal for informal dispute resolution. Contract – The written agreement between the Agency and the Contractor covering the Work. Contract Documents – Including but not limited to; the Contract, any Addendum (which pertain to the contract documents), Notice Inviting Bids, Instructions to Bidders; Bid (including documentation accompanying the Bid and any post-bid documentation submitted prior to the Notice of Award) when attached as an exhibit to the Contract, the Bonds, the General Provisions, permits from other agencies, the Technical Specifications, the Supplemental Provisions, the Plans, Standard Plans, Standard Specifications, Reference Specifications, and all Modifications issued after the execution of the Contract. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 3 of 63 Contractor – The individual, partnership, corporation, joint venture, or other legal entity having a Contract with the Agency to perform the Work. In the case of work being done under permit issued by the Agency, the permittee shall be constructed to be the Contractor. The term “prime contractor” shall mean Contractor. Contract Price – The total amount of money for which the Contract is awarded. Contract Unit Price – The amount stated in the Bid for a single unit of an item of work. County Sealer – The Sealer of Weights and Measures of the county in which the Contract is let. Days – Days shall mean consecutive calendar’s days unless otherwise specified. Deputy City Engineer, Construction Management & Inspection – The Construction Manager’s immediate supervisor and second level of appeal for informal dispute resolution. Dispute Board – Persons designated by the City Manager of the City of Carlsbad or Executive Manager of the Carlsbad Municipal Water District, to hear and advise the City Manager on claims submitted by the Contractor. The City Manager for the City of Carlsbad or the Executive Manager for the Carlsbad Municipal Water District is the last appeal level for informal dispute resolution. Electrolier – Street light assembly complete, including foundation, standard, luminaire arm, luminaire, etc. Engineer – The City Engineer of the City of Carlsbad or his/her approved representative. The Engineer is the third level of appeal for informal dispute resolution. Geotextile – Synthetic fiber used in civil engineering applications, serving the primary functions of separation and filtration. House Connection Sewer – A sewer, within a public street or right-of-way, proposed to connect any parcel, lot, or part of a lot with a mainline sewer. House Sewer – A sewer, wholly within private property, proposed to connect any building to a house connection sewer. Luminaire – The lamp housing including the optical and socket assemblies (and ballast if so specified). Luminaire Arm – The structural member, bracket, or mast arm, which, mounted on the standard, supports the luminaire. Minor Bid Item – A single contract item constituting less than 10 percent (10%) of the original Contract Price bid. Modification – Includes Change Orders and Supplemental Agreements. A Modification may only be used after the effective date of the Contract. Notice of Award – The written notice by the Agency to the successful Bidder stating that upon compliance by it with the required conditions, the Agency will execute the Contract. Notice to Proceed – A written notice given by the Agency to the Contractor fixing the date on which the Contract time will start. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 4 of 63 Own Organization - When used in Section 2-3.1 – Employees of the Contractor who are hired, directed, supervised and paid by the Contractor to accomplish the completion of the Work. Further, such employees have their employment taxes, State disability insurance payments, State and Federal income taxes paid and administered, as applicable, by the Contractor. When used in Section 2-3.1 ”own organization” means construction equipment that the Contractor owns or leases and uses to accomplish the Work. Equipment that is owner operated or leased equipment with an operator is not part of the Contractor's Own Organization and will not be included for the purpose of compliance with Section 2-3.1. Person – Any individual, firm, association, partnership, corporation, trust, joint venture, or other legal entity. Plans – The drawings, profiles, cross sections, working drawings, and supplemental drawings, or reproductions thereof, approved by the Engineer, which show the location, character, dimensions, or details of the Work. Private Contract – Work subject to Agency inspection, control, and approval, involving private funds, not administered by the Agency. Project Inspector – The Engineer’s designated representative for inspection, contract administration and first level for informal dispute resolution. Proposal – See Bid. Reference Specifications – Those bulletins, standards, rules, methods of analysis or test, codes, and specifications of other agencies, engineering societies, or industrial associations referred to in the Contract Documents. These refer to the latest edition, including amendments in effect and published at the time of advertising the project or issuing the permit, unless specifically referred to by edition, volume, or date. Roadway – The portion of a street reserved for vehicular use. Service Connection – Service connections are all or any portion of the conduit, cable, or duct, including meter, between a utility distribution line and an individual consumer. Sewer – Any conduit intended for the reception and transfer of sewage and fluid industrial waste. Specifications – General Provisions, Standard Specifications, Technical Specifications, Reference Specifications, Supplemental Provisions, and specifications in Supplemental Agreements between the Contractor and the Board. Standard – The shaft or pole used to support street lighting luminaire, traffic signal heads, mast arms, etc. Standard Plans – Details of standard structures, devices, or instructions referred to on the Plans or in Specifications by title or number. Standard Specifications – The Standard Specifications for Public Works Construction (SSPWC), the “Greenbook”. State – State of California. Storm Drain – Any conduit and appurtenances intended for the reception and transfer of storm water. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 5 of 63 Street – Any road, highway, parkway, freeway, alley, walk, or way. Subbase – A layer of specified material of planned thickness between a base and the subgrade. Subcontractor – An individual, firm, or corporation having a direct contract with the Contractor or with any other Subcontractor for the performance of a part of the Work. Subgrade – For roadways, that portion of the roadbed on which pavement, surfacing, base, subbase, or a layer of other material is placed. For structures, the soil prepared to support a structure. Supervision – Supervision, where used to indicate supervision by the Engineer, shall mean the performance of obligations, and the exercise of rights, specifically imposed upon and granted to the Agency in becoming a party to the Contract. Except as specifically stated herein, supervision by the Agency shall not mean active and direct superintendence of details of the Work. Supplemental Agreement – A written amendment of the Contract Documents signed by both parties. Supplemental Provisions – Additions and revisions to the Standard Specifications setting forth conditions and requirements peculiar to the work. Surety – Any individual, firm, or corporation, bound with and for the Contractor for the acceptable performance, execution, and completion of the Work, and for the satisfaction of all obligations incurred. Tonne – Also referred to as “metric ton”. Represents a unit of measure in the International System of Units equal to 1,000 kilograms. Utility – Tracks, overhead or underground wires, pipeline, conduits, ducts, or structures, sewers, or storm drains owned, operated, or maintained in or across a public right of way or private easement. Work – That which is proposed to be constructed or done under the Contract or permit, including the furnishing of all labor, materials, equipment, and services. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 6 of 63 1-3 ABBREVIATIONS 1-3.1 General. The abbreviation herein, together with others in general use, are applicable to these Standard Specifications and to project Plans or other Contract Documents. All abbreviations and symbols used on Plans for structural steel construction shall conform to those given by the “Manual of Steel Construction” published by the American Institute of Steel Construction, Inc. 1-3.2 Common Usage Abbreviation Word or Words ABAN .............................................................Abandon ABAND .......................................................Abandoned ABS ........................ Acrylonitrile – butadiene – styrene AC .................................................... Asphalt Concrete ACP ........................................... Asbestos cement pipe ACWS ..................... Asphalt concrete wearing surface ALT ................................................................Alternate APTS ................................. Apartment and Apartments AMER STD ................................... American Standard AWG ............... American Wire Gage (nonferrous wire) BC .................................................. Beginning of curve BCR ....................................... Beginning of curb return BDRY ............................................................Boundary BF ..................................................... Bottom of footing BLDG ........................................ Building and Buildings BM ............................................................. Bench mark BVC .................................... Beginning of vertical curve B/W ........................................................... Back of wall C/C ..................................................... Center to center CAB ...................................... Crushed aggregate base CAL/OSHA ............ California Occupational Safety and Health Administration CalTrans ....... California Department of Transportation CAP .................................... Corrugated aluminum pipe CB ............................................................. Catch Basin Cb ........................................................................ Curb CBP ............................... Catch Basin Connection Pipe CBR ....................................... California Bearing Ratio CCR ............................ California Code of Regulations CCTV ............................................... Closed Circuit TV CES .......................... Carlsbad Engineering Standards CF ................................................................ Curb face CF ................................................................ Cubic foot C&G .................................................... Curb and gutter CFR ................................ Code of Federal Regulations CFS ......................................... Cubic Feet per Second CIP ......................................................... Cast iron pipe CIPP ................................................ Cast-in place pipe CL ............................................. Clearance, center line CLF .................................................... Chain link fence CMB ............................... Crushed miscellaneous base CMC ......................................... Cement mortar-coated CML ............................................ Cement mortar-lined CMWD .................... Carlsbad Municipal Water District CO .................................................... Cleanout (Sewer) COL ..................................................................Column COMM ....................................................... Commercial CONC ........................................................... Concrete CONN ........................................................ Connection CONST .................................. Construct, Construction COORD ...................................................... Coordinate CSP ............................................ Corrugated steel pipe CSD ............................... Carlsbad Standard Drawings CTB ............................................ Cement treated base CV ............................................................ Check valve CY ............................................................... Cubic yard D .............................................................. Load of pipe dB ................................................................... Decibels DBL .................................................................. Double DF ............................................................... Douglas fir DIA ................................................................ Diameter DIP ..................................................... Ductile iron pipe DL ................................................................Dead load DR ...................................................... Dimension Ratio DT .................................................................Drain Tile DWG ............................................................... Drawing DWY .............................................................. Driveway DWY APPR ................................... Driveway approach E ....................................................................... Electric EA ........................................................................ Each EC ............................................................ End of curve ECR ................................................ End of curb return EF ................................................................ Each face EG ......................................................... Edge of gutter EGL .................................................. Energy grade line EI ................................................................... Elevation ELC ..................................... Electrolier lighting conduit ELT ........................................................ Extra-long ton ENGR ....................................... Engineer, Engineering EP ................................................... Edge of pavement ESMT ........................................................... Easement ETB .......................................... Emulsion-treated base EVC ............................................... End of vertical curb EWA ............................... Encina Wastewater Authority EXC ............................................................ Excavation EXP JT ................................................. Expansion joint EXST ............................................................... Existing F .................................................................. Fahrenheit F&C ................................................... Frame and cover F&I .................................................. Furnish and install FAB ............................................................... Fabricate FAS ............................................... Flashing arrow sign FD ............................................................... Floor drain FDN ............................................................ Foundation APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 7 of 63 FED SPEC ................................. Federal Specification FG ........................................................ Finished grade FH ............................................................. Fire hydrant FL ................................................................... Flow line FS ...................................................... Finished surface FT-LB .........................................................Foot-pound FTG .................................................................. Footing FW ............................................................ Face of wall G ........................................................................... Gas GA ..................................................................... Gauge GAL ............................................... Gallon and Gallons GALV ......................................................... Galvanized GAR ........................................... Garage and Garages GIP .............................................. Galvanized iron pipe GL ........................................ Ground line or grade line GM .............................................................. Gas meter GNV ............................................... Ground Not Visible GP ..................................................................Guy pole GPM ................................................ gallons per minute GR ...................................................................... Grade GRTG ............................................................... Grating GSP ........................................... Galvanized steel pipe H ............................................................ High or height HB .................................................................. Hose bib HC ................................................... House connection HDWL ........................................................... Headwall HGL .............................................. Hydraulic grade line HORIZ .......................................................... Horizontal HP ............................................................. Horsepower HPG ................................................ High pressure gas HPS ................................ High pressure sodium (Light) HYDR ............................................................ Hydraulic IE ......................................................... Invert Elevation ID ........................................................ Inside diameter INCL ...............................................................Including INSP .............................................................Inspection INV ...................................................................... Invert IP .................................................................... Iron pipe JC ..................................................... Junction chamber JCT .................................................................Junction JS ..................................................... Junction structure JT ......................................................................... Joint L ........................................................................ Length LAB ............................................................. Laboratory LAT ................................................................... Lateral LB ...................................................................... Pound LD ..................................................... Local depression LF ................................................................ Linear foot LH ............................................................... Lamp hole LL ...................................................................Live load LOL .............................................................Layout line LONG ........................................................Longitudinal LP ................................................................ Lamp post LPS ................................. Low pressure sodium (Light) LS ................................................................ Lump sum LTS .................................................... Lime treated soil LWD ............................... Leucadia Wastewater District MAINT ..................................................... Maintenance MAX ............................................................. Maximum MCR ............................................ Middle of curb return MEAS ............................................................. Measure MH ................................... Manhole, maintenance hole MIL SPEC .................................... Military specification MISC ..................................................... Miscellaneous MOD ................................................... Modified, modify MON ............................................................ Monument MSL .. Mean Sea Level (Reg. Standard Drawing M-12) MTBM ......................... Microtunneling Boring Machine MULT ...............................................................Multiple MUTCD .....Manual on Uniform Traffic Control Devices MVL ............................................... Mercury vapor light NCTD .............................. North County Transit District NRCP .............................. Nonreinforced concrete pipe OBS ...............................................................Obsolete OC ................................................................ On center OD ..................................................... Outside diameter OE .............................................................. Outer edge OHE ................................................ Overhead Electric OMWD ................. Olivenhain Municipal Water District OPP ...............................................................Opposite ORIG ................................................................Original PB ................................................................... Pull box PC .................................................... Point of curvature PCC ....................... Portland cement concrete or point of compound curvature PCVC ....................... Point of compound vertical curve PE ........................................................... Polyethylene PI .................................................. Point of intersection PL ............................................................. Property line PMB ............................ Processed miscellaneous base POC ...................................................... Point on curve POT .................................................... Point on tangent PP .............................................................. Power pole PRC .......................................... Point of reverse curve PRVC ............................ Point of reverse vertical curve PSI ......................................... Pounds per square inch PT .................................................... Point of tangency PVC .................................................. Polyvinyl chloride PVMT ........................................................... Pavement PVT R/W ....................................... Private right-of-way Q ........................ Rate of flow in cubic feet per second QUAD ....................................... Quadrangle, Quadrant R ....................................................................... Radius R&O ......................................................... Rock and oil R/W .......................................................... Right-of-way RA ...................................................... Recycling agent RAC ................................... Recycled asphalt concrete RAP ................................ Reclaimed asphalt pavement RBAC ............................. Rubberized asphalt concrete RC ................................................ Reinforced concrete RCB ...................................... Reinforced concrete box RCE ...................................... Registered civil engineer RCP ..................................... Reinforced concrete pipe RCV ........................................... Remote control valve REF ............................................................. Reference REINF ..............................Reinforced or reinforcement RES ...............................................................Reservoir RGE ........................ Registered geotechnical engineer ROW ....................................................... Right-of-Way RR ...................................................................Railroad RSE .............................. Registered structural engineer RTE .................................... Registered traffic engineer S .................................... Sewer or Slope, as applicable SCCP ............................... Steel cylinder concrete pipe SD ............................................................. Storm drain SDNR .............................. San Diego Northern Railway SDR ....... Standard thermoplastic pipe dimension ratio (ratio of pipe O.D. to minimum wall thickness) SDRSD ......... San Diego Regional Standard Drawings APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 8 of 63 SE ...................................................... Sand Equivalent SEC .................................................................. Section SF ............................................................. Square foot SFM ................................................ Sewer Force Main SI ....................... International System of Units (Metric) SPEC ..................................................... Specifications SPPWC .......................................... Standard Plans for Public Works Construction SSPWC ............................. Standard Specifications for Public Works Construction ST HWY ................................................ State highway STA ................................................................... Station STD ............................................................... Standard STR ..................................................................Straight STR GR ................................................ Straight grade STRUC .......................................... Structural/Structure SW .................................................................Sidewalk SWD ...................................................... Sidewalk drain SY ............................................................ Square yard T .................................................................. Telephone TAN ................................................................. Tangent TC .............................................................. Top of curb TEL ............................................................. Telephone TF ........................................................... Top of footing TOPO ........................................................ Topography TR ........................................................................ Tract TRANS ......................................................... Transition TS ......................... Traffic signal or transition structure TSC ............................................. Traffic signal conduit TSS ........................................... Traffic signal standard TW ..............................................................Top of wall TYP .................................................................. Typical UE .............................................. Underground Electric USA .................................... Underground Service Alert VAR ..................................................... Varies, Variable VB ................................................................ Valve box VC .......................................................... Vertical curve VCP ................................................... Vitrified clay pipe VERT ............................................................... Vertical VOL .................................................................. Volume VWD ....................................... Vallecitos Water District W ........................ Water, Wider or Width, as applicable WATCH .............. Work Area Traffic Control Handbook WI ............................................................ Wrought iron WM ........................................................... Water meter WPJ .......................................... Weakened plane joint XCONN ............................................ Cross connection XSEC ..................................................... Cross section APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 9 of 63 1-3.3 Institutions. Abbreviation Word or Words AASHTO ................. American Association of State Highway and Transportation Officials AISC ....................................................................American Institute of Steel Construction ANSI ...................................................................... American National Standards Institute API ...................................................................................... American Petroleum Institute AREA ............................................................ American Railway Engineering Association ASTM ............................................................ American Society for Testing and Materials AWPA................................................................. American Wood Preservers Association AWS ........................................................................................ American Welding Society AWWA ....................................................................... American Water Works Association FHWA.............................................................................. Federal Highway Administration GRI ................................................................................. Geosynthetic Research Institute NEMA ......................................................... National Electrical Manufacturers Association NOAA ................ National Oceanic and Atmospheric Administration (Dept. of Commerce) UL .................................................................................... Underwriters’ Laboratories Inc. USGS ............................................................................. United States Geological Survey APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 10 of 63 1-4 UNITS OF MEASURE. 1-4.1 General. U.S. Standard Measures, also called U.S. Customary System, are the principal measurement system in these specifications. However, certain material specifications and test requirements contained herein use SI units specifically and conversions to U.S. Standard Measures may or may not have been included in these circumstances. When U.S. Standard Measures are not included in parenthesis, then the SI units shall control. S.I. units and U.S. Standard Measures in parenthesis may or may not be exactly equivalent. Reference is also made to ASTM E 380 for definitions of various units of the SI system and a more extensive set of conversion factors. 1-4.2 Units of Measure and Their Abbreviations. U.S. Customary Unit (Equal To) SI Unit (Abbreviations) (Abbreviations) 1 mil (=0.001 in) ....................................................................................25.4 micrometer (µm) 1 inch (in) ..............................................................................................25.4 millimeter (mm) 1 inch (in) ..............................................................................................2.54 centimeter (cm) 1 foot (ft) ................................................................................................0.3048 meter (m) 1 yard (yd) .............................................................................................0.9144 meter (m) 1 mile (mi) .............................................................................................1.6093 kilometer (km) 1 square foot (ft2) ..................................................................................0.0929 square meter (m2) 1 square yard (yd2) ................................................................................0.8361 square meter (m2) 1 cubic foot (ft3) .....................................................................................0.0283 cubic meter (m3) 1 cubic yard (yd3) ..................................................................................0.7646 cubic meter (m3) 1 acre ....................................................................................................0.4047 hectare (ha) 1 U.S. gallon (gal) .................................................................................3.7854 Liter (L) 1 fluid ounce (fl. oz.) ..............................................................................29.5735 millileter (mL) 1 pound mass (lb) (avoirdupois) ...........................................................0.4536 kilogram (kg) 1 ounce mass (oz) .................................................................................0.02835 kilogram (kg) 1 Ton (=2000 lb avoirdupois) ................................................................0.9072 Tonne (= 907 kg) 1 Poise ..................................................................................................0.1 pascal . second (Pa . s) 1 centistoke (cs) ....................................................................................1 square millimeters per second (mm2/s) 1 pound force (lbf) .................................................................................4.4482 Newton (N) 1 pounds per square inch (psi) .............................................................6.8948 Kilopascal (kPa) 1 pound force per foot (lbf/ft) .................................................................1.4594 Newton per meter (N/m) 1 foot-pound force (ft-lbf).......................................................................1.3558 Joules (J) 1 foot-pound force per second ([ft-lbf]/s) ...............................................1.3558 Watt (W) 1 part per million (ppm) .........................................................................1 milligram/liter (mg/L) Temperature Units and Abbreviations Degree Fahrenheit (°F): ........................................................................Degree Celsius (°C): °F = (1.8 x °C) + 32 ...............................................................................°C = (°F – 32)/1.8 SI Units (abbreviation) Commonly Used in Both Systems 1 Ampere (A) 1 Volt (V) 1 Candela (cd) 1 Lumen (lm) 1 second (s) APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 11 of 63 Common Metric Prefixes kilo (k) ....................................................................................................103 centi (c)..................................................................................................10-2 milli (m) ..................................................................................................10-3 micro (µ) ................................................................................................10-6 nano (n) .................................................................................................10-9 pico (p) ..................................................................................................10-12 1-5 SYMBOLS ∆ Delta, the central angle or angle between tangents ∠ Angle % Percent ‘ Feet or minutes “ Inches or seconds 1 Number / per or (between words) ° Degree PL Property line CL Centerline SL Survey line or station line APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 12 of 63 SECTION 2 – SCOPE AND CONTROL OF WORK 2-1 AWARD AND EXECUTION OF CONTRACT. Award and execution of Contract will be as provided for in the Specifications, Instruction to Bidders, or Notice Inviting Bids. 2-2 ASSIGNMENT. No Contract or portion thereof may be assigned without consent of the Board, except that the Contractor may assign money due or which will accrue to it under the Contract. If given written notice, such assignment will be recognized by the Board to the extent permitted by law. Any assignment of money shall be subject to all proper withholdings in favor of the Agency and to all deductions provided for in the Contract. All money withheld, whether assigned or not, shall be subject to being used by the Agency for completion of the Work, should the Contractor be in default. 2-3 SUBCONTRACTS. 2-3.1 General. Each Bidder shall comply with the Chapter of the Public Contract Code including Sections 4100 through 4113. The following excerpts or summaries of some of the requirements of this Chapter are included below for information: The Bidder shall set forth in the Bid, as provided in 4104: “(a) The name and location of the place of business of each subcontractor who will perform work or labor or render service to the prime contractor in or about the construction of the work or improvements, or a subcontractor licensed by the State of California who, under subcontract to the prime contractor, specially fabricates and installs a portion of the work or improvement according to detailed drawings contained in the plans and specifications, in an amount in excess of one-half of 1 percent of the prime contractor’s total bid, or, in the case of bids or offers for the construction of streets or highways, including bridges, in excess of one-half of 1 percent of the prime contractor’s total bid or ten thousand dollars ($10,000), whichever is greater.” “(b) The portion of the work which will be done by each such subcontractor under this act. The prime contractor shall list only one subcontractor for each such portion as is defined by the prime contractor in his bid.” If the Contractor fails to specify a Subcontractor, or specifies more than one Subcontractor for the same portion of the work to be performed under the Contract (in excess of one-half of 1 percent of the Contractor’s total Bid), the Contractor shall be qualified to perform that portion itself, and shall perform that portion itself, except as otherwise provided in the Code. As provided in Section 4107, no Contractor whose Bid is accepted shall substitute any person as Subcontractor in place of the Subcontractor listed in the original Bid, except for causes and by procedures established in Section 4107.5. This section provides procedures to correct a clerical error in the listing of a Subcontractor. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 13 of 63 Section 4110 provides that a Contractor violating any of the provisions of the Chapter violates the Contract and the Board may exercise the option either to cancel the Contract or assess the Contractor a penalty in an amount of not more than 10 percent of the subcontract involved, after a public hearing. Should the Contractor fail to adhere to the provisions requiring the Contractor to complete 50 percent of the contract price with its own organization, the Agency may at its sole discretion elect to cancel the contract or deduct an amount equal to 10 percent of the value of the work performed in excess of 50 percent of the contract price by other than the Contractor’s own organization. The Board shall be the sole body for determination of a violation of these provisions. In any proceedings under this section, the prime contractor shall be entitled to a public hearing before the Board and shall be notified ten (10) days in advance of the time and location of said hearing. The determination of the City Council shall be final. 2-3.2 Additional Responsibility. The Contractor shall give personal attention to the fulfillment of the Contract and shall keep the Work under its control. The Contractor shall perform, with its own organization, Contract work amounting to at least 50 percent of the Contract Price except that any designated “Specialty Items” may be performed by subcontract, and the amount of any such “Specialty Items” so performed may be deducted from the Contract Price before computing the amount required to be performed by the Contractor with its own organization. “Specialty Items” will be identified by the Agency in the Bid or Proposal. Where an entire item is subcontracted, the value of work subcontracted will be based on the Contract Unit Price. When a portion of an item is subcontracted, the value of work subcontracted will be based on the estimated percentage of the Contract Unit Price. This will be determined from information submitted by the Contractor, and subject to approval by the Engineer. Before the work of any Subcontractor is started, the Contractor shall submit to the Engineer for approval a written statement showing the work to be subcontracted giving the name and business of each Subcontractor and description and value of each portion of the work to be so subcontracted. 2-3.3 Status of Subcontractors. Subcontractors shall be considered employees of the Contractor, and the Contractor shall be responsible for their work. 2-4 CONTRACT BONDS. Before execution of the Contract, the Bidder shall file surety bonds with the Agency to be approved by the Board in the amounts and for the purposes noted below. Bonds issued by a surety, who is authorized to issue bonds in California, and whose bonding limitation shown in said circular is sufficient to provide bonds in the amount required by the Contract shall be deemed to be approved unless specifically rejected by the Agency. Bonds from all other sureties shall be accompanied by all of the documents enumerated in Code of Civil Procedure 995.660 (a). The Bidder shall pay all bond premiums, costs, and incidentals. Each bond shall incorporate, by reference, the Contract and be signed by both the Bidder and Surety and the signature of the authorized agent of the Surety shall be notarized. The Contractor shall provide a faithful performance/warranty bond and payment bond (labor and materials bond) for this contract. The faithful performance/warranty bond shall be in a sum not less than one hundred percent of the total amount payable by the terms of this contract. The Contractor shall provide bonds to secure payment of laborers and materials suppliers in a sum not less than one hundred percent of the total amount payable by the terms of this contract. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 14 of 63 Both bonds shall extend in full force and effect and be retained by the Agency during this project until they are released according to the provisions of this section. The faithful performance/warranty bond will be reduced to 25 percent of the original amount 30 days after recordation of the Notice of Completion and will remain in full force and effect for the one year warranty period and until all warranty repairs are completed to the satisfaction of the Engineer. The bonds to secure payment of laborers and materials suppliers shall be released six months plus 30 days after recordation of the Notice of Completion if all claims have been paid. All bonds are to be placed with a surety insurance carrier admitted and authorized to transact the business of insurance in California and whose assets exceed their liabilities in an amount equal to or in excess of the amount of the bond. The bonds are to contain the following documents: 1) An original, or a certified copy, of the un-revoked appointment, power of attorney, by laws, or other instrument entitling or authorizing the person who executed the bond to do so. 2) A certified copy of the certificate of authority of the insurer issued by the insurance commissioner. If the bid is accepted, the Agency may require a financial statement of the assets and liabilities of the insurer at the end of the quarter calendar year prior to 30 days next preceding the date of the execution of the bond. The financial statement shall be made by an officer's certificate as defined in Section 173 of the Corporations Code. In the case of a foreign insurer, the financial statement may be verified by the oath of the principal officer or manager residing within the United States. Should any bond become insufficient, the Contractor shall renew the bond within 10 days after receiving notice from the Agency. Should any Surety at any time be unsatisfactory to the Board, notice will be given the Contractor to that effect. No further payments shall be deemed due or will be made under the contract until a new Surety shall qualify and be accepted by the Board. Changes in the Work or extensions of time, made pursuant to the Contract, shall in no way release the Contractor or Surety from its obligations. Notice of such changes or extensions shall be waived by the Surety. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 15 of 63 2-5 PLANS AND SPECIFICATIONS. 2-5.1 General. The Contractor shall keep at the Work site a copy of the Plans and Specifications, to which the Engineer shall have access at all times. The specifications for the work include the General Provisions, project technical specifications, Carlsbad Engineering Standards (CES), Standard Specifications for Public Works Construction, (SSPWC), Part 2 & 3, and the latest supplements thereto, current edition at the time of bid opening as published by the "Greenbook" Committee of Public Works Standards, Inc., hereinafter designated "SSPWC", as amended. The construction plans consist of annotations on the record drawing sheets, Exhibit A and Exhibit B of the contract documents. The standard drawings used for this project are the latest edition of the San Diego Area Regional Standard Drawings, hereinafter designated SDRSD, as issued by the San Diego County Department of Public Works, together with the most recent editions of the City of Carlsbad Engineering Standards and Carlsbad Standard Drawings, as issued by the City of Carlsbad and the Carlsbad Municipal Water District, hereinafter designated as CES and CSD, respectively. Copies of some of the pertinent standard drawings are enclosed as an appendix to these General Provisions. The Plans, Specifications, and other Contract Documents shall govern the Work. The Contract Documents are intended to be complementary and cooperative. Anything specified in the Specifications and not shown on the Plans, or shown on the Plans and not specified in the Specifications, shall be as though shown on or specified in both. The Plans shall be supplemented by such working drawings and shop drawings as are necessary to adequately control the Work. The Contractor shall ascertain the existence of any conditions affecting the cost of the Work through a reasonable examination of the Work site prior to submitting the Bid. Existing improvements visible at the Work site, for which no specific disposition is made on the Plans, but which interfere with the completion of the Work, shall be removed and disposed of by the Contractor. The Contractor shall, upon discovering any error or omission in the Plans or Specifications, immediately call it to the attention of the Engineer. 2-5.2 Precedence of Contract Documents. If there is a conflict between Contract Documents, the document highest in precedence shall control. The precedence shall be the most recent edition of the following documents listed in order of highest to lowest precedence: 1) Permits from other agencies as may be required by law. 2) Change orders, whichever occurs last. 3) Contract addenda, whichever occurs last. 4) Contract 5) Carlsbad General Provisions, Technical Specifications, and Supplemental Provisions. 6) Plans. 7) Standards plans. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 16 of 63 a) City of Carlsbad Standard Drawings. b) Carlsbad Municipal Water District Standard Drawings. c) City of Carlsbad modifications to the San Diego Area Regional Standard Drawings. d) San Diego Area Regional Standard Drawings. e) Traffic Signal Design Guidelines and Standards. f) State of California Department of Transportation Standard Plans. g) State of California Department of Transportation Standard Specifications. h) California Manual on Uniform Traffic Control Devices (CA MUTCD). 8) Standard Specifications for Public Works Construction, as amended. 9) Reference Specifications. 10) Manufacturer’s Installation Recommendations Detail drawings shall take precedence over general drawings. Change Orders, Supplemental Agreements and approved revisions to Plans and Specifications will take precedence over items 2) through 9) above. Detailed plans and plan views shall have precedence over general plans. 2-5.3 Submittals. 2-5.3.1 General. Submittals shall be provided, at the Contractor’s expense, as required in 2-5.3.2, 2-5.3.3 and 2-5.3.4, when required by the Plans or Special Provisions, or when requested by the Engineer. Materials shall neither be furnished nor fabricated, nor shall any work for which submittals are required by performed, before the required submittals have been reviewed and accepted by the Engineer. Neither review nor acceptance of submittals by the Engineer shall relieve the Contractor from responsibility for errors, omissions, or deviations from the Contract Documents, unless such deviations were specifically called to the attention of the Engineer in the letter of transmittal. The Contractor shall be responsible for the correctness of the submittals. The Contractor shall allow a minimum of 20 working days for review of submittals unless otherwise specified in the Special Provisions. Each submittal shall be accompanied by a letter of transmittal. Each submittal shall be consecutively numbered. Resubmittals shall be labeled with the number of the original submittal followed by an ascending alphabetical designation (e.g. The label ‘4-C’ would indicate the third instance that the fourth submittal had been given to the Engineer). Each sheet of each submittal shall be consecutively numbered. Each set of shop drawings and submittals shall be accompanied by a letter of transmittal on the Contractor’s letterhead. The Letter of Transmittal shall contain the following: 1) Project title and Agency contract number. 2) Number of complete sets. 3) Contractor’s certification statement. 4) Specification section number(s) pertaining to material submitted for review. 5) Submittal number (Submittal numbers shall be consecutive including subsequent submittals for the same materials.) 6) Description of the contents of the submittal. 7) Identification of deviations from the contract documents. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 17 of 63 When submitted for the Engineer's review, Shop Drawings shall bear the Contractor's certification that the Contractor has reviewed, checked, and approved the Shop Drawings and that they are in conformance with the requirements of the Contract Documents. The Contractor shall subscribe to and shall place the following certification on all submittals: "I hereby certify that the (equipment, material) shown and marked in this submittal is that proposed to be incorporated into this Project, is in compliance with the Contract Documents, can be installed in the allocated spaces, and is submitted for approval.” By: Title: ______________________________ Date: __________________________ Company Name: ______________________________________________________________ 2-5.3.2 Working Drawings. Working drawings are drawings showing details not shown on the Plans which are required to be designed by the Contractor. Working drawings shall be of a size and scale to clearly show all necessary details. Six copies and one reproducible shall be submitted. If no revisions are required, three of the copies will be returned to the Contractor. If revisions are required, the Engineer will return one copy along with the reproducible for resubmission. Upon acceptance, the Engineer will return two of the copies to the Contractor and retain the remaining copies and the reproducible. Working drawings are required in the following sections: TABLE 2-5.3.2 (A) Item Section Number Title Subject 1 7-10.4.1 Safety Orders Trench Shoring 2 207-2.5 Joints Reinforced Concrete Pipe 3 207-8.4 Joints Vitrified Clay Pipe 4 207-10.2.1 General Fabricated Steel Pipe 5 300-3.2 Cofferdams Structure Excavation & Backfill 6 303-1.6.1 General Falsework 7 303-1.7.1 General Placing Reinforcement 8 303-3.1 General Prestressed Concrete Construction 9 304-1.1.1 Shop Drawings Structural Steel 10 304-1.1.2 Falsework Plans Structural Steel 11 304-2.1 General Metal Hand Railings 12 306-2.1 General Jacking Operations 13 306-3.1 General Tunneling Operations 14 306-3.4 Tunnel Supports Tunneling Operations 15 306-6 Remodeling Existing Sewer Facilities Polyethylene Liner Installation 16 306-8 Microtunneling Microtunneling Operations 17 307-4.3 Controller Cabinet Wiring Diagrams Traffic Signal Construction Working drawings listed above as Items 5, 6, 8, 9, 10, 12, 13, 14 and 16 shall be prepared by a Civil or Structural Engineer registered by the State of California. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 18 of 63 2-5.3.3 Shop Drawings. Shop drawings are drawings showing details of manufactured or assembled products proposed to be incorporated into the Work. Shop drawings required shall be as specified in the Special Provisions. 2-5.3.4 Supporting Information. Supporting information is information required by the Specifications for the purposes of administration of the Contract, analysis for verification of conformance with the Specifications, the operation and maintenance of a manufactured product or system to be constructed as part of the Work, and other information as may be required by the Engineer. Six copies of the supporting information shall be submitted to the Engineer prior to the start of the Work unless otherwise specified in the Special Provisions or directed by the Engineer. Supporting information for systems shall be bound together and include all manufactured items for the system. If resubmittal is not required, three copies will be returned to the Contractor. Supporting information shall consist of the following and is required unless otherwise specified in the Special Provisions: 1) List of Subcontractors per 2-3.2. 2) List of Materials per 4-1.4. 3) Certifications per 4-1.5. 4) Construction Schedule per 6-1. 5) Confined Space Entry Program per 7-10.4.4. 6) Concrete mix designs per 201-1.1. 7) Asphalt concrete mix designs per 203-6.1. 8) Data, including, but not limited to, catalog sheets, manufacturer’s brochures, technical bulletins, specifications, diagrams, product samples, and other information necessary to describe a system, product or item. This information is required for irrigation systems, street lighting systems, and traffic signals, and may also be required for any product, manufactured item, or system. 2-5.4 RECORD DRAWINGS. The Contractor shall provide and keep up-to-date a complete "as-built" record set of blue-line prints, which shall be corrected in red daily and show every change from the original drawings and specifications and the exact "as-built" locations, sizes and kinds of equipment, underground piping, valves, and all other work not visible at surface grade. Prints for this purpose may be obtained from the Agency at cost. This set of drawings shall be kept on the job and shall be used only as a record set and shall be delivered to the Engineer within ten (10) days of completion of the work. Payment for performing the work required by Section 2-5.4 shall be included in the various bid items and no additional payment will be made therefore. 2-6 WORK TO BE DONE. The Contractor shall perform all work necessary to complete the Contract in a satisfactory manner. Unless otherwise provided, the Contractor shall furnish all materials, equipment, tools, labor, and incidentals necessary to complete the Work. 2-7 SUBSURFACE DATA. All soil and test hole data, water table elevations, and soil analyses shown on the drawings or included in the Specifications apply only at the location of the test holes and to the depths indicated. Soil test reports for test holes which have been drilled are available for inspection at the office of the Engineer. Any additional subsurface exploration shall be done by Bidders or the Contractor at their own expense. The indicated elevation of the water table is that which existed on the date when test hole data was determined. It is the Contractor’s responsibility to determine and allow for the elevation of groundwater at the date of project construction. A difference in elevation between groundwater shown in soil boring logs and groundwater actually encountered during construction will not be considered as a basis for extra work. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 19 of 63 2-8 RIGHT-OF-WAY. Rights-of-way, easements, or rights-of-entry for the Work will be provided by the Agency. Unless otherwise provided, the Contractor shall make arrangements, pay for, and assume all responsibility for acquiring, using, and disposing of additional work areas and facilities temporarily required. The Contractor shall indemnify and hold the Agency harmless from all claims for damages caused by such actions. 2-9 SURVEYING. (NOT USED) 2-10 AUTHORITY OF BOARD AND ENGINEER. The Board has the final authority in all matters affecting the Work. Within the scope of the Contract, the Engineer has the authority to enforce compliance with the Plans and Specifications. The Contractor shall promptly comply with instructions from the Engineer or an authorized representative. The decision of the Engineer is final and binding on all questions relating to: quantities; acceptability of material, equipment, or work; execution, progress or sequence of work; and interpretation of the Plans, Specifications, or other drawings. This shall be precedent to any payment under the Contract, unless otherwise ordered by the Board. 2-10.1 Availability of Records, The Contractor shall, at no charge to the Agency, provide copies of all records in the Contractor’s or subcontractor’s possession pertaining to the work that the Engineer may request. 2-10.2 Audit And Inspection, Contractor agrees to maintain and/or make available, to the Engineer, within San Diego County, accurate books and accounting records relative to all its activities and to contractually require all subcontractors to this Contract to do the same. The Engineer shall have the right to monitor, assess, and evaluate Contractor’s and its subcontractors performance pursuant to this Agreement, said monitoring, assessments, and evaluations to include, but not be limited to, audits, inspection of premises, reports, contracts, subcontracts and interviews of Contractor’s staff and the staff of all subcontractors to this contract. At any time during normal business hours and as often as the Engineer may deem necessary, upon reasonable advance notice, Contractor shall make available to the Engineer for examination, all of its, and all subcontractors to this contract, records with respect to all matters covered by this Contract and will permit the Engineer to audit, examine, copy and make excerpts or transcripts from such data and records, and to make audits of all invoices, materials, payrolls, records of personnel, and other data relating to all matters covered by this Contract. However, any such activities shall be carried out in a manner so as to not unreasonably interfere with Contractor’s ongoing business operations. Contractor and all subcontractors to this contract shall maintain such data and records for as long as may be required by applicable laws and regulations. 2-11 INSPECTION. The Work is subject to inspection and approval by the Engineer. The Contractor shall notify the Engineer before noon of the working day before inspection is required. Work shall be done only in the presence of the Engineer, unless otherwise authorized. Any work done without proper inspection will be subject to rejection. The Engineer and any authorized representatives shall at all times have access to the Work during its construction at shops and yards as well as the project site. The Contractor shall provide every reasonable facility for ascertaining that the materials and workmanship are in accordance with these specifications. Inspection of the Work shall not relieve the Contractor of the obligation to fulfill all conditions of the Contract. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 20 of 63 SECTION 3 – CHANGES IN WORK 3-1 CHANGES REQUESTED BY THE CONTRACTOR. 3-1.1 General. Changes in the Plans and Specifications, requested in writing by the Contractor, which do not materially affect the Work and which are not detrimental to the Work or to the interests of the Agency, may be granted by the Engineer. Nothing herein shall be construed as granting a right to the Contractor to demand acceptance of such changes. 3-1.2 Payment for Changes Requested by the Contractor. If such changes are granted, they shall be made at a reduction in cost or no additional cost to the Agency. 3-2 CHANGES INITIATED BY THE AGENCY. 3-2.1 General. The Agency may change the Plans, Specifications, character of the work, or quantity of work provided the total arithmetic dollar value of all such changes, both additive and deductive, does not exceed 25 percent of the Contract Price. Should it become necessary to exceed this limitation, the change shall be by written Supplemental Agreement between the Contractor and Agency, unless both parties agree to proceed with the change by Change Order. Change Orders shall be in writing and state the dollar value of the change or established method of payment, any adjustment in contract time of completion, and when negotiated prices are involved, shall provide for the Contractor’s signature indicating acceptance. 3-2.2 Payment. 3-2.2.1 Contract Unit Prices. If a change is ordered in an item of work covered by a Contract Unit Price, and such change does not involve substantial change in character of the work from that shown on the Plans or specified in the Specifications, then an adjustment in payment will be made. This adjustment will be based upon the increase or decrease in quantity and the Contract Unit Price. If the actual quantity of an item of work covered by a Contract Unit Price and constructed in conformance with the Plans and Specifications varies from the Bid quantity by 50 percent or less, payment will be made at the Contract Unit Price. If the actual quantity of said item of work varies from the Bid quantity by more than 50 percent, payment will be made per Section 3-2.2.2 or 3-2.2.3 as appropriate. If a change is ordered in an item of work covered by a Contract Unit Price, and such change does involve a substantial change in the character of the work from that shown on the Plans or specified in the Specifications, an adjustment in payment will be made per Section 3-2.4. 3-2.2.2 Increases of More Than 50 Percent. Should the actual quantity of an item of work covered by a Contract Unit Price and constructed in conformance with the Plans and Specifications, exceed the Bid quantity by more than 50 percent, payment for the quantity in excess of 150 percent of the Bid quantity will be made on the basis of an adjustment in the Contract Unit Price mutually agreed to by the Contractor and the Agency, or at the option of the Engineer, on the basis of Extra Work per Section 3-3. The Extra Work per Section 3-3, basis of payment, shall not include fixed costs. Fixed costs shall be deemed to have been recovered by the Contractor through payment for 150 percent of the Bid quantity at the Contract Unit Price. 3-2.2.3 Decreases of More Than 50 Percent. Should the actual quantity of an item of work covered by a Contract Unit Price, and constructed in conformance with the Plans and APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 21 of 63 Specifications, be less than 50 percent of the Bid quantity, an adjustment in payment will not be made unless so requested in writing by the Contractor. If the Contractor so requests, payment will be made on the basis of an adjustment in the Contract Unit Price mutually agreed to by the Contractor and the Agency, or at the option of the Engineer, on the basis of Extra Work per Section 3-3; however, in no case will payment be less than would be made for the actual quantity at the Contract Unit Price nor more than would be made for 50 percent of the Bid quantity at the Contract Unit Price. 3-2.3 Stipulated Unit Prices. Stipulated Unit Prices are unit prices established by the Agency in the Contract Documents as distinguished from Contract Unit Prices submitted by the Contractor. Stipulated Unit Prices may be used for the adjustment of Contract changes when so specified in the Special Provisions. 3-2.4 Agreed Prices. Agreed Prices are prices for new or unforeseen work, or adjustments in Contract Unit Prices per Section 3-2.2, established by mutual agreement between the Contractor and the Agency. If mutual agreement cannot be reached, the Engineer may direct the Contractor to proceed on the basis of Extra Work in accordance per Section 3-3, except as otherwise specified in Sections 3-2.2.2 and 3-2.2.3. 3.2.4.1 Schedule of Values. Prior to construction, Contractor shall provide a schedule of values for all lump sum bid items that shall be used for the purpose of progress payments. The prices shall be valid for the purpose of change orders to the project. 3.2.5 Eliminated Items. Should any Bid item be eliminated in its entirety, payment will be made to the Contractor for its actual costs incurred in connection with the eliminated item prior to notification in writing from the Engineer so stating its elimination. If material conforming to the Plans and Specifications is ordered by the Contractor for use in the eliminated item prior to the date of notification of elimination by the Engineer, and if the order for that material cannot be canceled, payment will be made to the Contractor for the actual cost of the material. In this case, the material shall become the property of the Agency. Payment will be made to the Contractor for its actual costs for any further handling. If the material is returnable, the material shall be returned and payment will be made to the Contractor for the actual cost of charges made by the supplier for returning the material and for handling by the Contractor. Actual costs, as used herein, shall be computed on the basis of Extra Work per Section 3-3. 3-3 EXTRA WORK. 3-3.1 General. New or unforeseen work will be classified as “extra work” when the Engineer determines that it is not covered by Contract Unit Prices or stipulated unit prices. 3-3.2 Payment. 3-3.2.1 General. When the price for the extra work cannot be agreed upon, the Agency will pay for the extra work based on the accumulation of costs as provided herein. 3-3.2.2 Basis for Establishing Costs. (a) Labor. The costs of labor will be the actual cost for wages of workers performing the extra work at the time the extra work is done, plus employer payments of payroll taxes, workers compensation insurance, liability insurance, health and welfare, pension, vacation, apprenticeship funds, and other direct costs, resulting from Federal, State, or local laws, as well as assessments or benefits required by lawful collective bargaining agreements. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 22 of 63 The use of a labor classification which would increase the extra work cost will not be permitted unless the Contractor establishes the necessity for such additional costs. Labor costs for equipment operators and helpers shall be reported only when such costs are not included in the invoice for equipment rental. The labor cost for foremen shall be proportioned to all of their assigned work and only that applicable to extra work will be paid. Nondirect labor costs, including superintendence, shall be considered part of the markup of Section 3-3.2.3 (a). (b) Materials. The cost of materials reported shall be at invoice or lowest current price at which such materials are locally available and delivered to the job site in the quantities involved, plus sales tax, freight, and delivery. The Agency reserves the right to approve materials and sources of supply, or to supply materials to the Contractor if necessary for the progress of the Work. No markup shall be applied to any material provided by the Agency. (c) Tool and Equipment Rental. No payment will be made for the use of tools which have a replacement value of $200 or less. Regardless of ownership, the rates and right-of-way delay factors to be used in determining rental and delay costs shall be the edition of the, “Labor Surcharge and Equipment Rental Rates” published by CALTRANS, current at the time of the actual use of the tool or equipment. The right-of-way delay factors therein shall be used as multipliers of the rental rates for determining the value of costs for delay to the Contractor and subcontractors, if any. The labor surcharge rates published therein are not a part of this contract. The rental rates paid shall include the cost of fuel, oil, lubrication, supplies, small tools, necessary attachments, repairs and maintenance of any kind, depreciation, storage, insurance, and all incidentals. Necessary loading and transportation costs for equipment used on the extra work shall be included. If equipment is used intermittently and, when not in use, could be returned to its rental source at less expense to the Agency than holding it at the Work site, it shall be returned, unless the Contractor elects to keep it at the Work site, at no expense to the Agency. All equipment shall be acceptable to the Engineer, in good working condition, and suitable for the purpose for which it is to be used. Manufacturer’s ratings and approved modifications shall be used to classify equipment and it shall be powered by a unit of at least the minimum rating recommended by the manufacturer. The reported rental time for equipment already at the Work site shall be the duration of its use on the extra work. This time begins when equipment is first put into actual operation on the extra work, plus the time required to move it from its previous site and back, or to a closer site. (d) Other Items. The Agency may authorize other items which may be required on the extra work, including labor, services, material, and equipment. These items must be different in their nature from those required for the Work, and be of a type not ordinarily available from the Contractor or Subcontractors. Invoices covering all such items in detail shall be submitted with the request for payment. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 23 of 63 (e) Invoices. Vendors’ invoices for material, equipment rental and other expenditures shall be submitted with the request for payment. If the request for payment is not substantiated by invoices or other documentation, the Agency may establish the cost of the item involved at the lowest price which was current at the time of the report. 3-3.2.3 Markup. (a) Work by Contractor. The following percentages shall be added to the Contractor's costs and shall constitute the markup for all overhead and profits: 1) Labor …………………………..… 20 2) Materials ……………………….. 15 3) Equipment Rental ………………. 15 4) Other Items and Expenditures .. 15 To the sum of the costs and markups provided for in this section, one percent shall be added as compensation for bonding. (b) Work by Subcontractor. When all or any part of the extra work is performed by a Subcontractor, the markup established in Section 3-3.2.3(a) shall be applied to the Subcontractor's actual cost of such work. A markup of 10 percent on the first $5,000 of the subcontracted portion of the extra work and a markup of 5 percent on work added in excess of $5,000 of the subcontracted portion of the extra work may be added by the Contractor. 3-3.3 Daily Reports by Contractor. When the price for the extra work cannot be agreed upon, the Contractor shall submit a daily report to the Engineer on forms approved by the Agency. Included are applicable delivery tickets, listing all labor, materials, and equipment involved for that day, and other services and expenditures when authorized. Payment for extra work will not be made until such time that the Contractor submits completed daily reports and all supporting documents to the Engineer. Failure to submit the daily report by the close of the next working day may waive any rights for that day. An attempt shall be made to reconcile the report daily, and it shall be signed by the Engineer and the Contractor. In the event of disagreement, pertinent notes shall be entered by each party to explain points which cannot be resolved immediately. Each party shall retain a signed copy of the report. Reports by Subcontractors or others shall be submitted through the Contractor. The report shall: 1. Show names of workers, classifications, and hours worked. 2. Describe and list quantities of materials used. 3. Show type of equipment, size, identification number, and hours of operation, including loading and transportation, if applicable. 4. Describe other services and expenditures in such detail as the Agency may require. 3-4 CHANGED CONDITIONS. The Contractor shall promptly notify the Engineer of the following Work site conditions (hereinafter called changed conditions), in writing, upon their discovery and before they are disturbed: 1. Subsurface or latent physical conditions differing materially from those represented in the Contract; APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 24 of 63 2. Unknown physical conditions of an unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character being performed; and 3. Material differing from that represented in the Contract which the Contractor believes may be hazardous waste, as defined in Section 25117 of the Health and Safety Code, that is required to be removed to a Class I, Class II, or Class III disposal site in accordance with provisions of existing law. The Engineer will promptly investigate conditions which appear to be changed conditions. If the Engineer determines that conditions are changed conditions and they will materially affect performance time, the Contractor, upon submitting a written request, will be granted an extension of time subject to the provisions of 6-6. If the Engineer determines that the conditions do not justify an adjustment in compensation, the Contractor will be notified in writing. This notice will also advise the Contractor of its obligation to notify the Engineer in writing if the Contractor disagrees. The Contractor’s failure to give notice of changed conditions promptly upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith. The Contractor shall not be entitled to the payment of any additional compensation for any act, or failure to act, by the Engineer, including failure or refusal to issue a change order, or for the happening of any event, thing, occurrence, or other cause, unless the Contractor shall have first given the Engineer due written notice of potential claim as hereinafter specified. Compliance with this section shall not be required as a prerequisite to notice provisions in Section 6-7.3 Contract Time Accounting, nor to any claim that is based on differences in measurement or errors of computation as to contract quantities. The written notice of potential claim for changed conditions shall be submitted by the Contractor to the Engineer upon their discovery and prior to the time that the Contractor performs the work giving rise to the potential claim. The Contractor’s failure to give written notice of potential claim for changed conditions to the agency upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith. The Contractor shall provide the City with a written document containing a description of the particular circumstances giving rise to the potential claim, the reasons for which the Contractor believes additional compensation may be due and nature of any and all costs involved within 20 working days of the date of service of the written notice of potential claim for changed conditions. Verbal notifications are disallowed. The potential claim shall include the following certification relative to the California False Claims Act, Government Code Sections 12650-12655. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 25 of 63 “The undersigned certifies that the above statements are made in full cognizance of the California False Claims Act, Government Code Sections 12650-12655. The undersigned further understands and agrees that this potential claim, unless resolved, must be restated as a claim in response to the City’s proposed final estimate in order for it to be further considered.” By: Title: ______________________________ Date: _________________________________ Company Name: _____________________________________________________________ The Contractor’s estimate of costs may be updated when actual costs are known. The Contractor shall submit substantiation of its actual costs to the Engineer within 20 working days after the affected work is completed. Failure to do so shall be sufficient cause for denial of any claim subsequently filed on the basis of said notice of potential claim. It is the intention of this section that differences between the parties arising under and by virtue of the contract be brought to the attention of the Engineer at the earliest possible time in order that such matters be settled, if possible, or other appropriate action promptly taken. 3-5 DISPUTED WORK. The Contractor shall give the agency written notice of potential claim prior to commencing any disputed work. Failure to give said notice shall constitute a waiver of all claims in connection therewith. If the contractor and the agency are unable to reach agreement on disputed work, the Agency may direct the contractor to proceed with the work. Prior to proceeding with dispute resolution pursuant to Public Contract Code provisions specified hereinafter, the contractor shall attempt to resolve all disputes informally through the following dispute resolution chain of command: 1. Project Inspector 2. Construction Manager 3. Deputy City Engineer, Construction Management & Inspection 4. City Engineer 5. City Manager The Contractor shall submit a complete report within 20 working days after completion of the disputed work stating its position on the claim, the contractual basis for the claim, along with all documentation supporting the costs and all other evidentiary materials. At each level of claim or appeal of claim the City will, within 10 working days of receipt of said claim or appeal of claim, review the Contractor’s report and respond with a position, request additional information or request that the Contractor meet and present its report. When additional information or a meeting is requested the City will provide its position within 10 working days of receipt of said additional information or Contractor’s presentation of its report. The Contractor may appeal each level’s position up to the City Manager after which the Contractor may proceed under the provisions of the Public Contract Code. The authority within the dispute resolution chain of command is limited to recommending a resolution to a claim to the City Manager. Actual approval of the claim is subject to the change order provisions in the contract. All claims by the -Contractor shall be resolved in accordance with Public Contract Code section APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 26 of 63 9204, which is set forth below: 9204. (a) The Legislature finds and declares that it is in the best interests of the state and its citizens to ensure that all construction business performed on a public works project in the state that is complete and not in dispute is paid in full and in a timely manner. (b) Notwithstanding any other law, including, but not limited to, Article 7.1 (commencing with Section 10240) of Chapter 1 of Part 2, Chapter 10 (commencing with Section 19100) of Part 2, and Article 1.5 (commencing with Section 20104) of Chapter 1 of Part 3, this section shall apply to any claim by a contractor in connection with a public works project. (c) For purposes of this section: (1) “Claim” means a separate demand by a contractor sent by registered mail or certified mail with return receipt requested, for one or more of the following: (A) A time extension, including, without limitation, for relief from damages or penalties for delay assessed by a public entity under a contract for a public works project. (B) Payment by the public entity of money or damages arising from work done by, or on behalf of, the contractor pursuant to the contract for a public works project and payment for which is not otherwise expressly provided or to which the claimant is not otherwise entitled. (C) Payment of an amount that is disputed by the public entity. (2) “Contractor” means any type of contractor within the meaning of Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code who has entered into a direct contract with a public entity for a public works project. (3) (A) “Public entity” means, without limitation, except as provided in subparagraph (B), a state agency, department, office, division, bureau, board, or commission, the California State University, the University of California, a city, including a charter city, county, including a charter county, city and county, including a charter city and county, district, special district, public authority, political subdivision, public corporation, or nonprofit transit corporation wholly owned by a public agency and formed to carry out the purposes of the public agency. (B) “Public entity” shall not include the following: (i) The Department of Water Resources as to any project under the jurisdiction of that department. (ii) The Department of Transportation as to any project under the jurisdiction of that department. (iii) The Department of Parks and Recreation as to any project under the jurisdiction of that department. (iv) The Department of Corrections and Rehabilitation with respect to any project under its jurisdiction pursuant to Chapter 11 (commencing with Section 7000) of Title 7 of Part 3 of the Penal Code. (v) The Military Department as to any project under the jurisdiction of that department. (vi) The Department of General Services as to all other projects. (vii) The High-Speed Rail Authority. (4) “Public works project” means the erection, construction, alteration, repair, or improvement of any public structure, building, road, or other public improvement of any kind. (5) “Subcontractor” means any type of contractor within the meaning of Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code who either is in direct contract with a contractor or is a lower tier subcontractor. (d) (1) (A) Upon receipt of a claim pursuant to this section, the public entity to which the claim applies shall conduct a reasonable review of the claim and, within a period not to exceed 45 days, shall provide the claimant a written statement identifying what portion of the claim is disputed and what portion is undisputed. Upon receipt of a claim, a public entity and a contractor may, by mutual agreement, extend the time period provided in this subdivision. (B) The claimant shall furnish reasonable documentation to support the claim. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 27 of 63 (C) If the public entity needs approval from its governing body to provide the claimant a written statement identifying the disputed portion and the undisputed portion of the claim, and the governing body does not meet within the 45 days or within the mutually agreed to extension of time following receipt of a claim sent by registered mail or certified mail, return receipt requested, the public entity shall have up to three days following the next duly publicly noticed meeting of the governing body after the 45-day period, or extension, expires to provide the claimant a written statement identifying the disputed portion and the undisputed portion. (D) Any payment due on an undisputed portion of the claim shall be processed and made within 60 days after the public entity issues its written statement. If the public entity fails to issue a written statement, paragraph (3) shall apply. (2) (A) If the claimant disputes the public entity’s written response, or if the public entity fails to respond to a claim issued pursuant to this section within the time prescribed, the claimant may demand in writing an informal conference to meet and confer for settlement of the issues in dispute. Upon receipt of a demand in writing sent by registered mail or certified mail, return receipt requested, the public entity shall schedule a meet and confer conference within 30 days for settlement of the dispute. (B) Within 10 business days following the conclusion of the meet and confer conference, if the claim or any portion of the claim remains in dispute, the public entity shall provide the claimant a written statement identifying the portion of the claim that remains in dispute and the portion that is undisputed. Any payment due on an undisputed portion of the claim shall be processed and made within 60 days after the public entity issues its written statement. Any disputed portion of the claim, as identified by the contractor in writing, shall be submitted to nonbinding mediation, with the public entity and the claimant sharing the associated costs equally. The public entity and claimant shall mutually agree to a mediator within 10 business days after the disputed portion of the claim has been identified in writing. If the parties cannot agree upon a mediator, each party shall select a mediator and those mediators shall select a qualified neutral third party to mediate with regard to the disputed portion of the claim. Each party shall bear the fees and costs charged by its respective mediator in connection with the selection of the neutral mediator. If mediation is unsuccessful, the parts of the claim remaining in dispute shall be subject to applicable procedures outside this section. (C) For purposes of this section, mediation includes any nonbinding process, including, but not limited to, neutral evaluation or a dispute review board, in which an independent third party or board assists the parties in dispute resolution through negotiation or by issuance of an evaluation. Any mediation utilized shall conform to the timeframes in this section. (D) Unless otherwise agreed to by the public entity and the contractor in writing, the mediation conducted pursuant to this section shall excuse any further obligation under Section 20104.4 to mediate after litigation has been commenced. (E) This section does not preclude a public entity from requiring arbitration of disputes under private arbitration or the Public Works Contract Arbitration Program, if mediation under this section does not resolve the parties’ dispute. (3) Failure by the public entity to respond to a claim from a contractor within the time periods described in this subdivision or to otherwise meet the time requirements of this section shall result in the claim being deemed rejected in its entirety. A claim that is denied by reason of the public entity’s failure to have responded to a claim, or its failure to otherwise meet the time requirements of this section, shall not constitute an adverse finding with regard to the merits of the claim or the responsibility or qualifications of the claimant. (4) Amounts not paid in a timely manner as required by this section shall bear interest at 7 percent per annum. (5) If a subcontractor or a lower tier subcontractor lacks legal standing to assert a claim against a public entity because privity of contract does not exist, the contractor may present to the public entity a claim on behalf of a subcontractor or lower tier subcontractor. A subcontractor may request in writing, either on his or her own behalf or on behalf of a lower tier subcontractor, that APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 28 of 63 the contractor present a claim for work which was performed by the subcontractor or by a lower tier subcontractor on behalf of the subcontractor. The subcontractor requesting that the claim be presented to the public entity shall furnish reasonable documentation to support the claim. Within 45 days of receipt of this written request, the contractor shall notify the subcontractor in writing as to whether the contractor presented the claim to the public entity and, if the original contractor did not present the claim, provide the subcontractor with a statement of the reasons for not having done so. (e) The text of this section or a summary of it shall be set forth in the plans or specifications for any public works project that may give rise to a claim under this section. (f) A waiver of the rights granted by this section is void and contrary to public policy, provided, however, that (1) upon receipt of a claim, the parties may mutually agree to waive, in writing, mediation and proceed directly to the commencement of a civil action or binding arbitration, as applicable; and (2) a public entity may prescribe reasonable change order, claim, and dispute resolution procedures and requirements in addition to the provisions of this section, so long as the contractual provisions do not conflict with or otherwise impair the timeframes and procedures set forth in this section. (g) This section applies to contracts entered into on or after January 1, 2017. (h) Nothing in this section shall impose liability upon a public entity that makes loans or grants available through a competitive application process, for the failure of an awardee to meet its contractual obligations. (i) This section shall remain in effect only until January 1, 2020, and as of that date is repealed, unless a later enacted statute, that is enacted before January 1, 2020, deletes or extends that date. In addition, all claims by Contractor for $375,000 or less shall be resolved in accordance with the procedures in the Public Contract Code, Division 2, Part 3, Chapter 1, Article 1.5 (commencing with Section 20104) which is set forth below ARTICLE 1.5 RESOLUTION OF CONSTRUCTION CLAIMS 20104. (a)(1) This article applies to all public works claims of three hundred seventy-five thousand dollars ($375,000) or less which arise between a contractor and a local agency. (2) This article shall not apply to any claims resulting from a contract between a contractor and a public agency when the public agency has elected to resolve any disputes pursuant to Article 7.1 (commencing with Section 10240) of Chapter 1 of Part 2. (b)(1) "Public work" has the same meaning as in Sections 3100 and 3106 of the Civil Code, except that "public work" does not include any work or improvement contracted for by the state or the Regents of the University of California. (2) "Claim" means a separate demand by the contractor for (A) a time extension, (B) payment of money or damages arising from work done by, or on behalf of, the contractor pursuant to the contract for a public work and payment of which is not otherwise expressly provided for or the claimant is not otherwise entitled to, or (C) an amount the payment of which is disputed by the local agency. (c) The provisions of this article or a summary thereof shall be set forth in the plans or specifications for any work which may give rise to a claim under this article. (d) This article applies only to contracts entered into on or after January 1, 1991. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 29 of 63 20104.2. For any claim subject to this article, the following requirements apply: (a) The claim shall be in writing and include the documents necessary to substantiate the claim. Claims must be filed on or before the date of final payment. Nothing in this subdivision is intended to extend the time limit or supersede notice requirements otherwise provided by contract for the filing of claims. (b)(1) For claims of less than fifty thousand dollars ($50,000), the local agency shall respond in writing to any written claim within 45 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant. (2) If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of the local agency and the claimant. (3) The local agency's written response to the claim, as further documented, shall be submitted to the claimant within 15 days after receipt of the further documentation or within a period of time no greater than that taken by the claimant in producing the additional information, whichever is greater. (c)(1) For claims of over fifty thousand dollars ($50,000) and less than or equal to three hundred seventy-five thousand dollars ($375,000), the local agency shall respond in writing to all written claims within 60 days of receipt of the claim, or may request, in writing, within 30 days of receipt of the claim, any additional documentation supporting the claim or relating to defenses to the claim the local agency may have against the claimant. (2) If additional information is thereafter required, it shall be requested and provided pursuant to this subdivision, upon mutual agreement of the local agency and the claimant. (3) The local agency's written response to the claim, as further documented, shall be submitted to the claimant within 30 days after receipt of the further documentation, or within a period of time no greater than that taken by the claimant in producing the additional information or requested documentation, whichever is greater. (d) If the claimant disputes the local agency's written response, or the local agency fails to respond within the time prescribed, the claimant may so notify the local agency, in writing, either within 15 days of receipt of the local agency's response or within 15 days of the local agency's failure to respond within the time prescribed, respectively, and demand an informal conference to meet and confer for settlement of the issues in dispute. Upon a demand, the local agency shall schedule a meet and confer conference within 30 days for settlement of the dispute. (e) Following the meet and confer conference, if the claim or any portion remains in dispute, the claimant may file a claim as provided in Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. For purposes of those provisions, the running of the period of time within which a claim must be filed shall be tolled from the time the claimant submits his or her written claim pursuant to subdivision (a) until the time that claim is denied as a result of the meet and confer process, including any period of time utilized by the meet and confer process. (f) This article does not apply to tort claims and nothing in this article is intended nor shall be construed to change the time periods for filing tort claims or actions specified by Chapter 1 (commencing with Section 900) and Chapter 2 (commencing with Section 910) of Part 3 of Division 3.6 of Title 1 of the Government Code. 20104.4. The following procedures are established for all civil actions filed to resolve claims subject to this article: (a) Within 60 days, but no earlier than 30 days, following the filing or responsive pleadings, the court shall submit the matter to non-binding mediation unless waived by mutual stipulation of both parties. The mediation process shall provide for the selection within 15 days by both parties of a disinterested third person as mediator, shall be commenced within 30 days of the submittal, and APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 30 of 63 shall be concluded within 15 days from the commencement of the mediation unless a time requirement is extended upon a good cause showing to the court or by stipulation of both parties. If the parties fail to select a mediator within the 15-day period, any party may petition the court to appoint the mediator. (b)(1) If the matter remains in dispute, the case shall be submitted to judicial arbitration pursuant to Chapter 2.5 (commencing with Section 1141.10) of Title 3 of Part 3 of the Code of Civil Procedure, notwithstanding Section 1141.11 of that code. The Civil Discovery Act of 1986 (Article 3 (commencing with Section 2016) of Chapter 3 of Title 3 of Part 4 of the Code of Civil procedure) shall apply to any proceeding brought under the subdivision consistent with the rules pertaining to judicial arbitration. (2) Notwithstanding any other provision of law, upon stipulation of the parties, arbitrators appointed for purposes of this article shall be experienced in construction law, and, upon stipulation of the parties, mediators and arbitrators shall be paid necessary and reasonable hourly rates of pay not to exceed their customary rate, and such fees and expenses shall be paid equally by the parties, except in the case of arbitration where the arbitrator, for good cause, determines a different division. In no event shall these fees or expenses be paid by state or county funds. (3) In addition to Chapter 2.5 (commencing with Section 1141.10) Title 3 of Part 3 of the Code of Civil Procedure, any party who after receiving an arbitration award requests a trial de novo but does not obtain a more favorable judgment shall, in addition to payment of costs and fees under that chapter, pay the attorney's fees of the other party arising out of the trial de novo. (c) The court may, upon request by any party, order any witnesses to participate in the mediation or arbitration process. 20104.6. (a) No local agency shall fail to pay money as to any portion of a claim which is undisputed except as otherwise provided in the contract. (b) In any suit filed under Section 20104.4, the local agency shall pay interest at the legal rate on any arbitration award or judgment. The interest shall begin to accrue on the date the suit is filed in a court of law. Although not to be construed as proceeding under extra work provisions, the Contractor shall keep and furnish records of disputed work in accordance with Section 3-3. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 31 of 63 SECTION 4 – CONTROL OF MATERIALS 4-1 MATERIALS AND WORKMANSHIP. 4-1.1. General. All materials, parts, and equipment furnished by the Contractor in the Work shall be new, high grade, and free from defects. Quality of work shall be in accordance with the generally accepted standards. Material and work quality shall be subject to the Engineer’s approval. Materials and work quality not conforming to the requirements of the Specifications shall be considered defective and will be subject to rejection. Defective work or material, whether in place or not, shall be removed immediately from the site by the Contractor, at its expense, when so directed by the Engineer. If the Contractor fails to replace any defective or damaged work or material after reasonable notice, the Engineer may cause such work or materials to be replaced. The replacement expense will be deducted from the amount to be paid to the Contractor. Used or secondhand materials, parts, and equipment may be used only if permitted by the Specifications. 4-1.2 Protection of Work and Materials. The Contractor shall provide and maintain storage facilities and employ such measures as will preserve the specified quality and fitness of materials to be used in the Work. Stored materials shall be reasonably accessible for inspection. The Contractor shall also adequately protect new and existing work and all items of equipment for the duration of the Contract. The Contractor shall not, without the Agency’s consent, assign, sell, mortgage, hypothecate, or remove equipment or materials which have been installed or delivered and which may be necessary for the completion of the Contract. 4-1.3 Inspection Requirements. 4-1.3.1 General. Unless otherwise specified, inspection is required at the source for such typical materials and fabricated items as bituminous paving mixtures, structural concrete, metal fabrication, metal casting, welding, concrete pipe manufacture, protective coating application, and similar shop or plant operations. Steel pipe in sizes less than 18 inches and vitrified clay and cast iron pipe in all sizes are acceptable upon certification as to compliance with the Specifications, subject to sampling and testing by the Agency. Standard items of equipment such as electric motors, conveyors, elevators, plumbing fixtures, etc., are subject to inspection at the job site only. Special items of equipment such as designed electrical panel boards, large pumps, sewage plant equipment, etc., are subject to inspection at the source, normally only for performance testing. The Specifications may require inspection at the source for other items not typical of those listed in this section. The Contractor shall provide the Engineer free and safe access to any and all parts of work at any time. Such free and safe access shall include means of safe access and egress, ventilation, lighting, shoring, dewatering and all elements pertaining to the safety of persons as contained in the State of California, California Code of Regulations, Title 8, Industrial Relations, Chapter 4, APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 32 of 63 Division of Industrial Safety, Subchapter 4, Construction Safety Orders and such other safety regulations as may apply. Contractor shall furnish Engineer with such information as may be necessary to keep the Engineer fully informed regarding progress and manner of work and character of materials. Inspection or testing of the whole or any portion of the work or materials incorporated in the work shall not relieve Contractor from any obligation to fulfill this Contract. 4-1.3.2 Inspection of Materials Not Locally Produced. When the Contractor intends to purchase materials, fabricated products, or equipment from sources located more than 50 miles outside the geographical limits of the Agency, an inspector or accredited testing laboratory (approved by the Engineer), shall be engaged by the Contractor at its expense, to inspect the materials, equipment or process. This approval shall be obtained before producing any material or equipment. The inspector or representative of the testing laboratory shall judge the materials by the requirements of the Plans and Specifications. The Contractor shall forward reports required by the Engineer. No material or equipment shall be shipped nor shall any processing, fabrication or treatment of such materials be done without proper inspection by the approved agent. Approval by said agent shall not relieve the Contractor of responsibility for complying with the Contract requirements. 4-1.3.3 Inspection by the Agency. The Agency will provide all inspection and testing laboratory services within 50 miles of the geographical limits of the Agency. For private contracts, all costs of inspection at the source, including salaries and mileage costs, shall be paid by the permittee. 4-1.4 Test of Material. Before incorporation in the Work, the Contractor shall submit samples of materials, as the Engineer may require, at no cost to the Agency. The Contractor, at its expense, shall deliver the materials for testing to the place and at the time designated by the Engineer. Unless otherwise provided, all initial testing will be performed under the direction of the Engineer, and at no expense to the Contractor. If the Contractor is to provide and pay for testing, it will be stated in the Specifications. For private contracts, the testing expense shall be borne by the permittee. The Contractor shall notify the Engineer in writing, at least 15 days in advance, of its intention to use materials for which tests are specified, to allow sufficient time to perform the tests. The notice shall name the proposed supplier and source of material. If the notice of intent to use is sent before the materials are available for testing or inspection, or is sent so far in advance that the materials on hand at the time will not last but will be replaced by a new lot prior to use on the Work, it will be the Contractor’s responsibility to renotify the Engineer when samples which are representative may be obtained. Except as specified in these Provisions, the Agency will bear the cost of testing of locally produced materials and/or on-site workmanship where the results of such tests meet or exceed the requirements indicated in the Standard Specifications, Technical Specification, and any Supplemental Provisions. The cost of all other tests shall be borne by the Contractor. At the option of the Engineer, the source of supply of each of the materials shall be approved by the Engineer before the delivery is started. All materials proposed for use may be inspected or tested at any time during their preparation and use. If, after incorporating such materials into the Work, it is found that sources of supply that have been approved do not furnish a uniform product, or if the product from any source proves unacceptable at any time, the Contractor shall furnish approved material from other approved sources. If any product proves unacceptable after improper storage, handling or for any other reason it shall be rejected, not incorporated into the work and shall be removed from the project site all at the Contractor’s expense. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 33 of 63 Compaction tests may be made by the Engineer and all costs for tests that meet or exceed the requirements of the specifications shall be borne by the Agency. Said tests may be made at any place along the work as deemed necessary by the Engineer. The costs of any retests made necessary by noncompliance with the specifications shall be borne by the Contractor. 4-1.5 Certification. The Engineer may waive materials testing requirements of the Specifications and accept the manufacturer’s written certification that the materials to be supplied meet those requirements. Material test data may be required as part of the certification. 4-1.6 Trade Names or Equals. The Contractor may supply any of the materials specified or offer an equivalent. The Engineer shall determine whether the material offered is equivalent to that specified. Adequate time shall be allowed for the Engineer to make this determination. Whenever any particular material, process, or equipment is indicated by patent, proprietary or brand name, or by name of manufacturer, such wording is used for the purpose of facilitating its description and shall be deemed to be followed by the words or equal. A listing of materials is not intended to be comprehensive, or in order of preference. The Contractor may offer any material, process, or equipment considered to be equivalent to that indicated. The substantiation of offers shall be submitted as provided in the contract documents. The Contractor shall, at its expense, furnish data concerning items offered by it as equivalent to those specified. The Contractor shall have the material tested as required by the Engineer to determine that the quality, strength, physical, chemical, or other characteristics, including durability, finish, efficiency, dimensions, service, and suitability are such that the item will fulfill its intended function. Test methods shall be subject to the approval of the Engineer. Test results shall be reported promptly to the Engineer, who will evaluate the results and determine if the substitute item is equivalent. The Engineer’s findings shall be final. Installation and use of a substitute item shall not be made until approved by the Engineer. If a substitute offered by the Contractor is not found to be equal to the specified material, the Contractor shall furnish and install the specified material. The specified Contract completion time shall not be affected by any circumstance developing from the provisions of this section. The Contractor is responsible for the satisfactory performance of substituted items. If, in the sole opinion of the Engineer, the substitution is determined to be unsatisfactory in performance, appearance, durability, compatibility with associated items, availability of repair parts and suitability of application the Contractor shall remove the substituted item and replace it with the originally specified item at no cost to the Agency. 4-1.7 Weighing and Metering Equipment. All scales and metering equipment used for proportioning materials shall be inspected for accuracy and certified within the past 12 months by the State of California Bureau of Weights and Measures, by the County Director or Sealer of Weights and Measures, or by a scale mechanic registered with or licensed by the County. The accuracy of the work of a scale service agency, except as stated herein, shall meet the standards of the California Business and Professions Code and the California Code of Regulations pertaining to weighing devices. A certificate of compliance shall be presented, prior APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 34 of 63 to operation, to the Engineer for approval and shall be renewed whenever required by the Engineer at no cost to the Agency. All scales shall be arranged so they may be read easily from the operator’s platform or area. They shall indicate the true net weight without the application of any factor. The figures of the scales shall be clearly legible. Scales shall be accurate to within 1 percent when tested with the plant shut down. Weighing equipment shall be so insulated against vibration or moving of other operating equipment in the plant area that the error in weighing with the entire plant running will not exceed 2 percent for any setting nor 1.5 percent for any batch. 4-1.8 Calibration of Testing Equipment. Testing equipment, such as, but not limited to pressure gages, metering devices, hydraulic systems, force (load) measuring instruments, and strain-measuring devices shall be calibrated by a testing agency acceptable to the Engineer at intervals not to exceed 12 months and following repairs, modification, or relocation of the equipment. Calibration certificates shall be provided when requested by the Engineer. 4-1.9 Construction Materials Dispute Resolution (Soils, Rock Materials, Concrete, Mortar and Related Materials, Masonry Materials, Bituminous Materials, Rock Products, and Modified Asphalts). In the interest of safety and public value, whenever credible evidence arises to contradict the test values of materials, the Agency and the Contractor will initiate an immediate and cooperative investigation. Test values of materials are results of the materials’ tests, as defined by these Specifications or by the special provisions, required to accept the Work. Credible evidence is process observations or test values gathered using industry accepted practices. A contradiction exists whenever test values or process observations of the same or similar materials are diverse enough such that the work acceptance or performance becomes suspect. The investigation shall allow access to all test results, procedures, and facilities relevant to the disputed work and consider all available information and, when necessary, gather new and additional information in an attempt to determine the validity, the cause, and if necessary, the remedy to the contradiction. If the cooperative investigation reaches any resolution mechanism acceptable to both the Agency and the Contractor, the contradiction shall be considered resolved and the cooperative investigation concluded. Whenever the cooperative investigation is unable to reach resolution, the investigation may then either conclude without resolution or continue by written notification of one party to the other requesting the implementation of a resolution process by committee. The continuance of the investigation shall be contingent upon recipient’s agreement and acknowledged in writing within 3 calendar days after receiving a request. Without acknowledgement, the investigation shall conclude without resolution. The committee shall consist of three State of California Registered Civil Engineers. Within 7 calendar days after the written request notification, the Agency and the Contractor will each select one engineer. Within 14 calendar days of the written request notification, the two selected engineers will select a third engineer. The goal in selection of the third member is to complement the professional experience of the first two engineers. Should the two engineers fail to select the third engineer, the Agency and the Contractor shall each propose 2 engineers to be the third member within 21 calendar days after the written request notification. The first two engineers previously selected shall then select one of the four proposed engineers in a blind draw. The committee shall be a continuance of the cooperative investigation and will re-consider all available information and if necessary gather new and additional information to determine the validity, the cause, and if necessary, the remedy to the contradiction. The committee will focus upon the performance adequacy of the material(s) using standard engineering principles and practices and to ensure public value, the committee may provide engineering recommendations as necessary. Unless otherwise agreed, the committee will have 30 calendar days from its formation to complete their review and submit their findings. The final resolution of the committee shall be by majority opinion, in writing, stamped and signed. Should the final resolution not be unanimous, the dissenter may attach a written, stamped, and signed minority opinion. Once started, the resolution process by committee shall continue to full conclusion unless: 1. Within 7 days of the formation of the committee, the Agency and the Contractor reach an acceptable resolution mechanism; or APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 35 of 63 2. Within 14 days of the formation of the committee, the initiating party withdraws its written notification and agrees to bear all investigative related costs thus far incurred; or 3. At any point by the mutual agreement of the Agency and the Contractor. Unless otherwise agreed, the Contractor shall bear and maintain a record for all the investigative costs until resolution. Should the investigation discover assignable causes for the contradiction, the assignable party, the Agency or the Contractor, shall bear all costs associated with the investigation. Should assignable causes for the contradiction extended to both parties, the investigation will assign costs cooperatively with each party or when necessary, equally. Should the investigation substantiate a contradiction without assignable cause, the investigation will assign costs cooperatively with each party or when necessary, equally. Should the investigation be unable to substantiate a contradiction, the initiator of the investigation shall bear all investigative costs. All claim notification requirements of the contract pertaining to the contradiction shall be suspended until the investigation is concluded. 4-2 MATERIALS TRANSPORTATION, HANDLING AND STORAGE. The Contractor shall order, purchase, transport, coordinate delivery, accept delivery, confirm the quantity and quality received, prepare storage area(s), store, handle, protect, move, relocate, remove and dispose excess of all materials used to accomplish the Work. Materials shall be delivered to the site of the work only during working hours, as defined in Section 6-7.2, and shall be accompanied by bills of lading that shall clearly state for each delivery: the name of the Contractor as consignee, the project name and number, address of delivery and name of consignor and a description of the material(s) shipped. Prior to storage of any materials which have been shipped to or by the Contractor to any location within the Agency’s boundaries the Contractor shall provide the Engineer a copy of lease agreements for each property where such materials are stored. The lease agreement shall clearly state the term of the lease, the description of materials allowed to be stored and shall provide for the removal of the materials and restoration of the storage site within the time allowed for the Work. All such storage shall conform to all laws and ordinances that may pertain to the materials stored and to preparation of the storage site and the location of the site on which the materials are stored. Loss, damage or deterioration of all stored materials shall be the Contractor’s responsibility. Conformance to the requirements of this section, both within and outside the limits of work are a part of the Work. The Engineer shall have the right to verify the suitability of materials and their proper storage at any time during the Work. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 36 of 63 SECTION 5 – UTILITIES 5-1 LOCATION. The Agency and affected utility companies have, by a search of known records, endeavored to locate and indicate on the Plans, all utilities which exist within the limits of the work. However, the accuracy and/or completeness of the nature, size and/or location of utilities indicated on the Plans is not guaranteed. Where underground main distribution conduits such as water, gas, sewer, electric power, telephone, or cable television are shown on the Plans, the Contractor shall assume that every property parcel will be served by a service connection for each type of utility. As provided in Section 4216 of the California Government Code, at least two working days prior to commencing any excavation, the Contractor shall contact the regional notification center (Underground Service Alert of Southern California) and obtain an inquiry identification number. The California Department of Transportation is not required by Section 4216 to become a member of the regional notification center. The Contractor shall contact it for location of its subsurface installations. The Contractor shall determine the location and depth of all utilities, including service connections, which have been marked by the respective owners and which may affect or be affected by its operations. If no pay item is provided in the Contract for this work, full compensation for such work shall be considered as included in the prices bid for other items of work. 5-2 PROTECTION. The Contractor shall not interrupt the service function or disturb the support of any utility without authority from the owner or order from the Agency. All valves, switches, vaults, and meters shall be maintained readily accessible for emergency shutoff. Where protection is required to ensure support of utilities located as shown on the Plans or in accordance with Section 5-1, the Contractor shall, unless otherwise provided, furnish and place the necessary protection at its expense. Upon learning of the existence and location of any utility omitted from or shown incorrectly on the Plans, the Contractor shall immediately notify the Engineer in writing. When authorized by the Engineer, support or protection of the utility will be paid for as provided in Section 3-2.2.3 or 3-3. The Contractor shall immediately notify the Engineer and the utility owner if any utility is disturbed or damaged. The Contractor shall bear the costs of repair or replacement of any utility damaged if located as noted in Section 5-1. When placing concrete around or contiguous to any non-metallic utility installation, the Contractor shall at its expense: 1. Furnish and install a two-inch cushion of expansion joint material or other similar resilient material; or 2. Provide a sleeve or other opening which will result in a two-inch minimum-clear annular space between the concrete and the utility; or 3. Provide other acceptable means to prevent embedment in or bonding to the concrete. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 37 of 63 Where concrete is used for backfill or for structures which would result in embedment, or partial embedment, of a metallic utility installation; or where the coating, bedding or other cathodic protection system is exposed or damaged by the Contractor’s operations, the Contractor shall notify the Engineer and arrange to secure the advice of the affected utility owner regarding the procedures required to maintain or restore the integrity of the system. 5-3 REMOVAL. Unless otherwise specified, the Contractor shall remove all interfering portions of utilities shown on the Plans or indicated in the Bid documents as “abandoned” or “to be abandoned in place”. Before starting removal operations, the Contractor shall ascertain from the Agency whether the abandonment is complete, and the costs involved in the removal and disposal shall be included in the Bid for the items of work necessitating such removals. 5-4 RELOCATION. When feasible, the owners responsible for utilities within the area affected by the Work will complete their necessary installations, relocations, repairs, or replacements before commencement of work by the Contractor. When the Plans or Specifications indicate that a utility installation is to be relocated, altered, or constructed by others, the Agency will conduct all negotiations with the owners and work will be done at no cost to the Contractor, except for manhole frame and cover sets to be brought to grade as provided in the Standard Specifications for Public Works Construction, Section 301-1.6, 2006 Edition. Utilities which are relocated in order to avoid interference shall be protected in their position and the cost of such protection shall be included in the Bid for the items of work necessitating such relocation. After award of the Contract, portions of utilities which are found to interfere with the Work will be relocated, altered or reconstructed by the owners, or the Engineer may order changes in the Work to avoid interference. Such changes will be paid for in accordance with Section 3-2. When the Plans or Specifications provide for the Contractor to alter, relocate, or reconstruct a utility, all costs for such work shall be included in the Bid for the items of work necessitating such work. Temporary or permanent relocation or alteration of utilities requested by the Contractor for its convenience shall be its responsibility and it shall make all arrangements and bear all costs. The utility owner will relocate service connections as necessary within the limits of the Work or within temporary construction or slope easements. When directed by the Engineer, the Contractor shall arrange for the relocation of service connections as necessary between the meter and property line, or between a meter and the limits of temporary construction or slope easements. The relocation of such service connections will be paid for in accordance with provisions of Section 3-3. Payment will include the restoration of all existing improvements which may be affected thereby. The Contractor may agree with the owner of any utility to disconnect and reconnect interfering service connections. The Agency will not be involved in any such agreement. In conformance with Section 5-6, the Contractor shall coordinate the work with utility agencies and companies. Prior to the installation of any and all utility structures within the limits of work by any utility agency or company, or its contractor, the Contractor shall place all curb or curb and gutter that is a part of the work and adjacent to the location where such utility structures are shown on the plans and are noted as being located, relocated or are otherwise shown as installed by others. In order to minimize delays to the Contractor caused by the failure of other parties to relocate utilities that interfere with the construction, the Contractor, upon the Engineer’s approval, may be permitted to temporarily omit the portion of work affected by the utility. If such temporary omission is approved by the Engineer the Contractor shall place survey or other physical control markers sufficient to locate the curb or curb and gutter to the satisfaction of the utility agency or company. Such temporary omission shall be for the Contractor’s convenience and no additional compensation will be allowed therefore or for additional work, materials or delay associated with the temporary omission. The portion thus omitted shall be constructed by the Contractor APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 38 of 63 immediately following the relocation of the utility involved unless otherwise directed by the Engineer. 5-5 DELAYS. The Contractor shall notify the Engineer of its construction schedule insofar as it affects the protection, removal, or relocation of utilities. Said notification shall be included as a part of the construction schedule required in Section 6-1. The Contractor shall notify the Engineer in writing of any subsequent changes in the construction schedule which will affect the time available for protection, removal, or relocation of utilities. The Contractor will not be entitled to damages or additional payment for delays attributable to utility relocations or alterations if correctly located, noted, and completed in accordance with Section 5-1. The Contractor may be given an extension of time for unforeseen delays attributable to unreasonably protracted interference by utilities in performing work correctly shown on the Plans. The Agency will assume responsibility for the timely removal, relocation, or protection of existing main or trunk line utility facilities within the area affected by the Work if such utilities are not identified in the Contract Documents. The Contractor will not be assessed liquidated damages for any delay caused by failure of Agency to provide for the timely removal, relocation, or protection of such existing facilities. If the Contractor sustains loss due to delays attributable to interferences, relocations, or alterations not covered by Section 5-1, which could not have been avoided by the judicious handling of forces, equipment, or plant, there shall be paid to the Contractor such amount as the Engineer may find to be fair and reasonable compensation for such part of the Contractor’s actual loss as was unavoidable and the Contractor may be granted an extension of time. 5-6 COOPERATION. When necessary, the Contractor shall so conduct its operations as to permit access to the Work site and provide time for utility work to be accomplished during the progress of the Work. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 39 of 63 SECTION 6 – PROSECUTION, PROGRESS, AND ACCEPTANCE OF THE WORK 6-1 CONSTRUCTION SCHEDULE AND COMMENCEMENT OF WORK. Except as otherwise provided herein and unless otherwise prohibited by permits from other agencies as may be required by law the Contractor shall begin work within 1 calendar days after receipt of the "Notice to Proceed". 6-1.1 Pre-Construction Meeting. After, or upon, notification of contract award, the Engineer will set the time and location for the Preconstruction Meeting. Attendance of the Contractor’s management personnel responsible for the management, administration, and execution of the project is mandatory for the meeting to be convened. Failure of the Contractor to have the Contractor’s responsible project personnel attend the Preconstruction Meeting will be grounds for default by Contractor per Section 6-4. No separate payment will be made for the Contractor’s attendance at the meeting. The notice to proceed will only be issued on or after the completion of the preconstruction meeting. 6-1.1.1 Baseline Construction Schedule Submittal. The Contractor shall submit the Baseline Construction Schedule per the submittal requirements of Section 2-5.3. The submittal of the Baseline Construction Schedule shall include each item and element of Sections 6-1.2 through 6-1.2.9 and shall be on hard (paper) copy and electronic media conforming to Section 6-1.3.3 Electronic Media. 6-1.2 Preparation and Review of the Baseline Construction Schedule. The Contractor shall prepare the Baseline Construction Schedule as a Critical Path Method (CPM) Schedule in the precedence diagram method (activity-on-node) format. The Baseline Construction Schedule shall depict a workable plan showing the sequence, duration, and interdependence of all activities required to represent the complete performance of all project work as well as periods where work is precluded. The Baseline Construction Schedule shall begin with the projected date of issuance of the notice to proceed and conclude with the date of final completion per the contract duration. The Baseline Construction Schedule shall include detail of all project phasing, staging, and sequencing, including all milestones necessary to define beginning and ending of each phase or stage. 6-1.2.1 Time-Scaled Network Diagram. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a complete time-scaled network diagram showing all of the activities, logic relationships, and milestones comprising the schedule. 6-1.2.2 Tabular Listing. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a tabular listing of all of the activities, showing for each activity the identification number, the description, the duration, the early start, the early finish, the late start, the late finish, the total float, and all predecessor and successor activities for the activity described. 6-1.2.3 Bar Chart. As a part of the Baseline Construction Schedule the Contractor shall prepare and submit to the Engineer a chart showing individual tasks and their durations arranged with the tasks on the vertical axis and duration on the horizontal axis. The bar chart shall use differing texture patterns or distinctive line types to show the critical path. 6-1.2.4 Schedule Software. The Contractor shall use commercially available software equal to the Windows 2000 compatible “Suretrak” program by Primavera or “Project” program by Microsoft Corporation to prepare the Baseline Construction Schedule and all updates thereto. The APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 40 of 63 Contractor shall submit to the Agency a CD-ROM data disk with all network information contained thereon, in a format readable by a Microsoft Windows 2000 system. The Agency will use a “Suretrak”, “Project” or equal software program for review of the Contractor’s schedule. Should the Contractor elect to use a scheduling program other than the “Suretrak” program by Primavera or “Project” program by Microsoft Corporation the Contractor shall provide the Engineer three copies of the substituted program that are fully licensed to the Agency and 32 class hours of on-site training by the program publisher for up to eight Agency staff members. The classes shall be presented on Mondays through Thursdays, inclusive, between the hours of 8:00 a.m. and 5:00 p.m. The on-site training shall be held at 1635 Faraday Avenue, Carlsbad, California. The dates and times of the on-site training shall be submitted to the Engineer for approval five working days before the start of the on-site training. The on-site training shall be completed prior to the submittal of the first Baseline Construction Schedule. 6-1.2.5 Schedule Activities. Except for submittal activities, activity durations shall not be shorter than 1 working day nor longer than 15 working days, unless specifically and individually allowed by the Engineer. The Baseline Construction Schedule shall include between 100 and 500 activities, including submittals, interfaces between utility companies and other agencies, project milestones and equipment and material deliveries. The number of activities will be sufficient, in the judgment of the Engineer, to communicate the Contractor’s plan for project execution, to accurately describe the project work, and to allow monitoring and evaluation of progress and of time impacts. Each activity’s description shall accurately define the work planned for the activity and each activity shall have recognizable beginning and end points. 6-1.2.6 Float. Float or slack time within the schedule is available without charge or compensation to whatever party or contingency first exhausts it. 6-1.2.7 Restraints to Activities. Any submittals, utility interfaces, or any furnishing of Agency supplied materials, equipment, or services, which may impact any activity’s construction shall be shown as a restraint to those activities. Time periods to accommodate the review and correction of submittals shall be included in the schedule. 6-1.2.8 Late Completion. A Baseline Construction Schedule showing a project duration longer than the specified contract duration will not be acceptable and will be grounds for determination of default by Contractor, per Section 6-4. 6-1.2.9 Early Completion. The Baseline Construction Schedule will show the Contractor’s plan to support and maintain the project for the entire contractual time span of the project. Should the Contractor propose a project duration shorter than contract duration, a complete Baseline Construction Schedule must be submitted, reflecting the shorter duration, in complete accordance with all schedule requirements of Section 6-1. The Engineer may choose to accept the Contractor’s proposal of a project duration shorter than the duration specified; provided the Agency is satisfied the shortened Baseline Construction Schedule is reasonable and the Agency and all other entities, public and private, which interface with the project are able to support the provisions of the shortened Baseline Construction Schedule. The Agency’s acceptance of a shortened duration project will be confirmed through the execution of a contract change order revising the project duration and implementing all contractual requirements including liquidated damages in accordance with the revised duration. 6-1.2.10 Engineer’s Review. The Construction Schedule is subject to the review of the Engineer. The Engineer’s determination that the Baseline Construction Schedule proposed by the Contractor complies with the requirements of these supplemental provisions shall be a condition precedent to issuance of the Notice to Proceed by the Engineer. If the Engineer determines that APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 41 of 63 the Construction Schedule does not meet the requirements of these specifications the Contractor shall correct the Construction Schedule to meet these specifications and resubmit it to the Engineer. Failure of the Contractor to obtain the Engineer’s determination that the initial Construction Schedule proposed by the Contractor complies with the requirements of these supplemental provisions within thirty (30) working days after the date of the preconstruction meeting shall be grounds for termination of the contract per Section 6-4. Days used by the Engineer to review the initial Construction Schedule will not be included in the 30 working days. The Engineer will review and return to the Contractor, with any comments, the Baseline Construction Schedule within 15 working days of submittal. The Baseline Construction Schedule will be returned marked as per Sections 6-1.2.10.1 through 6-1.2.10.3. 6-1.2.10.1 “Accepted.” The Contractor may proceed with the project work upon issuance of the Notice to Proceed, and will receive payment for the schedule in accordance with Section 6-1.8.1. 6-1.2.10.2 “Accepted with Comments.” The Contractor may proceed with the project work upon issuance of the Notice to Proceed. The Contractor must resubmit the schedule incorporating the comments prior to receipt of payment per Section 6-1.8.1. 6-1.2.10.3 “Not Accepted.” The Contractor must resubmit the schedule incorporating the corrections and changes of the comments prior to receipt of payment per Section 6-1.8.1. The Notice to Proceed will not be issued by the Engineer if the changes of the comments are not submitted as required hereinbefore and marked “Accepted” or “Accepted with Comments” by the Engineer. The Contractor, at the sole option of the Engineer, may be considered as having defaulted the contract under the provisions of Section 6-4 DEFAULT BY CONTRACTOR if the changes of the comments are not submitted as required hereinbefore and marked “Accepted” by the Engineer. 6-1.3 Preparation of Schedule Updates and Revisions. The Contractor shall meet with the Engineer during the last week of each month to agree upon each activity’s schedule status and shall submit monthly updates of the Baseline Construction Schedule confirming the agreements no later than the fifth working day of the following month. The monthly update will be submitted on hard (paper) copy and electronic media conforming to Section 6-1.3.3 Electronic Media per the submittal requirements of Section 2-5.3 and will include each item and element of Sections 6-1.2 through 6-1.2.9 and 6-1.3.1 through 6-1.3.7. 6-1.3.1 Actual Activity Dates. The actual dates each activity was started and/or completed during the month. After first reporting an actual date, the Contractor shall not change that actual date in later updates without specific notification to the Engineer with the update. 6-1.3.2 Activity Percent Complete. For each activity underway at the end of the month, the Contractor shall report the percentage determined by the Engineer as complete for the activity. 6-1.3.3 Electronic Media. The schedule data disk shall be a CD-ROM, labeled with the project name and number, the Contractor’s name and the date of preparation of the schedule data disk. The schedule data disk shall be readable by the software specified in Section 6-1.2.4 “Schedule Software” and shall be free of file locking, encryption or any other protocol that would impede full access of all data stored on it. 6-1.3.4 List of Changes. A list of all changes made to the activities or to the interconnecting logic, with an explanation for each change. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 42 of 63 6-1.3.5 Change Orders. Each monthly update will include the addition of the network revisions reflecting the change orders approved in the previous month. The network revisions will be as agreed upon during the review and acceptance of the Contractor’s change orders. 6-1.3.6 Bar Chart. Each monthly update will include a chart showing individual tasks and their durations arranged with the tasks on the vertical axis and duration on the horizontal axis. The bar chart shall use differing texture patterns or distinctive line types to show the critical path. 6-1.4 Engineer’s Review of Updated Construction Schedule. The Engineer will review and return the Updated Construction Schedule to the Contractor, with any comments, within 5 working days of submittal. The Updated Construction Schedule will be returned marked as per Sections 6-1.4.1 through 6-1.4.3. Any Updated Construction Schedule marked “Accepted with Comments” or “Not Accepted” by the Engineer will be returned to the Contractor for correction. Upon resubmittal the Engineer will review and return the resubmitted Updated Construction Schedule to the Contractor, with any comments, within 5 working days. Failure of the Contractor to submit a monthly updated construction schedule will invoke the same consequences as the Engineer returning a monthly updated construction schedule marked “Not Accepted”. 6-1.4.1 “Accepted.” The Contractor may proceed with the project work, and will receive payment for the schedule in accordance with Section 6-1.8.2. 6-1.4.2 “Accepted with Comments.” The Contractor may proceed with the project work. The Contractor must resubmit the Updated Construction Schedule to the Engineer incorporating the corrections and changes noted in the Engineer’s comments prior to receipt of payment per Section 6-1.8.2. 6-1.4.3 “Not Accepted.” The Contractor must resubmit the Updated Construction Schedule to the Engineer incorporating the corrections and changes noted in the Engineer’s comments prior to receipt of payment per Section 6-1.8.2. The Contractor, at the sole option of the Engineer, may be considered as having defaulted the contract under the provisions of Section 6-4 DEFAULT BY CONTRACTOR if the changes of the comments are not submitted and marked “Accepted” by the Engineer before the last day of the month in which the Updated Construction Schedule is due. If the Contractor fails to submit the corrected Updated Construction Schedule as required herein the Contractor may elect to proceed with the project at its own risk. Should the Contractor elect not to proceed with the project, any resulting delay, impact, or disruption to the project will be the Contractor’s responsibility. 6-1.5 Late Completion or Milestone Dates. Should the Schedule Update indicate a completion or contractually required milestone date later than the properly adjusted contract or milestone duration, the Agency may withhold Liquidated Damages for the number of days late. Should a subsequent “Accepted” Schedule Update remove all or a portion of the delay, all or the allocated portion of the previously held Liquidated Damages shall be released in the monthly payment to the Contractor immediately following the “Accepted” schedule. 6-1.6 Interim Revisions. Should the actual or projected progress of the work become substantially different from that depicted in the Project Schedule, independently of and prior to the next monthly update, the Contractor will submit a revised Baseline Construction Schedule, with a list and explanation of each change made to the schedule. The Revised Construction Schedule will be submitted per the submittal requirements of Section 2-5.3 and per the schedule review and acceptance requirements of Section 6-1, including but not limited to the acceptance and payment provisions. As used in this section “substantially different” means a time variance greater than 5 percent of the number of days of duration for the project. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 43 of 63 6-1.7 Final Schedule Update. The Contractor shall prepare and submit a final schedule update when one hundred percent of the construction work is completed. The Contractor’s Final Schedule Update must accurately represent the actual dates for all activities. The final schedule update shall be prepared and reviewed per Sections 6-1.3 Preparation of Schedule Updates and Revisions and 6-1. 4 Engineer’s Review of Updated Construction Schedule. Acceptance of the final schedule update is required for completion of the project and release of any and all funds retained per Section 9-3.2. 6-1.8 Measurement and Payment of Construction Schedule. The Contractor’s preparation, revision and maintenance of the Construction Schedule are incidental to the work and no separate payment will be made therefore. 6-2 PROSECUTION OF WORK. To minimize public inconvenience and possible hazard and to restore street and other work areas to their original condition and state of usefulness as soon as practicable, the Contractor shall diligently prosecute the Work to completion. If the Engineer determines that the Contractor is failing to prosecute the Work to the proper extent, the Contractor shall, upon orders from the Engineer, immediately take steps to remedy the situation. All costs of prosecuting the Work as described herein shall be included in the Contractor’s Bid. Should the Contractor fail to take the necessary steps to fully accomplish said purposes, after orders of the Engineer, the Engineer may suspend the work in whole or part, until the Contractor takes said steps. As soon as possible under the provisions of the Specifications, the Contractor shall backfill all excavations and restore to usefulness all improvements existing prior to the start of the Work. If Work is suspended through no fault of the Agency, all expenses and losses incurred by the Contractor during such suspensions shall be borne by the Contractor. If the Contractor fails to properly provide for public safety, traffic, and protection of the Work during periods of suspension, the Agency may elect to do so, and deduct the cost thereof from monies due the Contractor. Such actions will not relieve the Contractor from liability. 6-2.1 Order of Work. The work to be done shall consist of furnishing all labor, equipment and materials, and performing all operations necessary to complete the Project Work as shown on the Project Plans and as specified in the Specifications. The work includes the removal of the existing surge tank and the installation of new PULSCO hydro pneumatic surge tank. Removal existing and installation of new air compressor. Work includes reconnection of the new tank and compressor using new gaskets, 316 SS connection hardware and electrical connectors, conductors and hardware as described in the contract plans and specifications. 6-2.2.5 Weekend Work. Weekend work may be performed with consent or direction of the Engineer. 6-2.3 Project Meetings. The Engineer will establish the time and location of weekly Project Meetings. The Contractor’s Representative shall attend each Project Meeting. The Project Representative shall be the individual determined under Section 7-6, “The Contractor’s Representative”. No separate payment for attendance of the Contractor, the Contractor’s Representative or any other employee or subcontractor or subcontractor’s employee at these meetings will be made. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 44 of 63 6-3 SUSPENSION OF WORK. 6-3.1 General. The Work may be suspended in whole or in part when determined by the Engineer that the suspension is necessary in the interest of the Agency. The Contractor shall comply immediately with any written order of the Engineer. Such suspension shall be without liability to the Contractor on the part of the Agency except as otherwise specified in Section 6-6.3. 6-3.2 Archaeological and Paleontological Discoveries. If discovery is made of items of archaeological or paleontological interest, the Contractor shall immediately cease excavation in the area of discovery and shall not continue until ordered by the Engineer. When resumed, excavation operations within the area of discovery shall be as directed by the Engineer. Discoveries which may be encountered may include, but not be limited to, dwelling sites, stone implements or other artifacts, animal bones, human bones, and fossils. The Contractor shall be entitled to an extension of time and compensation in accordance with the provisions of Section 6-6. 6-4 DEFAULT BY CONTRACTOR. If the Contractor fails to begin delivery of material and equipment, to commence the Work within the time specified, to maintain the rate of delivery of material, to execute the Work in the manner and at such locations as specified, or fails to maintain the Work schedule which will insure the Agency’s interest, or, if the Contractor is not carrying out the intent of the Contract, the Agency may serve written notice upon the Contractor and the Surety on its Faithful Performance Bond demanding satisfactory compliance with the Contract. The Contract may be canceled by the Board without liability for damage, when in the Board’s opinion the Contractor is not complying in good faith, has become insolvent, or has assigned or subcontracted any part of the Work without the Board’s consent. In the event of such cancellation, the Contractor will be paid the actual amount due based on Contract Unit Prices or lump sums bid and the quantity of the Work completed at the time of cancellation, less damages caused to the Agency by acts of the Contractor. The Contractor, in having tendered a Bid, shall be deemed to have waived any and all claims for damages because of cancellation of Contract for any such reason. If the Agency declares the Contract canceled for any of the above reasons, written notice to that effect shall be served upon the Surety. The Surety shall, within five (5) days, assume control and perform the Work as successor to the Contractor. If the Surety assumes any part of the Work, it shall take the Contractor’s place in all respects for that part, and shall be paid by the Agency for all work performed by it in accordance with the Contract. If the Surety assumes the entire Contract, all money due the Contractor at the time of its default shall be payable to the Surety as the Work progresses, subject to the terms of the Contract. If the Surety does not assume control and perform the Work within 5 days after receiving notice of cancellation, or fails to continue to comply, the Agency may exclude the Surety from the premises. The Agency may then take possession of all material and equipment and complete the Work by Agency forces, by letting the unfinished Work to another Contractor, or by a combination of such methods. In any event, the cost of completing the Work shall be charged against the Contractor and its Surety and may be deducted from any money due or becoming due from the Agency. If the sums due under the Contract are insufficient for completion, the Contractor or Surety shall pay to the Agency within 5 days after the completion, all costs in excess of the sums due. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 45 of 63 The provisions of this section shall be in addition to all other rights and remedies available to the Agency under law. 6-5 TERMINATION OF CONTRACT. The Board may terminate the Contract at its own discretion or when conditions encountered during the Work make it impossible or impracticable to proceed, or when the Agency is prevented from proceeding with the Contract by act of God, by law, or by official action of a public authority. 6-6 DELAYS AND EXTENSIONS OF TIME. 6-6.1 General. If delays are caused by unforeseen events beyond the control of the Contractor, such delays will entitle the Contractor to an extension of time as provided herein, but the Contractor will not be entitled to damages or additional payment due to such delays, except as provided in 6-6.3. Such unforeseen events may include: war, government regulations, labor disputes, strikes, fires, floods, adverse weather or elements necessitating cessation of work, inability to obtain materials, labor or equipment, required extra work, or other specific events as may be further described in the Specifications. No extension of time will be granted for a delay caused by the Contractor’s inability to obtain materials unless the Contractor furnishes to the Engineer documentary proof. the proof must be provided in a timely manner in accordance with the sequence of the Contractor’s operations and the approved construction schedule. If delays beyond the Contractor’s control are caused by events other than those mentioned above, the Engineer may deem an extension of time to be in the best interests of the Agency. The Contractor will not be entitled to damages or additional payment due to such delays, except as provided in Section 6-6.3. If delays beyond the Contractor’s control are caused solely by action or inaction by the Agency, such delays will entitle the Contractor to an extension of time as provided in Section 6-6.2. 6-6.2 Extensions of Time. Extensions of time, when granted, will be based upon the effect of delays to the Work. They will not be granted for noncontrolling delays to minor portions of the Work unless it can be shown that such delays did or will delay the progress of the Work. 6-6.3 Payment for Delays to Contractor. The Contractor will be compensated for damages incurred due to delays for which the Agency is responsible. Such actual costs will be determined by the Engineer. The Agency will not be liable for damages which the Contractor could have avoided by any reasonable means, such as judicious handling of forces, equipment, or plant. The determination of what damages the Contractor could have avoided will be made by the Engineer. 6-6.4 Written Notice and Report. The Contractor shall provide written notice to the Engineer within two hours of the beginning of any period that the Contractor has placed any workers or equipment on standby for any reason that the Contractor has determined to be caused by the Agency or by any organization that the Agency may otherwise be obligated by. The Contractor shall provide continuing daily written notice to the Engineer, each working day, throughout the duration of such period of delay. The initial and continuing written notices shall include the classification of each workman and supervisor and the make and model of each piece of equipment placed on standby, the cumulative duration of the standby, the Contractor’s opinion of the cause of the delay and a cogent explanation of why the Contractor could not avoid the delay by reasonable means. Should the Contractor fail to provide the notice(s) required by this section the Contractor agrees that no delay has occurred and that it will not submit any claim(s) therefore. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 46 of 63 6-7 TIME OF COMPLETION. 6-7.1 General. The Contractor shall complete the Work within the time set forth in the Contract. The Contractor shall complete each portion of the Work within such time as set forth in the Contract for such portion. The time of completion of the Contract shall be expressed in working days. The Contractor shall diligently prosecute the work to completion within 130 working days after the starting date specified in the Notice to Proceed. 6-7.2 Working Day. A working day is any day within the period between the start of the Contract time as defined in Section 6-1 and the date provided for completion, or upon field acceptance by the Engineer for all work provided for in the Contract, whichever occurs first, other than: 1. Saturday, 2. Sunday, 3. any day designated as a holiday by the Agency, 4. any other day designated as a holiday in a Master Labor Agreement entered into by the Contractor or on behalf of the Contractor as an eligible member of a contractor association, 5. any day the Contractor is prevented from working at the beginning of the workday for cause as defined in Section 6-6.1, 6. any day the Contractor is prevented from working during the first 5 hours with at least 60 percent of the normal work force for cause as defined in Section 6-6.1. Unless otherwise approved in writing by the Engineer, the hours of work shall be between the hours of 7:00 a.m. and 4:00 p.m. on Mondays through Fridays, excluding Agency holidays. The Contractor shall obtain the written approval of the Engineer if the Contractor desires to work outside said hours or at any time during weekends and/or holidays. This written permission must be obtained at least 48 hours prior to such work The Engineer may approve work outside the hours and/or days stated herein when, in his/her sole opinion, such work conducted by the Contractor is beneficial to the best interests of the Agency. The Contractor shall pay the inspection costs of such work. 6-7.3 Contract Time Accounting. The Engineer will make a daily determination of each working day to be charged against the Contract time. These determinations will be discussed and the Contractor will be furnished a periodic statement showing allowable number of working days of Contract time, as adjusted, at the beginning of the reporting period. The statement will also indicate the number of working days charged during the reporting period and the number of working days of Contract time remaining. If the Contractor does not agree with the statement, it shall file a written protest within 15 days after receipt, setting forth the facts of the protest. Otherwise, the statement will be deemed to have been accepted. 6-8 COMPLETION, ACCEPTANCE, AND WARRANTY. The Work will be inspected by the Engineer for acceptance upon receipt of the Contractor’s written assertion that the Work has been completed. The Engineer will not accept the Work or any portion of the Work before all of the Work is completed and all outstanding deficiencies that may exist are corrected by the Contractor and the Engineer is satisfied that all the materials and workmanship, and all other features of the Work, meet the requirements of all of the specifications for the Work. Use, temporary, interim or permanent, of all, or portions of, the Work does not constitute acceptance of the Work. If, in the Engineer’s judgment, the Work has been completed and is ready for acceptance the Engineer will so certify to the Board. Upon such certification by the Engineer the Board may accept the APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 47 of 63 completed Work. Upon the Board’s acceptance of the Work the Engineer will cause a “Notice of Completion” to be filed in the office of the San Diego County Recorder. The date of recordation shall be the date of completion of the Work. All work shall be warranted for one (1) year after recordation of the "Notice of Completion" and any faulty work or materials discovered during the warranty period shall be repaired or replaced by the Contractor, at its expense. Twenty-five percent of the faithful performance bond shall be retained as a warranty bond for the one year warranty period. The Contractor shall replace or repair any such defective work in a manner satisfactory to the Engineer, after notice to do so from the Engineer, and within the time specified in the notice. If the Contractor fails to make such replacement or repairs within the time specified in the notice, the Agency may perform this work and the Contractor’s sureties shall be liable for the cost thereof. 6-9 LIQUIDATED DAMAGES. Failure of the Contractor to complete the Work within the time allowed will result in damages being sustained by the Agency. For each consecutive calendar day in excess of the time specified for completion of Work, as adjusted in accordance with Section 6-6, the Contractor shall pay the Agency, or have withheld monies due it, the sum of five hundred Dollars ($500.00). Such sum is liquidated damages and shall not be construed as a penalty and may be deducted from payments due the Contractor if such delay occurs. Execution of the Contract shall constitute agreement by the Agency and Contractor that five hundred per day is the minimum value of costs and actual damages caused by the Contractor to complete the Work within the allotted time. Any progress payments made after the specified completion date shall not constitute a waiver of this paragraph or of any damages. 6-10 USE OF IMPROVEMENT DURING CONSTRUCTION. The Agency reserves the right to take over and utilize all or part of any completed facility or appurtenance. The Contractor will be notified in writing in advance of such action. Such action by the Agency will relieve the Contractor of responsibility for injury or damage to said completed portions of the improvement resulting from use by public traffic or from the action of the elements or from any other cause, except Contractor operations or negligence. The Contractor will not be required to reclean such portions of the improvement before field acceptance, except for cleanup made necessary by its operations. Nothing in this section shall be construed as relieving the Contractor from full responsibility for correcting defective work or materials. In the event the Agency exercises its right to place into service and utilize all or part of any completed facility or appurtenance, the Agency will assume the responsibility and liability for injury to persons or property resulting from the utilization of the facility or appurtenance so placed into service, except for any such injury to persons or property caused by any willful or negligent act or omission by the Contractor, Subcontractor, their officers, employees, or agents. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 48 of 63 SECTION 7 – RESPONSIBILITIES OF THE CONTRACTOR 7-1 CONTRACTOR’S EQUIPMENT AND FACILITIES. The Contractor shall furnish and maintain in good condition all equipment and facilities as required for the proper execution and inspection of the Work. Such equipment and facilities shall meet all requirements of applicable ordinances and laws. 7-2 LABOR. 7-2.1 General. Only competent workers shall be employed on the Work. Any person employed who is found to be incompetent, intemperate, troublesome, disorderly, or otherwise objectionable, or who fails or refuses to perform work properly and acceptably, shall be immediately removed from the Work by the Contractor and not be reemployed on the Work. 7-2.2 Laws. The Contractor, its agents, and employees shall be bound by and comply with applicable provisions of the Labor Code and Federal, State, and local laws related to labor. The Contractor shall strictly adhere to the provisions of the Labor Code regarding minimum wages; the 8-hour day and 40-hour week; overtime; Saturday, Sunday, and holiday work; and nondiscrimination because of race, color, national origin, sex, or religion. The Contractor shall forfeit to the Agency the penalties prescribed in the Labor Code for violations. In accordance with the Labor Code, the Board has on file and will publish a schedule of prevailing wage rates for the types of work to be done under the Contract. The Contractor shall not pay less than these rates. Each worker shall be paid subsistence and travel as required by the collective bargaining agreement on file with the State of California Department of Industrial Relations. The Contractor’s attention is directed to Section 1776 of the Labor Code which imposes responsibility upon the Contractor for the maintenance, certification, and availability for inspection of such records for all persons employed by the Contractor or Subcontractor in connection with the project. The Contractor shall agree through the Contract to comply with this Section and the remaining provisions of the Labor Code. 7-3 LIABILITY INSURANCE. Insurance shall be required as specified in section 10 of the Public Works Contract. The cost of this insurance shall be included in the Contractor’s Bid. 7-4 WORKERS’ COMPENSATION INSURANCE. Before execution of the Contract by the Board, the Contractor shall file with the Engineer the following signed certification: “I am aware of the provisions of Section 3700 of the Labor Code which require every employer to be insured against liability for workers’ compensation or to undertake self-insurance in accordance with the provisions of that code, and I will comply with such provisions before commencing the performance of the work of this contract.” The Contractor shall also comply with Section 3800 of the Labor Code by securing, paying for, and maintaining in full force and effect for the duration of the contract, complete Workers’ Compensation Insurance, and shall furnish a Certificate of Insurance to the Engineer before APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 49 of 63 execution of the Contract. The Agency, its officers, or employees, will not be responsible for any claims in law or equity occasioned by failure of the Contractor to comply with this paragraph. All compensation insurance policies shall bear an endorsement or shall have attached a rider whereby it is provided that, in the event of expiration or proposed cancellation of such policies for any reason whatsoever, the Agency shall be notified by registered mail not less than 30 days before expiration or cancellation is effective. All insurance is to be placed with insurers that are admitted and authorized to conduct business in the state of California and are listed in the official publication of the Department of Insurance of the State of California. Policies issued by the State Compensation Fund meet the requirement for workers' compensation insurance. 7-5 PERMITS. Except as specified herein the Contractor will obtain, at no cost to the Contractor all City of Carlsbad encroachment, right-of-way, grading and building permits necessary to perform work for this contract on Agency property, streets, or other rights-of-way. Contractor shall not begin work until all permits incidental to the work are obtained. The Contractor shall obtain and pay for all permits for the disposal of all materials removed from the project. The cost of said permit(s) shall be included in the price bid for the appropriate bid item and no additional compensation will be allowed therefore. The Contractor shall obtain and pay for all costs incurred for permits necessitated by its operations such as, but not limited to, those permits required for night work, overload, blasting, and demolition. For private contracts, the Contractor shall obtain all permits incidental to the Work or made necessary by its operations, and pay all costs incurred by the permit requirements. The Contractor shall pay all business taxes or license fees that are required for the work. 7-5.1 Resource Agency Permits. (not used) 7-6 THE CONTRACTOR’S REPRESENTATIVE. Before starting work, the Contractor shall designate in writing a representative who shall have complete authority to act for it. An alternative representative may be designated as well. The representative or alternate shall be present at the Work site whenever work is in progress or whenever actions of the elements necessitate its presence to take measures necessary to protect the Work, persons, or property. Any order or communication given to this representative shall be deemed delivered to the Contractor. A joint venture shall designate only one representative and alternate. In the absence of the Contractor or its representative, instructions or directions may be given by the Engineer to the superintendent or person in charge of the specific work to which the order applies. Such order shall be complied with promptly and referred to the Contractor or its representative. In order to communicate with the Agency, the Contractor’s representative, superintendent, or person in charge of specific work shall be able to speak, read, and write the English language. 7-7 COOPERATION AND COLLATERAL WORK. The Contractor shall be responsible for ascertaining the nature and extent of any simultaneous, collateral, and essential work by others. The Agency, its workers and contractors and others, shall have the right to operate within or adjacent to the Work site during the performance of such work. The Agency, the Contractor, and each of such workers, contractors and others, shall coordinate their operations and cooperate to minimize interference. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 50 of 63 The Contractor shall include in its Bid all costs involved as a result of coordinating its work with others. the Contractor will not be entitled to additional compensation from the Agency for damages resulting from such simultaneous, collateral, and essential work. If necessary to avoid or minimize such damage or delay, the Contractor shall redeploy its work force to other parts of the Work. Should the Contractor be delayed by the Agency, and such delay could not have been reasonably foreseen or prevented by the Contractor, the Engineer will determine the extent of the delay, the effect on the project, and any extension of time. 7-7.1 Coordination. The Contractor shall coordinate and cooperate with all the utility companies during the relocation or construction of their lines. The Contractor may be granted a time extension if, in the opinion of the Engineer, a delay is caused by the utility company. No additional compensation will be made to the Contractor for any such delay. 7-8 PROJECT SITE MAINTENANCE. 7-8.1 Cleanup and Dust Control. Throughout all phases of construction, including suspension of work, and until the final acceptance, the Contractor shall keep the site clean and free from rubbish and debris. The Contractor shall also abate dust nuisance by cleaning, sweeping and sprinkling with water, or other means as necessary. The use of water resulting in mud on public streets will not be permitted as a substitute for sweeping or other methods. When required by the Plans or Specifications, the Contractor shall furnish and operate a self-loading motor sweeper with spray nozzles at least once each working day for the purpose of keeping paved areas acceptably clean wherever construction, including restoration, is incomplete. Materials and equipment shall be removed from the site as soon as they are no longer necessary. Before the final inspection, the site shall be cleared of equipment, unused materials, and rubbish so as to present a satisfactory clean and neat appearance. All cleanup costs shall be included in the Contractor’s Bid. Care shall be taken to prevent spillage on haul routes. Any such spillage shall be removed immediately and the area cleaned. Excess excavation material from catch basins or similar structures shall be removed from the site immediately. Sufficient material may remain for use as backfill if permitted by the Specifications. Forms and form lumber shall be removed from the site as soon as practicable after stripping. Failure of the Contractor to comply with the Engineer’s cleanup orders may result in an order to suspend work until the condition is corrected. No additional compensation will be allowed as a result of such suspension. Cleanup and dust control required herein shall also be executed on weekends and other non-working days when needed to preserve the health safety or welfare of the public. The Contractor shall conduct effective cleanup and dust control throughout the duration of the Contract. The Engineer may require increased levels of cleanup and dust control that, in his/her sole discretion, are necessary to preserve the health, safety and welfare of the public. Cleanup and dust control shall be considered incidental to the items of work that they are associated with and no additional payment will be made therefore. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 51 of 63 7-8.2 Air Pollution Control. The Contractor shall not discharge smoke, dust, or any other air contaminants into the atmosphere in such quantity as will violate the regulations of any legally constituted authority. 7-8.3 Vermin Control. At the time of acceptance, structures entirely constructed under the Contract shall be free of rodents, insects, vermin, and pests. Necessary extermination work shall be arranged and paid for by the Contractor as part of the Work within the Contract time, and shall be performed by a licensed exterminator in accordance with requirements of governing authorities. The Contractor shall be liable for injury to persons or property and responsible for the elimination of offensive odors resulting from extermination operations. 7-8.4 Sanitation. The Contractor shall provide and maintain enclosed toilets for the use of employees engaged in the Work. These accommodations shall be maintained in a neat and sanitary condition. They shall also comply with all applicable laws, ordinances, and regulations pertaining to public health and sanitation of dwellings and camps. Wastewater shall not be interrupted. Should the Contractor disrupt existing sewer facilities, sewage shall be conveyed in closed conduits and disposed of in a sanitary sewer system. Sewage shall not be permitted to flow in trenches or be covered by backfill. 7-8.5 Temporary Light, Power, and Water. The Contractor shall furnish, install, maintain, and remove all temporary light, power, and water at its own expense. These include piping, wiring, lamps, and other equipment necessary for the Work. The Contractor shall not draw water from any fire hydrant (except to extinguish a fire), without obtaining permission from the water agency concerned. The Contractor shall obtain a construction meter for water used for the construction, plant establishment, maintenance, cleanup, testing and all other work requiring water related to this contract. The Contractor shall contact the appropriate water agency for requirements. The Contractor shall pay all costs of temporary light, power and water including hookup, service, meter and any, and all, other charges, deposits and/or fees therefore. Said costs shall be considered incidental to the items of work that they are associated with and no additional payment will be made therefore. 7-8.6 Water Pollution Control. The Contractor shall exercise every reasonable precaution to protect channels, storm drains, and bodies of water from pollution. It shall conduct and schedule operations so as to minimize or avoid muddying and silting of said channels, drains, and waters. Water pollution control work shall consist of constructing those facilities which may be required to provide prevention, control, and abatement of water pollution. The Contractor shall comply with the California State Water Resources Control Board (SWRCB) Order Number 99-08-DWQ, National Pollutant Discharge Elimination System (NPDES) General Permit Number CAS000002, Waste Discharge Requirements (WDR’s) for Discharges of Stormwater Runoff associated with Construction Activity (General Permit) and subsequent adopted modifications and with all requirements of the Storm Water Pollution Prevention and Monitoring Plans for this project in accordance with these regulations. The Notice of Intent (NOI) shall not be filed for the project. 7-8.7 Drainage Control. The Contractor shall maintain drainage within and through the work areas. Earth dams will not be permitted in paved areas. Temporary dams of sandbags, asphaltic concrete, or other acceptable material will be permitted when necessary. Such dams shall be removed from the site as soon as their use is no longer necessary. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 52 of 63 7-8.8 Noise Control. All internal combustion engines used in the construction shall be equipped with mufflers in good repair when in use on the project with special attention to the City Noise Control Ordinance, Carlsbad Municipal Code Chapter 8.48. 7-9 PROTECTION AND RESTORATION OF EXISTING IMPROVEMENTS. The Contractor shall be responsible for the protection of public and private property adjacent to the Work and shall exercise due caution to avoid damage to such property. The Contractor shall repair or replace all existing improvements within the right-of-way which are not designated for removal (e.g., curbs, sidewalks, driveways, fences, walls, signs, utility installations, pavement, structures, etc.) which are damaged or removed as a result of its operations. When a portion of a sprinkler system within the right-of-way must be removed, the remaining lines shall be capped. Repairs and replacements shall be at least equal to existing improvements and shall match them in finish and dimension. Maintenance of street and traffic signal systems that are damaged, temporarily removed or relocated shall be done in conformance with 307-1.5. Trees, lawns, and shrubbery that are not to be removed shall be protected from damage or injury. If damaged or removed due to Contractor’s operations, they shall be restored or replaced in as nearly the original condition and location as is reasonably possible. Lawns shall be reseeded and covered with suitable mulch. The Contractor shall give reasonable notice to occupants or owners of adjacent property to permit them to salvage or relocate plants, trees, fences, sprinklers, and other improvements, within the right-of-way which are designated for removal and would be destroyed because of the Work. All costs to the Contractor for protecting, removing, and restoring existing improvements shall be included in the Bid. 7-10 PUBLIC CONVENIENCE AND SAFETY. 7-10.1 Traffic and Access. The Contractor’s operations shall cause no unnecessary inconvenience. The access rights of the public shall be considered at all times. Unless otherwise authorized, traffic shall be permitted to pass through the Work, or an approved detour shall be provided. Safe and adequate pedestrian and vehicular access shall be provided and maintained to: fire hydrants; commercial and industrial establishments; churches, schools and parking lots; service stations and motels; hospitals; police and fire stations; and establishments of similar nature. Access to these facilities shall be continuous and unobstructed unless otherwise approved by the Engineer. Safe and adequate pedestrian zones and public transportation stops, as well as pedestrian crossings of the Work at intervals not exceeding 90 m (300 feet), shall be maintained unless otherwise approved by the Engineer. Vehicular access to residential driveways shall be maintained to the property line except when necessary construction precludes such access for reasonable periods of time. If backfill has been completed to the extent that safe access may be provided, and the street is opened to local traffic, the Contractor shall immediately clear the street and driveways and provide and maintain access. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 53 of 63 The Contractor shall cooperate with the various parties involved in the delivery of mail and the collection and removal of trash and garbage to maintain existing schedules for these services. Grading operations, roadway excavation and fill construction shall be conducted by the Contractor in a manner to provide a reasonably satisfactory surface for traffic. When rough grading is completed, the roadbed surface shall be brought to a smooth, even condition satisfactory for traffic. Unless otherwise authorized, work shall be performed in only one-half the roadway at one time. One half shall be kept open and unobstructed until the opposite side is ready for use. If one-half a street only is being improved, the other half shall be conditioned and maintained as a detour. The Contractor shall schedule the work so as to prevent damage by all traffic, including but not limited to mail delivery. The Contractor shall not schedule work so as to conflict with trash pickup. The trash hauling schedule can be obtained by calling the City’s contracted waste disposal company, Coast Waste Management at 929-9417. During overlay operations, the Contractors schedule for overlay application shall be designated to provide residents and business owners whose streets are to be overlaid sufficient paved parking within an 800 foot distance from their homes or businesses. Seventy-two hours prior to the start of any construction in the public right-of-way that affects vehicular traffic and/or parking or pedestrian routes, the Contractor shall give written notification of the impending disruption. For a full street closure, all residences and/or businesses on the affected street or alley shall be notified. For partial street closures, or curb, sidewalk and driveway repairs, the residences and/or businesses directly affected by the work shall be notified. The notification shall be hand delivered and shall state the date and time the work will begin and its anticipated duration. The notification shall list two telephone numbers that may be called to obtain additional information. One number shall be the Contractor’s permanent office or field office and the other number shall be a 24-hour number answered by someone who is knowledgeable about the project. At least one of the phone numbers shall be in the (760) area code. An answering machine shall not be connected to either number. The notification shall also give a brief description of the work and simple instructions to the home or business owner on what they need to do to facilitate the construction. The Contractor shall submit the contents of the notification to the Engineer for approval. Notices shall not be distributed until approved by the Engineer. For residences, the notification shall be pre-cut in a manner that enables it to be affixed to a doorknob without adhesives. It shall be a minimum size of 3-1/2 inches by 8-1/2 inches and shall be brightly colored with contrasting printing. The material shall be equivalent in strength and durability to 65 lb. card stock. The printing on the notice shall be no smaller than 12 point. An example of such notice is provided in Appendix “A”. In addition to the notifications, the contractor shall post no parking signs 72 hours in advance of the work being performed. The no parking signs shall state the date and time of parking restriction for a duration not to exceed the time necessary to complete the work at that location. Failure of the contractor to meet the posted date requires re-posting the no parking signs 72 hours in advance of the rescheduled work. If the work is delayed or rescheduled the no parking signs shall be removed and re-posted 72 hours in advance of the rescheduled work. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 54 of 63 The preparation, materials, printing and distribution of the notifications shall be included in the contract price bid for traffic control and the Contractor will not be entitled to any additional compensation for printing and distributing these notices. The contractor shall replace all street markings and striping damaged by construction activities. The Contractor shall include in its Bid all costs for the above requirements. 7-10.2 Storage of Equipment and Materials in Public Streets. Construction materials shall not be stored in streets, roads, or highways for more than 5 days after unloading. All materials or equipment not installed or used in construction within 5 days after unloading shall be stored elsewhere by the Contractor at its expense unless authorized additional storage time. Construction equipment shall not be stored at the Work site before its actual use on the Work nor for more than 5 days after it is no longer needed. Time necessary for repair or assembly of equipment may be authorized by the Engineer. Excavated material, except that which is to be used as backfill in the adjacent trench, shall not be stored in public streets unless otherwise permitted. After placing backfill, all excess material shall be removed immediately from the site. 7-10.3 Street Closures, Detours, Barricades. The Contractor shall comply with all applicable State, County, and City requirements for closure of streets. The Contractor shall provide barriers, guards, lights, signs, temporary bridges, flagpersons, and watchpersons. The Contractor shall be responsible for compliance with additional public safety requirements which may arise. The Contractor shall furnish and install signs and warning devices and promptly remove them upon completion of the Work. After obtaining the Engineers approval and at least 5 working days before closing, detouring, partially closing or reopening any street, alley or other public thoroughfare the Contractor shall notify the following: 1) The Engineer ............................................................................ (760) 602-2720 2) Carlsbad Fire Department Dispatch .......................................... (760) 931-2197 3) Carlsbad Police Department Dispatch ...................................... (760) 931-2197 4) Carlsbad Traffic Signals Maintenance (extension 2937) ........... (760) 438-2980 5) Carlsbad Traffic Signals Operations.......................................... (760) 602-2752 6) North County Transit District ..................................................... (760) 967-2828 7) Waste Management ................................................................. (760) 929-9400 The Contractor shall comply with their requirements. The Contractor shall obtain the Engineer’s written approval prior to deviating from the requirements of 2) through, and including, 7) above. The Contractor shall obtain the written approval no less than five working days prior to placing any traffic control that affects bus stops. The Contractor shall secure approval, in advance, from authorities concerned for the use of any bridges proposed by it for public use. Temporary bridges shall be clearly posted as to load limit, with signs and posting conforming to current requirements covering “signs” as set forth in the Traffic Manual published by the California Department of Transportation. This manual shall also apply to the street closures, barricades, detours, lights, and other safety devices required. All costs involved shall be included in the Bid. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 55 of 63 Traffic controls shall be in accordance with the plans, The California Manual on Uniform Traffic Control Devices (FHWA MUTCD 2003 Revision 1, as amended for use in California) and these provisions. If any component in the traffic control system is damaged, displaced, or ceases to operate or function as specified, from any cause, during the progress of the work, the Contractor shall immediately repair said component to its original condition or replace said component and shall restore the component to its original location. In the event that the Contractor fails to install and/or maintain barricades or such other traffic signs, markings, delineation or devices as may be required herein, the Engineer may, at his/her sole option, install the traffic signs, markings, delineation or devices and charge the Contractor twenty dollars ($25.00) per day per traffic sign or device, or the actual cost of providing such traffic control facility, whichever is the greater. 7-10.4 Safety. 7-10.4.1 Safety Orders. The Contractor shall have at the Work site, copies or suitable extracts of: Construction Safety Orders, Tunnel Safety Orders and General Industry Safety Orders issued by the State Division of Industrial Safety. The Contractor shall comply with provisions of these and all other applicable laws, ordinances, and regulations. Before excavating any trench 5 feet or more in depth, the Contractor shall submit a detailed plan to the Agency showing the design of shoring, bracing, sloping, or other provisions to be made for the workers’ protection from the hazard of caving ground during the excavation of such trench. If the plan varies from the shoring system standards, the plan shall be prepared by a registered Civil Engineer. No excavation shall start until the Engineer has accepted the plan and the Contractor has obtained a permit from the State Division of Industrial Safety. A copy of the permit shall be submitted to the Engineer. Payment for performing all work necessary to provide safety measures shall be included in the prices bid for other items of work except where separate bid items for excavation safety are provided, or required by law. 7-10.4.2 Use of Explosives. Explosives may be used only when authorized in writing by the Engineer, or as otherwise stated in the Specifications. Explosives shall be handled, used, and stored in accordance with all applicable regulations. The Engineer’s approval of the use of explosives shall not relieve the Contractor from liability for claims caused by blasting operations. 7-10.4.3 Special Hazardous Substances and Processes. Materials that contain hazardous substances or mixtures may be required on the Work. A Material Safety Data Sheet as described in Section 5194 of the California Code of Regulations shall be requested by the Contractor from the manufacturer of any hazardous products used. Material usage shall be accomplished with strict adherence to California Division of Industrial Safety requirements and all manufacturer warnings and application instructions listed on the Material Safety Data Sheet and on the product container label. The Contractor shall notify the Engineer if a specified product cannot be used under safe conditions. 7-10.4.4 Confined Spaces. (a) Confined Space Entry Program. The Contractor shall be responsible for implementing, administering and maintaining a confined space entry program (CSEP) in accordance with Sections 5156, 5157 and 5158, Title 8, CCR. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 56 of 63 Prior to starting the Work, the Contractor shall prepare and submit its comprehensive CSEP to the Engineer. The CSEP shall address all potential physical and environmental hazards and contain procedures for safe entry into confined spaces, including, but not limited to the following: 1. Training of personnel 2. Purging and cleaning the space of materials and residue 3. Potential isolation and control of energy and material inflow 4. Controlled access to the space 5. Atmospheric testing of the space 6. Ventilation of the space 7. Special hazards consideration 8. Personal protective equipment 9. Rescue plan provisions The Contractor’s submittal shall include the names of its personnel, including subcontractor personnel, assigned to the project who will have CSEP responsibilities, their CSEP training, and their specific assignment and responsibility in carrying out the CSEP. (b) Permit-Required Confined Spaces. Entry into permit-required confined spaces as defined in Section 5157, Title 8, CCR may be required as a part of the Work. All manholes, tanks, vaults, pipelines, excavations, or other enclosed or partially enclosed spaces shall be considered permit- required confined spaces until the pre-entry procedures demonstrate otherwise. The Contractor shall implement a permit space program prior to performing any work in a permit-required confined space. A copy of the permit shall be available at all times for review by Contractor and Agency personnel at the Work site. (c) Payment. Payment for implementing, administering, and providing all equipment and personnel to perform the CSEP shall be included in the bid items for which the CSEP is required. 7-10.4.5 Safety and Protection of Workers and Public. The Contractor shall take all necessary precautions for the safety of employees on the work and shall comply with all applicable provisions of Federal, State and Municipal safety laws and building codes to prevent accidents or injury to persons on, about, or adjacent to the premises where the work is being performed. The Contractor shall erect and properly maintain at all times, as required by the conditions and progress of the work, all necessary safeguards for the protection of workers and public and shall use danger signs warning against hazards created by such features of construction as protruding nails, hoists, well holes, and falling materials. 7-11 PATENT FEES OR ROYALTIES. The Contractor shall absorb in its Bid the patent fees or royalties on any patented article or process furnished or used in the Work. The Contractor shall indemnify and hold the Agency harmless from any legal action that may be brought for infringement of patents. 7-12 ADVERTISING. The names, addresses and specialties of Contractors, Subcontractors, architects, or engineers may be displayed on removable signs. The size and location shall be subject to the Engineer’s approval. Commercial advertising matter shall not be attached to or painted on the surfaces of buildings, fences, canopies, or barricades. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 57 of 63 7-13 LAWS TO BE OBSERVED. The Contractor shall keep fully informed of State and National laws and County and Municipal ordinances and regulations which in any manner affect those employed in the Work or the materials used in the Work or in any way affect the conduct of the Work. The Contractor shall at all times observe and comply with such laws, ordinances, and regulations. Municipal ordinances that affect this work include Chapter 11.06. Excavation and Grading. If this notice specifies locations or possible materials, such as borrow pits or gravel beds, for use in the proposed construction project which would be subject to Section 1601 or Section 1603 of the Fish and Game Code, the conditions established pursuant to Section 1601 et seq. of the Fish and Game Code shall become conditions of the contract. 7-14 ANTITRUST CLAIMS. Section 7103.5 of the Public Contract Code provides: “In entering into a public works contract or a subcontract to supply goods, services, or materials pursuant to a public works contract, the contractor or subcontractor offers and agrees to assign to the awarding body all rights, title, and interest in and to all causes of action it may have under Section 4 of the Clayton Act (15 U.S.C. Sec 15) or Cartwright Act (Chapter 2 [commencing with Section 16700] of Part 2 of Division 7 of the Business and Professions Code), arising from purchases of goods, services, or materials pursuant to the public works contract or subcontract. The assignment shall be made and become effective at the time the awarding body tenders final payment to the contractor, without further acknowledgment of the parties.” APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 58 of 63 SECTION 8 – FACILITIES FOR AGENCY PERSONNEL (not used) APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 59 of 63 SECTION 9 – MEASUREMENT AND PAYMENT 9-1 MEASUREMENT OF QUANTITIES FOR UNIT PRICE WORK. 9-1.1 General. Unless otherwise specified, quantities of work shall be determined from measurements or dimensions in horizontal planes. However, linear quantities of pipe, piling, fencing and timber shall be considered as being the true length measured along longitudinal axis. Unless otherwise provided in Specifications, volumetric quantities shall be the product of the mean area of vertical or horizontal sections and the intervening horizontal or vertical dimension. The planimeter shall be considered an instrument of precision adapted to measurement of all areas. 9-1.2 Methods of Measurement. Materials and items of work which are to be paid for on basis of measurement shall be measured in accordance with methods stipulated in the particular sections involved. 9-1.3 Certified Weights. When payment is to be made on the basis of weight, the weighing shall be done on certified platform scales or, when approved by the Engineer, on a completely automated weighing and recording system. The Contractor shall furnish the Engineer with duplicate licensed weighmaster’s certificates showing actual net weights. The Agency will accept the certificates as evidence of weights delivered. 9-1.4 Units of Measurement. The system of measure for this contract shall be the U.S. Standard Measures. 9-2 LUMP SUM WORK. Items for which quantities are indicated “Lump Sum”, “L.S.”, or “Job”, shall be paid for at the price indicated in the Bid. Such payment shall be full compensation for the items of work and all work appurtenant thereto. When required by the Specifications or requested by the Engineer, the Contractor shall submit to the Engineer within 15 days after award of Contract, a detailed schedule in triplicate, to be used only as a basis for determining progress payments on a lump sum contract or designated lump sum bid item. This schedule shall equal the lump sum bid and shall be in such form and sufficiently detailed as to satisfy the Engineer that it correctly represents a reasonable apportionment of the lump sum. 9-3 PAYMENT 9-3.1 General. The quantities listed in the Bid schedule will not govern final payment. Payment to the Contractor will be made only for actual quantities of Contract items constructed in accordance with the Plans and Specifications. Upon completion of construction, if the actual quantities show either an increase or decrease from the quantities given in the Bid schedule, the Contract Unit Prices will prevail subject to the provisions of Section 3-2.2.1. The unit and lump sum prices to be paid shall be full compensation for the items of work and all appurtenant work, including furnishing all materials, labor, equipment, tools, and incidentals. Payment will not be made for materials wasted or disposed of in a manner not called for under the Contract. This includes rejected material not unloaded from vehicles, material rejected after it has been placed, and material placed outside of the Plan lines. No compensation will be allowed for disposing of rejected or excess material. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 60 of 63 Payment for work performed or materials furnished under an Assessment Act Contract will be made as provided in particular proceedings or legislative act under which such contract was awarded. Whenever any portion of the Work is performed by the Agency at the Contractor’s request, the cost thereof shall be charged against the Contractor, and may be deducted from any amount due or becoming due from the Agency. Whenever immediate action is required to prevent injury, death, or property damage, and precautions which are the Contractor’s responsibility have not been taken and are not reasonably expected to be taken, the Agency may, after reasonable attempt to notify the Contractor, cause such precautions to be taken and shall charge the cost thereof against the Contractor, or may deduct such cost from any amount due or becoming due from the Agency. Agency action or inaction under such circumstances shall not be construed as relieving the Contractor or its Surety from liability. Payment shall not relieve the Contractor from its obligations under the Contract; nor shall such payment be construed to be acceptance of any of the Work. Payment shall not be construed as the transfer of ownership of any equipment or materials to the Agency. Responsibility of ownership shall remain with the Contractor who shall be obligated to store any fully or partially completed work or structure for which payment has been made; or replace any materials or equipment required to be provided under the Contract which may be damaged, lost, stolen or otherwise degraded in any way prior to acceptance of the Work, except as provided in Section 6-10. Guarantee periods shall not be affected by any payment but shall commence on the date of recordation of the “Notice of Completion.” If, within the time fixed by law, a properly executed notice to stop payment is filed with the Agency, due to the Contractor’s failure to pay for labor or materials used in the Work, all money due for such labor or materials will be withheld from payment to the Contractor in accordance with applicable laws. At the expiration of 35 days from the date of acceptance of the Work by the Board, or as prescribed by law, the amount deducted from the final estimate and retained by the Agency will be paid to the Contractor except such amounts as are required by law to be withheld by properly executed and filed notices to stop payment, or as may be authorized by the Contract to be further retained. 9-3.2 Partial and Final Payment. The Engineer will, after award of Contract, establish a closure date for the purpose of making monthly progress payments. The Contractor may request in writing that such monthly closure date be changed. The Engineer may approve such request when it is compatible with the Agency’s payment procedure. Each month, the Engineer will make an approximate measurement of the work performed to the closure date as basis for making monthly progress payments. The estimated value will be based on contract unit prices, completed change order work and as provided for in Section 9-2 of these General Provisions. Progress payments shall be made no later than thirty (30) calendar days after the closure date. Five (5) working days following the closure date, the Engineer shall complete the detailed progress pay estimate and submit it to the Contractor for the Contractor’s information. Should the Contractor assert that additional payment is due, the Contractor shall within ten (10) days of receipt of the progress estimate, submit a supplemental payment request to the Engineer with adequate justification supporting the amount of supplemental payment request. Upon receipt of the supplemental payment request, the Engineer shall, as soon as practicable after receipt, APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 61 of 63 determine whether the supplemental payment request is a proper payment request. If the Engineer determines that the supplemental payment request is not proper, then the request shall be returned to the Contractor as soon as practicable, but not later than seven (7) days after receipt. The returned request shall be accompanied by a document setting forth in writing the reasons why the supplemental payment request was not proper. In conformance with Public Contract Code Section 20104.50, the City shall make payments within thirty (30) days after receipt of an undisputed and properly submitted supplemental payment request from the Contractor. If payment of the undisputed supplemental payment request is not made within thirty (30) days after receipt by the Engineer, then the City shall pay interest to the Contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure. From each progress estimate, 10 percent will be deducted and retained by the Agency, and the remainder less the amount of all previous payments will be paid. After 50 percent of the Work has been completed and if progress on the Work is satisfactory, the deduction to be made from remaining progress estimates and from the final estimate may be limited to $500 or 10 percent of the first half of total Contract amount, whichever is greater. No progress payment made to the Contractor or its sureties will constitute a waiver of the liquidated damages under 6-9. As provided in Section 22300 of the California Public Contract Code, the Contractor may substitute securities for any monies withheld by the Agency to ensure performance under the Contract. After final inspection, the Engineer will make a Final Payment Estimate and process a corresponding payment. This estimate will be in writing and shall be for the total amount owed the Contractor as determined by the Engineer and shall be itemized by the contract bid item and change order item with quantities and payment amounts and shall show all deductions made or to be made for prior payments and amounts to be deducted under provisions of the contract. All prior estimates and progress payments shall be subject to correction in the Final Payment Estimate. The Contractor shall have 30 calendar days from receipt of the Final Payment Estimate to make written statement disputing any bid item or change order item quantity or payment amount. The Contractor shall provide all documentation at the time of submitting the statement supporting its position. Should the Contractor fail to submit the statement and supporting documentation within the time specified, the Contractor acknowledges that full and final payment has been made for all contract bid items and change order items. If the Contractor submits a written statement with documentation in the aforementioned time, the Engineer will review the disputed item within 30 calendar days and make any appropriate adjustments on the Final Payment. Remaining disputed quantities or amounts not approved by the Engineer will be subject to resolution as specified in Section 3-5, Disputed Work. The written statement filed by the Contractor shall be in sufficient detail to enable the Engineer to ascertain the basis and amount of said disputed items. The Engineer will consider the merits of the Contractor’s claims. It will be the responsibility of the Contractor to furnish within a reasonable time such further information and details as may be required by the Engineer to determine the facts or contentions involved in its claims. Failure to submit such information and details will be sufficient cause for denying payment for the disputed items. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 62 of 63 9-3.2.1 Payment for Claims. Except for those final payment items disputed in the written statement required in Section 9-3.2 all claims of any dollar amount shall be submitted in a written statement by the Contractor no later than the date of receipt of the final payment estimate. Those final payment items disputed in the written statement required in Section 9-3.2 shall be submitted no later than 30 days after receipt of the Final Payment estimate. No claim will be considered that was not included in this written statement, nor will any claim be allowed for which written notice or protest is required under any provision of this contract including Sections 3-4 Changed Conditions, 3-5 Disputed Work, 6-6.3 Payment for Delays to Contractor, 6-6.4 Written Notice and Report, or 6-7.3 Contract Time Accounting, unless the Contractor has complied with notice or protest requirements. The claims filed by the Contractor shall be in sufficient detail to enable the Engineer to ascertain the basis and amount of said claims. The Engineer will consider and determine the Contractor’s claims and it will be the responsibility of the Contractor to furnish within a reasonable time such further information and details as may be required by the Engineer to determine the facts or contentions involved in its claims. Failure to submit such information and details will be sufficient cause for denying the claims. Payment for claims shall be processed within 30 calendar days of their resolution for those claims approved by the Engineer. The Contractor shall proceed with informal dispute resolution under Section 3-5, Disputed Work, for those claims remaining in dispute. 9-3.3 Delivered Materials. When provided for in the Specifications, and subject to the limitation and conditions therein, the cost of materials and equipment delivered but not incorporated into the Work will be included in the progress estimate. 9-3.3.1 Delivered Materials. The cost of materials and equipment delivered but not incorporated into the work will not be included in the progress estimate. 9-3.4 Mobilization. When a bid item is included in the Proposal form for mobilization and subject to the conditions and limitations in the Specifications, the costs of work in advance of construction operations and not directly attributable to any specific bid item will be included in the progress estimate. When no such bid item is provided, payment for such costs will be considered to be included in the other items of work. 9-3.4.1 Mobilization and Preparatory Work. Payment for mobilization and preparatory Work will be included in the various items of work and no other payment will be made. 9-4 JOB QUOTE ITEMS. Payment for each Bid Item shall be made at the quantity and type as listed in the Contractor's Proposal. All work shown or mentioned on the plans, in the Contract Documents, General Provisions, or Technical Provisions/Specifications shall be considered as included in the Bid Items. Contractor must protect existing utilities, improvements, landscaping, irrigation systems, and vegetation in place. If damaged during the work, Contractor is responsible to repair or replace any utilities, improvements, landscaping, irrigation systems, and vegetation at his expense. Furnish Surge Tank System (Item No. 1) Each The contract unit price paid for this bid item shall constitute full compensation to furnish and deliver the surge tank and appurtenances including the air compressor and all necessary components to fully install and operate the surge tank system. This includes all equipment, parts and fittings necessary to interconnect the air compressor system, surge tank and existing force main. APPENDIX “A” Revised 6/15/17 Contract No. 3840-14 Page 63 of 63 Remove Existing and Install New Surge Tank System (Item No. 2) Lump Sum Remove and dispose of existing surge tank equipment. Install new surge tank system including surge tank and air compressor and all necessary components. Includes full start-up of the system. $33(1',;% SECTION 01010 SCOPE OF WORK APPENDIX “B” June 2019 GENERAL SCOPE OF WORK North Batiquitos Lift Station Hydropneumatic Surge Tank Replacement Contract No. 3840-14 01010-Page 1 of 4 SECTION 01010 GENERAL SCOPE OF WORK AND PROCEDURES OF CONSTRUCTION FOR NORTH BATIQUITOS LIFT STATION HYDROPNEUMATIC SURGE TANK REPLACEMENT PART 1--GENERAL 1.1 WORK REQUIRED UNDER CONTRACT DOCUMENTS A. The work generally includes, but is not limited to, furnishing products, labor, tools, transportation, and service to construct complete the following: Remove the existing hydropneumatics surge tank and air compressor system and replace it with a system equivalent to the original equipment including necessary modifications to meet current operational and installation regulations. The system will be supplied and installed providing a fully functioning turnkey product including all accessories. Existing system will be disposed of by the Contractor. 1.2 PROJECT LOCATION A. The North Batiquitos Wastewater Lift Station is located at 7382 Gabbiano Lane in the southwestern quadrant of Carlsbad, California. The site is adjacent to a walking trail on the north shore of the Batiquitos Lagoon. PART 2—PRODUCTS A. General: Surge Analysis and Sizing: Sizing of the tank and air compressor shall be based on the existing system O&M records and record drawings. B. Hydropneumatic Surge Tank: • Tank material shall be all 316 SS. • Designed, manufactured, hydro-tested and stamped per ASME PV&B Code Sec. VII, Div. 1. Hydrotest pressure is 1.3 times of MAWP. • MAWP: 150 psig @ 120 deg. F. Corrosion allowance:0 • One (1) 8” ANSI B16.5 Class 150 flanged connections (316 SS) for water inlet and outlet. Include dissimilar metal installation components to prevent dielectric action at connections. • One (1) 1” NPT drain connection (316 SS). • As required (estimated. quantity of six ½” NPT), SA-182-316 SS, 3000# couplings. • Four (4) support legs (316 SS), 18”” high from bottom flange face to baseplates. Two lifting lugs. • Manway: One (1) 12” x 16” elliptical (316 SS). • Internal and external finish: None. Interior and exterior 316 stainless steel surfaces to have a hot finish clean of weld splatter and debris with no grinding, no polishing or passivation. APPENDIX “B” June 2019 GENERAL SCOPE OF WORK North Batiquitos Lift Station Hydropneumatic Surge Tank Replacement Contract No. 3840-14 01010-Page 2 of 4 C. Air Compressor: • One (1) simplex air compressor with own motor starter. • Compressor is air-cooled, oil-lubricated, singe-acting, tow stage reciprocating, with OSHA belt guard. • One (1) 80-gallon ASME air receiver (200 psig MAWP). Receiver is unlined and coated with standard factory paint and color. Includes a pressure gauge and safety valve set to receiver MAWP (i.e. 200 psi). • One (1) NEMA adjustable pressure switch (or transducer) for automatic start/stop control. • One (1) NEMA rated steel enclosure with magnetic motor starter, power on light, 120V control power transformer, ON/OFF switch, and will shut down compressor on over-load, and low-oil. • Compressor is furnished with standard factory coat finish and colors. • Supplied loose for field installation: One (1) automatic condensate drain valve for air receiver, one (1) 316 SS flex connector, and one (1) set of vibration pads. D. Level/Pressure Control System: • One (1) level controller NEMA 4X, PULSCO’s Skypark 750. • One (1) 4-20 mA differential pressure (i.e. level) transmitter. Diaphragm seal(s) included. • One (1) visual level gauge assembly. • Two (2) air-service solenoid valves, ½” NPT. One (1) air service check valves, ½” NPT. • Ten (10) air-service ball valves, ½” to 1” NPT. E. Other System Components: • One (1) ½” NPT safety valve. One (1) pressure gauge, 4” dial. One (1) ½” NPT vent air muffler. PART 3—EXECUTION A. Requirements for Constructions: • Installation shall include all anchoring systems to address seismic design requirements. • Contractor shall provide submittal with PE stamped anchor bolt calculations and layout recommendations. B. Start-Up and Training. • Contractor will provide a manufacturer’s representative for installation assistance, inspection, field testing, functional testing, adjustment, training, and start-up of supplied system and components: one trip, not to exceed two consecutive days. Contractor to demonstrate readiness prior to scheduling visit. C. Drawings and Submittals: • Contactor will provide Fabrication and Installation Drawings, Installation Instructions, Operation and Maintenance Manual in electronic PD format. In addition, a maximum of four hardcopies. APPENDIX “B” June 2019 GENERAL SCOPE OF WORK North Batiquitos Lift Station Hydropneumatic Surge Tank Replacement Contract No. 3840-14 01010-Page 3 of 4 • Submittals shall be provided consistent with the requirements specified in the General Provisions of this Contract. D. Preventative Maintenance Program: • Contractor will provide 5-year maintenance program for the system. This shall include annual inspections of the equipment scheduled with City O&M staff with written inspection report provided after each visit. **END OF SECTION** APPENDIX "C" DRAWING 306-6 ANNOTATED REVISIONS REMOVE EXISTING SURGE TANK SYSTEM AND REPLACE WITH EQUAL. REMOVE EXISTING AND REPLACE SURGE TANK SYSTEM WITH NEW EQUAL SYSTEM EXISTING EQUIPMENT PAD FOR SURGE TANK, SHOP DRAWINGS NOT AVAILABLE FIELD INSPECT FOR DIMENSIONS. REPLACE EXISTING SURGE TANK SYSTEM AND REPLACE WITH EQUAL, INCLUDE ALL PIPE AND ELECTRICAL CONNECTIONS. APPENDIX "D" EXISTING SURGE TANK DOCUMENTS